PART IPRELIMINARY
Citation
1. This Order may be cited as the Leeds Supertram (Land Acquisition and Road Works) Order 2001.
Interpretation
2.—(1) In this order, unless the context otherwise requires—
“the 1965 Act” means the Compulsory Purchase Act 1965();
“the 1991 Act” means the New Roads and Streets Works Act 1991();
“the 1993 Act” means the Leeds Supertram Act 1993();
“the Applications Rules” means the Transport and Works (Applications and Objections Procedure) Rules 1992;
“authorised works” means the works authorised by the 1993 Act and the works authorised by this Order;
“the book of reference” means the book of reference described in rule 7(5) of the Applications Rules certified by the Secretary of State as the book of reference for the purposes of this Order;
“the City” means the City of Leeds;
“the Council” means Leeds City Council;
“the Executive” means the West Yorkshire Passenger Transport Executive;
“highway” and “highway authority” have the same meaning as in the Highways Act 1980();
“the land plans” means the plans described in rule 7(3) of the Applications Rules certified by the Secretary of State as the land plans for the purposes of this Order;
“the limits of deviation” means the limits of deviation for the road works shown on the works plans;
“the limits of land to be acquired” means the limits of land to be acquired shown on the land plans;
“maintain” includes inspect, repair, adjust, alter, remove, reconstruct and replace and “maintenance” shall be construed accordingly;
“the road works” means the works authorised by article 13(1) below;
“the sections” means the sections described in rule 7(2) of the Applications Rules certified by the Secretary of State as the sections for the purposes of this Order;
“street” means a street within the meaning of section 67(1) of the 1992 Act and includes part of a street;
“street authority”, in relation to a street, has the same meaning as in Part III of the 1991 Act;
“the tramway system” has the same meaning as in the 1993 Act (as extended by article 20(1) below);
“the tribunal” means the Lands Tribunal;
“the works plans” means the plans described in rule 7(1)(a) of the Applications Rules certified by the Secretary of State as the works plans for the purposes of this Order.
(2) Where the book of reference, the sections, the land plans or the works plans was or were revised before this Order was made, any reference to it or them in this Order is to the latest version as certified under article 22 below.
(3) References in this Order to rights over land include references to rights to do, or to place and maintain, anything in, on or under land or in the air-space over its surface.
(4) All directions, distances, areas, lengths and points stated in any description of works, powers or lands shall be construed as if the words “or thereabouts” were inserted after each such direction, distance, area, length and point.
PART IIACQUISITION OF LAND
Power to acquire land
3.—(1) Except in relation to the land described in paragraph (2) below, the Executive may acquire compulsorily—
(a)so much of the land in the City shown on the land plans within the limits of land to be acquired and described in the book of reference as may be required for the authorised works; and
(b)without prejudice to the generality of sub-paragraph (a) above, so much of the land in the City specified in columns (1) and (2) of Schedule 1 to this Order (being land shown on the land plans and described in the book of reference) as may be required for the purpose specified in relation to that land in column (3) of that Schedule;
and it may use any land so acquired for those purposes or for any other purposes connected with or ancillary to the tramway system.
(2) The Council may acquire compulsorily so much of the land in the City shown on the land plans numbered 70 and described and so numbered in the book of reference as they may require to make available to the Executive for the purpose of—
(a)the construction of so much of Works Nos 9, 9A and 9B authorised by the 1993 Act as is to be situated on that land and any purpose connected with, or ancillary to, that purpose; and
(b)the provision pursuant to that Act of an interchange terminus, car park and associated facilities.
(3) The provisions of this article shall have effect without prejudice to the powers of the Executive under sections 10(2) and 33 of the 1993 Act, and under any other provisions of that Act permitting land to be entered upon, taken or used without requiring the compulsory acquisition of that land.
(4) In this Part, “ the acquiring authority” means the Council in the case of an acquisition pursuant to paragraph (2) above, and in any other case means the Executive.
Application of Part I of the Compulsory Purchase Act 1965
4.—(1) Part I of the 1965 Act, in so far as not modified by or inconsistent with the provisions of this Order, shall apply to the acquisition of land under this Order—
(a)as it applies to a compulsory purchase to which the Acquisition of Land Act 1981() applies; and
(b)as if this Order were a compulsory purchase order under that Act.
(2) Part I of the 1965 Act, as so applied, shall have effect as if—
(a)section 4 (which provides a time limit for compulsory purchase of land) and paragraph 3(3) of Schedule 3 (which makes provision as to the giving of bonds) were omitted; and
(b)in section 11(1) (which confers power to enter on and to take possession of land subject to a notice to treat on giving not less than 14 days' notice) for the reference to 14 days' notice there were substituted—
(i)in a case where the notice to treat relates only to the acquisition of an easement or other right over the land, a reference to notice of one month; or
(ii)in any other case, a reference to notice of 3 months.
Application of the Compulsory Purchase (Vesting Declarations) Act 1981
5.—(1) The Compulsory Purchase (Vesting Declarations) Act 1981() shall apply as if this Order were a compulsory purchase order.
(2) In its application by virtue of paragraph (1) above, the Compulsory Purchase (Vesting Declarations) Act 1981 shall have effect with the following modifications.
(3) In section 3 (preliminary notices), for subsection (1) there shall be substituted—
“(1) Before making a declaration under section 4 below with respect to any land which is subject to a compulsory purchase order the acquiring authority shall include the particulars specified in subsection (3) below in a notice which is—
(a)given to every person with a relevant interest in the land with respect to which the declaration is to be made (other than a mortgagee who is not in possession), and
(b)published in the London Gazette and in one or more local newspapers circulating in the locality of the authorised works”.
(4) In that section, in subsection (2), for “(1)(b)” there shall be substituted “(1)” and after “given” there shall be inserted “and published”.
(5) In that section, subsections (5) and (6) shall be omitted and at the end there shall be inserted—
“(5) For the purposes of this section, a person has a relevant interest in land if—
(a)he is for the time being entitled to dispose of the fee simple of the land, whether in possession or reversion, or
(b)he holds, or is entitled to the rents and profits of, the land under a lease or agreement, the unexpired term of which exceeds one month.”.
(6) In section 5 (earliest date for execution of declaration) in subsection (1), after “publication” there shall be inserted “in the London Gazette and in one or more local newspapers circulating in the locality of the authorised works”.
(7) In section 7 (constructive notice to treat) in subsection (1)(a), the words “(as modified by section 4 of the Acquisition of Land Act 1981)” shall be omitted.
(8) References to the Compulsory Purchase Act 1965 shall be construed as references to that Act as applied to the acquisition of land under article 4 above.
Powers to acquire new rights
6.—(1) The Executive and the Council may compulsorily acquire such easements or other rights over any land referred to in paragraphs (1) and (2) of article 3 above as may be required for any purpose for which that land may be acquired by them under that article, by creating them as well as by acquiring easements or other rights already in existence.
(2) Subject to section 8 of the 1965 Act (as substituted by paragraph 5 of Schedule 2 to this Order), where the acquiring authority acquires a right over land under paragraph (1) above it shall not be required to acquire a greater interest in the land.
(3) Schedule 2 to this Order shall have effect for the purpose of modifying the enactments relating to compensation and the provisions of the 1965 Act in their application in relation to the compulsory acquisition under this article of a right over land by the creation of a new right.
Disregard of certain interests and improvements
7.—(1) In assessing the compensation (if any) payable to any person on the acquisition from him of any land under this Order, the tribunal shall not take into account—
(a)any interest in land, or
(b)any enhancement of the value of any interest in land by reason of any building erected, works executed or improvement or alteration made on relevant land,
if the tribunal is satisfied that the creation of the interest, the erection of the building, the execution of the works or the making of the improvement or alteration was not reasonably necessary and was undertaken with a view to obtaining compensation or increased compensation.
(2) In paragraph (1) above “relevant land” means the land acquired from the person concerned or any other land with which he is, or was at the time when the building was erected, the works executed or the improvement or alteration made, directly or indirectly concerned.
Acquisition of part of certain properties
8.—(1) This article shall apply instead of section 8(1) of the 1965 Act (as applied by article 4 above) in any case where—
(a)a notice to treat is served on a person (“the owner”) under the 1965 Act (as so applied) in respect of land forming only part of a house, building or factory or of land consisting of a house with a park or garden (“the land subject to the notice to treat”); and
(b)a copy of this article is served on the owner with the notice to treat.
(2) In such a case, the owner may, within the period of 21 days beginning with the day on which the notice were served, serve on the acquiring authority a counter-notice objecting to the sale of the land subject to the notice to treat and stating that he is willing and able to sell the whole (“the land subject to the counter-notice”).
(3) If no such counter-notice is served within that period, the owner shall be required to sell the land subject to the notice to treat.
(4) If such a counter-notice is served within that period, the question whether the owner shall be required to sell only the land subject to the notice to treat shall, unless the acquiring authority agrees to take the land subject to the counter-notice, be referred to the tribunal.
(5) If on such a reference the tribunal determines that the land subject to the notice to treat can be taken—
(a)without material detriment to the remainder of the land subject to the counter-notice, or
(b)in the case of part of land consisting of a house with a park or garden, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house,
the owner shall be required to sell the land subject to the notice to treat.
(6) If on such a reference the tribunal determine that only part of the land subject to the notice to treat can be taken—
(a)without material detriment to the remainder of the land subject to the counter-notice, or
(b)in the case of part of land consisting of a house with a park or garden, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house,
the notice to treat shall be deemed to be a notice to treat for that part.
(7) If on such a reference the tribunal determine that—
(a)the land subject to the notice to treat cannot be taken without material detriment to the remainder of the land subject to the counter-notice, but
(b)the material detriment is confined to a part of the land subject to the counter-notice,
the notice to treat shall be deemed to be a notice to treat for the land to which the material detriment is confined in addition to the land already subject to the notice, whether or not the additional land is land which the acquiring authority is authorised to acquire compulsorily under this Order.
(8) If the acquiring authority agrees to take the land subject to the counter-notice, or if the tribunal determine that—
(a)none of the land subject to the notice to treat can be taken without material detriment to the remainder of the land subject to the counter-notice or, as the case may be, without material detriment to the remainder of the land subject to the counter-notice and without seriously affecting the amenity and convenience of the house, and
(b)that the material detriment is not confined to a part of the land subject to the counter-notice,
the notice to treat shall be deemed to be a notice to treat for the land subject to the counter-notice whether or not the whole of that land is land which the acquiring authority is authorised to acquire compulsorily under this Order.
(9) In any case where by virtue of a determination by the tribunal under this article a notice to treat is deemed to a be a notice to treat for less land or more land than that specified in the notice, the acquiring authority may, within the period of 6 weeks beginning with the day on which the determination is made, withdraw the notice to treat; and if it does so it shall pay the owner compensation for any loss or expense occasioned to him by the giving and withdrawal of the notice, to be determined in case of dispute by the tribunal.
(10) Where the owner is required under this article to sell only part of a house, building or factory or of land consisting of a house with a park or garden, the acquiring authority shall pay him compensation for any loss sustained by him due to the severance of that part in addition to the value of the interest acquired.
Temporary use of land for construction of works
9.—(1) The Executive may, in connection with the carrying out of the authorised works—
(a)enter upon and take temporary possession of the land in the City specified in column (1) of Schedule 3 to this Order for the purpose specified in relation to that land in column (2) of that Schedule relating to the authorised works specified in column (3) of that Schedule;
(b)remove any buildings and vegetation from that land; and
(c)construct temporary works (including the provision of means of access) and buildings on the land.
(2) Not less than 28 days before entering upon and taking temporary possession of land under this article the Executive shall serve notice of the intended entry on the owners and occupiers of the land.
(3) The Executive may not, without the agreement of the owners of the land, remain in possession of any land under this article after the end of the period of one year beginning with the date of completion of the work or works specified in relation to that land in column (3) of Schedule 3 to this Order.
(4) Before giving up possession of land of which temporary possession has been taken under this article, the Executive shall remove all temporary works and restore the land to the reasonable satisfaction of the owners of the land; but the Executive shall not be required to replace a building removed under this article.
(5) The Executive shall pay compensation to the owners and occupiers of land of which temporary possession is taken under this article for any loss or damage arising from the exercise in relation to the land of the powers conferred by this article.
(6) Any dispute as to a person’s entitlement to compensation under paragraph (5) above, or as to the amount of the compensation, shall be determined under Part I of the Land Compensation Act 1961().
(7) Without prejudice to article 25 below, nothing in this article shall affect any liability to pay compensation under section 10(2) of the 1965 Act or under any other enactment in respect of loss or damage arising from the execution of any works, other than loss or damage for which compensation is payable under paragraph (5) above.
(8) The powers of compulsory acquisition of land conferred by this Order shall not apply in relation to any land of which temporary possession may be taken under paragraph (1) above except that the Executive shall not be precluded from acquiring new rights over any part of that land under article 6 above.
(9) Where the Executive takes possession of land under this article, it shall not be required to acquire the land or any interest in it.
(10) In this article “building” includes any structure or other erection.
Extinction or suspension of private rights of way
10.—(1) All private rights of way over land subject to compulsory acquisition under this Order shall be extinguished—
(a)as from the acquisition of the land by the acquiring authority, whether compulsorily or by agreement, or
(b)on the entry on the land by the acquiring authority under section 11(1) of the 1965 Act,
whichever is sooner.
(2) All private rights of way over land of which the Executive takes temporary possession under this Order shall be suspended and unenforceable for as long as the Executive remains in lawful possession of the land.
(3) Any person who suffers loss by the extinguishment or suspension of any private right of way under this article shall be entitled to compensation to be determined, in case of dispute, under Part I of the Land Compensation Act 1961.
(4) This article does not apply in relation to any right of way to which section 271 or 272 of the Town and Country Planning Act 1990() (extinquishment of rights of statutory undertakers etc.) applies.
Time limit for exercise of powers of acquisition
11.—(1) After the end of the period of 5 years beginning with the day on which this Order comes into force—
(a)no notice to treat shall be served under Part I of the 1965 Act as applied to the acquisition of land by article 4 above;
(b)no declaration shall be executed under section 4 of the Compulsory Purchase (Vesting Declarations) Act 1981, as applied by article 5 above.
(2) The powers conferred by article 9 above shall cease at the end of the period referred to in paragraph (1) above, save that nothing in this paragraph shall prevent the Executive remaining in possession of land after the end of that period, if the land was entered and possession of it was taken before the end of that period.
Acquisition: supplementary matters
12.—(1) Parts II and III of Schedule 2 to the Acquisition of Land Act 1981 (exception of minerals from compulsory purchase and regulation of the working of mines or minerals underlying an authorised undertaking) shall have effect in relation to land to which article 3(1) or (2) above applies as if it were comprised in a compulsory purchase order providing for the incorporation with that order of those Parts of that Schedule.
(2) In their application by virtue of paragraph (1) above, Parts II and III of Schedule 2 to the Acquisition of Land Act 1981 shall have effect as if references to the undertaking were references to the undertaking which the Executive is authorised by this Order or the 1993 Act to carry on.
(3) Sections 31 and 32 of the 1993 Act shall apply to an acquisition under this Part as it applies to an acquisition under Part III of the 1993 Act.
(4) Sections 38(4) and 40(9) of the 1993 Act (trial holes) shall apply to the exercise of powers under section 11(3) of the 1965 Act as applied by article 4 above.
(5) Section 39(2) of the 1993 Act (so far as continued in effect by article 23(3) and (4) below) and section 41(2) and (3) of that Act shall apply to an acquisition under this Part as it applies to an acquisition under Part III of the 1993 Act; and section 41(4) shall have effect as if the reference to land acquired, held or used under the 1993 Act included reference to land acquired, held or used under this Order.
PART IIIMATTERS CONCERNING WORKS
Further works
13.—(1) The Executive may, in the lines and situations shown on the works plans and in accordance with the levels shown on the sections, construct and maintain the following works—
Work No. 1: a road for the realignment of Chadwick Street in the City, commencing in Chadwick Street at a point 20 metres east of its junction with Black Bull Street and terminating at a point 121 metres south-east of its commencement; and
Work No. 2: a road for the realignment of Waterloo Street in the City, commencing in Waterloo Street at a point 20 metres east of its junction with Hunslet Road and terminating at a point 109 metres east of its commencement.
(2) In constructing and maintaining the road works, the Executive may—
(a)deviate laterally from the line and situation shown on the works plans within the limits of deviation for that work shown on the works plans;
(b)deviate vertically from the levels shown on the sections to any extent not exceeding 3 metres upwards or downwards.
(3) The Executive may carry out and maintain such of the following works as may be necessary or expedient for the purposes of, in connection with or in consequence of, the construction of the road works, namely—
(a)works for the alteration or demolition of any building or structure,
(b)works to alter the position of apparatus or street furniture, including mains, sewers, drains and cables,
(c)landscaping and other works to mitigate any adverse effects of the construction, maintenance or operation of the road works, and
(d)works for the benefit or protection of premises affected by the road works,
together with such other works (of whatever nature) as may be necessary or expedient as aforementioned.
(4) Works carried out under paragraph (3) above shall be carried out within the limits of land to be acquired.
Further works: supplementary provision
14.—(1) The Executive may permanently stop up all or any of Chadwick Street as existing between points W and X shown on the works plans upon the practical completion of Work No. 1 authorised by article 13(1) above to the reasonable satisfaction of the street authority and its opening for use.
(2) The Executive may permanently stop up all or any of Waterloo Street as existing between points Y and Z shown on the works plans upon the practical completion of Work No. 2 authorised by article 13(1) above to the reasonable satisfaction of the street authority and its opening for use.
(3) For the purposes of the construction of the road works, the Executive may temporarily stop up or alter Waterloo Street, Chadwick Street, Chadwick Street South and Black Bull Street in the City and for any reasonable time—
(a)divert traffic from any of those streets, and
(b)subject to paragraphs (4) and (5) below, prevent all persons from passing along those streets.
(4) The Executive shall provide reasonable access for pedestrians going to or from premises abutting on a street affected by the exercise of the powers conferred by paragraph (3) above if there would otherwise be no such access.
(5) The Executive shall not exercise the powers of paragraph (3) above without the consent of the street authority, such consent not to be unreasonably withheld.
(6) When Work No. 1 or Work No. 2 authorised by article 13(1) above is completed to the reasonable satisfaction of the street authority, unless otherwise agreed the realigned part of the street shall be maintained by and at the expense of the Executive for a period of 12 months from its completion and at the expiry of that period by and at the expense of the street authority.
(7) Nothing in paragraph (6) above shall prejudice the operation of section 87 of the 1991 Act (prospectively maintainable highways); and the Executive shall not by reason of any duty under this article to maintain a street be taken to be the street authority in relation to that street for the purposes of Part III of that Act.
(8) Nothing in paragraph (6) above shall have effect in relation to street works as respects which the provisions of Part III of the 1991 Act apply.
(9) The street authority and the Executive may enter into agreements with respect to the exercise of the powers conferred by article 13 above and this article, and without prejudice to the generality of this paragraph, such an agreement may provide for the street authority to carry out any function under this Part which relates to the street in question, and contain such terms as to payment and otherwise as the parties consider appropriate.
Designation of tramways
15.—(1) Work No. 2 authorised by the 1993 Act may be constructed within the limits of deviation relating to it provided for in the deposited plans for that Act and at the levels permitted by that Act so that any part of it is situated within the carriageway of Chadwick Street or Chadwick Street South in the City.
(2) Work No. 7 authorised by the 1993 Act may be constructed within the limits of deviation relating to it provided for in the deposited plans for that Act and at the levels permitted by that Act so that any part of it between its commencement and chainage 360 metres is situated within the carriageway of Thorpe Lane in the City.
(3) So far as any part of Work No. 2 or Work No. 7 authorised by the 1993 Act is constructed as mentioned in paragraph (1) or (2) above, it shall be treated for the purposes of the 1993 Act as if authorised and designated by that Act as tramway.
(4) If any part of the railways designated as tramway in the 1993 Act is constructed within the limits provided for it in the deposited plans for that Act and at the levels permitted by that Act so that it is not situated in the carriageway or a reserved area between dual carriageways, except in relation to sections 7(7), 16 and 68 of that Act it shall be treated for the purposes of the 1993 Act as if it had not been so designated as tramway; and if part of Work No. 7 authorised by that Act at or about chainage 1240 metres is so constructed, Thorpe Lane shall be treated as if it were specified in Schedule 2 to the 1993 Act.
(5) In paragraphs (1) and (2) above, references to Chadwick Street include reference to that street as it may be realigned under article 13(1) above or pursuant to Work No. 2B authorised by the 1993 Act, and references to Thorpe Lane include reference to that street as it may be realigned pursuant to Work No. 7A authorised by that Act.
(6) In paragraphs (1), (2) and (4) above, “carriageway” includes any part of the carriageway in respect of which works have been carried out under section 7(4) of the 1993 Act.
Stopping up of means of access
16.—(1) The Executive may stop up and discontinue the private means of vehicular access to the premises known as 170 Briggate in the City at point A shown on the land plans, and carry out any incidental operations in the highway for the purpose.
(2) Any person who suffers loss by the stopping up authorised by paragraph (1) above shall be entitled to compensation to be determined, in case of dispute, under Part I of the Land Compensation Act 1961.
Further level crossings in consequence of changes of road layout
17. Where the railways authorised by the 1993 Act cross the highways specified in Schedule 4 to this Order, those highways shall be treated for the purposes of that Act as if they were specified in Schedule 2 to the 1993 Act.
Discharge of water
18.—(1) The Executive may use any watercourse or any public sewer or drain for the drainage of water in connection with the construction or maintenance of the works authorised by article 13 above and for that purpose may within the limits of land to be acquired lay down, take up and alter pipes and may, on any land within those limits, make openings into, and connections with, the watercourse, sewer or drain.
(2) The Executive shall not discharge any water into any watercourse, public sewer or drain except with the consent of the person to which it belongs; and such consent may be given subject to such terms and conditions as the authority may reasonably impose but shall not be unreasonably withheld.
(3) The Executive shall not make any opening into any public sewer or drain except in accordance with plans approved by, and under the superintendence (if provided) of, the authority to which the sewer or drain belongs, but such approval shall not be unreasonably withheld.
(4) The Executive shall not, in the exercise of the powers conferred by this article, damage or interfere with the beds or banks of any watercourse forming part of a main river.
(5) The Executive shall take such steps as are reasonably practicable to secure that any water discharged into a watercourse or public sewer or drain under the powers conferred by this article is as free as may be practicable from gravel, soil or other solid substance or oil or matter in suspension.
(6) This article does not authorise the entry into controlled waters of any matter whose entry or discharge into controlled waters is prohibited by section 85(1), (2) or (3) of the Water Resources Act 1991().
(7) In this article—
(a)“public sewer or drain” means a sewer or drain which belongs to a sewerage undertaker, the Environment Agency or a local authority;
(b)“watercourse” includes all rivers, streams, ditches, drains, cuts, culverts, dykes, sluices, sewers and passages through which water flows except a public sewer or drain; and
(c)other expressions used both in this article and in the Water Resources Act 1991 have the same meaning as in that Act.
Safeguarding works to buildings
19.—(1) Subject to the following provisions of this article the Executive may at its own expense and from time to time carry out such safeguarding works to any building which is within the limits of land to be acquired and which lies within 30 metres of any of the works authorised by article 13 above (“relevant works”), as the Executive considers to be necessary or expedient.
(2) Safeguarding works may be carried out—
(a)at any time before or during the construction in the vicinity of the building of any part of the relevant works, or
(b)after the completion of the construction of that part of the relevant works, at any time up to the end of the period of 5 years beginning with the day on which that part of the relevant works is first opened for use.
(3) For the purpose of determining how the functions under this article are to be exercised the Executive may enter and survey any building falling within paragraph (1) above and any land within the limits of land to be acquired belonging to it.
(4) For the purpose of carrying out safeguarding works under this article to a building the Executive may (subject to paragraphs (5) and (6) below)—
(a)enter the building and any land within the limits of land to be acquired belonging to it, and
(b)where the works cannot be carried out reasonably conveniently without entering land within the limits of land to be acquired adjacent to the building, enter the adjacent land (but not any building erected on it).
(5) Before exercising—
(a)a right under paragraph (1) above to carry out safeguarding works to a building,
(b)a right under paragraph (3) above to enter a building,
(c)a right under paragraph (4)(a) above to enter a building or land, or
(d)a right under paragraph (4)(b) above to enter land,
the Executive shall, except in the case of emergency, serve on the owners and occupiers of the building or land not less than 14 days' notice of its intention to exercise that right and in a case falling within sub-paragraph (a) or (c) above, specifying the safeguarding works proposed to be carried out.
(6) Where notice is served under paragraph (5)(a), (c) or (d) above, the owner or occupier of the building or land concerned may, by serving a counter-notice within the period of 10 days beginning with the day on which the notice is served, require the question whether it is necessary or expedient to carry out the safeguarding works or to enter the building or land to be referred to arbitration under article 28 below.
(7) The Executive shall compensate the owners and occupiers of any building or land in relation to which the powers of this article have been exercised for any loss or damage arising to them by reason of the exercise of those powers.
(8) Where—
(a)safeguarding works are carried out under this article to a building, and
(b)within the period of 5 years beginning with the day on which the part of the relevant works constructed within the vicinity of the building is first opened for use, it appears that the safeguarding works are inadequate to protect the building against damage caused by the construction or operation of that part of the works,
the Executive shall compensate the owners and occupiers of the building for any damage sustained by them.
(9) Without prejudice to article 25 below, nothing in this article shall relieve the Executive from any liability to pay compensation under section 10(2) of the 1965 Act.
(10) Any compensation payable under paragraph (7) or (8) above shall be determined, in case of dispute, under Part I of the Land Compensation Act 1961.
(11) In this article—
(a)“building” includes any structure or erection or any part of a building, structure or erection,
(b)any reference to a building within a specified distance of a work includes—
(i)in the case of a work under the surface of the ground, a reference to any building within the specified distance of the point on the surface below which the work is situated, and
(ii)where a work has not commenced, a reference to a building within the specified distance of the proposed site of the work, and
(c)“safeguarding works”, in relation to a building means—
(i)underpinning, strengthening and any other works the purpose of which is to prevent damage which may be caused to the building by the construction, maintenance or operation of the relevant works, and
(ii)any works the purpose of which is to remedy any damage which has been caused to the building by the construction, maintenance or operation of the relevant works.
Leeds Supertram Act 1993
20.—(1) References to the tramway system in the 1993 Act shall be treated, so far as relevant, as including references to the works authorised by article 13 above.
(2) The works and matters authorised by articles 13, 14 and 19 above shall be treated as authorised by the 1993 Act for the purposes of sections 38 to 42 and 61 of that Act.
Application of New Roads and Street Works Act 1991
21.—(1) The road works shall be treated as major highway works for the purposes of Part III of the 1991 Act.
(2) In Part III of the 1991 Act, references, in relation to major highway works, to the highway authority concerned shall, in relation to works which are major highway works by virtue of paragraph (1) above, be construed as references to the Executive; provided that nothing in this paragraph shall affect the operation of section 39 of the 1993 Act as applied by article 20(2) above.
(3) The provisions of the 1991 Act mentioned in paragraph (4) below and any regulations made, or code of practice issued or approved under, those provisions shall apply (with the necessary modifications) in relation to the stopping up, alteration or diversion of a street by the Executive under the powers conferred by this Part where no street works are executed in that street as they would apply if the stopping up, alteration or diversion were occasioned by street works executed in that street by the Executive.
(4) The provisions of the 1991 Act referred to in paragraph (3) above are—
section 54 (advance notice of certain works),
section 55 (notice of starting date of works),
section 59 (general duty of street authority to co-ordinate works),
section 60 (general duty of undertakers to co-operate),
section 69 (works likely to affect other apparatus in the street),
section 76 (liability for cost of temporary traffic regulations),
section 77 (liability for cost of use of alternative route), and
all such other provisions as apply for the purposes of the provisions mentioned above.
(5) Sections 54 and 55 of the 1991 Act as applied by paragraph (3) above shall have effect as if reference in section 57 of that Act to emergency works were a reference to a stopping up, alteration or diversion (as the case may be) required in a case of emergency.
PART IVMISCELLANEOUS AND GENERAL
Certification of plans etc.
22. The Executive shall, as soon as practicable after the making of this Order, submit copies of the book of reference, the sections, the land plans and the works plans to the Secretary of State for certification that they are, respectively, the book of reference, sections, land plans and works plans referred to in this Order; and a document so certified shall be admissible in any proceedings as evidence of the contents of the document of which it is a copy.
For protection of Railtrack
23.—(1) Schedule 5 to this Order (which includes provisions for the protection of Railtrack) shall have effect.
(2) Section 39 of the 1993 Act, which contains protective provisions for the protection of Railtrack shall cease to have effect with respect to the authorised works or the compulsory acquisition of land for those works.
(3) Subject to paragraph (4) below, nothing in paragraph (2) above shall affect section 39 of the 1993 Act in its application to any land, property or interest of the British Railways Board.
(4) Paragraph (2) of section 39 of the 1993 Act, as continued in effect by paragraph (3) above, shall not apply to the land specified in clause 10(5)(b) of the agreement referred to in paragraph 1(1)(c) of Schedule 6 to this Order.
Agreements and undertakings connected with 1993 Act
24. Schedule 6 to this Order (which relates to certain agreements and undertakings connected with the 1993 Act) shall have effect.
No double recovery
25. Compensation shall not be payable in respect of the same matter both under this Order and under any other enactment, any contract or any rule of law.
Withholding of consent
26. Where it is provided in this Order that any consent or approval is not to be unreasonably withheld, any dispute as to whether it is so unreasonably withheld or as to the conditions subject to which it is given shall be determined by arbitration.
Service of notices
27.—(1) A notice or other document required or authorised to be served for the purposes of this Order may be served by post.
(2) Where the person on whom a notice or other document to be served for the purposes of this Order is a body corporate, the notice or document is duly served if it is served on the secretary or clerk of that body.
(3) For the purposes of section 7 of the Interpretation Act 1978 as it applies for the purposes of this article, the proper address of any person in relation to the service on him of a notice or document under paragraph (1) above is, if he has given an address for service, that address, and otherwise—
(a)in the case of the secretary or clerk of a body corporate, the registered or principal office of that body; and
(b)in any other case, his last known address at the time of service.
(4) Where for the purposes of this Order a notice or other document is required or authorised to be served on a person as having an interest in, or as the occupier of, land and his name or address cannot be ascertained after reasonable inquiry, the notice may be served by—
(a)addressing it to him by name or by the description of “owner”, or as the case may be “occupier”, of the land (describing it); and
(b)either leaving it in the hands of a person who is or appears to be resident or employed on the land or leaving it conspicuously affixed to some building or object on or near the land.
(5) This article shall not be taken to exclude the employment of any method of service not expressly provided for by it.
Arbitration
28. Where under this Order any difference (other than a difference to which the provisions of the 1965 Act apply) is to be determined by or referred to arbitration, then, unless otherwise provided, the difference shall be referred to and settled by a single arbitrator to be agreed between the parties or, failing agreement, to be appointed, on the application of either party (after notice in writing to the other), by the President of the Institution of Civil Engineers.
John Prescott
Secretary of State for the Environment, Transport and the Regions
28th January 2001