- Y Diweddaraf sydd Ar Gael (Diwygiedig)
- Pwynt Penodol mewn Amser (03/05/2023)
- Gwreiddiol (a wnaed Fel)
Point in time view as at 03/05/2023.
There are currently no known outstanding effects for the The A303 Sparkford to Ilchester Dualling Development Consent Order 2021, SCHEDULE 8.
Revised legislation carried on this site may not be fully up to date. At the current time any known changes or effects made by subsequent legislation have been applied to the text of the legislation you are viewing by the editorial team. Please see ‘Frequently Asked Questions’ for details regarding the timescales for which new effects are identified and recorded on this site.
Article 42
1. For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker concerned.E+W
Commencement Information
I1Sch. 8 para. 1 in force at 19.2.2021, see art. 1
2. In this Part of this Schedule—E+W
“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means—
in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989 M1), belonging to or maintained by that utility undertaker for the purposes of electricity supply;
in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 1986 M2 for the purposes of gas supply;
in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and
in the case of a sewerage undertaker—
any drain or works vested in the utility undertaker under the Water Industry Act 1991 M3; and
any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) M4 (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 M5 (agreements to adopt sewer, drain or sewage disposal works, at future date) of that Act,
and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,
and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;
“functions” includes powers and duties;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land;
“plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; and
“utility undertaker” means—
any licence holder within the meaning of Part 1 of the Electricity Act 1989;
a gas transporter within the meaning of Part 1 of the Gas Act 1986;
a water undertaker within the meaning of the Water Industry Act 1991; and
a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,
for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.
Commencement Information
I2Sch. 8 para. 2 in force at 19.2.2021, see art. 1
Marginal Citations
M11989 c. 29. The definition of “electrical plant” (in section 64) was amended by paragraphs 24 and 38(1) and (3) of Schedule 6 to the Utilities Act 2000 (c. 27).
M4Section 102(4) was amended by section 96(1)(c) of the Water Act 2003 (c. 37) and paragraph 90 of Schedule 7 to the Water Act 2014 (c. 21).
M5Section 104 was amended by sections 96(4) and 101(2) of, and Part 3 of Schedule 9 to, the Water Act 2003, section 42(3) of the Flood and Water Management Act 2010 (c. 29) and section 11 of the Water Act 2014.
3. This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.
Commencement Information
I3Sch. 8 para. 3 in force at 19.2.2021, see art. 1
4.—(1) Where any street is stopped up under article 16 (permanent stopping up and restriction of streets and private means of access), any utility undertaker whose apparatus is in the street has the same powers and rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to the utility undertaker legal easements reasonably satisfactory to the utility undertaker in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of the utility undertaker to require the removal of that apparatus under paragraph 7 or the power of the undertaker to carry out works under paragraph 9.
(2) Regardless of the temporary stopping up or diversion of any highway under the powers conferred by article 15 (temporary stopping up and restriction of use of streets and highways), a utility undertaker is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.
Commencement Information
I4Sch. 8 para. 4 in force at 19.2.2021, see art. 1
5. The undertaker, in the case of the powers conferred by article 21 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.
Commencement Information
I5Sch. 8 para. 5 in force at 19.2.2021, see art. 1
6. Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.
Commencement Information
I6Sch. 8 para. 6 in force at 19.2.2021, see art. 1
7.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that the utility undertaker's apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).
(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question 28 days' written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.
(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 45 (arbitration).
(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 45 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.
(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.
(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.
Commencement Information
I7Sch. 8 para. 7 in force at 19.2.2021, see art. 1
8.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 45 (arbitration).
(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
Commencement Information
I8Sch. 8 para. 8 in force at 19.2.2021, see art. 1
9.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 7(2), the undertaker must submit to the utility undertaker in question a plan of the works to be executed.
(2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.
(3) Any requirements made by a utility undertaker under sub-paragraph (2) are to be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.
(4) If a utility undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).
(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.
(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.
(7) In relation to works which will or may be situated on, over, under or within 10 metres measured in any direction of any electricity apparatus, the plan to be submitted to the utility undertaker under sub-paragraph (1) must be detailed, include a method statement and describe—
(a)the exact position of the works;
(b)the level at which they are proposed to be constructed or renewed;
(c)the manner of their construction or renewal;
(d)the position of all electricity apparatus; and
(e)by way of detailed drawings, every alteration proposed to be made to such apparatus.
Commencement Information
I9Sch. 8 para. 9 in force at 19.2.2021, see art. 1
10.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 7(2).
(2) The value of any apparatus removed under the provisions of this Part of this Schedule must be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.
(3) If in accordance with the provisions of this Part of this Schedule—
(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 45 (arbitration) to be necessary then, if such placing involves cost exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.
(4) For the purposes of sub-paragraph (3)—
(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.
(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.
Commencement Information
I10Sch. 8 para. 10 in force at 19.2.2021, see art. 1
11.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 5 or 7 any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—E+W
(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and
(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,
by reason or in consequence of any such damage or interruption.
(2) The fact that any act or thing may have been done by a utility undertaker on behalf of the undertaker or in accordance with a plan approved by a utility undertaker or in accordance with any requirement of a utility undertaker or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1).
(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.
(4) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker and, if such consent is withheld, the undertaker has the sole conduct of any settlement or compromise of any proceedings necessary to resist the claim or demand.
Commencement Information
I11Sch. 8 para. 11 in force at 19.2.2021, see art. 1
12. Where in consequence of the proposed construction of any part of the authorised development, the undertaker or a utility undertaker requires the removal of apparatus under paragraph 7(2) or a utility undertaker makes requirements for the protection or alteration of apparatus under paragraph 9, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the utility undertaker's undertaking and each utility undertaker must use its best endeavours to co-operate with the undertaker for that purpose.
Commencement Information
I12Sch. 8 para. 12 in force at 19.2.2021, see art. 1
13. Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus in land belonging to the undertaker on the date on which this Order is made.E+W
Commencement Information
I13Sch. 8 para. 13 in force at 19.2.2021, see art. 1
14. For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.E+W
Commencement Information
I14Sch. 8 para. 14 in force at 19.2.2021, see art. 1
15. In this Part of this Schedule—E+W
“the 2003 Act” means the Communications Act 2003 M6;
“electronic communications apparatus” has the same meaning as in the electronic communications code;
“the electronic communications code” has the same meaning as in section 106 M7 (application of the electronic communications code) of the 2003 Act;
“electronic communications code network” means—
so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and
an electronic communications network which the undertaker is providing or proposing to provide;
“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;
“infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7 (infrastructure system) of that code; and
“operator” means the operator of an electronic communications code network.
Commencement Information
I15Sch. 8 para. 15 in force at 19.2.2021, see art. 1
Marginal Citations
M7Section 106 was amended by section 4 of the Digital Economy Act 2017 (c. 30).
16. The exercise of the powers conferred by article 35 (statutory undertakers) is subject to Part 10 (undertaker's works affecting electronic communications apparatus) of the electronic communications code.E+W
Commencement Information
I16Sch. 8 para. 16 in force at 19.2.2021, see art. 1
17.—(1) Subject to sub-paragraphs (2) to (4), if as a result of the authorised development or its construction, or of any subsidence resulting from the authorised development—E+W
(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised development), or other property of an operator; or
(b)there is any interruption in the supply of the service provided by an operator,
the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.
(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.
(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker and, if such consent is withheld, the undertaker has the sole conduct of any settlement or compromise of any proceedings necessary to resist the claim or demand.
(4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 45 (arbitration).
(5) This Part of this Schedule does not apply to—
(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or
(b)any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development.
(6) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and on operator in respect of any apparatus in land belonging to the undertaker on the date on which this Order is made.
Commencement Information
I17Sch. 8 para. 17 in force at 19.2.2021, see art. 1
18. The provisions of this Part have effect for the protection of the drainage authority unless otherwise agreed in writing between the undertaker and the drainage authority.E+W
Commencement Information
I18Sch. 8 para. 18 in force at 19.2.2021, see art. 1
19. In this Part of this Schedule—E+W
“construction” includes execution, placing, altering, replacing, relaying and removal, and “construct” is to be construed accordingly;
“drainage authority” means—
the drainage board concerned within the meaning of section 23 M8 (prohibition on obstructions etc. in watercourses) of the Land Drainage Act 1991;
in the case where the drainage board concerned is a member of the Somerset Drainage Board Consortium, that Consortium; or
in the case of any area for which there is no such drainage board, the lead local flood authority within the meaning of section 6 (other definitions) of the Flood and Water Management Act 2010 M9;
“drainage work” means any watercourse and includes any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage or flood defence which is the responsibility of the drainage authority subject to such changes as notified to the undertaker;
“ordinary watercourse” has the meaning given by section 72 (interpretation) of the Land Drainage Act 1991;
“plans” includes any information reasonably required by the drainage authority including location details, grid references, sections, drawings, specifications, assessments and method statements;
“specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 9 metres of a drainage work or is otherwise likely to—
affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work;
affect the flow, purity or quality of water in any watercourse; or
affect the conservation, distribution or use of water resources.
Commencement Information
I19Sch. 8 para. 19 in force at 19.2.2021, see art. 1
Marginal Citations
M81991 c. 59. The definition of “drainage board” is in section 23(8), which was amended by paragraph 32 of Schedule 2 to the Flood and Water Management Act 2010 (c. 29),
20.—(1) Before commencing construction of a specified work, the undertaker must submit to the drainage authority plans of the specified work and such further particulars available to it as the drainage authority may within 28 days of the submission of the plans reasonably require.E+W
(2) The undertaker must not commence construction of the specified work until approval, unconditionally or conditionally, has been given as provided in this paragraph.
(3) A specified work must not be constructed except in accordance with such plans as may be approved in writing by the drainage authority or determined under paragraph 28.
(4) Any approval of the drainage authority required under this paragraph—
(a)must not be unreasonably withheld or delayed;
(b)is deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval, or submission of further particulars (where required by the drainage authority under sub-paragraph (1)) whichever is the later; and
(c)may be given subject to such reasonable requirements as the drainage authority may make for the protection of any drainage work, for the protection of any navigation work, for the protection of water resources, for the prevention of pollution or in the discharge of its environmental functions.
(5) Any refusal under this paragraph must be accompanied by a statement of the reasons for refusal.
Commencement Information
I20Sch. 8 para. 20 in force at 19.2.2021, see art. 1
21. Without limiting the scope of paragraph 20, the requirements which the drainage authority may make under that paragraph include conditions requiring the undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified work (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary—E+W
(a)to safeguard any drainage work against damage by reason of any specified work; or
(b)to secure that the efficiency of any drainage work for flood defence and land drainage purposes is not impaired, and that the risk of flooding is not otherwise increased,
by reason of any specified work.
Commencement Information
I21Sch. 8 para. 21 in force at 19.2.2021, see art. 1
22.—(1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 21, must be constructed—E+W
(a)without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part of this Schedule; and
(b)to the reasonable satisfaction of the drainage authority,
and an officer of the drainage authority is entitled to watch and inspect the construction of such works.
(2) The undertaker must give to the drainage authority—
(a)not less than 14 days' notice in writing of its intention to commence construction of any specified work; and
(b)notice in writing of its completion not later than 7 days after the date of completion.
(3) If the drainage authority reasonably requires, the undertaker must construct all or part of the protective works so that they are in place before the construction of the specified work.
(4) If any part of a specified work or any protective work required by the drainage authority is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the drainage authority may by notice in writing require the undertaker at the undertaker's expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is agreed, to restore the site to its former condition to such extent and within such limits as the drainage authority reasonably requires.
(5) Subject to sub-paragraph (6), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served on the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the drainage authority may execute the works specified in the notice and any expenditure incurred by it in so doing is recoverable from the undertaker.
(6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the drainage authority must not except in an emergency exercise the powers conferred by sub-paragraph (5) until the dispute has been finally determined.
Commencement Information
I22Sch. 8 para. 22 in force at 19.2.2021, see art. 1
23.—(1) Subject to sub-paragraph (5), the undertaker must from the commencement of the construction of the specified work maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation and on land held by the undertaker for the purposes of or in connection with the specified work, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence.E+W
(2) If any drainage work which the undertaker is liable to maintain is not maintained to the reasonable satisfaction of the drainage authority, the drainage authority may by notice in writing require the undertaker to repair and restore the work, or any part of the work, or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed), to remove the specified work and restore the site to its former condition, to such extent and within such limits as the drainage authority reasonably requires.
(3) If, within a reasonable period being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the undertaker, the undertaker has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the drainage authority may do what is necessary for such compliance and may recover any expenditure reasonably incurred by it in so doing from the undertaker.
(4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), the drainage authority must not except in a case of emergency exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined.
(5) This paragraph does not apply to—
(a)drainage works which are vested in the drainage authority, or which the drainage authority or another person is liable to maintain and is not prevented by this Order from so doing; and
(b)any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule, provided that any obstruction is removed as soon as reasonably practicable.
Commencement Information
I23Sch. 8 para. 23 in force at 19.2.2021, see art. 1
24. If by reason of the construction of a specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes or land drainage is impaired, or that drainage work is otherwise damaged, the impairment or damage must be made good by the undertaker as soon as reasonably practicable to the reasonable satisfaction of the drainage authority and, if the undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the undertaker the expense reasonably incurred by it in doing so.E+W
Commencement Information
I24Sch. 8 para. 24 in force at 19.2.2021, see art. 1
25. The undertaker must indemnify the drainage authority in respect of all costs, charges and expenses which the drainage authority may reasonably incur, have to pay or sustain—E+W
(a)in the examination or approval of plans under this Part of this Schedule;
(b)in inspecting the construction of the specified work or any protective works required by the drainage authority under this Part of this Schedule; and
(c)in carrying out any surveys or tests by the drainage authority which are reasonably required in connection with the construction of the specified work.
Commencement Information
I25Sch. 8 para. 25 in force at 19.2.2021, see art. 1
26.—(1) Without limiting the other provisions of this Part of this Schedule, the undertaker must indemnify the drainage authority from all claims, demands, proceedings, costs, damages, expenses or loss, which may be made or taken against, recovered from, or incurred by, the drainage authority by reason of—E+W
(a)any damage to any drainage work;
(b)any raising or lowering of the water table in land adjoining the authorised project or in any sewers, drains and watercourses; or
(c)any flooding or increased flooding of any such lands,
caused by the construction of any specified work or any act or omission of the undertaker, its contractors, agents or employees whilst engaged on the work.
(2) The drainage authority must give to the undertaker reasonable notice of any such claim or demand, and no settlement or compromise may be made without the agreement of the undertaker which agreement must not be unreasonably withheld or delayed.
Commencement Information
I26Sch. 8 para. 26 in force at 19.2.2021, see art. 1
27. The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the undertaker from any liability under this Part of this Schedule.E+W
Commencement Information
I27Sch. 8 para. 27 in force at 19.2.2021, see art. 1
28. Any dispute arising between the undertaker and the drainage authority under this Part of this Schedule, if the parties agree, is to be determined by arbitration under article 45 (arbitration), but otherwise is to be determined by the Secretary of State for Environment, Food and Rural Affairs and [F1the Secretary of State for Energy Security and Net Zero] acting jointly on a reference to them by the undertaker or the drainage authority, after notice in writing by one to the other.E+W
Textual Amendments
F1Words in Sch. 8 para. 28 substituted (3.5.2023) by The Secretaries of State for Energy Security and Net Zero, for Science, Innovation and Technology, for Business and Trade, and for Culture, Media and Sport and the Transfer of Functions (National Security and Investment Act 2021 etc) Order 2023 (S.I. 2023/424), art. 1(2), Sch. para. 69 (with art. 17)
Commencement Information
I28Sch. 8 para. 28 in force at 19.2.2021, see art. 1
29. The provisions of this Part of this Schedule have effect unless otherwise agreed in writing between the undertaker and the local highway authority.E+W
Commencement Information
I29Sch. 8 para. 29 in force at 19.2.2021, see art. 1
30. In this Part of this Schedule—E+W
“Commuted Sum” means the sum to be paid by the undertaker to the local highway authority for the future maintenance of Non-standard Highway Assets not previously forming part of the local highway which will be transferred to the local highway authority, as calculated in accordance with paragraph 50 of this Part of this Schedule;
“Design Detailing” in relation to any Works, means any detailed design or amended detailed design relating to those Works which is approved by the Secretary of State pursuant to requirement 12(1) or (4);
“Detailed Information” means the following drawings, specifications and other information relating to the local highway, which must be in accordance with the Design Detailing—
boundary, environmental and mitigation fencing;
road restraint systems (vehicle and pedestrian);
drainage and ducting;
earthworks;
road pavements;
kerbs, footways and paved areas;
traffic signs and road markings;
road lighting (including columns and brackets);
electrical work for road lighting and traffic signs;
highway structures;
landscaping, planting and any boundary features which will form part of the local highway;
utility diversions;
a schedule of timings for the works, including dates and durations for any closures of any part of the local highway;
traffic management proposals including any diversionary routes;
a schedule of condition of all local highway within the order limits; and
where local highway is occupied under this Order in connection with any Works but is not itself subject to Works, specification of the condition in which the local highway will be returned post occupation;
“Detailed Local Operating Agreement” means an agreement made pursuant to paragraph 32 of this Part of this Schedule;
“local highway” means any public, vehicular highway which vests or is intended at the completion of works to vest in or be otherwise maintainable by the local highway authority;
“local highway authority” means Somerset County Council;
“Non-standard Highway Assets” means highway assets which the local highway authority will become responsible for maintaining and which incur maintenance costs beyond the normal costs of maintaining the public highway having regard to the lists of standard and non-standard assets set out in paragraph 50(2) of this Part of this Schedule;
“Other Detailed Information” relating to any Works, means—
a schedule of timings for the Works, including dates and durations of any closures of any part of a local highway;
traffic management proposals, including any diversionary routes and any Detailed Local Operating Agreement;
a schedule of condition of the affected local highway within the Order limits; and
where the local highway is occupied under this Order in connection with the Works but Works are not undertaken on, to or under the local highway, a specification of the condition in which the local highway will be returned after the occupation has finished;
“Provisional Certificate” means a certificate issued by the local highway authority to certify that the Works to which the certificate relates have been completed in accordance with this Part of this Schedule and are ready for use for public traffic; and
“Works” means any works authorised by this Order undertaken on, to or under any local highway.
Commencement Information
I30Sch. 8 para. 30 in force at 19.2.2021, see art. 1
31. Before commencing the construction of, or the carrying out of any work authorised by this Order which involves interference with a local highway (including interference with the use by the public of a local highway and temporary or permanent stopping up of any part of a local highway), the undertaker must provide to the local highway authority the Detailed Information relating to the interference, and the Works must not be carried out except in accordance with the Detailed Information submitted to the local highway authority or as otherwise agreed between the undertaker and the local highway authority.E+W
Commencement Information
I31Sch. 8 para. 31 in force at 19.2.2021, see art. 1
32.—(1) Before commencing the construction of, or the carrying out of any work authorised by this Order which involves interference with a local highway (including interference with the use by the public of a local highway and temporary or permanent stopping up of any part of a local highway), the undertaker must use reasonable endeavours to agree with the local highway authority a Detailed Local Operating Agreement covering the following—E+W
(a)communications and customer care: communication with stakeholders and identification of which party is responsible for each activity;
(b)operational areas – scheme operational areas: definitions and scheme extents for the works areas, zone of influence and Free Recovery Area;
(c)asset handover: describing the scheme existing assets and activities to be undertaken to enable commencement and completion of Works, and the party responsible for each;
(d)asset inspection;
(e)routine maintenance and repair;
(f)winter maintenance and severe weather;
(g)continuity of technology;
(h)occupancy management;
(i)incidents;
(j)traffic management: provides the key activities to be undertaken with regard to the design, installation, maintenance and removal of Traffic Management; and
(k)claims made by and against the undertaker.
(2) Any agreement completed under sub-paragraph (1) must continue in force until the completion of the Works or the removal of the undertaker from all local highways, whichever is the earlier.
(3) Where agreement cannot be reached under sub-paragraph (1), the terms of the detailed local operating agreement will be resolved by arbitration under article 45 (arbitration).
Commencement Information
I32Sch. 8 para. 32 in force at 19.2.2021, see art. 1
33.—(1) Before commencing the construction of, or the carrying out of any Works the undertaker must provide to the local highway authority the Design Detailing and the Other Detailed Information relating to those Works.E+W
(2) The undertaker must not commence construction of, or the carrying out of the Works in question until approval has been given by the local highway authority to the Other Detailed Information or the Other Detailed Information has otherwise been agreed in writing between the undertaker and the local highway authority.
(3) The Works must not be constructed except in accordance with the Other Detailed Information as may be approved or agreed in accordance with sub-paragraph (2).
(4) If within 28 days after the Other Detailed Information has been submitted the local highway authority has not approved or disapproved it or it has not been otherwise agreed, the local highway authority is deemed to have approved it as submitted.
Commencement Information
I33Sch. 8 para. 33 in force at 19.2.2021, see art. 1
34.—(1) The undertaker will allow and facilitate an appropriately qualified officer of the local highway authority to participate in the design process for the detailed design of those parts of the authorised development which are local highway, and will have reasonable regard to any views of that officer in finalising the detailed design prior to any element reaching design fix or freeze; provided always that it will be the decision of the undertaker whether it implements such views and for the avoidance of doubt any such view shared by the officer will not be an instruction, requirement or authorisation under this Order.E+W
(2) Participation under sub-paragraph (1) will be in the form of invitations to attend design meetings not less than once per calendar month and the provision to the local highway authority of such drawings, cross sections and design proposals as are required to allow the local highway authority to provide views on detailed design proposals to the undertaker.
(3) Any participation by the local highway authority (or its appropriately qualified officer) in accordance with this paragraph will be at the cost of the local highway authority.
Commencement Information
I34Sch. 8 para. 34 in force at 19.2.2021, see art. 1
35.—(1) Any officer of the local highway authority duly appointed for the purpose may at all reasonable times, subject to any necessary and reasonable health and safety restrictions imposed by the undertaker, enter upon and inspect any part of the authorised development which—E+W
(a)is in, over, under or adjacent to any local highway, or
(b)may affect any local highway or any property of the local highway authority,
during the carrying out of the Works, and the undertaker must give to such officer all reasonable facilities for such inspection.
(2) The testing of materials used in any Works affecting local highways must be carried out at the expense of the undertaker in accordance with the Manual of Contract Documents for Highway Works Appendix 1/5 (Specification for Highway Works). The local highway authority must receive copies of all test certificates and results which have been requested by it in writing as soon as reasonably practicable. Notwithstanding the foregoing, the local highway authority has full power to test all or any materials used or proposed to be used in any work to the local highway at its own expense and the undertaker must provide such information and materials as is reasonably necessary to facilitate such testing.
(3) The undertaker must not alter, disturb or in any way interfere with any property of the local highway authority on or under any local highway, or the access thereto (except to the extent authorised under the powers conferred by this Order), without the prior written consent of the local highway authority.
Commencement Information
I35Sch. 8 para. 35 in force at 19.2.2021, see art. 1
36.—(1) The undertaker must procure that an appropriately qualified safety auditor undertakes road safety audit stages 3 and 4 on the Works including any Works to local highways in accordance with the Design Manual for Roads and Bridges (“DMRB”) Volume 5 Section 2 Part 2 (GG 119) or any replacement or modification of that standard and must provide copies of the reports of such audits to the local highway authority.E+W
(2) The local highway authority must be invited to participate in the stage 2, 3 and 4 road safety audits conducted under sub-paragraph (1).
(3) Where the report of the stage 3 road safety audit identifies any recommended works to the local highway, the undertaker must use reasonable endeavours to agree with the local highway authority which works or alternative proposals require to be implemented, provided that no works may be implemented which would give rise to any new or materially different environmental effects in comparison with those identified in the Environmental Statement.
(4) Where the report of the stage 4 road safety audit identifies any recommended works to the local highway, the undertaker must use reasonable endeavours to agree with the local highway authority which works or alternative proposals require to be implemented.
(5) Any works which the undertaker considers are required to be carried out to the local highway in accordance with the report of the stage 3 or stage 4 road safety audit, which works may not give rise to any new or materially different environmental effects in comparison with those identified in the Environmental Statement, must be undertaken by and at the expense of the undertaker to the reasonable satisfaction of the local highway authority.
(6) The undertaker must use reasonable endeavours to agree with the local highway authority a programme for any works to be carried out under sub-paragraph (5), which programme must include timing of any closures of any part of the highway, traffic management arrangements, signage and diversion routes where required.
(7) The carrying out of works under sub-paragraph (5) are to be taken to be works carried under this Order.
(8) Where, agreement cannot be reached under this paragraph, the terms of the Detailed Local Operating Agreement will be resolved by arbitration under article 45 (arbitration).
Commencement Information
I36Sch. 8 para. 36 in force at 19.2.2021, see art. 1
37. Provision must be made in accordance with the local highway authority's reasonable requirements at the site of the Works to prevent mud and other materials from being carried on to the adjacent highway by vehicles and plant. The operational highway in the vicinity of the site of the Works is to be swept as required to ensure its safe use as a public highway.E+W
Commencement Information
I37Sch. 8 para. 37 in force at 19.2.2021, see art. 1
38. The undertaker must not, except with the consent of the local highway authority, erect or retain on or over a local highway to which the public continues to have access any scaffolding or other structure which obstructs the local highway.E+W
Commencement Information
I38Sch. 8 para. 38 in force at 19.2.2021, see art. 1
39. Except in an emergency or where necessary to secure the safety of the public, no direction or instruction may be given by the local highway authority to the contractors, servants or agents of the undertaker regarding any highway operations without the prior consent in writing of the undertaker.E+W
Commencement Information
I39Sch. 8 para. 39 in force at 19.2.2021, see art. 1
40. In exercising the powers conferred by the Order in relation to any local highway the undertaker must have regard to the potential disruption of traffic which may be caused, seek to minimise such disruption so far as is reasonably practicable and must at no time prevent or unreasonably impede access by emergency service vehicles to any property.E+W
Commencement Information
I40Sch. 8 para. 40 in force at 19.2.2021, see art. 1
41. The undertaker must, if reasonably required by the local highway authority, provide and maintain during such time as the undertaker may occupy any part of a local highway for the purpose of the construction of any part of the authorised development, temporary ramps for vehicular or pedestrian traffic, or both, and any other traffic measures required to protect the safety of road traffic.E+W
Commencement Information
I41Sch. 8 para. 41 in force at 19.2.2021, see art. 1
42.—(1) If reasonably requested by the local highway authority, the undertaker must execute and complete a transfer to the local highway authority of any land and rights within the local highway compulsorily acquired by the undertaker pursuant to articles 23 (compulsory acquisition of land) and 26 (compulsory acquisition of rights) for the construction, operation and maintenance of the local highway or to facilitate it, or as is incidental to it, at nil consideration provided that the undertaker has completed all necessary works within the local highway for which that land and rights were compulsorily acquired.E+W
(2) Sub-paragraph (1) above does not apply in relation to any land within the local highway compulsorily acquired by the undertaker that has been or is proposed to be permanently stopped up and rights extinguished pursuant to article 16 (permanent stopping up and restriction of use of highways, streets and private means of access).
Commencement Information
I42Sch. 8 para. 42 in force at 19.2.2021, see art. 1
43.—(1) Where the undertaker carries out any Works to any local highway it must make good any defects in those Works notified to it by the local highway authority within the period of 52 weeks after the date of the completion of the Works to that area of local highway to the reasonable satisfaction of the local highway authority.E+W
(2) The carrying out of any remedial works required under sub-paragraph (1) are to be regarded as works carried out under this Order.
(3) The carrying out of any remedial works required under sub-paragraph (1) requires the submission of such items of Detailed Information to the local highway authority as the undertaker deems to be reasonable in the circumstances but always including a description of the works to be carried out, a schedule of timings for the works, including dates and durations for any closures of any part of the local highway and traffic management proposals.
Commencement Information
I43Sch. 8 para. 43 in force at 19.2.2021, see art. 1
44.—(1) The Works must all be completed on such date or dates that will be notified by the undertaker to the local highway authority in writing. The completion of Works for the purposes of paragraph 43 of this Schedule will be such date notified under this paragraph.E+W
(2) Prior to the completion of the Works, the undertaker must invite the local highway authority to participate in inspection of the Works to identify any defects or incomplete works. Any defects must be rectified and any incomplete works carried out prior to any notice of completion being issued under sub-paragraph (1).
Commencement Information
I44Sch. 8 para. 44 in force at 19.2.2021, see art. 1
45. The undertaker will hold the local highway authority harmless and indemnified from and against any liability, loss, cost or claim arising out of or incidental to the carrying out of the Works (other than those arising out of or in consequence of any negligent act, default or omission of the local highway authority) provided that no claim can be settled or liability accepted by the local highway authority without first obtaining the written approval of the undertaker, such approval not to be unreasonably withheld or delayed.E+W
Commencement Information
I45Sch. 8 para. 45 in force at 19.2.2021, see art. 1
46.—(1) When the undertaker considers that the Works have reached completion it must notify the local highway authority and must allow the local highway authority the opportunity to inspect the Works and the undertaker must give proper consideration to any representations that are made by the local highway authority.E+W
(2) The undertaker may not notify the local highway authority under sub-paragraph (1) until either—
(a)a stage 3 safety audit has been carried out in respect of the Works in question in accordance with GG19 of DMRB and in the opinion of the undertaker any recommended works identified in the audit have been completed; or
(b)if the Works in question were not subject to a safety audit, the local highway authority has been provided an opportunity to inspect the works and the undertaker has in its opinion completed any further works required to address any safety deficiencies or defects identified as a result of the inspection.
Commencement Information
I46Sch. 8 para. 46 in force at 19.2.2021, see art. 1
47. The local highway authority must, if requested to do so by the undertaker, issue to the undertaker a provisional certificate in relation to any part of the Works, after completion of that part of the Works if the local highway authority is satisfied that the Works have been completed in accordance with this Part of this Schedule.E+W
Commencement Information
I47Sch. 8 para. 47 in force at 19.2.2021, see art. 1
48. No earlier than 52 weeks from the date of issue of the Provisional Certificate, the local highway authority must issue a Final Certificate, certifying that all outstanding defects relating to the part of the Works in question and which required remediation have been so remedied, provided that—E+W
(a)all identified defects requiring remediation have been so remedied such that the local highway authority consider the Final Certificate may be issued;
(b)a stage 4 safety audit has been carried out (if a stage 4 safety audit is required in accordance with GG19 of DMRB in connection with the Works), and following proper consideration of the representations of the local highway authority, any additional works, alterations or amendments to the Works as a result of the stage 4 safety audit have been completed to the reasonable satisfaction of the local highway authority;
(c)the undertaker has given the local highway authority an opportunity to inspect the Works and has given proper consideration to any representations made by the local highway authority;
(d)the undertaker has paid to the local highway authority any Commuted Sum due in relation to the part of the local highway to which the Provisional Certificate relates;
(e)the undertaker has provided the local highway authority with such detailed information as the local highway authority may reasonably require in relation to the Works as built; and
(f)all costs charges, expenses payable to the local highway authority pursuant to this Part have been paid.
Commencement Information
I48Sch. 8 para. 48 in force at 19.2.2021, see art. 1
49. The undertaker must pay to the local highway authority in respect of the highway works a sum equal to the whole of any costs and expenses which the local highway authority reasonably incur—E+W
(a)in the examination or approval of the Other Detailed Information under this Part;
(b)in inspecting the construction of the Works including any works required by the local highway authority under this Part;
(c)in carrying out any surveys which are reasonably required in connection with the construction of the Works; and
(d)in the transfer pursuant to paragraph 42 to the local highway authority of the land and rights acquired by the undertaker.
Commencement Information
I49Sch. 8 para. 49 in force at 19.2.2021, see art. 1
50.—(1) The undertaker must, within 3 months of the date of approval of plans showing the limits of responsibility for the operational maintenance of the Works under requirement 13, prepare a list of assets not previously forming part of the local highway for which the local highway authority will be responsible for maintenance following completion of the Works.E+W
(2) The undertaker must use reasonable endeavours to agree a schedule of items on the list agreed under sub-paragraph (1) which are Non-standard Highway Assets having regard to the following—
(a)standard highway assets include—
(i)carriageways surfaced in concrete asphaltic materials (non-pigmented binder and non-coloured aggregates);
(ii)carriageways in shared surface roads, courtyards and housing squares surfaced in 200mm x 100mm x 80mm rectangular concrete block paving (optional);
(iii)footway surfaced in concrete asphaltic materials (non-pigmented binder or coloured aggregates);
(iv)footways adjacent to block paved carriageways also surfaced in 200mm x 100mm x 65mm thick concrete block paving (optional);
(v)cycleways surfaced in concrete asphaltic materials (red pigmented binders and/or aggregates);
(vi)pre-cast concrete kerbing;
(vii)gully drainage, connection pipes and gravity draining highway carrier drains;
(viii)galvanised pedestrian guard railing;
(ix)standard highway lighting layouts, columns and lanterns;
(x)standard illuminated and non-illuminated highway signs;
(xi)passively safe sign posts where required for road safety;
(xii)bollards and markers posts manufactured from plastic derivatives or recycled plastic/rubber;
(xiii)road markings;
(xiv)grass verges;
(b)Non-Standard Highway Assets include—
(i)any culvert, bridge, retaining wall or other structure
(ii)special features such as noise fencing, vehicle restraint barriers, pedestrian guard railing, knee rails and fences, gates
(iii)landscaping features such as planting, trees, hedging
(iv)sustainable drainage systems (“SuDS”) or non-standard highway drainage features such as—
(aa)flow control devices and attenuation storage;
(bb)SuDS including maintenance of any landscaping;
(cc)oil or petrol interceptors including the disposal of contaminated waste;
(dd)pumping stations and their energy charges;
(ee)watercourses and swales.
(3) Where the schedule prepared under paragraph (2) cannot be agreed, the determination of the schedule will be referred to arbitration under article 45 (arbitration).
(4) Following agreement of the schedule under sub-paragraph (2) or determination under sub-paragraph (3), the local highway authority must prepare a calculation of the Commuted Sum based on the maintenance the local highway authority considers to be required for the schedule of Non-Standard Highway Assets agreed under sub-paragraph (2) or determined under sub-paragraph (3) and must use reasonable endeavours to agree it with the undertaker.
(5) The undertaker must be provided with a complete breakdown of the calculation of the Commuted Sum by the local highway authority under sub-paragraph (4) including any assumptions used.
(6) Where the calculation prepared under sub-paragraph (4) cannot be agreed, the determination of the Commuted Sum will be referred to arbitration under article 45 (arbitration)
(7) The undertaker must pay the Commuted Sum to the local highway authority in one instalment within 10 working days of the later of—
(a)the date of completion of the authorised development; or
(b)the date of agreement of the value of the Commuted Sum under sub-paragraph (4) or determination under sub-paragraph (6).
Commencement Information
I50Sch. 8 para. 50 in force at 19.2.2021, see art. 1
51. Nothing in this Part of this Schedule prevents the local highway authority from carrying out any work or taking such action as deemed appropriate forthwith without prior notice to the undertaker in the event of an emergency or danger to the public.E+W
Commencement Information
I51Sch. 8 para. 51 in force at 19.2.2021, see art. 1
52. Any difference arising between the undertaker and the local highway authority under this Part of this Schedule (other than in difference as to the meaning or construction of this Part of this Schedule) will be resolved by arbitration under article 45 (arbitration).E+W
Commencement Information
I52Sch. 8 para. 52 in force at 19.2.2021, see art. 1
53. The provisions of this Part of this Schedule have effect unless otherwise agreed in writing between the undertaker and the local highway authority.E+W
Commencement Information
I53Sch. 8 para. 53 in force at 19.2.2021, see art. 1
54. In this Part of this Schedule—E+W
“Design Detailing” in relation to any Works, means any detailed design or amended detailed design relating to those Works which is approved by the Secretary of State pursuant to requirement 12(1) or (4);
“Detailed Information” means the following drawings, specifications and other information relating to the local highway, which must be in accordance with the Design Detailing—
the rights of way and access plans;
the schedule of widths and limitations, including details of any gates and stiles;
details of surfacing, kerbs and drainage; and
details of any signage to be altered or erected;
“local highway” means any public, non-vehicular highway which vests or is intended at the completion of works to vest in or be otherwise maintainable by the local highway authority being footpaths, footways, cycleways and bridleways;
“Works” means any works authorised by this Order undertaken on, to or under any local highway.
Commencement Information
I54Sch. 8 para. 54 in force at 19.2.2021, see art. 1
55. Before commencing the construction of, or the carrying out of any work authorised by this Order which involves interference with a local highway (including interference with the use by the public of a local highway and temporary or permanent stopping up of any part of a local highway), the undertaker must provide to the local highway authority the Detailed Information relating to the interference, and the Works must not be carried out except in accordance with the Detailed Information submitted to the local highway authority or as otherwise agreed between the undertaker and the local highway authority.E+W
Commencement Information
I55Sch. 8 para. 55 in force at 19.2.2021, see art. 1
56. Any officer of the local highway authority duly appointed for the purpose may at all reasonable times, subject to any necessary and reasonable health and safety restrictions imposed by the undertaker, enter upon and inspect any part of the authorised development which is in, over or under any local highway, or which may affect any local highway or any property of the local highway authority, during the carrying out of the Works, and the undertaker must give to such officer all reasonable facilities for such inspection.E+W
Commencement Information
I56Sch. 8 para. 56 in force at 19.2.2021, see art. 1
57. The testing of materials used in any Works affecting local highways must be carried out at the expense of the undertaker in accordance with Manual of Contract Documents for Highway Works Appendix 1/5 (Specification for Highway Works). The local highway authority must receive copies of all test certificates and results which have been requested by it in writing as soon as reasonably practicable. Notwithstanding the foregoing, the local highway authority have full power to test all or any materials used or proposed to be used in any work to the local highway at its own expense and the undertaker must provide such information and materials as is reasonably necessary to facilitate such testing.E+W
Commencement Information
I57Sch. 8 para. 57 in force at 19.2.2021, see art. 1
58.—(1) Where the undertaker carries out any Works to any local highway it must make good any defects in those Works notified to it by the local highway authority within the period of 52 weeks after the date of the completion of the Works to that area of local highway to the reasonable satisfaction of the local highway authority.E+W
(2) The carrying out of any remedial works required under sub-paragraph (1) are Works under this Order.
(3) The carrying out of any remedial works required under sub-paragraph (1) requires the submission of such items of Detailed Information to the local highway authority as the undertaker deems to be reasonable in the circumstances but always including a description of the works to be carried out, a schedule of timings for the works, including dates and durations for any closures of any part of the local highway and traffic management proposals.
Commencement Information
I58Sch. 8 para. 58 in force at 19.2.2021, see art. 1
59. The undertaker must notify the local highway authority of the date of the completion of the works to any area of local highway within 5 working days of such completion.E+W
Commencement Information
I59Sch. 8 para. 59 in force at 19.2.2021, see art. 1
60. The undertaker will hold the local highway authority harmless and indemnified from and against any liability, loss, cost or claim arising out of or incidental to the carrying out of the Works (other than those arising out of or in consequence of any negligent act, default or omission of the local highway authority) provided that no claim can be settled or liability accepted by the local highway authority without first obtaining the written approval of the undertaker, such approval not to be unreasonably withheld or delayed.E+W
Commencement Information
I60Sch. 8 para. 60 in force at 19.2.2021, see art. 1
61. The undertaker must indemnify the local highway authority in respect of all costs, charges and expenses which the local highway authority may reasonably incur, have to pay or sustain in—E+W
(a)inspecting the construction of the Works including any works required by the local highway authority under this Part of this Schedule;
(b)carrying out any surveys by the local highway authority which are reasonably required in connection with the construction of the Works.
Commencement Information
I61Sch. 8 para. 61 in force at 19.2.2021, see art. 1
62. Nothing in this Part of this Schedule prevents the local highway authority from carrying out any work or taking such action as deemed appropriate forthwith without prior notice to the undertaker in the event of an emergency or danger to the public.E+W
Commencement Information
I62Sch. 8 para. 62 in force at 19.2.2021, see art. 1
63. Any difference arising between the undertaker and the local highway authority under this Part of this Schedule (other than in difference as to the meaning or construction of this Part of this Schedule) will be resolved by arbitration under article 45 (arbitration).E+W
Commencement Information
I63Sch. 8 para. 63 in force at 19.2.2021, see art. 1
Yr Offeryn Cyfan you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.
Would you like to continue?
Y Rhestrau you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.
Would you like to continue?
Y Diweddaraf sydd Ar Gael (diwygiedig):Y fersiwn ddiweddaraf sydd ar gael o’r ddeddfwriaeth yn cynnwys newidiadau a wnaed gan ddeddfwriaeth ddilynol ac wedi eu gweithredu gan ein tîm golygyddol. Gellir gweld y newidiadau nad ydym wedi eu gweithredu i’r testun eto yn yr ardal ‘Newidiadau i Ddeddfwriaeth’.
Gwreiddiol (Fel y’i Deddfwyd neu y’i Gwnaed): Mae'r wreiddiol fersiwn y ddeddfwriaeth fel ag yr oedd pan gafodd ei deddfu neu eu gwneud. Ni wnaed unrhyw newidiadau i’r testun.
Pwynt Penodol mewn Amser: This becomes available after navigating to view revised legislation as it stood at a certain point in time via Advanced Features > Show Timeline of Changes or via a point in time advanced search.
Rhychwant ddaearyddol: Indicates the geographical area that this provision applies to. For further information see ‘Frequently Asked Questions’.
Dangos Llinell Amser Newidiadau: See how this legislation has or could change over time. Turning this feature on will show extra navigation options to go to these specific points in time. Return to the latest available version by using the controls above in the What Version box.
Gallwch wneud defnydd o ddogfennau atodol hanfodol a gwybodaeth ar gyfer yr eitem ddeddfwriaeth o’r tab hwn. Yn ddibynnol ar yr eitem ddeddfwriaeth sydd i’w gweld, gallai hyn gynnwys:
This timeline shows the different points in time where a change occurred. The dates will coincide with the earliest date on which the change (e.g an insertion, a repeal or a substitution) that was applied came into force. The first date in the timeline will usually be the earliest date when the provision came into force. In some cases the first date is 01/02/1991 (or for Northern Ireland legislation 01/01/2006). This date is our basedate. No versions before this date are available. For further information see the Editorial Practice Guide and Glossary under Help.
Defnyddiwch y ddewislen hon i agor dogfennau hanfodol sy’n cyd-fynd â’r ddeddfwriaeth a gwybodaeth am yr eitem hon o ddeddfwriaeth. Gan ddibynnu ar yr eitem o ddeddfwriaeth sy’n cael ei gweld gall hyn gynnwys:
liciwch ‘Gweld Mwy’ neu ddewis ‘Rhagor o Adnoddau’ am wybodaeth ychwanegol gan gynnwys