Chwilio Deddfwriaeth

The Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022

 Help about what version

Pa Fersiwn

  • Y Diweddaraf sydd Ar Gael (Diwygiedig)
  • Gwreiddiol (a wnaed Fel)
 Help about opening options

Dewisiadau AgorExpand opening options

Close

Print Options

Status:

Dyma’r fersiwn wreiddiol (fel y’i gwnaed yn wreiddiol). This item of legislation is currently only available in its original format.

Statutory Instruments

2022 No. 871

Transport And Works, England

Transport, England

The Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022

Made

12th July 2022

Coming into force

2nd August 2022

An application has been made to the Secretary of State in accordance with the Transport and Works (Applications and Objections Procedure) (England and Wales) Rules 2006(1) for an Order under sections 1 and 5 of the Transport and Works Act 1992(2) (“the 1992 Act”).

The Secretary of State caused an inquiry to be held for the purposes of the application pursuant to section 11 of the 1992 Act.

The Secretary of State, having considered the objections made and not withdrawn and the report of the person who held the inquiry, has determined to make an Order giving effect to the proposals comprised in the application with modifications which in the opinion of the Secretary of State do not make any substantial change in the proposals.

Notice of the Secretary of State’s determination was published in the London Gazette on 8th July 2022.

The Secretary of State, in exercise of the powers conferred by sections 1 and 5 of, and paragraphs 3 to 5, 7, 8, 10, 11, 16 and 17 of Schedule 1 to, the 1992 Act makes the following Order—

PART 1PRELIMINARY

Citation and Commencement

1.  This Order may be cited as the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022 and comes into force on 2nd July 2022.

Interpretation

2.—(1) In this Order—

the 1961 Act” means the Land Compensation Act 1961(3);

the 1965 Act” means the Compulsory Purchase Act 1965(4);

the 1980 Act” means the Highways Act 1980(5);

the 1981 Act” means the Compulsory Purchase (Vesting Declarations) Act 1981(6);

the 1990 Act” means the Town and Country Planning Act 1990(7);

the 1991 Act” means the New Roads and Street Works Act 1991(8);

the 2003 Act” means the Communications Act 2003(9);

address” includes any number or address used for the purposes of electronic transmission;

authorised works” means the works authorised by the prior approval and any associated or similar works authorised by the Town and Country Planning (General Permitted Development) (England) Order 2015(10);

book of reference” means the book of reference certified by the Secretary of State as the book of reference for the purposes of this Order;

building” includes any structure or erection or any part of a building, structure or erection;

carriageway” has the same meaning as in the 1980 Act;

deposited plans” means the plans certified by the Secretary of State as the deposited plans for the purposes of this Order;

electronic transmission” means a communication transmitted—

(a)

by means of an electronic communications network; or

(b)

by other means but while in electronic form;

and in this definition “electronic communications network” has the same meaning as in section 32(1)(11) (meaning of electronic communications networks and services) of the 2003 Act;

footway” has the same meaning as in the 1980 Act;

highway” and “highway authority” have the same meaning as in the 1980 Act;

maintain” includes inspect, repair, adjust, alter, remove, reconstruct and replace, and “maintenance“ is to be construed accordingly;

Network Rail” means Network Rail Infrastructure Limited (Company registration number 02904587) whose registered office is at 1 Eversholt Street, London NW1 2DN;

the Order limits” means the limits of land to be acquired or used which are shown on the deposited plans and described in the book of reference;

owner”, in relation to land, has the same meaning as in section 7 (interpretation) of the Acquisition of Land Act 1981(12);

prior approval” means the prior approval issued by Oxford City Council and dated 26 November 2021 (reference 21/02007/PA18) including any variation or replacement of such prior approval;

street” has the meaning given in section 48(1) (streets, street works and undertakers) of the 1991 Act and “street” includes part of a street;

street authority” in relation to a street, has the same meaning as in Part 3 of the 1991 Act;

the tribunal” means the Lands Chamber of the Upper Tribunal; and

the undertaking” means the railway undertaking of Network Rail as from time to time existing.

(2) References in this Order to rights over land include references to rights to do, or to place and maintain, anything in, on or under land or in the air-space above its surface.

(3) All measurements stated in any description of land in the book of reference are approximate.

(4) References in this Order to numbered plots are references to plot numbers shown on the deposited plans.

PART 2ACQUISITION AND POSSESSION OF LAND

Powers of acquisition

Power to acquire land

3.—(1) Network Rail may acquire compulsorily so much of the land shown on the deposited plans and described in the book of reference as may be required for the purposes of the authorised works or their maintenance and may use any land so acquired for those purposes.

(2) This article is subject to article 6 (power to acquire new rights) and article 8 (temporary possession of land).

Application of Part 1 of the 1965 Act

4.—(1) Part 1 of the 1965 Act, in so far as not modified by or inconsistent with the provisions of this Order, applies to the acquisition of land under this Order—

(a)as it applies to a compulsory purchase to which the Acquisition of Land Act 1981(13) applies; and

(b)as if this Order were a compulsory purchase order under that Act.

(2) Part 1 of the 1965 Act, as applied by paragraph (1), has effect with the following modifications.

(3) Omit section 4 (which provides a time limit for compulsory purchase of land).

(4) In section 4A(1)(14) (extension of time limit during challenge) for “section 23 of the Acquisition of Land Act 1981 (application to High Court in respect of compulsory purchase order), the three year period mentioned in section 4”, substitute “section 22 of the Transport and Works Act 1992 (validity of orders under section 1 or 3), the five year period mentioned in article 13 (time limit for exercise of powers of acquisition) of the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022”.

(5) In section 11(1B)(15) (powers of entry), in a case where the notice to treat relates only to the acquisition of an easement or other right over land, for “3 months” substitute “1 month”.

(6) In section 11A(16) (powers of entry: further notices of entry)—

(a)in subsection (1)(a), after “land” insert “under that provision”; and

(b)in subsection (2), after “land” insert “under that provision”.

(7) In section 22(2) (interests omitted from purchase), for “section 4 of this Act” substitute “article 14 (time limit for exercise of powers of acquisition) of the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022”.

(8) In Schedule 2A(17) (counter-notice requiring purchase of land not in notice to treat)—

(a)omit paragraphs 1(2) and 14(2); and

(b)after paragraph 29, insert—

PART 4INTERPRETATION

30.  In this Schedule, references to entering on and taking possession of land do not include doing so under article 8 (temporary possession of land) of the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022..

Application of the 1981 Act

5.—(1) The 1981 Act applies as if this Order were a compulsory purchase order.

(2) The 1981 Act, as applied by paragraph (1), has effect with the following modifications.

(3) In section 5 (earliest date for execution of declaration), in subsection (2), omit the words from “, and this subsection” to the end.

(4) Omit section 5A(18) (time limit for general vesting declaration).

(5) In section 5B(1)(19) (extension of time limit during challenge) for “section 23 of the Acquisition of Land Act 1981 (application to High Court in respect of compulsory purchase order), the three year period mentioned in section 5A” substitute “section 22 of the Transport and Works Act 1992 (validity of orders under section 1 or 3), the five year period mentioned in article 13 (time limit for exercise of powers of acquisition) of the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022”.

(6) In section 6(20) (notices after execution of declaration), in subsection (1)(b) for “section 15 of, or paragraph 6 of Schedule 1 to, the Acquisition of Land Act 1981” substitute “section 14A of the Transport and Works Act 1992”.

(7) In section 7(21) (constructive notice to treat), in subsection (1)(a), omit “(as modified by section 4 of the Acquisition of Land Act 1981)”.

(8) In Schedule A1(22) (counter-notice requiring purchase of land not in general vesting declaration), omit paragraph 1(2).

(9) References to the 1965 Act are to be construed as references to that Act as applied to the acquisition of land under article 3 (power to acquire land) by article 4 (application of Part 1 of the 1965 Act).

Power to acquire new rights

6.—(1) Subject to paragraph (2), Network Rail may acquire compulsorily such easements or other rights over any land which it is authorised to acquire under article 3 (power to acquire land) as may be required for any purpose for which that land may be acquired under that provision, by creating them as well as by acquiring easements or other rights already in existence.

(2) Subject to Schedule 2A (counter-notice requiring purchase of land not in notice to treat) to the 1965 Act (as substituted by paragraph 5(8) of Schedule 1 (modification of compensation and compulsory purchase enactments for creation of new rights)) where Network Rail acquires a right over land under paragraph (1), Network Rail is not required to acquire a greater interest in that land.

(3) Schedule 1 has effect for the purpose of modifying the enactments relating to compensation and the provisions of the 1965 Act in their application in relation to the compulsory acquisition under this article of a right over land by the creation of a new right.

Power to acquire subsoil or airspace only

7.—(1) Network Rail may acquire compulsorily so much of, or such rights in, the subsoil of or the airspace over the land referred to in article 3(1) (power to acquire land) as may be required for any purpose for which that land may be acquired under that provision instead of acquiring the whole of the land.

(2) Where Network Rail acquires any part of, or rights in, the subsoil of or the airspace over the land under paragraph (1), Network Rail is not required to acquire an interest in any other part of the land.

(3) Paragraph (2) does not prevent Schedule 2A to the 1965 Act (as modified by article 4 (application of Part 1 of the 1965 Act)) or Schedule A1 to the 1981 Act (as modified by article 5 (application of the 1981 Act)) from applying where Network Rail acquires a cellar, vault, arch or other construction forming part of a house, building or manufactory.

Temporary Possession of Land

Temporary possession of land

8.—(1) Network Rail may, in connection with the carrying out of the authorised works, enter upon and take temporary possession of the land specified in columns (1) and (2) of Schedule 2 (land of which temporary possession may be taken) for the purpose specified in relation to that land in column (3) of that Schedule and may, in connection with the carrying out of the authorised works—

(a)remove any buildings, materials (including any waste material) and vegetation from that land;

(b)construct temporary works (including the provision of means of access) and buildings on that land;

(c)temporarily occupy and use airspace for the purposes of the operation of a crane in connection with the construction of the authorised works; and

(d)construct or undertake any works specified in relation to that land in column (2) of Schedule 2, or any works of mitigation.

(2) Subject to paragraph (11), Network Rail may, in connection with the carrying out of the authorised works, enter upon and take possession of any other land within the Order limits in respect of which no notice of entry has been served under section 11(23) (powers of entry) of the 1965 Act (other than in connection with the acquisition of rights only) and no declaration has been made under section 4(24) (execution of declaration) of the 1981 Act and may, in connection with the carrying out of the authorised works—

(a)remove any buildings, materials (including any waste material) and vegetation from that land;

(b)construct temporary works (including the provision of means of access) and buildings on that land; and

(c)construct any permanent works comprising part of the authorised works.

(3) Not less than 28 days before entering upon and taking temporary possession of land under this article Network Rail must serve notice of the intended entry on the owners and occupiers of the land.

(4) Network Rail may not, without the agreement of the owners of the land, remain in possession of any land under this article—

(a)in the case of land specified in paragraph (1) after the end of the period of one year beginning with the date of completion of the work specified in relation to that land in column (3) of Schedule 2; or

(b)in the case of land referred to in paragraph (2), after the end of the period of one year beginning with the date of completion of the work for which temporary possession of the land was taken unless Network Rail has, before the end of that period, served a notice of entry under section 11(1) of the 1965 Act or made a declaration under section 4 of the 1981 Act.

(5) Before giving up possession of land of which temporary possession has been taken under this article, Network Rail must remove all temporary works and restore the land to the reasonable satisfaction of the owners of the land, but Network Rail is not required to—

(a)replace a building or materials removed under this article; or

(b)restore the land on which any works have been constructed under paragraph (2)(c).

(6) Network Rail must pay compensation to the owners and occupiers of land of which temporary possession is taken under this article for any loss or damage arising from the exercise in relation to the land of the powers conferred by this article.

(7) Any dispute as to a person’s entitlement to compensation under paragraph (6), or as to the amount of the compensation, is to be determined, in case of dispute, as if it were a dispute under Part 1 of the 1961 Act.

(8) Without affecting article 20 (no double recovery), nothing in this article affects any liability to pay compensation under section 10(2)(25) (further provision as to compensation for injurious affection) of the 1965 Act or under any other enactment in respect of loss or damage arising from the execution of any works, other than loss or damage for which compensation is payable under paragraph (6).

(9) Where Network Rail takes possession of land under this article, Network Rail is not required to acquire the land or any interest in it.

(10) Section 13(26) (refusal to give possession to acquiring authority) of the 1965 Act applies to the temporary use of land under this article to the same extent as it applies to the compulsory acquisition of land under this Order by virtue of article 4 (application of Part 1 of the 1965 Act).

(11) Paragraph (2) does not authorise Network Rail to take temporary possession of any land which it is not authorised to acquire under article 3 (power to acquire land).

Temporary use of land for maintenance works

9.—(1) Subject to paragraph (2), at any time during the maintenance period relating to any of the authorised works, Network Rail may—

(a)enter upon and take temporary possession of any Order land if such possession is reasonably required for the purpose of maintaining the work or any ancillary works connected with it; and

(b)construct such temporary works (including the provision of means of access) and buildings on the land as may be reasonably necessary for that purpose.

(2) Paragraph (1) does not authorise Network Rail to take temporary possession of—

(a)any house or garden belonging to a house; or

(b)any building (other than a house) if it is for the time being occupied.

(3) Not less than 28 days before entering upon and taking temporary possession of land under this article Network Rail must serve notice of the intended entry on the owners and occupiers of the land.

(4) Network Rail may only remain in possession of land under this article for so long as may be reasonably necessary to carry out the maintenance of works for which possession of the land was taken.

(5) Before giving up possession of land of which temporary possession has been taken under this article, Network Rail must remove all temporary works and restore the land to the reasonable satisfaction of the owners of the land.

(6) Network Rail must pay compensation to the owners and occupiers of land of which temporary possession is taken under this article for any loss or damage arising from the exercise in relation to the land of the powers conferred by this article.

(7) Any dispute as to a person’s entitlement to compensation under paragraph (6), or as to the amount of the compensation, is to be determined as if it were a dispute under Part 1 of the 1961 Act.

(8) Without affecting article 20 (no double recovery), nothing in this article affects any liability to pay compensation under section 10(2) (further provision as to compensation for injurious affection) of the 1965 Act or under any other enactment in respect of loss or damage arising from the execution of any works, other than loss or damage for which compensation is payable under paragraph (6).

(9) Where Network Rail takes possession of land under this article, it is not required to acquire the land or any interest in it.

(10) Section 13 (refusal to give possession to acquiring authority) of the 1965 Act applies to the temporary use of land under this article to the same extent as it applies to the compulsory acquisition of land under this Order by virtue of article 4 (application of Part 1 of the 1965 Act).

(11) In this article “the maintenance period” in relation to an authorised work means the period of 5 years beginning with the date on which the work is opened for use.

Compensation

Disregard of certain interests and improvements

10.—(1) In assessing the compensation payable to any person on the acquisition from that person of any land under this Order, the tribunal must not take into account—

(a)any interest in land; or

(b)any enhancement of the value of any interest in land by reason of any building erected, works executed or improvement or alteration made on the relevant land,

if the tribunal is satisfied that the creation of the interest, the erection of the building, the execution of the works or the making of the improvement or alteration was not reasonably necessary and was undertaken with a view to obtaining compensation or increased compensation.

(2) In paragraph (1) “relevant land” means the land acquired from the person concerned or any other land with which that person is, or was at the time when the building was erected, the works executed or the improvement or alteration made, directly or indirectly concerned.

Set-off for enhancement in value of retained land

11.—(1) In assessing the compensation payable to any person in respect of the acquisition from that person under this Order of any land (including the subsoil) the tribunal must set off against the value of the land so acquired any increase in value of any contiguous or adjacent land belonging to that person in the same capacity which will accrue to that person by reason of the construction of the authorised works.

(2) In assessing the compensation payable to any person in respect of the acquisition from that person of any new rights over land (including the subsoil) under article 6 (power to acquire new rights), the tribunal is to set-off against the value of the rights so acquired—

(a)any increase in the value of the land over which the new rights are acquired; and

(b)any increase in value of any contiguous or adjacent land belonging to that person in the same capacity,

which will accrue to that person by reason of the construction of the authorised works.

(3) The 1961 Act has effect, subject to paragraphs (1) and (2), as if this Order were a local enactment for the purposes of that Act.

Supplementary

Extinction or suspension of private rights of way

12.—(1) Subject to the provisions of this article, all private rights of way over land subject to compulsory acquisition under this Order are extinguished—

(a)as from the date of acquisition of the land by Network Rail, whether compulsorily or by agreement; or

(b)on the date of entry on the land by Network Rail under section 11(1) (powers of entry) of the 1965 Act,

whichever is the sooner.

(2) Subject to the provisions of this article, all private rights of way over land owned by Network Rail which, being within the Order limits, is required for the purposes of the authorised works, are extinguished on the appropriation of the land for any of those purposes by Network Rail.

(3) Subject to the provisions of this article, all private rights of way over land subject to the compulsory acquisition of rights under this Order are extinguished in so far as their continuance would be inconsistent with the exercise of the right—

(a)as from the date of the acquisition of the right by Network Rail, whether compulsorily or by agreement; or

(b)on the date of entry on the land by Network Rail under section 11(1) of the 1965 Act,

whichever is the sooner.

(4) Subject to the provisions of this article, all private rights of way over land of which Network Rail takes temporary possession under this Order are suspended and unenforceable for as long as Network Rail remains in lawful possession of the land.

(5) Any person who suffers loss by the extinguishment or suspension of any private right of way under this article is entitled to compensation to be determined, in case of dispute, as if it were a dispute under Part 1 of the 1961 Act.

(6) This article does not apply in relation to any right of way to which section 271 (extinguishment of rights of statutory undertakers: preliminary notices) or 272(27) (extinguishment of rights of electronic communications code network operators: preliminary notices) of the 1990 Act or paragraph 1 of Schedule 4 (provisions relating to statutory undertakers, etc.) to this Order applies.

(7) Paragraphs (1) to (4) have effect subject to—

(a)any notice given by Network Rail before the completion of the acquisition of the land, Network Rail’s appropriation of it, Network Rail’s entry onto it or Network Rail’s taking temporary possession of it that any or all of those paragraphs do not apply to any right of way specified in the notice; and

(b)any agreement made (whether before or after any of the events mentioned in sub-paragraph (a) and before or after the coming into force of this Order) between Network Rail and the person in or to whom the right of way in question is vested or belongs which makes reference to this article.

(8) In respect of Plots 6b and 6c (as shown on the deposited plans)—

(a)notwithstanding paragraph (1), no private rights of way over Plots 6b or 6c are extinguished on the occurrence of the events in paragraphs (1)(a) or (b);

(b)subject to Network Rail providing or there being available an alternative or diverted route Network Rail may suspend any private rights of way over Plots 6b and 6c for any purpose in connection with the carrying out of the authorised works;

(c)not less than 28 days before suspending any private rights of way pursuant to sub-paragraph (b), Network Rail must serve notice of the suspension on persons in or to whom the right of way in question is vested or belongs and such notice must specify the period of suspension;

(d)any right suspended pursuant to sub-paragraph (b) is unenforceable for the period specified in the notice served under sub-paragraph (c).

(9) Notwithstanding paragraph (1), no private rights of way over Plot 17b (as shown on the deposited plans) are extinguished in accordance with paragraph (1) until the new junction has been constructed between Cripley Road and Roger Dudman Way pursuant to the prior approval and is available for use by the public.

Time limit for exercise of powers of acquisition

13.—(1) After the end of the period of 5 years beginning with the day on which this Order comes into force—

(a)no notice to treat is to be served under Part 1 of the 1965 Act as applied to the acquisition of land by article 4 (application of Part 1 of the 1965 Act); and

(b)no declaration is to be executed under section 4 (execution of declaration) of the 1981 Act as applied by article 5 (application of the 1981 Act).

(2) The powers conferred by article 8 (temporary possession of land) cease at the end of the period referred to in paragraph (1), except that nothing in this paragraph prevents Network Rail from remaining in possession of land after the end of that period, if the land was entered and possession of it was taken before the end of that period.

PART 3MISCELLANEOUS AND GENERAL

Level crossing to be stopped up

14.—(1) Subject to the provisions of this article, the level crossing listed in column (2) of Schedule 3 (closure of level crossing) is stopped up and discontinued.

(2) Upon the stopping up and discontinuance of the level crossing referred to in paragraph (1) all rights of way (whether public or private) over that crossing are extinguished.

(3) Any person who suffers loss by reason of the extinguishment of any private right of way under this article is entitled to compensation to be determined, in the case of dispute, as if it were a dispute under Part 1 of the 1961 Act.

Use of private roads for construction

15.—(1) Network Rail may use any private road within the Order limits for the passage of persons or vehicles (with or without materials, plant and machinery) for the purposes of, or in connection with, the construction of the authorised works.

(2) Network Rail must compensate the person liable for the repair of a road to which paragraph (1) applies for any loss or damage which that person may suffer by reason of the exercise of the power conferred by paragraph (1).

(3) Any dispute as to a person’s entitlement to compensation under paragraph (2), or as to the amount of such compensation, is to be determined as if it were a dispute under Part 1 of the 1961 Act.

Power to survey and investigate land

16.—(1) Network Rail may for the purposes of this Order—

(a)survey or investigate any land shown within the Order limits or which may be affected by the authorised works;

(b)without limitation on the scope of sub-paragraph (a), make trial holes in such positions on the land as Network Rail thinks fit to investigate the nature of the surface layer and subsoil and remove soil samples;

(c)without limitation on the scope of paragraph (a), carry out ecological or archaeological investigations on such land;

(d)place on, leave on and remove from the land apparatus for use in connection with the survey and investigation of land and making of trial holes; and

(e)enter on the land for the purpose of exercising the powers conferred by sub-paragraphs (a) to (d).

(2) No land may be entered or equipment placed or left on or removed from the land under paragraph (1), unless at least 7 days’ notice has been served on every owner and occupier of the land.

(3) Notice given in accordance with paragraph (2) must include—

(a)a statement of the recipient’s rights under paragraph (14); and

(b)a copy of any warrant issued under paragraph (7).

(4) If Network Rail proposes to do any of the following, the notice must include details of what is proposed—

(a)searching, boring or excavating;

(b)leaving apparatus on the land;

(c)taking samples;

(d)an aerial survey.

(5) If Network Rail obtains a warrant after giving notice in accordance with paragraph (2) it must give a copy of the warrant to all those to whom it gave that notice.

(6) Any person entering land under this article on behalf of Network Rail—

(a)must, if so required, before or after entering the land produce written evidence of authority to do so including any warrant issued under paragraph (7);

(b)may not use force unless a justice of the peace has issued a warrant under paragraph (7) authorising the person to do so;

(c)may take onto the land such vehicles and equipment as are necessary to carry out the survey or investigation or to make the trial holes;

(d)may only enter and survey land at a reasonable time; and

(e)must, if the land is unoccupied or the occupier is absent from the land when the person enters it, leave it as secure against trespassers as when the person entered it.

(7) A justice of the peace may issue a warrant authorising a person to use force in the exercise of the power conferred by this article if satisfied—

(a)that another person has prevented or is likely to prevent the exercise of that power; and

(b)that it is reasonable to use force in the exercise of that power.

(8) The force that may be authorised by a warrant is limited to that which is reasonably necessary.

(9) A warrant authorising the person to use force must specify the number of occasions on which Network Rail can rely on the warrant when entering and surveying or investigating land.

(10) The number specified for the purposes of paragraph (9) must be the number which the justice of the peace considers appropriate to achieve the purpose for which the entry and survey or investigation are required.

(11) Any evidence in proceedings for a warrant under this article must be given on oath.

(12) No trial holes are to be made under this article—

(a)in a carriageway or footway without the consent of the highway authority; or

(b)in a private street without the consent of the street authority,

but such consent must not be unreasonably withheld.

(13) If either a highway authority or a street authority which receives an application for consent fails to notify Network Rail of its decision within 28 days of receiving the application for consent—

(a)under paragraph (12)(a) in the case of a highway authority; or

(b)under paragraph (12)(b) in the case of a street authority,

that authority is deemed to have granted consent.

(14) Network Rail must compensate the owners and occupiers of the land for any loss or damage arising by reason of the exercise of the powers conferred by this article, such compensation to be determined, in case of dispute, as if it were a dispute under Part 1 of the 1961 Act.

(15) Nothing in this article overrides the requirement to obtain scheduled monument consent under the Ancient Monuments and Archaeological Areas Act 1979(28).

Statutory undertakers, etc.

17.  Schedule 4 (provisions relating to statutory undertakers, etc.) has effect.

Certification of plans, etc.

18.  Network Rail must, as soon as practicable after the making of this Order, submit copies of the book of reference and the deposited plans to the Secretary of State for certification that they are, respectively, true copies of the book of reference and deposited plans referred to in this Order; and a document so certified is admissible in any proceedings as evidence of the contents of the document of which it is a copy.

Service of notices

19.—(1) A notice or other document required or authorised to be served for the purposes of this Order may be served—

(a)by post; or

(b)with the consent of the recipient and subject to paragraphs (6) to (8) by electronic transmission.

(2) Where the person on whom a notice or other document to be served for the purposes of this Order is a body corporate, the notice or document is duly served if it is served on the secretary or clerk of that body.

(3) For the purposes of section 7 (references to service by post) of the Interpretation Act 1978(29) as it applies for the purposes of this article, the proper address of any person in relation to the service on that person of a notice or document under paragraph (1) is, if that person has given an address for service, that address, and otherwise—

(a)in the case of the secretary or clerk of a body corporate, the registered or principal office of that body; and

(b)in any other case, the last known address of that person at the time of service.

(4) Where for the purposes of this Order a notice or other document is required or authorised to be served on a person as having any interest in, or as the occupier of, land and the name or address of that person cannot be ascertained after reasonable enquiry, the notice may be served by—

(a)addressing it to that person by name or by the description of “owner”, or as the case may be “occupier”, of the land (describing it); and

(b)either leaving it in the hands of a person who is or appears to be resident or employed on the land or leaving it conspicuously affixed to some building or object on or near the land.

(5) Where a notice or other document required to be served or sent for the purposes of this Order is served or sent by electronic transmission the requirement is taken to be fulfilled where the recipient of the notice or other document to be transmitted has given his consent to the use of electronic transmission either in writing or by electronic transmission.

(6) Where the recipient of a notice or other document served or sent by electronic transmission notifies the sender within 7 days of receipt that the recipient requires a paper copy of all or any part of that notice or other document the sender must provide such a copy as soon as reasonably practicable.

(7) Any consent to the use of electronic transmission given by a person may be revoked by that person in accordance with paragraph (8).

(8) Where a person is no longer willing to accept the use of electronic transmission for any of the purposes of this Order—

(a)that person must give notice in writing or by electronic transmission revoking any consent given by that person for that purpose; and

(b)such revocation is final and takes effect on a date specified by the person in the notice but that date must not be less than 7 days after the date on which the notice is given.

(9) This article does not exclude the employment of any method of service not expressly provided for by it.

No double recovery

20.  Compensation is not payable in respect of the same matter both under this Order and under any other enactment, any contract or any rule of law.

Arbitration

21.  Any difference under any provision of this Order, unless otherwise provided for, must be referred to and settled by a single arbitrator to be agreed between the parties or, failing agreement, to be appointed on the application of either party (after giving notice in writing to the other) by the President of the Institution of Civil Engineers.

Protective provisions

22.  Schedule 5 (protective provisions) has effect.

Disapplication of legislative provisions

23.  The provisions of the Neighbourhood Planning Act 2017(30) are dis-applied insofar as they related to the temporary occupation of land under article 8 (temporary possession of land).

Signed by authority of the Secretary of State for Transport

Natasha Kopala

Head of the Transport and Works Act Orders Unit

Department for Transport

12th July 2022

SCHEDULES

Article 6

SCHEDULE 1MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS

Compensation enactments

1.  The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply with the necessary modifications as respects compensation in the case of a compulsory acquisition under this Order of a right by the creation of a new right as they apply as respects compensation for the compulsory purchase of land and interests in land.

2.—(1) Without limitation on the scope of paragraph 1, the 1961 Act has effect subject to the modifications set out in sub-paragraph (2).

(2) For section 5A(5A) (relevant valuation date) of the 1961 Act substitute—

(5A) If—

(a)the acquiring authority enters on land for the purposes of exercising a right in pursuance of a notice of entry under section 11(1) of the 1965 Act (as modified by paragraph 5(5) of Schedule 1 to the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022 (“the 2022 Order”));

(b)the acquiring authority is subsequently required by a determination under paragraph 12 of Schedule 2A to the 1965 Act (as substituted by paragraph 5(8) of Schedule 1 to the 2022 Order) to acquire an interest in the land; and

(c)the acquiring authority enters on and takes possession of that land,

the authority is deemed for the purposes of subsection (3)(a) to have entered on that land when it entered on that land for the purpose of exercising that right..

3.—(1) Without limitation on the scope of paragraph 1, the Land Compensation Act 1973(31) has effect subject to the modifications set out in sub-paragraph (2).

(2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 (measure of compensation in case of severance) of the 1965 Act as substituted by paragraph 5(3)—

(a)for “land is acquired or taken” substitute “a right over land is purchased”; and

(b)for “acquired or taken from him” substitute “over which the right is exercisable”.

Application of Part 1 of the 1965 Act

4.  Part 1 of the 1965 Act, as applied by article 4 (application of Part 1 of the 1965 Act) to the acquisition of land under article 3(1) (power to acquire land) applies to the compulsory acquisition of rights under article 6(1) (power to acquire new rights)—

(a)with the modifications specified in paragraph 5; and

(b)with such other modifications as may be necessary.

5.—(1) The modifications referred to in paragraph 4(a) are as follows.

(2) References in the 1965 Act to land are, in the appropriate contexts, to be read (according to the requirements of the particular context) as referring to, or as including references to—

(a)the right acquired or to be acquired; or

(b)the land over which the right is or is to be exercisable.

(3) For section 7 (measure of compensation in the case of severance) of the 1965 Act substitute—

7.  In assessing the compensation to be paid by the acquiring authority under this Act regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired is depreciated by the acquisition of the right but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.

(4) The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

(a)section 9(4) (failure by owners to convey);

(b)paragraph 10(3) of Schedule 1 (owners under incapacity);

(c)paragraph 2(3) of Schedule 2 (absent and untraced owners); and

(d)paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are modified so as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired is vested absolutely in the acquiring authority.

(5) Section 11(32) (powers of entry) of the 1965 Act is modified so as to secure that, where the acquiring authority has served notice to treat in respect of any right, as well as the notice of entry required by subsection (1) of that section (as it applies to a compulsory acquisition under article 3(1)), it has power, exercisable in the equivalent circumstances and subject to the equivalent conditions, to enter for the purpose of exercising that right; and sections 11A(33) (powers of entry: further notices of entry), 11B(34) (counter-notice requiring possession to be taken on specified date), 12(35) (unauthorised entry) and 13(36)(refusal to give possession to acquiring authority) of the 1965 Act are modified correspondingly.

(6) Section 20(37) (tenants at will, etc.) of the 1965 Act applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition of the land under this Order, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right in question.

(7) Section 22 (interests omitted from purchase) of the 1965 Act (as modified by article 4(7)) is modified so as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired, subject to compliance with that section as respects compensation.

(8) For Schedule 2A to the 1965 Act substitute—

SCHEDULE 2ACOUNTER-NOTICE REQUIRING PURCHASE OF LAND NOT IN NOTICE TO TREAT

Introduction

1.(1) This Schedule applies where an acquiring authority serves a notice to treat in respect of a right over the whole or part of a house, building or factory.

(2) But see article 7 (power to acquire subsoil or airspace only) of the Network Rail (Oxford Station Phase 2 Improvements (Land Only)) Order 2022 which excludes the acquisition of subsoil or airspace only from this Schedule.

2.  In this Schedule “house” includes any park or garden belonging to a house.

Counter-notice requiring purchase of land

3.  A person who is able to sell the house, building or factory (“the owner”) may serve a counter-notice requiring the authority to purchase the owner’s interest in the house, building or factory.

4.  A counter-notice under paragraph 3 must be served within the period of 28 days beginning with the day on which the notice to treat was served.

Response to counter-notice

5.  On receiving a counter-notice, the authority must decide whether to—

(a)withdraw the notice to treat,

(b)accept the counter-notice, or

(c)refer the counter-notice to the Upper Tribunal.

6.  The authority must serve notice of its decision on the owner within the period of 3 months beginning with the day on which the counter-notice is served (“the decision period”).

7.  If the authority decides to refer the counter-notice to the Upper Tribunal it must do so within the decision period.

8.  If the authority does not serve notice of a decision within the decision period it is to be treated as if it had served notice of a decision to withdraw the notice to treat at the end of that period.

9.  If the authority serve notice of a decision to accept the counter-notice, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in the house, building or factory.

Determination by Upper Tribunal

10.  On a referral under paragraph 7, the Upper Tribunal must determine whether the acquisition of the right would—

(a)in the case of a house, building or factory, cause material detriment to the house, building or factory, or

(b)in the case of a park or garden, seriously affect the amenity or convenience of the house to which the park or garden belongs.

11.  In making its determination, the Upper Tribunal must take into account—

(a)the effect of the acquisition of the right,

(b)the proposed use of the right to be acquired, and

(c)if the right is proposed to be acquired for works or other purposes extending to other land, the effect of the whole of the works and the use of the other land.

12.  If the Upper Tribunal determines that the acquisition of the right would have either of the consequences described in paragraph 10, it must determine how much of the house, building or factory the acquiring authority ought to be required to take.

13.  If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in that land.

14.(1) If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the authority may at any time within the period of 6 weeks beginning with the day on which the Upper Tribunal makes its determination withdraw the notice to treat in relation to that land.

(2) If the acquiring authority withdraws the notice to treat under this paragraph it must pay the person on whom the notice was served compensation for any loss or expense caused by the giving and withdrawal of the notice.

(3) Any dispute as to the compensation is to be determined by the Upper Tribunal..

Article 8

SCHEDULE 2LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN

(1)

Area

(2)

Number of land shown on the deposited plans

(3)

Purpose for which temporary possession may be taken

County of Oxfordshire1, 2, 3, 4, 4a, 5, 6, 6a, 7a, 17a

Temporary access right for

Network Rail and its licensees to pass and re-pass

2Strengthening or improvement works for existing Castle Mill Stream Bridge, or removal to put in place temporary bridge structure and re-instatement of Castle Mill Stream Bridge, together with ancillary works
3, 4, 6a, 7a, 17aAccess, construction works to improve road and work site
14, 15Access, construction works, work site and temporary rights to moor and/or anchor vessels and construction platforms
17bAccess and construction works to improve road and work site
17c, 32, 34, 36Access, construction works and works site
37, 38Access, construction works, works site and works compound
40Access, construction works, works site and provision of temporary nursery relocation facility

Article 14

SCHEDULE 3CLOSURE OF LEVEL CROSSING

(1)

Area

(2)

Level crossing to be discontinued

County of OxfordshireDisused crossing known as Oxford Station Emergency level crossing over Botley Road and associated rights comprised in Plot 34

Articles 12 and 17

SCHEDULE 4PROVISIONS RELATING TO STATUTORY UNDERTAKERS, ETC.

1.  Sections 271 to 274(38) (extinguishment of rights of statutory undertakers, etc. and power of statutory undertakers etc. to remove or re-site apparatus) of the 1990 Act apply in relation to any land acquired or appropriated by Network Rail under this Order subject to the following provisions of this Schedule; and all such other provisions of that Act as apply for the purposes of those provisions (including sections 275 to 278, which contain provisions consequential on the extinguishment of any rights under sections 271 and 272, and sections 279(2) to (4), 280 and 282(39), which provide for the payment of compensation) have effect accordingly.

2.  In the provisions of the 1990 Act, as applied by paragraph (1)—

(a)references to the appropriate Minister are references to the Secretary of State; and

(b)references to land acquired or appropriated as mentioned in section 271(1) of the 1990 Act are references to land acquired or appropriated as mentioned in paragraph (1).

3.  Where any apparatus of public utility undertakers or of a public communications provider is removed in pursuance of a notice or order given or made under section 271, 272 or 273 of the 1990 Act, as applied by paragraph (1), any person who is the owner or occupier of premises to which a supply was given from that apparatus is entitled to recover from Network Rail compensation in respect of expenditure reasonably incurred by that person, in consequence of the removal, for the purpose of effecting a connection between the premises and any other apparatus from which a supply is given.

4.  Paragraph (3) does not apply in the case of the removal of a public sewer but where such a sewer is removed in pursuance of such a notice or order as is mentioned in that paragraph, any person who is—

(a)the owner or occupier of premises the drains of which communicated with that sewer; or

(b)the owner of a private sewer which communicated with that sewer,

is entitled to recover from Network Rail compensation in respect of expenditure reasonably incurred by that person, in consequence of the removal, for the purpose of making the drain or sewer communicate with any other public sewer or with a private sewage disposal plant.

5.  The provisions of the 1990 Act mentioned in paragraph (1), as applied by that paragraph, do not have effect in relation to apparatus in respect of which Part 3 of the 1991 Act applies.

6.  In this Schedule—

public communications provider” has the same meaning as in section 151(1) of the 2003 Act; and

public utility undertakers” has the same meaning as in the 1980 Act.

Article 22

SCHEDULE 5PROTECTIVE PROVISIONS

PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

Application

1.  For the protection of the undertakers referred to in this Part of this Schedule the following provisions have effect unless otherwise agreed in writing between Network Rail and the undertaker concerned.

2.  The provisions of Schedule 4 (provisions relating to statutory undertakers, etc.), in so far as they relate to the removal of apparatus, do not apply in relation to apparatus to which this Part of this Schedule applies.

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between Network Rail and the undertaker are regulated by the provisions of Part 3 of the 1991 Act.

Interpretation

4.  In this Part of this Schedule—

alternative apparatus” means alternative apparatus adequate to enable the undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989(40)) belonging to or maintained by that undertaker;

(b)

in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 1986(41) for the purposes of gas supply;

(c)

in the case of a water undertaker, any mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the undertaker under the Water Industry Act 1991(42); and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4)(43) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104(44) (agreement to adopt sewers, drains or sewage disposal works at future date) of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

undertaker” means—

(e)

any licence holder within the meaning of Part 1 of the Electricity Act 1989;

(f)

a gas transporter within the meaning of Part 1 of the Gas Act 1986;

(g)

a water undertaker within the meaning of the Water Industry Act 1991; and

(h)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised works, and in relation to any apparatus, means the undertaker to whom it belongs or by whom it is maintained.

Acquisition of apparatus

5.  Regardless of any provision in this Order or anything shown on the deposited plans, Network Rail must not acquire any apparatus otherwise than by agreement.

Alternative apparatus

6.—(1) If, in the exercise of the powers conferred by this Order, Network Rail acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of an undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the undertaker in question.

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, Network Rail requires the removal of any apparatus placed in that land, it must give to the undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed.

(3) Any alternative apparatus to be constructed in land of Network Rail under this Part of this Schedule is to be constructed in such manner and in such line or situation as may be agreed between the undertaker in question and Network Rail, or in default of such agreement settled by arbitration in accordance with article 21 (arbitration).

(4) In any case where alternative apparatus is to be provided or constructed under sub-paragraph (2), or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus, Network Rail must, subject to sub-paragraph (5), afford to the undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of Network Rail and subsequently for the maintenance of that apparatus.

(5) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of Network Rail, or Network Rail is unable to afford such facilities and rights as are mentioned in sub-paragraph (4) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker in question must, on receipt of a written notice to that effect from Network Rail, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(6) The undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 21 (arbitration), and after the grant to the undertaker of any such facilities and rights as are referred to in sub-paragraph (4) or (5), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by Network Rail to be removed under the provisions of this Part of this Schedule.

(7) Regardless of anything in sub-paragraph (6), if Network Rail gives notice in writing to the undertaker in question that it desires itself to execute any work to which this paragraph applies, that work, instead of being executed by the undertaker, must be executed by Network Rail without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the undertaker.

(8) Nothing in sub-paragraph (7) authorises Network Rail to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Facilities and rights for alternative apparatus

7.—(1) Where, in accordance with the provisions of this Part of this Schedule, Network Rail affords to an undertaker facilities and rights for the construction and maintenance in land of Network Rail of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between Network Rail and the undertaker in question or in default of agreement settled by arbitration in accordance with article 21 (arbitration).

(2) In settling those terms and conditions in respect of alternative apparatus to be constructed in or along any railway of Network Rail, the arbitrator must—

(a)give effect to all reasonable requirements of Network Rail for ensuring the safety and efficient operation of the railway and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of Network Rail or the traffic on the railway; and

(b)so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the railway for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by Network Rail in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by Network Rail to that undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Existing apparatus: protection and access

8.—(1) Not less than 28 days before starting the execution of any of the authorised works that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 6(2), Network Rail must submit to the undertaker in question a plan, section and description of the works to be executed.

(2) Those works are to be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and an officer of the undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by an undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If an undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by Network Rail, reasonably requires the removal of any apparatus and gives written notice to Network Rail of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by Network Rail under paragraph 6(2).

(5) Nothing in this paragraph precludes Network Rail from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) Network Rail is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Expenses

9.—(1) Subject to the following provisions of this paragraph, Network Rail must repay to an undertaker the reasonable expenses incurred by that undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any of such works as are referred to in paragraph 6(2).

(2) The value of any apparatus removed under the provisions of this Part of this Schedule (other than apparatus that is re-used as alternative apparatus) is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by Network Rail or, in default of agreement, is not determined by arbitration in accordance with article 21 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to an undertaker in respect of works under sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

(6) Any dispute as to whether a financial benefit is conferred in accordance with sub-paragraph (5) or as to the amount of such financial benefit which cannot be agreed is to be determined in accordance with article 21 (arbitration).

Damage to apparatus: costs, losses, etc.

10.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the authorised works any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of an undertaker or there is any interruption in any service provided or in the supply of any goods by any undertaker, Network Rail must—

(a)bear and pay the cost reasonably incurred by that undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an undertaker, its officers, servants, contractors or agents.

(3) An undertaker must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Enactments and agreements

11.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and an undertaker in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

1.—(1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between Network Rail and the operator.

(2) In this Part of this Schedule—

electronic communications apparatus” has the same meaning as in the electronic communications code;

the electronic communications code” has the same meaning as in Chapter 1 (electronic communications, networks and services) of Part 2 of the 2003 Act(45);

electronic communications code network” means—

(a)

so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network which the Secretary of State is providing or proposing to provide;

electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 (application of electronic communications code) of the 2003 Act;

infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7(2) of that code; and

operator” means the operator of an electronic communications code network.

2.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised works or their construction, or of any subsidence resulting from any of those works—

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator,

Network Rail must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and must—

(i)make reasonable compensation to that operator for loss sustained by it; and

(ii)indemnify that operator against claims, demands, proceedings, costs, damages and expenses which may be made or taken against, or recovered from, or incurred by, that operator by reason, or in consequence, of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand may be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between Network Rail and the operator under this paragraph is to be referred to and settled by arbitration under article 21 (arbitration).

3.  This Part of this Schedule does not apply to—

(a)any apparatus in respect of which the relations between Network Rail and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised works.

4.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and an operator in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

PART 3FOR THE PROTECTION OF SOUTHERN GAS NETWORKS PLC AS GAS UNDERTAKER

Application

1.  For the protection of SGN the following provisions will have effect unless otherwise agreed in writing between the undertaker and SGN.

Interpretation

2.  In this Part of this Schedule—

1991 Act” means the New Roads and Street Works Act 1991;

alternative apparatus” means appropriate alternative apparatus to the satisfaction of SGN to enable SGN to fulfil its statutory functions in a manner no less efficient than that enabled by its existing apparatus;

apparatus” means any gas mains, pipes, pressure governors, ventilators, cathodic protections, cables or other apparatus belonging to or maintained by SGN for the purposes of gas distribution together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of SGN for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

“authorised works” has the same meaning in article 2 (interpretation) of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Part of this Schedule;

commence” means beginning to carry out any material operation (as defined in section 56(4) of the 1990 Act) forming part of the authorised works

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by SGN (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for managing a ground subsidence event;

ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, requires the undertaker to submit for SGN’s approval a ground mitigation scheme;

ground subsidence event” means any ground subsidence identified by the monitoring activities carried out pursuant to the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme and is identified in that scheme as requiring a ground mitigation scheme;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” includes the ability and right to do any of the following in relation to any apparatus or alternative apparatus of SGN including retain, lay, construct, inspect, maintain, protect, use, access, enlarge, replace, renew, remove, decommission or render unusable or remove the apparatus;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary to describe and assess the works to be executed;

rights” includes rights and restrictive covenants, and in relation to decommissioned apparatus the surrender of rights, release of liabilities and transfer of decommissioned apparatus;

SGN” means Southern Gas Networks plc or its successors in title or successor bodies and/or any successor as a gas transporter within the meaning of Part 1 (gas supply) of the Gas Act 1986.

specified works” means any of the authorised works or activities undertaken in association with the authorised works which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under sub-paragraph 7(2) or otherwise; and/or

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under sub-paragraph 6(2) or otherwise;

undertaker” means Network Rail as defined in article 2 (interpretation) of this Order.

On Street Apparatus

3.—(1) Except for paragraphs 5 (removal of apparatus) in so far as sub-paragraph 3(2) applies, 6 (facilities and rights for alternative apparatus) in so far as sub-paragraph 3(2) below applies, 7 (retained apparatus: protection), 8 (expenses) and 9 (indemnity) of this Part of this Schedule which apply in respect of the exercise of all or any powers under this Order affecting the rights and apparatus of SGN, the other provisions of this Part of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and SGN are regulated by the provisions of Part 3 of the 1991 Act.

(2) Paragraph 5 and 6 of this Part of this Schedule apply to diversions even where carried out under the 1991 Act, in circumstances where any apparatus is diverted from an alignment within the existing adopted public highway but not wholly replaced within the existing adopted public highway.

(3) The Protective Provisions in this Part of this Schedule apply and take precedence over Parts 1 and 2 of Schedule 5 to this Order which do not apply to SGN.

Acquisition of land

4.—(1) Regardless of any provision in this Order or anything shown on the deposited plans or contained in the book of reference, the undertaker may not appropriate or acquire any land interest or appropriate, acquire, extinguish, interfere with or override any easement, other interest or right and/or apparatus of SGN otherwise than by agreement.

(2) As a condition of agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between SGN and the undertaker) that are subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement and/or other legal or land interest of SGN and/or affects the provisions of any enactment or agreement regulating the relations between SGN and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as SGN reasonably requires enter into such deeds of consent and variations upon such terms and conditions as may be agreed between SGN and the undertaker acting reasonably and which must be no less favourable on the whole to SGN than the pre-agreement position unless otherwise agreed by SGN, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

(3) The undertaker and SGN agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus/including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by SGN and/or other enactments relied upon by SGN as of right or other use in relation to the apparatus, then the provisions in this Schedule shall prevail.

(4) Any agreement or consent granted by SGN under paragraph 8 or any other paragraph of this Part of this Schedule, is not to be taken to constitute agreement under sub-paragraph (1).

(5) As a condition of an agreement between the parties in sub-paragraph (1) that involves decommissioned apparatus being left in situ the undertaker must unless otherwise agreed accept a surrender of any existing easement and/or other interest of SGN in such decommissioned apparatus and consequently acquire title to such decommissioned apparatus and release SGN from all liabilities in respect of such decommissioned apparatus from the date of such surrender.

(6) Where an undertaker acquires land which is subject to any SGN right or interest (including, without limitation, easements and agreements relating to rights or other interests) and the provisions of paragraph 6 do not apply, the undertaker must—

(a)retain any notice of SGN’s easement, right or other interest on the title to the relevant land when registering the undertaker’s title to such acquired land; and

(b)(where no such notice of SGN’s easement, right or other interest on the title exists in relation to such acquired land or any such notice is registered only on the Land Charges Register) include (with its application to register title to the undertaker’s interest in such acquired land at the Land Registry) a notice of SGN’s easement, right or other interest in relation to such acquired land and SGN must provide reasonable assistance to the undertaker to assist that registration; and

(c)provide up to date official entry copies to SGN within 20 working days of receipt of such up to date official entry copies.

Removal of apparatus

5.—(1) If, in the exercise of the agreement reached in accordance with paragraph 4 or in any other authorised manner, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be decommissioned or removed under this Part of this Schedule and any right of SGN to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, is in operation, and the rights and facilities referred to in sub-paragraph (2) have been provided, to the reasonable satisfaction of SGN and in accordance with sub-paragraph (2) to (5) inclusive.

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to SGN advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order SGN reasonably needs to move or remove any of its apparatus) the undertaker must afford to SGN to its satisfaction (taking into account paragraph 6(1)) the necessary facilities and rights—

(a)for the construction of alternative apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by SGN in respect of the apparatus);

(b)subsequently for the maintenance of that apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by SGN in respect of the apparatus); and

(c)to allow access to that apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by SGN in respect of the apparatus).

(3) If the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, SGN may, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to assist the undertaker in obtaining the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for SGN to use its compulsory purchase powers to this end unless it (in its absolute discretion) elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between SGN and the undertaker.

(5) SGN must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the prior grant to SGN of such facilities and rights as are referred to in sub-paragraph (2) or (3) have been afforded to SGN to its satisfaction, then proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to decommission or remove any apparatus required by the undertaker to be decommissioned or removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

6.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for SGN facilities and rights in land for the access to, construction and maintenance alternative apparatus in substitution for apparatus to be decommissioned or removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and SGN and must be no less favourable on the whole to SGN than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed unless otherwise agreed by SGN.

(2) If the facilities and rights to be afforded by the undertaker and agreed with SGN under sub-paragraph (1) in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to SGN than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed (in SGN’s reasonable opinion) then the terms and conditions to which those facilities and rights are subject in the matter will be referred to arbitration in accordance with paragraph 13 (arbitration) of this Part of this Schedule and the arbitrator is to make such provision for the payment of compensation by the undertaker to SGN as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection of SGN

7.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to SGN a plan and, if reasonably required by SGN, a ground monitoring scheme in respect of those works.

(2) The plan to be submitted to SGN under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant etc.;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and

(f)any intended maintenance regimes.

(3) the undertaker must not commence any works to which sub-paragraphs (1) and (2) apply until SGN has given written approval of the plan so submitted.

(4) Any approval of SGN required under sub-paragraph (3)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (5) or (7); and

(b)must not be unreasonably withheld.

(5) In relation to any work to which sub-paragraphs (1) and/or (2) apply, SGN may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Works to which this paragraph applies must only be executed in accordance with the plan, submitted under sub-paragraphs (1) and (2) or as relevant sub-paragraph (4), as approved or as amended from time to time by agreement between the undertaker and SGN and in accordance with all conditions imposed under sub-paragraph (4)(a), and SGN will be entitled to watch and inspect the execution of those works having given reasonable notice of their wish to do so.

(7) Where SGN requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to SGN’s satisfaction prior to the commencement of any authorised works (or any relevant part thereof) for which protective works are required prior to commencement.

(8) If SGN, in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 5 to 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the authorised works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(10) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to SGN notice as soon as is reasonably practicable and a plan of those works and must comply with—

(a)the conditions imposed under sub-paragraph (4)(a) insofar as is reasonably practicable in the circumstances (where any such applicable conditions have been imposed at that time); and

(b)sub-paragraph (11) at a times.

(11) As soon as reasonably practicable after any ground subsidence event attributable to the authorised works the undertaker must implement an appropriate ground mitigation scheme save that SGN retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 8 (expenses).

Expenses

8.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to SGN on demand all charges, costs and expenses reasonably anticipated or incurred by SGN in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or rights or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works as are referred to in this Part of this Schedule including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by SGN in connection with the negotiation or acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs (including professional fees) incurred by SGN as a consequence of SGN—

(i)using its own compulsory purchase powers to acquire any necessary rights under sub-paragraph 5(3) if it elects to do so; and/or

(ii)exercising any compulsory purchase powers in the Order transferred to or benefitting SGN;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule; and

(g)any watching brief pursuant to sub-paragraph 7(6).

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 21 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to SGN by virtue of sub-paragraph (1) will be reduced by the amount of that excess save where it is not possible or appropriate in the circumstances (including due to statutory or regulatory changes) to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

Indemnity

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule (including without limitation relocation, diversion, decommissioning, construction and maintenance of apparatus or alternative apparatus) or in consequence of the construction, use, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of SGN, or there is any interruption in any service provided, or in the supply of any goods, by SGN, or SGN becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand the cost reasonably incurred by SGN in making good such damage or restoring the supply; and

(b)indemnify SGN for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from SGN, by reason or in consequence of any such damage or interruption or SGN becoming liable to any third party as aforesaid other than arising from any default of SGN.

(2) The fact that any act or thing may have been done by SGN on behalf of the undertaker or in accordance with a plan approved by SGN (save where that plan has been negligently approved by SGN) or in accordance with any requirement of SGN or under its supervision including under any watching brief will not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of sub-paragraph (1) unless SGN fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraphs (1) or (2) imposes any liability on the undertaker in respect of any damage or interruption to the extent that it is attributable to the neglect or default of SGN, its officers, servants, contractors or agents.

(4) SGN must give the undertaker reasonable notice of any such third party claim or demand and no settlement or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

Enactments and agreements

10.  Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between SGN and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and SGN in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

11.—(1) Where in consequence of the proposed construction of any of the authorised works, the undertaker or SGN requires the removal of apparatus under paragraph 5(2) or SGN makes requirements for the protection or alteration of apparatus under paragraph 7, the undertaker shall use its best endeavours to co-ordinate the execution of the authorised works efficiently and in the interests of safety and taking into account the need to ensure the safe and efficient operation of SGN’s undertaking and SGN shall use its best endeavours to co-operate with the undertaker for that purpose.

(2) Whenever SGN’s consent, agreement or approval is required in relation to plans, documents or other information submitted by SGN or the taking of action by SGN, it must not be unreasonably withheld or delayed.

Access

12.  If in consequence of the agreement reached in accordance with sub-paragraph 4(1) or the powers granted under this Order the access to any apparatus (including appropriate working areas required to reasonably and safely undertake necessary works by SGN in respect of the apparatus) is materially obstructed, the undertaker must provide such alternative rights and means of access to such apparatus as will enable SGN to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

13.  Any difference or dispute arising between the undertaker and SGN under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and SGN, be determined by arbitration in accordance with article 21 (arbitration).

Notices

14.  The plans submitted to SGN by the undertaker pursuant to paragraph 7(1) must be sent to SGN at easements@sgn.co.uk or such other address as SGN may from time to time appoint instead for that purpose and notify to the undertaker.

PART 4THAMES WATER PROTECTIVE PROVISIONS

Application

1.  For the protection of the undertaker referred to in this Part of this Schedule the following provisions have effect unless otherwise agreed in writing between Network Rail and the undertaker.

2.  This Part of this Schedule does not apply to apparatus in respect of which the relations between Network Rail and the undertaker are regulated by the provisions of Part 3 of the 1991 Act.

3.  This Part of this Schedule includes all protective provisions between Network Rail and the undertaker and Schedule 5 has no effect on the obligations between Network Rail and the undertaker.

Interpretation

4.  In this Part of this Schedule—

alternative apparatus” means alternative apparatus adequate to enable the undertaker to fulfil its statutory functions in a manner no less efficient and effective than previously;

apparatus” means—

(a)

in the case of a water undertaker—

(i)

mains, pipes or other apparatus or accessories (as defined in section 219(1) (general interpretation) of the Water Industry Act 1991(46)) belonging to or maintained by the undertaker for the purposes of water supply; and

(ii)

any water mains or service pipes which are the subject of a notice of intention to adopt under section 51A(47) (adoption of water mains and service pipes) of the Water Industry Act 1991;

(b)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the undertaker under the Water Industry Act 1991); and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 (agreements to adopt sewer, drain or sewage disposal works, at future date) of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

undertaker” means Thames Water Utilities Limited.

Acquisition of apparatus

5.  Regardless of any provision in this Order or anything shown on the deposited plans, Network Rail must not acquire any apparatus otherwise than by agreement.

Alternative apparatus

6.—(1) If, in the exercise of the powers conferred by this Order, Network Rail acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of the undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the undertaker in accordance with sub-paragraphs (2) to (8).

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, Network Rail requires the removal of any apparatus placed in that land, it must give to the undertaker written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed.

(3) Any alternative apparatus to be constructed in land of Network Rail under this Part of this Schedule is to be constructed in such manner and in such line or situation as may be agreed between the undertaker and Network Rail, or in default of such agreement settled by arbitration in accordance with article 21 (arbitration).

(4) In any case where alternative apparatus is to be provided or constructed under sub-paragraph (2), or if in consequence of the exercise of any of the powers conferred by this Order the undertaker reasonably needs to remove any of its apparatus, Network Rail must, subject to sub-paragraph (5), afford to the undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of Network Rail and subsequently for the maintenance of that apparatus.

(5) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of Network Rail, or Network Rail is unable to afford such facilities and rights as are mentioned in sub-paragraph (4), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the undertaker must, on receipt of a written notice to that effect from Network Rail, as soon as reasonably possible use its reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(6) The undertaker must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 21 (arbitration), and after the grant to the undertaker of any such facilities and rights as are referred to in sub-paragraph (4) or (5), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by Network Rail to be removed under the provisions of this Schedule.

(7) Regardless of anything in sub-paragraph (7), if Network Rail gives notice in writing to the undertaker that it desires itself to execute any work to which this paragraph applies, that work, instead of being executed by the undertaker, must be executed by Network Rail without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the undertaker.

(8) Nothing in sub-paragraph (6) authorises Network Rail to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 600 millimetres of the apparatus.

7.—(1) Where, in accordance with the provisions of this Schedule, Network Rail affords to the undertaker facilities and rights for the construction and maintenance in land of Network Rail of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between Network Rail and the undertaker or in default of agreement settled by arbitration in accordance with article 21 (arbitration).

(2) In settling those terms and conditions in respect of alternative apparatus to be constructed in or along any railway of Network Rail, the arbitrator must—

(a)give effect to all reasonable requirements of Network Rail for ensuring the safety and efficient operation of the railway and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of Network Rail or the traffic on the railway; and

(b)so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the railway for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by Network Rail in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the undertaker than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by Network Rail to the undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Existing apparatus: protection and access

8.—(1) In connection with the execution of any of the authorised works that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 6(2) Network Rail must 2 months prior to any notice required under paragraph 8(2) consult with the undertaker on its plans and works to be executed and use reasonable endeavours to incorporate any comments from the undertaker.

(2) Not less than 35 days before starting the execution of any of the authorised works that are near to, or will or may affect, any apparatus the removal of which has not been required by Network Rail under paragraph 6(2), Network Rail must submit to the undertaker a plan, section and description of the works to be executed.

(3) Those works are to be executed only in accordance with the plan, section and description submitted under sub-paragraph (2) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (4) by the undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and an officer of the undertaker is entitled to watch and inspect the execution of those works.

(4) Any requirements made by the undertaker under sub-paragraph (3) must be made within a period of 30 days beginning with the date on which a plan, section and description under sub-paragraph (2) are submitted to it.

(5) If the undertaker in accordance with sub-paragraph (4) and in consequence of the works proposed by Network Rail, reasonably requires the removal of any apparatus and gives written notice to Network Rail of that requirement, paragraphs 1 to 8 apply as if the removal of the apparatus had been required by Network Rail under paragraph 6(2).

(6) Nothing in this paragraph precludes Network Rail from submitting at any time or from time to time, but in no case less than 35 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(7) Network Rail is not required to comply with sub-paragraphs (1) and (2) in a case of emergency but in that case it must give to the undertaker notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.

Expenses

9.—(1) Subject to the following provisions of this paragraph, Network Rail will indemnify the undertaker in respect of all reasonable costs, charges and expenses incurred by that undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus (and in considering whether these are required) or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of rights or interests in land for that purpose) which may be required in consequence of the execution of any of such works as are referred to in paragraph 6(2).

(2) The value of any apparatus removed under the provisions of this Part of this Schedule (other than apparatus that is re-used as alternative apparatus) is to be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

(3) If in accordance with the provisions of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by Network Rail or, in default of agreement, is not determined by arbitration in accordance with article 21 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker by virtue of sub-paragraph (1) is to be reduced by the amount of that excess provided always that no deduction is to be applied should the new apparatus or its specific placement be required in order to comply with current design standards.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to the undertaker in respect of works under sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

(6) Any dispute as to whether a financial benefit is conferred in accordance with sub-paragraph (5) or as to the amount of such financial benefit which cannot be agreed is to be determined in accordance with article 21 (arbitration).

Damage to apparatus: costs, losses, etc.

10.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of any of the authorised works or in consequence of the construction, use, maintenance or failure of any of the authorised works or in consequence of any act or default of the Network Rail (or any person employed or authorised by him) in the course of carrying out such works or any subsidence resulting from any of the authorised works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or damage to the property of the undertaker, or there is any interruption in any service provided, or in the supply of any goods, by the undertaker, or the undertaker becomes liable to a third party for any expense, loss, demand, proceeding, damage, interruption, claim, penalty, cost, action or liability to the extent that is attributable to the act, neglect or default of Network Rail, its officers, contractors or agents, Network Rail must—

(a)indemnify the reasonable cost incurred by the undertaker in making good such damage or restoring the supply; and

(b)indemnify the undertaker for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from the undertaker, by reason or in consequence of any such damage or interruption or the undertaker becoming liable to any third party.

(2) Nothing in sub-paragraph (1) imposes any liability on Network Rail with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of the undertaker, its officers, servants, contractors or agents.

(3) The undertaker must give Network Rail reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of Network Rail which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Enactments and agreements

11.  Nothing in this Schedule affects the provisions of any enactment or agreement regulating the relations between Network Rail and the undertaker in respect of any apparatus laid or erected in land belonging to Network Rail on the date on which this Order is made.

EXPLANATORY NOTE

(This note is not part of the Order)

This Order confers powers on Network Rail Infrastructure Limited (Network Rail) to acquire compulsorily land and extinguish rights in land required in connection with improvement works to Oxford Station authorised by a prior approval pursuant to Part 18 of the Town and Country Planning (General Permitted Development) (England) Order 2015 from Oxford City Council in the County of Oxfordshire. The Order also confers powers of temporary use of land in connection with that development.

A copy of the deposited plans and the book of reference referred to in this Order may be inspected, on request, at the offices of Network Rail Infrastructure Limited at Network Rail National Records Centre, Unit 5, Audax Road, Clifton Moor, York, YO30 4US.

(2)

1992 c. 42. Section 1 was amended by paragraphs 51 and 52 of Schedule 2 to the Planning Act 2008 (c. 29). Section 5 was amended by S.I. 2012/1659.

(11)

Section 32(1) was amended by S.I. 2011/1210.

(12)

1981. c. 67. The definition of “owner” was amended by paragraph 9 of Schedule 15 of the Planning and Compensation Act 1991 (c. 34). There are other amendments to section 7 which are not relevant to this Order.

(14)

Section 4A was inserted by section 202(1) of Housing and Planning Act 2016 (c. 22).

(15)

Subsection (1B) of section 11 was inserted by section 186(1) and (2)(b) of the Housing and Planning Act 2016.

(16)

Section 11A was inserted by section 186(3) of the Housing and Planning Act 2016.

(17)

Schedule 2A was inserted by section 199(1) of, and paragraphs 1 and 3 of Schedule 17 to, the Housing and Planning Act 2016.

(18)

Section 5A was inserted by section 182(2) of the Housing and Planning Act 2016.

(19)

Section 5B was inserted by section 202(2) of the Housing and Planning Act 2016.

(20)

Section 6 was amended by paragraph 52(2) of Schedule 2 to the Planning (Consequential Provisions) Act 1990 (c. 11) and paragraph 7 of Schedule 15 to the Housing and Planning Act 2016.

(21)

Section 7 was amended by paragraph 3 of Schedule 18 to the Housing and Planning Act 2016.

(22)

Schedule A1 was inserted by paragraph 6 of Schedule 18 to the Housing and Planning Act 2016.

(23)

Section 11 was amended by section 34(1) of, and paragraph 14(3) of Schedule 4 to, the Acquisition of Land Act 1981 (c. 67), section 3 of, and Part 1 of Schedule 1 to the Housing (Consequential Provisions) act 1985 (c. 71), section 14 of, and paragraph 12(1) of Schedule 5 to, the Church of England (Miscellaneous Provisions) Measure 2006 (No. 1), sections 186(2), 187(2) and 188 of, and paragraph 6 of Schedule 14 and paragraph 3 of Schedule 16 to, the Housing and Planning Act 2016 and S.I. 2009/1307.

(24)

Section 4 was amended by section 184 and 185 of, and paragraph 1 and 2 of Schedule 18 to, the Housing and Planning Act 2016.

(25)

Section 10 was amended by section 4 of, and paragraph 13(2) of Schedule 2 to, the Planning (Consequential Provisions) Act 1990 (c. 11) and S.I. 2009/1307.

(26)

Section 13 was amended by sections 62(3) and 139 of, and paragraphs 27 and 28 of Schedule 13, and Part 3 of Schedule 23 to, the Tribunals, Courts and Enforcement Act 2007 (c. 15).

(27)

Section 272 was amended by paragraph 103(1 and (2) pf Schedule 17 to the Communications Act 2003 (c. 21).

(32)

Section 11 was amended by section 34(1) of, and paragraph 14(3) of Schedule 4 to, the Acquisition of Land Act 1981 (c. 67), section 3 of, and Part 1 of Schedule 1 to, the Housing (Consequential Provisions) Act 1985 (c. 71), section 14 of, and paragraph 12(1) of Schedule 5 to, the Church of England (Miscellaneous Provisions) Measure 2006 (No. 1), sections 186(2), 187(2) and 188 of, and paragraph 6 of Schedule 14 and paragraph 3 of Schedule 6 to, the Housing and Planning Act 2016 (c. 22) and S.I. 2009/1307.

(33)

Section 11A was inserted by section 186(3) of the Housing and Planning Act 2016.

(34)

Section 11B was inserted by section 187(2) of the Housing and Planning Act 2016.

(35)

Section 12 was amended by section 56(2) of, and Part 1 of Schedule 9 to, the Courts Act 1971 (c. 23) and paragraph 4 of Schedule 16 to the Housing and Planning Act 2016.

(36)

Section 13 was amended by sections 62(3), 139(4) to (9) and 146 of, and paragraphs 27 and 28 of Schedule 13 and Part 3 of Schedule 23 to, the Tribunals, Courts and Enforcement Act 2007 (c. 15).

(37)

Section 20 was amended by paragraph 4 of Schedule 15 to the Planning and Compensation Act 1991 (c. 34) and S.I. 2009/1307.

(38)

Sections 272 to 274 were amended by paragraph 103(1) and (2) of Schedule 17 to the 2003 Act .

(39)

Section 279(3) was amended by paragraph 103(1) and (2), and section 280 was amended by paragraph 104, of Schedule 17 to the 2003 Act . Sections 280 and 282 were amended by S.I. 2009/1307.

(40)

1989 c. 29. The definition of “electrical plant” (in section 64) was amended by paragraphs 24 and 38(1) and (3) of Schedule 6 to the Utilities Act 2000 (c. 27).

(41)

1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45),and was further amended by sections 3(2) and 76 of, and Part 1 of Schedule 23 to, the Energy Act 2004 (c. 20) and S.I. 2011/2704.

(43)

Section 102(4) was amended by section 96(1)(c)of the Water Act 2003 (c. 37).

(44)

Section 104 was amended by sections 96(4) and 101(2) of, and Part 3 of Schedule 9 to, the Water Act 2003 and section 42(3) of the Flood and Water Management Act 2010 (c. 29).

(45)

2003 c.21.

(47)

Section 51A was inserted by section 92(1) of the Water Act 2003 (c. 37).

Yn ôl i’r brig

Options/Help