Chwilio Deddfwriaeth

The Hornsea Two Offshore Wind Farm Order 2016

 Help about what version

Pa Fersiwn

 Help about advanced features

Nodweddion Uwch

Changes to legislation:

There are outstanding changes not yet made by the legislation.gov.uk editorial team to The Hornsea Two Offshore Wind Farm Order 2016. Any changes that have already been made by the team appear in the content and are referenced with annotations. Help about Changes to Legislation

Close

Changes to Legislation

Revised legislation carried on this site may not be fully up to date. Changes and effects are recorded by our editorial team in lists which can be found in the ‘Changes to Legislation’ area. Where those effects have yet to be applied to the text of the legislation by the editorial team they are also listed alongside the legislation in the affected provisions. Use the ‘more’ link to open the changes and effects relevant to the provision you are viewing.

View outstanding changes

Changes and effects yet to be applied to :

Changes and effects yet to be applied to the whole Instrument associated Parts and Chapters:

Whole provisions yet to be inserted into this Instrument (including any effects on those provisions):

Articles 2 and 6

SCHEDULE 1E+W+SAuthorised project

PART 1E+W+SAuthorised development

1.  The authorised development includes—E+W+S

(a)the nationally significant infrastructure project (as defined in sections 14 and 15 of the 2008 Act) described in paragraph 2; and

(b)the associated development (within the meaning of section 115(2) of the 2008 Act) described in paragraphs 3 and 4.

Commencement Information

I1Sch. 1 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

2.—(1) The nationally significant infrastructure project comprises up to 2 offshore wind generating stations with a combined gross electrical output capacity of up to 1,800 megawatts as follows—E+W+S

Work No. 1A — An offshore wind generating station within the wind farm area comprising—

(a)subject to sub-paragraph (2), up to 300 wind turbine generators fixed to the seabed;

(b)a network of subsea intra-array electrical circuits connecting the structures comprised in Work No. 1A—

(i)with other such structures;

(ii)with any other structure located within the wind farm area; and

(iii)with the network of electrical circuits comprised in Work Nos. 1B, 2A and 2B;

(c)subject to sub-paragraph (3), up to 2 offshore accommodation platforms fixed to the seabed which may be connected to one of the offshore HVAC collector substations or offshore HVDC converter substations within Work No. 2A by an unsupported steel bridge and up to 2 electrical circuits each connecting an accommodation platform to either an offshore HVAC collector substation or to a wind turbine generator in order to power the accommodation platform;

Work No. 1B — An offshore wind generating station within the wind farm area comprising—

(a)subject to sub-paragraph (2), up to 300 wind turbine generators fixed to the seabed;

(b)a network of subsea intra-array electrical circuits connecting the structures comprised in Work No. 1B—

(i)with other such structures;

(ii)with any other structure located within the wind farm area; and

(iii)with the network of electrical circuits comprised in Work Nos. 1A, 2A and 2B;

(c)subject to sub-paragraph (3), up to 2 offshore accommodation platforms fixed to the seabed which may be connected to one of the offshore HVAC collector substations or offshore HVDC converter substations within Work No. 2B by an unsupported steel bridge and up to 2 electrical circuits each connecting an accommodation platform to either an offshore HVAC collector substation or to a wind turbine generator in order to power the accommodation platform.

Co-ordinates for wind farm area (limits of deviation for Work Nos. 1A, 1B, 2A and 2B)—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

(2) The combined total of wind turbine generators constructed within Work Nos. 1A and 1B must not exceed 300.

(3) The combined total of accommodation platforms constructed within Work Nos. 1A and 1B must not exceed 2.

Commencement Information

I2Sch. 1 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

3.—(1) The associated development includes the following Works—E+W+S

Work No. 2A — Subject to sub-paragraph (2), up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

Work No. 2B — Subject to sub-paragraph (2), up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

Work No. 3A — Subject to sub-paragraph (3), in the event that the mode of transmission is HVAC, up to 2 offshore reactive compensation substations fixed to the seabed at latitude point 53° 37′ 54.291″ N and longitude point 0° 55′ 59.731″ E and at latitude point 53° 38′ 9.295″ N and longitude point 0° 55′ 49.576″ E subject to deviation within the limits of deviation for Work Nos. 3A and 3B;

Work No. 3B — Subject to sub-paragraph (3), in the event that the mode of transmission is HVAC, up to 2 offshore reactive compensation substations fixed to the seabed at latitude point 53° 37′ 54.291″ N and longitude point 0° 55′ 59.731″ E and at latitude point 53° 38′ 9.295″ N and longitude point 0° 55′ 49.576″ E subject to deviation within the limits of deviation for Work Nos. 3A and 3B;

Co-ordinates for limits of deviation for Work Nos. 3A and 3B—

PointLatitudeLongitude
153° 38′ 1.918″ N0° 55′ 55.183″ E
253° 38′ 2.362″ N0° 55′ 58.099″ E
353° 38′ 2.438″ N0° 56′ 0.367″ E
453° 38′ 2.185″ N0° 56′ 3.394″ E
553° 38′ 1.735″ N0° 56′ 5.560″ E
653° 38′ 1.074″ N0° 56′ 7.567″ E
753° 37′ 59.900″ N0° 56′ 9.900″ E
853° 37′ 58.446″ N0° 56′ 11.733″ E
953° 37′ 57.216″ N0° 56′ 12.723″ E
1053° 37′ 55.456″ N0° 56′ 13.477″ E
1153° 37′ 54.094″ N0° 56′ 13.597″ E
1253° 37′ 52.296″ N0° 56′ 13.156″ E
1353° 37′ 51.011″ N0° 56′ 12.387″ E
1453° 37′ 49.821″ N0° 56′ 11.266″ E
1553° 37′ 48.441″ N0° 56′ 9.279″ E
1653° 37′ 47.358″ N0° 56′ 6.825″ E
1753° 37′ 46.776″ N0° 56′ 4.750″ E
1853° 37′ 46.409″ N0° 56′ 2.540″ E
1953° 37′ 46.268″ N0° 56′ 0.258″ E
2053° 37′ 46.357″ N0° 55′ 57.969″ E
2153° 37′ 46.828″ N0° 55′ 55.017″ E
2253° 37′ 47.678″ N0° 55′ 52.316″ E
2353° 37′ 48.540″ N0° 55′ 50.538″ E
2453° 37′ 49.567″ N0° 55′ 49.029″ E
2553° 37′ 51.143″ N0° 55′ 47.509″ E
2653° 37′ 52.881″ N0° 55′ 46.618″ E
2753° 37′ 54.238″ N0° 55′ 46.392″ E
2853° 37′ 56.046″ N0° 55′ 46.691″ E
2953° 37′ 57.351″ N0° 55′ 47.359″ E
3053° 37′ 58.570″ N0° 55′ 48.386″ E
3153° 38′ 0.004″ N0° 55′ 50.262″ E
3253° 38′ 1.153″ N0° 55′ 52.630″ E
3353° 38′ 1.792″ N0° 55′ 54.657″ E
3453° 38′ 1.346″ N0° 55′ 51.708″ E
3553° 38′ 1.300″ N0° 55′ 48.665″ E
3653° 38′ 1.657″ N0° 55′ 45.681″ E
3753° 38′ 2.399″ N0° 55′ 42.906″ E
3853° 38′ 3.490″ N0° 55′ 40.477″ E
3953° 38′ 5.257″ N0° 55′ 38.112″ E
4053° 38′ 6.910″ N0° 55′ 36.872″ E
4153° 38′ 8.684″ N0° 55′ 36.281″ E
4253° 38′ 10.939″ N0° 55′ 36.497″ E
4353° 38′ 12.244″ N0° 55′ 37.130″ E
4453° 38′ 13.467″ N0° 55′ 38.122″ E
4553° 38′ 15.233″ N0° 55′ 40.491″ E
4653° 38′ 16.080″ N0° 55′ 42.277″ E
4753° 38′ 16.738″ N0° 55′ 44.277″ E
4853° 38′ 17.187″ N0° 55′ 46.433″ E
4953° 38′ 17.441″ N0° 55′ 49.447″ E
5053° 38′ 17.365″ N0° 55′ 51.746″ E
5153° 38′ 16.908″ N0° 55′ 54.716″ E
5253° 38′ 16.068″ N0° 55′ 57.438″ E
5353° 38′ 15.210″ N0° 55′ 59.234″ E
5453° 38′ 13.812″ N0° 56′ 1.201″ E
5553° 38′ 12.609″ N0° 56′ 2.302″ E
5653° 38′ 10.868″ N0° 56′ 3.211″ E
5753° 38′ 9.507″ N0° 56′ 3.449″ E
5853° 38′ 8.141″ N0° 56′ 3.296″ E
5953° 38′ 6.381″ N0° 56′ 2.496″ E
6053° 38′ 4.772″ N0° 56′ 1.053″ E
6153° 38′ 3.714″ N0° 55′ 59.591″ E
6253° 38′ 2.560″ N0° 55′ 57.217″ E

Work No. 4A — Subject to sub-paragraph (4), a marine connection to the shore within the marine export cable area, including cable and pipeline crossing works which—

(a)if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2A via and connecting with the offshore reactive compensation substations comprised in Work No. 3A; or

(b)if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2A,

and in either case terminating at Work No. 5A;

Work No. 4B — Subject to sub-paragraph (4), a marine connection to the shore within the marine export cable area, including cable and pipeline crossing works which—

(a)if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2B via and connecting with the offshore reactive compensation substation comprised in Work No. 3B; or

(b)if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2B,

and in either case terminating at Work No. 5B;

Principal co-ordinates for marine export cable area (limits of deviation for Work Nos. 4A and 4B) whose full co-ordinates are set out in the offshore works plans—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 46′ 7.286″ N1° 38′ 16.673″ E
2553° 46′ 4.677″ N1° 37′ 22.711″ E
2753° 44′ 47.813″ N1° 28′ 38.495″ E
3253° 44′ 47.743″ N1° 27′ 26.607″ E
3453° 44′ 36.477″ N1° 25′ 23.743″ E
14153° 42′ 30.629″ N1° 15′ 58.654″ E
15253° 42′ 28.182″ N1° 14′ 34.895″ E
26453° 39′ 35.134″ N1° 6′ 29.785″ E
31653° 38′ 17.582″ N1° 2′ 16.928″ E
44753° 36′ 54.624″ N0° 51′ 31.062″ E
44953° 36′ 15.738″ N0° 48′ 52.425″ E
51353° 35′ 21.166″ N0° 43′ 44.242″ E
51553° 31′ 50.425″ N0° 40′ 55.898″ E
51653° 31′ 38.281″ N0° 40′ 8.340″ E
52153° 28′ 36.676″ N0° 20′ 3.846″ E
53253° 31′ 43.122″ N0° 12′ 21.707″ E
53353° 30′ 57.432″ N0° 5′ 59.890″ E
53453° 31′ 11.028″ N0° 5′ 42.539″ E
53553° 30′ 42.954″ N0° 5′ 10.787″ E
53653° 30′ 42.180″ N0° 5′ 9.912″ E
53753° 30′ 46.588″ N0° 4′ 55.345″ E
53853° 30′ 52.245″ N0° 4′ 59.515″ E
53953° 31′ 25.514″ N0° 5′ 24.049″ E
54053° 31′ 29.574″ N0° 5′ 27.043″ E
58053° 32′ 16.976″ N0° 12′ 37.072″ E
76353° 29′ 11.523″ N0° 20′ 5.981″ E
100153° 31′ 28.589″ N0° 35′ 44.348″ E
100253° 32′ 0.855″ N0° 37′ 42.781″ E
100353° 32′ 17.793″ N0° 39′ 31.883″ E
100453° 32′ 35.749″ N0° 39′ 45.737″ E
100553° 33′ 8.117″ N0° 39′ 47.665″ E
100653° 34′ 28.861″ N0° 41′ 27.396″ E
100753° 35′ 42.522″ N0° 42′ 37.802″ E
101053° 36′ 25.571″ N0° 43′ 54.129″ E
108153° 37′ 2.569″ N0° 47′ 31.846″ E
108353° 37′ 30.986″ N0° 49′ 14.023″ E
108653° 37′ 29.991″ N0° 51′ 27.606″ E
108753° 37′ 36.904″ N0° 52′ 22.841″ E
111153° 38′ 45.654″ N0° 57′ 1.237″ E
114353° 39′ 16.652″ N1° 1′ 1.016″ E
114953° 39′ 42.566″ N1° 1′ 40.167″ E
115553° 41′ 20.037″ N1° 6′ 45.836″ E
115753° 42′ 59.843″ N1° 14′ 18.127″ E
116453° 43′ 0.151″ N1° 15′ 37.960″ E
116553° 44′ 0.963″ N1° 20′ 9.157″ E
116653° 49′ 6.492″ N1° 25′ 51.682″ E
116753° 50′ 7.210″ N1° 26′ 59.953″ E

Work No. 5A — A foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4A, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays (Work No. 6A);

Work No. 5B — A foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4B, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays (Work No. 6B);

Onshore

Work No. 6A — Subject to sub-paragraph (5), up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5A and the onshore electrical circuits comprised in Work No. 7A;

Work No. 6B — Subject to sub-paragraph (5), up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5B and the onshore electrical circuits comprised in Work No. 7B;

Work No. 7A — Subject to sub-paragraph (6), a connection consisting of 2 underground transmission electrical circuits and associated electrical circuit ducts if the mode of transmission is HVDC and up to 8 underground transmission electrical circuits and associated electrical circuit ducts if the mode of transmission is HVAC, proceeding from Work No. 6A at co-ordinate—

  • Easting 537725, Northing 402577

to Work No. 8A at co-ordinate—

  • Easting 514946, Northing 419297; and

in the event that Work No. 7A is constructed before Work No. 7B, the electrical circuit ducts associated with the underground transmission electrical circuits comprised in Work No. 7B;

Work No. 7B — Subject to sub-paragraph (6), a connection consisting of 2 underground transmission electrical circuits and associated electrical circuit ducts if the mode of transmission is HVDC and up to 8 underground transmission electrical circuits and associated electrical circuit ducts if the mode of transmission is HVAC, proceeding from Work No. 6B at co-ordinate—

  • Easting 537725, Northing 402577

to Work No. 8B at co-ordinate—

  • Easting 514946, Northing 419297; and

in the event that Work No. 7B is constructed before Work No. 7A, the electrical circuit ducts associated with the underground transmission electrical circuits comprised in Work No. 7A;

Work No. 8A — Subject to sub-paragraph (7), up to 2 electrical transmission stations including up to 2 main buildings abutting an open yard (which may be partitioned with concrete or steel walls or fences containing switchgear, electrical reactors and other electrical equipment) and associated facilities on land adjoining the North Killingholme National Grid substation.

If the electrical circuits comprised in Work Nos. 4A, 5A and 7A are HVDC, the electrical transmission stations will include facilities to convert the current to HVAC;

Work No. 8B — Subject to sub-paragraph (7), up to 2 electrical transmission stations including up to 2 main buildings abutting an open yard (which may be partitioned with concrete or steel walls or fences containing switchgear, electrical reactors and other electrical equipment) and associated facilities on land adjoining the North Killingholme National Grid substation.

If the electrical circuits comprised in Work Nos. 4B, 5B and 7B are HVDC, the electrical transmission stations will include facilities to convert the current to HVAC;

Work No. 9A — Subject to sub-paragraph (8), a connection consisting of up to 2 underground electrical circuits between Work No. 8A and the North Killingholme National Grid substation, including a connection above ground and electrical engineering works within the National Grid substation buildings and compound;

Work No. 9B — Subject to sub-paragraph (8), a connection consisting of up to 2 underground electrical circuits between Work No. 8B and the North Killingholme National Grid substation, including a connection above ground and electrical engineering works within the National Grid substation buildings and compound;

Work No. 10 — Improvements to the verge, highway and private access road running north from Chase Hill Road between the junction with Haven Road in the east and Eastfield Road in the west.

(2) The combined total of offshore HVAC collector substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 6, and the combined total of offshore HVDC converter substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 2.

(3) The combined total of offshore reactive compensation substations constructed in whole or in part within Work Nos. 3A and 3B must not exceed 2.

(4) The combined total of electrical circuits constructed in whole or in part within Work Nos. 4A and 4B must not exceed—

(a)2, in the event that the mode of transmission is HVDC; and

(b)8, in the event that the mode of transmission is HVAC.

(5) The combined total of underground electrical circuit transition joint bays constructed in whole or in part within Work Nos. 6A and 6B must not exceed 8.

(6) The combined total of electrical circuits constructed in whole or in part within Work Nos. 7A and 7B must not exceed—

(a)2, in the event that the mode of transmission is HVDC; and

(b)8, in the event that the mode of transmission is HVAC.

(7) The combined total of electrical transmission stations constructed in whole or in part within Work Nos. 8A and 8B must not exceed 2.

(8) The combined total of electrical circuits constructed in whole or in part within Work Nos. 9A and 9B must not exceed 2.

Commencement Information

I3Sch. 1 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

4.  The associated development includes such further development as may be necessary or expedient in connection with each of the Works within the Order limits and is within the scope of the environmental impact assessment recorded in the environmental statement including—E+W+S

(a)scour protection around the foundations of the offshore structures;

(b)dredging;

(c)cable protection measures such as rock placement and the placement of concrete mattresses and frond mattresses;

(d)the disposal of seabed sediments produced during construction drilling and seabed preparation for the installation of the foundations of the offshore structures or during seabed preparation for cable laying;

(e)works to alter the position of apparatus, including mains, sewers, drains and cables;

(f)works to alter the course of, or otherwise interfere with, non-navigable rivers, streams or watercourses;

(g)landscaping and other works to mitigate any adverse effects of the construction, maintenance or operation of the authorised development;

(h)works for the benefit or protection of land affected by the authorised development;

(i)working sites in connection with the construction of the authorised development;

(j)compensation compounds;

(k)works to secure means of access;

(l)works to construct surface water drainage systems;

(m)in connection with Work Nos. 8A and 8B, private roads and hardstanding for parking;

(n)link or earthing boxes associated with Work Nos. 6A and 6B;

(o)jointing pits (including link or earthing boxes) associated with Work Nos. 7A and 7B;

(p)a temporary haul road and temporary access track, both alongside and used for the purpose of constructing Work Nos. 7A and 7B;

(q)works to enable utility services to be run from Chase Hill Road to Work Nos. 8A and 8B; and

(r)such other works and apparatus, plant and machinery of whatever nature as may be necessary or expedient for the purposes of or in connection with the construction of the authorised development.

Commencement Information

I4Sch. 1 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SAncillary works

Commencement Information

I5Sch. 1 Pt. 2 in force at 7.9.2016, see art. 1(2)

Works and operations within the Order limits comprising—

(a)temporary anchorage of vessels; and

(b)buoys, beacons, fenders and other navigational warning or ship impact protection works.

PART 3E+W+SRequirements

Time limitsE+W+S

1.  The authorised development must be commenced on or before 6th September 2021.

Commencement Information

I6Sch. 1 Pt. 3 para. 1 in force at 7.9.2016, see art. 1(2)

Detailed design parametersE+W+S

2.—(1) No wind turbine generator forming part of Work No. 1A or 1B may—

(a)be more than 151 metres from LAT to the turbine hub;

(b)exceed a height of 276 metres from LAT to the upper tip of the vertical blade;

(c)exceed a rotor diameter of 241.03 metres;

(d)be less than 34.97 metres from LAT to the lowest point of the rotating blade;

(e)be less than 810 metres from the nearest wind turbine generator in all directions.

(2) In this Requirement, references to the location of a wind turbine generator are references to the centre point of the turbine.

(3) No offshore accommodation platform forming part of Work No. 1A or 1B may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(4) No offshore HVAC collector substation forming part of Work No. 2A or 2B may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(5) No offshore HVDC converter substation forming part of Work No. 2A or 2B may—

(a)exceed 110 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 16,200 square metres in area or 180 metres in width.

(6) No offshore reactive compensation substation comprised in Work No. 3A or 3B may—

(a)exceed 64 metres in height above LAT; or

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(7) The diameter of the electrical cables comprising the electrical circuits must not exceed—

(a)within Work Nos. 1A and 1B, 170 millimetres;

(b)within Work Nos. 2A and 2B, 300 millimetres;

(c)within Work Nos. 4A, 4B, 5A and 5B—

(i)190 millimetres, where the mode of transmission is HVDC; and

(ii)300 millimetres, where the mode of transmission is HVAC.

(8) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 1A and 1B must not exceed 685 kilometres.

(9) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 2A and 2B must not exceed 300 kilometres.

(10) The combined total length of the electrical circuits comprised in Work Nos. 4A, 4B, 5A and 5B seaward of MHWS must not exceed 1,200 kilometres.

(11) The combined total area of cable protection for the electrical circuits comprising Work Nos. 1A and 1B must not exceed 1,246,700 square metres.

(12) The combined total area of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 546,000 square metres.

(13) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 2,055,200 square metres.

(14) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 44,800 square metres.

(15) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 1A and 1B must not exceed 712,400 cubic metres.

(16) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 312,000 cubic metres.

(17) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 1,174,400 cubic metres.

(18) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 25,600 cubic metres.

(19) The electrical circuits comprised in Work Nos. 1A, 1B, 2A, 2B, 4A and 4B must be installed by use of, or a combination of, ploughing, trenching, jetting, rock-cutting, dredging, surface laying with post-lay burial and, where ground conditions make burial impracticable, by surface laying.

(20) The electrical circuits comprised in Work Nos. 5A and 5B must be installed by use of, or a combination of, a trenchless technique, ploughing, trenching and jetting, with the exception that, where the electrical circuits comprised in Work Nos. 5A and 5B cross under the existing sea wall, they must be installed using a trenchless technique.

(21) The combined total area in which the underground electrical circuit transition joint bays comprised in Work Nos. 6A and 6B may be contained must not exceed 2,000 square metres, and no underground electrical circuit transition joint bay within that area may individually exceed 25 metres in length or 10 metres in width.

(22) The diameter of the cables within Work Nos. 7A, 7B, 9A and 9B must not exceed 180 millimetres.

(23) No main building forming part of Work No. 8A or 8B may—

(a)where the mode of transmission is HVDC, exceed—

(i)40 metres in height;

(ii)69.5 metres in width;

(iii)135 metres in length; or

(b)where the mode of transmission is HVAC, exceed—

(i)15 metres in height;

(ii)18.5 metres in width;

(iii)82.5 metres in length.

(24) The combined total area of the site of Work Nos. 8A and 8B must not exceed 35,672 square metres, excluding any area of land required for landscaping and mitigation.

(25) The electrical circuits comprised in Work Nos. 7A and 7B must be installed by use of a trenchless technique where crossing under a main river.

(26) The width of the corridor occupied by the connection comprised in Work Nos. 7A and 7B following completion of construction of those works must not exceed 30 metres, except where those works overlap with Work No. 5A, 5B, 6A or 6B in which case the width of the corridor occupied by the connection comprising Work Nos. 7A and 7B must not exceed 150 metres.

Commencement Information

I7Sch. 1 Pt. 3 para. 2 in force at 7.9.2016, see art. 1(2)

Colour and lightingE+W+S

3.  Except as otherwise required by Trinity House under Condition 4 of each of the deemed marine licences, the undertaker must exhibit such lights, with such shape, colour and character as required by the Air Navigation Order 2009(1) or as otherwise directed by the Civil Aviation Authority or the Secretary of State for Defence.

Commencement Information

I8Sch. 1 Pt. 3 para. 3 in force at 7.9.2016, see art. 1(2)

Foundation methodsE+W+S

4.—(1) The undertaker must in fixing to the seabed any structures comprised in Work Nos. 1A, 1B, 2A, 2B, 3A and 3B use one of the following methods—

(a)monopile foundations;

(b)jacket foundations supported by piles; or

(c)gravity base foundations.

(2) The undertaker must not use the monopile foundation method or any other method that includes braced monopiles to fix to the seabed any offshore HVDC converter substation.

(3) The following parameters apply in respect of the foundation methods used to fix wind turbine generators to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 2,827 square metres;

(ii)the number of piles per jacket must not exceed 12;

(iii)the diameter of each pile must not exceed 6 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and scour protection for each individual structure must not exceed 12,596 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 21.1 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 7,543 square metres;

(ii)the seabed levelling diameter must not exceed 78 metres;

(iii)the cone diameter must not exceed 58 metres at its base.

(4) The following parameters apply in respect of the foundation methods used to fix offshore accommodation platforms to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,414 square metres;

(ii)the number of piles must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(5) The following parameters apply in respect of the foundation methods used to fix offshore HVAC collector substations to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,924 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3.5 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 12,723 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(6) The following parameters apply in respect of the foundation methods used to fix offshore HVDC converter substations to the seabed—

(a)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 17,318 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 72;

(iv)the number of piles per jacket must not exceed 18;

(v)the diameter of each pile must not exceed 3.5 metres;

(b)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 50,894 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 32;

(iv)the number of piles per jacket must not exceed 8;

(v)the diameter of each pile must not exceed 15 metres;

(c)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 27,300 square metres;

(ii)the number of pontoons for each individual structure must not exceed 3;

(iii)the pontoons must not exceed 170 metres in length or 35 metres in width.

(7) The following parameters apply in respect of the foundation methods used to fix the offshore reactive compensation substation to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,414 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(8) The combined total volume of scour protection for the wind turbine generators and the offshore accommodation platforms forming part of the authorised development must not exceed 4,761,555 cubic metres.

Commencement Information

I9Sch. 1 Pt. 3 para. 4 in force at 7.9.2016, see art. 1(2)

Archaeology landward of mean low water springsE+W+S

5.—(1) No part of the authorised development landward of MLWS may be commenced within the area of a local planning authority until a written scheme for the investigation of areas of archaeological interest landward of MLWS has been submitted to and approved by the local planning authority.

(2) The scheme must identify areas where field work or a watching brief (or both) are required and the measures to be taken to evaluate, protect, record or preserve any significant archaeological remains that may be found.

(3) Any archaeological works or watching brief must be carried out—

(a)in accordance with the approved scheme;

(b)by a suitably qualified person or body approved by the local planning authority.

(4) Staged reports of the measures taken to evaluate, protect, record or preserve any significant archaeological remains that are found must be submitted to and approved by the local planning authority before the commencement of any works that would affect those remains.

Commencement Information

I10Sch. 1 para. 5 in force at 7.9.2016, see art. 1(2)

Ecological management plan landward of mean low water springsE+W+S

6.—(1) No part of the authorised development landward of MLWS may be commenced within the area of a local planning authority until a ecological management plan relating to the land landward of MLWS based on the outline ecological management plan and reflecting the survey results and ecological mitigation measures included in the environmental statement has been submitted to and approved by the local planning authority in consultation with Natural England, the Environment Agency and, to the extent that the plan relates to the intertidal area, the MMO.

(2) The ecological management plan must include an implementation timetable and must be carried out as approved.

(3) The ecological management plan must be submitted for approval at least 4 months before the intended start of construction unless otherwise agreed by the local planning authority in consultation with Natural England.

Commencement Information

I11Sch. 1 para. 6 in force at 7.9.2016, see art. 1(2)

Code of construction practiceE+W+S

7.—(1) No part of the authorised development landward of MLWS may be commenced within the area of a local planning authority until a code of construction practice relating to the Works landward of MLWS based on the outline code of construction practice has been submitted to and approved by the local planning authority.

(2) Before giving approval in the case of a construction traffic management plan referred to in sub-paragraph (3)(e) and a travel plan referred to in sub-paragraph (3)(l), the local planning authority must consult the highway authority and Highways England.

(3) The code of construction practice must include—

(a)an external lighting scheme for the construction phase;

(b)construction noise and vibration monitoring and management measures;

(c)air quality and dust monitoring and management measures during construction;

(d)a site waste management plan detailing sustainable site waste management measures;

(e)a construction traffic management plan;

(f)measures to prevent and control spillage of oil, chemicals and other potentially harmful liquids;

(g)details of the storage of materials during construction;

(h)measures for the protection of surface and ground water during construction;

(i)a communication plan;

(j)a health and safety plan, including details of how health and safety risks are to be identified and managed during construction;

(k)details of screening and fencing to be installed during construction; and

(l)a travel plan for the construction workforce to include details of—

(i)expected means of travel to and from the construction sites;

(ii)numbers of construction staff, working hours and modal split;

(iii)details of the number of car parking spaces to be provided on sites and if appropriate a car park management plan;

(iv)specification of measures to encourage sustainable travel to and from the construction site for construction staff;

(v)responsibility and timescales for implementing proposed measures;

(vi)targets for vehicle trips and modal splits;

(vii)formal monitoring regime for those targets; and

(viii)details of mess or canteen facilities for staff.

(4) All construction works must be undertaken in accordance with the approved code.

Commencement Information

I12Sch. 1 para. 7 in force at 7.9.2016, see art. 1(2)

Landscape schemeE+W+S

8.—(1) No part of the authorised development landward of MLWS may be commenced within the area of a local planning authority until a landscape scheme has been submitted to and approved by the local planning authority.

(2) The landscape scheme must include the provisions of the outline landscape scheme and management plan, subject to any variation approved by the local planning authority, and, in addition details of—

(a)cultivation, importing of materials and other operations to ensure plant establishment;

(b)proposed finished ground levels;

(c)hard surfacing materials; and

(d)minor structures, refuse or other storage units, signs and lighting.

Commencement Information

I13Sch. 1 para. 8 in force at 7.9.2016, see art. 1(2)

Implementation and maintenance of landscapingE+W+S

9.—(1) Landscape works must be carried out in accordance with the relevant landscape scheme approved under Requirement 8.

(2) Any tree or shrub planted as part of an approved landscape scheme that within a period of 5 years after planting, is removed, dies or becomes, in the opinion of the local planning authority, seriously damaged or diseased, must be replaced in the first available planting season with a specimen of the same species and size as that originally planted, unless alternative timing or a different specimen is otherwise approved by the local planning authority.

Commencement Information

I14Sch. 1 para. 9 in force at 7.9.2016, see art. 1(2)

Offshore decommissioningE+W+S

10.  No part of the authorised development seaward of MLWS may be commenced until a decommissioning programme in compliance with any notice served on the undertaker by the Secretary of State under section 105(2) of the 2004 Act has been submitted to the Secretary of State for approval in relation to that part.

Commencement Information

I15Sch. 1 para. 10 in force at 7.9.2016, see art. 1(2)

Highway accessesE+W+S

11.—(1) No permanent or temporary means of access to a highway to be used by vehicular traffic or any alteration to an existing means of access to a highway used by vehicular traffic may be commenced until details of the design and layout of such works have been submitted to and approved by the local planning authority in consultation with the highway authority.

(2) The highway accesses must be constructed in accordance with the approved details.

Commencement Information

I16Sch. 1 para. 11 in force at 7.9.2016, see art. 1(2)

Contaminated land and groundwater schemeE+W+S

12.—(1) No part of the authorised development within the area of a local planning authority may be commenced until a scheme to deal with the contamination of any land (including groundwater) within the Order limits that is likely to cause significant harm to persons or pollution of controlled waters or the environment has been submitted to, and approved by, the local planning authority in consultation with the Environment Agency and, to the extent that the plan relates to the intertidal area, the MMO.

(2) The scheme must include an investigation and assessment report, prepared by a specialist consultant approved by the local planning authority, to identify the extent of any contamination and the remedial measures to be taken for that stage to render the land fit for its intended purpose, together with a management plan which sets out long-term measures with respect to any contaminants remaining on the site.

(3) No remedial work constituting a material operation (as defined in section 155 of the 2008 Act) in respect of contamination of any land (including groundwater) within the Order limits may be carried out until the scheme has been approved.

(4) In carrying out the works for the authorised development, the undertaker must not conduct trenchless technique operations unless the scheme includes a hydrogeological risk assessment demonstrating that such operations are unlikely to cause an unacceptable risk to groundwater quality.

(5) Remediation must be carried out in accordance with the approved scheme.

(6) In this Requirement, “controlled waters” has the meaning given in Part 3 of the Water Resources Act 1991(2).

Commencement Information

I17Sch. 1 para. 12 in force at 7.9.2016, see art. 1(2)

Surface water drainage schemeE+W+S

13.—(1) No part of any electrical transmission station may be commenced until a detailed surface water drainage scheme based on sustainable drainage principles and an assessment of the hydrological and hydrogeological context of the electrical transmission station has been submitted to and approved by the local planning authority, in consultation with the drainage board concerned within the meaning of section 23 of the Land Drainage Act 1991.

(2) Construction of the electrical transmission station must be carried out in accordance with the approved scheme.

Commencement Information

I18Sch. 1 para. 13 in force at 7.9.2016, see art. 1(2)

Colour and detailed design approval: electrical transmission stationsE+W+S

14.—(1) Unless otherwise agreed by the local planning authority, the electrical transmission stations must be coloured using one or more of the following colours—

(a)bluebell (RAL Code 270 50 30);

(b)lilac (RAL Code 270 60 25);

(c)chalk blue (RAL Code 270 70 20);

(d)Baltic blue (RAL Code 270 80 15);

(e)white lilac (RAL Code 270 85 10);

(f)blue white (RAL Code 270 90 05).

(2) Despite sub-paragraph (1), construction of Work No. 8A must not commence until details of the layout, scale and external appearance of that Work have been submitted to and approved by the local planning authority.

(3) Despite sub-paragraph (1), construction of Work No. 8B must not commence until details of the layout, scale and external appearance of that work have been submitted to and approved by the local planning authority.

(4) The construction of Work Nos. 8A and 8B must be carried out in accordance with the approved details.

Commencement Information

I19Sch. 1 para. 14 in force at 7.9.2016, see art. 1(2)

Access road within plots 45 to 49E+W+S

15.—(1) The undertaker must not use the access road along the crest of the sea defences within the plots numbered 45 to 49 on the land plans during the construction of Work Nos. 4A, 4B, 5A, 5B, 6A and 6B.

(2) Except in an emergency, the access road along the sea defences within the plots numbered 45 to 49 on the land plans must not be used by the undertaker following the construction of Work Nos. 4A, 4B, 5A, 5B, 6A and 6B until a scheme for the protection of the sea defences from use of the access road by the undertaker during the operation and maintenance of the authorised development has been submitted to and approved by the Environment Agency, such approval not to be unreasonably withheld or delayed.

(3) If the Environment Agency fails to notify the undertaker of its decision on whether to give approval within 2 months of receiving the scheme for approval, the Environment Agency is deemed to have given approval.

(4) The use of the access road must be in accordance with the approved scheme.

Commencement Information

I20Sch. 1 para. 15 in force at 7.9.2016, see art. 1(2)

Port traffic management planE+W+S

16.—(1) No part of the authorised development seaward of MLWS (excluding ducting and related works which are an integral part of works landward of MLWS) may be commenced until—

(a)a traffic management plan for the onshore port-related traffic to and from the selected base port or ports for construction or operation (or both) of that part of the authorised development has been submitted to and approved by the relevant planning authority in consultation with the relevant highway authority; or

(b)the relevant planning authority has confirmed, after consultation with the relevant highway authority, that no traffic management plan is required for that part of the authorised development.

(2) All traffic management plans must be implemented as approved at all times specified within the relevant traffic management plan during the construction and operation of the authorised development.

(3) In this Requirement—

“relevant highway authority” means the highway authority in whose area the selected base port is located;

“relevant planning authority” means the local planning authority in whose area the selected base port is located;

“selected base port” means a port situated in England and/or Wales and used by management personnel for the construction or ongoing operational management of the authorised development (or both).

Commencement Information

I21Sch. 1 para. 16 in force at 7.9.2016, see art. 1(2)

Employment and skills planE+W+S

17.—(1) No part of the authorised development may be commenced until an employment and skills plan based on the outline employment and skills plan has been submitted to and approved by North Lincolnshire Council in consultation with North East Lincolnshire Council, East Lindsey District Council and the Humber Local Enterprise Partnership.

(2) The plan must include—

(a)proposals for the provision of information to the Humber Local Enterprise Partnership on the employment and supply chain opportunities associated with the construction, operation and maintenance of the authorised development including details of the core qualifications and skillsets required to access those opportunities;

(b)proposals for local advertising of employment and supply chain opportunities during the construction of the authorised development;

(c)proposals for the undertaker to provide outreach employment presentations during the period of construction of the authorised development at appropriate times and locations; and

(d)proposals for local advertising of employment and supply chain opportunities during the operation of the authorised development.

(3) The approved employment and skills plan must be implemented and maintained during the construction and operation of the authorised development.

(4) In this Requirement, “Humber Local Enterprise Partnership” means the local enterprise partnership established in June 2011 with the objective of promoting and developing the natural economic area surrounding the Humber estuary.

Commencement Information

I22Sch. 1 para. 17 in force at 7.9.2016, see art. 1(2)

Offshore co-operationE+W+S

18.—(1) Before submitting the pre-construction plans and documentation required to be submitted to the MMO for approval under Condition 8 of each of the deemed marine licences, the undertaker in respect of the relevant licence must provide a copy of the plans and documentation to the other undertaker under this Order.

(2) The other undertaker must provide any comments on the plans and documentation to the first undertaker within 14 days of receipt.

(3) Each undertaker must participate in liaison meetings with the other undertaker as requested from time to time by the MMO in writing in advance; and the meetings must be chaired by the MMO and must consider such matters as are determined by the MMO relating to the efficient operation of a deemed marine licence where it has an impact on the efficient operation of any other deemed marine licence.

Commencement Information

I23Sch. 1 para. 18 in force at 7.9.2016, see art. 1(2)

Compensation compoundsE+W+S

19.—(1) The undertaker may exercise the powers conferred by this Order in relation to the compensation compounds shown coloured green on the compensation compounds plan only where—

(a)the undertaker exercises, or intends to exercise, the powers conferred by this Order in relation to the Order land shown hatched green on the compensation compounds plan; and

(b)sub-paragraph (4) applies.

(2) The undertaker may exercise the powers conferred by this Order only in relation to the compensation compound access coloured pink and labelled 14-A1c on the compensation compounds plan only where the undertaker exercises, or intends to exercise, the powers conferred by this Order in relation to the compensation compound shown coloured green and labelled 14-C3 on the compensation compounds plan in accordance with sub-paragraph (1).

(3) Where the undertaker exercises the powers conferred by this Order in relation to—

(a)the compensation compounds shown coloured green on the compensation compounds plan in accordance with sub-paragraph (1); or

(b)the compensation compound access coloured pink and labelled 14-A1c on the compensation compounds plan in accordance with sub-paragraph (2),

those powers may be exercised only for the benefit of the Hornsea Project One undertaker in connection with the carrying out of works authorised by the Hornsea One Offshore Wind Farm Order 2014.

(4) This sub-paragraph applies where—

(a)the carrying out of works authorised by this Order in the Order land shown hatched green on the compensation compounds plan would overlap temporally with the carrying out of works authorised by the Hornsea One Offshore Wind Farm Order 2014 in that land; or

(b)works authorised by this Order in the Order land shown hatched green on the compensation compounds plan are carried out and completed before the works authorised by the Hornsea One Offshore Wind Farm Order 2014 in that land commence.

Commencement Information

I24Sch. 1 para. 19 in force at 7.9.2016, see art. 1(2)

Onshore decommissioning planE+W+S

20.—(1) Within 3 months of the cessation of commercial operation of the connection works, an onshore decommissioning plan must be submitted to the local planning authority for its approval.

(2) The decommissioning plan must be implemented as approved.

Commencement Information

I25Sch. 1 para. 20 in force at 7.9.2016, see art. 1(2)

North Coates airfieldE+W+S

21.  No part of the authorised development may be commenced within half a mile of the perimeter of the North Coates airfield until a plan to secure its safe operation during the construction and operation of the authorised development has been submitted to and approved by the Secretary of State following consultation with the operator of North Coates airfield and the Civil Aviation Authority.

Commencement Information

I26Sch. 1 para. 21 in force at 7.9.2016, see art. 1(2)

Control of noise during operational phaseE+W+S

22.—(1) The combined rating level (LAr,Tr) of the noise emitted during normal operation from the electrical transmission station, converter and associated plant, must not exceed 35 decibels at any residential property that has planning permission on 1st December 2014.

(2) The assessment must be carried out in accordance with BS 4142:2014 “Methods for rating and assessing industrial and commercial sound”(3).

Commencement Information

I27Sch. 1 para. 22 in force at 7.9.2016, see art. 1(2)

Onshore co-operationE+W+S

23.—(1) Before submitting any plan or document required to be submitted for approval under the Requirements, the undertaker in respect of the works to which the plan or document relates must provide a copy of the plan or document to the other undertaker under this Order.

(2) The other undertaker must provide any comments on the plan or document to the first undertaker within 14 days of receipt.

(3) On submission of any plan or document referred to in sub-paragraph (1) for approval, the undertaker in respect of the works to which the plan or document relates must also submit any comments received from the other undertaker under sub-paragraph (2) or a statement confirming that no such comments were received.

(4) Each undertaker must participate in liaison meetings with the other undertaker as requested from time to time by the local planning authority in writing in advance; and the meetings must be chaired by the local planning authority and must consider such matters as are determined by the local planning authority relating to the efficient construction and operation of the Project A works and the shared works above MLWS where they have an impact on the efficient construction and operation of the Project B works and the shared works above MLWS (and vice versa).

Commencement Information

I28Sch. 1 para. 23 in force at 7.9.2016, see art. 1(2)

Intertidal access management planE+W+S

24.—(1) No part of the authorised development within the intertidal area may be commenced until an intertidal access management plan setting out details of the access routes to the intertidal area, the methods for accessing the intertidal area, the expected number of vehicles that will be accessing the intertidal area and the expected number of vehicle trips to the intertidal area required in relation to that part of the authorised development has been submitted to and approved by the local planning authority in consultation with Natural England.

(2) The undertaker must not exercise the power to maintain under article 7 (maintenance of authorised project) in the intertidal area until an intertidal access management plan setting out details of the access routes to the intertidal area, the methods for accessing the intertidal area, the expected number of vehicles that will be accessing the intertidal area and the expected number of vehicle trips to the intertidal area required for such maintenance activities has been submitted to and approved by the local planning authority in consultation with Natural England.

(3) If the local planning authority fails to notify the undertaker of its decision on whether to give approval within 2 months of receiving an intertidal access management plan for approval, the local planning authority is deemed to have given approval.

(4) The intertidal access management plan must be implemented as approved, unless otherwise agreed by the local planning authority.

Commencement Information

I29Sch. 1 para. 24 in force at 7.9.2016, see art. 1(2)

Navigational safety at Saturn, Mimas and Tethys offshore platformsE+W+S

25.—(1) No construction of any wind turbine generator forming part of the authorised development may commence until the Secretary of State, having consulted with the operator, is satisfied that appropriate mitigation will be implemented and maintained for the life of the authorised development.

(2) In this Requirement—

“appropriate mitigation” means measures to mitigate any adverse impacts which the operation of the authorised development will have on the ability of the operator’s radar early warning system to ensure the safety of its Saturn, Mimas and Tethys offshore platforms during the life of the authorised development;

“operator” means ConocoPhillips (U.K.) Limited (company number 00524868) or successor operator of any of the Saturn, Mimas or Tethys offshore platforms;

“radar early warning system” means the radar early warning system used to monitor and track vessels proximate to the operator’s offshore facilities via radio and network links (which is comprised primarily of radars fitted on a number of operator’s offshore platforms and provides a multi-site, multi-sensor integrated marine surveillance system with logistic and emergency response co-ordination facilities).

(3) The undertaker must comply with all obligations contained within the appropriate mitigation for the life of the authorised development.

Commencement Information

I30Sch. 1 para. 25 in force at 7.9.2016, see art. 1(2)

Requirement for written approvalE+W+S

26.  Where the approval, agreement or confirmation of the Secretary of State, the local planning authority or another person is required under a Requirement, that approval, agreement or confirmation must be given in writing.

Commencement Information

I31Sch. 1 para. 26 in force at 7.9.2016, see art. 1(2)

Amendments to approved plans, etc.E+W+S

27.—(1) Where a Requirement requires the authorised development to be carried out in accordance with a plan, scheme, code or details approved by the local planning authority or any other person (the “approved plan”), the approved plan must be taken to include any amendments that may subsequently be approved by the local planning authority or other person.

(2) Any amendments to the approved plan must be in accordance with the principles and assessments set out in the environmental statement; and approval for such amendments may be given only where it has been demonstrated to the satisfaction of the local planning authority or other person that the amendments are unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

(3) Where the approved plan is required to be approved after consultation with another person, any amendments may be approved only after consultation with that person.

Commencement Information

I32Sch. 1 para. 27 in force at 7.9.2016, see art. 1(2)

Article 9

SCHEDULE 2E+W+SStreets subject to street works

Commencement Information

I33Sch. 2 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Streets subject to street works

District of East LindseyPermissive footpath along sea wall
District of East LindseySheep Marsh Lane
District of East LindseyUnnamed highway north of Sheep Marsh Lane providing access to Poplar Piggeries and area to the north
District of East LindseySea Lane
District of East LindseyTetn/19/1 (public footpath)
District of East LindseyNorth Coates Road
District of East LindseyTetn/343/1 (public footpath)
District of East LindseyTetn/12/5 (public footpath)
District of East LindseyTetn/13/5 (public footpath)
District of East LindseyUnnamed highway east of New Delights access
District of East LindseyTetney Lock Road
District of East LindseyHumberston Road (A1031)
District of East LindseyTetn/14/4 (public footpath)
District of East LindseyHolton Road
District of East LindseyHoLC/5/4 (public footpath)
District of East LindseyStation Road, Tetney
District of East LindseyHoLC/4/1 (public footpath)
District of East LindseyLouth Road (A16)
District of East LindseyHigh Street, North Thoresby (B1201)
District of East LindseyStation Road, North Thoresby (B1201)
District of East LindseyHoLC/10/1 (public footpath)
North East LincolnshireBrigsley FP84 (public footpath)
North East LincolnshireBrigsley FP83 (public footpath)
North East LincolnshireWaithe Lane
North East LincolnshireBrigsley BW75 (public bridleway)
North East LincolnshireWaltham Road, Brigsley (B1203)
North East LincolnshireWaltham Road, Barnoldby le Beck (C148)
North East LincolnshireBradley FP95 (public footpath)
North East LincolnshireBradley Road
North East LincolnshireBradley BW93 (public bridleway)
North East LincolnshireLaceby FP95 (public footpath)
North East LincolnshireLaceby BW97 (public bridleway)
North East LincolnshireLaceby FP96 (public footpath)
North East LincolnshireGrimsby Road (A46)
North East LincolnshireAylesby FP103 (public footpath)
North East LincolnshireAylesby FP110 (public footpath)
North East LincolnshireAylesby Road
North East LincolnshireAylesby BW108 (public bridleway)
North East LincolnshireBeech Holt Lane
North East LincolnshireNooking Lane
West Lindsey DistrictWells Road
North East LincolnshireRiby Road (A1173)
North East LincolnshireStallingborough FP26 (public footpath)
North East LincolnshireStallingborough FP24 (public footpath)
North East LincolnshireKeelby Road
North East LincolnshireHabrough FP4 (public footpath)
North East LincolnshireRoxton Road south of A180 between Keelby and Immingham
North East LincolnshireA180(T)
North East LincolnshireStation Road, Habrough (B1210)
North East LincolnshireImmingham Road (B1210)
North East LincolnshireHabrough FP8 (public footpath)
North East LincolnshireHabrough FP7 (public footpath)
North East LincolnshireKillingholme Road/ Habrough Road
North Lincolnshire Council

South Killingholme 94 (public footpath)

FP/SKIL/94

North Lincolnshire CouncilHabrough Road/Faulding Lane
North Lincolnshire Council

South Killingholme 87 (public footpath)

FP/SKIL/87

North Lincolnshire CouncilHabrough Road
North Lincolnshire Council

South Killingholme 88 (public footpath)

FP/SKIL/88

North Lincolnshire CouncilProposed A160 upgrade/realignment (HA Improvement Scheme)
North Lincolnshire CouncilUlceby Road (A160)
North Lincolnshire CouncilUlceby Road access to houses
North Lincolnshire CouncilTop Road
North Lincolnshire CouncilCurrently unconstructed road on route of proposed cable route (part of the A160 improvement works) north of the A160 and west of Top Road (area hatched between points 119 and 120 on the onshore works plan 24)
North Lincolnshire Council

South Killingholme 87 (public footpath)

FP/SKIL/87

North Lincolnshire Council

South Killingholme 85 (public footpath)

FP/SKIL/85

North Lincolnshire CouncilChurch Lane/ Nicholson Road
North Lincolnshire CouncilChase Hill Road
North Lincolnshire CouncilEastfield Road
North Lincolnshire CouncilBrick Lane/Dean Street
North Lincolnshire Council

North Killingholme 86 (public footpath)

FP/NKIL/86

North Lincolnshire Council

North Killingholme 79 (public footpath)

FP/NKIL/79

Article 11

SCHEDULE 3E+W+SStreets to be temporarily stopped up

Commencement Information

I34Sch. 3 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Street to be temporarily stopped up

(3)

Extent of temporary stopping up

District of East LindseyPermissive footpathBetween points F1 and F2 as shown in a dotted black line on sheet 1 of the onshore works plans
District of East LindseyPermissive footpathBetween points F3 and F4 as shown in a dotted black line on sheet 1 of the onshore works plans
District of East LindseyUnnamed highway north of Sheep Marsh Lane providing access to Poplar Piggeries and area to the northBetween points 1 and 2 as shown hatched on sheet 2 of the onshore works plans
District of East LindseyUnnamed highway north of Sheep Marsh Lane providing access to Poplar Piggeries and area to the northBetween points 3 and 4 as shown hatched on sheet 2 of the onshore works plans
District of East LindseyUnnamed highway north of Sheep Marsh Lane providing access to Poplar Piggeries and area to the northBetween points 5 and 6 as shown hatched on sheet 2 of the onshore works plans
District of East LindseySea LaneBetween points 7 and 8 as shown hatched on sheet 2 of the onshore works plans
District of East LindseyFootpath Tetn/19/1Between points F5 and F6 as shown in a dotted black line on sheet 3 of the onshore works plans
District of East LindseyFootpath Tetn/19/1Between points F7 and F8 as shown in a dotted black line on sheet 3 of the onshore works plans
District of East LindseyNorth Coates RoadBetween points 9 and 10 as shown hatched on sheet 4 of the onshore works plans
District of East LindseyFootpath Tetn/13/5Between points F9 and F10 as shown in a dotted black line on sheet 4 of the onshore works plans
District of East LindseyUnnamed highway east of New Delights accessBetween points 11 and 12 as shown hatched on sheet 4 of the onshore works plans
District of East LindseyUnnamed highway east of New Delights accessBetween points 13 and 14 as shown hatched on sheet 4 of the onshore works plans
District of East LindseyUnnamed highway east of New Delights accessBetween points 15 and 16 as shown hatched on Sheet 4 of the onshore works plans
District of East LindseyUnnamed highway east of New Delights accessBetween points 17 and 18 as shown hatched on sheet 5 of the onshore works plans
District of East LindseyUnnamed highway east of New Delights accessBetween points 19 and 20 as shown hatched on sheet 5 of the onshore works plans
District of East LindseyTetney Lock RoadBetween points 21 and 22 as shown hatched on sheet 5 of the onshore works plans
District of East LindseyTetney Lock RoadBetween points 23 and 24 as shown hatched on sheet 5 of the onshore works plans
District of East LindseyHumberston RoadBetween points 25 and 26 as shown hatched on sheet 5 of the onshore works plans
District of East LindseyFootpath Tetn/14/4Between points F11 and F12 as shown in a dotted black line on sheet 6 of the onshore works plans
District of East LindseyHolton RoadBetween points 27 and 28 as shown hatched on sheet 6 of the onshore works plans
District of East LindseyHolton RoadBetween points 121 and 122 as shown hatched on sheet 6 of the onshore works plans
District of East LindseyHolton RoadBetween points 123 and 124 as shown hatched on sheet 6 of the onshore works plans
District of East LindseyFootpath HoLC/5/4Between points F13 and F14 as shown in a dotted black line on sheet 7 of the onshore works plans
District of East LindseyFootpath HoLC/5/4Between points F14 and F15 as shown in a dotted black line on sheet 7 of the onshore works plans
District of East LindseyStation Road, TetneyBetween points 29 and 30 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyStation Road, TetneyBetween points 31 and 32 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyStation Road, TetneyBetween points 33 and 34 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyFootpath HoLC/4/1Between points F16 and F17 as shown in a dotted black line on sheet 7 of the onshore works plans
District of East LindseyLouth Road (A16)Between points 35 and 36 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyLouth Road (A16)Between points 36 and 37 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyLouth Road (A16)Between points 38 and 39 as shown hatched on sheet 7 of the onshore works plans
District of East LindseyFootpath HoLC/10/1Between points F18 and F19 as shown in a dotted black line on sheet 8 of the onshore works plans
North East LincolnshireFootpath FP84Between points F18 and F21 as shown in a dotted black line on sheet 8 of the onshore works plans
North East LincolnshireFootpath FP83Between points F20 and F20.1 as shown in a dotted black line on sheet 8 of the onshore works plans
North East LincolnshireWaithe LaneBetween points 40 and 41 as shown hatched on sheet 8 of the onshore works plans
North East LincolnshireWaithe LaneBetween points 127 and 128 as shown hatched on sheet 9 of the onshore works plans
North East LincolnshireWaithe LaneBetween points 42 and 43 as shown hatched on sheet 9 of the onshore works plans
North East LincolnshireBridleway BW75Between points F22 and F23 as shown in a dotted black line on sheet 9 of the onshore works plans
North East LincolnshireWaltham Road (B1203)Between points 44 and 45 as shown hatched on sheet 9 of the onshore works plans
North East LincolnshireWaltham Road (B1203)Between points 46 and 47 as shown hatched on sheet 9 of the onshore works plans
North East LincolnshireWaltham Road (B1203)Between points 48 and 49 as shown hatched on sheet 9 of the onshore works plans
North East LincolnshireWaltham Road (C148)Between points 50 and 51 as shown hatched on sheet 10 of the onshore works plans
North East LincolnshireBradley RoadBetween points 52 and 53 as shown hatched on sheet 11 of the onshore works plans
North East LincolnshireFootpath FP95Between points F24 and F25 as shown in a dotted black line on sheet 12 of the onshore works plans
North East LincolnshireFootpath FP95Between points F26 and F27 as shown in a dotted black line on sheet 12 of the onshore works plans
North East LincolnshireBradley RoadBetween points 54 and 55 as shown hatched on sheet 12 of the onshore works plans
North East LincolnshireBradley RoadBetween points 56 and 57 as shown hatched on sheet 12 of the onshore works plans
North East LincolnshireBridleway BW93Between points F28 and F29 as shown in a dotted black line on sheet 12 of the onshore works plans
North East LincolnshireFootpath FP95Between points F30 and F31 as shown in a dotted black line on sheet 13 of the onshore works plans
North East LincolnshireBridleway BW97Between points F32 and F33 as shown in a dotted black line on sheet 14 of the onshore works plans
North East LincolnshireFootpath FP96Between points F34 and F35 as shown in a dotted black line on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 58 and 59 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 60 and 61 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 62 and 63 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 64 and 65 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 60 and 65 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireGrimsby Road (A46)Between points 58 and 62 as shown hatched on sheet 14 of the onshore works plans
North East LincolnshireFootpath FP103Between points F36 and F37 as shown in a dotted black line on sheet 15 of the onshore works plans
North East LincolnshireFootpath FP110Between points F38 and F39 as shown in a dotted black line on sheet 15 of the onshore works plans
North East LincolnshireAylesby RoadBetween points 66 and 67 as shown hatched on sheet 15 of the onshore works plans
North East LincolnshireBridleway BW108Between points F40 and F41 as shown in a dotted black line on sheet 15 of the onshore works plans
North East LincolnshireBeech Holt Lane/Nooking LaneBetween points 68 and 69 as shown hatched on sheet 16 of the onshore works plans
West Lindsey DistrictWells RoadBetween points 70 and 71 as shown hatched on sheet 17 of the onshore works plans
North East LincolnshireRiby Road (A1173)Between points 72 and 73 as shown hatched on sheet 18 of the onshore works plans
North East LincolnshireRiby Road (A1173)Between points 74 and 75 as shown hatched on sheet 18 of the onshore works plans
North East LincolnshireFootpath FP26Between points F42 and F43 as shown in a dotted black line on sheet 19 of the onshore works plans
North East LincolnshireKeelby RoadBetween points 76 and 77 as shown hatched on sheet 19 of the onshore works plans
North East LincolnshireKeelby RoadBetween points 78 and 79 as shown hatched on sheet 19 of the onshore works plans
North East LincolnshireRoxton RoadBetween points 80 and 81 as shown hatched on sheet 20 of the onshore works plans
North East LincolnshireRoxton RoadBetween points 82 and 83 as shown hatched on sheet 20 of the onshore works plans
North East LincolnshireStation Road (B1210)Between points 92 and 93 as shown hatched on sheet 22 of the onshore works plans
North East LincolnshireImmingham Road (B1210)Between points 94 and 95 as shown hatched on sheet 23 of the onshore works plans
North East LincolnshireImmingham Road (B1210)Between points 96 and 97 as shown hatched on sheet 23 of the onshore works plans
North East LincolnshireFootpath FP8Between points F44 and F45 as shown in a dotted black line on sheet 23 of the onshore works plans
North East LincolnshireFootpath FP7Between points F46 and F47 as shown in a dotted black line on sheet 23 of the onshore works plans
North East LincolnshireKillingholme Road/ Habrough RoadBetween points 98 and 99 as shown hatched on sheet 23 of the onshore works plans
North Lincolnshire CouncilFootpath 94Between points F48 and F49 as shown in a dotted black line on sheet 24 of the onshore works plans
North Lincolnshire CouncilFaulding LaneBetween points 100 and 101 as shown hatched on sheet 24 of the onshore works plans
North Lincolnshire CouncilFootpath 87Between points F50 and F51 as shown in a dotted black line on sheet 24 of the onshore works plans
North Lincolnshire CouncilFootpath 88Between points F52 and F53 as shown in a dotted black line on sheet 24 of the onshore works plans
North Lincolnshire CouncilHabrough RoadBetween points 102 and 103 as shown hatched on sheet 24 of the onshore works plans
North Lincolnshire CouncilUlceby Road (A160)Between points 104 and 105 as shown hatched on sheet 24 of the onshore works plans
North Lincolnshire CouncilOn cable route – potential future roadBetween points 119 and 120 as shown hatched on sheet 24 of the onshore works plans
North Lincolnshire CouncilTop RoadBetween points 106 and 107 as shown hatched on sheet 25 of the onshore works plans
North Lincolnshire CouncilFootpath 87Between points F54 and F55 as shown in a dotted black line on sheet 25 of the onshore works plans
North Lincolnshire CouncilFootpath 87Between points F56 and F57 as shown in a dotted black line on sheet 25 of the onshore works plans
North Lincolnshire CouncilChurch LaneBetween points 108 and 109 as shown hatched on sheet 25 of the onshore works plans
North Lincolnshire CouncilChurch LaneBetween points 109 and 111 as shown hatched on sheet 25 of the onshore works plans
North Lincolnshire CouncilChase Hill RoadBetween points 112 and 113 as shown hatched on sheet 26 of the onshore works plans
North Lincolnshire CouncilChase Hill RoadBetween points 114 and 115 as shown hatched on sheet 26 of the onshore works plans
North Lincolnshire CouncilBrick LaneBetween points 115 and 116 as shown hatched on sheet 26 and 27 of the onshore works plans
North Lincolnshire CouncilFootpath 86Between points F58 and F59 as shown in a dotted black line on sheet 27 of the onshore works plans
North Lincolnshire CouncilFootpath 79Between points F60 and F61 as shown in a dotted black line on sheet 27 of the onshore works plans
North Lincolnshire CouncilFootpath 86Between points F62 and F65 as shown in a dotted black line on sheet 27 of the onshore works plans
North Lincolnshire CouncilFootpath 86Between points F65 and F64 as shown in a dotted red line on sheet 27 of the onshore works plans
North Lincolnshire CouncilChase Hill RoadBetween points 117 and 118 as shown hatched on sheet 27 of the onshore works plans

Article 12

SCHEDULE 4E+W+SAccess to works

Commencement Information

I35Sch. 4 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Description of Access

District of East LindseyBetween point A1 (north side of Sheep Marsh Lane) shown on sheet 1 of the onshore works plans and Work Nos. 5A, 5B, 6A, 6B, 7A and 7B
District of East LindseyBetween point A2 (unnamed highway north of Sheep Marsh Lane providing access to Poplar Piggeries) shown on sheet 2 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A3 (north side of North Coates Road) shown on sheet 3 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A4 (south side of North Coates Road) shown on sheet 4 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A5 (north side of unnamed highway east of New Delights access) shown on sheet 4 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A51 (north side of Tetney Lock Road east of New Delights access) shown on sheet 4 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A52 (north side of unnamed highway east of New Delights access) shown on sheet 4 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A53 (north side of unnamed highway east of New Delights access) shown on sheet 4 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A6 (north side of Tetney Lock Road west of Cow Marsh Lane) shown on sheet 5 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A7 (south side of unnamed highway east of New Delights access) shown on sheet 5 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A8 (north side of unnamed highway east of New Delights access) shown on sheet 5 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A9 (north side of Tetney Lock Road east of Humberston Road) shown on sheet 5 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A10 (west side of Holton Road) shown on sheet 6 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A11 (south side of Holton Road) shown on sheet 6 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A12 (north side of Station Road) shown on sheet 7 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A13 (north side of Station Road to the west of the dismantled railway line) shown on sheet 7 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A14 (north side of Station Road) shown on sheet 7 of the onshore works plans and Work Nos. 7A and 7B
District of East LindseyBetween point A15 (west side of A16) shown on sheet 8 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A16 (west side of B1203, Waltham Road) shown on sheet 9 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A56 (east side of B1203, Waltham Road) shown on sheet 9 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A17 (south side of C148 Waltham Road) shown on sheet 10 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A18 (north side of C148 Waltham Road) shown on sheet 10 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A20 (west side of Bradley Road north of Waltham) shown on sheet 11 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A21 (west side of Bradley Road south of Netherwood Farm access point) shown on sheet 12 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A22 (west side of Bradley Road Netherwood Farm south access point) shown on sheet 12 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A23 (south-east side of A46 east of Laceby) shown on sheet 14 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A24 (north-west side of A46 east of Laceby) shown on sheet 14 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A25 (south-east side of Aylesby Road) shown on sheet 15 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A26 (north side of Beach Holt Lane/Nooking Lane west of Aylesby) shown on sheet 16 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A57 (north side of Nooking Lane west of Aylesby) shown on sheet 16 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A27 (south-east side of Wells Road) shown on sheet 17 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A28 (north-west side of Wells Road) shown on sheet 17 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A29 (east side of A1173) shown on sheet 18 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A30 (north-west side of A1173 at Stallingborough Grange Farm) shown on sheet 18 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A31 (south-east side of Keelby Road, north of Wood View) shown on sheet 19 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A32 (north-west side of Keelby Road north of Wood View) shown on sheet 19 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A33 (north-west side of Keelby Road north of Wood View) shown on sheet 19 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A34 (south-east side of Roxton Road south of railway) shown on sheet 20 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A35 (east side of Roxton Road north of railway) shown on sheet 20 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A36 (west side of Roxton Road north of railway) shown on sheet 20 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A39 (south-east side of B1210 Station Road south of A180) shown on sheet 22 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A40 (south side of B1210 Immingham Road) shown on sheet 23 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A41 (north side of B1210 Immingham Road) shown on sheet 23 of the onshore works plans and Work Nos. 7A and 7B
North East LincolnshireBetween point A42 (east side of Killingholme Road/Habrough Road, opposite Hill Farm) shown on sheet 23 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A43 (north side of Faulding Lane) shown on sheet 24 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A54 (west side of Habrough Road south of A160) shown on sheet 24 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A55 (east side of Habrough Road) shown on sheet 24 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A44 (residential access road north of A160, west of A160/Habrough Road roundabout) shown on sheet 24 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A45 (north-east side of Top Road) shown on sheet 25 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A46 (south side of Church Lane) shown on sheet 25 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A47 (north side of Church Lane) shown on sheet 25 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A48 (south side of Chase Hill Road west of Eastfield Road) shown on sheet 26 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A49 (north side of Chase Hill Road west of Eastfield Road) shown on sheet 26 of the onshore works plans and Work Nos. 7A and 7B
North LincolnshireBetween point A50 (Brick Lane, north side of Chase Hill Road) shown on sheet 26 of the onshore works plans and Work Nos. 7A and 7B

Articles 19 and 26

SCHEDULE 5E+W+SLand in which only new rights, etc. may be acquired

Commencement Information

I36Sch. 5 in force at 7.9.2016, see art. 1(2)

(1)

Number of land shown on land plans

(2)

Purpose for which rights may be acquired

1, 2, 3, 4, 19, 20, 21, 22, 23, 24, 26, 27, 28To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within an up to 320-metre corridor within the Order land and to obtain access for such purposes
5, 6, 7, 8, 9, 10, 11, 12, 13, 14, 15, 16, 17, 18, 25, 29, 30, 31, 32To ground and lay anchor for vessels within the Order land
509, 510To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within the Order land and to obtain access for such purposes
33, 511To install, maintain and use an access track and to obtain access for such purposes
35To install, retain, maintain and operate transition jointing bays for the connection of offshore cable circuits to onshore cable circuits and apparatus (and to impose requirements for their protection) within an up to 150-metre corridor within the Order land and to obtain access for such purposes
37, 38, 39, 67, 68, 69, 79, 80, 81, 83, 84, 85, 86, 87, 88, 92, 96, 97, 98, 99, 107, 113, 119, 123, 131, 132, 134, 135, 139, 140, 141, 147, 148, 149, 150, 151, 152, 153, 155, 161, 168, 169, 173, 175, 180, 183, 187, 188, 189, 190, 191, 192, 193, 194, 195, 196, 197, 198, 199, 200, 201, 202, 203, 204, 205, 206, 207, 208, 211, 215, 216, 217, 218, 219, 220, 221, 222, 223, 228, 232, 234, 248, 249, 250, 251, 252, 255, 256, 261, 262, 268, 275, 281, 282, 285, 289, 291, 293, 294, 295, 296, 297, 298, 299, 300, 307, 308, 309, 310, 311, 312, 313, 314, 317, 325, 327, 332, 333, 334, 338, 339, 342, 347, 352, 360, 361, 364, 365, 394, 403, 404, 411, 420, 421, 424, 426, 429, 430, 431, 432, 433, 434, 438, 439, 440, 445, 448, 449, 450, 451, 452, 453, 454, 459, 460, 461, 465, 466, 468, 471, 472, 476, 482, 486, 487, 488, 489, 490, 491, 492, 497, 499, 503To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within an up to 30-metre corridor within the Order land and to obtain access for such purposes
45, 46, 47, 48, 49To install, maintain and use an access track and to obtain access for the purposes only of maintaining and operating the authorised project
273To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within an up to 30-metre corridor within the Order land and to obtain access for such purposes but not extending to breaking open the surface of the Order land
388, 437To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within an up to 30-metre corridor within the Order land
507, 519To install, retain, maintain and operate apparatus (and to impose requirements for its protection) within the Order land and to install, maintain and use an access track and to obtain access for such purposes
512, 521To install, retain, maintain and operate services (and to impose requirements for their protection) within the Order land and to install, maintain and use an access road and to obtain access for such purposes

Article 19

SCHEDULE 6E+W+SModification of compensation and compulsory purchase enactments for creation of new rights, etc.

Compensation enactments modifiedE+W+S

1.  The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right and in the case of the imposition of a restrictive covenant as they apply as respects compensation on the compulsory purchase of land and interests in land.

Commencement Information

I37Sch. 6 para. 1 in force at 7.9.2016, see art. 1(2)

Land Compensation Act 1973 modifiedE+W+S

2.—(1) Without limiting paragraph 1, the Land Compensation Act 1973(4) has effect subject to the modifications set out in sub-paragraphs (2) and (3).

(2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 of the 1965 Act as substituted by paragraph 4,—

(a)for “land is acquired or taken from”, substitute “a right or restrictive covenant over land is purchased from or imposed on the land of”; and

(b)for “acquired or taken from him”, substitute “over which the right is exercisable or the restrictive covenant enforceable”.

(3) In section 58(1) (determination of material detriment where part of house etc. proposed for compulsory acquisition), as it applies to determinations under section 8 of the 1965 Act as substituted by paragraph 5,—

(a)for “part” in paragraphs (a) and (b), substitute “a right over or restrictive covenant affecting land consisting”;

(b)for “severance”, substitute “right or restrictive covenant over or affecting the whole of the house, building or manufactory or of the house and the park or garden”;

(c)for “part proposed”, substitute “right or restrictive covenant proposed”; and

(d)for “part is”, substitute “right or restrictive covenant is”.

Commencement Information

I38Sch. 6 para. 2 in force at 7.9.2016, see art. 1(2)

Compulsory Purchase Act 1965 modifiedE+W+S

3.—(1) The 1965 Act has effect with the modifications necessary to make it apply to the compulsory acquisition under this Order of a right by the creation of a new right, or to the imposition under this Order of a restrictive covenant, as it applies to the compulsory acquisition under this Order of land, so that, in appropriate contexts, references in that Act to land must be read (according to the requirements of the particular context) as referring to, or as including references to—

(a)the right acquired or to be acquired or the restrictive covenant imposed or to be imposed; or

(b)the land over which the right is or is to be exercisable or the restrictive covenant is or is to be enforceable.

(2) Without limiting sub-paragraph (1), Part 1 of the 1965 Act applies in relation to the compulsory acquisition under this Order of a right by the creation of a new right, or in relation to the imposition of a restrictive covenant, with the modifications specified in the following provisions of this Schedule.

Commencement Information

I39Sch. 6 para. 3 in force at 7.9.2016, see art. 1(2)

4.  For section 7 of the 1965 Act (measure of compensation in case of severance), substitute the following section—

7.  In assessing the compensation to be paid by the acquiring authority under this Act, regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the restrictive covenant but also to the damage (if any) to be sustained thereby by the owner of the land in relation to other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act..

Commencement Information

I40Sch. 6 para. 4 in force at 7.9.2016, see art. 1(2)

5.  For section 8 of the 1965 Act (other provisions as to divided land), substitute the following section—

8.(1) Where in consequence of the service on a person under section 5 of this Act of a notice to treat in respect of a right over, or a restrictive covenant affecting, land consisting of a house, building or manufactory or of a park or garden belonging to a house (the “relevant land”)—

(a)a question of disputed compensation in respect of the purchase of the right or the imposition of the restrictive covenant would apart from this section fall to be determined by the Upper Tribunal (the “tribunal”); and

(b)before the tribunal has determined that question the tribunal is satisfied that the person has an interest in the whole of the relevant land and is able and willing to sell that interest and—

(i)where that land consists of a house, building or manufactory, that the right cannot be purchased or the restrictive covenant imposed without material detriment to that land; or

(ii)where that land consists of such a park or garden, that the right cannot be purchased or the restrictive covenant imposed without seriously affecting the amenity or convenience of the house to which that land belongs,

the Hornsea Two Offshore Wind Farm Order 2016 (the “Order”), in relation to that person, ceases to authorise the purchase of the right or the imposition of a restrictive covenant and be deemed to authorise the purchase of that person’s interest in the whole of the relevant land including, where the land consists of such a park or garden, the house to which it belongs, and the notice is deemed to have been served in respect of that interest on such date as the tribunal directs.

(2) Any question as to the extent of the land in which the Order is deemed to authorise the purchase of an interest by virtue of subsection (1) must be determined by the tribunal.

(3) Where, in consequence of a determination of the tribunal that it is satisfied as mentioned in subsection (1), the Order is deemed by virtue of that subsection to authorise the purchase of an interest in land, the acquiring authority may, at any time within the period of 6 weeks beginning with the date of the determination, withdraw the notice to treat in consequence of which the determination was made; but nothing in this subsection prejudices any other power of the authority to withdraw the notice..

Commencement Information

I41Sch. 6 para. 5 in force at 7.9.2016, see art. 1(2)

6.  The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

(a)section 9(4) (refusal to convey, failure to make title, etc.);

(b)paragraph 10(3) of Schedule 1 (persons without power to sell their interests);

(c)paragraph 2(3) of Schedule 2 (absent and untraced owners); and

(d)paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are modified so as to secure that, as against persons with interests in the land that are expressed to be overridden by the deed, the right that is to be compulsorily acquired or the restrictive covenant that is to be imposed is vested absolutely in the acquiring authority.

Commencement Information

I42Sch. 6 para. 6 in force at 7.9.2016, see art. 1(2)

7.  Section 11 of the 1965 Act (powers of entry) is modified so as to secure that, as from the date on which the acquiring authority has served notice to treat in respect of any right or restrictive covenant, it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant (which is deemed for this purpose to have been created on the date of service of the notice); and sections 12 (unauthorised entry) and 13 (refusal to give possession to acquiring authority) of the 1965 Act(5) are modified correspondingly.

Commencement Information

I43Sch. 6 para. 7 in force at 7.9.2016, see art. 1(2)

8.  Section 20 of the 1965 Act(6) (tenants at will, etc.) applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.

Commencement Information

I44Sch. 6 para. 8 in force at 7.9.2016, see art. 1(2)

9.  Section 22 of the 1965 Act (interests omitted from purchase) is modified so as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired or to enforce the restrictive covenant imposed, subject to compliance with that section as respects compensation.

Commencement Information

I45Sch. 6 para. 9 in force at 7.9.2016, see art. 1(2)

Article 26

SCHEDULE 7E+W+SLand of which temporary possession may be taken

PART 1E+W+SAuthorised project

Commencement Information

I46Sch. 7 Pt. 1 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Number of land shown on land plans

(3)

Purpose for which temporary possession may be taken

(4)

Relevant part of authorised project

In the County of Lincolnshire, East Lindsey District36Worksite and access for the construction and carrying out of the authorised projectWork Nos. 5A, 5B, 6A, 6B, 7A and 7B
In the County of Lincolnshire, East Lindsey District40, 41, 43, 44, 70, 71, 77, 93, 94, 100, 101, 102, 103, 104, 105, 106, 108, 109, 118, 124, 125, 126, 130, 137, 138, 154, 157, 158, 179, 184, 185Worksite and access for the construction and carrying out of the authorised projectWork Nos. 7A and 7B
In the County of Lincolnshire, East Lindsey District34, 50, 53, 54, 56, 57, 58, 59, 60, 61, 62, 63, 64, 65, 66, 73, 74, 76, 78, 89, 90, 91, 110, 111, 112, 114, 115, 116, 117, 120, 121, 122, 127, 128, 129, 142, 143, 156, 159, 160, 162, 164, 165, 166, 167, 170, 171, 177, 178, 181, 182Laying and use of temporary vehicular access trackWork Nos. 7A and 7B
In the County of Lincolnshire, East Lindsey District172, 174, 176Laying of temporary public footpaths and bridlewaysWork Nos. 7A and 7B
In the County of North East Lincolnshire213, 214, 224, 226, 229, 230, 245, 246, 247, 257, 258, 259, 277, 278, 280, 283, 284, 287, 288, 301, 302, 318, 319, 322, 324, 330, 331, 335, 336, 345, 346, 350, 351, 353, 356, 359, 362, 363, 372, 374, 392, 393, 395, 397, 401, 402, 405, 406, 407, 408, 412, 414, 419Worksite and access for the construction and carrying out of the authorised projectWork Nos. 7A and 7B
In the County of North East Lincolnshire209, 210, 212, 231, 239, 241, 242, 264, 265, 266, 267, 269, 270, 271, 272, 274, 315, 316, 320, 337, 340, 341, 343, 355, 368, 370, 371, 375, 376, 377, 379, 381, 416, 418Laying and use of temporary vehicular access trackWork Nos. 7A and 7B
In the County of North East Lincolnshire244, 290, 292, 326, 329Laying of temporary public footpaths and bridlewaysWork Nos. 7A and 7B
In the County of North Lincolnshire422, 423, 425, 427, 435, 436, 441, 442, 443, 444, 446, 455, 456, 458, 462, 463, 467, 469, 470, 473, 474, 477, 478, 479, 483, 484, 493, 496, 498Worksite and access for the construction and carrying out of the authorised projectWork Nos. 7A and 7B
In the County of North Lincolnshire513, 514, 515, 520, 522Laying and use of temporary vehicular access trackWork Nos. 8A, 8B, 9A, 9B and 10
In the County of North Lincolnshire502, 504, 505Worksite and access for the construction and carrying out of the authorised projectWork Nos. 7A, 7B, 8A, 8B, 9A and 9B
In the County of North Lincolnshire508, 517, 518Worksite and access for the construction and carrying out of the authorised projectWork Nos. 8A, 8B, 9A and 9B

PART 2E+W+SCompensation compounds

Commencement Information

I47Sch. 7 Pt. 2 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Number of land shown on land plans

(3)

Purpose for which temporary possession may be taken

In the County of Lincolnshire, East Lindsey District72, 95, 136, 186Compensation compound in respect of worksite and access
In the County of Lincolnshire, East Lindsey District73, 185Compensation compound access in respect of vehicular access track to and from a compensation compound
In the County of North East Lincolnshire225, 233, 235, 243, 260, 276, 279, 286, 321, 328, 344, 348, 349, 354, 373, 396, 398, 409, 410, 413Compensation compound in respect of worksite and access
In the County of North East Lincolnshire239, 241, 242, 263, 293, 294, 296, 297, 355, 399, 400Compensation compound access in respect of vehicular access track to and from a compensation compound
In the County of North Lincolnshire428, 447, 457, 464, 475, 485, 494, 495, 501Compensation compound in respect of worksite and access

PART 3E+W+SAuthorised project: access

Commencement Information

I48Sch. 7 Pt. 3 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Number of land shown on land plans

In the County of Lincolnshire, East Lindsey District42, 51, 52, 55, 75, 82, 133, 144, 145, 146, 163
In the County of North East Lincolnshire236, 237, 238, 240, 253, 254, 303, 304, 305, 306, 323, 357, 358, 366, 367, 369, 378, 380, 415, 417
In the County of North Lincolnshire480, 481, 516

PART 4E+W+SCompensation compounds: access

Commencement Information

I49Sch. 7 Pt. 4 in force at 7.9.2016, see art. 1(2)

(1)

Area

(2)

Number of land shown on land plans

In the County of North East Lincolnshire240

Articles 2 and 36

SCHEDULE 8E+W+SMarine Licence A1: Project A – Generation Assets

PART 1E+W+SLicensed activities

InterpretationE+W+S

1.—(1) In this licence—

“2008 Act” means the Planning Act 2008;

“2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works described in clause 2 of Part 1 of this licence that are not development within the meaning of section 32 of the 2008 Act;

“Annex 1 habitat” means a habitat set out in Annex 1 to Council Directive 92/43/EEC of 21st May 1992 on the conservation of natural habitats and of wild fauna and flora;

“authorised deposits” means the substances and articles specified in clause 2(3) of Part 1 of this licence;

“authorised development” means the development described in Part 1 of Schedule 1 to the Order that is development within the meaning of section 32 of the 2008 Act;

“authorised project” means the authorised development and the ancillary works authorised by the Order;

“authorised scheme” means Work No. 1A described in clause 2 of Part 1 of this licence;

“commence” means the first carrying out of any part of the licensed activities, except for pre-construction surveys and monitoring; and “commencement” must be construed accordingly;

“Condition” means a condition set out in Part 2 of this licence;

“construction vessel” means any vessel involved in the course of or used for the construction and/or maintenance of the authorised project;

“debris” means items or equipment of a significant size left on the seabed being lost from survey or construction vessels or the structures comprised within the authorised scheme;

“EIA Regulations” means the Infrastructure Planning (Environmental Impact Assessment) Regulations 2009;

“electrical circuit” means a number of electrical conductors necessary to transmit electricity between 2 points within the authorised project, comprising—

(a)

in the case of HVAC transmission, 3 conductors which may be bundled as 1 cable; and

(b)

in the case of HVDC transmission 2 conductors, which may be attached together or take the form of single cables,

and the electrical circuit may include 1 or more auxiliary cables (normally fibre-optic cables) for the purpose of control, monitoring, protection or general communications;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of Part 4 of the 2009 Act;

“environmental statement” means the document certified as the environmental statement by the Secretary of State under article 40 of the Order;

“gravity base foundation” means—

(a)

a structure principally of concrete or steel (or both) that rests on the seabed due to its own weight and that of added ballast or to the weight of water above it and may include associated equipment including suction piles, J-tubes and access platforms; or

(b)

a structure principally of concrete or steel (or both) consisting of a platform supported on 2 pontoons to which the platform is connected by columns which may be connected by braces;

“HVAC” means high voltage alternating current;

“HVDC” means high voltage direct current;

“in-principle monitoring plan” means the document certified as the in-principle monitoring plan by the Secretary of State under article 40 of the Order;

“intra-array electrical circuits” means the circuits described in clause 2(2)(b) of Part 1 of this licence;

“jacket foundation” means a lattice construction comprising tubular members and joints fixed to the seabed with piles (either driven/drilled piles or suction piles) which will include platforms and J-tubes and may include braced monopiles and a transition piece;

“Kingfisher Fortnightly Bulletin” means the bulletin published by the Humber Seafood Institute or such other alternative publication approved in writing by the MMO;

“LAT” means lowest astronomical tide;

“licensed activities” means the activities specified in Part 1 of this licence;

“maintain”, unless otherwise provided for, includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development; and any derivative of “maintain” must be construed accordingly;

“Marine Noise Registry” means the online database maintained by the Joint Nature Conservation Committee on behalf of the Department for Environment, Food and Rural Affairs that records the spatial and temporal distribution of impulsive noise-generating activities in United Kingdom seas in order that they can be analysed to determine whether they may potentially compromise the achievement of good environmental status;

“MCA” means the Maritime and Coastguard Agency;

“MHWS” (mean high water springs) means the highest level which spring tides reach on average over a period of time;

“MMO” means the Marine Management Organisation;

“monopile foundation” means a foundation comprising a large diameter steel or concrete tube or pile driven vertically into the seabed, J-tubes and platforms and may include external structural devices such as bracing members or steel anchor wires and a transition piece;

“notice to mariners” includes any notice to mariners which may be issued by Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore accommodation platform” means a platform housing or incorporating temporary accommodation, landing ports for vessels and helicopters, standby electricity generation equipment, marking and lighting and other equipment facilities to assist in the co-ordination of marine activities related to the authorised scheme;

“offshore HVAC collector substation” means a structure serving as a collection point for the intra-array electrical circuits and containing equipment for the purpose of transforming the electricity generated at the wind turbine generators to a higher voltage; it may also include a helicopter platform;

“offshore HVDC converter substation” means a structure that contains equipment to convert HVAC electricity to HVDC electricity; it may also include a helicopter platform;

“Order” means the Hornsea Two Offshore Wind Farm Order 2016;

“Order limits” means the limits shown on the works plans within which the authorised project may be carried out;

“suction pile” means a large diameter steel cylinder that is fixed to the base of the foundation, partially penetrates the seabed and remains in place using its weight and hydrostatic pressure differential;

“survey vessel” means a vessel licensed to carry out environmental or engineering surveys;

“Trinity House” means the Corporation of Trinity House of Deptford Strond;

“UK Hydrographic Office” means the Hydrographic Office of the Ministry of Defence or any replacement body or successor to its functions;

“undertaker” means Optimus Wind Limited (company number 07883284) or, to the extent that the benefit of the provisions of the Order and related statutory rights in relation to Work No. 1A and such associated development or ancillary works has been transferred under article 35 of the Order to another person, that other person;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water that is at the time in, on or over water;

“wind farm area” means the area within the limits of deviation for Work No. 1A whose co-ordinates are set out in Part 1 of Schedule 1 to the Order and shown on the works plans;

“wind turbine generator” means a structure comprising any or all of a tower, rotor, blades, nacelle and ancillary electrical and other equipment or structures, which may include lighting and a helicopter platform, fixed to a foundation;

“working day” means any day other than a Saturday, Sunday or public holiday in England and Wales;

“Work No. 1A” means an offshore wind generating station within the wind farm area and described as Work No. 1A in clause 2 of Part 1 of this licence;

“Work No. 1B” means an offshore wind generating station within the wind farm area and described as Work No. 1B in Part 1 of Schedule 1 to the Order;

“Work No. 2A” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“Work No. 2B” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“works plans” means the plans certified as the works plans by the Secretary of State under article 40 of the Order, comprising the offshore works plans, the intertidal works plans and the onshore works plans.

(2) A reference to any statute, order, regulation or similar instrument must be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a)all times are Greenwich Mean Time (GMT);

(b)all co-ordinates are latitude and longitude degrees, minutes and seconds to 3 decimal places in WGS84 Datum.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence is—

(a)Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle-upon-Tyne NE4 7YH

Tel: 0300 123 1032

E-mail: marine.consents@marinemanagement.org.uk

(b)Marine Management Organisation (referred to as the “MMO Coastal Office”)

Neville House

Central Riverside

Bell Street

North Shields

Tyne and Wear NE30 1LJ

Tel (24-hour answer phone): 0191 257 4520 or 0191 257 0159

E-mail: northshields@marinemanagement.org.uk

(c)Trinity House

Tower Hill

London EC3N 4DH

Tel: 020 7481 6900

(d)The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset TA1 2DN

Tel: 01823 337 900

(e)Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton SO15 1EG

Tel: 023 8032 9191

(f)Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk NR33 0HT

Tel: 01502 562 244

(g)Natural England

Foss House

Kings Pool

1-2 Peasholme Green

York YO1 7PX

Tel: 0300 060 1911

(h)Historic Buildings and Monuments Commission for England (referred to as “Historic England”)

Eastgate Court

195-205 High Street

Guildford GU1 3EH

Tel: 01483 252 057.

Commencement Information

I50Sch. 8 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

Details of licensed activitiesE+W+S

2.—(1) This licence authorises the undertaker (and any agent or contractor acting on its behalf) to carry out the following licensable marine activities pursuant to section 66(1) of the 2009 Act, subject to the Conditions—

(a)the deposit at sea of the substances and articles specified in paragraph (3);

(b)the construction of works in or over the sea and/or on or under the sea bed;

(c)dredging for the purposes of seabed preparation for foundation works and/or electrical circuit works;

(d)the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation;

(e)the disposal at disposal site reference HU211 of up to 2,427,666 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 1A, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 1A and 1B disposed of at disposal site reference HU211 must not exceed 2,427,666 cubic metres;

(f)the disposal at disposal site reference HU211 of up to 400,852 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 1A, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 1A and 1B disposed of at disposal site reference HU211 must not exceed 400,852 cubic metres; and

(g)the removal of the substances and articles specified in paragraph (3).

(2) The activities are authorised in relation to the construction, maintenance and operation of—

Work No. 1A — An offshore wind generating station within the wind farm area comprising—

(a)up to 300 wind turbine generators fixed to the seabed, provided that the combined total of wind turbine generators constructed in whole or in part within Work Nos. 1A and 1B must not exceed 300;

(b)a network of subsea intra-array electrical circuits connecting the structures comprised in Work No. 1A—

(i)with other such structures;

(ii)with any other structure located within the wind farm area; and

(iii)with the network of electrical circuits comprised in Work Nos. 1B, 2A and 2B;

(c)up to 2 offshore accommodation platforms fixed to the seabed which may be connected to one of the offshore HVAC collector substations or offshore HVDC converter substations within Work No. 2A by an unsupported steel bridge and up to 2 electrical circuits each connecting an accommodation platform to either an offshore HVAC collector substation or to a wind turbine generator in order to power the accommodation platform, provided that the combined total of offshore accommodation platforms constructed in whole or in part within Work Nos. 1A and 1B must not exceed 2.

Co-ordinates for wind farm area (limits of deviation for Work Nos. 1A, 1B, 2A and 2B)—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

And in connection with Work No. 1A, further associated development as may be necessary or expedient in connection with the authorised scheme within the Order limits and is within the scope of the environmental impact assessment recorded in the environmental statement.

And in connection with Work No. 1A, ancillary works consisting of works and operations within the Order limits comprising temporary anchorage of vessels and buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) The substances or articles authorised for deposit at sea and removal are—

(a)iron and steel;

(b)stone and rock;

(c)concrete;

(d)sand and gravel;

(e)plastic and synthetic; and

(f)material extracted from within the wind farm area during construction drilling and seabed preparation for foundation works.

(4) The grid co-ordinates for disposal site reference HU211 are—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

(5) Section 72 of the 2009 Act applies to this licence, except that subsections (7) and (8) relating to the transfer of the licence apply only to a transfer not falling within article 35 of the Order.

Commencement Information

I51Sch. 8 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

Maintenance of authorised projectE+W+S

3.—(1) The undertaker may at any time maintain the authorised project, except to the extent that this licence or an agreement made under this licence provides otherwise.

(2) No maintenance works whose likely effects on the environment require to be assessed in accordance with the EIA Regulations and are not assessed in the environmental statement may be carried out, unless otherwise approved by the MMO.

(3) Where the MMO’s approval is required under paragraph (2), approval may be given only where it has been demonstrated to the satisfaction of the MMO that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I52Sch. 8 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

DurationE+W+S

4.  This licence remains in force until the authorised scheme has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the Energy Act 2004, including any modification to the programme under section 108(7), and the completion of the programme has been confirmed by the Secretary of State in writing.

Commencement Information

I53Sch. 8 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SLicence conditions

Design parametersE+W+S

1.—(1) No wind turbine generator forming part of Work No. 1A may—

(a)be more than 151 metres from LAT to the turbine hub;

(b)exceed a height of 276 metres from LAT to the upper tip of the vertical blade;

(c)exceed a rotor diameter of 241.03 metres;

(d)be less than 34.97 metres from LAT to the lowest point of the rotating blade;

(e)be less than 810 metres from the nearest wind turbine generator in all directions.

(2) In this Condition, references to the location of a wind turbine generator are references to the centre point of the turbine.

(3) No offshore accommodation platform forming part of Work No. 1A may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(4) The diameter of the electrical cables comprising the electrical circuits within Work No. 1A must not exceed 170 millimetres.

(5) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 1A and 1B must not exceed 685 kilometres.

(6) The electrical circuits comprised in Work No. 1A must be installed by use of, or a combination of, ploughing, trenching, jetting, rock-cutting, dredging, surface laying with post-lay burial and, where ground conditions make burial impracticable, by surface laying.

Commencement Information

I54Sch. 8 Pt. 2 para. 1 in force at 7.9.2016, see art. 1(2)

2.—(1) The undertaker must in fixing to the seabed any structures comprised in Work No. 1A use one of the following methods—

(a)monopile foundations;

(b)jacket foundations supported by piles; or

(c)gravity base foundations.

(2) The following parameters apply in respect of the foundation methods used to fix wind turbine generators comprised in Work No. 1A to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 2,827 square metres;

(ii)the number of piles per jacket must not exceed 12;

(iii)the diameter of each pile must not exceed 6 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and scour protection for each individual structure must not exceed 12,596 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 21.1 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 7,543 square metres;

(ii)the seabed levelling diameter must not exceed 78 metres;

(iii)the cone diameter must not exceed 58 metres at its base.

(3) The following parameters apply in respect of the foundation methods used to fix offshore accommodation platforms to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,414 square metres;

(ii)the number of piles must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(4) The total volume of scour protection for the wind turbine generators and the offshore accommodation platforms forming part of Work No. 1A must not exceed 4,761,555 cubic metres, provided that the combined total volume of scour protection for the wind turbine generators and the offshore accommodation platforms forming part of Work Nos. 1A and 1B must not exceed 4,761,555 cubic metres.

Commencement Information

I55Sch. 8 Pt. 2 para. 2 in force at 7.9.2016, see art. 1(2)

Navigational practice, safety and emergency responseE+W+S

3.—(1) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has given written approval for an emergency response co-operation plan which includes full details of the emergency co-operation plans for the construction, operation and decommissioning phases of that part of the authorised scheme in accordance with the MCA recommendations contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”(8).

(2) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and, so far as is applicable to that stage of the development, adequately addressed all MCA recommendations as appropriate to the authorised scheme contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” (including its annexes).

(3) The emergency response co-operation plan must be implemented as approved, unless otherwise agreed in writing by the MMO, in consultation with the MCA.

Commencement Information

I56Sch. 8 Pt. 2 para. 3 in force at 7.9.2016, see art. 1(2)

Aids to navigationE+W+S

4.—(1) The undertaker must during the whole period from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning—

(a)exhibit such lights, marks, sounds, signals and other aids to navigation and take such other steps for the prevention of danger to navigation as Trinity House may from time to time direct;

(b)colour all structures in the authorised scheme as directed by Trinity House;

(c)keep Trinity House and the MMO informed of progress of the authorised scheme seaward of MHWS including—

(i)notice of commencement of construction of the authorised scheme within 24 hours of commencement having occurred;

(ii)notice within 24 hours of any aids to navigation being established by the undertaker; and

(iii)notice within 5 working days of completion of construction of the authorised scheme;

(d)submit reports to Trinity House detailing the working condition of aids to navigation quarterly, or as requested by Trinity House;

(e)notify Trinity House and the MMO of any failure of the aids to navigation and the timescales and plans for remedying such failures as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

(2) Except as otherwise required by Trinity House under paragraph (1), the undertaker must colour all structures comprised in Work No. 1A yellow (colour code RAL 1023) from at least highest astronomical tide to a height as directed by Trinity House.

(3) Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

Commencement Information

I57Sch. 8 Pt. 2 para. 4 in force at 7.9.2016, see art. 1(2)

Notifications and inspectionsE+W+S

5.—(1) The undertaker must ensure that—

(a)a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i)all agents and contractors notified to the MMO in accordance with the Conditions; and

(ii)the masters and transport managers responsible for the vessels notified to the MMO in accordance with the Conditions;

(b)within 28 days of receipt of a copy of this licence, the persons referred to in sub-paragraph (a) provide a completed confirmation form to the MMO confirming their understanding of the terms of this licence.

(2) Only the persons and vessels notified to the MMO in accordance with Condition 11 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection at the following locations—

(a)the undertaker’s registered address;

(b)any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits; and

(c)on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made.

(4) The documents referred to in paragraph (1)(a) must be available for inspection by an enforcement officer at the locations set out in paragraph (3) at any time.

(5) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or any other associated works or vessels to facilitate any inspection that the MMO considers necessary to inspect the works during construction and operation of the authorised scheme.

(6) The undertaker must inform the MMO Marine Licensing Team and the MMO Coastal Office in writing at least 5 working days before the commencement of the licensed activities or any part of them.

(7) The Kingfisher Information Service of Seafish must be informed by email of details of the vessel routes, timings and locations relating to the construction of the authorised scheme or relevant part to kingfisher@seafish.co.uk—

(a)at least 2 weeks before the construction of the authorised scheme or relevant part, for inclusion in the Kingfisher Fortnightly Bulletin and offshore hazard awareness data; and

(b)on completion of the construction of the authorised scheme or relevant part.

Confirmation of notification must be provided to the MMO within 5 working days of notification to the Kingfisher Information Service of Seafish.

(8) The undertaker must ensure that a notice to mariners is issued at least 10 working days before the commencement of the licensed activities advising of the commencement of licensed activities within the wind farm area and the expected vessel routes from the local service ports to the location of the works comprised within the authorised scheme.

(9) The undertaker must ensure that the notices to mariners are updated and reissued at weekly intervals during construction activities and at least 5 days before any planned operation and maintenance works and supplemented with VHF radio broadcasts agreed with the MCA in accordance with the construction and monitoring programme approved under Condition 8(2)(a). Copies of all notices must be provided to the MMO within 10 working days of issue.

(10) The undertaker must notify—

(a)the UK Hydrographic Office of commencement (within 2 weeks), progress and completion (within 2 weeks) of the authorised scheme in order that all necessary amendments to nautical charts are made, and the undertaker must send a copy of such notifications to the MMO; and

(b)the Defence Geographic Centre (at least 4 weeks before) of the commencement of the authorised scheme and of the progress and completion (within 2 weeks) of the authorised scheme, in order that all necessary amendments to aviation charts are made.

(11) In case of damage to, or destruction or decay of, the authorised scheme or any part of it seaward of MHWS, the undertaker must as soon as reasonably practicable, and no later than 24 hours following the undertaker becoming aware of any such damage, destruction or decay, notify the MMO, Trinity House, MCA and the UK Hydrographic Office.

(12) In the event that the Marine Noise Registry has gone live before the commencement of impact pile driving—

(a)the undertaker must submit details of the expected location, start and end dates of impact pile driving to the Marine Noise Registry before the commencement of the impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

(13) In the event that the Marine Noise Registry has gone live at the time of impact pile driving—

(a)the undertaker must submit the exact locations and dates of impact pile driving to the Marine Noise Registry at 6-month intervals from the commencement of impact pile driving until the completion of impact pile driving. The final data must be submitted within 12 weeks of completion of impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

Commencement Information

I58Sch. 8 para. 5 in force at 7.9.2016, see art. 1(2)

Chemicals, drilling and debrisE+W+S

6.—(1) All chemicals used in the construction of the authorised scheme must be selected from the list of notified chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002(9), unless otherwise agreed in writing by the MMO.

(2) The undertaker must ensure that any coatings or treatments are suitable for use in the marine environment and are used in accordance with guidelines approved by Health and Safety Executive or the Environment Agency Pollution Prevention Guidelines.

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110% of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences, which disposal may also require a marine licence.

(5) The undertaker must ensure that, where practicable, any debris arising from the construction of the authorised scheme or temporary works placed seaward of MHWS is removed by a date no later than 28 days following the undertaker becoming aware of the debris after the completion of the authorised scheme (or by such later date as may be agreed in writing by the MMO). In the event that the debris cannot practicably be removed, the undertaker must notify the MMO, Trinity House and the MCA within 7 days of becoming aware that the debris cannot practicably be removed.

(6) At least 10 days before the commencement of the licensed activities, the undertaker must submit to the MMO an audit sheet covering all aspects of the construction of the authorised scheme, and no works may commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a)loading facilities;

(b)vessels;

(c)equipment;

(d)shipment routes;

(e)working schedules; and

(f)all components and materials to be used in the construction of the authorised scheme.

(7) The audit sheet must be maintained throughout the construction of the authorised scheme, and the MMO must be notified of any changes on a fortnightly basis.

(8) In the event that the undertaker becomes aware that any of the materials on the audit sheet cannot be accounted for, it must notify the MMO within 24 hours where possible, and in any event within 5 days of becoming aware using the dropped object procedure form. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so. Local fishermen must be invited to send a representative to be present during the survey. The MMO may require any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(9) All debris arising from the operation and maintenance of the authorised scheme must be reported to the MMO using the dropped object procedure form within 24 hours where possible, and in any event within 5 days of the undertaker becoming aware of the incident. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so and any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(10) The undertaker must inform the MMO of the location and quantities of inert material and dredged material disposed of each month under this licence, by submission of a disposal return by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(11) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 1A;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 1A; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 1A;

is disposed of at disposal site reference HU211.

(12) The undertaker must ensure that no waste concrete slurry or wash water from concrete or cement works is discharged into the marine environment. Concrete, cement mixing and washing areas must be contained to prevent run-off entering the water through the freeing ports.

(13) The undertaker must ensure that any rock material used in the construction of the authorised scheme is from a recognised source, free from contaminants and containing minimal fines.

(14) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU211.

Commencement Information

I59Sch. 8 para. 6 in force at 7.9.2016, see art. 1(2)

Force majeureE+W+S

7.  If, due to stress of weather or any other cause, the master of a vessel determines that it is necessary to deposit—

(a)authorised deposits outside of the wind farm area or disposal site reference HU211; or

(b)unauthorised deposits within or outside of the wind farm area or disposal site reference HU211,

because the safety of human life or of the vessel is threatened, full details of the circumstances of the deposit must be notified to the MMO within 48 hours.

Commencement Information

I60Sch. 8 para. 7 in force at 7.9.2016, see art. 1(2)

Pre-construction plans and documentationE+W+S

8.—(1) The licensed activities may not commence until a plan setting out proposed details of the authorised scheme and including the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO following appropriate consultation with Trinity House and the MCA—

(a)number, dimensions, specification, foundation types and depth for each wind turbine generator and offshore accommodation platform;

(b)grid co-ordinates of the centre point of the proposed location for each wind turbine generator and offshore accommodation platform, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions;

(c)proposed layout of all cables, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions; and

(d)location and specification of all other aspects of the authorised scheme, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions.

(2) The licensed activities, or any phase of those activities, may not commence until a code of construction practice incorporating the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO—

(a)a construction and monitoring programme, to include details of—

(i)the proposed construction start date;

(ii)proposed timings for mobilisation of plant, delivery of materials and installation works; and

(iii)proposed pre-construction surveys, baseline report format and content, construction monitoring, post-construction monitoring and related reporting in accordance with Conditions 13, 14 and 15. The pre-construction survey programme and all pre-construction survey methodologies must be submitted to the MMO for written approval by the MMO in consultation with the relevant statutory nature conservation body at least 4 months before the commencement of any survey works detailed within;

(b)a construction method statement in accordance with the environmental statement, including details of—

(i)foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii)turbine installation, including any seabed preparation and scour protection;

(iii)installation of offshore accommodation platforms, including any seabed preparation and scour protection;

(iv)circuit installation, including any seabed preparation and circuit protection;

(v)contractors;

(vi)vessels; and

(vii)associated works;

(c)a project environmental management and monitoring plan, to include details of—

(i)a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised scheme in relation to all activities carried out seaward of MHWS. The plan must include a mechanism for reporting oil, fuel and chemical spills to the MMO Marine Pollution Response Team;

(ii)a chemical risk analysis to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii)a disposal plan detailing the locations, methods and timings of dredging and disposal, as well as disposal site monitoring requirements;

(iv)waste management and disposal arrangements;

(v)locations of any archaeological exclusion zones agreed as part of the written scheme of archaeological investigation approved under sub-paragraph (g); and

(vi)the appointment and responsibilities of a fisheries liaison officer and an environmental liaison officer;

(d)a scour protection management and cable armouring plan providing details of the need, type, sources, quantity, location and installation methods for scour protection and cable armouring to be within the scope of the environmental impact assessment recorded in the environmental statement;

(e)in the event that driven or part-driven pile foundations are proposed to be used, a marine mammal mitigation protocol, the intention of which is to prevent injury and/or significant disturbance to marine mammals, following current best practice as advised by the statutory nature conservation bodies, which may include, but is not limited to—

(i)identification of a marine mammal mitigation zone (“MMMZ”);

(ii)appointment of an appropriate number of suitably qualified marine mammal observers;

(iii)methods for the detection of marine mammals within the MMMZ whether visually (by the marine mammal observers) or acoustically using passive acoustic monitoring equipment or other means of detection;

(iv)a reporting methodology to enable efficient communication between the marine mammal observers and the person responsible for approving commencement of piling;

(v)an appropriate soft start procedure whereby piling activities do not commence until an agreed time has elapsed and during which marine mammals have not been detected within the MMMZ;

(vi)where appropriate, methods for the application of acoustic deterrent devices; and

(vii)where appropriate, consideration of the use of noise reduction at source technologies;

(f)a cable specification and installation plan, to include—

(i)technical specification of offshore electrical circuits, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice; and

(ii)a detailed cable laying plan, including geotechnical data, cable laying techniques and a cable burial risk assessment encompassing the identification of any cable protection that exceeds 5% of navigable depth referenced to Chart Datum and, in the event that any area of cable protection exceeding 5% of navigable depth is identified, details of any steps (to be determined following consultation with the MCA) to be taken to ensure existing and future safe navigation is not compromised;

(g)a written scheme of archaeological investigation in relation to the wind farm area in accordance with industry good practice, to include—

(i)details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii)a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver- or remotely-operated vehicle investigations;

(iii)analysis and reporting of survey data to be submitted to the MMO within 4 months of survey completion;

(iv)delivery of any mitigation including, where necessary, archaeological exclusion zones;

(v)monitoring during and post-construction, including a conservation programme for finds;

(vi)archiving of archaeological material; and

(vii)a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised scheme;

(h)a plan for marine mammal monitoring setting out the circumstances in which marine mammal monitoring will be required and the monitoring to be carried out in such circumstances;

(i)an offshore project maintenance plan to be submitted to the MMO at least 4 months before commencement of the operation of the licensed activities and to include provision for the review and resubmission of the plan every 3 years during the operational phase;

(j)an aids to navigation management plan specifying how the undertaker will ensure compliance with Condition 4 from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning;

(k)an ornithological monitoring plan setting out the circumstances in which ornithological monitoring will be required and the monitoring to be carried out in such circumstances.

(3) Before the submission of the pre-construction plans and documentation required by this Condition, the undertaker must provide a copy of the plans and documentation to the other undertakers under the Order.

(4) The undertaker must participate in liaison meetings with other undertakers under the Order as requested from time to time by the MMO in writing in advance. The meetings must be chaired by the MMO and must consider such matters as are determined by the MMO relating to the efficient operation of a deemed marine licence where it has an impact on the efficient operation of any other deemed marine licence issued under the Order (including as varied or transferred).

(5) Before giving its approval under paragraph (2), the MMO must—

(a)in relation to any programme, statement, plan or protocol submitted under sub-paragraphs (a) to (f), (h), (i) or (k), consult the relevant statutory nature conservation body;

(b)in relation to a scheme submitted under sub-paragraph (g), consult Historic England; and

(c)in relation to a plan submitted under sub-paragraph (j), consult Trinity House.

(6) In the event that driven or part-driven pile foundations are proposed to be used, the MMO must not approve the plan referred to in paragraph (1) or the code referred to in paragraph (2) unless the MMO is satisfied, after consulting such persons as the Secretary of State may specify in relation to the plan or the part of the code specified by the Secretary of State (in addition to the persons with whom consultation is otherwise required under this Condition), that either the plan or code (or both of them) provide such mitigation as is necessary to avoid adversely affecting the integrity (within the meaning of the 2007 Regulations) of a relevant site, to the extent that marine mammals are a protected feature of that site.

(7) The mitigation referred to in paragraph (6) may include (without limitation)—

(a)seasonal restrictions to piling;

(b)scheduling of piling, having regard to previous, ongoing and future piling associated with other offshore developments, based on an updated assessment of cumulative impacts;

(c)subject to the terms and conditions of this licence, changing the location of wind turbine generators;

(d)the use of alternative foundation methodologies, such as jacket foundations (suction piles) or gravity base foundations;

(e)the use of noise reduction at source technologies;

(f)the use of other relevant technologies or methodologies that may emerge in the future.

(8) In paragraph (6), “relevant site” means—

(a)a European offshore marine site;

(b)a European site.

(9) For the purpose of paragraph (6)—

(a)the Southern North Sea possible Special Area of Conservation must be treated as a European offshore marine site until—

(i)that Area (or any part of it) becomes a European offshore marine site or a European site; or

(ii)it is decided that no part of that Area should be a European offshore marine site or a European site; and

(b)harbour porpoise must be treated as a protected feature of the Southern North Sea possible Special Area of Conservation.

(10) In this Condition—

“2007 Regulations” means the Offshore Marine Conservation (Natural Habitats, &c.) Regulations 2007(10);

“disturbance” must be construed in accordance with regulation 39(1)(b) of the 2007 Regulations;

“European offshore marine site” has the meaning given in regulation 15 of the 2007 Regulations;

“European site” has the meaning given in regulation 24 of the 2007 Regulations;

“Southern North Sea possible Special Area of Conservation” means the Southern North Sea possible Special Area of Conservation as set out in the JNCC 2016 Harbour Porpoise Possible Special Area of Conservation Consultation dated January 2016(11).

Commencement Information

I61Sch. 8 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Record of the Historic Environment, by submitting a Historic England OASIS form with a digital copy of the report within 6 months of completion of construction of the authorised scheme. The undertaker must notify the MMO that the OASIS report has been submitted to the National Record of the Historic Environment within 2 weeks of the submission.

Commencement Information

I62Sch. 8 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Each programme, statement, plan, protocol or scheme required to be approved under Condition 8

(a)must be submitted for approval at least 4 months before the intended start of construction, except where otherwise stated or where an alternative date is agreed in writing by the MMO; and

(b)must be accompanied by—

(i)a statement confirming that the undertaker has complied with Condition 8(3) in relation to the programme, statement, plan, protocol or scheme; and

(ii)any comments received by the undertaker from the other undertakers, or a statement from the undertaker confirming that no such comments were received.

(2) The undertaker must comply with the plans and documentation approved under Condition 8 in carrying out the licensed activities unless otherwise agreed in writing by the MMO.

(3) Before agreeing an alternative date under paragraph (1)(a) or a change to approved details under paragraph (2) relating to any document in respect of which consultation is required under Condition 8(5), the MMO must consult the relevant consultation body referred to in that Condition.

Commencement Information

I63Sch. 8 para. 10 in force at 7.9.2016, see art. 1(2)

Reporting of engaged agents, contractors and vesselsE+W+S

11.—(1) The undertaker must provide the following information to the MMO—

(a)the name and function of any agent or contractor appointed to engage in the licensed activities at least 5 working days before the commencement of the licensed activities or any part of them; and

(b)each week during the construction of the authorised scheme, a completed Hydrographic Note H102 listing the construction vessels currently and to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO and MMO Coastal Office in writing before the agent, contractor or vessel engages in the licensed activities.

(3) All agents, contractors and vessel operators comply with the Conditions.

Commencement Information

I64Sch. 8 para. 11 in force at 7.9.2016, see art. 1(2)

Equipment and operation of vessels engaged in licensed activitiesE+W+S

12.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of the activities in accordance with the Conditions and must comply with paragraphs (2) to (5).

(2) All motor-powered vessels must be fitted with—

(a)an electronic positioning aid to provide navigational data;

(b)radar;

(c)an echo sounder; and

(d)multi-channel VHF.

(3) All vessel names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All communication on VHF working frequencies must be in English.

(5) No vessel may engage in the licensed activities until all the equipment specified in paragraph (2) is fully operational.

Commencement Information

I65Sch. 8 para. 12 in force at 7.9.2016, see art. 1(2)

Pre-construction monitoring and surveysE+W+S

13.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant conservation body of proposed pre-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format and content for a pre-construction baseline report; and—

(a)the survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the post-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement; and

(b)the baseline report proposals must ensure that the outcome of the agreed surveys together with existing data and reports are drawn together to present a valid statement of the pre-construction position, with any limitations, and must make clear what post-construction comparison is intended and the justification for this being required.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the pre-construction surveys must comprise, in outline—

(a)a high-resolution swath bathymetric survey to include a 100% coverage and a side-scan sonar survey of the parts of the wind farm area in which it is proposed to carry out construction works and disposal activities under this licence;

(b)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k);

(c)a survey to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) in the parts of the wind farm area in which it is proposed to carry out construction works under this licence; and

(d)any marine mammal monitoring required by the plan for marine mammal monitoring submitted in accordance with Condition 8(2)(h).

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing by the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I66Sch. 8 para. 13 in force at 7.9.2016, see art. 1(2)

Construction monitoringE+W+S

14.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of any proposed construction monitoring, including methodologies and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the construction monitoring must comprise, in outline—

(a)unless the MMO agrees otherwise in writing, measurements of noise generated by the installation of the first 4 foundations of each discrete foundation type to be constructed under this licence where driven or part-driven pile foundations are used;

(b)recording of any visual sightings or acoustic detection of marine mammals where required as part of the marine mammal mitigation protocol under Condition 8(2)(e); and

(c)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k).

(3) The undertaker must carry out the surveys approved under paragraph (1), including any further noise monitoring required in writing by the MMO under paragraph (4), and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) The results of the initial noise measurements monitored in accordance with paragraph (2)(a) must be provided to the MMO within 6 weeks of the installation of the first 4 foundations of each discrete foundation type for the MMO to determine, following assessment of this report, whether any further noise monitoring is required.

(5) Construction monitoring must include vessel traffic monitoring by automatic identification system for the duration of the construction period. A report must be submitted to the MMO and the MCA at the end of each year of the construction period.

Commencement Information

I67Sch. 8 para. 14 in force at 7.9.2016, see art. 1(2)

Post-constructionE+W+S

15.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of proposed post-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt of specific proposals, so far as applicable, the post-construction surveys must comprise, in outline—

(a)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k);

(b)a high-resolution swath bathymetric survey of the following to assess any changes in bedform morphology—

(i)a representative sample area, as may be agreed in writing with the MMO, of the parts of the wind farm area within which construction works and disposal activities were carried out under this licence, and such further monitoring as may be required to ensure that the cables have been buried or protected; and

(ii)an area not to exceed 125% of the predicted scour area around a selection of turbines, such selection to be based on the desk-based assessment;

(c)a survey to determine any change in the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) identified in the pre-construction survey in the parts of the wind farm area in which construction works were carried out. The survey design must be informed by the results of the pre-construction benthic survey;

(d)any marine mammal monitoring required by the plan for marine mammal monitoring submitted in accordance with Condition 8(2)(h); and

(e)vessel traffic monitoring by automatic identification system, for 28 days taking account seasonal variations in traffic patterns, for a maximum duration of 1 year post-construction. A report must be submitted to the MMO and the MCA at the end of the first year after construction is completed.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) Before carrying out the survey required under paragraph (2)(b), the undertaker must submit to the MMO for written approval a desk-based assessment (which takes account of all factors which influence scour) identifying the turbines with greatest potential for scour. The survey must be used to validate the desk-based assessment, and the significance of any differences between the predicted scour and recorded scour must be assessed in the survey report which must be submitted to the MMO. The need for further surveys must be agreed in writing with the MMO following submission of the first year of survey data.

Commencement Information

I68Sch. 8 para. 15 in force at 7.9.2016, see art. 1(2)

Offshore decommissioningE+W+S

16.—(1) No decommissioning activities may commence until a plan for the carrying out of the activities has been submitted to and approved in writing by the MMO.

(2) The plan must be submitted for approval at least 4 months before the intended start of the decommissioning activities, except where otherwise stated or unless otherwise agreed in writing by the MMO.

(3) The plan must be implemented as approved.

Commencement Information

I69Sch. 8 para. 16 in force at 7.9.2016, see art. 1(2)

Amendments to approved plans, etc.E+W+S

17.—(1) Where any Condition requires the licensed activities to be carried out in accordance with any plan, programme, code, statement, protocol, scheme or details (the “plan”) approved by the MMO, the approved plan must be taken to include any amendment to the plan that may subsequently be approved in writing by the MMO.

(2) Any amendment to the plan must be in accordance with the principles and assessments set out in the environmental statement, and approval for an amendment may be given only where it has been demonstrated to the satisfaction of the MMO that the amendment is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I70Sch. 8 para. 17 in force at 7.9.2016, see art. 1(2)

Articles 2 and 36

SCHEDULE 9E+W+SMarine Licence A2: Project A – Transmission Assets

PART 1E+W+SLicensed activities

InterpretationE+W+S

1.—(1) In this licence—

“2008 Act” means the Planning Act 2008;

“2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works described in clause 2 of Part 1 of this licence that are not development within the meaning of section 32 of the 2008 Act;

“Annex 1 habitat” means a habitat set out in Annex 1 to Council Directive 92/43/EEC of 21st May 1992 on the conservation of natural habitats and of wild fauna and flora;

“authorised deposits” means the substances and articles specified in clause 2(3) of Part 1 of this licence;

“authorised development” means the development described in Part 1 of Schedule 1 to the Order that is development within the meaning of section 32 of the 2008 Act;

“authorised project” means the authorised development and the ancillary works authorised by the Order;

“authorised scheme” means Work Nos. 2A, 3A, 4A and 5A described in clause 2 of Part 1 of this licence;

“Cefas” means the Centre for Environment, Fisheries and Aquaculture Science or any replacement body;

“commence” means the first carrying out of any part of the licensed activities, except for pre-construction surveys and monitoring; and “commencement” must be construed accordingly;

“Condition” means a condition set out in Part 2 of this licence;

“construction vessel” means any vessel involved in the course of or used for the construction and/or maintenance of the authorised project;

“debris” means items or equipment of a significant size left on the seabed being lost from survey or construction vessels or the structures comprised within the authorised scheme;

“EIA Regulations” means the Infrastructure Planning (Environmental Impact Assessment) Regulations 2009;

“electrical circuit” means a number of electrical conductors necessary to transmit electricity between 2 points within the authorised project, comprising—

(a)

in the case of HVAC transmission, 3 conductors which may be bundled as 1 cable; and

(b)

in the case of HVDC transmission, 2 conductors, which may be attached together or take the form of single cables,

and the electrical circuit may include 1 or more auxiliary cables (normally fibre-optic cables) for the purpose of control, monitoring, protection or general communications;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of Part 4 of the 2009 Act;

“environmental statement” means the document certified as the environmental statement by the Secretary of State under article 40 of the Order;

“gravity base foundation” means—

(a)

a structure principally of concrete or steel (or both) that rests on the seabed due to its own weight and that of added ballast or to the weight of water above it and may include associated equipment including suction piles, J-tubes and access platforms; or

(b)

a structure principally of concrete or steel (or both) consisting of a platform supported on 2 pontoons to which the platform is connected by columns which may be connected by braces;

“high tide” means the state of the tide when it reaches its highest level during a tidal cycle, as may be published from time to time on the UK Hydrographic Office Admiralty EasyTide Website or such other publication as may be approved by the MMO;

“HVAC” means high voltage alternating current;

“HVDC” means high voltage direct current;

“in-principle monitoring plan” means the document certified as the in-principle monitoring plan by the Secretary of State under article 40 of the Order;

“intertidal area” means the area between MHWS and MLWS;

“intertidal works plans” means the part of the works plans described as the intertidal works plans;

“jacket foundation” means a lattice construction comprising tubular members and joints fixed to the seabed with piles (either driven/drilled piles or suction piles) which will include platforms and J-tubes and may include braced monopiles and a transition piece;

“Kingfisher Fortnightly Bulletin” means the bulletin published by the Humber Seafood Institute or such other alternative publication approved in writing by the MMO;

“LAT” means lowest astronomical tide;

“licensed activities” means the activities specified in Part 1 of this licence;

“maintain”, unless otherwise provided for, includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development; and any derivative of “maintain” must be construed accordingly;

“major storm event” means a greater than 1 in 10 year wave event within the offshore Order limits seaward of MHWS in terms of wave height, measured by reference to the height of waves recorded at the nearest wave buoy to the authorised scheme as agreed with the MMO and the WaveNet data published by Cefas, or such other means of measurement as may be agreed with the MMO;

“Marine Noise Registry” means the online database maintained by the Joint Nature Conservation Committee on behalf of the Department for Environment, Food and Rural Affairs that records the spatial and temporal distribution of impulsive noise-generating activities in UK seas in order that they can be analysed to determine whether they may potentially compromise the achievement of good environmental status;

“MCA” means the Maritime and Coastguard Agency;

“MHWS” (mean high water springs) means the highest level which spring tides reach on average over a period of time;

“MLWS” (mean low water springs) means the lowest level which spring tides reach on average over a period of time;

“MMO” means the Marine Management Organisation;

“monopile foundation” means a foundation comprising a large diameter steel or concrete tube or pile driven vertically into the seabed, J-tubes and platforms and may include external structural devices such as bracing members or steel anchor wires and a transition piece;

“notice to mariners” includes any notice to mariners which may be issued by Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore HVAC collector substation” means a structure serving as a collection point for the intra-array electrical circuits and containing equipment for the purpose of transforming the electricity generated at the wind turbine generators to a higher voltage; it may also include a helicopter platform;

“offshore HVDC converter substation” means a structure that contains equipment to convert HVAC electricity to HVDC electricity; it may also include a helicopter platform;

“offshore Order limits” means the limits shown on the offshore works plans and the intertidal works plans within which the authorised scheme may be carried out whose grid co-ordinates are set out in clause 2(2) of Part 1 of this licence;

“offshore reactive compensation substation” means a structure housing electrical reactors for the purpose of limiting electrical losses in the course of HVAC transmission by providing reactive compensation; it may also include a helicopter platform;

“offshore works plans” means the part of the works plans described as the offshore works plans;

“Order” means the Hornsea Two Offshore Wind Farm Order 2016;

“Order limits” means the limits shown on the works plans within which the authorised project may be carried out;

“suction pile” means a large diameter steel cylinder that is fixed to the base of the foundation, partially penetrates the seabed and remains in place using its weight and hydrostatic pressure differential;

“survey vessel” means a vessel licensed to carry out environmental or engineering surveys;

“Trinity House” means the Corporation of Trinity House of Deptford Strond;

“UK Hydrographic Office” means the Hydrographic Office of the Ministry of Defence or any replacement body or successor to its functions;

“undertaker” means Optimus Wind Limited (company number 07883284) or, to the extent that the benefit of the provisions of the Order and related statutory rights in relation to Work Nos. 2A, 3A, 4A or 5A and such associated development or ancillary works has been transferred under article 35 of the Order to another person, that other person;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water that is at the time in, on or over water;

“wind turbine generator” means a structure comprising any or all of a tower, rotor, blades, nacelle and ancillary electrical and other equipment or structures, which may include lighting and a helicopter platform, fixed to a foundation;

“working day” means any day other than a Saturday, Sunday or public holiday in England and Wales;

“Work No. 2A” means the works described as Work No. 2A in clause 2 of Part 1 of this licence;

“Work No. 2B” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“Work No. 3A” means the works described as Work No. 3A in clause 2 of Part 1 of this licence;

“Work No. 3B” means up to 2 offshore reactive compensation substations fixed to the seabed in the event that the mode of transmission is HVAC;

“Work No. 4A” means the works described as Work No. 4A in clause 2 of Part 1 of this licence;

“Work No. 4B” means a marine connection to the shore, including cable and pipeline crossing works which—

(a)

if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2B via and connecting with the offshore reactive compensation substation comprised in Work No. 3B; or

(b)

if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2B,

and in either case terminating at Work No. 5B;

“Work No. 5A” means the works described as Work No. 5A in clause 2 of Part 1 of this licence;

“Work No. 5B” means a foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4B, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays comprising Work No. 6B;

“Work No. 6A” means up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5A and the onshore electrical circuits;

“Work No. 6B” means up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5B and the onshore electrical circuits;

“works plans” means the plans certified as the works plans by the Secretary of State under article 40 of the Order, comprising the offshore works plans, the intertidal works plans and the onshore works plans.

(2) A reference to any statute, order, regulation or similar instrument must be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a)all times are Greenwich Mean Time (GMT);

(b)all co-ordinates are latitude and longitude degrees, minutes and seconds to 3 decimal places in WGS84 Datum.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence is—

(a)Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle-upon-Tyne NE4 7YH

Tel: 0300 123 1032

E-mail: marine.consents@marinemanagement.org.uk

(b)Marine Management Organisation (referred to as the “MMO Coastal Office”)

Neville House

Central Riverside

Bell Street

North Shields

Tyne and Wear NE30 1LJ

Tel (24-hour answer phone): 0191 257 4520 or 0191 257 0159

E-mail: northshields@marinemanagement.org.uk

(c)Trinity House

Tower Hill

London EC3N 4DH

Tel: 020 7481 6900

(d)The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset TA1 2DN

Tel: 01823 337 900

(e)Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton SO15 1EG

Tel: 023 8032 9191

(f)Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk NR33 0HT

Tel: 01502 562 244

(g)Natural England

Foss House

Kings Pool

1-2 Peasholme Green

York YO1 7PX

Tel: 0300 060 1911

(h)Historic Buildings and Monuments Commission for England (referred to as “Historic England”)

Eastgate Court

195-205 High Street

Guildford GU1 3EH

Tel: 01483 252 057

(i)Environment Agency

Waterside House

Waterside North

Lincoln LN2 5HA

Tel: 03708 506 506.

Commencement Information

I71Sch. 9 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

Details of licensed activitiesE+W+S

2.—(1) This licence authorises the undertaker (and any agent or contractor acting on its behalf) to carry out the following licensable marine activities pursuant to section 66(1) of the 2009 Act, subject to the Conditions—

(a)the deposit at sea of the substances and articles specified in paragraph (3);

(b)the construction of works in or over the sea and/or on or under the sea bed;

(c)dredging for the purposes of seabed preparation for foundation works and/or electrical circuit works;

(d)the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation;

(e)the disposal at disposal site reference HU211 of up to 324,454 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 2A, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 2A and 2B disposed of at disposal site reference HU211 must not exceed 324,454 cubic metres;

(f)the disposal at disposal site reference HU211 of up to 92,048 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 2A and 4A, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 2A, 2B, 4A and 4B disposed of at disposal site reference HU211 must not exceed 92,048 cubic metres;

(g)the disposal at disposal site reference HU209 of up to 38,485 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 3A, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 3A and 3B disposed of at disposal site reference HU209 must not exceed 38,485 cubic metres;

(h)the disposal at disposal site reference HU209 of up to 1,269,000 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 4A, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 4A and 4B disposed of at disposal site reference HU209 must not exceed 1,269,000 cubic metres;

(i)the disposal at disposal site reference HU210 of up to 131,000 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 4A, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 4A and 4B disposed of at disposal site reference HU210 must not exceed 131,000 cubic metres; and

(j)the removal of the substances and articles specified in paragraph (3).

(2) The activities are authorised in relation to the construction, maintenance and operation of—

Work No. 2A — Up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B, provided that—

(a)the combined total of offshore HVAC collector substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 6; and

(b)the combined total of offshore HVDC converter substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 2.

Co-ordinates for wind farm area (limits of deviation for Work No. 2A)—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

Work No. 3A — In the event that the mode of transmission is HVAC, up to 2 offshore reactive compensation substations fixed to the seabed at latitude point 53° 37′ 54.291″ N and longitude point 0° 55′ 59.731″ E and at latitude point 53° 38′ 9.295″ N and longitude point 0° 55′ 49.576″ E subject to deviation within the following limits of deviation, provided that the combined total of offshore reactive compensation substations constructed in whole or in part within Work Nos. 3A and 3B must not exceed 2—

PointLatitudeLongitude
153° 38′ 1.918″ N0° 55′ 55.183″ E
253° 38′ 2.362″ N0° 55′ 58.099″ E
353° 38′ 2.438″ N0° 56′ 0.367″ E
453° 38′ 2.185″ N0° 56′ 3.394″ E
553° 38′ 1.735″ N0° 56′ 5.560″ E
653° 38′ 1.074″ N0° 56′ 7.567″ E
753° 37′ 59.900″ N0° 56′ 9.900″ E
853° 37′ 58.446″ N0° 56′ 11.733″ E
953° 37′ 57.216″ N0° 56′ 12.723″ E
1053° 37′ 55.456″ N0° 56′ 13.477″ E
1153° 37′ 54.094″ N0° 56′ 13.597″ E
1253° 37′ 52.296″ N0° 56′ 13.156″ E
1353° 37′ 51.011″ N0° 56′ 12.387″ E
1453° 37′ 49.821″ N0° 56′ 11.266″ E
1553° 37′ 48.441″ N0° 56′ 9.279″ E
1653° 37′ 47.358″ N0° 56′ 6.825″ E
1753° 37′ 46.776″ N0° 56′ 4.750″ E
1853° 37′ 46.409″ N0° 56′ 2.540″ E
1953° 37′ 46.268″ N0° 56′ 0.258″ E
2053° 37′ 46.357″ N0° 55′ 57.969″ E
2153° 37′ 46.828″ N0° 55′ 55.017″ E
2253° 37′ 47.678″ N0° 55′ 52.316″ E
2353° 37′ 48.540″ N0° 55′ 50.538″ E
2453° 37′ 49.567″ N0° 55′ 49.029″ E
2553° 37′ 51.143″ N0° 55′ 47.509″ E
2653° 37′ 52.881″ N0° 55′ 46.618″ E
2753° 37′ 54.238″ N0° 55′ 46.392″ E
2853° 37′ 56.046″ N0° 55′ 46.691″ E
2953° 37′ 57.351″ N0° 55′ 47.359″ E
3053° 37′ 58.570″ N0° 55′ 48.386″ E
3153° 38′ 0.004″ N0° 55′ 50.262″ E
3253° 38′ 1.153″ N0° 55′ 52.630″ E
3353° 38′ 1.792″ N0° 55′ 54.657″ E
3453° 38′ 1.346″ N0° 55′ 51.708″ E
3553° 38′ 1.300″ N0° 55′ 48.665″ E
3653° 38′ 1.657″ N0° 55′ 45.681″ E
3753° 38′ 2.399″ N0° 55′ 42.906″ E
3853° 38′ 3.490″ N0° 55′ 40.477″ E
3953° 38′ 5.257″ N0° 55′ 38.112″ E
4053° 38′ 6.910″ N0° 55′ 36.872″ E
4153° 38′ 8.684″ N0° 55′ 36.281″ E
4253° 38′ 10.939″ N0° 55′ 36.497″ E
4353° 38′ 12.244″ N0° 55′ 37.130″ E
4453° 38′ 13.467″ N0° 55′ 38.122″ E
4553° 38′ 15.233″ N0° 55′ 40.491″ E
4653° 38′ 16.080″ N0° 55′ 42.277″ E
4753° 38′ 16.738″ N0° 55′ 44.277″ E
4853° 38′ 17.187″ N0° 55′ 46.433″ E
4953° 38′ 17.441″ N0° 55′ 49.447″ E
5053° 38′ 17.365″ N0° 55′ 51.746″ E
5153° 38′ 16.908″ N0° 55′ 54.716″ E
5253° 38′ 16.068″ N0° 55′ 57.438″ E
5353° 38′ 15.210″ N0° 55′ 59.234″ E
5453° 38′ 13.812″ N0° 56′ 1.201″ E
5553° 38′ 12.609″ N0° 56′ 2.302″ E
5653° 38′ 10.868″ N0° 56′ 3.211″ E
5753° 38′ 9.507″ N0° 56′ 3.449″ E
5853° 38′ 8.141″ N0° 56′ 3.296″ E
5953° 38′ 6.381″ N0° 56′ 2.496″ E
6053° 38′ 4.772″ N0° 56′ 1.053″ E
6153° 38′ 3.714″ N0° 55′ 59.591″ E
6253° 38′ 2.560″ N0° 55′ 57.217″ E

Work No. 4A — A marine connection to the shore, including cable and pipeline crossing works which—

(a)if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2A via and connecting with the offshore reactive compensation substations comprised in Work No. 3A; or

(b)if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2A,

and in either case terminating at Work No. 5A, provided that the combined total of electrical circuits constructed in whole or in part within Work Nos. 4A and 4B must not exceed, in the event that the mode of transmission is HVDC, 2, and in the event that the mode of transmission is HVAC, 8.

Principal co-ordinates for marine export cable area (limits of deviation for Work No. 4A) whose full co-ordinates are set out in the offshore works plans—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 46′ 7.286″ N1° 38′ 16.673″ E
2553° 46′ 4.677″ N1° 37′ 22.711″ E
2753° 44′ 47.813″ N1° 28′ 38.495″ E
3253° 44′ 47.743″ N1° 27′ 26.607″ E
3453° 44′ 36.477″ N1° 25′ 23.743″ E
14153° 42′ 30.629″ N1° 15′ 58.654″ E
15253° 42′ 28.182″ N1° 14′ 34.895″ E
26453° 39′ 35.134″ N1° 6′ 29.785″ E
31653° 38′ 17.582″ N1° 2′ 16.928″ E
44753° 36′ 54.624″ N0° 51′ 31.062″ E
44953° 36′ 15.738″ N0° 48′ 52.425″ E
51353° 35′ 21.166″ N0° 43′ 44.242″ E
51553° 31′ 50.425″ N0° 40′ 55.898″ E
51653° 31′ 38.281″ N0° 40′ 8.340″ E
52153° 28′ 36.676″ N0° 20′ 3.846″ E
53253° 31′ 43.122″ N0° 12′ 21.707″ E
53353° 30′ 57.432″ N0° 5′ 59.890″ E
53453° 31′ 11.028″ N0° 5′ 42.539″ E
53553° 30′ 42.954″ N0° 5′ 10.787″ E
53653° 30′ 42.180″ N0° 5′ 9.912″ E
53753° 30′ 46.588″ N0° 4′ 55.345″ E
53853° 30′ 52.245″ N0° 4′ 59.515″ E
53953° 31′ 25.514″ N0° 5′ 24.049″ E
54053° 31′ 29.574″ N0° 5′ 27.043″ E
58053° 32′ 16.976″ N0° 12′ 37.072″ E
76353° 29′ 11.523″ N0° 20′ 5.981″ E
100153° 31′ 28.589″ N0° 35′ 44.348″ E
100253° 32′ 0.855″ N0° 37′ 42.781″ E
100353° 32′ 17.793″ N0° 39′ 31.883″ E
100453° 32′ 35.749″ N0° 39′ 45.737″ E
100553° 33′ 8.117″ N0° 39′ 47.665″ E
100653° 34′ 28.861″ N0° 41′ 27.396″ E
100753° 35′ 42.522″ N0° 42′ 37.802″ E
101053° 36′ 25.571″ N0° 43′ 54.129″ E
108153° 37′ 2.569″ N0° 47′ 31.846″ E
108353° 37′ 30.986″ N0° 49′ 14.023″ E
108653° 37′ 29.991″ N0° 51′ 27.606″ E
108753° 37′ 36.904″ N0° 52′ 22.841″ E
111153° 38′ 45.654″ N0° 57′ 1.237″ E
114353° 39′ 16.652″ N1° 1′ 1.016″ E
114953° 39′ 42.566″ N1° 1′ 40.167″ E
115553° 41′ 20.037″ N1° 6′ 45.836″ E
115753° 42′ 59.843″ N1° 14′ 18.127″ E
116453° 43′ 0.151″ N1° 15′ 37.960″ E
116553° 44′ 0.963″ N1° 20′ 9.157″ E
116653° 49′ 6.492″ N1° 25′ 51.682″ E
116753° 50′ 7.210″ N1° 26′ 59.953″ E

Work No. 5A — A foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4A, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays (Work No. 6A).

And in connection with Work Nos. 2A, 3A, 4A and 5A, further associated development as may be necessary or expedient in connection with the authorised scheme within the Order limits and is within the scope of the environmental impact assessment recorded in the environmental statement.

And in connection with Work Nos. 2A, 3A, 4A and 5A, ancillary works consisting of works and operations within the Order limits comprising temporary anchorage of vessels and buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) The substances or articles authorised for deposit at sea and removal are—

(a)iron and steel;

(b)stone and rock;

(c)concrete;

(d)sand and gravel;

(e)plastic and synthetic; and

(f)material extracted from within the offshore Order limits during construction drilling and seabed preparation for foundation works and cable sandwave preparation works.

(4) The grid co-ordinates for disposal site reference HU211 are—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

(5) The grid co-ordinates for disposal site reference HU209 are—

PointLatitudeLongitude
A53° 36′ 40.490″ N0° 50′ 41.571″ E
B53° 36′ 54.624″ N0° 51′ 31.062″ E
C53° 37′ 22.048″ N0° 55′ 08.301″ E
D53° 37′ 38.643″ N0° 57′ 17.843″ E
E53° 37′ 56.680″ N0° 59′ 39.524″ E
F53° 38′ 15.917″ N1° 02′ 08.601″ E
G53° 39′ 35.134″ N1° 06′ 29.785″ E
H53° 41′ 22.549″ N1° 11′ 30.804″ E
I53° 42′ 14.598″ N1° 10′ 44.250″ E
J53° 41′ 19.717″ N1° 06′ 44.682″ E
K53° 39′ 41.954″ N1° 01′ 38.714″ E
L53° 39′ 16.652″ N1° 01′ 01.016″ E
M53° 38′ 45.654″ N0° 57′ 01.237″ E
N53° 37′ 36.904″ N0° 52′ 22.841″ E
O53° 37′ 29.991″ N0° 51′ 27.606″ E
P53° 37′ 30.124″ N0° 50′ 57.716″ E

(6) The grid co-ordinates for disposal site reference HU210 are—

PointLatitudeLongitude
W53° 43′ 14.348″ N1° 19′ 13.563″ E
X53° 43′ 52.989″ N1° 22′ 07.248″ E
Y53° 44′ 22.957″ N1° 21′ 47.484″ E
Z53° 43′ 44.110″ N1° 18′ 53.902″ E

(7) Section 72 of the 2009 Act applies to this licence, except that subsections (7) and (8) relating to the transfer of the licence apply only to a transfer not falling within article 35 of the Order.

Commencement Information

I72Sch. 9 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

Maintenance of authorised projectE+W+S

3.—(1) The undertaker may at any time maintain the authorised project, except to the extent that this licence or an agreement made under this licence provides otherwise.

(2) No maintenance works whose likely effects on the environment require to be assessed in accordance with the EIA Regulations and are not assessed in the environmental statement may be carried out, unless otherwise approved by the MMO.

(3) Where the MMO’s approval is required under paragraph (2), approval may be given only where it has been demonstrated to the satisfaction of the MMO that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I73Sch. 9 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

DurationE+W+S

4.  This licence remains in force until the authorised scheme has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the Energy Act 2004, including any modification to the programme under section 108, and the completion of the programme has been confirmed by the Secretary of State in writing.

Commencement Information

I74Sch. 9 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SLicence conditions

Design parametersE+W+S

1.—(1) No offshore HVAC collector substation forming part of Work No. 2A may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(2) No offshore HVDC converter substation forming part of Work No. 2A may—

(a)exceed 110 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 16,200 square metres in area or 180 metres in width.

(3) The offshore reactive compensation substation comprised in Work No. 3A must not—

(a)exceed 64 metres in height above LAT; or

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(4) The diameter of the electrical cables comprising the electrical circuits must not exceed—

(a)within Work No. 2A, 300 millimetres;

(b)within Work Nos. 4A and 5A—

(i)190 millimetres, where the mode of transmission is HVDC; and

(ii)300 millimetres, where the mode of transmission is HVAC.

(5) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 2A and 2B must not exceed 300 kilometres.

(6) The combined total length of the electrical circuits comprised in Work Nos. 4A, 4B, 5A and 5B seaward of MHWS must not exceed 1,200 kilometres.

(7) The combined total area of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 546,000 square metres.

(8) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 2,055,200 square metres.

(9) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 44,800 square metres.

(10) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 312,000 cubic metres.

(11) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 1,174,400 cubic metres.

(12) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 25,600 cubic metres.

(13) The electrical circuits comprised in Work Nos. 2A and 4A must be installed by use of, or a combination of, ploughing, trenching, jetting, rock-cutting, dredging, surface laying with post-lay burial, and where ground conditions make burial impracticable, by surface laying.

(14) The electrical circuits comprised in Work No. 5A must be installed by use of, or a combination of, ploughing, trenching and jetting, with the exception that, where the electrical circuits comprised in Work No. 5A cross under the existing sea wall, they must be installed using a trenchless technique.

Commencement Information

I75Sch. 9 Pt. 2 para. 1 in force at 7.9.2016, see art. 1(2)

2.—(1) The undertaker must in fixing to the seabed any structures comprised in Work Nos. 2A and 3A use one of the following methods—

(a)monopile foundations;

(b)jacket foundations supported by piles; or

(c)gravity base foundations.

(2) The undertaker must not use the monopile foundation method or any other method that includes braced monopiles to fix to the seabed any offshore HVDC converter substation.

(3) The following parameters apply in respect of the foundation methods used to fix offshore HVAC collector substations to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,924 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3.5 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 12,723 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(4) The following parameters apply in respect of the foundation methods used to fix offshore HVDC converter substations to the seabed—

(a)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 17,318 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 72;

(iv)the number of piles per jacket must not exceed 18;

(v)the diameter of each pile must not exceed 3.5 metres;

(b)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 50,894 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 32;

(iv)the number of piles per jacket must not exceed 8;

(v)the diameter of each pile must not exceed 15 metres;

(c)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 27,300 square metres;

(ii)the number of pontoons for each individual structure must not exceed 3;

(iii)the pontoons must not exceed 170 metres in length or 35 metres in width.

(5) The following parameters apply in respect of the foundation methods used to fix the offshore reactive compensation substation to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,414 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

Commencement Information

I76Sch. 9 Pt. 2 para. 2 in force at 7.9.2016, see art. 1(2)

Navigational practice, safety and emergency responseE+W+S

3.—(1) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has given written approval for an emergency response co-operation plan which includes full details of the emergency co-operation plans for the construction, operation and decommissioning phases of that part of the authorised scheme in accordance with the MCA recommendations contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

(2) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and, so far as is applicable to that stage of the development, adequately addressed all MCA recommendations as appropriate to the authorised scheme contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” (including its annexes).

(3) The emergency response co-operation plan must be implemented as approved, unless otherwise agreed in writing by the MMO, in consultation with the MCA.

Commencement Information

I77Sch. 9 Pt. 2 para. 3 in force at 7.9.2016, see art. 1(2)

Aids to navigationE+W+S

4.—(1) The undertaker must during the whole period from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning—

(a)exhibit such lights, marks, sounds, signals and other aids to navigation and take such other steps for the prevention of danger to navigation as Trinity House may from time to time direct;

(b)colour all structures in the authorised scheme as directed by Trinity House;

(c)keep Trinity House and the MMO informed of progress of the authorised scheme seaward of MHWS including—

(i)notice of commencement of construction of the authorised scheme within 24 hours of commencement having occurred;

(ii)notice within 24 hours of any aids to navigation being established by the undertaker; and

(iii)notice within 5 working days of completion of construction of the authorised scheme;

(d)submit reports to Trinity House detailing the working condition of aids to navigation quarterly, or as requested by Trinity House;

(e)notify Trinity House and the MMO of any failure of the aids to navigation and the timescales and plans for remedying such failures as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

(2) Except as otherwise required by Trinity House under paragraph (1), the undertaker must colour all structures comprised in Work Nos. 2A and 3A yellow (colour code RAL 1023) from at least highest astronomical tide to a height as directed by Trinity House.

(3) Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

Commencement Information

I78Sch. 9 Pt. 2 para. 4 in force at 7.9.2016, see art. 1(2)

Notifications and inspectionsE+W+S

5.—(1) The undertaker must ensure that—

(a)a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i)all agents and contractors notified to the MMO in accordance with the Conditions; and

(ii)the masters and transport managers responsible for the vessels notified to the MMO in accordance with the Conditions;

(b)within 28 days of receipt of a copy of this licence, the persons referred to in sub-paragraph (a) provide a completed confirmation form to the MMO confirming their understanding of the terms and conditions of this licence.

(2) Only the persons and vessels notified to the MMO in accordance with Condition 11 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection at the following locations—

(a)the undertaker’s registered address;

(b)any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit for the authorised deposits; and

(c)on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made.

(4) The documents referred to in paragraph (1)(a) must be available for inspection by an enforcement officer at the locations set out in paragraph (3) at any time.

(5) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or any other associated works or vessels to facilitate any inspection that the MMO considers necessary to inspect the works during construction and operation of the authorised scheme.

(6) The undertaker must inform the MMO Marine Licensing Team and the MMO Coastal Office in writing at least 5 working days before the commencement of the licensed activities or any part of them.

(7) The Kingfisher Information Service of Seafish must be informed by email of details of the vessel routes, timings and locations relating to the construction of the authorised scheme or relevant part to kingfisher@seafish.co.uk—

(a)at least 2 weeks before the construction of the authorised scheme or relevant part, for inclusion in the Kingfisher Fortnightly Bulletin and offshore hazard awareness data; and

(b)on completion of the construction of the authorised scheme or relevant part.

Confirmation of notification must be provided to the MMO within 5 working days of notification to the Kingfisher Information Service of Seafish.

(8) The undertaker must ensure that a notice to mariners is issued at least 10 working days before the commencement of the licensed activities advising of the commencement of licensed activities within the offshore Order limits and the expected vessel routes from the local service ports to the location of the works comprised within the authorised scheme.

(9) The undertaker must ensure that the notices to mariners are updated and reissued at weekly intervals during construction activities and at least 5 days before any planned operation and maintenance works and supplemented with VHF radio broadcasts agreed with the MCA in accordance with the construction and monitoring programme approved under Condition 8(2)(a). Copies of all notices must be provided to the MMO within 10 working days of issue.

(10) The undertaker must notify—

(a)the UK Hydrographic Office of commencement (within 2 weeks), progress and completion (within 2 weeks) of the authorised scheme in order that all necessary amendments to nautical charts are made, and the undertaker must send a copy of such notifications to the MMO; and

(b)the Defence Geographic Centre (at least 4 weeks before) of the commencement of the authorised scheme, and of the progress and completion (within 2 weeks) of the authorised scheme, in order that all necessary amendments to aviation charts are made.

(11) In case of damage to, or destruction or decay of, the authorised scheme or any part of it seaward of MHWS, the undertaker must as soon as reasonably practicable, and no later than 24 hours following the undertaker becoming aware of any such damage, destruction or decay, notify the MMO, Trinity House, MCA and the UK Hydrographic Office.

(12) In the event that the Marine Noise Registry has gone live before the commencement of impact pile driving—

(a)the undertaker must submit details of the expected location, start and end dates of impact pile driving to the Marine Noise Registry before the commencement of the impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

(13) In the event that the Marine Noise Registry has gone live at the time of impact pile driving—

(a)the undertaker must submit the exact locations and dates of impact pile driving to the Marine Noise Registry at 6-month intervals from the commencement of impact pile driving until the completion of impact pile driving. The final data must be submitted within 12 weeks of completion of impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

Commencement Information

I79Sch. 9 para. 5 in force at 7.9.2016, see art. 1(2)

Chemicals, drilling and debrisE+W+S

6.—(1) All chemicals used in the construction of the authorised scheme must be selected from the list of notified chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002, unless otherwise agreed in writing by the MMO.

(2) The undertaker must ensure that any coatings or treatments are suitable for use in the marine environment and are used in accordance with guidelines approved by Health and Safety Executive or the Environment Agency Pollution Prevention Guidelines.

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110% of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences, which disposal may also require a marine licence.

(5) The undertaker must ensure that, where practicable, any debris arising from the construction of the authorised scheme or temporary works placed seaward of MHWS is removed by a date no later than 28 days following the undertaker becoming aware of the debris after the completion of the authorised scheme (or by such later date as may be agreed in writing by the MMO). In the event that the debris cannot practicably be removed, the undertaker must notify the MMO, Trinity House and the MCA within 7 days of becoming aware that the debris cannot practicably be removed.

(6) At least 10 days before the commencement of the licensed activities, the undertaker must submit to the MMO an audit sheet covering all aspects of the construction of the authorised scheme, and no works may commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a)loading facilities;

(b)vessels;

(c)equipment;

(d)shipment routes;

(e)working schedules; and

(f)all components and materials to be used in the construction of the authorised scheme.

(7) The audit sheet must be maintained throughout the construction of the authorised scheme, and the MMO must be notified of any changes on a fortnightly basis.

(8) In the event that the undertaker becomes aware that any of the materials on the audit sheet cannot be accounted for, it must notify the MMO within 24 hours where possible, and in any event within 5 days of becoming aware using the dropped object procedure form. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so. Local fishermen must be invited to send a representative to be present during the survey. The MMO may require any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(9) All debris arising from the operation and maintenance of the authorised scheme must be reported to the MMO using the dropped object procedure form within 24 hours where possible, and in any event within 5 days of the undertaker becoming aware of the incident. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so and any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(10) The undertaker must inform the MMO of the location and quantities of inert material and dredged material disposed of each month under this licence at each of disposal site reference HU211, disposal site reference HU209 and disposal site reference HU210, by submission of a disposal return for each disposal area by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(11) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 2A;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 2A; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 2A and Work No. 4A,

is disposed of at disposal site reference HU211.

(12) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 3A;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 3A; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 4A,

is disposed of at disposal site reference HU209.

(13) The undertaker must ensure that only inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 4A is disposed of at disposal site reference HU210.

(14) The undertaker must ensure that no waste concrete slurry or wash water from concrete or cement works are discharged into the marine environment. Concrete, cement mixing and washing areas must be contained to prevent run-off entering the water through the freeing ports.

(15) The undertaker must ensure that any rock material used in the construction of the authorised scheme is from a recognised source, free from contaminants and containing minimal fines.

(16) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU211.

(17) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU209.

(18) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU210.

Commencement Information

I80Sch. 9 para. 6 in force at 7.9.2016, see art. 1(2)

Force majeureE+W+S

7.  If, due to stress of weather or any other cause, the master of a vessel determines that it is necessary to deposit—

(a)authorised deposits outside of the offshore Order limits or disposal site references HU209, HU210 or HU211; or

(b)unauthorised deposits within or outside of the offshore Order limits or disposal site references HU209, HU210 or HU211,

because the safety of human life and/or of the vessel is threatened, full details of the circumstances of the deposit must be notified to the MMO within 48 hours.

Commencement Information

I81Sch. 9 para. 7 in force at 7.9.2016, see art. 1(2)

Pre-construction plans and documentationE+W+S

8.—(1) The licensed activities may not commence until a plan setting out proposed details of the authorised scheme and including the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO following appropriate consultation with Trinity House and the MCA—

(a)number, dimensions, specification, foundation types and depth for each offshore HVAC collector substation, offshore HVDC converter substation and offshore reactive compensation substation;

(b)grid co-ordinates of the centre point of the proposed location for each offshore HVAC collector substation, offshore HVDC converter substation and offshore reactive compensation substation, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions;

(c)proposed layout of all cables, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions; and

(d)location and specification of all other aspects of the authorised scheme, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions.

(2) The licensed activities, or any phase of those activities, may not commence until a code of construction practice incorporating the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO—

(a)a construction and monitoring programme, to include details of—

(i)the proposed construction start date;

(ii)proposed timings for mobilisation of plant, delivery of materials and installation works; and

(iii)proposed pre-construction surveys, baseline report format and content, construction monitoring, post-construction monitoring and related reporting in accordance with Conditions 13, 14 and 15. The pre-construction survey programme and all pre-construction survey methodologies must be submitted to the MMO for written approval by the MMO in consultation with the relevant statutory nature conservation body at least 4 months before the commencement of any survey works detailed within;

(b)a construction method statement in accordance with the environmental statement, including details of—

(i)foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii)installation of offshore HVAC collector substations, offshore HVDC converter substations and offshore reactive compensation substations, including any seabed preparation and scour protection;

(iii)circuit installation, including any seabed preparation and circuit protection;

(iv)contractors;

(v)vessels; and

(vi)associated works;

(c)a project environmental management and monitoring plan, to include details of—

(i)a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised scheme in relation to all activities carried out seaward of MHWS. The plan must include a mechanism for reporting oil, fuel and chemical spills to the MMO Marine Pollution Response Team;

(ii)a chemical risk analysis to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii)a disposal plan detailing the locations, methods and timings of dredging and disposal, as well as disposal site monitoring requirements;

(iv)waste management and disposal arrangements;

(v)locations of any archaeological exclusion zones agreed as part of the written scheme of archaeological investigation approved under sub-paragraph (g);

(vi)any seasonal restrictions on construction works; and

(vii)the appointment and responsibilities of a fisheries liaison officer, an environmental liaison officer and an intertidal ecological clerk of works;

(d)a scour protection management and cable armouring plan providing details of the need, type, sources, quantity, location and installation methods for scour protection and cable armouring to be within the scope of the environmental impact assessment recorded in the environmental statement;

(e)in the event that driven or part-driven pile foundations are proposed to be used, a marine mammal mitigation protocol, the intention of which is to prevent injury and/or significant disturbance to marine mammals, following current best practice as advised by the statutory nature conservation bodies, which may include, but is not limited to—

(i)identification of a marine mammal mitigation zone (“MMMZ”);

(ii)appointment of an appropriate number of suitably qualified marine mammal observers;

(iii)methods for the detection of marine mammals within the MMMZ whether visually (by the marine mammal observers) or acoustically using passive acoustic monitoring equipment or other means of detection;

(iv)a reporting methodology to enable efficient communication between the marine mammal observers and the person responsible for approving commencement of piling;

(v)an appropriate soft start procedure whereby piling activities do not commence until an agreed time has elapsed and during which marine mammals have not been detected within the MMMZ;

(vi)where appropriate, methods for the application of acoustic deterrent devices; and

(vii)where appropriate, consideration of the use of noise reduction at source technologies;

(f)a cable specification and installation plan, to include—

(i)technical specification of offshore electrical circuits, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice;

(ii)a detailed cable laying plan, including geotechnical data, cable laying techniques and a cable burial risk assessment encompassing the identification of any cable protection that exceeds 5% of navigable depth referenced to Chart Datum and, in the event that any area of cable protection exceeding 5% of navigable depth is identified, details of any steps (to be determined following consultation with the MCA) to be taken to ensure existing and future safe navigation is not compromised;

(iii)details of the steps to be taken, where the offshore electrical circuits across the intertidal area are buried using trenching or ploughing to ensure that the excavation and subsequent backfilling is carried out in such a way as to maintain the sediment profile so far as is reasonably practicable; and

(iv)details of the steps to be taken, where the offshore electrical circuits across the intertidal area are installed using a trenchless technique;

(g)a written scheme of archaeological investigation in relation to the offshore Order limits seaward of MHWS in accordance with industry good practice, to include—

(i)details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii)a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver- or remotely-operated vehicle investigations;

(iii)analysis and reporting of survey data to be submitted to the MMO within 4 months of survey completion;

(iv)delivery of any mitigation including, where necessary, archaeological exclusion zones;

(v)monitoring during and post-construction, including a conservation programme for finds;

(vi)archiving of archaeological material; and

(vii)a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised scheme;

(h)a proposed survey and reinstatement plan for Salicornia forming Annex 1 habitat in the parts of the offshore Order limits within which it is proposed to carry out construction works comprised in Work No. 5A, including the circumstances in which reinstatement will be required and the proposed methods of reinstatement;

(i)an offshore project maintenance plan to be submitted to the MMO at least 4 months before commencement of the operation of the licensed activities and to include provision for the review and resubmission of the plan every 3 years during the operational phase;

(j)an aids to navigation management plan specifying how the undertaker will ensure compliance with Condition 4 from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning.

(3) Before the submission of the pre-construction plans and documentation required by this Condition, the undertaker must provide a copy of the plans and documentation to the other undertakers under the Order.

(4) The undertaker must participate in liaison meetings with other undertakers under the Order as requested from time to time by the MMO in writing in advance. The meetings must be chaired by the MMO and must consider such matters as are determined by the MMO relating to the efficient operation of a deemed marine licence where it has an impact on the efficient operation of any other deemed marine licence issued under the Order (including as varied or transferred).

(5) Before giving its approval under paragraph (2), the MMO must—

(a)in relation to any programme or plan submitted under sub-paragraphs (a), (c), (d), (f), (h) or (i), consult the relevant statutory nature conservation body and the Environment Agency;

(b)in relation to any statement or protocol submitted under sub-paragraphs (b) or (e), consult the relevant statutory nature conservation body;

(c)in relation to a scheme submitted under sub-paragraph (g), consult Historic England; and

(d)in relation to a plan submitted under sub-paragraph (j), consult Trinity House.

(6) In the event that driven or part-driven pile foundations are proposed to be used, the MMO must not approve the plan referred to in paragraph (1) or the code referred to in paragraph (2) unless the MMO is satisfied, after consulting such persons as the Secretary of State may specify in relation to the plan or the part of the code specified by the Secretary of State (in addition to the persons with whom consultation is otherwise required under this Condition), that either the plan or code (or both of them) provide such mitigation as is necessary to avoid adversely affecting the integrity (within the meaning of the 2007 Regulations) of a relevant site, to the extent that marine mammals are a protected feature of that site.

(7) The mitigation referred to in paragraph (6) may include (without limitation)—

(a)seasonal restrictions to piling;

(b)scheduling of piling, having regard to previous, ongoing and future piling associated with other offshore developments, based on an updated assessment of cumulative impacts;

(c)the use of alternative foundation methodologies, such as jacket foundations (suction piles) or gravity base foundations;

(d)the use of noise reduction at source technologies;

(e)the use of other relevant technologies or methodologies that may emerge in the future.

(8) In paragraph (6), “relevant site” means—

(a)a European offshore marine site;

(b)a European site.

(9) For the purpose of paragraph (6)—

(a)the Southern North Sea possible Special Area of Conservation must be treated as a European offshore marine site until—

(i)that Area (or any part of it) becomes a European offshore marine site or a European site; or

(ii)it is decided that no part of that Area should be a European offshore marine site or a European site; and

(b)harbour porpoise must be treated as a protected feature of the Southern North Sea possible Special Area of Conservation.

(10) In this Condition—

“2007 Regulations” means the Offshore Marine Conservation (Natural Habitats, &c.) Regulations 2007;

“disturbance” must be construed in accordance with regulation 39(1)(b) of the 2007 Regulations;

“European offshore marine site” has the meaning given in regulation 15 of the 2007 Regulations;

“European site” has the meaning given in regulation 24 of the 2007 Regulations;

“Southern North Sea possible Special Area of Conservation” means the Southern North Sea possible Special Area of Conservation as set out in the JNCC 2016 Harbour Porpoise Possible Special Area of Conservation Consultation dated January 2016.

Commencement Information

I82Sch. 9 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Record of the Historic Environment, by submitting a Historic England OASIS form with a digital copy of the report within 6 months of completion of construction of the authorised scheme. The undertaker must notify the MMO and, where the report relates to the intertidal area, Lincolnshire County Council that the OASIS report has been submitted to the National Record of the Historic Environment within 2 weeks of the submission.

Commencement Information

I83Sch. 9 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Each programme, statement, plan, protocol or scheme required to be approved under Condition 8—

(a)must be submitted for approval at least 4 months before the intended start of construction, except where otherwise stated or where an alternative date is agreed in writing by the MMO; and

(b)must be accompanied by—

(i)a statement confirming that the undertaker has complied with Condition 8(3) in relation to the programme, statement, plan, protocol or scheme;

(ii)any comments received by the undertaker from the other undertakers, or a statement from the undertaker confirming that no such comments were received; and

(iii)details of any consultation that has been carried out with the undertakers with the benefit of all or part of the deemed marine licences under the Hornsea One Offshore Wind Farm Order 2014 and any comments received from those undertakers.

(2) The undertaker must comply with the plans and documentation approved under Condition 8 in carrying out the licensed activities unless otherwise agreed in writing by the MMO.

(3) Before agreeing an alternative date under paragraph (1)(a) or a change to approved details under paragraph (2) relating to any document in respect of which consultation is required under Condition 8, the MMO must consult the relevant consultation body referred to in that Condition.

Commencement Information

I84Sch. 9 para. 10 in force at 7.9.2016, see art. 1(2)

Reporting of engaged agents, contractors and vesselsE+W+S

11.—(1) The undertaker must provide the following information to the MMO—

(a)the name and function of any agent or contractor appointed to engage in the licensed activities at least 5 working days before the commencement of the licensed activities or any part of them; and

(b)each week during the construction of the authorised scheme, a completed Hydrographic Note H102 listing the construction vessels currently and to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO and MMO Coastal Office in writing before the agent, contractor or vessel engages in the licensed activities.

(3) All agents, contractors and vessel operators must comply with the Conditions.

Commencement Information

I85Sch. 9 para. 11 in force at 7.9.2016, see art. 1(2)

Equipment and operation of vessels engaged in licensed activitiesE+W+S

12.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of the activities in accordance with the Conditions and must comply with paragraphs (2) to (5).

(2) All motor-powered vessels must be fitted with—

(a)an electronic positioning aid to provide navigational data;

(b)radar;

(c)an echo sounder; and

(d)multi-channel VHF.

(3) All vessel names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All communication on VHF working frequencies must be in English.

(5) No vessel may engage in the licensed activities until all the equipment specified in paragraph (2) is fully operational.

Commencement Information

I86Sch. 9 para. 12 in force at 7.9.2016, see art. 1(2)

Pre-construction monitoring and surveysE+W+S

13.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body and, in respect of the surveys required under paragraph (2)(b) and (c), in consultation with the Environment Agency, of proposed pre-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format and content for a pre-construction baseline report; and—

(a)the survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the post-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement; and

(b)the baseline report proposals must ensure that the outcome of the agreed surveys together with existing data and reports are drawn together to present a valid statement of the pre-construction position, with any limitations, and must make clear what post-construction comparison is intended and the justification for this being required.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the pre-construction surveys must comprise, in outline—

(a)a survey to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) in the parts of the offshore Order limits in which it is proposed to carry out construction works under this licence;

(b)a phase 1 survey of the intertidal area within which it is proposed to carry out construction works;

(c)a high-resolution swath bathymetric survey to include a 100% coverage and a side-scan sonar survey of the parts of the offshore Order limits within which it is proposed to carry out construction works and disposal activities under this licence; and

(d)a grab survey and particle size analysis in the parts of the offshore Order limits within which it is proposed to carry out dredging and disposal activities relating to Work Nos. 3A and 4A under this licence within a period not greater than 12 months before the dredging and disposal activities to determine the extent of suitable herring spawning habitat within those areas.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing by the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I87Sch. 9 para. 13 in force at 7.9.2016, see art. 1(2)

Construction monitoringE+W+S

14.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of any proposed construction monitoring, including methodologies and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the construction monitoring must comprise, in outline—

(a)unless the MMO agrees otherwise in writing, measurements of noise generated by the installation of the first 4 foundations of each discrete foundation type comprised in Work No. 2A to be constructed under this licence where driven or part-driven pile foundations are used;

(b)recording of any visual sightings or acoustic detection of marine mammals where required as part of the marine mammal mitigation protocol under Condition 8(2)(e); and

(c)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k).

(3) The undertaker must carry out the surveys approved under paragraph (1), including any further noise monitoring required in writing by the MMO under paragraph (4), and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) The results of the initial noise measurements monitored in accordance with paragraph (2)(a) must be provided to the MMO within 6 weeks of the installation of the first 4 foundations of each discrete foundation type for the MMO to determine, following assessment of this report, whether any further noise monitoring is required.

(5) Construction monitoring must include vessel traffic monitoring by automatic identification system for the duration of the construction period. A report must be submitted to the MMO and the MCA at the end of each year of the construction period.

Commencement Information

I88Sch. 9 para. 14 in force at 7.9.2016, see art. 1(2)

Post-constructionE+W+S

15.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body and, in respect of the surveys required under paragraph (2)(a), (b) and (c), in consultation with the Environment Agency, of proposed post-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt of specific proposals, so far as applicable, the post-construction surveys must comprise, in outline—

(a)a survey to determine any change in the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) identified in the pre-construction survey in the parts of the offshore Order limits in which construction works were carried out. The survey design must be informed by the results of the pre-construction benthic survey;

(b)a high-resolution swath bathymetric survey to be undertaken no sooner than 6 months following completion of construction works and disposal activities to include a 100% coverage of the parts of the offshore Order limits with a water depth no greater than 12 metres (referenced to Chart Datum) within which construction works and disposal activities were carried out under this licence to assess any changes in bedform morphology and such further monitoring as may be required to ensure that the cables have been buried or protected and sediment is able to move over any installed cable protection. The need for further surveys must be agreed in writing with the MMO following submission of the first year of survey data;

(c)a high-resolution bathymetric survey of a representative sample area, as may be agreed in writing with the MMO, of the parts of the offshore Order limits with a water depth no greater than 12 metres (referenced to Chart Datum) within which construction works and disposal activities were carried out under this licence following the first major storm event the timing of which must be agreed with the MMO in consultation with Natural England and the Environment Agency;

(d)a grab survey and particle size analysis in the parts of the offshore Order limits within which dredging and disposal activities relating to Work Nos. 3A and 4A were carried out under this licence within 12 months of the completion of the dredging and disposal activities to determine the extent of suitable herring spawning ground habitat within those areas; and

(e)vessel traffic monitoring by automatic identification system, for 28 days taking account seasonal variations in traffic patterns, for a maximum duration of 1 year post-construction. A report must be submitted to the MMO and the MCA at the end of the first year after construction is completed.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I89Sch. 9 para. 15 in force at 7.9.2016, see art. 1(2)

Offshore decommissioningE+W+S

16.—(1) No decommissioning activities may commence until a plan for the carrying out of the activities has been submitted to and approved in writing by the MMO and, where the plan relates to the decommissioning of Work No. 4A or 5A, the MMO must consult the Environment Agency before giving its approval.

(2) The plan must be submitted for approval at least 4 months before the intended start of the decommissioning activities, except where otherwise stated or unless otherwise agreed in writing by the MMO.

(3) The plan must be implemented as approved.

Commencement Information

I90Sch. 9 para. 16 in force at 7.9.2016, see art. 1(2)

Amendments to approved plans, etc.E+W+S

17.—(1) Where any Condition requires the licensed activities to be carried out in accordance with any plan, programme, code, statement, protocol scheme or details (the “plan”) approved by the MMO, the approved plan must be taken to include any amendment to the plan that may subsequently be approved in writing by the MMO.

(2) Any amendment to the plan must be in accordance with the principles and assessments set out in the environmental statement, and approval for an amendment may be given only where it has been demonstrated to the satisfaction of the MMO that amendment is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I91Sch. 9 para. 17 in force at 7.9.2016, see art. 1(2)

Restrictions in intertidal area and Humber Estuary Special Area of ConservationE+W+S

18.—(1) The cable protection to be used within the Humber Estuary Special Area of Conservation must be frond mattressing, unless otherwise agreed in writing with the MMO.

(2) No cable protection may be used within the intertidal area of the Humber Estuary Special Area of Conservation.

(3) The undertaker must not construct or install the licensed activities comprised in Work No. 4A or 5A in the intertidal area during the overwintering period unless otherwise agreed in writing with the MMO, in consultation with Natural England.

(4) The undertaker must not construct or install the licensed activities comprised in Work Nos. 4A and 5A in the intertidal area within 500 metres seaward of the seawall during the period of time commencing 2 hours before a high tide predicted to be greater than 6.5 metres Chart Datum and ending 2 hours after a high tide predicted to be greater than 6.5 metres Chart Datum between 1st April and 31st May (inclusive) and 1st August to 30th September (inclusive), unless provided for in the construction and monitoring programme submitted and approved under Condition 8(2)(a) or the construction method statement submitted and approved under Condition 8(2)(b) or unless otherwise agreed in writing by the MMO, in consultation with Natural England.

(5) The undertaker must not carry out inspections in the intertidal area during the overwintering period to the extent that the inspections require to be carried out—

(a)more than once per overwintering period;

(b)over more than 2 consecutive days by people on foot; or

(c)by more than 5 people on foot at any one time,

unless otherwise agreed in writing with the MMO, in consultation with Natural England or unless provided for in the offshore project maintenance plan submitted and approved under Condition 8(2)(i).

(6) Where this Condition provides that the MMO may agree to an alternative to what is otherwise provided under this Condition—

(a)any alternative must be in accordance with the principles and assessments set out in the environmental statement; and

(b)agreement to any alternative may be given only where it has been demonstrated to the satisfaction of the MMO that the alternative is unlikely to give rise to any materially new or materially different effects from those assessed in the environmental statement.

(7) In this Condition, “overwintering period” means the period between 1st October and 31st March (inclusive).

Commencement Information

I92Sch. 9 para. 18 in force at 7.9.2016, see art. 1(2)

Articles 2 and 36

SCHEDULE 10E+W+SMarine Licence B1: Project B – Generation Assets

PART 1E+W+SLicensed activities

InterpretationE+W+S

1.—(1) In this licence—

“2008 Act” means the Planning Act 2008;

“2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works described in clause 2 of Part 1 of this licence that are not development within the meaning of section 32 of the 2008 Act;

“Annex 1 habitat” means a habitat set out in Annex 1 to Council Directive 92/43/EEC of 21st May 1992 on the conservation of natural habitats and of wild fauna and flora;

“authorised deposits” means the substances and articles specified in clause 2(3) of Part 1 of this licence;

“authorised development” means the development described in Part 1 of Schedule 1 to the Order that is development within the meaning of section 32 of the 2008 Act;

“authorised project” means the authorised development and the ancillary works authorised by the Order;

“authorised scheme” means Work No. 1B described in clause 2 of Part 1 of this licence;

“commence” means the first carrying out of any part of the licensed activities, except for pre-construction surveys and monitoring; and “commencement” must be construed accordingly;

“Condition” means a condition set out in Part 2 of this licence;

“construction vessel” means any vessel involved in the course of or used for the construction and/or maintenance of the authorised project;

“debris” means items or equipment of a significant size left on the seabed being lost from survey or construction vessels or the structures comprised within the authorised scheme;

“EIA Regulations” means the Infrastructure Planning (Environmental Impact Assessment) Regulations 2009;

“electrical circuit” means a number of electrical conductors necessary to transmit electricity between 2 points within the authorised project, comprising—

(a)

in the case of HVAC transmission, 3 conductors which may be bundled as 1 cable; and

(b)

in the case of HVDC transmission, 2 conductors, which may be attached together or take the form of single cables,

and the electrical circuit may include 1 or more auxiliary cables (normally fibre-optic cables) for the purpose of control, monitoring, protection or general communications;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of Part 4 of the 2009 Act;

“environmental statement” means the document certified as the environmental statement by the Secretary of State under article 40 of the Order;

“gravity base foundation” means—

(a)

a structure principally of concrete or steel (or both) that rests on the seabed due to its own weight and that of added ballast or to the weight of water above it and may include associated equipment including suction piles, J-tubes and access platforms; or

(b)

a structure principally of concrete or steel (or both) consisting of a platform supported on 2 pontoons to which the platform is connected by columns which may be connected by braces;

“HVAC” means high voltage alternating current;

“HVDC” means high voltage direct current;

“in-principle monitoring plan” means the document certified as the in-principle monitoring plan by the Secretary of State under article 40 of the Order;

“intra-array electrical circuits” means the circuits described in clause 2(2)(b) of Part 1 of this licence;

“jacket foundation” means a lattice construction comprising tubular members and joints fixed to the seabed with piles (either driven/drilled piles or suction piles) which will include platforms and J-tubes and may include braced monopiles and a transition piece;

“Kingfisher Fortnightly Bulletin” means the bulletin published by the Humber Seafood Institute or such other alternative publication approved in writing by the MMO;

“LAT” means lowest astronomical tide;

“licensed activities” means the activities specified in Part 1 of this licence;

“maintain”, unless otherwise provided for, includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development; and any derivative of “maintain” must be construed accordingly;

“Marine Noise Registry” means the online database maintained by the Joint Nature Conservation Committee on behalf of the Department for Environment, Food and Rural Affairs that records the spatial and temporal distribution of impulsive noise-generating activities in United Kingdom seas in order that they can be analysed to determine whether they may potentially compromise the achievement of good environmental status;

“MCA” means the Maritime and Coastguard Agency;

“MHWS” (mean high water springs) means the highest level which spring tides reach on average over a period of time;

“MMO” means the Marine Management Organisation;

“monopile foundation” means a foundation comprising a large diameter steel or concrete tube or pile driven vertically into the seabed, J-tubes and platforms and may include external structural devices such as bracing members or steel anchor wires and a transition piece;

“notice to mariners” includes any notice to mariners which may be issued by Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore accommodation platform” means a platform housing or incorporating temporary accommodation, landing ports for vessels and helicopters, standby electricity generation equipment, marking and lighting and other equipment facilities to assist in the co-ordination of marine activities related to the authorised scheme;

“offshore HVAC collector substation” means a structure serving as a collection point for the intra-array electrical circuits and containing equipment for the purpose of transforming the electricity generated at the wind turbine generators to a higher voltage; it may also include a helicopter platform;

“offshore HVDC converter substation” means a structure that contains equipment to convert HVAC electricity to HVDC electricity; it may also include a helicopter platform;

“Order” means the Hornsea Two Offshore Wind Farm Order 2016;

“Order limits” means the limits shown on the works plans within which the authorised project may be carried out;

“suction pile” means a large diameter steel cylinder that is fixed to the base of the foundation, partially penetrates the seabed and remains in place using its weight and hydrostatic pressure differential;

“survey vessel” means a vessel licensed to carry out environmental or engineering surveys;

“Trinity House” means the Corporation of Trinity House of Deptford Strond;

“UK Hydrographic Office” means the Hydrographic Office of the Ministry of Defence or any replacement body or successor to its functions;

“undertaker” means Breesea Limited (company number 07883217) or, to the extent that the benefit of the provisions of the Order and related statutory rights in relation to Work No. 1B and such associated development or ancillary works has been transferred under article 35 of the Order to another person, that other person;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water that is at the time in, on or over water;

“wind farm area” means the area within the limits of deviation for Work No. 1B whose co-ordinates are set out in Part 1 of Schedule 1 to the Order and shown on the works plans;

“wind turbine generator” means a structure comprising any or all of a tower, rotor, blades, nacelle and ancillary electrical and other equipment or structures, which may include lighting and a helicopter platform, fixed to a foundation;

“working day” means any day other than a Saturday, Sunday or public holiday in England and Wales;

“Work No. 1A” means an offshore wind generating station within the wind farm area and described as Work No. 1A in Part 1 of Schedule 1 to the Order;

“Work No. 1B” means an offshore wind generating station within the wind farm area and described as Work No. 1B in clause 2 of Part 1 of this licence;

“Work No. 2A” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“Work No. 2B” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“works plans” means the plans certified as the works plans by the Secretary of State under article 40 of the Order, comprising the offshore works plans, the intertidal works plans and the onshore works plans.

(2) A reference to any statute, order, regulation or similar instrument must be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a)all times are Greenwich Mean Time (GMT);

(b)all co-ordinates are latitude and longitude degrees, minutes and seconds to 3 decimal places in WGS84 Datum.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence is—

(a)Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle-upon-Tyne NE4 7YH

Tel: 0300 123 1032

E-mail: marine.consents@marinemanagement.org.uk

(b)Marine Management Organisation (referred to as the “MMO Coastal Office”)

Neville House

Central Riverside

Bell Street

North Shields

Tyne and Wear NE30 1LJ

Tel (24-hour answer phone): 0191 257 4520 or 0191 257 0159

E-mail: northshields@marinemanagement.org.uk

(c)Trinity House

Tower Hill

London EC3N 4DH

Tel: 020 7481 6900

(d)The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset TA1 2DN

Tel: 01823 337 900

(e)Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton SO15 1EG

Tel: 023 8032 9191

(f)Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk NR33 0HT

Tel: 01502 562 244

(g)Natural England

Foss House

Kings Pool

1-2 Peasholme Green

York YO1 7PX

Tel: 0300 060 1911

(h)Historic Buildings and Monuments Commission for England (referred to as “Historic England”)

Eastgate Court

195-205 High Street

Guildford GU1 3EH

Tel: 01483 252 057.

Commencement Information

I93Sch. 10 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

Details of licensed activitiesE+W+S

2.—(1) This licence authorises the undertaker (and any agent or contractor acting on its behalf) to carry out the following licensable marine activities pursuant to section 66(1) of the 2009 Act, subject to the Conditions—

(a)the deposit at sea of the substances and articles specified in paragraph (3);

(b)the construction of works in or over the sea and/or on or under the sea bed;

(c)dredging for the purposes of seabed preparation for foundation works and/or electrical circuit works;

(d)the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation;

(e)the disposal at disposal site reference HU211 of up to 2,427,666 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 1B, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 1A and 1B disposed of at disposal site reference HU211 must not exceed 2,427,666 cubic metres;

(f)the disposal at disposal site reference HU211 of up to 400,852 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 1B, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 1A and 1B disposed of at disposal site reference HU211 must not exceed 400,852 cubic metres; and

(g)the removal of the substances and articles specified in paragraph (3).

(2) The activities are authorised in relation to the construction, maintenance and operation of—

Work No. 1B — An offshore wind generating station within the wind farm area comprising—

(a)up to 300 wind turbine generators fixed to the seabed, provided that the combined total of wind turbine generators constructed in whole or in part within Work Nos. 1A and 1B must not exceed 300;

(b)a network of subsea intra-array electrical circuits connecting the structures comprised in Work No. 1B—

(i)with other such structures;

(ii)with any other structure located within the wind farm area; and

(iii)with the network of electrical circuits comprised in Work Nos. 1A, 2A and 2B;

(c)up to 2 offshore accommodation platforms fixed to the seabed which may be connected to one of the offshore HVAC collector substations or offshore HVDC converter substations within Work No. 2B by an unsupported steel bridge and up to 2 electrical circuits each connecting an accommodation platform to either an offshore HVAC collector substation or to a wind turbine generator in order to power the accommodation platform, provided that the combined total of offshore accommodation platforms constructed in whole or in part within Work Nos. 1A and 1B must not exceed 2.

Co-ordinates for wind farm area (limits of deviation for Work Nos. 1A, 1B, 2A and 2B)—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

And in connection with Work No. 1B, further associated development as may be necessary or expedient in connection with the authorised scheme within the Order limits and is within the scope of the environmental impact assessment recorded in the environmental statement.

And in connection with Work No. 1B, ancillary works consisting of works and operations within the Order limits comprising temporary anchorage of vessels and buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) The substances or articles authorised for deposit at sea and removal are—

(a)iron and steel;

(b)stone and rock;

(c)concrete;

(d)sand and gravel;

(e)plastic and synthetic; and

(f)material extracted from within the wind farm area during construction drilling and seabed preparation for foundation works.

(4) The grid co-ordinates for disposal site reference HU211 are—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

(5) Section 72 of the 2009 Act applies to this licence, except that subsections (7) and (8) relating to the transfer of the licence apply only to a transfer not falling within article 35 of the Order.

Commencement Information

I94Sch. 10 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

Maintenance of authorised projectE+W+S

3.—(1) The undertaker may at any time maintain the authorised project, except to the extent that this licence or an agreement made under this licence provides otherwise.

(2) No maintenance works whose likely effects on the environment require to be assessed in accordance with the EIA Regulations and are not assessed in the environmental statement may be carried out, unless otherwise approved by the MMO.

(3) Where the MMO’s approval is required under paragraph (2), approval may be given only where it has been demonstrated to the satisfaction of the MMO that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I95Sch. 10 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

DurationE+W+S

4.  This licence remains in force until the authorised scheme has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the Energy Act 2004, including any modification to the programme under section 108, and the completion of the programme has been confirmed by the Secretary of State in writing.

Commencement Information

I96Sch. 10 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SLicence conditions

Design parametersE+W+S

1.—(1) No wind turbine generator forming part of Work No. 1B may—

(a)be more than 151 metres from LAT to the turbine hub;

(b)exceed a height of 276 metres from LAT to the upper tip of the vertical blade;

(c)exceed a rotor diameter of 241.03 metres;

(d)be less than 34.97 metres from LAT to the lowest point of the rotating blade;

(e)be less than 810 metres from the nearest wind turbine generator in all directions.

(2) In this Condition, references to the location of a wind turbine generator are references to the centre point of the turbine.

(3) No offshore accommodation platform forming part of Work No. 1B may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres in area or 60 metres in width.

(4) The diameter of the electrical cables comprising the electrical circuits within Work No. 1B must not exceed 170 millimetres.

(5) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 1A and 1B must not exceed 685 kilometres.

(6) The electrical circuits comprised in Work No. 1B must be installed by use of, or a combination of, ploughing, trenching, jetting, rock-cutting, dredging, surface laying with post-lay burial, and where ground conditions make burial impracticable, by surface laying.

Commencement Information

I97Sch. 10 Pt. 2 para. 1 in force at 7.9.2016, see art. 1(2)

2.—(1) The undertaker must in fixing to the seabed any structures comprised in Work No. 1B use one of the following methods—

(a)monopile foundations;

(b)jacket foundations supported by piles; or

(c)gravity base foundations.

(2) The following parameters apply in respect of the foundation methods used to fix wind turbine generators comprised in Work No. 1B to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 2,827 square metres;

(ii)the number of piles per jacket must not exceed 12;

(iii)the diameter of each pile must not exceed 6 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and scour protection for each individual structure must not exceed 12,596 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 21.1 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 7,543 square metres;

(ii)the seabed levelling diameter must not exceed 78 metres;

(iii)the cone diameter must not exceed 58 metres at its base.

(3) The following parameters apply in respect of the foundation methods used to fix offshore accommodation platforms to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,414 square metres;

(ii)the number of piles must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(4) The total volume of scour protection for the wind turbine generators and the offshore accommodation platforms forming part of Work No. 1B must not exceed 4,761,555 cubic metres, provided that the combined total volume of scour protection for the wind turbine generators and the offshore accommodation platforms forming part of Work Nos. 1A and 1B must not exceed 4,761,555 cubic metres.

Commencement Information

I98Sch. 10 Pt. 2 para. 2 in force at 7.9.2016, see art. 1(2)

Navigational practice, safety and emergency responseE+W+S

3.—(1) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has given written approval for an emergency response co-operation plan which includes full details of the emergency co-operation plans for the construction, operation and decommissioning phases of that part of the authorised scheme in accordance with the MCA recommendations contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

(2) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and, so far as is applicable to that stage of the development, adequately addressed all MCA recommendations as appropriate to the authorised scheme contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” (including its annexes).

(3) The emergency response co-operation plan must be implemented as approved, unless otherwise agreed in writing by the MMO, in consultation with the MCA.

Commencement Information

I99Sch. 10 Pt. 2 para. 3 in force at 7.9.2016, see art. 1(2)

Aids to navigationE+W+S

4.—(1) The undertaker must during the whole period from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning—

(a)exhibit such lights, marks, sounds, signals and other aids to navigation and take such other steps for the prevention of danger to navigation as Trinity House may from time to time direct;

(b)colour all structures in the authorised scheme as directed by Trinity House;

(c)keep Trinity House and the MMO informed of progress of the authorised scheme seaward of MHWS including—

(i)notice of commencement of construction of the authorised scheme within 24 hours of commencement having occurred;

(ii)notice within 24 hours of any aids to navigation being established by the undertaker; and

(iii)notice within 5 working days of completion of construction of the authorised scheme;

(d)submit reports to Trinity House detailing the working condition of aids to navigation quarterly, or as requested by Trinity House;

(e)notify Trinity House and the MMO of any failure of the aids to navigation and the timescales and plans for remedying such failures as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

(2) Except as otherwise required by Trinity House under paragraph (1), the undertaker must colour all structures comprised in Work No. 1B yellow (colour code RAL 1023) from at least highest astronomical tide to a height as directed by Trinity House.

(3) Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

Commencement Information

I100Sch. 10 Pt. 2 para. 4 in force at 7.9.2016, see art. 1(2)

Notifications and inspectionsE+W+S

5.—(1) The undertaker must ensure that—

(a)a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i)all agents and contractors notified to the MMO in accordance with the Conditions; and

(ii)the masters and transport managers responsible for the vessels notified to the MMO in accordance with the Conditions;

(b)within 28 days of receipt of a copy of this licence, the persons referred to in sub-paragraph (a) provide a completed confirmation form to the MMO confirming their understanding of the terms and conditions of this licence.

(2) Only the persons and vessels notified to the MMO in accordance with Condition 11 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection at the following locations—

(a)the undertaker’s registered address;

(b)any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits; and

(c)on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made.

(4) The documents referred to in paragraph (1)(a) must be available for inspection by an enforcement officer at the locations set out in paragraph (3) at any time.

(5) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or any other associated works or vessels to facilitate any inspection that the MMO considers necessary to inspect the works during construction and operation of the authorised scheme.

(6) The undertaker must inform the MMO Marine Licensing Team and the MMO Coastal Office in writing at least 5 working days before the commencement of the licensed activities or any part of them.

(7) The Kingfisher Information Service of Seafish must be informed by email of details of the vessel routes, timings and locations relating to the construction of the authorised scheme or relevant part to kingfisher@seafish.co.uk—

(a)at least 2 weeks before the construction of the authorised scheme or relevant part, for inclusion in the Kingfisher Fortnightly Bulletin and offshore hazard awareness data; and

(b)on completion of the construction of the authorised scheme or relevant part.

Confirmation of notification must be provided to the MMO within 5 working days of notification to the Kingfisher Information Service of Seafish.

(8) The undertaker must ensure that a notice to mariners is issued at least 10 working days before the commencement of the licensed activities advising of the commencement of licensed activities within the wind farm area and the expected vessel routes from the local service ports to the location of the works comprised within the authorised scheme.

(9) The undertaker must ensure that the notices to mariners are updated and reissued at weekly intervals during construction activities and at least 5 days before any planned operation and maintenance works and supplemented with VHF radio broadcasts agreed with the MCA in accordance with the construction and monitoring programme approved under Condition 8(2)(a). Copies of all notices must be provided to the MMO within 10 working days of issue.

(10) The undertaker must notify—

(a)the UK Hydrographic Office of commencement (within 2 weeks), progress and completion (within 2 weeks) of the authorised scheme in order that all necessary amendments to nautical charts are made, and the undertaker must send a copy of such notifications to the MMO; and

(b)the Defence Geographic Centre (at least 4 weeks before) of the commencement of the authorised scheme and of the progress and completion (within 2 weeks) of the authorised scheme, in order that all necessary amendments to aviation charts are made.

(11) In case of damage to, or destruction or decay of, the authorised scheme or any part of it seaward of MHWS, the undertaker must as soon as reasonably practicable, and no later than 24 hours following the undertaker becoming aware of any such damage, destruction or decay, notify the MMO, Trinity House, MCA and the UK Hydrographic Office.

(12) In the event that the Marine Noise Registry has gone live before the commencement of impact pile driving—

(a)the undertaker must submit details of the expected location, start and end dates of impact pile driving to the Marine Noise Registry before the commencement of the impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

(13) In the event that the Marine Noise Registry has gone live at the time of impact pile driving—

(a)the undertaker must submit the exact locations and dates of impact pile driving to the Marine Noise Registry at 6-month intervals from the commencement of impact pile driving until the completion of impact pile driving. The final data must be submitted within 12 weeks of completion of impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

Commencement Information

I101Sch. 10 para. 5 in force at 7.9.2016, see art. 1(2)

Chemicals, drilling and debrisE+W+S

6.—(1) All chemicals used in the construction of the authorised scheme must be selected from the list of notified chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002, unless otherwise agreed in writing by the MMO.

(2) The undertaker must ensure that any coatings or treatments are suitable for use in the marine environment and are used in accordance with guidelines approved by Health and Safety Executive or the Environment Agency Pollution Prevention Guidelines.

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110% of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences, which disposal may also require a marine licence.

(5) The undertaker must ensure that, where practicable, any debris arising from the construction of the authorised scheme or temporary works placed seaward of MHWS is removed by a date no later than 28 days following the undertaker becoming aware of the debris after the completion of the authorised scheme (or by such later date as may be agreed in writing by the MMO). In the event that the debris cannot practicably be removed, the undertaker must notify the MMO, Trinity House and the MCA within 7 days of becoming aware that the debris cannot practicably be removed.

(6) At least 10 days before the commencement of the licensed activities, the undertaker must submit to the MMO an audit sheet covering all aspects of the construction of the authorised scheme, and no works may commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a)loading facilities;

(b)vessels;

(c)equipment;

(d)shipment routes;

(e)working schedules; and

(f)all components and materials to be used in the construction of the authorised scheme.

(7) The audit sheet must be maintained throughout the construction of the authorised scheme, and the MMO must be notified of any changes on a fortnightly basis.

(8) In the event that the undertaker becomes aware that any of the materials on the audit sheet cannot be accounted for, it must notify the MMO within 24 hours where possible, and in any event within 5 days of becoming aware using the dropped object procedure form. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so. Local fishermen must be invited to send a representative to be present during the survey. The MMO may require any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(9) All debris arising from the operation and maintenance of the authorised scheme must be reported to the MMO using the dropped object procedure form within 24 hours where possible, and in any event within 5 days of the undertaker becoming aware of the incident. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so and any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(10) The undertaker must inform the MMO of the location and quantities of inert material and dredged material disposed of each month under this licence, by submission of a disposal return by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(11) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 1B;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 1B; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 1B;

is disposed of at disposal site reference HU211.

(12) The undertaker must ensure that no waste concrete slurry or wash water from concrete or cement works is discharged into the marine environment. Concrete, cement mixing and washing areas must be contained to prevent run-off entering the water through the freeing ports.

(13) The undertaker must ensure that any rock material used in the construction of the authorised scheme is from a recognised source, free from contaminants and containing minimal fines.

(14) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU211.

Commencement Information

I102Sch. 10 para. 6 in force at 7.9.2016, see art. 1(2)

Force majeureE+W+S

7.  If, due to stress of weather or any other cause, the master of a vessel determines that it is necessary to deposit—

(a)authorised deposits outside of the wind farm area or disposal site reference HU211; or

(b)unauthorised deposits within or outside of the wind farm area or disposal site reference HU211,

because the safety of human life and/or of the vessel is threatened, full details of the circumstances of the deposit must be notified to the MMO within 48 hours.

Commencement Information

I103Sch. 10 para. 7 in force at 7.9.2016, see art. 1(2)

Pre-construction plans and documentationE+W+S

8.—(1) The licensed activities may not commence until a plan setting out proposed details of the authorised scheme and including the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO following appropriate consultation with Trinity House and the MCA—

(a)number, dimensions, specification, foundation types and depth for each wind turbine generator and offshore accommodation platform;

(b)grid co-ordinates of the centre point of the proposed location for each wind turbine generator and offshore accommodation platform, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions;

(c)proposed layout of all cables, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions; and

(d)location and specification of all other aspects of the authorised scheme, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions.

(2) The licensed activities, or any phase of those activities, may not commence until a code of construction practice incorporating the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO—

(a)a construction and monitoring programme, to include details of—

(i)the proposed construction start date;

(ii)proposed timings for mobilisation of plant, delivery of materials and installation works; and

(iii)proposed pre-construction surveys, baseline report format and content, construction monitoring, post-construction monitoring and related reporting in accordance with Conditions 13, 14 and 15. The pre-construction survey programme and all pre-construction survey methodologies must be submitted to the MMO for written approval by the MMO in consultation with the relevant statutory nature conservation body at least 4 months before the commencement of any survey works detailed within;

(b)a construction method statement in accordance with the environmental statement, including details of—

(i)foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii)turbine installation, including any seabed preparation and scour protection;

(iii)installation of offshore accommodation platforms, including any seabed preparation and scour protection;

(iv)circuit installation, including any seabed preparation and circuit protection;

(v)contractors;

(vi)vessels; and

(vii)associated works;

(c)a project environmental management and monitoring plan, to include details of—

(i)a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised scheme in relation to all activities carried out seaward of MHWS. The plan must include a mechanism for reporting oil, fuel and chemical spills to the MMO Marine Pollution Response Team;

(ii)a chemical risk analysis to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii)a disposal plan detailing the locations, methods and timings of dredging and disposal, as well as disposal site monitoring requirements;

(iv)waste management and disposal arrangements;

(v)locations of any archaeological exclusion zones agreed as part of the written scheme of archaeological investigation approved under sub-paragraph (g); and

(vi)the appointment and responsibilities of a fisheries liaison officer and an environmental liaison officer;

(d)a scour protection management and cable armouring plan providing details of the need, type, sources, quantity, location and installation methods for scour protection and cable armouring to be within the scope of the environmental impact assessment recorded in the environmental statement;

(e)in the event that driven or part-driven pile foundations are proposed to be used, a marine mammal mitigation protocol, the intention of which is to prevent injury and/or significant disturbance to marine mammals, following current best practice as advised by the statutory nature conservation bodies, which may include, but is not limited to—

(i)identification of a marine mammal mitigation zone (“MMMZ”);

(ii)appointment of an appropriate number of suitably qualified marine mammal observers;

(iii)methods for the detection of marine mammals within the MMMZ whether visually (by the marine mammal observers) or acoustically using passive acoustic monitoring equipment or other means of detection;

(iv)a reporting methodology to enable efficient communication between the marine mammal observers and the person responsible for approving commencement of piling;

(v)an appropriate soft start procedure whereby piling activities do not commence until an agreed time has elapsed and during which marine mammals have not been detected within the MMMZ;

(vi)where appropriate, methods for the application of acoustic deterrent devices; and

(vii)where appropriate, consideration of the use of noise reduction at source technologies;

(f)a cable specification and installation plan, to include—

(i)technical specification of offshore electrical circuits, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice; and

(ii)a detailed cable laying plan, including geotechnical data, cable laying techniques and a cable burial risk assessment encompassing the identification of any cable protection that exceeds 5% of navigable depth referenced to Chart Datum and, in the event that any area of cable protection exceeding 5% of navigable depth is identified, details of any steps (to be determined following consultation with the MCA) to be taken to ensure existing and future safe navigation is not compromised;

(g)a written scheme of archaeological investigation in relation to the wind farm area in accordance with industry good practice, to include—

(i)details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii)a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver- or remotely-operated vehicle investigations;

(iii)analysis and reporting of survey data to be submitted to the MMO within 4 months of survey completion;

(iv)delivery of any mitigation including, where necessary, archaeological exclusion zones;

(v)monitoring during and post-construction, including a conservation programme for finds;

(vi)archiving of archaeological material; and

(vii)a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised scheme;

(h)a plan for marine mammal monitoring setting out the circumstances in which marine mammal monitoring will be required and the monitoring to be carried out in such circumstances;

(i)an offshore project maintenance plan to be submitted to the MMO at least 4 months before commencement of the operation of the licensed activities and to include provision for the review and resubmission of the plan every 3 years during the operational phase;

(j)an aids to navigation management plan specifying how the undertaker will ensure compliance with Condition 4 from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning;

(k)an ornithological monitoring plan setting out the circumstances in which ornithological monitoring will be required and the monitoring to be carried out in such circumstances.

(3) Before the submission of the pre-construction plans and documentation required by this Condition, the undertaker must provide a copy of the plans and documentation to the other undertakers under the Order.

(4) The undertaker must participate in liaison meetings with other undertakers under the Order as requested from time to time by the MMO in writing in advance. The meetings must be chaired by the MMO and must consider such matters as are determined by the MMO relating to the efficient operation of a deemed marine licence where it has an impact on the efficient operation of any other deemed marine licence issued under the Order (including as varied or transferred).

(5) Before giving its approval under paragraph (2), the MMO must—

(a)in relation to any programme, statement, plan or protocol submitted under sub-paragraphs (a) to (f), (h), (i) or (k), consult the relevant statutory nature conservation body;

(b)in relation to a scheme submitted under sub-paragraph (g), consult Historic England; and

(c)in relation to a plan submitted under sub-paragraph (j), consult Trinity House.

(6) In the event that driven or part-driven pile foundations are proposed to be used, the MMO must not approve the plan referred to in paragraph (1) or the code referred to in paragraph (2) unless the MMO is satisfied, after consulting such persons as the Secretary of State may specify in relation to the plan or the part of the code specified by the Secretary of State (in addition to the persons with whom consultation is otherwise required under this Condition), that either the plan or code (or both of them) provide such mitigation as is necessary to avoid adversely affecting the integrity (within the meaning of the 2007 Regulations) of a relevant site, to the extent that marine mammals are a protected feature of that site.

(7) The mitigation referred to in paragraph (6) may include (without limitation)—

(a)seasonal restrictions to piling;

(b)scheduling of piling, having regard to previous, ongoing and future piling associated with other offshore developments, based on an updated assessment of cumulative impacts;

(c)subject to the terms and conditions of this licence, changing the location of wind turbine generators;

(d)the use of alternative foundation methodologies, such as jacket foundations (suction piles) or gravity base foundations;

(e)the use of noise reduction at source technologies;

(f)the use of other relevant technologies or methodologies that may emerge in the future.

(8) In paragraph (6), “relevant site” means—

(a)a European offshore marine site;

(b)a European site.

(9) For the purpose of paragraph (6)—

(a)the Southern North Sea possible Special Area of Conservation must be treated as a European offshore marine site until—

(i)that Area (or any part of it) becomes a European offshore marine site or a European site; or

(ii)it is decided that no part of that Area should be a European offshore marine site or a European site; and

(b)harbour porpoise must be treated as a protected feature of the Southern North Sea possible Special Area of Conservation.

(10) In this Condition—

“2007 Regulations” means the Offshore Marine Conservation (Natural Habitats, &c.) Regulations 2007;

“disturbance” must be construed in accordance with regulation 39(1)(b) of the 2007 Regulations;

“European offshore marine site” has the meaning given in regulation 15 of the 2007 Regulations;

“European site” has the meaning given in regulation 24 of the 2007 Regulations;

“Southern North Sea possible Special Area of Conservation” means the Southern North Sea possible Special Area of Conservation as set out in the JNCC 2016 Harbour Porpoise Possible Special Area of Conservation Consultation dated January 2016.

Commencement Information

I104Sch. 10 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Record of the Historic Environment, by submitting a Historic England OASIS form with a digital copy of the report within 6 months of completion of construction of the authorised scheme. The undertaker must notify the MMO that the OASIS report has been submitted to the National Record of the Historic Environment within 2 weeks of the submission.

Commencement Information

I105Sch. 10 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Each programme, statement, plan, protocol or scheme required to be approved under Condition 8—

(a)must be submitted for approval at least 4 months before the intended start of construction, except where otherwise stated or where an alternative date is agreed in writing by the MMO; and

(b)must be accompanied by—

(i)a statement confirming that the undertaker has complied with Condition 8(3) in relation to the programme, statement, plan, protocol or scheme; and

(ii)any comments received by the undertaker from the other undertakers, or a statement from the undertaker confirming that no such comments were received.

(2) The undertaker must comply with the plans and documentation approved under Condition 8 in carrying out the licensed activities unless otherwise agreed in writing by the MMO.

(3) Before agreeing an alternative date under paragraph (1)(a) or a change to approved details under paragraph (2) relating to any document in respect of which consultation is required under Condition 8, the MMO must consult the relevant consultation body referred to in that Condition.

Commencement Information

I106Sch. 10 para. 10 in force at 7.9.2016, see art. 1(2)

Reporting of engaged agents, contractors and vesselsE+W+S

11.—(1) The undertaker must provide the following information to the MMO—

(a)the name and function of any agent or contractor appointed to engage in the licensed activities at least 5 working days before the commencement of the licensed activities or any part of them; and

(b)each week during the construction of the authorised scheme, a completed Hydrographic Note H102 listing the construction vessels currently and to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO and MMO Coastal Office in writing before the agent, contractor or vessel engages in the licensed activities.

(3) All agents, contractors and vessel operators must comply with the Conditions.

Commencement Information

I107Sch. 10 para. 11 in force at 7.9.2016, see art. 1(2)

Equipment and operation of vessels engaged in licensed activitiesE+W+S

12.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of such activities in accordance with the Conditions and must comply with paragraphs (2) to (5).

(2) All motor-powered vessels must be fitted with—

(a)an electronic positioning aid to provide navigational data;

(b)radar;

(c)an echo sounder; and

(d)multi-channel VHF.

(3) All vessel names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All communication on VHF working frequencies must be in English.

(5) No vessel may engage in the licensed activities until all the equipment specified in paragraph (2) is fully operational.

Commencement Information

I108Sch. 10 para. 12 in force at 7.9.2016, see art. 1(2)

Pre-construction monitoring and surveysE+W+S

13.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant conservation body of proposed pre-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format and content for a pre-construction baseline report; and—

(a)the survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the post-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement; and

(b)the baseline report proposals must ensure that the outcome of the agreed surveys together with existing data and reports are drawn together to present a valid statement of the pre-construction position, with any limitations, and must make clear what post-construction comparison is intended and the justification for this being required.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the pre-construction surveys must comprise, in outline—

(a)a high-resolution swath bathymetric survey to include a 100% coverage and a side-scan sonar survey of the parts of the wind farm area in which it is proposed to carry out construction works and disposal activities under this licence;

(b)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k);

(c)a survey to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) in the parts of the wind farm area in which it is proposed to carry out construction works under this licence; and

(d)any marine mammal monitoring required by the plan for marine mammal monitoring submitted in accordance with Condition 8(2)(h).

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing by the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I109Sch. 10 para. 13 in force at 7.9.2016, see art. 1(2)

Construction monitoringE+W+S

14.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of any proposed construction monitoring, including methodologies and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the construction monitoring must comprise, in outline—

(a)unless the MMO agrees otherwise in writing, measurements of noise generated by the installation of the first 4 foundations of each discrete foundation type to be constructed under this licence where driven or part-driven pile foundations are used;

(b)recording of any visual sightings or acoustic detection of marine mammals where required as part of the marine mammal mitigation protocol under Condition 8(2)(e); and

(c)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k).

(3) The undertaker must carry out the surveys approved under paragraph (1), including any further noise monitoring required in writing by the MMO under paragraph (4), and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) The results of the initial noise measurements monitored in accordance with paragraph (2)(a) must be provided to the MMO within 6 weeks of the installation of the first 4 foundations of each discrete foundation type for the MMO to determine, following assessment of this report, whether any further noise monitoring is required.

(5) Construction monitoring must include vessel traffic monitoring by automatic identification system for the duration of the construction period. A report must be submitted to the MMO and the MCA at the end of each year of the construction period.

Commencement Information

I110Sch. 10 para. 14 in force at 7.9.2016, see art. 1(2)

Post-constructionE+W+S

15.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of proposed post-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt of specific proposals, so far as applicable, the post-construction surveys must comprise, in outline—

(a)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k);

(b)a high-resolution swath bathymetric survey of the following to assess any changes in bedform morphology—

(i)a representative sample area, as may be agreed in writing with the MMO, of the parts of the wind farm area within which construction works and disposal activities were carried out under this licence, and such further monitoring as may be required to ensure that the cables have been buried or protected; and

(ii)an area not to exceed 125% of the predicted scour area around a selection of turbines, such selection to be based on the desk-based assessment;

(c)a survey to determine any change in the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) identified in the pre-construction survey in the parts of the wind farm area in which construction works were carried out. The survey design must be informed by the results of the pre-construction benthic survey;

(d)any marine mammal monitoring required by the plan for marine mammal monitoring submitted in accordance with Condition 8(2)(h); and

(e)vessel traffic monitoring by automatic identification system, for 28 days taking account seasonal variations in traffic patterns, for a maximum duration of 1 year post-construction. A report must be submitted to the MMO and the MCA at the end of the first year after construction is completed.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) Before carrying out the survey required under paragraph (2)(b), the undertaker must submit to the MMO for written approval a desk-based assessment (which takes account of all factors which influence scour) identifying the turbines with greatest potential for scour. The survey must be used to validate the desk-based assessment, and the significance of any differences between the predicted scour and recorded scour must be assessed in the survey report which must be submitted to the MMO. The need for further surveys must be agreed in writing with the MMO following submission of the first year of survey data.

Commencement Information

I111Sch. 10 para. 15 in force at 7.9.2016, see art. 1(2)

Offshore decommissioningE+W+S

16.—(1) No decommissioning activities may commence until a plan for the carrying out of the activities has been submitted to and approved in writing by the MMO.

(2) The plan must be submitted for approval at least 4 months before the intended start of the decommissioning activities, except where otherwise stated or unless otherwise agreed in writing by the MMO.

(3) The plan must be implemented as approved.

Commencement Information

I112Sch. 10 para. 16 in force at 7.9.2016, see art. 1(2)

Amendments to approved plans, etc.E+W+S

17.—(1) Where any Condition requires the licensed activities to be carried out in accordance with any plan, programme, code, statement, protocol scheme or details (the “plan”) approved by the MMO, the approved plan must be taken to include any amendment to the plan that may subsequently be approved in writing by the MMO.

(2) Any amendment to the plan must be in accordance with the principles and assessments set out in the environmental statement, and approval for an amendment may be given only where it has been demonstrated to the satisfaction of the MMO that amendment is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I113Sch. 10 para. 17 in force at 7.9.2016, see art. 1(2)

Articles 2 and 36

SCHEDULE 11E+W+SMarine Licence B2: Project B – Transmission Assets

PART 1E+W+SLicensed activities

InterpretationE+W+S

1.—(1) In this licence—

“2008 Act” means the Planning Act 2008;

“2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works described in clause 2 of Part 1 of this licence that are not development within the meaning of section 32 of the 2008 Act;

“Annex 1 habitat” means a habitat set out in Annex 1 to Council Directive 92/43/EEC of 21st May 1992 on the conservation of natural habitats and of wild fauna and flora;

“authorised deposits” means the substances and articles specified in clause 2(3) of Part 1 of this licence;

“authorised development” means development described in Part 1 of Schedule 1 to the Order that is development within the meaning of section 32 of the 2008 Act;

“authorised project” means the authorised development and the ancillary works authorised by the Order;

“authorised scheme” means Work Nos. 2B, 3B, 4B and 5B described in clause 2 of Part 1 of this licence;

“Cefas” means the Centre for Environment, Fisheries and Aquaculture Science or any replacement body;

“commence” means the first carrying out of any part of the licensed activities, except for pre-construction surveys and monitoring; and “commencement” must be construed accordingly;

“Condition” means a condition set out in Part 2 of this licence;

“construction vessel” means any vessel involved in the course of or used for the construction and/or maintenance of the authorised project;

“debris” means items or equipment of a significant size left on the seabed being lost from survey or construction vessels or the structures comprised within the authorised scheme;

“EIA Regulations” means the Infrastructure Planning (Environmental Impact Assessment) Regulations 2009;

“electrical circuit” means a number of electrical conductors necessary to transmit electricity between 2 points within the authorised project, comprising—

(a)

in the case of HVAC transmission, 3 conductors which may be bundled as 1 cable; and

(b)

in the case of HVDC transmission 2 conductors, which may be attached together or take the form of single cables,

and the electrical circuit may include 1 or more auxiliary cables (normally fibre-optic cables) for the purpose of control, monitoring, protection or general communications;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of Part 4 of the 2009 Act;

“environmental statement” means the document certified as the environmental statement by the Secretary of State under article 40 of the Order;

“gravity base foundation” means—

(a)

a structure principally of concrete or steel (or both) that rests on the seabed due either to its own weight and that of added ballast or to the weight of water above it and may include associated equipment including suction piles, J-tubes and access platforms; or

(b)

a structure principally of concrete and/or steel consisting of a platform supported on 2 pontoons to which the platform is connected by columns which may be connected by braces;

“high tide” means the state of the tide when it reaches its highest level during a tidal cycle, as may be published from time to time on the UK Hydrographic Office Admiralty EasyTide Website or such other publication as may be approved by the MMO;

“HVAC” means high voltage alternating current;

“HVDC” means high voltage direct current;

“in-principle monitoring plan” means the document certified as the in-principle monitoring plan by the Secretary of State under article 40 of the Order;

“intertidal area” means the area between MHWS and MLWS;

“intertidal works plans” means the part of the works plans described as the intertidal works plans;

“jacket foundation” means a lattice construction comprising tubular members and joints fixed to the seabed with piles (either driven/drilled piles or suction piles) which will include platforms and J-tubes and may include braced monopiles and a transition piece;

“Kingfisher Fortnightly Bulletin” means the bulletin published by the Humber Seafood Institute or such other alternative publication approved in writing by the MMO;

“LAT” means lowest astronomical tide;

“licensed activities” means the activities specified in Part 1 of this licence;

“maintain”, unless otherwise provided for, includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development; and any derivative of “maintain” must be construed accordingly;

“major storm event” means a greater than 1 in10 year wave event within the offshore Order limits seaward of MHWS in terms of wave height, measured by reference to the height of waves recorded at the nearest wave buoy to the authorised scheme as agreed with the MMO, and the WaveNet data published by Cefas, or such other means of measurement as may be agreed with the MMO;

“Marine Noise Registry” means the online database maintained by the Joint Nature Conservation Committee on behalf of the Department of Environment, Food and Rural Affairs that records the spatial and temporal distribution of impulsive noise-generating activities in United Kingdom seas in order that they can be analysed to determine whether they may potentially compromise the achievement of good environmental status;

“MCA” means the Maritime and Coastguard Agency;

“MHWS” (mean high water springs) means the highest level which spring tides reach on average over a period of time;

“MLWS” (mean low water springs) means the lowest level which spring tides reach on average over a period of time;

“MMO” means the Marine Management Organisation;

“monopile foundation” means a foundation comprising a large diameter steel or concrete tube or pile driven vertically into the seabed, J-tubes and platforms and may include external structural devices such as bracing members or steel anchor wires and a transition piece;

“notice to mariners” includes any notice to mariners which may be issued by Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore HVAC collector substation” means a structure serving as a collection point for the intra-array electrical circuits and containing equipment for the purpose of transforming the electricity generated at the wind turbine generators to a higher voltage; it may also include a helicopter platform;

“offshore HVDC converter substation” means a structure that contains equipment to convert HVAC electricity to HVDC electricity; it may also include a helicopter platform;

“offshore Order limits” means the limits shown on the offshore works plans and the intertidal works plans within which the authorised scheme may be carried out whose grid co-ordinates are set out in clause 2(2) of Part 1 of this licence;

“offshore reactive compensation substation” means a structure housing electrical reactors for the purpose of limiting electrical losses in the course of HVAC transmission by providing reactive compensation; it may also include a helicopter platform;

“offshore works plans” means the part of the works plans described as the offshore works plans;

“Order” means the Hornsea Two Offshore Wind Farm Order 2016;

“Order limits” means the limits shown on the works plans within which the authorised project may be carried out;

“suction pile” means a large diameter steel cylinder that is fixed to the base of the foundation, partially penetrates the seabed and remains in place using its weight and hydrostatic pressure differential;

“survey vessel” means a vessel licensed to carry out environmental or engineering surveys;

“Trinity House” means the Corporation of Trinity House of Deptford Strond;

“UK Hydrographic Office” means the Hydrographic Office of the Ministry of Defence or any replacement body or successor to its functions;

“undertaker” means Breesea Limited (company number 07883217) or, to the extent that the benefit of the provisions of the Order and related statutory rights in relation to Work No. 2B, 3B, 4B or 5B and such associated development or ancillary works has been transferred under article 35 of the Order to another person, that other person;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water that is at the time in, on or over water;

“wind turbine generator” means a structure comprising any or all of a tower, rotor, blades, nacelle and ancillary electrical and other equipment or structures, which may include lighting and a helicopter platform, fixed to a foundation;

“working day” means any day other than a Saturday, Sunday or public holiday in England and Wales;

“Work No. 2A” means up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B;

“Work No. 2B” means the works described as Work No. 2B in clause 2 of Part 1 of this licence;

“Work No. 3A” means up to 2 offshore reactive compensation substations fixed to the seabed in the event that the mode of transmission is HVAC;

“Work No. 3B” means the works described as Work No. 3B in clause 2 of Part 1 of this licence;

“Work No. 4A” means a marine connection to the shore, including cable and pipeline crossing works which—

(a)

if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2A via and connecting with the offshore reactive compensation substation comprised in Work No. 3A; or

(b)

if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2A,

and in either case terminating at Work No. 5A;

“Work No. 4B” means the works described as Work No. 4B in clause 2 of Part 1 of this licence;

“Work No. 5A” means a foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4A, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays comprising Work No. 6A;

“Work No. 5B” means the works described as Work No. 5B in clause 2 of Part 1 of this licence;

“Work No. 6A” means up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5A and the onshore electrical circuits;

“Work No. 6B” means up to 8 underground electrical circuit transition joint bays in the vicinity of Horseshoe Point in the parish of North Coates in the county of Lincolnshire, housing the connections between the offshore electrical circuits comprised in Work No. 5B and the onshore electrical circuits;

“works plans” means the plans certified as the works plans by the Secretary of State under article 40 of the Order, comprising the offshore works plans, the intertidal works plans and the onshore works plans.

(2) A reference to any statute, order, regulation or similar instrument must be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a)all times are Greenwich Mean Time (GMT);

(b)all co-ordinates are latitude and longitude degrees, minutes and seconds to 3 decimal places in WGS84 Datum.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence is—

(a)Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle-upon-Tyne NE4 7YH

Tel: 0300 123 1032

E-mail: marine.consents@marinemanagement.org.uk

(b)Marine Management Organisation (referred to as the “MMO Coastal Office”)

Neville House

Central Riverside

Bell Street

North Shields

Tyne and Wear NE30 1LJ

Tel (24-hour answer phone): 0191 257 4520 or 0191 257 0159

E-mail:

(c)Trinity House

Tower Hill

London EC3N 4DH

Tel: 020 7481 6900

(d)The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset TA1 2DN

Tel: 01823 337 900

(e)Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton SO15 1EG

Tel: 023 8032 9191

(f)Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk NR33 0HT

Tel: 01502 562 244

(g)Natural England

Foss House

Kings Pool

1-2 Peasholme Green

York YO1 7PX

Tel: 0300 060 1911

(h)Historic Buildings and Monuments Commission for England (referred to as “Historic England”)

Eastgate Court

195-205 High Street

Guildford GU1 3EH

Tel: 01483 252 057

(i)Environment Agency

Waterside House

Waterside North

Lincoln LN2 5HA

Tel: 03708 506 506.

Commencement Information

I114Sch. 11 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

Details of licensed activitiesE+W+S

2.—(1) This licence authorises the undertaker (and any agent or contractor acting on its behalf) to carry out the following licensable marine activities pursuant to section 66(1) of the 2009 Act, subject to the Conditions—

(a)the deposit at sea of the substances and articles specified in paragraph (3);

(b)the construction of works in or over the sea and/or on or under the sea bed;

(c)dredging for the purposes of seabed preparation for foundation works and/or electrical circuit works;

(d)the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation;

(e)the disposal at disposal site reference HU211 of up to 324,454 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 2B, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 2A and 2B disposed of at disposal site reference HU211 must not exceed 324,454 cubic metres;

(f)the disposal at disposal site reference HU211 of up to 92,048 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 2B and 4B, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 2A, 2B, 4A and 4B disposed of at disposal site reference HU211 must not exceed 92,048 cubic metres;

(g)the disposal at disposal site reference HU209 of up to 38,485 cubic metres comprising inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work No. 3B, provided that the combined total volume of inert material of natural origin produced during construction drilling and seabed preparation for foundation works and/or dredged material produced during seabed preparation for foundation works comprised in Work Nos. 3A and 3B disposed of at disposal site reference HU209 must not exceed 38,485 cubic metres;

(h)the disposal at disposal site reference HU209 of up to 1,269,000 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 4B, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 4A and 4B disposed of at disposal site reference HU209 must not exceed 1,269,000 cubic metres;

(i)the disposal at disposal site reference HU210 of up to 131,000 cubic metres comprising inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work No. 4B, provided that the combined total volume of inert material of natural origin and/or dredged material produced during cable laying preparation works comprised in Work Nos. 4A and 4B disposed of at disposal site reference HU210 must not exceed 131,000 cubic metres; and

(j)the removal of the substances and articles specified in paragraph (3).

(2) The activities are authorised in relation to the construction, maintenance and operation of—

Work No. 2B — Up to 6 offshore HVAC collector substations and, in the event that the mode of transmission is HVDC, up to 2 offshore HVDC converter substations together with a network of electrical circuits connecting the structures within Work Nos. 2A and 2B, provided that—

(a)the combined total of offshore HVAC collector substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 6; and

(b)the combined total of offshore HVDC converter substations constructed in whole or in part within Work Nos. 2A and 2B must not exceed 2.

Co-ordinates for wind farm area (limits of deviation for Work No. 2B)—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

Work No. 3B — In the event that the mode of transmission is HVAC, up to 2 offshore reactive compensation substations fixed to the seabed at latitude point 53° 37′ 54.291″ N and longitude point 0° 55′ 59.731″ E and at latitude point 53° 38′ 9.295″ N and longitude point 0° 55′ 49.576″ E subject to deviation within the following limits of deviation, provided that the combined total of offshore reactive compensation substations constructed in whole or in part within Work Nos. 3A and 3B must not exceed 2—

PointLatitudeLongitude
153° 38′ 1.918″ N0° 55′ 55.183″ E
253° 38′ 2.362″ N0° 55′ 58.099″ E
353° 38′ 2.438″ N0° 56′ 0.367″ E
453° 38′ 2.185″ N0° 56′ 3.394″ E
553° 38′ 1.735″ N0° 56′ 5.560″ E
653° 38′ 1.074″ N0° 56′ 7.567″ E
753° 37′ 59.900″ N0° 56′ 9.900″ E
853° 37′ 58.446″ N0° 56′ 11.733″ E
953° 37′ 57.216″ N0° 56′ 12.723″ E
1053° 37′ 55.456″ N0° 56′ 13.477″ E
1153° 37′ 54.094″ N0° 56′ 13.597″ E
1253° 37′ 52.296″ N0° 56′ 13.156″ E
1353° 37′ 51.011″ N0° 56′ 12.387″ E
1453° 37′ 49.821″ N0° 56′ 11.266″ E
1553° 37′ 48.441″ N0° 56′ 9.279″ E
1653° 37′ 47.358″ N0° 56′ 6.825″ E
1753° 37′ 46.776″ N0° 56′ 4.750″ E
1853° 37′ 46.409″ N0° 56′ 2.540″ E
1953° 37′ 46.268″ N0° 56′ 0.258″ E
2053° 37′ 46.357″ N0° 55′ 57.969″ E
2153° 37′ 46.828″ N0° 55′ 55.017″ E
2253° 37′ 47.678″ N0° 55′ 52.316″ E
2353° 37′ 48.540″ N0° 55′ 50.538″ E
2453° 37′ 49.567″ N0° 55′ 49.029″ E
2553° 37′ 51.143″ N0° 55′ 47.509″ E
2653° 37′ 52.881″ N0° 55′ 46.618″ E
2753° 37′ 54.238″ N0° 55′ 46.392″ E
2853° 37′ 56.046″ N0° 55′ 46.691″ E
2953° 37′ 57.351″ N0° 55′ 47.359″ E
3053° 37′ 58.570″ N0° 55′ 48.386″ E
3153° 38′ 0.004″ N0° 55′ 50.262″ E
3253° 38′ 1.153″ N0° 55′ 52.630″ E
3353° 38′ 1.792″ N0° 55′ 54.657″ E
3453° 38′ 1.346″ N0° 55′ 51.708″ E
3553° 38′ 1.300″ N0° 55′ 48.665″ E
3653° 38′ 1.657″ N0° 55′ 45.681″ E
3753° 38′ 2.399″ N0° 55′ 42.906″ E
3853° 38′ 3.490″ N0° 55′ 40.477″ E
3953° 38′ 5.257″ N0° 55′ 38.112″ E
4053° 38′ 6.910″ N0° 55′ 36.872″ E
4153° 38′ 8.684″ N0° 55′ 36.281″ E
4253° 38′ 10.939″ N0° 55′ 36.497″ E
4353° 38′ 12.244″ N0° 55′ 37.130″ E
4453° 38′ 13.467″ N0° 55′ 38.122″ E
4553° 38′ 15.233″ N0° 55′ 40.491″ E
4653° 38′ 16.080″ N0° 55′ 42.277″ E
4753° 38′ 16.738″ N0° 55′ 44.277″ E
4853° 38′ 17.187″ N0° 55′ 46.433″ E
4953° 38′ 17.441″ N0° 55′ 49.447″ E
5053° 38′ 17.365″ N0° 55′ 51.746″ E
5153° 38′ 16.908″ N0° 55′ 54.716″ E
5253° 38′ 16.068″ N0° 55′ 57.438″ E
5353° 38′ 15.210″ N0° 55′ 59.234″ E
5453° 38′ 13.812″ N0° 56′ 1.201″ E
5553° 38′ 12.609″ N0° 56′ 2.302″ E
5653° 38′ 10.868″ N0° 56′ 3.211″ E
5753° 38′ 9.507″ N0° 56′ 3.449″ E
5853° 38′ 8.141″ N0° 56′ 3.296″ E
5953° 38′ 6.381″ N0° 56′ 2.496″ E
6053° 38′ 4.772″ N0° 56′ 1.053″ E
6153° 38′ 3.714″ N0° 55′ 59.591″ E
6253° 38′ 2.560″ N0° 55′ 57.217″ E

Work No. 4B — A marine connection to the shore, including cable and pipeline crossing works which—

(a)if the mode of transmission is HVAC, consists of up to 8 subsea electrical circuits proceeding from the offshore HVAC collector substations comprised in Work No. 2B via and connecting with the offshore reactive compensation substations comprised in Work No. 3B; or

(b)if the mode of transmission is HVDC, consists of up to 2 subsea electrical circuits proceeding from the offshore HVDC converter substations comprised in Work No. 2B,

and in either case terminating at Work No. 5B, provided that the combined total of electrical circuits constructed in whole or in part within Work Nos. 4A and 4B must not exceed, in the event that the mode of transmission is HVDC, 2, and in the event that the mode of transmission is HVAC, 8.

Principal co-ordinates for marine export cable area (limits of deviation for Work No. 4B) whose full co-ordinates are set out in the offshore works plans—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 46′ 7.286″ N1° 38′ 16.673″ E
2553° 46′ 4.677″ N1° 37′ 22.711″ E
2753° 44′ 47.813″ N1° 28′ 38.495″ E
3253° 44′ 47.743″ N1° 27′ 26.607″ E
3453° 44′ 36.477″ N1° 25′ 23.743″ E
14153° 42′ 30.629″ N1° 15′ 58.654″ E
15253° 42′ 28.182″ N1° 14′ 34.895″ E
26453° 39′ 35.134″ N1° 6′ 29.785″ E
31653° 38′ 17.582″ N1° 2′ 16.928″ E
44753° 36′ 54.624″ N0° 51′ 31.062″ E
44953° 36′ 15.738″ N0° 48′ 52.425″ E
51353° 35′ 21.166″ N0° 43′ 44.242″ E
51553° 31′ 50.425″ N0° 40′ 55.898″ E
51653° 31′ 38.281″ N0° 40′ 8.340″ E
52153° 28′ 36.676″ N0° 20′ 3.846″ E
53253° 31′ 43.122″ N0° 12′ 21.707″ E
53353° 30′ 57.432″ N0° 5′ 59.890″ E
53453° 31′ 11.028″ N0° 5′ 42.539″ E
53553° 30′ 42.954″ N0° 5′ 10.787″ E
53653° 30′ 42.180″ N0° 5′ 9.912″ E
53753° 30′ 46.588″ N0° 4′ 55.345″ E
53853° 30′ 52.245″ N0° 4′ 59.515″ E
53953° 31′ 25.514″ N0° 5′ 24.049″ E
54053° 31′ 29.574″ N0° 5′ 27.043″ E
58053° 32′ 16.976″ N0° 12′ 37.072″ E
76353° 29′ 11.523″ N0° 20′ 5.981″ E
100153° 31′ 28.589″ N0° 35′ 44.348″ E
100253° 32′ 0.855″ N0° 37′ 42.781″ E
100353° 32′ 17.793″ N0° 39′ 31.883″ E
100453° 32′ 35.749″ N0° 39′ 45.737″ E
100553° 33′ 8.117″ N0° 39′ 47.665″ E
100653° 34′ 28.861″ N0° 41′ 27.396″ E
100753° 35′ 42.522″ N0° 42′ 37.802″ E
101053° 36′ 25.571″ N0° 43′ 54.129″ E
108153° 37′ 2.569″ N0° 47′ 31.846″ E
108353° 37′ 30.986″ N0° 49′ 14.023″ E
108653° 37′ 29.991″ N0° 51′ 27.606″ E
108753° 37′ 36.904″ N0° 52′ 22.841″ E
111153° 38′ 45.654″ N0° 57′ 1.237″ E
114353° 39′ 16.652″ N1° 1′ 1.016″ E
114953° 39′ 42.566″ N1° 1′ 40.167″ E
115553° 41′ 20.037″ N1° 6′ 45.836″ E
115753° 42′ 59.843″ N1° 14′ 18.127″ E
116453° 43′ 0.151″ N1° 15′ 37.960″ E
116553° 44′ 0.963″ N1° 20′ 9.157″ E
116653° 49′ 6.492″ N1° 25′ 51.682″ E
116753° 50′ 7.210″ N1° 26′ 59.953″ E

Work No. 5B — A foreshore connection consisting of an extension of the electrical circuits comprised in Work No. 4B, including cable crossing works, crossing under the existing sea wall using a trenchless technique and terminating at the electrical circuit transition joint bays (Work No. 6B).

And in connection with Work Nos. 2B, 3B, 4B and 5B, further associated development as may be necessary or expedient in connection with the authorised scheme within the Order limits and is within the scope of the environmental impact assessment recorded in the environmental statement.

And in connection with Work Nos. 2B, 3B, 4B and 5B, ancillary works consisting of works and operations within the Order limits comprising temporary anchorage of vessels and buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) The substances or articles authorised for deposit at sea and removal are—

(a)iron and steel;

(b)stone and rock;

(c)concrete;

(d)sand and gravel;

(e)plastic and synthetic; and

(f)material extracted from within the offshore Order limits during construction drilling and seabed preparation for foundation works and cable sandwave preparation works.

(4) The grid co-ordinates for disposal site reference HU211 are—

PointLatitudeLongitude
154° 0′ 31.626″ N1° 26′ 19.993″ E
254° 0′ 18.479″ N1° 38′ 37.320″ E
354° 0′ 15.768″ N1° 40′ 21.864″ E
453° 59′ 36.924″ N2° 3′ 45.936″ E
553° 57′ 24.509″ N2° 6′ 6.700″ E
653° 57′ 12.481″ N2° 4′ 32.376″ E
753° 56′ 46.586″ N2° 5′ 4.031″ E
853° 56′ 16.303″ N2° 1′ 15.269″ E
953° 55′ 22.663″ N2° 2′ 14.219″ E
1053° 55′ 2.525″ N1° 59′ 45.776″ E
1153° 55′ 35.429″ N1° 59′ 20.944″ E
1253° 55′ 8.162″ N1° 56′ 10.619″ E
1353° 55′ 23.329″ N1° 55′ 20.262″ E
1453° 55′ 37.592″ N1° 53′ 38.108″ E
1553° 55′ 31.318″ N1° 52′ 54.282″ E
1653° 56′ 22.870″ N1° 51′ 57.409″ E
1753° 55′ 46.445″ N1° 47′ 47.796″ E
1853° 58′ 42.179″ N1° 44′ 31.880″ E
1953° 58′ 17.828″ N1° 41′ 46.795″ E
2053° 56′ 29.670″ N1° 43′ 45.592″ E
2153° 56′ 3.228″ N1° 41′ 0.143″ E
2253° 55′ 9.293″ N1° 39′ 52.024″ E
2353° 50′ 5.118″ N1° 38′ 58.430″ E
2453° 50′ 7.210″ N1° 26′ 59.953″ E

(5) The grid co-ordinates for disposal site reference HU209 are—

PointLatitudeLongitude
A53° 36′ 40.490″ N0° 50′ 41.571″ E
B53° 36′ 54.624″ N0° 51′ 31.062″ E
C53° 37′ 22.048″ N0° 55′ 08.301″ E
D53° 37′ 38.643″ N0° 57′ 17.843″ E
E53° 37′ 56.680″ N0° 59′ 39.524″ E
F53° 38′ 15.917″ N1° 02′ 08.601″ E
G53° 39′ 35.134″ N1° 06′ 29.785″ E
H53° 41′ 22.549″ N1° 11′ 30.804″ E
I53° 42′ 14.598″ N1° 10′ 44.250″ E
J53° 41′ 19.717″ N1° 06′ 44.682″ E
K53° 39′ 41.954″ N1° 01′ 38.714″ E
L53° 39′ 16.652″ N1° 01′ 01.016″ E
M53° 38′ 45.654″ N0° 57′ 01.237″ E
N53° 37′ 36.904″ N0° 52′ 22.841″ E
O53° 37′ 29.991″ N0° 51′ 27.606″ E
P53° 37′ 30.124″ N0° 50′ 57.716″ E

(6) The grid co-ordinates for disposal site reference HU210 are—

PointLatitudeLongitude
W53° 43′ 14.348″ N1° 19′ 13.563″ E
X53° 43′ 52.989″ N1° 22′ 07.248″ E
Y53° 44′ 22.957″ N1° 21′ 47.484″ E
Z53° 43′ 44.110″ N1° 18′ 53.902″ E

(7) Section 72 of the 2009 Act applies to this licence, except that subsections (7) and (8) relating to the transfer of the licence apply only to a transfer not falling within article 35 of the Order.

Commencement Information

I115Sch. 11 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

Maintenance of authorised projectE+W+S

3.—(1) The undertaker may at any time maintain the authorised project, except to the extent that this licence or an agreement made under this licence provides otherwise.

(2) No maintenance works whose likely effects on the environment require to be assessed in accordance with the EIA Regulations and are not assessed in the environmental statement may be carried out, unless otherwise approved by the MMO.

(3) Where the MMO’s approval is required under paragraph (2), approval may be given only where it has been demonstrated to the satisfaction of the MMO that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I116Sch. 11 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

DurationE+W+S

4.  This licence remains in force until the authorised scheme has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the Energy Act 2004, including any modification to the programme under section 108, and the completion of the programme has been confirmed by the Secretary of State in writing.

Commencement Information

I117Sch. 11 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SLicence conditions

Design parametersE+W+S

1.—(1) No offshore HVAC collector substation forming part of Work No. 2B may—

(a)exceed 64 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 3,600 square metres or 60 metres in width.

(2) No offshore HVDC converter substation forming part of Work No. 2B may—

(a)exceed 110 metres in height above LAT;

(b)have a platform that at its greatest extent exceeds 16,200 square metres in area or 180 metres in width.

(3) The offshore reactive compensation substation comprised in Work No. 3B must not—

(a)exceed 64 metres in height above LAT; or

(b)have a platform that at its greatest extent exceeds 3,600 square metres or 60 metres in width.

(4) The diameter of the electrical cables comprising the electrical circuits must not exceed the following limitations—

(a)within Work No. 2B, 300 millimetres;

(b)within Work Nos. 4B and 5B—

(i)190 millimetres, where the mode of transmission is HVDC; and

(ii)300 millimetres, where the mode of transmission is HVAC.

(5) The combined total length of the connections in the form of electrical circuits between the structures comprised in Work Nos. 2A and 2B must not exceed 300 kilometres.

(6) The combined total length of the electrical circuits comprised in Work Nos. 4A, 4B, 5A and 5B seaward of MHWS must not exceed 1,200 kilometres.

(7) The combined total area of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 546,000 square metres.

(8) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 2,055,200 square metres.

(9) The combined total area of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 44,800 square metres.

(10) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 2A and 2B must not exceed 312,000 cubic metres.

(11) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located outside the Humber Estuary Special Area of Conservation must not exceed 1,174,400 cubic metres.

(12) The combined total volume of cable protection for the electrical circuits comprising Work Nos. 4A and 4B located within the Humber Estuary Special Area of Conservation must not exceed 25,600 cubic metres.

(13) The electrical circuits comprised in Work Nos. 2B and 4B must be installed by use of, or a combination of, ploughing, trenching, jetting, rock-cutting, dredging, surface laying with post-lay burial, and where ground conditions make burial impracticable, by surface laying.

(14) The electrical circuits comprised in Work No. 5B must be installed by use of, or a combination of, ploughing, trenching and jetting, with the exception that, where the electrical circuits comprised in Work No. 5B cross under the existing sea wall, they must be installed using a trenchless technique.

Commencement Information

I118Sch. 11 Pt. 2 para. 1 in force at 7.9.2016, see art. 1(2)

2.—(1) The undertaker must in fixing to the seabed any structures comprised in Work Nos. 2B and 3B use one of the following methods—

(a)monopile foundations;

(b)jacket foundations supported by piles; or

(c)gravity base foundations.

(2) The undertaker must not use the monopile foundation method or any other method which includes braced monopiles to fix to the seabed any offshore HVDC converter substation.

(3) The following parameters apply in respect of the foundation methods used to fix offshore HVAC collector substations to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 1,924 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3.5 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 12,723 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

(4) The following parameters apply in respect of the foundation methods used to fix offshore HVDC converter substations to the seabed—

(a)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 17,318 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 72;

(iv)the number of piles per jacket must not exceed 18;

(v)the diameter of each pile must not exceed 3.5 metres;

(b)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 50,894 square metres;

(ii)the number of jacket foundations per topside must not exceed 4;

(iii)the number of piles per topside must not exceed 32;

(iv)the number of piles per jacket must not exceed 8;

(v)the diameter of each pile must not exceed 15 metres;

(c)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 27,300 square metres;

(ii)the number of pontoons for each individual structure must not exceed 3;

(iii)the pontoons must not exceed 170 metres in length or 35 metres in width.

(5) The following parameters apply in respect of the foundation methods used to fix the offshore reactive compensation substation to the seabed—

(a)where monopile foundations are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,963 square metres;

(ii)the diameter of each foundation must not exceed 10 metres;

(b)where jacket foundations (driven/drilled piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 1,414 square metres;

(ii)the number of piles per jacket must not exceed 8;

(iii)the diameter of each pile must not exceed 3 metres;

(c)where jacket foundations (suction piles) are used—

(i)the area occupied by the foundations and the scour protection must not exceed 6,362 square metres;

(ii)the number of piles per jacket must not exceed 4;

(iii)the diameter of each pile must not exceed 15 metres;

(d)where gravity base foundations are used—

(i)the area occupied by the foundations and the scour protection for each individual structure must not exceed 6,362 square metres;

(ii)the seabed levelling diameter must not exceed 70 metres;

(iii)the cone diameter must not exceed 50 metres at its base.

Commencement Information

I119Sch. 11 Pt. 2 para. 2 in force at 7.9.2016, see art. 1(2)

Navigational practice, safety and emergency responseE+W+S

3.—(1) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has given written approval for an emergency response co-operation plan which includes full details of the emergency co-operation plans for the construction, operation and decommissioning phases of that part of the authorised scheme in accordance with the MCA recommendations contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

(2) No part of the authorised scheme seaward of MHWS may commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and, so far as is applicable to that stage of the development, adequately addressed all MCA recommendations as appropriate to the authorised scheme contained within MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” (including its annexes).

(3) The emergency response co-operation plan must be implemented as approved, unless otherwise agreed in writing by the MMO, in consultation with the MCA.

Commencement Information

I120Sch. 11 Pt. 2 para. 3 in force at 7.9.2016, see art. 1(2)

Aids to navigationE+W+S

4.—(1) The undertaker must during the whole period from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning—

(a)exhibit such lights, marks, sounds, signals and other aids to navigation and take such other steps for the prevention of danger to navigation as Trinity House may from time to time direct;

(b)colour all structures in the authorised scheme as directed by Trinity House;

(c)keep Trinity House and the MMO informed of progress of the authorised scheme seaward of MHWS including—

(i)notice of commencement of construction of the authorised scheme within 24 hours of commencement having occurred;

(ii)notice within 24 hours of any aids to navigation being established by the undertaker; and

(iii)notice within 5 working days of completion of construction of the authorised scheme;

(d)submit reports to Trinity House detailing the working condition of aids to navigation quarterly, or as requested by Trinity House;

(e)notify Trinity House and the MMO of any failure of the aids to navigation and the timescales and plans for remedying such failures as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

(2) Except as otherwise required by Trinity House under paragraph (1), the undertaker must colour all structures comprised in Work Nos. 2B and 3B yellow (colour code RAL 1023) from at least highest astronomical tide to a height as directed by Trinity House.

(3) Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

Commencement Information

I121Sch. 11 Pt. 2 para. 4 in force at 7.9.2016, see art. 1(2)

Notifications and inspectionsE+W+S

5.—(1) The undertaker must ensure that—

(a)a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i)all agents and contractors notified to the MMO in accordance with the Conditions; and

(ii)the masters and transport managers responsible for the vessels notified to the MMO in accordance with the Conditions;

(b)within 28 days of receipt of a copy of this licence, the persons referred to in sub-paragraph (a) provide a completed confirmation form to the MMO confirming their understanding of the terms and conditions of this licence.

(2) Only the persons and vessels notified to the MMO in accordance with Condition 11 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection at the following locations—

(a)the undertaker’s registered address;

(b)any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits; and

(c)on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made.

(4) The documents referred to in paragraph (1)(a) must be available for inspection by an enforcement officer at the locations set out in paragraph (3) at any time.

(5) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or any other associated works or vessels to facilitate any inspection that the MMO considers necessary to inspect the works during construction and operation of the authorised scheme.

(6) The undertaker must inform the MMO Marine Licensing Team and the MMO Coastal Office in writing at least 5 working days before the commencement of the licensed activities or any part of them.

(7) The Kingfisher Information Service of Seafish must be informed by email of details of the vessel routes, timings and locations relating to the construction of the authorised scheme or relevant part to kingfisher@seafish.co.uk—

(a)at least 2 weeks before the construction of the authorised scheme or relevant part, for inclusion in the Kingfisher Fortnightly Bulletin and offshore hazard awareness data; and

(b)on completion of the construction of the authorised scheme or relevant part.

Confirmation of notification must be provided to the MMO within 5 working days of notification to the Kingfisher Information Service of Seafish.

(8) The undertaker must ensure that a notice to mariners is issued at least 10 working days before the commencement of the licensed activities advising of the commencement of licensed activities within the offshore Order limits and the expected vessel routes from the local service ports to the location of the works comprised within the authorised scheme.

(9) The undertaker must ensure that the notices to mariners are updated and reissued at weekly intervals during construction activities and at least 5 days before any planned operation and maintenance works and supplemented with VHF radio broadcasts agreed with the MCA in accordance with the construction and monitoring programme approved under Condition 8(2)(a). Copies of all notices must be provided to the MMO within 10 working days of issue.

(10) The undertaker must notify—

(a)the UK Hydrographic Office of commencement (within 2 weeks), progress and completion (within 2 weeks) of the authorised scheme in order that all necessary amendments to nautical charts are made, and the undertaker must send a copy of such notifications to the MMO; and

(b)the Defence Geographic Centre (at least 4 weeks before) of the commencement of the authorised scheme and of the progress and completion (within 2 weeks) of the authorised scheme, in order that all necessary amendments to aviation charts are made.

(11) In case of damage to, or destruction or decay of, the authorised scheme or any part of it seaward of MHWS, the undertaker must as soon as reasonably practicable, and no later than 24 hours following the undertaker becoming aware of any such damage, destruction or decay, notify the MMO, Trinity House, MCA and the UK Hydrographic Office.

(12) In the event that the Marine Noise Registry has gone live before the commencement of impact pile driving—

(a)the undertaker must submit details of the expected location, start and end dates of impact pile driving to the Marine Noise Registry before the commencement of the impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

(13) In the event that the Marine Noise Registry has gone live at the time of impact pile driving—

(a)the undertaker must submit the exact locations and dates of impact pile driving to the Marine Noise Registry at 6-month intervals from the commencement of impact pile driving until the completion of impact pile driving. The final data must be submitted within 12 weeks of completion of impact pile driving; and

(b)the undertaker must notify the MMO of the successful submission of the details required under sub-paragraph (a) within 7 days of the submission.

Commencement Information

I122Sch. 11 para. 5 in force at 7.9.2016, see art. 1(2)

Chemicals, drilling and debrisE+W+S

6.—(1) All chemicals used in the construction of the authorised scheme must be selected from the list of notified chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002, unless otherwise agreed in writing by the MMO.

(2) The undertaker must ensure that any coatings or treatments are suitable for use in the marine environment and are used in accordance with guidelines approved by Health and Safety Executive or the Environment Agency Pollution Prevention Guidelines.

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110% of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences, which disposal may also require a marine licence.

(5) The undertaker must ensure that, where practicable, any debris arising from the construction of the authorised scheme or temporary works placed seaward of MHWS is removed by a date no later than 28 days following the undertaker becoming aware of the debris after the completion of the authorised scheme (or by such later date as may be agreed in writing by the MMO). In the event that the debris cannot practicably be removed, the undertaker must notify the MMO, Trinity House and the MCA within 7 days of becoming aware that the debris cannot practicably be removed.

(6) At least 10 days before the commencement of the licensed activities, the undertaker must submit to the MMO an audit sheet covering all aspects of the construction of the authorised scheme, and no works may commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a)loading facilities;

(b)vessels;

(c)equipment;

(d)shipment routes;

(e)working schedules; and

(f)all components and materials to be used in the construction of the authorised scheme.

(7) The audit sheet must be maintained throughout the construction of the authorised scheme, and the MMO must be notified of any changes on a fortnightly basis.

(8) In the event that the undertaker becomes aware that any of the materials on the audit sheet cannot be accounted for, it must notify the MMO within 24 hours where possible, and in any event within 5 days of becoming aware using the dropped object procedure form. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so. Local fishermen must be invited to send a representative to be present during the survey. The MMO may require any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(9) All debris arising from the operation and maintenance of the authorised scheme must be reported to the MMO using the dropped object procedure form within 24 hours where possible, and in any event within 5 days of the undertaker becoming aware of the incident. On receipt of the dropped object procedure form, the MMO may require relevant surveys to be carried out by the undertaker (such as side-scan sonar) if reasonable to do so and any new obstructions associated with the authorised scheme to be removed from the seabed at the undertaker’s expense if reasonable to do so.

(10) The undertaker must inform the MMO of the location and quantities of inert material and dredged material disposed of each month under this licence at each of disposal site reference HU211, disposal site reference HU209 and disposal site reference HU210, by submission of a disposal return for each disposal area by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(11) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 2B;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 2B; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work Nos. 2B and 4B,

is disposed of at disposal site reference HU211.

(12) The undertaker must ensure that only—

(a)inert material of natural origin and drilling mud, produced during construction drilling and seabed preparation for foundation works comprised in Work No. 3B;

(b)dredged material produced during seabed preparation for foundation works comprised in Work No. 3B; and

(c)inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 4B,

is disposed of at disposal site reference HU209.

(13) The undertaker must ensure that only inert material of natural origin and dredged material produced during cable laying preparation works comprised in Work No. 4B is disposed of at disposal site reference HU210.

(14) The undertaker must ensure that no waste concrete slurry or wash water from concrete or cement works is discharged into the marine environment. Concrete, cement mixing and washing areas must be contained to prevent run-off entering the water through the freeing ports.

(15) The undertaker must ensure that any rock material used in the construction of the authorised scheme is from a recognised source, free from contaminants and containing minimal fines.

(16) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU211.

(17) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU209.

(18) The undertaker must notify the MMO within 48 hours of the completion of the final authorised disposal at disposal site reference HU210.

Commencement Information

I123Sch. 11 para. 6 in force at 7.9.2016, see art. 1(2)

Force majeureE+W+S

7.  If, due to stress of weather or any other cause, the master of a vessel determines that it is necessary to deposit—

(a)authorised deposits outside of the offshore Order limits or disposal site references HU209, HU210 or HU211; or

(b)unauthorised deposits within or outside of the offshore Order limits or disposal site references HU209, HU210 or HU211,

because the safety of human life and/or of the vessel is threatened, full details of the circumstances of the deposit must be notified to the MMO within 48 hours.

Commencement Information

I124Sch. 11 para. 7 in force at 7.9.2016, see art. 1(2)

Pre-construction plans and documentationE+W+S

8.—(1) The licensed activities may not commence until a plan setting out proposed details of the authorised scheme and including the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO following appropriate consultation with Trinity House and the MCA—

(a)number, dimensions, specification, foundation types and depth for each offshore HVAC collector substation, offshore HVDC converter substation and offshore reactive compensation substation;

(b)grid co-ordinates of the centre point of the proposed location for each offshore HVAC collector substation, offshore HVDC converter substation and offshore reactive compensation substation, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions;

(c)proposed layout of all cables, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions; and

(d)location and specification of all other aspects of the authorised scheme, subject to any micro-siting required due to anthropological constraints, environmental constraints or difficult ground conditions.

(2) The licensed activities, or any phase of those activities, may not commence until a code of construction practice incorporating the following (insofar as relevant to that activity or phase of activity) has been submitted to and approved in writing by the MMO—

(a)a construction and monitoring programme, to include details of—

(i)the proposed construction start date;

(ii)proposed timings for mobilisation of plant, delivery of materials and installation works; and

(iii)proposed pre-construction surveys, baseline report format and content, construction monitoring, post-construction monitoring and related reporting in accordance with Conditions 13, 14 and 15. The pre-construction survey programme and all pre-construction survey methodologies must be submitted to the MMO for written approval by the MMO in consultation with the relevant statutory nature conservation body at least 4 months before the commencement of any survey works detailed within;

(b)a construction method statement in accordance with the environmental statement, including details of—

(i)foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii)installation of offshore HVAC collector substations, offshore HVDC converter substations and offshore reactive compensation substations, including any seabed preparation and scour protection;

(iii)circuit installation, including any seabed preparation and circuit protection;

(iv)contractors;

(v)vessels; and

(vi)associated works;

(c)a project environmental management and monitoring plan, to include details of—

(i)a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised scheme in relation to all activities carried out seaward of MHWS. The plan must include a mechanism for reporting oil, fuel and chemical spills to the MMO Marine Pollution Response Team;

(ii)a chemical risk analysis to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii)a disposal plan detailing the locations, methods and timings of dredging and disposal, as well as disposal site monitoring requirements;

(iv)waste management and disposal arrangements;

(v)locations of any archaeological exclusion zones agreed as part of the written scheme of archaeological investigation approved under sub-paragraph (g);

(vi)any seasonal restrictions on construction works; and

(vii)the appointment and responsibilities of a fisheries liaison officer, an environmental liaison officer and an intertidal ecological clerk of works;

(d)a scour protection management and cable armouring plan providing details of the need, type, sources, quantity, location and installation methods for scour protection and cable armouring to be within the scope of the environmental impact assessment recorded in the environmental statement;

(e)in the event that driven or part-driven pile foundations are proposed to be used, a marine mammal mitigation protocol, the intention of which is to prevent injury and/or significant disturbance to marine mammals, following current best practice as advised by the statutory nature conservation bodies, which may include, but is not limited to—

(i)identification of a marine mammal mitigation zone (“MMMZ”);

(ii)appointment of an appropriate number of suitably qualified marine mammal observers;

(iii)methods for the detection of marine mammals within the MMMZ whether visually (by the marine mammal observers) or acoustically using passive acoustic monitoring equipment or other means of detection;

(iv)a reporting methodology to enable efficient communication between the marine mammal observers and the person responsible for approving commencement of piling;

(v)an appropriate soft start procedure whereby piling activities do not commence until an agreed time has elapsed and during which marine mammals have not been detected within the MMMZ;

(vi)where appropriate, methods for the application of acoustic deterrent devices; and

(vii)where appropriate, consideration of the use of noise reduction at source technologies;

(f)a cable specification and installation plan, to include—

(i)technical specification of offshore electrical circuits, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice;

(ii)a detailed cable laying plan, including geotechnical data, cable laying techniques and a cable burial risk assessment encompassing the identification of any cable protection that exceeds 5% of navigable depth referenced to Chart Datum and, in the event that any area of cable protection exceeding 5% of navigable depth is identified, details of any steps (to be determined following consultation with the MCA) to be taken to ensure existing and future safe navigation is not compromised;

(iii)details of the steps to be taken, where the offshore electrical circuits across the intertidal area are buried using trenching or ploughing to ensure that the excavation and subsequent backfilling is carried out in such a way as to maintain the sediment profile so far as is reasonably practicable; and

(iv)details of the steps to be taken, where the offshore electrical circuits across the intertidal area are installed using a trenchless technique;

(g)a written scheme of archaeological investigation in relation to the offshore Order limits seaward of MHWS in accordance with industry good practice to include—

(i)details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii)a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver- or remotely-operated vehicle investigations;

(iii)analysis and reporting of survey data to be submitted to the MMO within 4 months of survey completion;

(iv)delivery of any mitigation including, where necessary, archaeological exclusion zones;

(v)monitoring during and post-construction, including a conservation programme for finds;

(vi)archiving of archaeological material; and

(vii)a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised scheme;

(h)a proposed survey and reinstatement plan for Salicornia forming Annex 1 habitat in the parts of the offshore Order limits within which it is proposed to carry out construction works comprised in Work No. 5B, including the circumstances in which reinstatement will be required and the proposed methods of reinstatement;

(i)an offshore project maintenance plan to be submitted to the MMO at least 4 months before commencement of the operation of the licensed activities and to include provision for the review and resubmission of the plan every 3 years during the operational phase;

(j)an aids to navigation management plan specifying how the undertaker will ensure compliance with Condition 4 from the start of construction of the authorised scheme seaward of MHWS to the completion of decommissioning.

(3) Before the submission of the pre-construction plans and documentation required by this Condition, the undertaker must provide a copy of the plans and documentation to the other undertakers under the Order.

(4) The undertaker must participate in liaison meetings with other undertakers under the Order as requested from time to time by the MMO in writing in advance. The meetings must be chaired by the MMO and must consider such matters as are determined by the MMO relating to the efficient operation of a deemed marine licence where it has an impact on the efficient operation of any other deemed marine licence issued under the Order (including as varied or transferred).

(5) Before giving its approval under paragraph (2), the MMO must—

(a)in relation to any programme or plan submitted under sub-paragraphs (a), (c), (d), (f), (h) or (i), consult the relevant statutory nature conservation body and the Environment Agency;

(b)in relation to any statement or protocol submitted under sub-paragraphs (b) or (e), consult the relevant statutory nature conservation body;

(c)in relation to a scheme submitted under sub-paragraph (g), consult Historic England; and

(d)in relation to a plan submitted under sub-paragraph (j), consult Trinity House.

(6) In the event that driven or part-driven pile foundations are proposed to be used, the MMO must not approve the plan referred to in paragraph (1) or the code referred to in paragraph (2) unless the MMO is satisfied, after consulting such persons as the Secretary of State may specify in relation to the plan or the part of the code specified by the Secretary of State (in addition to the persons with whom consultation is otherwise required under this Condition), that either the plan or code (or both of them) provide such mitigation as is necessary to avoid adversely affecting the integrity (within the meaning of the 2007 Regulations) of a relevant site, to the extent that marine mammals are a protected feature of that site.

(7) The mitigation referred to in paragraph (6) may include (without limitation)—

(a)seasonal restrictions to piling;

(b)scheduling of piling, having regard to previous, ongoing and future piling associated with other offshore developments, based on an updated assessment of cumulative impacts;

(c)the use of alternative foundation methodologies, such as jacket foundations (suction piles) or gravity base foundations;

(d)the use of noise reduction at source technologies;

(e)the use of other relevant technologies or methodologies that may emerge in the future.

(8) In paragraph (6), “relevant site” means—

(a)a European offshore marine site;

(b)a European site.

(9) For the purpose of paragraph (6)—

(a)the Southern North Sea possible Special Area of Conservation must be treated as a European offshore marine site until—

(i)that Area (or any part of it) becomes a European offshore marine site or a European site; or

(ii)it is decided that no part of that Area should be a European offshore marine site or a European site; and

(b)harbour porpoise must be treated as a protected feature of the Southern North Sea possible Special Area of Conservation.

(10) In this Condition—

“2007 Regulations” means the Offshore Marine Conservation (Natural Habitats, &c.) Regulations 2007;

“disturbance” must be construed in accordance with regulation 39(1)(b) of the 2007 Regulations;

“European offshore marine site” has the meaning given in regulation 15 of the 2007 Regulations;

“European site” has the meaning given in regulation 24 of the 2007 Regulations;

“Southern North Sea possible Special Area of Conservation” means the Southern North Sea possible Special Area of Conservation as set out in the JNCC 2016 Harbour Porpoise Possible Special Area of Conservation Consultation dated January 2016.

Commencement Information

I125Sch. 11 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Record of the Historic Environment, by submitting a Historic England OASIS form with a digital copy of the report within 6 months of completion of construction of the authorised scheme. The undertaker must notify the MMO and, where the report relates to the intertidal area, Lincolnshire County Council that the OASIS report has been submitted to the National Record of the Historic Environment within 2 weeks of the submission.

Commencement Information

I126Sch. 11 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Each programme, statement, plan, protocol or scheme required to be approved under Condition 8

(a)must be submitted for approval at least 4 months before the intended start of construction, except where otherwise stated or where an alternative date is agreed in writing by the MMO; and

(b)must be accompanied by—

(i)a statement confirming that the undertaker has complied with Condition 8(3) in relation to the programme, statement, plan, protocol or scheme;

(ii)any comments received by the undertaker from the other undertakers, or a statement from the undertaker confirming that no such comments were received; and

(iii)details of any consultation that has been carried out with the undertakers with the benefit of all or part of the deemed marine licences under the Hornsea One Offshore Wind Farm Order 2014 and any comments received from those undertakers.

(2) The undertaker must comply with the plans and documentation approved under Condition 8 in carrying out the licensed activities unless otherwise agreed in writing by the MMO.

(3) Before agreeing an alternative date under paragraph (1)(a) or a change to approved details under paragraph (2) relating to any document in respect of which consultation is required under Condition 8, the MMO must consult the relevant consultation body referred to in that Condition.

Commencement Information

I127Sch. 11 para. 10 in force at 7.9.2016, see art. 1(2)

Reporting of engaged agents, contractors and vesselsE+W+S

11.—(1) The undertaker must provide the following information to the MMO—

(a)the name and function of any agent or contractor appointed to engage in the licensed activities at least 5 working days before the commencement of the licensed activities or any part of them; and

(b)each week during the construction of the authorised scheme, a completed Hydrographic Note H102 listing the construction vessels currently and to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO and MMO Coastal Office in writing before the agent, contractor or vessel engages in the licensed activities.

(3) All agents, contractors and vessel operators must comply with the Conditions.

Commencement Information

I128Sch. 11 para. 11 in force at 7.9.2016, see art. 1(2)

Equipment and operation of vessels engaged in licensed activitiesE+W+S

12.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of the activities in accordance with the Conditions and must comply with paragraphs (2) to (5).

(2) All motor-powered vessels must be fitted with—

(a)an electronic positioning aid to provide navigational data;

(b)radar;

(c)an echo sounder; and

(d)multi-channel VHF.

(3) All vessel names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All communication on VHF working frequencies must be in English.

(5) No vessel may engage in the licensed activities until all the equipment specified in paragraph (2) is fully operational.

Commencement Information

I129Sch. 11 para. 12 in force at 7.9.2016, see art. 1(2)

Pre-construction monitoring and surveysE+W+S

13.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body and, in respect of the surveys required under paragraph (2)(b) and (c), in consultation with the Environment Agency, of proposed pre-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format and content for a pre-construction baseline report; and—

(a)the survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the post-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement; and

(b)the baseline report proposals must ensure that the outcome of the agreed surveys together with existing data and reports are drawn together to present a valid statement of the pre-construction position, with any limitations, and must make clear what post-construction comparison is intended and the justification for this being required.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the pre-construction surveys must comprise, in outline—

(a)a survey to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) in the parts of the offshore Order limits in which it is proposed to carry out construction works under this licence;

(b)a phase 1 survey of the intertidal area within which it is proposed to carry out construction works;

(c)a high-resolution swath bathymetric survey to include a 100% coverage and a side-scan sonar survey of the parts of the offshore Order limits within which it is proposed to carry out construction works and disposal activities under this licence; and

(d)a grab survey and particle size analysis in the parts of the offshore Order limits within which it is proposed to carry out dredging and disposal activities relating to Work Nos. 3B and 4B under this licence within a period not greater than 12 months before the dredging and disposal activities to determine the extent of suitable herring spawning habitat within those areas.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing by the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I130Sch. 11 para. 13 in force at 7.9.2016, see art. 1(2)

Construction monitoringE+W+S

14.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body of any proposed construction monitoring, including methodologies and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt from the undertaker of specific proposals pursuant to this Condition, so far as applicable, the construction monitoring must comprise, in outline—

(a)unless the MMO agrees otherwise in writing, measurements of noise generated by the installation of the first 4 foundations of each discrete foundation type comprised in Work No. 2B to be constructed under this licence where driven or part-driven pile foundations are used;

(b)recording of any visual sightings or acoustic detection of marine mammals where required as part of the marine mammal mitigation protocol under Condition 8(2)(e); and

(c)any ornithological monitoring required by the ornithological monitoring plan submitted in accordance with Condition 8(2)(k).

(3) The undertaker must carry out the surveys approved under paragraph (1), including any further noise monitoring required in writing by the MMO under paragraph (4), and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

(4) The results of the initial noise measurements monitored in accordance with paragraph (2)(a) must be provided to the MMO within 6 weeks of the installation of the first 4 foundations of each discrete foundation type, for the MMO to determine, following assessment of this report, whether any further noise monitoring is required.

(5) Construction monitoring must include vessel traffic monitoring by automatic identification system for the duration of the construction period. A report must be submitted to the MMO and the MCA at the end of each year of the construction period.

Commencement Information

I131Sch. 11 para. 14 in force at 7.9.2016, see art. 1(2)

Post-constructionE+W+S

15.—(1) The undertaker must, in discharging Condition 8(2)(a), submit details for written approval by the MMO in consultation with the relevant statutory nature conservation body and, in respect of the surveys required under paragraph (2)(a), (b) and (c), in consultation with the Environment Agency, of proposed post-construction surveys, including methodologies (including appropriate buffers, where relevant) and timings, and a proposed format, content and timings for providing reports on the results. The survey proposals must be in general accordance with the principles set out in the in-principle monitoring plan and must specify each survey’s objectives and explain how it will assist in either informing a useful and valid comparison with the pre-construction position and/or will enable the validation or otherwise of key predictions in the environmental statement.

(2) Subject to receipt of specific proposals, so far as applicable, the post-construction surveys must comprise, in outline—

(a)a survey to determine any change in the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex 1 habitats) identified in the pre-construction survey in the parts of the offshore Order limits in which construction works were carried out. The survey design must be informed by the results of the pre-construction benthic survey;

(b)a high-resolution swath bathymetric survey to be undertaken no sooner than 6 months following completion of construction works and disposal activities to include a 100% coverage of the parts of the offshore Order limits with a water depth no greater than 12 metres (referenced to Chart Datum) within which construction works and disposal activities were carried out under this licence to assess any changes in bedform morphology and such further monitoring as may be required to ensure that the cables have been buried or protected and sediment is able to move over any installed cable protection. The need for further surveys must be agreed in writing with the MMO following submission of the first year of survey data;

(c)a high-resolution bathymetric survey of a representative sample area, as may be agreed in writing with the MMO, of the parts of the offshore Order limits with a water depth no greater than 12 metres (referenced to Chart Datum) within which construction works and disposal activities were carried out under this licence following the first major storm event the timing of which must be agreed with the MMO in consultation with Natural England and the Environment Agency;

(d)a grab survey and particle size analysis in the parts of the offshore Order limits within which dredging and disposal activities relating to Work Nos. 3B and 4B were carried out under this licence within 12 months of the completion of the dredging and disposal activities to determine the extent of suitable herring spawning ground habitat within those areas; and

(e)vessel traffic monitoring by automatic identification system, for 28 days taking account seasonal variations in traffic patterns, for a maximum duration of 1 year post- construction. A report must be submitted to the MMO and the MCA at the end of the first year after construction is completed.

(3) The undertaker must carry out the surveys agreed under paragraph (1) and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed in writing with the MMO in consultation with the relevant statutory nature conservation body.

Commencement Information

I132Sch. 11 para. 15 in force at 7.9.2016, see art. 1(2)

Offshore decommissioningE+W+S

16.—(1) No decommissioning activities may commence until a plan for the carrying out of the activities has been submitted to and approved in writing by the MMO and, where the plan relates to the decommissioning of Work No. 4B or 5B, the MMO must consult the Environment Agency before giving its approval.

(2) The plan must be submitted for approval at least 4 months before the intended start of the decommissioning activities, except where otherwise stated or unless otherwise agreed in writing by the MMO.

(3) The plan must be implemented as approved.

Commencement Information

I133Sch. 11 para. 16 in force at 7.9.2016, see art. 1(2)

Amendments to approved plans, etc.E+W+S

17.—(1) Where any Condition requires the licensed activities to be carried out in accordance with any plan, programme, code, statement, protocol scheme or details (the “plan”) approved by the MMO, the approved plan must be taken to include any amendment to the plan that may subsequently be approved in writing by the MMO.

(2) Any amendment to the plan must be in accordance with the principles and assessments set out in the environmental statement, and approval for an amendment may be given only where it has been demonstrated to the satisfaction of the MMO that amendment is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I134Sch. 11 para. 17 in force at 7.9.2016, see art. 1(2)

Restrictions in intertidal area and Humber Estuary Special Area of ConservationE+W+S

18.—(1) The cable protection to be used within the Humber Estuary Special Area of Conservation must be frond mattressing, unless otherwise agreed in writing with the MMO.

(2) No cable protection may be used within the intertidal area of the Humber Estuary Special Area of Conservation.

(3) The undertaker must not construct or install the licensed activities comprised in Work No. 4B or 5B in the intertidal area during the overwintering period unless otherwise agreed in writing with the MMO, in consultation with Natural England.

(4) The undertaker must not construct or install the licensed activities comprised in Work Nos. 4B and 5B in the intertidal area within 500 metres seaward of the seawall during the period of time commencing 2 hours before a high tide predicted to be greater than 6.5 metres Chart Datum and ending 2 hours after a high tide predicted to be greater than 6.5 metres Chart Datum between 1st April and 31st May (inclusive) and 1st August to 30th September (inclusive), unless provided for in the construction and monitoring programme submitted and approved under Condition 8(2)(a) or the construction method statement submitted and approved under Condition 8(2)(b) or unless otherwise agreed in writing by the MMO, in consultation with Natural England.

(5) The undertaker must not carry out inspections in the intertidal area during the overwintering period to the extent that such inspections require to be carried out—

(a)more than once per overwintering period;

(b)over more than 2 consecutive days by people on foot; or

(c)by more than 5 people on foot at any one time,

unless otherwise agreed in writing with the MMO, in consultation with Natural England or unless provided for in the offshore project maintenance plan submitted and approved under Condition 8(2)(i).

(6) Where this Condition provides that the MMO may agree to an alternative to what is otherwise provided under this Condition—

(a)any alternative must be in accordance with the principles and assessments set out in the environmental statement; and

(b)agreement to any alternative may be given only where it has been demonstrated to the satisfaction of the MMO that the alternative is unlikely to give rise to any materially new or materially different effects from those assessed in the environmental statement.

(7) In this Condition, “overwintering period” means the period between 1st October and 31st March (inclusive).

Commencement Information

I135Sch. 11 para. 18 in force at 7.9.2016, see art. 1(2)

Article 39

SCHEDULE 12E+W+SProtective provisions

PART 1E+W+SProtection for Environment Agency and drainage authorities

1.  The provisions of this Part have effect for the protection of a drainage authority unless otherwise agreed in writing between the relevant undertaker and the drainage authority.E+W+S

Commencement Information

I136Sch. 12 Pt. 1 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“construction” includes execution, placing, altering, replacing, relaying and removal; and “construct” and “constructed” must be construed accordingly;

“drainage authority” means—

(a)

in relation to an ordinary watercourse, the drainage board concerned within the meaning of section 23 of the Land Drainage Act 1991; and

(b)

in relation to a main river or any sea defence work, the Environment Agency;

“drainage work” means any watercourse other than the River Humber and includes any land that provides or is expected to provide flood storage capacity for any watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence, sea defence or tidal monitoring;

“ordinary watercourse” has the meaning given in the Land Drainage Act 1991(12);

“plans” includes sections, drawings, specifications and method statements;

“relevant undertaker” means—

(a)

in relation to specified work that is Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to specified work that is Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to specified work that is shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea;

“specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 16 metres of a drainage work or is otherwise likely to—

(a)

affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work;

(b)

affect the flow, purity, or quality of water in any watercourse; or

(c)

affect the conservation, distribution or use of water resources.

Commencement Information

I137Sch. 12 Pt. 1 para. 2 in force at 7.9.2016, see art. 1(2)

3.—(1) Before beginning to construct any specified work, the relevant undertaker must submit to the drainage authority plans of the specified work and such further particulars available to it as the drainage authority may within 28 days of the submission of the plans reasonably require.E+W+S

(2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the drainage authority or determined under paragraph 11.

(3) Any approval of the drainage authority required under this paragraph—

(a)must not be unreasonably withheld or delayed;

(b)is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval( or submission of further particulars if required by the drainage authority under sub-paragraph (1)) or, in the case of a refusal, if it is not accompanied by a statement of the grounds of refusal; and

(c)may be given subject to such reasonable requirements as the drainage authority may make for the protection of any drainage work or, where the drainage authority is the Environment Agency, for the protection of water resources for the prevention of pollution or in the discharge of its environmental duties.

(4) The drainage authority must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b).

Commencement Information

I138Sch. 12 Pt. 1 para. 3 in force at 7.9.2016, see art. 1(2)

4.  Without limiting paragraph 3, the requirements which the drainage authority may make under that paragraph include conditions requiring the relevant undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified work (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary—E+W+S

(a)to safeguard any drainage work against damage; or

(b)to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

Commencement Information

I139Sch. 12 Pt. 1 para. 4 in force at 7.9.2016, see art. 1(2)

5.—(1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 4, must be constructed—E+W+S

(a)without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part; and

(b)to the reasonable satisfaction of the drainage authority,

and an officer of the drainage authority is entitled to watch and inspect the construction of such works.

(2) The relevant undertaker must give to the drainage authority—

(a)not less than 14 days’ notice in writing of its intention to commence construction of any specified work; and

(b)notice in writing of its completion not later than 7 days after the date on which it is brought into use.

(3) If the drainage authority reasonably requires, the relevant undertaker must construct all or part of the protective works so that they are in place before the construction of the specified work.

(4) If any part of a specified work or any protective work required by the drainage authority is constructed otherwise than in accordance with the requirements of this Part, the drainage authority may by notice in writing require the relevant undertaker at the relevant undertaker’s expense to comply with the requirements of this Part or (if the relevant undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the drainage authority reasonably requires.

(5) Subject to sub-paragraph (6), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served on the relevant undertaker, the relevant undertaker has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the drainage authority may execute the works specified in the notice, and any expenditure incurred by it in so doing is recoverable from the relevant undertaker.

(6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the drainage authority must not except in emergency exercise the powers conferred by sub-paragraph (5) until the dispute has been finally determined.

Commencement Information

I140Sch. 12 Pt. 1 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Subject to sub-paragraph (5) the relevant undertaker must from the commencement of the construction of any specified work maintain in good repair and condition and free from obstruction any drainage work that is situated within the limits of deviation on land held by the relevant undertaker for the purposes of or in connection with the specified work, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence.E+W+S

(2) If any drainage work that the relevant undertaker is liable to maintain is not maintained to the reasonable satisfaction of the drainage authority, the drainage authority may by notice in writing require the relevant undertaker to repair and restore the work, or any part of such work, or (if the relevant undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the drainage authority reasonably requires.

(3) If, within a reasonable period being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the relevant undertaker, the relevant undertaker has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the drainage authority may do what is necessary for such compliance and may recover any expenditure reasonably incurred by it in so doing from the relevant undertaker.

(4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), the drainage authority must not except in a case of emergency exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined.

(5) This paragraph does not apply to—

(a)drainage works that are vested in the drainage authority or that the drainage authority or another person is liable to maintain and is not prevented by this Order from so doing; and

(b)any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part.

Commencement Information

I141Sch. 12 Pt. 1 para. 6 in force at 7.9.2016, see art. 1(2)

7.  If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or the drainage work is otherwise damaged, the impairment or damage must be made good by the relevant undertaker to the reasonable satisfaction of the drainage authority and, if the relevant undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the relevant undertaker the expense reasonably incurred by it in doing so.E+W+S

Commencement Information

I142Sch. 12 Pt. 1 para. 7 in force at 7.9.2016, see art. 1(2)

8.  The relevant undertaker must indemnify the drainage authority in respect of all costs, charges and expenses that the drainage authority may reasonably incur, have to pay or may sustain—E+W+S

(a)in the examination or approval of plans under this Part;

(b)in inspecting the construction of any specified work or any protective works required by the drainage authority under this Part; and

(c)in carrying out of any surveys or tests by the drainage authority that are reasonably required in connection with the construction of the specified work.

Commencement Information

I143Sch. 12 Pt. 1 para. 8 in force at 7.9.2016, see art. 1(2)

9.—(1) Without limiting the other provisions of this Part, the relevant undertaker must indemnify the drainage authority in respect of all claims, demands, proceedings, costs, damages, expenses or loss that may be made or taken against, recovered from or incurred by, the drainage authority by reason of—E+W+S

(a)any damage to any drainage work so as to impair its efficiency for the purposes of flood defence;

(b)any raising or lowering of the water table in land adjoining the authorised development or any sewers, drains and watercourses; or

(c)any flooding or increased flooding of any such land; and

(d)where the drainage authority is the Environment Agency, inadequate water quality in any watercourse or other surface waters or in any groundwater,

that is caused by the construction of any specified work or any act or omission of the relevant undertaker, its contractors, agents or employees whilst engaged on the work.

(2) The drainage authority must give to the relevant undertaker reasonable notice of any such claim or demand, and no settlement or compromise may be made without the agreement of the relevant undertaker which agreement must not be unreasonably withheld or delayed.

Commencement Information

I144Sch. 12 Pt. 1 para. 9 in force at 7.9.2016, see art. 1(2)

10.  The fact that any work or thing has been executed or done by the relevant undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the relevant undertaker from any liability under this Part.E+W+S

Commencement Information

I145Sch. 12 Pt. 1 para. 10 in force at 7.9.2016, see art. 1(2)

11.  Any dispute between the relevant undertaker and the drainage authority under this Part, if the parties agree, must be determined by arbitration under article 41 (arbitration), but otherwise must be determined by the Secretary of State for Environment, Food and Rural Affairs and the Secretary of State for Business, Energy and Industrial Strategy acting jointly on a reference to them by the relevant undertaker or the drainage authority, after notice in writing by one to the other.E+W+S

Commencement Information

I146Sch. 12 Pt. 1 para. 11 in force at 7.9.2016, see art. 1(2)

PART 2E+W+SProtection for Network Rail Infrastructure Limited, etc.

1.  The provisions of this Part have effect unless otherwise agreed in writing between the undertaker and Network Rail and, in the case of paragraph 15, any other person on whom rights or obligations are conferred by that paragraph.E+W+S

Commencement Information

I147Sch. 12 Pt. 2 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“construction” includes execution, placing, alteration and reconstruction; and “construct” and “constructed” have corresponding meanings;

“engineer” means an engineer appointed by Network Rail for the purposes of this Order;

“network licence” means the network licence, as amended from time to time, granted to Network Rail Infrastructure Limited by the Secretary of State in exercise of the powers in section 8 of the Railways Act 1993(13);

“Network Rail” means—

(a)

Network Rail Infrastructure Limited (company number 2904587); and

(b)

any associated company of Network Rail Infrastructure Limited that holds property for railway purposes,

and for the purpose of paragraph (b) “associated company” means any company that is (within the meaning of section 1159 of the Companies Act 2006(14)) the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited;

“plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property;

“railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993(15)) or station lease;

“railway property” means—

(a)

any railway belonging to Network Rail;

(b)

any station, land, works, apparatus and equipment belonging to Network Rail or connected with any such railway; and

(c)

any easement or other property interest held or used by Network Rail for the purposes of such railway or works, apparatus or equipment;

“relevant undertaker” means—

(a)

in relation to specified work that is Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to specified work that is Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to specified work that is shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea;

“specified work” means so much of any of the authorised development as is situated on, across, under, over or within 15 metres of, or may in any way adversely affect, railway property.

Commencement Information

I148Sch. 12 Pt. 2 para. 2 in force at 7.9.2016, see art. 1(2)

3.—(1) Where under this Part Network Rail is required to give its consent, agreement or approval in respect of any matter, that consent, agreement or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute.E+W+S

(2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must—

(a)co-operate with the relevant undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and

(b)use their reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised development pursuant to this Order.

Commencement Information

I149Sch. 12 Pt. 2 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) The undertaker must not exercise the powers conferred by article 17 (authority to survey and investigate land) or section 11(3) of the 1965 Act (powers of entry) in respect of any railway property unless the exercise of such powers is with the consent of Network Rail.E+W+S

(2) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the consent of Network Rail.

(3) The undertaker must not exercise the powers conferred by sections 271 (extinguishment of rights of statutory undertakers: preliminary notices) or 272 (extinguishment of rights of electronic code communications operators: preliminary notices) of the 1990 Act(16) or article 28 (statutory undertakers) in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the consent of Network Rail.

(4) The undertaker must not under the powers of this Order acquire or use or acquire new rights over any railway property except with the consent of Network Rail.

(5) Where Network Rail is asked to give its consent pursuant to this paragraph, its consent must not be unreasonably withheld but may be given subject to reasonable conditions.

Commencement Information

I150Sch. 12 Pt. 2 para. 4 in force at 7.9.2016, see art. 1(2)

5.—(1) The relevant undertaker must before commencing construction of any specified work supply to Network Rail proper and sufficient plans of that work for the reasonable approval of the engineer, and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration.E+W+S

(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld, and if, by the end of the period of 28 days beginning with the date on which such plans have been supplied to Network Rail, the engineer has not intimated disapproval of those plans and the grounds of disapproval—

(a)the relevant undertaker may serve on the engineer written notice requiring the engineer to intimate approval or disapproval within a further period of 28 days beginning with the date on which the engineer receives written notice from the relevant undertaker; and

(b)if by the expiry of the further 28 days the engineer has not intimated approval or disapproval, the engineer is deemed to have approved the plans as supplied.

(3) If, by the end of the period of 28 days beginning with the date on which written notice was served on the engineer under sub-paragraph (2), Network Rail gives notice to the relevant undertaker that Network Rail desires itself to construct any part of a specified work that in the opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail, then, if the relevant undertaker desires such part of the specified work to be constructed, Network Rail must construct it with all reasonable dispatch on behalf of and to the reasonable satisfaction of the relevant undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph, and under the supervision (where appropriate and if given) of the relevant undertaker.

(4) When signifying approval of the plans the engineer may specify any protective works (whether temporary or permanent) that in the engineer’s opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using them (including any relocation, de-commissioning or removal of works, apparatus or equipment necessitated by a specified work or the comfort and safety of passengers who may be affected by the specified work), and—

(a)such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the relevant undertaker, if Network Rail so desires, at the expense of the relevant undertaker in either case, with all reasonable dispatch; and

(b)the relevant undertaker must not commence the construction of the specified work until the engineer has notified the relevant undertaker that the protective works have been completed to the engineer’s reasonable satisfaction.

Commencement Information

I151Sch. 12 Pt. 2 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Any specified work and any protective works to be constructed by virtue of paragraph 5(4) must, when commenced, be constructed—E+W+S

(a)with all reasonable dispatch in accordance with the plans approved or deemed to have been approved or settled under paragraph 5;

(b)under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

(c)in such manner as to cause as little damage as is possible to railway property; and

(d)so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic on it and the use by passengers of railway property.

(2) If any damage to railway property or any such interference or obstruction is caused by the carrying out of, or in consequence of the construction of a specified work, the relevant undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may sustain by reason of any such damage, interference or obstruction.

(3) Nothing in this Part imposes—

(a)any liability on the relevant undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of Network Rail or its servants, contractors or agents; or

(b)any liability on Network Rail with respect of any damage, costs, expenses or loss attributable to the negligence of the relevant undertaker or its servants, contractors or agents.

Commencement Information

I152Sch. 12 Pt. 2 para. 6 in force at 7.9.2016, see art. 1(2)

7.  The relevant undertaker must—E+W+S

(a)at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

(b)supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

Commencement Information

I153Sch. 12 Pt. 2 para. 7 in force at 7.9.2016, see art. 1(2)

8.  Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.E+W+S

Commencement Information

I154Sch. 12 Pt. 2 para. 8 in force at 7.9.2016, see art. 1(2)

9.—(1) If any permanent or temporary alterations or additions to railway property are reasonably necessary in consequence of the construction of a specified work, or during a period of 24 months after the completion of that work in order to ensure the safety of railway property or the continued safe operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail.E+W+S

(2) If Network Rail gives to the relevant undertaker reasonable notice of its intention to carry out such alterations or additions (which must be specified in the notice), the relevant undertaker must pay to Network Rail the reasonable cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs that may be expected to be reasonably incurred by Network Rail in maintaining, working and, when necessary, renewing any such alterations or additions.

(3) If during the construction of a specified work by the relevant undertaker, Network Rail gives notice to the relevant undertaker that Network Rail desires itself to construct that part of the specified work which in the opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail, then, if the relevant undertaker decides that part of the specified work is to be constructed,—

(a)Network Rail may assume construction of that part of the specified work; and

(b)the relevant undertaker must, notwithstanding any approval of a specified work under paragraph 5(1), pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss that it may suffer by reason of the execution by Network Rail of that part of the specified work.

(4) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 10(a) provide such details of the formula by which those sums have been calculated as the relevant undertaker may reasonably require.

(5) If the cost of maintaining, working or renewing railway property is reduced in consequence of any such alterations or additions, a capitalised sum representing the saving must be set off against any sum payable by the relevant undertaker to Network Rail under this paragraph.

Commencement Information

I155Sch. 12 Pt. 2 para. 9 in force at 7.9.2016, see art. 1(2)

10.  The relevant undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses reasonably incurred by Network Rail—E+W+S

(a)in constructing any part of a specified work on behalf of the relevant undertaker as provided by paragraph 5(3) or in constructing any protective works under the provisions of paragraph 5(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works;

(b)in respect of the approval by the engineer of plans submitted by the relevant undertaker and the supervision by the engineer of the construction of a specified work;

(c)in respect of the employment or procurement of the services of any inspectors, signallers, guards and other persons whom it may be reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work;

(d)in respect of any special traffic working resulting from any speed restrictions that may in the opinion of the engineer, require to be imposed by reason or in consequence of the construction or failure of a specified work or from the substitution or diversion of services that may be reasonably necessary for the same reason; and

(e)in respect of any additional temporary lighting of railway property in the vicinity of the specified work, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work.

Commencement Information

I156Sch. 12 Pt. 2 para. 10 in force at 7.9.2016, see art. 1(2)

11.—(1) In this paragraph—E+W+S

“EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail’s apparatus generated by the operation of the authorised development, where such interference is of a level that adversely affects the safe operation of Network Rail’s apparatus;

“Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the authorised development) that are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications.

(2) This paragraph applies to EMI only to the extent that the EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 5(1) for the relevant part of the authorised development giving rise to EMI (unless the relevant undertaker has been given notice in writing before the approval of those plans of the intention to make such change).

(3) Subject to sub-paragraph (5), the relevant undertaker must in the design and construction of the authorised development take all measures necessary to prevent EMI and establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness.

(4) In order to facilitate the relevant undertaker’s compliance with sub-paragraph (3)—

(a)the relevant undertaker must consult Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus that may be at risk of EMI, and thereafter must continue to consult Network Rail (both before and after formal submission of plans under paragraph 5(1)) in order to identify all potential causes of EMI and the measures required to eliminate them;

(b)Network Rail must make available to the relevant undertaker all information in the possession of Network Rail reasonably requested by the relevant undertaker in respect of Network Rail’s apparatus identified pursuant to paragraph (a); and

(c)Network Rail must allow the relevant undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to paragraph (a).

(5) In any case where it is established that EMI can reasonably be prevented only by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution selected are in the reasonable discretion of Network Rail, and in relation to such modifications paragraph 5(1) has effect subject to this sub-paragraph.

(6) If, at any time before the commencement of commercial operation of the authorised development and notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing or commissioning of the authorised development causes EMI, then the relevant undertaker must immediately on receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) immediately cease to use (or procure the cessation of use of) the relevant undertaker’s apparatus causing the EMI until all measures necessary have been taken to remedy the EMI by way of modification to the source of the EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5)) to Network Rail’s apparatus.

(7) In the event of EMI having occurred—

(a)the relevant undertaker must afford reasonable facilities to Network Rail for access to the relevant undertaker’s apparatus in the investigation of the EMI;

(b)Network Rail must afford reasonable facilities to the relevant undertaker for access to Network Rail’s apparatus in the investigation of the EMI; and

(c)Network Rail must make available to the relevant undertaker any additional material information in its possession reasonably requested by the relevant undertaker in respect of Network Rail’s apparatus or the EMI.

(8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to sub-paragraphs (5) or (6)—

(a)Network Rail must allow the relevant undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus; and

(b)any modifications to Network Rail’s apparatus approved pursuant to those sub-paragraphs must be carried out and completed by the relevant undertaker in accordance with paragraph 6.

(9) To the extent that it would not otherwise do so, the indemnity in paragraph 15(1) applies to the costs and expenses reasonably incurred or losses suffered by Network Rail through the implementation of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which sub-paragraph (6) applies.

(10) For the purpose of paragraph 10(a), any modifications to Network Rail’s apparatus under this paragraph are deemed to be protective works referred to in that sub-paragraph.

(11) In relation to any dispute arising under this paragraph, the reference in article 41 (arbitration) to an arbitrator to be agreed must be read as a reference to an arbitrator being a member of the Institution of Engineering and Technology to be agreed.

Commencement Information

I157Sch. 12 Pt. 2 para. 11 in force at 7.9.2016, see art. 1(2)

12.  If at any time after the completion of a specified work, not being a work vested in Network Rail, Network Rail gives notice to the relevant undertaker informing it that the state of maintenance of any part of the specified work appears to be such as adversely affects the operation of railway property, the relevant undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect railway property.E+W+S

Commencement Information

I158Sch. 12 Pt. 2 para. 12 in force at 7.9.2016, see art. 1(2)

13.  The relevant undertaker—E+W+S

(a)must not provide any illumination or illuminated sign or signal on or in connection with a specified work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail; and

(b)must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway.

Commencement Information

I159Sch. 12 Pt. 2 para. 13 in force at 7.9.2016, see art. 1(2)

14.  Any additional expenses that Network Rail may reasonably incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work must, provided that 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the relevant undertaker, be repaid by the relevant undertaker to Network Rail.E+W+S

Commencement Information

I160Sch. 12 Pt. 2 para. 14 in force at 7.9.2016, see art. 1(2)

15.—(1) The relevant undertaker—E+W+S

(a)must pay to Network Rail all reasonable costs, charges, damages and expenses not otherwise provided for in this Part that may be occasioned to or reasonably incurred by Network Rail by reason of—

(i)the construction, maintenance or failure of a specified work; or

(ii)any act or omission of the relevant undertaker or of any person in its employ or of its contractors or others whilst engaged on a specified work; and

(b)indemnify and keep indemnified Network Rail from and against all claims and demands arising out of or in connection with a specified work or any such failure, act or omission.

(2) The fact that any act or thing may have been done by Network Rail on behalf of the relevant undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the supervision of the engineer does not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the relevant undertaker from any liability under sub-paragraph (1).

(3) Network Rail must give the relevant undertaker reasonable notice of any such claim or demand, and no settlement or compromise of such a claim or demand may be made without the prior consent of the relevant undertaker.

(4) The sums payable by the relevant undertaker under sub-paragraph (1) must include a sum equivalent to the relevant costs.

(5) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums which Network Rail receives under sub-paragraph (4) that relates to the relevant costs of that train operator.

(6) The obligation under sub-paragraph (4) to pay Network Rail the relevant costs may, in the event of default, be enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub-paragraph (5).

(7) In this paragraph—

“relevant costs” means the costs, direct losses and expenses (including loss of revenue) reasonably incurred by each train operator as a consequence of any restriction of the use of Network Rail’s railway network as a result of the construction, maintenance or failure of a specified work or any act or omission as mentioned in sub-paragraph (1);

“train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993.

Commencement Information

I161Sch. 12 Pt. 2 para. 15 in force at 7.9.2016, see art. 1(2)

16.  Network Rail must, on receipt of a request from the relevant undertaker, from time to time provide the relevant undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the relevant undertaker is or will become liable under this Part (including the amount of the relevant costs mentioned in paragraph 15) and with such information as may reasonably enable the relevant undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Part (including any claim relating to the relevant costs).E+W+S

Commencement Information

I162Sch. 12 Pt. 2 para. 16 in force at 7.9.2016, see art. 1(2)

17.  In the assessment of any sums payable to Network Rail under this Part, no account must be taken of any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the relevant undertaker under this Part or increasing the sums so payable.E+W+S

Commencement Information

I163Sch. 12 Pt. 2 para. 17 in force at 7.9.2016, see art. 1(2)

18.  Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part 1 of the Railways Act 1993.E+W+S

Commencement Information

I164Sch. 12 Pt. 2 para. 18 in force at 7.9.2016, see art. 1(2)

19.  The undertaker must give written notice to Network Rail where any application is proposed to be made by the undertaker for the Secretary of State’s consent under article 35 (transfer of benefit of Order) and any such notice must be given no later than 28 days before any such application is made and must describe or give (as appropriate)—E+W+S

(a)the nature of the application to be made;

(b)the extent of the geographical area to which the application relates; and

(c)the name and address of the person acting for the Secretary of State to whom the application is to be made.

Commencement Information

I165Sch. 12 Pt. 2 para. 19 in force at 7.9.2016, see art. 1(2)

20.  The undertaker must no later than 28 days from the date that the plans submitted to and certified by the Secretary of State in accordance with article 40 (certification of plans, etc.), provide a set of those plans to Network Rail in the form of a computer disc with read-only memory.E+W+S

Commencement Information

I166Sch. 12 Pt. 2 para. 20 in force at 7.9.2016, see art. 1(2)

PART 3E+W+SProtection for operators of electronic communications code networks

1.  The provisions of this Part have effect for the protection of an operator unless otherwise agreed in writing between the undertaker and the operator.E+W+S

Commencement Information

I167Sch. 12 Pt. 3 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“conduit system” has the same meaning as in the electronic communications code; and references to providing a conduit system must be construed in accordance with paragraph 1(3A) of the code(17);

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(18);

“electronic communications code network” means—

(a)

so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network that the Secretary of State is providing or proposing to provide;

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

“operator” means the operator of an electronic communications code network;

“relevant undertaker” means—

(a)

in relation to authorised development that is Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to authorised development that is Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to authorised development that is shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea.

Commencement Information

I168Sch. 12 Pt. 3 para. 2 in force at 7.9.2016, see art. 1(2)

3.  Paragraph 23 of Schedule 2 to the Telecommunications Act 1984(19) (which provides a procedure for certain cases where works involve the alteration of electronic communications apparatus) applies in relation to the exercise of the powers of article 28 (statutory undertakers).E+W+S

Commencement Information

I169Sch. 12 Pt. 3 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development, its construction or any subsidence resulting from that development—E+W+S

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or other property of an operator); or

(b)there is any interruption in the supply of the service provided by an operator,

the relevant undertaker must—

(c)bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply;

(d)make reasonable compensation to an operator for loss sustained by it; and

(e)indemnify an operator against claims, demands, proceedings, costs, damages and expenses that may be made or taken against, or recovered from, or incurred by, an operator by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any claim or demand, and no settlement or compromise of the claim or demand may be made without the consent of the undertaker which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this paragraph must be referred to and settled by arbitration under article 41 (arbitration).

Commencement Information

I170Sch. 12 Pt. 3 para. 4 in force at 7.9.2016, see art. 1(2)

5.  This Part does not apply to any apparatus in respect of which the relations between the undertaker and an operator are regulated by Part 3 of the 1991 Act.E+W+S

Commencement Information

I171Sch. 12 Pt. 3 para. 5 in force at 7.9.2016, see art. 1(2)

PART 4E+W+SProtection for utility undertakers

1.  The provisions of this Part have effect for the protection of a utility undertaker unless otherwise agreed in writing between the undertaker and the utility undertaker in question.E+W+S

Commencement Information

I172Sch. 12 Pt. 4 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

“apparatus”—

(a)

in the case of a utility undertaker within paragraph (a) of the definition of that term, means electric lines or electrical plant (as defined in the 1989 Act(20)) belonging to or maintained by the utility undertaker;

(b)

in the case of a utility undertaker within paragraph (b) of the definition of that term, means any mains, pipes or other apparatus belonging to or maintained by the utility undertaker for the purposes of gas supply;

(c)

in the case of a utility undertaker within paragraph (c) of the definition of that term, means—

(i)

mains, pipes or other apparatus belonging to, or maintained by, the utility undertaker for the purposes of water supply; and

(ii)

any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991(21);

(d)

in the case of a utility undertaker within paragraph (d) of the definition of that term—

(i)

means—

(aa)

any drain or works vested in the sewerage undertaker under the Water Industry Act 1991; and

(bb)

any sewer that is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act(22) or an agreement to adopt made under section 104 of that Act; and

(ii)

includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and in each case includes any structure in which apparatus is or is to be lodged or that gives or will give access to apparatus;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or on land;

“relevant undertaker” means—

(a)

in relation to works that are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works that are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works that are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea;

“utility undertaker” means—

(a)

a licence holder within the meaning of Part 1 of the 1989 Act;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(23);

(c)

a water undertaker(24); and

(d)

a sewerage undertaker,

for the area of the authorised development and, in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained; but does not include—

(e)

Anglian Water Services Limited (company number 02366656);

(f)

Centrica plc (company number 03033654);

(g)

VPI Immingham LLP (registered number OC300980);

(h)

C.GEN Killingholme Limited (company number 06422434); or

(i)

the Hornsea One companies (as defined in Part 12).

Commencement Information

I173Sch. 12 Pt. 4 para. 2 in force at 7.9.2016, see art. 1(2)

3.  This Part does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by Part 3 of the 1991 Act.E+W+S

Commencement Information

I174Sch. 12 Pt. 4 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) Despite any provision in this Order or anything shown on the land plans the undertaker must not acquire any apparatus other than by agreement.E+W+S

(2) The undertaker must not in the exercise of the powers in this Order acquire any right over, or occupy or use, all or any part of the electricity sub-station within the land shown numbered plot 510 on the land plans without the consent of the utility undertaker responsible for its operation.

(3) Consent for the purpose of sub-paragraph (2) must not be unreasonably withheld but may be granted subject to reasonable conditions.

Commencement Information

I175Sch. 12 Pt. 4 para. 4 in force at 7.9.2016, see art. 1(2)

5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, the apparatus must not be removed under this Part, and any right of a utility undertaker to maintain the apparatus in the land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question.E+W+S

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the relevant undertaker requires the removal of any apparatus placed in that land, it must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed; and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the relevant undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the relevant undertaker and for the subsequent maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the relevant undertaker, or the relevant undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the relevant undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the relevant undertaker under this Part must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the relevant undertaker or in default of agreement settled by arbitration in accordance with article 41.

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 41, and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the relevant undertaker to be removed under this Part.

(6) Despite anything in sub-paragraph (5), if the relevant undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work to which this subparagraph applies, that work, instead of being executed by the utility undertaker, must be executed by the relevant undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) Sub-paragraph (6) applies to any part of any work necessary in connection with the construction of alternative apparatus, or the removal of apparatus required to be removed, as will take place in any land of the relevant undertaker.

(8) Nothing in sub-paragraph (6) authorises the relevant undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Commencement Information

I176Sch. 12 Pt. 4 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Where, in accordance with this Part, the relevant undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the relevant undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted on such terms and conditions as may be agreed between the relevant undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 41.E+W+S

(2) In settling those terms and conditions in respect of the alternative apparatus to be constructed, the arbitrator must—

(a)give effect to all reasonable requirements of the relevant undertaker for ensuring the safety and efficient operation of the electricity generating station and for securing any subsequent alterations or adaptations of the alternative apparatus that may be required to prevent interference with any proposed works of the relevant undertaker; and

(b)so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by the relevant undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and right enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the relevant undertaker to that utility undertaker as appears to the arbitrator to be reasonable, having regard to all the circumstances of the particular case.

Commencement Information

I177Sch. 12 Pt. 4 para. 6 in force at 7.9.2016, see art. 1(2)

7.—(1) Not less than 28 days before commencing the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the relevant undertaker under that sub-paragraph, the relevant undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.E+W+S

(2) The works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and an officer of the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by the utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the relevant undertaker, reasonably requires the removal of any apparatus and gives written notice to the relevant undertaker of that requirement, paragraphs 5 and 6 apply as if the removal of the apparatus had been required by the relevant undertaker under paragraph 5(2).

(5) Nothing in this paragraph precludes the relevant undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The relevant undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonable practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Commencement Information

I178Sch. 12 Pt. 4 para. 7 in force at 7.9.2016, see art. 1(2)

8.  If in consequence of the exercise of the powers conferred by this Order the access to any apparatus is materially obstructed, the relevant undertaker must provide such alternative means of access to such apparatus as will enable the utility undertaker to maintain or use the apparatus no less effectively than was possible before the obstruction.E+W+S

Commencement Information

I179Sch. 12 Pt. 4 para. 8 in force at 7.9.2016, see art. 1(2)

9.—(1) Subject to the following provisions of this paragraph, the relevant undertaker must pay to a utility undertaker the reasonable expenses incurred by the utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus that may be required in consequence of the execution of any works referred to in paragraph 5(2).E+W+S

(2) The value of any apparatus removed under this Part must be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

(3) If in accordance with this Part—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the relevant undertaker or, in default of agreement, is not determined by arbitration in accordance with article 41 to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount that apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which, apart from this sub-paragraph, would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I180Sch. 12 Pt. 4 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the relevant undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the relevant undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker must give the relevant undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the relevant undertaker, which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I181Sch. 12 Pt. 4 para. 10 in force at 7.9.2016, see art. 1(2)

PART 5E+W+SProtection for Associated British Ports

1.  The provisions of this Part have effect for the protection of A. B. Ports unless otherwise agreed in writing between the undertaker and A. B. PortsE+W+S

Commencement Information

I182Sch. 12 Pt. 5 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“A. B. Ports” means Associated British Ports;

“accumulation” means any accumulation of silt or other material that constitutes an impediment to navigation;

“construction” includes execution and placing, maintenance, extension, enlargement, alteration, replacement, relaying, and removal (including the removal of the electrical circuits comprised in Work Nos. 6A and 6B); and “construct” and “constructed” must be construed accordingly;

“erosion” means any erosion of the bed or banks of the River Humber or of any jetty or other structure of whatever nature;

“plans” includes sections, descriptions, drawings and specifications;

“relevant undertaker” means—

(a)

in relation to specified works that is Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to specified works that is Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to specified works that is shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea;

“specified works” means so much of Work Nos. 6A and 6B and any associated development or ancillary works as are within A. B. Ports’ jurisdiction.

Commencement Information

I183Sch. 12 Pt. 5 para. 2 in force at 7.9.2016, see art. 1(2)

3.  The undertaker must not under the powers of this Order acquire land or acquire new rights over land held by A. B. Ports for the purpose of its statutory undertaking without the consent of A. B. Ports, which consent must not be unreasonably withheld but may be given subject to reasonable conditions.E+W+S

Commencement Information

I184Sch. 12 Pt. 5 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) Before commencing the construction of the specified works, the relevant undertaker must furnish to A. B. Ports for its approval, which it must not unreasonably withhold, plans of the specified works showing the general mode of construction, depth and method of trenching and possible cable protection; and the specified works—E+W+S

(a)must not be constructed otherwise than in accordance with the plans approved by A. B. Ports; and

(b)must be executed to the reasonable satisfaction of A. B. Ports.

(2) When submitting plans in respect of the specified works to the Secretary of State pursuant to article 40 (certification of plans, etc.), the relevant undertaker must—

(a)send a copy of those plans to A. B. Ports; and

(b)on receipt of approval of plans or of any conditions or restrictions imposed by the Secretary of State, send a copy to A. B. Ports.

(3) If A. B. Ports fails to express its disapproval of any plans within 56 days after they have been furnished to it under sub-paragraph (1), it is deemed to have approved them.

Commencement Information

I185Sch. 12 Pt. 5 para. 4 in force at 7.9.2016, see art. 1(2)

5.  The relevant undertaker must give to A. B. Ports—E+W+S

(a)not less than 14 days’ written notice of its intention to commence the construction of the specified works; and

(b)not more than 14 days after completion of the construction, written notice of such completion.

Commencement Information

I186Sch. 12 Pt. 5 para. 5 in force at 7.9.2016, see art. 1(2)

6.  The relevant undertaker must at all reasonable times during construction of the specified works and afterwards allow A. B. Ports, its servants and agents, access to the specified works and all reasonable facilities for inspection of the specified works.E+W+S

Commencement Information

I187Sch. 12 Pt. 5 para. 6 in force at 7.9.2016, see art. 1(2)

7.—(1) After the purpose of any temporary works has been accomplished, the relevant undertaker must with all reasonable dispatch, or after a reasonable period of notice in writing from A. B. Ports requiring the relevant undertaker so to do, remove any such temporary works or any materials relating to them that may have been placed below the level of high water by or on behalf of the relevant undertaker.E+W+S

(2) If the relevant undertaker fails to do so within a reasonable period after receiving such notice, A. B. Ports may remove them and may recover the reasonable costs of doing so from the relevant undertaker.

Commencement Information

I188Sch. 12 Pt. 5 para. 7 in force at 7.9.2016, see art. 1(2)

8.—(1) If during the construction of the specified works it is agreed, or in the absence of agreement it is proved to the satisfaction of an arbitrator appointed under article 41 (arbitration), that any accumulation or erosion has been caused wholly or partly by the construction of the specified works or exercise of powers under this Order, the relevant undertaker, if so requested by A. B. Ports acting reasonably, must remedy the accumulation or erosion to the extent attributable to the construction or exercise of powers.E+W+S

(2) If the relevant undertaker refuses or fails to do so, A. B. Ports may itself cause the work to be done and may recover the reasonable cost of doing so from the relevant undertaker.

Commencement Information

I189Sch. 12 Pt. 5 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The relevant undertaker must pay to A. B. Ports the reasonable costs of such alterations to the marking and lighting of the navigational channel of the river as may be necessary during or in consequence of the construction of the specified works.E+W+S

Commencement Information

I190Sch. 12 Pt. 5 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Without limiting the other provisions of this Part, the relevant undertaker must indemnify A. B. Ports in respect of all losses, costs, charges, damages and expenses however caused (including a reasonable and proper proportion of the overhead charges of A. B. Ports) that may reasonably be incurred by or occasioned to A. B. Ports by reason of or arising from or in connection with—E+W+S

(a)the perusal of plans and the inspection of the specified works by A. B. Ports or its duly authorised representative;

(b)the construction or failure of the specified works or the undertaking by A. B. Ports of works or measures to prevent or remedy danger or impediment to navigation or damage to any property of A. B. Ports arising from such construction or failure; or

(c)any act or omission of the relevant undertaker or its servants or agents whilst engaged in the construction of any of the specified works.

(2) Without limiting sub-paragraph (1), the relevant undertaker must indemnify A. B. Ports in respect of all claims and demands arising out of, or in connection with, such construction, or failure or act or omission as is mentioned in that sub-paragraph.

(3) Nothing in this paragraph imposes any liability on the relevant undertaker to the extent that any losses, costs, charges, damages, expenses, claims or demands referred to in sub-paragraph (1) or (2) are attributable to negligence on the part of A. B. Ports or of any person in its employ or of its contractors or agents.

(4) A. B. Ports must give to the relevant undertaker notice in writing of any claim or demand for which the relevant undertaker may be liable under this paragraph, and no settlement or compromise of any such claim or demand may be made without the consent in writing of the relevant undertaker.

Commencement Information

I191Sch. 12 Pt. 5 para. 10 in force at 7.9.2016, see art. 1(2)

11.  The fact that any work or thing has been executed or done with the consent of A. B. Ports and in accordance with any conditions or restrictions prescribed by A. B. Ports or in accordance with any plans approved or deemed to be approved by A. B. Ports or to its satisfaction or in accordance with any directions or award of any arbitrator or in accordance with any plans approved by the Secretary of State and any conditions or restrictions imposed by the Secretary of State does not relieve the relevant undertaker from any liability under this Part.E+W+S

Commencement Information

I192Sch. 12 Pt. 5 para. 11 in force at 7.9.2016, see art. 1(2)

12.  With the exception of any duty owed by A. B. Ports to the relevant undertaker expressly provided for in this Part, nothing in this Order must be construed as imposing on A. B. Ports, either directly or indirectly, any form of duty or liability to which A. B. Ports would not otherwise be subject which is enforceable by proceedings before any court.E+W+S

Commencement Information

I193Sch. 12 Pt. 5 para. 12 in force at 7.9.2016, see art. 1(2)

13.  Nothing in this Order affects prejudicially any statutory or other rights, powers or privileges vested in, or enjoyed by, A. B. Ports at the commencement of this Order or any title of A. B. Ports in, to or over any lands or foreshore held or acquired by it.E+W+S

Commencement Information

I194Sch. 12 Pt. 5 para. 13 in force at 7.9.2016, see art. 1(2)

PART 6E+W+SProtection for Anglian Water Services Limited

1.  The provisions of this Part have effect for the protection of Anglian Water unless otherwise agreed in writing between the undertaker and Anglian Water.E+W+S

Commencement Information

I195Sch. 12 Pt. 6 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfill its statutory functions in no less efficient a manner than previously;

“Anglian Water” means Anglian Water Services Limited (company number 02366656);

“apparatus” means—

(a)

any works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;

(b)

any drain or works vested in Anglian Water under the Water Industry Act 1991; and

(c)

any sewer that is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,

and includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any sewer, drain, or works (within the meaning of section 219 of that Act) and any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or on land;

“plan” includes section, drawing, specification and method statement;

“relevant undertaker” means—

(a)

in relation to works that are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works that are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works that are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea.

Commencement Information

I196Sch. 12 Pt. 6 para. 2 in force at 7.9.2016, see art. 1(2)

3.  This Part does not apply to apparatus in respect of which the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 of the 1991 Act.E+W+S

Commencement Information

I197Sch. 12 Pt. 6 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) The relevant undertaker must not—E+W+S

(a)execute any works that interfere with, build over or are near to any apparatus within the Order land;

(b)execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus; or

(c)where the apparatus is laid in a trench, execute any filling around the apparatus within the standard protection strips, which are the strips of land falling the following distances to either side of the medial line of any apparatus—

(i)2.25 metres, where the diameter of the pipe is less than 150 millimetres;

(ii)3 metres, where the diameter of the pipe is 150 millimetres or more but less than 450 millimetres;

(iii)4.5 metres, where the diameter of the pipe is 450 millimetres or more but less than 750 millimetres; and

(iv)6 metres, where the diameter of the pipe is 750 millimetres or more,

unless the relevant undertaker has submitted to Anglian Water, not less than 28 days before starting the execution of any works, a plan and description of the works to be executed.

(2) The works must be executed only in accordance with the plan and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and an officer of Anglian Water is entitled to watch and inspect the execution of the works.

(3) Any requirements made by Anglian Water under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan and description under sub-paragraph (1) are submitted to it.

(4) Nothing in this paragraph precludes the relevant undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan and description instead of the plan and description previously submitted, and once the relevant undertaker has done so the provisions of this paragraph apply to and in respect of the new plan and description.

(5) The relevant undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to Anglian Water notice as soon as is reasonably practicable and a plan and description of the works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

(6) It is reasonable for Anglian Water to require that the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or the filling around the apparatus (where the apparatus is laid in a trench) be executed by Anglian Water.

(7) Anglian Water must execute any requirement made under sub-paragraph (6) in a timely manner.

Commencement Information

I198Sch. 12 Pt. 6 para. 4 in force at 7.9.2016, see art. 1(2)

5.  The alteration, extension, removal or relocation of any apparatus must not be implemented until—E+W+S

(a)any requirement for any permits under the Environmental Permitting (England and Wales) Regulations 2010 or other legislation and any other associated consents are obtained, and any approval or agreement required from Anglian Water on alternative outfall locations as a result of such relocation are obtained, such approvals or agreements from Anglian Water not to be unreasonably withheld or delayed; and

(b)the relevant undertaker has given to Anglian Water written notice of its requirement to alter, extend, remove or relocate apparatus together with a plan and description of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed, and such works to be executed only in accordance with the plan and description submitted and in accordance with such reasonable requirements as may be made by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it.

Commencement Information

I199Sch. 12 Pt. 6 para. 5 in force at 7.9.2016, see art. 1(2)

6.  If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the relevant undertaker, Anglian Water must, on receipt of a written notice to that effect from the relevant undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.E+W+S

Commencement Information

I200Sch. 12 Pt. 6 para. 6 in force at 7.9.2016, see art. 1(2)

7.  Any alternative apparatus to be constructed in land of the relevant undertaker under this Part must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the relevant undertaker or in default of agreement settled by arbitration in accordance with article 41 (arbitration).E+W+S

Commencement Information

I201Sch. 12 Pt. 6 para. 7 in force at 7.9.2016, see art. 1(2)

8.—(1) Where, in exercise of the powers conferred by this Order,—E+W+S

(a)the relevant undertaker acquires any interest in any land in which apparatus is placed; and

(b)the apparatus is to be relocated, extended, removed or altered in any way,

no alteration or extension may take place until Anglian Water has established, to its reasonable satisfaction, contingency arrangements in order to conduct its functions for the duration of the works to relocate, extend, remove or alter the apparatus.

(2) Anglian Water must use reasonable endeavours to establish contingency arrangements in a timely manner.

Commencement Information

I202Sch. 12 Pt. 6 para. 8 in force at 7.9.2016, see art. 1(2)

9.  Despite any provision in this Order or anything shown on any plan, the relevant undertaker must not acquire any apparatus otherwise than by agreement; and before extinguishing any existing rights for Anglian Water to use, keep, inspect, renew and maintain its apparatus in the Order land, the relevant undertaker must, with the agreement of Anglian Water, create a new right to use, keep, inspect, renew and maintain the apparatus that is reasonably convenient for Anglian Water, such agreement not to be unreasonably withheld or delayed, and to be subject to arbitration under article 41.E+W+S

Commencement Information

I203Sch. 12 Pt. 6 para. 9 in force at 7.9.2016, see art. 1(2)

10.  If, in consequence of the exercise of the powers conferred by this Order the access to any apparatus is materially obstructed, the relevant undertaker must provide such alternative means of access to the apparatus as will enable Anglian Water to maintain or use the apparatus no less effectively than was possible before the obstruction.E+W+S

Commencement Information

I204Sch. 12 Pt. 6 para. 10 in force at 7.9.2016, see art. 1(2)

11.  If, in consequence of the exercise of the powers conferred by this Order, previously unmapped sewers, lateral drains or other apparatus are identified by the relevant undertaker, notification of the location of such assets must be given to Anglian Water as soon as reasonably practicable and, if identified by Anglian Water as being within its responsibility, must be afforded the same protection as other Anglian Water assets.E+W+S

Commencement Information

I205Sch. 12 Pt. 6 para. 11 in force at 7.9.2016, see art. 1(2)

12.  If, for any reason or in consequence of the construction of any of the works referred to in paragraphs 4 to 9 and 11, any damage is caused to any apparatus (other than apparatus, the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the relevant undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by Anglian Water in making good any damage or restoring the supply; and

(b)make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs properly and reasonably incurred by Anglian Water,

by reason or in consequence of the damage or interruption.

Commencement Information

I206Sch. 12 Pt. 6 para. 12 in force at 7.9.2016, see art. 1(2)

13.  The relevant undertaker must pay to Anglian Water the reasonable expenses incurred by Anglian Water in executing the works reasonably required under paragraph 4(6) and paragraph 5 and in complying with a written notice under paragraph 6.E+W+S

Commencement Information

I207Sch. 12 Pt. 6 para. 13 in force at 7.9.2016, see art. 1(2)

14.  Nothing in paragraph 12 imposes any liability on the relevant undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Anglian Water, its officer, servants, contractors or agents.E+W+S

Commencement Information

I208Sch. 12 Pt. 6 para. 14 in force at 7.9.2016, see art. 1(2)

15.  Any difference or dispute arising between the undertaker and Anglian Water under this Part must, unless otherwise agreed in writing between the undertaker and Anglian Water, be determined by arbitration in accordance with article 41.E+W+S

Commencement Information

I209Sch. 12 Pt. 6 para. 15 in force at 7.9.2016, see art. 1(2)

PART 7E+W+SProtection for Centrica plc

1.  The provisions of this Part have effect for the protection of Centrica unless otherwise agreed in writing between the undertaker and Centrica.E+W+S

Commencement Information

I210Sch. 12 Pt. 7 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“access road” means the road providing access to Centrica’s power station from Chase Hill Road;

“apparatus” means Centrica’s pipelines, cables, structures, or other electrical, gas or telecommunication infrastructure owned, occupied or maintained by Centrica for the purposes of its undertaking;

“Centrica” means Centrica plc (company number 03033654) and all of its subsidiaries and group companies including but not limited to Centrica KPS Limited (company number 05006144), Centrica Storage Limited (company number 03294124) and Centrica Energy Limited (company number 02877398) or any successor company in title and function;

“relevant undertaker” means—

(a)

in relation to works which are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works which are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works which are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea.

Commencement Information

I211Sch. 12 Pt. 7 para. 2 in force at 7.9.2016, see art. 1(2)

3.  Before extinguishing any existing rights for Centrica to place, install, keep, inspect, renew and maintain its apparatus on, over or in the Order land or to cross the Order land to access its apparatus, the relevant undertaker, with the agreement of Centrica, must create a new right, which is consistent with the existing right being extinguished, to place, install, keep, inspect, renew and maintain the apparatus in the same location or a new right of access that is reasonably convenient for Centrica, such agreement not to be unreasonably withheld or delayed.E+W+S

Commencement Information

I212Sch. 12 Pt. 7 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) Except where paragraph 5 applies, no works may commence within 10 metres of apparatus or on, to or within 10 metres in any direction of the access road until a construction method statement to protect the apparatus or the access road as the case may be has been prepared by the relevant undertaker and submitted to and agreed with Centrica (provided that Centrica must not unreasonably withhold or delay such agreement).E+W+S

(2) The construction method statement must include provisions in respect of—

(a)the location and methods of reinforcement of crossing points over the apparatus and restrictions on building and altering the ground level over the apparatus elsewhere;

(b)a mechanism for the enforcement of the relevant undertaker’s use of designated crossing points over the apparatus and the agreed reinforcement methods; and

(c)adoption of a prior notification and consent regime which would require the relevant undertaker to—

(i)seek Centrica’s consent to the carrying out of the proposed development within the vicinity of the apparatus or on or to the access road, such consent not to be unreasonably withheld, and comply with any reasonable conditions attached by Centrica to its consent; and

(ii)notify Centrica of its intention to carry out any development within the vicinity of the apparatus or on or to the access road, such notification to be provided at least 48 hours before any such development occurs; and

the authorised development must be carried out in accordance with the approved construction method statement.

Commencement Information

I213Sch. 12 Pt. 7 para. 4 in force at 7.9.2016, see art. 1(2)

5.—(1) If the relevant undertaker acquires or overrides any interest in any land in which apparatus is laid, the apparatus must not be removed under this Part and any right of Centrica to maintain the apparatus in that land must not be extinguished until alternative apparatus has been constructed at the relevant undertaker’s expense and is in operation to the reasonable satisfaction of Centrica in accordance with sub-paragraphs (2) to (5).E+W+S

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the relevant undertaker requires the removal of apparatus in that land, it must give to Centrica 56 days’ advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed; and in that case (or if, in consequence of the exercise of any of the powers conferred by this Order, Centrica reasonably needs to remove the apparatus) the relevant undertaker must, subject to sub-paragraph (3), afford to Centrica to its satisfaction (taking into account paragraph 6(1)) the necessary facilities and rights for—

(a)the construction of an alternative apparatus in other land of the relevant undertaker or Centrica; and

(b)subsequently the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the relevant undertaker or Centrica, or the relevant undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, Centrica must, on receipt of a written notice to that effect from the relevant undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed, except that this obligation does not extend to the requirement for Centrica to seek compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of the relevant undertaker or Centrica under this Part must be constructed in such manner and in such line or situation as may be agreed between Centrica and the relevant undertaker.

(5) Centrica must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to Centrica of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to, at the cost of the relevant undertaker, construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the relevant undertaker to be removed under this Part.

Commencement Information

I214Sch. 12 Pt. 7 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Where, in accordance with this Part, the relevant undertaker affords to Centrica facilities and rights for the construction and maintenance in land of the relevant undertaker of alternative apparatus in substitution for the apparatus to be removed, those facilities and rights must be granted on such terms and conditions as may be agreed between the relevant undertaker and Centrica and must be no less favourable on the whole to Centrica than the facilities and rights enjoyed by it in respect of the apparatus to be removed, unless agreed otherwise by Centrica.E+W+S

(2) If the facilities and rights to be afforded by the relevant undertaker and agreed with Centrica under sub-paragraph (1) in respect of any alternative apparatus, or the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to Centrica than the facilities and rights enjoyed by it in respect of the apparatus to be removed or the terms and conditions to which those facilities and rights are subject, the matter must be referred to arbitration, and the arbitrator must make such provision for the payment of compensation by the relevant undertaker to Centrica as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I215Sch. 12 Pt. 7 para. 6 in force at 7.9.2016, see art. 1(2)

7.  If for any reason or in consequence of the construction or operation of the authorised development any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Centrica or to the access road, the relevant undertaker must bear and pay the cost reasonably incurred by Centrica in making good any damage by reason or in consequence of any such damage, provided that the maximum liability of the relevant undertaker or the maximum liability of the relevant undertakers (in aggregate) is limited to £50,000,000 per claim or series of claims arising from 1 event.E+W+S

Commencement Information

I216Sch. 12 Pt. 7 para. 7 in force at 7.9.2016, see art. 1(2)

8.  The relevant undertaker must use its best endeavours to co-ordinate the execution and operation of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Centrica’s undertaking, and Centrica must use its best endeavours to co-operate with the relevant undertaker for that purpose.E+W+S

Commencement Information

I217Sch. 12 Pt. 7 para. 8 in force at 7.9.2016, see art. 1(2)

9.  Despite any provision in this Order or anything shown on the land plans or contained in the book of reference, the undertaker must not acquire any apparatus, override any easement or other interest of Centrica, acquire any land or other interest of Centrica or create any new rights over any land or other interest of Centrica otherwise than by agreement of Centrica, which agreement must not be unreasonably withheld.E+W+S

Commencement Information

I218Sch. 12 Pt. 7 para. 9 in force at 7.9.2016, see art. 1(2)

10.  Any dispute arising between the undertaker and Centrica under this Part must be determined by arbitration as provided in article 41 (arbitration).E+W+S

Commencement Information

I219Sch. 12 Pt. 7 para. 10 in force at 7.9.2016, see art. 1(2)

PART 8E+W+SProtection for VPI Immingham LLP

1.  The provisions of this Part have effect for the protection of VPI unless otherwise agreed in writing between the undertaker and VPI.E+W+S

Commencement Information

I220Sch. 12 Pt. 8 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“pipeline” means the gas pipeline crossing the Order land owned and operated by VPI used at various times for the passage of gas and all ancillary apparatus including such works and apparatus properly appurtenant to the pipeline as are specified by section 65(2) of the Pipe-lines Act 1962(25);

“relevant undertaker” means—

(a)

in relation to works which are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works which are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works which are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea;

“VPI” means VPI Immingham LLP (registered number OC300980).

Commencement Information

I221Sch. 12 Pt. 8 para. 2 in force at 7.9.2016, see art. 1(2)

3.  Before commencing any part of the authorised development or the operation of the authorised development that would have an effect on the operation and maintenance of the pipeline and access to it, the relevant undertaker must submit to VPI plans and sections of the proposed works and such further particulars as VPI may, within 28 days from the day on which plans and sections are submitted under this paragraph, reasonably require.E+W+S

Commencement Information

I222Sch. 12 Pt. 8 para. 3 in force at 7.9.2016, see art. 1(2)

4.  No works comprising any part of the authorised development or the operation of the authorised development that would have an effect in full or in part on the operation, maintenance, repair, replacement and abandonment of the pipeline and access to it may be commenced until plans and sections in respect of the works submitted under paragraph 3 have been approved by VPI.E+W+S

Commencement Information

I223Sch. 12 Pt. 8 para. 4 in force at 7.9.2016, see art. 1(2)

5.  Any approval of VPI required under paragraph 4 must not be unreasonably withheld or delayed but may be given subject to such reasonable requirements as VPI may require to be made for—E+W+S

(a)the continuing safety and operational viability of the pipeline; and

(b)the requirement for VPI to have uninterrupted and unimpeded access to the pipeline at all times.

Commencement Information

I224Sch. 12 Pt. 8 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Subject to sub-paragraphs (2) and (3), if, by reason or in consequence of the construction of any of the works referred to in paragraph 3, any damage is caused to any apparatus or property of VPI, or there is any interruption in any service provided, or in the supply of any goods, by VPI, the relevant undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by VPI in making good such damage or restoring the supply; and

(b)make reasonable compensation to VPI for any other expenses, loss, damages, penalty or costs incurred by VPI,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the relevant undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of VPI, its officers, servants, contractors or agents.

(3) VPI must give the relevant undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the relevant undertaker, which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I225Sch. 12 Pt. 8 para. 6 in force at 7.9.2016, see art. 1(2)

7.  Any dispute arising between the undertaker and VPI under this Part must be determined by arbitration as provided in article 41 (arbitration).E+W+S

Commencement Information

I226Sch. 12 Pt. 8 para. 7 in force at 7.9.2016, see art. 1(2)

PART 9E+W+SProtection for Phillips 66 Limited

1.  The provisions of this Part have effect for the protection of P66 unless otherwise agreed in writing between the undertaker and P66.E+W+S

Commencement Information

I227Sch. 12 Pt. 9 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“P66” means Phillips 66 Limited (company number 529086);

“pipeline” means the crude oil pipeline owned and operated by P66 used at various times for the passage of multi-purpose hydrocarbon fuels and all ancillary apparatus including such works and apparatus properly appurtenant to the pipeline as are specified by section 65(2) of the Pipe-lines Act 1962;

“relevant undertaker” means—

(a)

in relation to works which are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works which are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works which are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea.

Commencement Information

I228Sch. 12 Pt. 9 para. 2 in force at 7.9.2016, see art. 1(2)

3.  Before commencing any part of the authorised development or the operation of the authorised development that would have an effect on the operation and maintenance of the pipeline and access to it, the relevant undertaker must submit to P66 plans and sections of the proposed works and such further particulars as P66 may, within 28 days from the day on which plans and sections are submitted under this paragraph, reasonably require.E+W+S

Commencement Information

I229Sch. 12 Pt. 9 para. 3 in force at 7.9.2016, see art. 1(2)

4.  No works comprising any part of the authorised development or the operation of the authorised development that would have an effect in full or in part on the operation, maintenance, repair, replacement and abandonment of the pipeline and access to it may be commenced until plans and sections in respect of the works submitted under paragraph 3 have been approved by P66.E+W+S

Commencement Information

I230Sch. 12 Pt. 9 para. 4 in force at 7.9.2016, see art. 1(2)

5.  Any approval of P66 required under paragraph 4 must not be unreasonably withheld or delayed but may be given subject to such reasonable requirements as P66 may require to be made for—E+W+S

(a)the continuing safety and operational viability of the pipeline; and

(b)the requirement for P66 to have uninterrupted and unimpeded access to the pipeline at all times.

Commencement Information

I231Sch. 12 Pt. 9 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Subject to sub-paragraphs (2) and (3), if, by reason or in consequence of the construction of any of the works referred to in paragraph 3, any damage is caused to any apparatus or property of P66, or there is any interruption in any service provided, or in the supply of any goods, by P66, the relevant undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by P66 in making good such damage or restoring the supply; and

(b)make reasonable compensation to P66 for any other expenses, loss, damages, penalty or costs incurred by P66,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the relevant undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of P66, its officers, servants, contractors or agents.

(3) P66 must give the relevant undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the relevant undertaker, which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I232Sch. 12 Pt. 9 para. 6 in force at 7.9.2016, see art. 1(2)

7.  Any dispute arising between the undertaker and P66 under this Part must be determined by arbitration as provided in article 41(arbitration).E+W+S

Commencement Information

I233Sch. 12 Pt. 9 para. 7 in force at 7.9.2016, see art. 1(2)

PART 10E+W+SProtection for ConocoPhillips (U.K.) Limited

1.  The provisions of this Part have effect for the protection of ConocoPhillips unless otherwise agreed in writing between the undertaker and ConocoPhillips.E+W+S

Commencement Information

I234Sch. 12 Pt. 10 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“ConocoPhillips” means ConocoPhillips (U.K.) Limited (company number 00524868);

“pipeline” means the condensate pipeline running from the ConocoPhillips Theddlethorpe Gas Terminal to the Humber Oil Refinery, operated by ConocoPhillips on behalf of the pipeline owners and all ancillary apparatus including such works and apparatus properly appurtenant to the pipeline as are specified by section 65(2) of the Pipe-lines Act 1962;

“relevant undertaker” means—

(a)

in relation to works which are Project A works or associated development or ancillary works relating to Project A works, Optimus Wind;

(b)

in relation to works which are Project B works or associated development or ancillary works relating to Project B works, Breesea; and

(c)

in relation to works which are shared works or associated development or ancillary works relating to shared works, Optimus Wind and Breesea.

Commencement Information

I235Sch. 12 Pt. 10 para. 2 in force at 7.9.2016, see art. 1(2)

3.  Not less than 28 days before commencing any part of the authorised development or the operation of the authorised development that is near to and would or may have an effect on the operation and maintenance of the pipeline and access to it, the relevant undertaker must submit to ConocoPhillips plans and sections of the proposed works and such further particulars as ConocoPhillips may, within 28 days from the day on which plans and sections are submitted under this paragraph, reasonably require.E+W+S

Commencement Information

I236Sch. 12 Pt. 10 para. 3 in force at 7.9.2016, see art. 1(2)

4.  No works comprising any part of the authorised development or the operation of the authorised undertaking which would have an effect in full or in part on the operation, maintenance, repair, replacement and abandonment of the pipeline and access to it may be commenced until plans and sections in respect of the works submitted under paragraph 3 have been approved by ConocoPhillips.E+W+S

Commencement Information

I237Sch. 12 Pt. 10 para. 4 in force at 7.9.2016, see art. 1(2)

5.  Any approval of ConocoPhillips required under paragraph 4 must not be unreasonably withheld or delayed but may be given subject to such reasonable requirements as ConocoPhillips may require to be made for—E+W+S

(a)the continuing safety and operational viability of the pipeline; and

(b)the requirement for ConocoPhillips to have uninterrupted and unimpeded access to the pipeline at all times.

Commencement Information

I238Sch. 12 Pt. 10 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Subject to sub-paragraphs (2) and (3), if, by reason or in consequence of the construction of any of the works referred to in paragraph 3, any damage is caused to any apparatus or property of ConocoPhillips, or there is any interruption in any service provided, or in the supply of any goods, by ConocoPhillips, the relevant undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by ConocoPhillips in making good such damage or restoring the supply; and

(b)make reasonable compensation to ConocoPhillips for any other expenses, loss, damages, penalty or costs incurred by ConocoPhillips,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the relevant undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of ConocoPhillips, its officers, servants, contractors or agents.

(3) ConocoPhillips must give the relevant undertaker reasonable notice of any claim or demand, and no settlement or compromise may be made without the consent of the relevant undertaker, which, if it withholds consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I239Sch. 12 Pt. 10 para. 6 in force at 7.9.2016, see art. 1(2)

7.  Any dispute arising between the undertaker and ConocoPhillips under this Part must be determined by arbitration as provided in article 41 (arbitration).E+W+S

Commencement Information

I240Sch. 12 Pt. 10 para. 7 in force at 7.9.2016, see art. 1(2)

PART 11E+W+SProtection for C.GEN Killingholme Limited

1.  The provisions of this Part apply to govern the relationship between the undertaker and C.GEN unless otherwise agreed in writing between the undertaker and C.GEN.E+W+S

Commencement Information

I241Sch. 12 Pt. 11 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“approving party” means the party from whom an approval should be, has been or should have been obtained under this Part, being—

(a)

in the case of specified works by C.GEN, Optimus Wind and Breesea, to the extent that they continue to have powers under this Order in respect of any part of the Order land shown numbered 503, 505, 506, 507 or 509 on the land plans, and any party who has powers under this Order in respect of that Order land by virtue of article 35 (transfer of benefit of Order); and

(b)

in the case of specified works by the undertaker, C.GEN;

“C.GEN” means C.GEN Killingholme Limited (company number 06422434);

“C.GEN relevant land” means the area of land shown coloured yellow on the Plan;

“construction” includes execution, placing, altering, replacing, reconstruction, relaying, maintenance, extensions, enlargement and removal; and “construct” and “constructed” must be construed accordingly;

“crossing zones” means those areas of land shown coloured green on the Plan;

“dominant land” means the Order land shown numbered 500 and 506 on the land plans;

“drainage ditch” means the ditch shown by a black line marked “Drain” on the Plan;

“grid connection land” means the C.GEN relevant land, the thermal buffer zone and the crossing zones;

“Hornsea Project Substation Site” means the site shown outlined in pink on the Plan;

“Plan” means the plan certified as the C.GEN protective provisions plan by the Secretary of State under article 40 (certification of plans, etc.);

“plans” includes sections, drawings, specifications, designs, design data, software, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of the grid connection land;

“promoting party” means the party who is seeking, has sought or should have sought an approval under this Part, being—

(a)

the undertaker, in the case of specified works by the undertaker; and

(b)

C.GEN, in the case of specified works by C.GEN;

“servient land” means any pond, ponds or any watercourse on land under the ownership of C.GEN as at the date of this Order;

“specified works” means so much of any works or operations by the undertaker or C.GEN as is in, on, under or over the grid connection land;

“thermal buffer zone” means the area of land shown coloured red on the Plan.

Commencement Information

I242Sch. 12 Pt. 11 para. 2 in force at 7.9.2016, see art. 1(2)

3.  The undertaker must not under the powers of this Order acquire—E+W+S

(a)new rights over the C.GEN relevant land; or

(b)new rights over the thermal buffer zone, except for the purposes of access and maintenance; or

(c)new rights over crossing zones,

without the consent of C.GEN, such consent not to be unreasonably withheld or delayed but which may be given subject to reasonable conditions.

Commencement Information

I243Sch. 12 Pt. 11 para. 3 in force at 7.9.2016, see art. 1(2)

4.—(1) The promoting party must give to the approving party not less than 28 days’ written notice of its intention to commence the construction of any specified works and at the same time must submit plans for the specified works to the approving party.E+W+S

(2) Not more than 14 days after completion of the construction of the specified works, the promoting party must give the approving party written notice of such completion.

Commencement Information

I244Sch. 12 Pt. 11 para. 4 in force at 7.9.2016, see art. 1(2)

5.—(1) Following receipt of the notification of the intention to commence the construction of the specified works under paragraph 4(1), the approving party must within 14 days give notice in writing to the promoting party that (acting reasonably)—E+W+S

(a)it approves the plans; or

(b)it does not approve the plans and provide reasons for this.

(2) Where the approving party confirms that it does not approve the plans for the specified works, then both parties must, acting reasonably, enter into negotiations to seek to agree the plans.

(3) If following the expiry of 14 days from the date of notification under sub-paragraph (1)(b) no agreement has been reached, the matter must be determined in accordance with paragraph 22.

Commencement Information

I245Sch. 12 Pt. 11 para. 5 in force at 7.9.2016, see art. 1(2)

6.—(1) Any specified works must be constructed—E+W+S

(a)without unreasonable delay in accordance with the plans approved or settled under this Part; and

(b)to the reasonable satisfaction of the approving party.

(2) If any part of the specified works is constructed otherwise than in accordance with the requirements of this Part, the approving party may by notice in writing require the promoting party at the promoting party’s own expense to comply with the requirements of this Part or (if the promoting party so elects and the approving party in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the works and, where removal is required, to restore the site to its former condition to such extent and within such limits as the approving party reasonably requires.

(3) Subject to sub-paragraph (4), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (2) is served on the promoting party, the promoting party has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the approving party may execute the works specified in the notice and any expenditure incurred by it in so doing is recoverable from the promoting party.

(4) In the event of any dispute as to whether sub-paragraph (2) is properly applicable to any works in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the approving party must not except in an emergency exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined.

Commencement Information

I246Sch. 12 Pt. 11 para. 6 in force at 7.9.2016, see art. 1(2)

7.  The promoting party must at all reasonable times during construction of the specified works and thereafter allow the approving party, its servants and agents, access to the works and all reasonable facilities for inspection of the works.E+W+S

Commencement Information

I247Sch. 12 Pt. 11 para. 7 in force at 7.9.2016, see art. 1(2)

8.—(1) After the purpose of any temporary works has been accomplished, the promoting party must with all reasonable dispatch, or after a reasonable period of notice in writing from the approving party requiring the promoting party to do so, remove the temporary works or any materials relating to them which may have been placed in, on, under or over the grid connection land by or on behalf of the promoting party.E+W+S

(2) If the promoting party fails to do so within a reasonable period after receiving notice under sub-paragraph (1), the approving party may remove them and may recover the reasonable costs of doing so from the promoting party.

Commencement Information

I248Sch. 12 Pt. 11 para. 8 in force at 7.9.2016, see art. 1(2)

9.—(1) If any damage to the grid connection land or any apparatus of any approving party on the grid connection land or any interference or obstruction is caused by the carrying out of, or in consequence of the construction of specified works, the promoting party must, notwithstanding any approval, make good the damage to the reasonable satisfaction of the approving party and must pay to the approving party all reasonable expenses to which the approving party may be put and compensation for any loss which it may sustain by reason of the damage, interference or obstruction in accordance with paragraph 10.E+W+S

(2) If the promoting party refuses or fails to do so, the approving party may cause the work to be done and may recover the reasonable cost of doing so from the promoting party.

Commencement Information

I249Sch. 12 Pt. 11 para. 9 in force at 7.9.2016, see art. 1(2)

10.—(1) Without limiting the other provisions of this Part, the promoting party is responsible for, and must make good to the approving party, all losses, costs, charges, damages and expenses however caused (including a reasonable and proper proportion of the overhead charges of the approving party) that may reasonably be incurred by or occasioned to the approving party by reason of or arising from or in connection with—E+W+S

(a)the perusal of plans and the inspection of the specified works by the approving party or its duly authorised representative;

(b)the construction or failure of the specified works, or the undertaking by the approving party of works or measures to prevent or remedy damage to any property of the approving party arising from such construction or failure;

(c)any act or omission of the promoting party or its servants or agents whilst engaged in the construction of any of the specified works.

(2) The approving party must give to the promoting party notice in writing of any claim or demand for which the promoting party may be liable under this paragraph, and no settlement or compromise of any such claim or demand may be made without the consent in writing of the promoting party.

(3) Nothing in this paragraph imposes any liability on the promoting party to the extent that any losses, costs, charges, damages, expenses, claims or demands referred to in sub-paragraph (1) are attributable to negligence on the part of the approving party or of any person in its employ or of its contractors or agents.

Commencement Information

I250Sch. 12 Pt. 11 para. 10 in force at 7.9.2016, see art. 1(2)

11.  The fact that any work or thing has been executed or done with the consent of the approving party and in accordance with any conditions or restrictions prescribed by the approving party or in accordance with any plans approved by the approving party or to its satisfaction or in accordance with any directions or award of any arbitrator does not relieve the promoting party from any liability under this Part.E+W+S

Commencement Information

I251Sch. 12 Pt. 11 para. 11 in force at 7.9.2016, see art. 1(2)

12.  Any consent or approval of an approving party required under this Part—E+W+S

(a)must not be unreasonably withheld or delayed; and

(b)may be given subject to reasonable conditions.

Commencement Information

I252Sch. 12 Pt. 11 para. 12 in force at 7.9.2016, see art. 1(2)

13.  Any consent or approval of an approving party required under this Part is deemed to have been given if it is neither given nor refused within 28 days beginning with the date on which the application for consent or approval was submitted to the approving party.E+W+S

Commencement Information

I253Sch. 12 Pt. 11 para. 13 in force at 7.9.2016, see art. 1(2)

14.  Without limiting paragraph 12, it is not be reasonable for an approving party to withhold or delay any consent or approval under this Part in relation to specified works in, on, under, or over the grid connection land solely on the basis of thermal interaction between the circuit and any adjacent circuit, whether existing or proposed, where it has been demonstrated that there will be no material thermal interaction, which is deemed to have been demonstrated where the separation between the circuits is 6 metres or more (from the centre line of each circuit).E+W+S

Commencement Information

I254Sch. 12 Pt. 11 para. 14 in force at 7.9.2016, see art. 1(2)

15.  Without limiting paragraph 12, and in addition to the circumstances described in paragraph 14, it is not reasonable for the approving party to withhold or delay any consent or approval under this Part in relation to specified works in, on, under, or over the crossing zones solely on the basis of thermal interaction where the plans of the specified works submitted under paragraph 4 demonstrate that all reasonable steps have been taken to minimise thermal interaction between the circuit and any other circuit, whether existing or proposed.E+W+S

Commencement Information

I255Sch. 12 Pt. 11 para. 15 in force at 7.9.2016, see art. 1(2)

16.  With the exception of any duty owed by the approving party to the promoting party expressly provided for in the foregoing provisions of this Part, nothing in this Order must be construed as imposing on the approving party, either directly or indirectly, any form of duty or liability to which the approving party would not otherwise be subject which is enforceable by proceedings before any court.E+W+S

Commencement Information

I256Sch. 12 Pt. 11 para. 16 in force at 7.9.2016, see art. 1(2)

17.  Except as this Part provides, nothing in this Order affects prejudicially any statutory or other rights, powers or privileges vested in, or enjoyed by, the approving party at the commencement of this Order or any title of the approving party in, to or over any lands held or acquired by it.E+W+S

Commencement Information

I257Sch. 12 Pt. 11 para. 17 in force at 7.9.2016, see art. 1(2)

18.  In the event that the promoting party requires to alter the course of, modify, or remove any part of the drainage ditch the alteration, modification or removal works must be approved in writing by the approving party before the works are carried out, and such approval may not be unreasonably withheld or delayed but may be given subject to reasonable conditions.E+W+S

Commencement Information

I258Sch. 12 Pt. 11 para. 18 in force at 7.9.2016, see art. 1(2)

19.  The undertaker must ensure that the rate or volume of water discharged from the dominant land onto, over, across or through the servient land will not result in a significant increase in the exercise of the rights of the easement enjoyed by the dominant land on, over, across and through the servient land other than with the prior written approval of C.GEN.E+W+S

Commencement Information

I259Sch. 12 Pt. 11 para. 19 in force at 7.9.2016, see art. 1(2)

20.  The undertaker must not exercise the powers conferred by article 18 (compulsory acquisition of land) or article 19 (compulsory acquisition of rights) in respect of the Order land shown numbered 510 on the land plans to extinguish any rights that C.GEN has to connect into the North Killingholme National Grid substation.E+W+S

Commencement Information

I260Sch. 12 Pt. 11 para. 20 in force at 7.9.2016, see art. 1(2)

21.  The provisions of this Part enure for the benefit of the undertaker, C.GEN and any statutory successor of either that is licensed under section 6 of the 1989 Act and is in occupation or use of the Hornsea Project Substation Site, the grid connection land or any part of it pursuant to its undertaking.E+W+S

Commencement Information

I261Sch. 12 para. 21 in force at 7.9.2016, see art. 1(2)

22.  Any dispute or difference arising between Optimus Wind, Breesea or any other party having powers under this Order in respect of the Order land shown numbered 503, 505, 506, 507 or 509 on the land plans by virtue of article 35 (transfer of benefit of Order) on the one hand (the “undertaker”) and C.GEN on the other as to their respective rights, duties and obligations under this Part or as to any matters arising out of it or in connection with the subject matter of this Part must be determined by a single arbitrator whose appointment is to be agreed on between the undertaker and C.GEN or, where agreement cannot be reached within 14 days, who is to be appointed on the application of either party (after notice in writing to the other party) by the President or Deputy President of the Royal Institute of Chartered Arbitrators.E+W+S

Commencement Information

I262Sch. 12 para. 22 in force at 7.9.2016, see art. 1(2)

PART 12E+W+SProtection for Hornsea One companies

1.  The provisions of this Part apply for the protection of the Hornsea One companies unless otherwise agreed in writing between the undertaker and the Hornsea One companies.E+W+S

Commencement Information

I263Sch. 12 Pt. 12 para. 1 in force at 7.9.2016, see art. 1(2)

2.  In this Part—E+W+S

“apparatus” means the cables, structures or other infrastructure owned, occupied or maintained by any Hornsea One company or its successor in title, including any offshore transmission owner, within the Hornsea One Order land;

“construction” includes execution, placing, altering, replacing, reconstruction, relaying, maintenance, extensions, enlargement and removal; and “construct” and “constructed” must be construed accordingly;

“Hornsea One” means the wind farms to be constructed pursuant to the Hornsea One Order including, whether pursuant to the Hornsea One Order or otherwise, all elements of the connection of the wind farms to the National Grid at North Killingholme substation;

“Hornsea One company” means an undertaker with the benefit of all or part of the Hornsea One Order for the time being, being the holder of a licence under section 6 of the 1989 Act; and “Hornsea One companies” means all such undertakers;

“Hornsea One disposal areas” means disposal site reference HU209 and HU210 whose co-ordinates are specified in the deemed marine licence in Schedule 11 to the Hornsea One Order;

“Hornsea One Order” means the Hornsea One Offshore Wind Farm Order 2014;

“Hornsea One Order land” means the land within the Order limits defined in the Hornsea One Order together with the land edged red on plan HOW01095_4 submitted to support planning application reference PA/2015/0398 submitted to North Lincolnshire Council;

“plans” includes sections, drawings, specifications, designs, design data, software, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of the Hornsea One Order land;

“proposed Hornsea One circuit route” means the proposed route for any electrical circuit to serve Hornsea One as shown on plans produced to the undertaker by the relevant Hornsea One company pursuant to paragraph 16;

“relevant Hornsea One company” means the Hornsea One company whose undertaking includes the part of Hornsea One or the part of the Hornsea One Order land affected by the particular proposals of the undertaker;

“specified works” means so much of any works or operations authorised by this Order (or authorised by any planning permission or marine licence intended to operate in conjunction with this Order) as is—

(a)

in, on, under, over or within 500 metres of a proposed Hornsea One circuit route or existing installed electrical circuit (seaward of MHWS);

(b)

in, on, under, over or within 25 metres of a proposed Hornsea One circuit route or existing installed electrical circuit (landward of MHWS); or

(c)

in, on, under, over or within 1,000 metres of other apparatus installed or to be installed as part of Hornsea One.

Commencement Information

I264Sch. 12 Pt. 12 para. 2 in force at 7.9.2016, see art. 1(2)

3.  The consent of a Hornsea One company under this Part is not required where the Hornsea One Order has expired without the authorised development having been commenced pursuant to requirement 1 of Part 3 of Schedule 1 to the Hornsea One Order or the project has been abandoned.E+W+S

Commencement Information

I265Sch. 12 Pt. 12 para. 3 in force at 7.9.2016, see art. 1(2)

4.  Where conditions are included in any consent granted by a Hornsea One company pursuant to this Part, the undertaker must comply with the conditions if it chooses to implement or rely on the consent, unless the conditions are waived or varied in writing by the relevant Hornsea One company.E+W+S

Commencement Information

I266Sch. 12 Pt. 12 para. 4 in force at 7.9.2016, see art. 1(2)

5.  It is reasonable for the relevant Hornsea One company to require as a condition of granting consent under this Part that the undertaker enter into a cable proximity agreement on reasonable terms reflecting industry good practice if the undertaker proposes to install an electrical circuit at any point closer than 500 metres to the centre line of any electrical circuit installed to serve Hornsea One or is to cross a proposed Hornsea One circuit route.E+W+S

Commencement Information

I267Sch. 12 Pt. 12 para. 5 in force at 7.9.2016, see art. 1(2)

6.  The undertaker must not under the powers of this Order—E+W+S

(a)acquire any of the Hornsea One Order land or acquire new or existing rights or interfere with existing rights or impose restrictive covenants or acquire any rights of temporary use over or in relation to the Hornsea One Order land without the consent of the relevant Hornsea One company, which must not be unreasonably withheld or delayed but which may be made subject to reasonable conditions;

(b)carry out any specified works without the consent of the relevant Hornsea One company, which must not be unreasonably withheld or delayed but which may be made subject to reasonable conditions.

Commencement Information

I268Sch. 12 Pt. 12 para. 6 in force at 7.9.2016, see art. 1(2)

7.—(1) Subject to obtaining consent pursuant to paragraph 6(b) and before beginning to construct any specified works, the undertaker must submit plans of the specified works to the relevant Hornsea One company and must submit such further particulars available to it that the relevant Hornsea One company may reasonably require.E+W+S

(2) Any specified works must be constructed without unreasonable delay in accordance with the plans approved in writing by the relevant Hornsea One company.

(3) Any approval of the relevant Hornsea One company required under this paragraph may be made subject to such reasonable conditions as it may make for the protection of the Hornsea One Order Land, the apparatus and apparatus for Hornsea One not yet installed.

(4) If any part of the specified works is constructed otherwise than in accordance with the requirements of this Part, the relevant Hornsea One company may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part.

Commencement Information

I269Sch. 12 Pt. 12 para. 7 in force at 7.9.2016, see art. 1(2)

8.  The undertaker must give to the relevant Hornsea One company not less than 28 days’ written notice of its intention to commence the construction of the specified works and, not more than 28 days after completion of their construction, must give the relevant Hornsea One company written notice of the completion.E+W+S

Commencement Information

I270Sch. 12 Pt. 12 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The undertaker must at all reasonable times during construction of the specified works and thereafter allow the relevant Hornsea One company and its servants and agents access to the works and all reasonable facilities for inspection of the works.E+W+S

Commencement Information

I271Sch. 12 Pt. 12 para. 9 in force at 7.9.2016, see art. 1(2)

10.  After the purpose of any temporary works has been accomplished, the undertaker must with all reasonable dispatch, or after a reasonable period of notice in writing from the relevant Hornsea One company requiring the undertaker so to do, remove the temporary works or any materials relating to them that may have been placed by or on behalf of the undertaker—E+W+S

(a)in, on, under, over, or within 500 metres of a proposed Hornsea One circuit route or existing installed electrical circuit (seaward of MHWS); or

(b)in, on, under, over, or within 25 metres of a proposed Hornsea One circuit route or existing installed electrical circuit (landward of MHWS).

Commencement Information

I272Sch. 12 Pt. 12 para. 10 in force at 7.9.2016, see art. 1(2)

11.  With the exception of any duty owed by the relevant Hornsea One company to the undertaker expressly provided for in the foregoing provisions of this Part, nothing in this Order must be construed as imposing on the relevant Hornsea One company, either directly or indirectly, any form of duty or liability to which the relevant Hornsea One company would not otherwise be subject which is enforceable by proceedings before any court.E+W+S

Commencement Information

I273Sch. 12 Pt. 12 para. 11 in force at 7.9.2016, see art. 1(2)

12.  The undertaker must consult the relevant Hornsea One company in relation to any draft disposal plan which proposes to deposit material within the Hornsea One disposal areas and must make such amendments as are reasonably requested by the relevant Hornsea One company before submission to the MMO for approval.E+W+S

Commencement Information

I274Sch. 12 Pt. 12 para. 12 in force at 7.9.2016, see art. 1(2)

13.  Subject to complying with all relevant health and safety considerations, the undertaker must permit representatives of the relevant Hornsea One company on any vessel carrying out dredging or disposal activities related to the Hornsea One disposal areas to monitor and verify the dredging and disposal carried out in terms of location, method, timing, quantity, nature of materials and other relevant matters.E+W+S

Commencement Information

I275Sch. 12 Pt. 12 para. 13 in force at 7.9.2016, see art. 1(2)

14.  The undertaker must give reasonable notice in writing to the relevant Hornsea One company of the intended departure of all vessels referred to in paragraph 13 together with written information concerning the proposed dredging and disposal activities and must comply with all reasonable requests from the relevant Hornsea One company to enable the verification referred to in that paragraph to be carried out effectively and efficiently.E+W+S

Commencement Information

I276Sch. 12 Pt. 12 para. 14 in force at 7.9.2016, see art. 1(2)

15.  The undertaker must provide to the relevant Hornsea One company a copy of each disposal return required to be submitted to the MMO pursuant to the approved disposal plan under this Order relevant to the Hornsea One disposal areas, such returns to include, without limitation, the actual volumes of materials disposed of, the disposal locations, the approved monitoring plan and the results of monitoring conducted.E+W+S

Commencement Information

I277Sch. 12 Pt. 12 para. 15 in force at 7.9.2016, see art. 1(2)

16.  To ensure its compliance with this Part, the undertaker must before carrying out any works or operations pursuant to this Order request up-to-date written confirmation from the relevant Hornsea One company of the precise route of any existing installed apparatus and any proposed Hornsea One circuit route or other apparatus to be installed by the relevant Hornsea One company.E+W+S

Commencement Information

I278Sch. 12 Pt. 12 para. 16 in force at 7.9.2016, see art. 1(2)

17.  The undertaker and the Hornsea One companies must each act in good faith and use reasonable endeavours to co-operate with, and provide assistance to, each other as may be required to give effect to the provisions of this Part.E+W+S

Commencement Information

I279Sch. 12 Pt. 12 para. 17 in force at 7.9.2016, see art. 1(2)

18.  Any dispute arising between the undertaker and the relevant Hornsea One company under this Part must be determined by arbitration under article 41 (arbitration).E+W+S

Commencement Information

I280Sch. 12 Pt. 12 para. 18 in force at 7.9.2016, see art. 1(2)

Article 40

SCHEDULE 13E+W+SDocuments to be certified

1.  The land plans listed below—E+W+S

PINS Document No.Description of PlanReport No.Version
4.1Land plans: key planUK06-060700-DRW-00012
4.1Land plans: offshore plans – page 1UK06-060700-DRW-00012
4.1Land plans: offshore plans – page 2UK06-060700-DRW-00011
4.1Land plans: offshore plans – page 3UK06-060700-DRW-00011
4.1Land plans: intertidal plans – page 1UK06-060700-DRW-00011
4.1Land plans: intertidal plans – page 2UK06-060700-DRW-00011
4.1Land plans: intertidal plans – page 3UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 4UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 5UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 6UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 7UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 8UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 9UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 10UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 11UK06-060700-DRW-00012
4.1Land plans: onshore plans – page 12UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 13UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 14UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 15UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 16UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 17UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 18UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 19UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 20UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 21UK06-060700-DRW-00012
4.1Land plans: onshore plans – page 22UK06-060700-DRW-00012
4.1Land plans: onshore plans – page 23UK06-060700-DRW-00012
4.1Land plans: onshore plans – page 24UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 25UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 26UK06-060700-DRW-00011
4.1Land plans: onshore plans – page 27UK06-060700-DRW-00012
4.1Land plans: inset plans – page 1UK06-060700-DRW-00011
4.1Land plans: inset plans – page 2UK06-060700-DRW-00011
4.1Land plans: inset plans – page 3UK06-060700-DRW-00011
4.1Land plans: inset plans – page 4UK06-060700-DRW-00011
4.1Land plans: inset plans – page 5UK06-060700-DRW-00011
4.1Land plans: inset plans – page 6UK06-060700-DRW-00011
4.1Land plans: inset plans – page 7UK06-060700-DRW-00011
4.1Land plans: inset plans – page 8UK06-060700-DRW-00011
4.1Land plans: inset plans – page 9UK06-060700-DRW-00011
4.1Land plans: inset plans – page 10UK06-060700-DRW-00011
4.1Land plans: inset plans – page 11UK06-060700-DRW-00011
4.1Land plans: inset plans – page 12UK06-060700-DRW-00011
4.1Land plans: inset plans – page 13UK06-060700-DRW-00012
4.1Land plans: inset plans – page 14UK06-060700-DRW-00011
4.1Land plans: inset plans – page 15UK06-060700-DRW-00011
4.1Land plans: inset plans – page 16UK06-060700-DRW-00011
4.1Land plans: inset plans – page 17UK06-060700-DRW-00011
4.1Land plans: inset plans – page 18UK06-060700-DRW-00011
4.1Land plans: inset plans – page 19UK06-060700-DRW-00011
4.1Land plans: inset plans – page 20UK06-060700-DRW-00012
4.1Land plans: inset plans – page 21UK06-060700-DRW-00011
4.1Land plans: inset plans – page 22UK06-060700-DRW-00011
4.1Land plans: inset plans – page 23UK06-060700-DRW-00011
4.1Land plans: inset plans – page 24UK06-060700-DRW-00011
4.1Land plans: inset plans – page 25UK06-060700-DRW-00011
4.1Land plans: inset plans – page 26UK06-060700-DRW-00011

Commencement Information

I281Sch. 13 para. 1 in force at 7.9.2016, see art. 1(2)

2.  The offshore works plans listed below—E+W+S

PINS Document No.Description of PlanReport No.Version
5.1Works plans: master index sheetsUK06-060700-DRW-00033
5.1Offshore works plans: map index sheetUK06-060700-DRW-00023
5.1Offshore works plans – sheet 1UK06-060700-DRW-00023
5.1Offshore works plans – sheet 2UK06-060700-DRW-00023
5.1Offshore works plans – sheet 3UK06-060700-DRW-00022
5.1Offshore works plans – sheet 4UK06-060700-DRW-00022
5.1List of co-ordinates for offshore works and disposal areas – pages i to xiUK06-060700-DRW-00022

Commencement Information

I282Sch. 13 para. 2 in force at 7.9.2016, see art. 1(2)

3.  The intertidal works plans listed below—E+W+S

PINS Document No.Description of PlanReport No.Version
5.3Works plans: master index sheetsUK06-060700-DRW-00033
5.3Intertidal works plans: map index sheetUK06-060700-DRW-00041
5.3Intertidal works plans – sheet 1UK06-060700-DRW-00041
5.3Intertidal works plans – sheet 2UK06-060700-DRW-00041
5.3Intertidal works plans – sheet 3UK06-060700-DRW-00041
5.3Intertidal works plans – sheet 4UK06-060700-DRW-00041
5.3List of co-ordinates for intertidal worksUK06-060700-DRW-00041

Commencement Information

I283Sch. 13 para. 3 in force at 7.9.2016, see art. 1(2)

4.  The onshore works plans listed below—E+W+S

PINS Document No.Description of PlanReport No.Version
5.2Works plans: master index sheetsUK06-060700-DRW-00033
5.2Onshore works plans: map index sheetUK06-060700-DRW-00032
5.2Onshore works plans – sheet 1UK06-060700-DRW-00031
5.2Onshore works plans – sheet 2UK06-060700-DRW-00031
5.2Onshore works plans – sheet 3UK06-060700-DRW-00031
5.2Onshore works plans – sheet 4UK06-060700-DRW-00031
5.2Onshore works plans – sheet 5UK06-060700-DRW-00031
5.2Onshore works plans – sheet 6UK06-060700-DRW-00031
5.2Onshore works plans – sheet 7UK06-060700-DRW-00031
5.2Onshore works plans – sheet 8UK06-060700-DRW-00031
5.2Onshore works plans – sheet 9UK06-060700-DRW-00031
5.2Onshore works plans – sheet 10UK06-060700-DRW-00031
5.2Onshore works plans – sheet 11UK06-060700-DRW-00032
5.2Onshore works plans – sheet 12UK06-060700-DRW-00031
5.2Onshore works plans – sheet 13UK06-060700-DRW-00031
5.2Onshore works plans – sheet 14UK06-060700-DRW-00031
5.2Onshore works plans – sheet 15UK06-060700-DRW-00031
5.2Onshore works plans – sheet 16UK06-060700-DRW-00031
5.2Onshore works plans – sheet 17UK06-060700-DRW-00031
5.2Onshore works plans – sheet 18UK06-060700-DRW-00031
5.2Onshore works plans – sheet 19UK06-060700-DRW-00031
5.2Onshore works plans – sheet 20UK06-060700-DRW-00031
5.2Onshore works plans – sheet 21UK06-060700-DRW-00032
5.2Onshore works plans – sheet 22UK06-060700-DRW-00032
5.2Onshore works plans – sheet 23UK06-060700-DRW-00032
5.2Onshore works plans – sheet 24UK06-060700-DRW-00031
5.2Onshore works plans – sheet 25UK06-060700-DRW-00031
5.2Onshore works plans – sheet 26UK06-060700-DRW-00031
5.2Onshore works plans – sheet 27UK06-060700-DRW-00032
5.2List of co-ordinates for onshore works – pages i to ivUK06-060700-DRW-00032

Commencement Information

I284Sch. 13 para. 4 in force at 7.9.2016, see art. 1(2)

5.  The compensation compounds plan listed below—E+W+S

PINS Document No.Description of PlanReport No.Version
7.4.5.6Compensation compounds plan – sheet 1UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 2UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 3UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 4UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 5UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 6UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 7UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 8UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 9UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 10UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 11UK06-050709-DRW-00012
7.4.5.6Compensation compounds plan – sheet 12UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 13UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 14UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 15UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 16UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 17UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 18UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 19UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 20UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 21UK06-050709-DRW-00012
7.4.5.6Compensation compounds plan – sheet 22UK06-050709-DRW-00012
7.4.5.6Compensation compounds plan – sheet 23UK06-050709-DRW-00012
7.4.5.6Compensation compounds plan – sheet 24UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 25UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 26UK06-050709-DRW-00011
7.4.5.6Compensation compounds plan – sheet 27UK06-050709-DRW-00011

Commencement Information

I285Sch. 13 para. 5 in force at 7.9.2016, see art. 1(2)

6.  The environmental statement that accompanied the application.E+W+S

Commencement Information

I286Sch. 13 para. 6 in force at 7.9.2016, see art. 1(2)

7.  The book of reference dated December 2015 (version 4).E+W+S

Commencement Information

I287Sch. 13 para. 7 in force at 7.9.2016, see art. 1(2)

8.  The outline code of construction practice dated December 2015 (version 2).E+W+S

Commencement Information

I288Sch. 13 para. 8 in force at 7.9.2016, see art. 1(2)

9.  The outline ecological management plan dated November 2015 (version 2).E+W+S

Commencement Information

I289Sch. 13 para. 9 in force at 7.9.2016, see art. 1(2)

10.  The outline landscape scheme and management plan dated January 2015.E+W+S

Commencement Information

I290Sch. 13 para. 10 in force at 7.9.2016, see art. 1(2)

11.  The outline employment and skills plan dated November 2015.E+W+S

Commencement Information

I291Sch. 13 para. 11 in force at 7.9.2016, see art. 1(2)

12.  The in-principle monitoring plan dated November 2015 (version 2).E+W+S

Commencement Information

I292Sch. 13 para. 12 in force at 7.9.2016, see art. 1(2)

13.  The C.GEN protective provisions plan submitted on 24th September 2015 (referred to as the “Hornsea Protective Provisions Plan”).E+W+S

Commencement Information

I293Sch. 13 para. 13 in force at 7.9.2016, see art. 1(2)

14.  Plan HOW01095_4 submitted to North Lincolnshire Council to support planning application reference PA/2015/0398 (referred to in paragraph 2 of Part 12 of Schedule 12).E+W+S

Commencement Information

I294Sch. 13 para. 14 in force at 7.9.2016, see art. 1(2)

(2)

See section 104(1).

(3)

The document is available from:

(5)

Section 13 was amended by section 139 of the Tribunals, Courts and Enforcement Act 2007 (c.15) and by paragraph 28 of Schedule 13 and Part 3 of Schedule 23 to that Act.

(6)

Section 20 was amended by paragraph 4 of Schedule 15 to the Planning and Compensation Act 1991 (c.34) and paragraph 70 of Schedule 1 to S.I. 2009/1307.

(7)

Section 108 was amended by section 69(5) of the Energy Act 2008.

(9)

S.I. 2002/1355, amended by S.I. 2011/982.

(12)

See section 72(1).

(13)

1993 c.43. Section 8 was amended by paragraph 4 of Schedule 17 and Part 4 of Schedule 31 to the Transport Act 2000 (c.38), paragraphs 3 and 5 of Schedule 2 to the Railways and Transport Safety Act 2003 (c.20), paragraph 3 of Schedule 1 and Part 1 of Schedule 13 to the Railways Act 2005 (c.14) and Part 1of Schedule 1 to S.I. 2015/1682.

(14)

2006 c.46.

(15)

“Access agreement” is defined in section 83. The definition was amended by section 230 of the Transport Act 2000.

(16)

Section 272 was amended by paragraph 103 of Schedule 17 to the Communications Act 2003.

(17)

Paragraph 1(3A) was added to the code (Schedule 2 to the Telecommunications Act 1984) by paragraph 4 of Schedule 3 to the Communications Act 2003.

(18)

“The electronic communications code” is defined in section 106(1).

(19)

1984 c.12.

(20)

See section 64. The definition of “electrical plant” was amended by paragraph 38(3) of Schedule 6 to the Utilities Act 2000 (c.27).

(21)

Section 51A was inserted by section 92(1) of the Water Act 2003.

(22)

Section 102(4) was amended by section 96 of the Water Act 2003. Section 104 was amended by section 96 of, and Part 3 of Schedule 9 to, the Water Act 2003 and by section 42(3) of the Flood and Water Management Act 2010.

(23)

1986 c.44. “Gas transporter” is defined in section 7. A new section 7 was substituted by section 5 of the Gas Act 1995 (c.45) and was further amended by section 76 of the Utilities Act 2000.

(24)

“Water undertaker” is defined in Schedule 1 to the Interpretation Act 1978.

(25)

1962 c.58. Section 65(2) was amended by paragraph 6 of Schedule 2 to the Energy Act 2011 (c.16) and S.I. 2000/1937 and 2011/2305.

Yn ôl i’r brig

Options/Help

Print Options

You have chosen to open yr Offeryn Cyfan

Yr Offeryn Cyfan you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open Schedules only

Y Rhestrau you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

Close

Mae deddfwriaeth ar gael mewn fersiynau gwahanol:

Y Diweddaraf sydd Ar Gael (diwygiedig):Y fersiwn ddiweddaraf sydd ar gael o’r ddeddfwriaeth yn cynnwys newidiadau a wnaed gan ddeddfwriaeth ddilynol ac wedi eu gweithredu gan ein tîm golygyddol. Gellir gweld y newidiadau nad ydym wedi eu gweithredu i’r testun eto yn yr ardal ‘Newidiadau i Ddeddfwriaeth’.

Gwreiddiol (Fel y’i Deddfwyd neu y’i Gwnaed): Mae'r wreiddiol fersiwn y ddeddfwriaeth fel ag yr oedd pan gafodd ei deddfu neu eu gwneud. Ni wnaed unrhyw newidiadau i’r testun.

Close

Gweler y wybodaeth ychwanegol ochr yn ochr â’r cynnwys

Rhychwant ddaearyddol: Indicates the geographical area that this provision applies to. For further information see ‘Frequently Asked Questions’.

Dangos Llinell Amser Newidiadau: See how this legislation has or could change over time. Turning this feature on will show extra navigation options to go to these specific points in time. Return to the latest available version by using the controls above in the What Version box.

Close

Dewisiadau Agor

Dewisiadau gwahanol i agor deddfwriaeth er mwyn gweld rhagor o gynnwys ar y sgrin ar yr un pryd

Close

Rhagor o Adnoddau

Gallwch wneud defnydd o ddogfennau atodol hanfodol a gwybodaeth ar gyfer yr eitem ddeddfwriaeth o’r tab hwn. Yn ddibynnol ar yr eitem ddeddfwriaeth sydd i’w gweld, gallai hyn gynnwys:

  • y PDF print gwreiddiol y fel deddfwyd fersiwn a ddefnyddiwyd am y copi print
  • rhestr o newidiadau a wnaed gan a/neu yn effeithio ar yr eitem hon o ddeddfwriaeth
  • manylion rhoi grym a newid cyffredinol
  • pob fformat o’r holl ddogfennau cysylltiedig
  • slipiau cywiro
  • dolenni i ddeddfwriaeth gysylltiedig ac adnoddau gwybodaeth eraill
Close

Llinell Amser Newidiadau

This timeline shows the different points in time where a change occurred. The dates will coincide with the earliest date on which the change (e.g an insertion, a repeal or a substitution) that was applied came into force. The first date in the timeline will usually be the earliest date when the provision came into force. In some cases the first date is 01/02/1991 (or for Northern Ireland legislation 01/01/2006). This date is our basedate. No versions before this date are available. For further information see the Editorial Practice Guide and Glossary under Help.

Close

Rhagor o Adnoddau

Defnyddiwch y ddewislen hon i agor dogfennau hanfodol sy’n cyd-fynd â’r ddeddfwriaeth a gwybodaeth am yr eitem hon o ddeddfwriaeth. Gan ddibynnu ar yr eitem o ddeddfwriaeth sy’n cael ei gweld gall hyn gynnwys:

  • y PDF print gwreiddiol y fel gwnaed fersiwn a ddefnyddiwyd am y copi print
  • slipiau cywiro

liciwch ‘Gweld Mwy’ neu ddewis ‘Rhagor o Adnoddau’ am wybodaeth ychwanegol gan gynnwys

  • rhestr o newidiadau a wnaed gan a/neu yn effeithio ar yr eitem hon o ddeddfwriaeth
  • manylion rhoi grym a newid cyffredinol
  • pob fformat o’r holl ddogfennau cysylltiedig
  • dolenni i ddeddfwriaeth gysylltiedig ac adnoddau gwybodaeth eraill