New Roads and Street Works Act 1991 (c. 22)

Part I U.K. New Roads in England and Wales

Concession agreements E+W

1 Concession agreements. E+W

(1) In this Part a “concession agreement” means an agreement entered into by a highway authority under which a person (the “concessionaire”), in return for undertaking such obligations as may be specified in the agreement with respect to the design, construction, maintenance, operation or improvement of a special road, is appointed to enjoy the right (conferred or to be conferred by a toll order under this Part) to charge tolls in respect of the use of the road.

References in this Part to a concession agreement are to the agreement as varied or supplemented from time to time.

(2) Except as otherwise expressly provided by this Part, the provisions of the M1 Highways Act 1980 apply in relation to a special road in relation to which a concession agreement is in force (referred to in this Part as a “road subject to a concession”) as in relation to any other special road provided or to be provided by the highway authority.

(3) A concession agreement shall provide that any land held by the concessionaire which in the opinion of the highway authority is required, in connection with the matters provided for in the agreement, for any purpose for which the authority may acquire land under Part XII of the M2 Highways Act 1980 shall be transferred to the highway authority without payment.

(4) A concession agreement relating to the design and construction of a special road shall provide that if the special road scheme authorising the provision of the road is not made or confirmed, or if the highway authority decide not to proceed with the proposed road, the authority shall pay to the concessionaire such compensation in respect of costs incurred by him as may be determined in accordance with the agreement.

(5) A concession agreement relating to the design and construction of a special road shall provide that if the concessionaire fails to complete the road in accordance with the agreement, he shall, without prejudice to any other liability, pay to the highway authority such compensation as may be determined in accordance with the agreement in respect of costs incurred by them.

Those costs shall be taken to include the relevant administrative expenses of the authority, including an appropriate sum in respect of general staff costs and overheads.

Marginal Citations

M1 1980 c. 66.

M2 1980 c. 66.

2 Exercise of highway functions by concessionaire. E+W

(1) A concession agreement may authorise the concessionaire to exercise in place of the highway authority such highway functions to which this section applies as may be specified in the agreement.

(2) For this purpose “highway functions” means all functions in relation to the road subject to the concession which are exercisable, in whatever capacity, by the authority who are the highway authority; and this section applies to all such functions, except—

(a) powers to make schemes or orders under the Highways Act 1980,

(b) powers to make regulations or orders, or give directions, under the M3 Road Traffic Regulation Act 1984, and

(c) such other functions as may be prescribed by the Secretary of State by regulations.

(3) A highway function exercisable by the concessionaire may be exercised by the highway authority themselves only—

(a) in an emergency, or

(b) if it appears to the authority that such exercise is necessary or expedient in the interests of road safety, or

(c) if it appears to the authority that the concessionaire has failed or is unable properly to discharge the function in any respect;

and the highway authority shall not be liable for anything done or omitted by the concessionaire in the exercise or purported exercise of a highway function.

(4) The highway authority may recover from the concessionaire the costs incurred by them in exercising in the circumstances mentioned in subsection (3)(a), (b) or (c) a highway function exercisable by the concessionaire.

Those costs shall be taken to include the relevant administrative expenses of the authority, including an appropriate sum in respect of general staff costs and overheads.

(5) The concessionaire shall in the exercise of a highway function act in accordance with the terms of the concession agreement; and the agreement may provide for the withdrawal of the concessionaire’s authority to exercise any such function.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Modifications etc. (not altering text)

C1 S. 2 applied (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 45 (with art. 51, Sch. 10 paras. 68, 85)

Marginal Citations

M3 1984 c. 27.

3 Provisions as to traffic regulation. E+W

(1) The following provisions have effect with respect to the operation of the M4 Road Traffic Regulation Act 1984 (“the 1984 Act”) in relation to a road subject to a concession.

(2) The traffic authority shall consult the concessionaire before making any regulations or order under the 1984 Act specifically relating to the road.

(3) The concessionaire may cause or permit traffic signs (within the meaning of section 64(1) of the 1984 Act) to be placed on or near the road, but subject to any directions given by the traffic authority.

If the concessionaire fails to comply with a direction of the traffic authority as to the placing of traffic signs, the authority may themselves carry out the work required and recover from the concessionaire the expenses reasonably incurred by them in doing so.

(4) The concessionaire may issue a notice under section 14 of the 1984 Act (temporary restriction or prohibition of traffic) having the same effect as a notice issued under that section by the traffic authority.

The Secretary of State may by regulations make provision excluding in relation to such a notice issued by a concessionaire the provisions of the 1984 Act relating to—

(a) the procedure in connection with the issue of the notice,

(b) the maximum duration of the notice, and

(c) the making of provision in relation to alternative roads,

and making instead such other provision as appears to him to be appropriate.

(5) A notice issued by the concessionaire by virtue of subsection (4) may be revoked or varied by the traffic authority and shall cease to have effect if provision inconsistent with it is made by that authority by order or notice under section 14 of the 1984 Act.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Marginal Citations

M4 1984 c. 27.

4 Leasing of land to concessionaire. E+W

(1) A highway authority who have entered into a concession agreement may grant to the concessionaire a lease of any land if it appears to the authority to be expedient to do so for the purpose of or in connection with the exercise by the concessionaire of his functions under the agreement.

(2) No enactment or rule of law regulating the rights and obligations of landlords and tenants shall prejudice the operation of an agreement between the authority and the concessionaire as to the terms on which land which is the subject of a lease granted under subsection (1) is provided for the concessionaire’s use.

(3) Accordingly no such enactment or rule of law applies in relation to the rights and obligations of the parties to a lease so granted—

(a) so as to exclude or modify in any respect any of the rights and obligations of those parties under the terms of the lease, whether with respect to the termination of the tenancy or any other matter;

(b) so as to confer or impose on either party any right or obligation arising out of or connected with anything done or omitted on or in relation to land which is the subject of the lease, in addition to any such right or obligation provided for by the terms of the lease;

(c) so as to restrict the enforcement (whether by action for damages or otherwise) by either party to the lease of any obligation of the other party under the lease.

5 Transfer or termination of concession. E+W

(1) The rights of a concessionaire under a concession agreement may be assigned with the consent of the highway authority; and references in this Part to the concessionaire shall be construed as references to the person for the time being entitled to exercise those rights.

(2) On the termination of a concession agreement (by effluxion of time or otherwise) there shall be transferred to the highway authority by virtue of this section all such property, rights and liabilities of the concessionaire as in accordance with the concession agreement fall to be so transferred in the circumstances.

Schedule 1 contains supplementary provisions with respect to that transfer.

(3) Where a concession agreement terminates or is terminated before the end of the toll period, the highway authority—

(a) shall take reasonable steps to secure the appointment of a new concessionaire, and

(b) may, for a period of not more than two years until a new appointment or an extension toll order takes effect or the toll period ends, charge and collect tolls in the same way as a concessionaire.

(4) A concession agreement may contain provision as to the circumstances in which, and extent to which, any sum received by the highway authority—

(a) in consideration for the appointment of a new concessionaire, or

(b) by way of tolls collected by virtue of subsection (3)(b),

is to be applied for the benefit of the former concessionaire or his creditors, as the case may be.

Toll orders E+W

6 Toll orders. E+W

(1) An order authorising the charging of tolls (a “toll order”) may be made in relation to a special road proposed to be provided by a highway authority.

The order shall state whether it authorises the charging of tolls by a concessionaire or by the highway authority.

[F1 (1A) Subsection (1) is subject to section 33(4) of the Planning Act 2008 (exclusion of powers to make or confirm orders in relation to highways for which development consent required).]

(2) A toll order relating to a special road to be provided by the Secretary of State shall be made by the Secretary of State; and a toll order relating to a special road to be provided by [F2 a strategic highways company or] a local highway authority shall be made by [F3 the company or] the authority and confirmed by the Secretary of State.

(3) Schedule 2 has effect as to the making or confirmation of a toll order and as to its validity and date of operation.

(4) The proceedings required to be taken in relation to a toll order shall (so far as practicable) be taken concurrently with the proceedings required to be taken under the M5 Highways Act 1980 in relation to the special road scheme authorising the provision of the road to which the order relates.

(5) The Secretary of State shall not make or confirm the scheme or the toll order unless he makes or confirms them both.

(6) The power conferred on the Secretary of State by this section to make or confirm a toll order is exercisable by statutory instrument.

Textual Amendments

F1 S. 6(1A) inserted (1.3.2010) by Planning Act 2008 (c. 29), s. 241(8), Sch. 2 para. 49 (with s. 226); S.I. 2010/101, art. 2 (with art. 6)

F2 Words in s. 6(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 114(a); S.I. 2015/481, reg. 2(a)

F3 Words in s. 6(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 114(b); S.I. 2015/481, reg. 2(a)

Marginal Citations

M5 1980 c. 66.

7 The toll period. E+W

(1) A toll order shall provide for tolls to be chargeable for a period (the “toll period”) specified in or determined in accordance with the order.

(2) The order may provide for the toll period to end—

(a) on a date, or at the end of a period, specified in the order, or

(b) on a date determined by reference to—

(i) the achievement of a specified financial objective, or

(ii) the passage of a specified number of vehicles,

or such other factors, or combinations of factors, as may be specified in the order, or

(c) on whichever is the earlier or later of dates specified in or determined in accordance with the order.

(3) In the case of a toll order authorising the charging of tolls by a concessionaire, it is for the highway authority to decide any matter relevant to determining the date on which the toll period ends.

8 Amount of tolls chargeable by concessionaire. E+W

(1) A toll order authorising the charging of tolls by a concessionaire shall specify the maximum tolls which may be charged if, and only if, the road to which the order relates consists of or includes a major crossing to which there is no reasonably convenient alternative.

(2) The Secretary of State may make provision by regulations as to what is to be treated as a major crossing for this purpose and as to the circumstances in which another route is to be taken to be, or not to be, a reasonably convenient alternative.

(3) Subject to any such regulations, a major crossing means a crossing of navigable waters more than 100 metres wide and a reasonably convenient alternative means another crossing (other than a ferry) which is free of toll and is within five miles of the crossing in question.

For this purpose—

(a) the width of tidal waters shall be ascertained by reference to the mean high-water mark and the width of other waters by reference to the ordinary limits of the waters, and

(b) the distance between two crossings shall be taken to be the shortest distance between the centre lines of the two crossings.

(4) The order shall specify the maximum tolls which may be charged for the use of the crossing or any length of the road including the crossing; and if the condition as to absence of a reasonably convenient alternative is satisfied in relation to certain types of traffic only, the order shall make provision only in relation to those types of traffic.

If that condition ceases to be satisfied, generally or in relation to certain types of traffic, the provisions of the order as to maximum tolls shall cease to apply, or cease to apply to that type of traffic, for so long as that remains the case.

(5) The order may specify different maxima for different descriptions of traffic (which need not correspond with the classes of traffic prescribed by the special road scheme) and may provide for the amounts to be varied in accordance with a formula specified in the order.

(6) Regulations under this section shall be made by statutory instrument and shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament.

Any regulations so made do not apply in relation to an order if notice of the draft order, and of the relevant draft special road scheme, have been published before the regulations come into force.

9 Amount of tolls chargeable by highway authority. E+W

(1) A toll order authorising the charging of tolls by the highway authority shall in every case specify the maximum tolls which may be charged for the use of the road or any length of the road in respect of which tolls are charged.

(2) The order may specify different maxima for different descriptions of traffic (which need not correspond with the classes of traffic prescribed by the special road scheme) and may provide for the amounts to be varied in accordance with a formula specified in the order.

10 Application of enactments relating to monopolies, &c. E+W

(1) [F4 For the purposes of the Enterprise Act 2002, a person] authorised by a toll order to charge tolls shall be deemed to supply a service, namely, providing the facility to use the road in return for the toll charged.

F5 (2) . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

F6 (3) . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Textual Amendments

F4 Words in s. 10(1) substituted (20.6.2003) by The Enterprise Act 2002 (Consequential and Supplemental Provisions) Order 2003 (S.I. 2003/1398), art. 1, Sch. para. 18(2)(a)

F5 S. 10(2) repealed (20.6.2003) by The Enterprise Act 2002 (Consequential and Supplemental Provisions) Order 2003 (S.I. 2003/1398), art. 1, Sch. para. 18(2)(b)

F6 S. 10(1)(b)(c)(3) repealed (1.3.2000) by S.I. 2000/311, art. 27

11 Variation or revocation of toll order. E+W

(1) A toll order may be varied or revoked—

(a) by an order made by the Secretary of State if he is the highway authority for the road, and

(b) by an order made by the highway authority and confirmed by the Secretary of State in any other case.

(2) The Secretary of State may confirm an order made by another authority either without modifications or subject to such modifications as he thinks fit.

(3) A toll order may not be varied so as to extend the toll period; and a toll order which does not authorise the charging of tolls in respect of the whole length of the special road to which it relates may not be varied so as to extend the length of road in respect of which tolls may be charged.

(4) A toll order relating to a road subject to a concession may not be varied or revoked without the consent of the concessionaire.

(5) An order under this section may contain such supplementary, incidental and transitional provisions as appear to the highway authority to be necessary or expedient.

(6) An order under this section made by the Secretary of State, and an instrument made by the Secretary of State confirming an order under this section made by another authority, shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

The provisions of Schedule 2 (procedure in connection with toll orders) do not apply.

12 Extension toll orders. E+W

(1) An order authorising the charging of tolls by the highway authority (an “extension toll order”) may be made in relation to a road which is or has been subject to a concession.

(2) An extension toll order relating to a special road for which the Secretary of State is the highway authority shall be made by the Secretary of State; and an extension toll order relating to a road for which the highway authority is [F7 a strategic highways company or] a local highway authority shall be made by [F8 that company or] that authority and confirmed by the Secretary of State.

(3) Any extension toll order must be made so as to come into force not later than—

(a) the end of the toll period under the previous toll order, or

(b) where the concession agreement terminates or is terminated before the end of that period, two years after the termination of the agreement,

whichever is the earlier.

(4) The following provisions of this Act apply in relation to an extension toll order as in relation to a toll order under section 6(1)—

• section 7(1) and (2) (the toll period),

• section 9 (amount of tolls chargeable by highway authority),

• section 10 (application of enactments relating to monopolies, &c.),

• section 11 (variation or revocation of order),

• sections 13 to 17 (further provisions with respect to tolls), and

• section 18 (annual report by Secretary of State).

(5) An extension toll order made by the Secretary of State, and an instrument made by the Secretary of State confirming an extension toll order made by [F9 a strategic highways company or] a local highway authority, shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

The provisions of Schedule 2 (procedure in connection with toll orders) do not apply.

Textual Amendments

F7 Words in s. 12(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 115(2)(a); S.I. 2015/481, reg. 2(a)

F8 Words in s. 12(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 115(2)(b); S.I. 2015/481, reg. 2(a)

F9 Words in s. 12(5) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 115(3); S.I. 2015/481, reg. 2(a)

Further provisions with respect to tolls E+W

13 Further provisions as to charging of tolls. E+W

(1) A toll order may contain provision exempting from liability for tolls such descriptions of traffic as may be specified in the order.

This does not affect the power of the person authorised by the order to charge tolls to grant such other exemptions from toll as he thinks fit.

(2) A toll order shall contain provision exempting from liability to pay any toll—

(a) a police vehicle, identifiable as such by writing or markings on it or otherwise by its appearance, if being used for police purposes;

[F10 (b) a vehicle which is exempt from vehicle excise duty under—

(i) paragraph 4 (fire engines),

(ii) paragraph 6 (ambulances),

(iii) paragraph 18 (invalid carriages),

(iv) paragraph 19 (vehicles for use by or for purposes of certain disabled people), or

(v) paragraph 20 (vehicles used for carriage of disabled people by recognised bodies),

of Schedule 2 to the Vehicle Excise and Registration Act 1994.]

(3) A person authorised by a toll order to charge tolls may, subject to the provisions of the order—

(a) suspend the collection of tolls;

(b) enter into agreements under which persons compound in advance, on such terms as may be agreed, for the payment of tolls;

(c) charge different tolls according to—

(i) the distance travelled, or

(ii) the day, time of day, week, month or other period; and

(d) charge different tolls for different descriptions of traffic.

In the case of a concessionaire the powers mentioned above are exercisable subject to the provisions of the concession agreement.

Textual Amendments

F10 S. 13(2)(b) substituted for s. 36(2)(b)-(d) (1.9.1994) by 1994 c. 22, ss. 63, 66, Sch. 3 para. 28 (with s. 57(4))

14 Collection of tolls. E+W

(1) The Secretary of State may make provision by regulations with respect to the collection of tolls in pursuance of a toll order.

(2) Different provision may be made for different types of road or different types of toll, or for particular roads or particular tolls.

(3) Regulations may, in particular, impose requirements with respect to—

(a) the displaying of lists of tolls, and

(b) the manner of implementing changes in the amount of tolls;

and where any such requirements are imposed, a toll may not be demanded unless they are, or as the case may be have been, complied with.

(4) A person who in respect of the use of a road to which a toll order relates demands a toll—

(a) which he is not authorised to charge, or

(b) which by virtue of subsection (3) may not be demanded,

commits an offence and is liable on summary conviction to a fine not exceeding level 3 on the standard scale.

(5) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

15 Refusal or failure to pay tolls. E+W

(1) A person who without reasonable excuse refuses or fails to pay, or who attempts to evade payment of, a toll which he is liable to pay by virtue of a toll order commits an offence and is liable on summary conviction to a fine not exceeding level 3 on the standard scale.

(2) If it appears to a person employed for the purpose of collecting tolls that a person has, without reasonable excuse, refused or failed to pay a toll which he is liable to pay by virtue of a toll order, he may—

(a) refuse to permit him to pass, or prevent him from passing, through any place at which tolls are payable, and

(b) require him to remove his vehicle from any such place by a particular route, and if he does not comply with such a requirement cause the vehicle to be so removed;

and for the purpose of exercising the powers conferred by this subsection, a person employed for the purpose of the collection of tolls may call upon such assistance as he thinks necessary.

(3) Where a person does not comply with a requirement under subsection (2)(b) as to the removal of his vehicle, he is liable to pay a prescribed charge in respect of the removal of the vehicle.

(4) Where there remains unpaid—

(a) a toll which a person is liable to pay by virtue of a toll order, or

(b) a prescribed charge which he is liable to pay by virtue of subsection (3),

the person authorised to charge tolls may recover from the person liable the amount of the toll or charge together with a reasonable sum to cover administrative expenses.

(5) In this section a “prescribed charge” means such charge as may be specified in, or calculated in accordance with, regulations made by the Secretary of State.

The regulations may provide for the amount of the charge, or any amount used for the purpose of calculating the charge, to be varied in accordance with a formula specified in the regulations.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

16 Facilities for collection of tolls. E+W

(1) A person authorised by a toll order to charge tolls may set up and maintain facilities for the collection of tolls.

The consent of the highway authority is required for the setting up of any such facilities by a concessionaire.

(2) Those responsible for the design and construction of facilities for the collection of tolls, and those responsible for the collection of tolls at such facilities, shall have due regard to the need to avoid delaying the passage of such vehicles as are mentioned in section 13(2)(a), (b) or (c) (police vehicles, ambulances and fire engines).

(3) The power of the highway authority under section 239(4)(c) of the M6 Highways Act 1980 to acquire land for the provision of buildings or facilities to be used in connection with the use of the special road includes, in the case of a road subject to a toll order, power to acquire any land required for the purpose of setting up facilities for the collection of tolls.

(4) Facilities for the collection of tolls are exempt from rating and shall not be included in any rating list.

(5) In this section “facilities for the collection of tolls” means such buildings, structures or other facilities within the boundary of the road, or on land adjoining the road, as are reasonably required for the purpose of or in connection with the collection of tolls in pursuance of a toll order.

Marginal Citations

M6 1980 c. 66.

17 Restriction of access to toll roads. E+W

(1) Where a toll order is in force in relation to a road, no highway or private means of access to premises shall be so constructed as to afford access to the road except with the consent of the highway authority and, where the road is subject to a concession, of the concessionaire.

(2) Subsection (1) does not apply to the construction of a highway or private means of access by or on behalf of a government department or Minister of the Crown which the department or Minister is satisfied is reasonably required for discharging any function of the department or Minister.

Annual Report E+W

18 Annual report on concession agreements and toll orders. E+W

(1) The Secretary of State shall in respect of each calendar year lay before Parliament a report—

(a) stating the number of concession agreements entered into by him during that year,

(b) stating the number of new roads opened to public use during that year for which he is the highway authority and which at the time of their opening were subject to a concession,

(c) listing the toll orders, and orders varying or revoking toll orders, made or confirmed by him in that year, and

(d) containing such information as appears to him to be appropriate with respect to the toll orders (whenever made) which are in force during that year or any part of it.

(2) The report shall be laid on or before 31st July in the following calendar year.

Miscellaneous E+W

19 Environmental assessment of projects involving special roads. E+W

In section 105A of the M7 Highways Act 1980 (environmental assessment of certain highway projects), after subsection (2) (cases in which environmental statement must be published) insert—

“(2A) Any project for the construction or improvement of a special road which falls within Annex II to the Directive shall be treated as having such characteristics that it should be made subject to an environmental assessment in accordance with the Directive.”.

Marginal Citations

M7 1980 c. 66.

20 Classification of traffic for purposes of special roads. E+W

(1) In section 17 of the Highways Act 1980 (classification of traffic for purposes of special roads), in subsection (3) omit the words from “and references” to the end (which relate to the effect of an amending order on existing schemes) and after that subsection insert—

“(4) An amending order may contain provision applying the amendments made by the order to existing schemes (whether made by the Minister or a local highway authority); and in the absence of such provision an amending order does not affect the classes of traffic prescribed in an existing scheme.

In this subsection an “existing scheme” means a scheme under section 16 made before the order comes into operation.”.

(2) In section 325 of the M8 Highways Act 1980 (provisions as to orders, &c.)—

(a) omit subsection (3) (which requires affirmative resolution for an order under section 17 varying the classes of traffic for the purposes of special roads); and

(b) in subsection (2)(b) (orders subject to negative resolution), after “section” insert “ 17 above or ”.

Marginal Citations

M8 1980 c. 66.

21 Certain special roads not necessarily trunk roads. E+W

(1) In section 19 of the Highways Act 1980 (under which a special road provided by the Secretary of State becomes a trunk road), after subsection (2) add—

“(3) Subsections (1) and (2) above have effect subject to any provision of the scheme under section 16 directing that the special road in question or any part of it shall not be a trunk road.

Any such provision does not affect the power of the Minister to make an order under section 10(2)(a) with respect to the special road or part.”.

(2) In section 1(1) of the Highways Act 1980 (highways for which the Minister is the highway authority), after paragraph (a) (trunk roads) insert—

“(aa) any special road provided by him;”.

(3) In section 2 of the Highways Act 1980 (responsibility of local highway authority for roads ceasing to be trunk roads), make the present provision subsection (1) and after it insert—

“(2) In the case of a special road provided by the Minister, subsection (1) above has effect subject to any provision of the order directing that the Minister shall continue to be the highway authority for the road.”.

22 Adoption of privately constructed roads. E+W

(1) In section 38 of the Highways Act 1980 (power of highway authorities to adopt by agreement), for subsection (3) (adoption by local highway authority of private road or way) substitute—

“(3) A local highway authority may agree with any person to undertake the maintenance of a way—

(a) which that person is willing and has the necessary power to dedicate as a highway, or

(b) which is to be constructed by that person, or by a highway authority on his behalf, and which he proposes to dedicate as a highway;

and where an agreement is made under this subsection the way to which the agreement relates shall, on such date as may be specified in the agreement, become for the purposes of this Act a highway maintainable at the public expense.

(3A) The Minister may agree with any person to undertake the maintenance of a road—

(a) which that person is willing and has the necessary power to dedicate as a highway, or

(b) which is to be constructed by that person, or by a highway authority on his behalf, and which he proposes to dedicate as a highway,

and which the Minister proposes should become a trunk road; and where an agreement is made under this subsection the road shall become for the purposes of this Act a highway maintainable at the public expense on the date on which an order comes into force under section 10 directing that the road become a trunk road or, if later, the date on which the road is opened for the purposes of through traffic.”.

(2) In section 10 of the M9 Highways Act 1980 (general provisions as to trunk roads)—

(a) in subsection (2)(a) (highways which may be made trunk roads) for “, or any highway proposed to be constructed by the Minister,” substitute— “or any proposed highway—

(i) to be constructed by the Minister, or

(ii) in relation to which the Minister has entered or proposes to enter into an agreement under section 38(3A),”;

(b) in subsection (4) omit the words from “Without prejudice” to the end of paragraph (b), for “highway proposed to be constructed by the Minister” substitute “ proposed highway ” and omit “by the Minister” in the second place where it occurs; and

(c) in subsection (7) for “highway proposed to be constructed by the Minister” substitute “ proposed highway ”.

Marginal Citations

M9 1980 c. 66.

23 Execution of works by highway authority at expense of another. E+W

In Part XIII of the Highways Act 1980 (financial provisions), for section 278 (contributions by persons deriving special benefit from works) substitute—

“278 Agreements as to execution of works.

(1) A highway authority may, if they are satisfied it will be of benefit to the public, enter into an agreement with any person—

(a) for the execution by the authority of any works which the authority are or may be authorised to execute, or

(b) for the execution by the authority of such works incorporating particular modifications, additions or features, or at a particular time or in a particular manner,

on terms that that person pays the whole or such part of the cost of the works as may be specified in or determined in accordance with the agreement.

(2) Without prejudice to the generality of the reference in subsection (1) to the cost of the works, that reference shall be taken to include—

(a) the whole of the costs incurred by the highway authority in or in connection with—

(i) the making of the agreement,

(ii) the making or confirmation of any scheme or order required for the purposes of the works,

(iii) the granting of any authorisation, permission or consent required for the purposes of the works, and

(iv) the acquisition by the authority of any land required for the purposes of the works; and

(b) all relevant administrative expenses of the highway authority, including an appropriate sum in respect of general staff costs and overheads.

(3) The agreement may also provide for the making to the highway authority of payments in respect of the maintenance of the works to which the agreement relates and may contain such incidental and consequential provisions as appear to the highway authority to be necessary or expedient for the purposes of the agreement.

(4) The fact that works are to be executed in pursuance of an agreement under this section does not affect the power of the authority to acquire land, by agreement or compulsorily, for the purposes of the works.

(5) If any amount due to a highway authority in pursuance of an agreement under this section is not paid in accordance with the agreement, the authority may—

(a) direct that any means of access or other facility afforded by the works to which the agreement relates shall not be used until that amount has been paid,

(b) recover that amount from any person having an estate or interest in any land for the benefit of which any such means of access or other facility is afforded, and

(c) declare that amount to be a charge on any such land (identifying it) and on all estates and interests therein.

(6) If it appears to the highway authority that a direction under subsection (5)(a) is not being complied with, the authority may execute such works as are necessary to stop up the means of access or deny the facility, as the case may be, and may for that purpose enter any land.

(7) Where a highway authority recovers an amount from a person by virtue of subsection (5)(b), he may in turn recover from any other person having an estate or interest in land for the benefit of which the means of access or other facility was afforded such contribution as may be found by the court to be just and equitable.

This does not affect the right of any of those persons to recover from the person liable under the agreement the amount which they are made to pay.

(8) The M10 Local Land Charges Act 1975 applies in relation to a charge under subsection (5)(c) in favour of the Secretary of State as in relation to a charge in favour of a local authority.”.

Marginal Citations

M10 1975 C. 76

24 Exercise of road traffic regulation powers. E+W

In Part X of the M11 Road Traffic Regulation Act 1984 (general and supplementary provisions), after section 122 insert—

“122A Prospective exercise of powers.

(1) Any power under this Act to make an order or give a direction may be exercised before the road to which it relates is open for public use, so as to take effect immediately on the road’s becoming open for public use.

(2) The procedure for making an order or giving a direction applies in such a case with such modifications as may be prescribed.”.

Marginal Citations

M11 1984 c. 27.

General E+W

25 Application of provisions of the Highways Act 1980, &c. E+W

(1) The following provisions of the M12 Highways Act 1980 apply for the purposes of this Part as if it were a part of that Act—

• section 302 (inquiries),

• section 303 (penalty for obstructing execution of Act),

• section 312 (restriction on institution of proceedings for offence),

• section 319 (judges and justices not to be disqualified by liability to rates),

• sections 320 to 322 (provisions as to notices), and

• section 323 (reckoning of periods).

(2) Nothing in this Part shall be construed as restricting the powers of a highway authority with respect to a road subject to a concession—

(a) as to the matters which may be provided for in the concession agreement or as to the making of agreements of any other description for any purpose connected with the special road; or

(b) as to the acquisition, by agreement or compulsorily, of any land which in the opinion of the authority is required, in connection with the road, for any purpose for which the authority may acquire land under Part XII of the Highways Act 1980.

(3) Nothing in a concession agreement shall be construed as affecting the status of the road subject to the concession as a highway maintainable at the public expense.

Marginal Citations

M12 1980 c. 66.

26 Interpretation. E+W

(1) In this Part the following expressions have the same meaning as in the Highways Act 1980—

• “highway authority”,

• “local highway authority”,

• “special road”,

• “special road authority”, and

• “traffic”;

and “special road scheme” means a scheme under section 16 of that Act authorising the provision of a special road.

[F11 (1A) In this Part, “strategic highways company” means a company for the time being appointed under Part 1 of the Infrastructure Act 2015.]

(2) Where a concession agreement is entered into jointly by two or more local highway authorities, references in this Part to the highway authority shall be construed—

(a) as references to each of those authorities in relation to times, circumstances and purposes before the special road scheme becomes operative, and

(b) in relation to times, circumstances and purposes after the special road scheme becomes operative, as references to the authority which in accordance with the scheme is the special road authority.

(3) The expressions listed below are defined or otherwise fall to be construed for the purposes of this Part in accordance with the provisions indicated—

concession agreement	section 1(1)
concessionaire	sections 1(1) and 5(1)
extension toll order	section 12(1)
highway authority	section 26(1) and (2)
local highway authority	section 26(1)
road subject to a concession	section 1(2)
special road	section 26(1)
special road authority	section 26(1)
special road scheme	section 26(1)
[F12 strategic highways company]	[F13 section 26(1)]
toll order	section 6
toll period	section 7
traffic	section 26(1).

Textual Amendments

F11 S. 26(1A) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 116(2); S.I. 2015/481, reg. 2(a)

F12 Words in s. 26(3) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 116(3)(a); S.I. 2015/481, reg. 2(a)

F13 Words in s. 26(3) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 116(3)(b); S.I. 2015/481, reg. 2(a)

Commencement Information

I1 S. 26 wholly in force at 01.11.1991, see s. 170 and S.I. 1991/2288, art.3, Sch.

Part II U.K. New Roads in Scotland

Toll Roads S

27 Toll orders. S

(1) An order authorising the charging of tolls (a “toll order”) by a roads authority may be made in relation to a special road proposed to be provided by that roads authority.

(2) A toll order relating to a special road to be provided by the Secretary of State shall be made by the Secretary of State; and a toll order relating to a special road to be provided by a local roads authority shall be made by the authority and confirmed by the Secretary of State.

(3) Part IIA [F14 and paragraphs 15 and 18 of Part III] of Schedule 1 to the M13 Roads (Scotland) Act 1984 apply to the making or confirmation of a toll order and Schedule 2 to that Act applies to a toll order with regard to its validity and date of operation.

(4) The proceedings required by Part IIA of Schedule 1 to that Act to be taken for the purposes of a toll order shall (so far as practicable) be taken concurrently with the proceedings required to be taken for the purposes of the special road scheme authorising the provision of the road to which the order relates.

(5) The Secretary of State shall not make or confirm the scheme or the toll order unless he makes or confirms them both.

(6) If under paragraph 3(b) of Schedule 2 to that Act the court quashes a toll order, the special road scheme for the road in respect of which the toll order was made shall also cease to have effect.

(7) Where a roads authority enter into a contract with a person for the design or construction of a road which both parties intend will be subject to a toll order, the contract shall make provision for the compensation of that person for such expenses as may be agreed in accordance with the contract in the event of—

(a) the roads authority deciding not to proceed with the special road scheme, or

(b) the Secretary of State failing to make or confirm either the toll order or the scheme.

(8) Where a roads authority enter into a contract such as is mentioned in subsection (7) above and the person who has contracted to design or construct the road fails to complete the road in accordance with the contract he shall, without prejudice to any other liability, pay the authority such compensation in respect of costs incurred by them as may be determined in accordance with the contract.

Those costs shall be taken to include the relevant administrative expenses of the authority, including an appropriate sum in respect of general staff costs and overheads.

(9) Where a toll order has been made—

(a) the road in respect of which it has been made, and

(b) such buildings, structures or other facilities within the boundary of the road or on land adjoining the road as are reasonably required for the purpose of or in connection with the collection of tolls,

are exempt from rating and shall not be included in any valuation roll.

[F15 (9A) On the date when a toll order comes into force any provision of any enactment (other than an enactment contained in this Act) which confers a power or imposes a duty to charge tolls for the use of all or part of any road to which the toll order relates shall cease to have effect.]

(10) The power conferred on the Secretary of State by this section to make or confirm a toll order is exercisable by statutory instrument.

Textual Amendments

F14 Words in s. 27(3) substituted (28.12.2007) by Transport and Works (Scotland) Act 2007 (asp 8), s. 30(4), sch. 2 para. 4; S.S.I. 2007/516, art. 2

F15 S. 27(9A) inserted (S.) (4.1.1995) by 1994 c. 39, s. 148(2) (with s. 128(8)); S.I. 1994/2850, art. 3(a), Sch. 2

Marginal Citations

M13 1984 c. 54.

28 Assignation of rights under a toll order. S

(1) A toll order may authorise the special road authority in whose name it is made to assign, subject to subsection (2), to a person, for such period and subject to such terms and conditions as they think fit, their rights under a toll order to charge and to collect tolls.

(2) A special road authority may grant such an assignation only to a person who has undertaken such obligations as may be specified in the assignation with respect to the design, construction, maintenance, operation or improvement of the road.

(3) In this Part, a person to whom the rights under a toll order to charge and to collect tolls have been assigned is referred to as a concessionaire.

(4) References in this Part to a person authorised to charge tolls include references to a concessionaire.

(5) Where a special road authority grants an assignation under this section, they shall also assign to the concessionaire such income as they receive in respect of—

(a) charging for the occupation of the road,

(b) charging for any services in relation to the road other than services which they themselves have supplied, or

(c) any contribution made by a third party towards the cost of maintenance or improvement of the road,

except to the extent that they themselves have incurred expense in such cases.

(6) A special road authority shall not make a charge as mentioned in subsection (5) without consulting the concessionaire with regard to the amount to be charged in such cases as the authority has discretion as to the amount to be charged.

29 The toll period. S

(1) A toll order shall provide for tolls to be chargeable for a period (the “toll period”) specified in or determined in accordance with the order.

(2) The order may provide for the toll period to end—

(a) on a date, or at the end of a period, specified in the order, or

(b) on a date determined by reference to—

(i) the achievement of a specified financial objective, or

(ii) the passage of a specified number of vehicles,

or such other factors, or combinations of factors, as may be specified in the order, or

(c) on whichever is the earlier or later of dates specified in or determined in accordance with the order.

(3) Where an assignation has been granted under section 28(1), it is for the special road authority to decide any matter relevant to determining the date on which the toll period ends.

30 Extension toll orders. S

(1) Where a toll order authorises the special road authority to assign their rights under the order to charge and collect tolls and—

(a) the authority fail to do so;

(b) such an assignation terminates or is terminated within the toll period; or

(c) the authority wish to charge and collect tolls beyond the toll period,

a further order (an “extension toll order”) may be made to authorise the authority to charge and collect tolls for a new toll period.

(2) An extension toll order shall not authorise the special road authority to assign their rights under it to charge and collect tolls.

(3) An extension toll order relating to a special road for which the Secretary of State is roads authority shall be made by the Secretary of State; and an extension toll order relating to a road for which the roads authority is a local authority shall be made by that authority and confirmed by the Secretary of State.

(4) Any extension toll order must be made so as to come into force not later than—

(a) the end of the toll period under the previous toll order; or

(b) where the assignation under section 28(1) terminates or is terminated before the end of that period, two years after the termination of the assignation,

whichever is the earlier.

(5) The following provisions of this Act apply in relation to an extension toll order as in relation to a toll order under section 27(1)—

• section 29(1) and (2) (the toll period)

• section 31 (amount of tolls chargeable by special road authority),

• section 33 (application of enactments relating to monopolies, etc.),

• section 34 (variation and revocation of order),

• sections 36 to 40 (further provisions with respect to tolls), and

• section 41 (report by Secretary of State).

(6) The power of the Secretary of State to make or confirm an extension toll order shall be exercisable by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament; and the provisions of Schedules 1 and 2 to the M14 Roads (Scotland) Act 1984 (procedure in connection with orders) shall not apply to an order under this section.

Marginal Citations

M14 1984 c. 54.

31 Amount of tolls chargeable. S

(1) Where a toll order does not authorise a special road authority to assign their rights under the order to charge and to collect tolls, the toll order shall in every case specify the maximum tolls which may be charged for the use of the road or any length of the road in respect of which tolls are charged.

(2) The order may specify different maxima for different descriptions of traffic (which need not correspond with the classes of traffic prescribed by the special road scheme) and may provide for the amounts to be varied in accordance with a formula specified in the order.

(3) Subject to section 32, where a toll order does authorise a special road authority to assign their rights under the order to charge and to collect tolls, it shall not specify any maximum in respect of tolls which may be charged by the concessionaire.

(4) Where a special road authority has authority to assign as described in subsection (3) but no such assignation is made, they shall not charge any tolls in respect of that road unless an extension toll order is made in respect of that road.

32 Toll order in respect of major crossings. S

(1) A toll order which relates to a road which consists of or includes a major crossing to which there is no reasonably convenient alternative shall specify the maximum tolls which may be charged in respect of that road.

(2) The Secretary of State may make provision by regulations as to what is to be treated as a major crossing for this purpose and as to the circumstances in which another route is to be taken to be, or not to be, a reasonably convenient alternative.

(3) Subject to any such regulations, a major crossing means a crossing of navigable waters more than 100 metres wide and a reasonably convenient alternative means another crossing (other than a ferry) which is free of toll and is within five miles of the crossing in question.

For this purpose—

(a) the width of tidal waters shall be ascertained by reference to the mean high-water mark and the width of other waters by reference to the ordinary limits of the waters, and

(b) the distance between two crossings shall be taken to be the shortest distance between the centre lines of the two crossings.

(4) The order shall specify the maximum tolls which may be charged for the use of the crossing or any length of the road including the crossing; and if the condition as to absence of a reasonably convenient alternative is satisfied in relation to certain types of traffic only, the order shall make provision only in relation to those types of traffic.

If that condition ceases to be satisfied, generally or in relation to certain types of traffic, the provisions of the order as to maximum tolls shall, where an assignation has been granted under section 28(1), cease to apply, or cease to apply to that type of traffic, for so long as that remains the case.

(5) The order may specify different maxima for different descriptions of traffic (which need not correspond with the classes of traffic prescribed by the special road scheme) and may provide for the amounts to be varied in accordance with a formula specified in the order.

(6) Regulations under this section shall be made by statutory instrument and shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament.

Any regulations so made do not apply in relation to an order if notice of the draft order, and of the relevant draft special road scheme, have been published before the regulations come into force.

33 Application of enactments relating to monopolies, &c. S

(1) [F16 For the purposes of the Enterprise Act 2002, a person] authorised to charge tolls shall be deemed to supply a service, namely, providing the facility to use the road in return for the toll charged.

F17 (2) . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

F18 (3) . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Textual Amendments

F16 Words in s. 33(1) substituted (20.6.2003) by The Enterprise Act 2002 (Consequential and Supplemental Provisions) Order 2003 (S.I. 2003/1398), art. 1, Sch. para. 18(3)(a)

F17 S. 33(2) repealed (20.6.2003) by The Enterprise Act 2002 (Consequential and Supplemental Provisions) Order 2003 (S.I. 2003/1398), art. 1, Sch. para. 18(3)(b)

F18 S. 33(1)(b)(c)(3) repealed (1.3.2000) by S.I. 2000/311, art. 27

34 Variation or revocation of toll order. S

(1) A toll order may be varied or revoked—

(a) by an order made by the Secretary of State if he made the toll order; and

(b) by an order made by the local roads authority and confirmed by the Secretary of State in any other case.

(2) Without prejudice to section 30 above (extension toll orders), a toll order may not be varied so as to extend the toll period.

(3) A toll order which does not authorise the charging of tolls in respect of the whole length of the special road to which it relates may not be varied so as to extend the length of road in respect of which tolls may be charged.

(4) The Secretary of State may confirm an order made by a local roads authority either without modifications or subject to such modifications as he thinks fit.

(5) Where an assignation has been granted under section 28(1), the toll order may not be varied or revoked without the consent of the concessionaire.

(6) An order under this section may contain such supplementary, incidental and transitional provisions as appear to the roads authority making the order to be necessary or expedient.

(7) The power conferred on the Secretary of State by this section to vary, revoke or confirm an order is exercisable by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament; and the provisions of Schedules 1 and 2 to the M15 Roads (Scotland) Act 1984 (procedure in connection with orders) shall not apply to an order under this section.

Marginal Citations

M15 1984 c. 54.

35 Transfer or termination of assignation. S

(1) The rights of a concessionaire under an assignation granted under section 28(1) may, with the consent of the special road authority, be assigned by the concessionaire.

(2) Where an assignation granted by the special road authority under section 28(1) terminates or is terminated before the end of the toll period, the authority shall take reasonable steps to grant a fresh assignation to a new concessionaire and the authority may charge and collect tolls in the same way as a concessionaire within the period of two years beginning with that termination but, within that period, only until the earliest, if any, of the following events—

(a) the granting of a fresh assignation;

(b) the expiry of the toll period;

(c) the commencement of an extension toll order.

(3) References in this Part (including this section) to an assignation granted under section 28(1) shall include references to a fresh assignation granted by virtue of subsection (2) above.

(4) An assignation granted under section 28(1) may contain provision as to the circumstances in which, and the extent to which, any sum received by the special road authority—

(a) in consideration for the appointment of a new concessionaire, or

(b) by way of tolls collected by virtue of subsection (2),

is to be applied for the benefit of the former concessionaire or his creditors, as the case may be.

(5) Where an assignation granted by the special road authority under section 28(1) terminates or is terminated before the end of the toll period and the authority either intends to grant a fresh assignation or to charge and collect tolls itself then, for the purposes of the M16 Transfer of Undertakings (Protection of Employment) Regulations 1981, or any regulations replacing those regulations, the concessionaire shall be treated as transferring to the authority an undertaking which, if a new concessionaire is appointed, the authority shall be treated as then transferring to the new concessionaire.

(6) References in this Part to the termination of an assignation are references to the termination of the rights assigned under the assignation.

Marginal Citations

M16 S.I. 1981/1794.

Further provision with respect to tolls S

36 Further provision as to charging of tolls. S

(1) A toll order may contain provision exempting from liability for tolls such descriptions of traffic as may be specified in the order.

This does not affect the power of the person authorised to charge tolls to grant such other exemptions from toll as he thinks fit.

(2) A toll order shall contain provision exempting from liability to pay any toll—

(a) a police vehicle, identifiable as such by writing or markings on it or otherwise by its appearance, if being used for police purposes;

[F19 (b) a vehicle which is exempt from vehicle excise duty under—

(i) paragraph 4 (fire engines),

(ii) paragraph 6 (ambulances),

(iii) paragraph 18 (invalid carriages),

(iv) paragraph 19 (vehicles for use by or for purposes of certain disabled people), or

(v) paragraph 20 (vehicles used for carriage of disabled people by recognised bodies),

of Schedule 2 to the Vehicle Excise and Registration Act 1994.]

(3) A person authorised to charge tolls may, subject to the provisions of the order—

(a) suspend the collection of tolls;

(b) enter into agreements under which persons compound in advance, on such terms as may be agreed, for the payment of tolls;

(c) charge different tolls according to—

(i) the distance travelled; or

(ii) the day, time of day, week, month or other period; and

(d) charge different tolls for different descriptions of traffic.

In the case of a concessionaire the powers mentioned above are exercisable subject to the provisions of the assignation.

Textual Amendments

F19 S. 36(2)(b) substituted (for s. 36(2)(b)-(d)) by (1.9.1994) by 1994 c. 22 ss. 63, 66, Sch. 3, para. 28; (with s. 57(4))

37 Collection of tolls. S

(1) The Secretary of State may make provision by regulations with respect to the collection of tolls in pursuance of a toll order.

(2) Different provision may be made for different types of road or different types of toll, or for particular roads or particular tolls.

(3) Regulations may, in particular, impose requirements with respect to—

(a) the displaying of lists of tolls, and

(b) the manner of implementing changes in the amount of tolls;

and where any such requirements are imposed, a toll may not be demanded unless they are, or as the case may be have been, complied with.

(4) A person who in respect of the use of a road to which a toll order relates demands a toll—

(a) which he is not authorised to charge, or

(b) which by virtue of subsection (3) may not be demanded,

commits an offence and is liable on summary conviction to a fine not exceeding level 3 on the standard scale.

(5) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

38 Refusal or failure to pay tolls. S

(1) A person who without reasonable excuse refuses or fails to pay, or who attempts to evade payment of, a toll which he is liable to pay by virtue of a toll order commits an offence and is liable on summary conviction to a fine not exceeding level 3 on the standard scale.

(2) If it appears to a person employed for the purpose of collecting tolls that a person has, without reasonable excuse, refused or failed to pay a toll which he is liable to pay by virtue of a toll order, he may—

(a) refuse to permit him to pass, or prevent him from passing, through any place at which tolls are payable, and

(b) require him to remove his vehicle from any such place by a particular route, and if he does not comply with such a requirement cause the vehicle to be so removed;

and for the purpose of exercising the powers conferred by this subsection, a person employed for the purpose of the collection of tolls may call upon such assistance as he thinks necessary.

(3) Where a person does not comply with a requirement under subsection (2)(b) as to the removal of his vehicle, he is liable to pay a prescribed charge in respect of the removal of the vehicle.

(4) Where there remains unpaid—

(a) a toll which a person is liable to pay by virtue of a toll order, or

(b) a prescribed charge which he is liable to pay by virtue of subsection (3),

the person authorised to charge tolls may recover from the person liable the amount of the toll or charge together with a reasonable sum to cover administrative expenses.

(5) In this section a “prescribed charge” means such charge as may be specified in, or calculated in accordance with, regulations made by the Secretary of State.

The regulations may provide for the amount of the charge, or any amount used for the purpose of calculating the charge, to be varied in accordance with a formula specified in the regulations.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

39 Facilities for collection of tolls. S

(1) A person authorised to charge tolls may set up and maintain facilities for the collection of tolls.

The consent of the special road authority is required for the setting up of any such facilities by a concessionaire.

(2) Those responsible for the design and construction of facilities for the collection of tolls, and those responsible for the collection of tolls at such facilities, shall have due regard to the need to avoid delaying the passage of such vehicles as are mentioned in section 36(2)(a), (b) or (c) (police vehicles, ambulances and fire engines).

(3) The power of the special road authority under section 104(3)(c) of the M17 Roads (Scotland) Act 1984 to acquire land for the provision of buildings or facilities to be used in connection with the use of the special road includes, in the case of a road subject to a toll order, power to acquire any land required for the purpose of setting up facilities for the collection of tolls.

(4) In this section “facilities for the collection of tolls” means such buildings, structures or other facilities within the boundary of the road, or on land adjoining the road, as are reasonably required for the purpose of or in connection with the collection of tolls in pursuance of a toll order.

Marginal Citations

M17 1984 c. 54.

40 Restriction of access to toll roads. S

(1) Where a toll order is in force in relation to a road, no road or private means of access to land shall be so constructed as to afford access to the road except with the consent of the special road authority and, where an assignation has been granted under section 28(1), the concessionaire.

(2) Subsection (1) does not apply to the construction of a road or private means of access by or on behalf of a government department or Minister of the Crown which the department or Minister is satisfied is reasonably required for discharging any function of the department or Minister.

Report S

41 Report on toll roads and toll orders in Scotland. S

(1) In any calendar year in which there occurs an event to which this section applies, the Secretary of State shall in respect of that year lay before Parliament a report informing Parliament of that occurrence or, as the case may be, the number of such occurrences.

(2) This section applies to the following events—

(a) the Secretary of State enters into a contract for the design and construction of a road which is to be subject to a toll order;

(b) there is opened to public use a new road subject to a toll order for which he is the roads authority;

(c) a toll order, or an order varying or revoking a toll order, is made or confirmed by him.

(3) A report under this section shall contain such information as appears to him to be appropriate with respect to the toll orders (whenever made) which are in force during that year or any part of it.

(4) A report under this section shall be laid on or before 31st July in the following calendar year.

Supplementary provisions S

42 Environmental assessment of projects involving special roads. S

(1) In section 20A of the M18 Roads (Scotland) Act 1984 (environmental assessment of certain road construction projects), after subsection (2) (cases in which environmental statement must be published) insert—

“(2A) Any project for the construction of a special road which falls within Annex II to the Directive shall be treated as having such characteristics that it should be made subject to an environmental assessment in accordance with the Directive.”.

(2) In section 55A of that Act (environmental assessment of certain road improvement projects), in subsection (2) (cases in which environmental statement must be published) after the word “and” there shall be inserted the words “ either the project is in respect of a special road or the project ”.

Marginal Citations

M18 1984 c. 54.

43 Provisions as to traffic regulation. S

(1) The following provisions have effect with respect to the operation of the M19 Road Traffic Regulation Act 1984 (“the 1984 Act”) in relation to a road in respect of which an assignation has been granted under section 28(1).

(2) The traffic authority shall consult the concessionaire before making any regulations or order under the 1984 Act specifically relating to the road.

(3) The concessionaire may cause or permit traffic signs (within the meaning of section 64(1) of the 1984 Act) to be placed on or near the road, but subject to any directions given by the traffic authority.

If the concessionaire fails to comply with a direction of the traffic authority as to the placing of traffic signs, the authority may themselves carry out the work required and recover from the concessionaire the expenses reasonably incurred by them in doing so.

(4) The concessionaire may issue a notice under section 14 of the 1984 Act (temporary restriction or prohibition of traffic) having the same effect as a notice issued under that section by the traffic authority.

The Secretary of State may by regulations make provision excluding in relation to such a notice issued by a concessionaire the provisions of the 1984 Act relating to—

(a) the procedure in connection with the issue of the notice,

(b) the maximum duration of the notice, and

(c) the making of provision in relation to alternative roads,

and making instead such other provision as appears to him to be appropriate.

(5) A notice issued by the concessionaire by virtue of subsection (4) may be revoked or varied by the traffic authority and shall cease to have effect if provision inconsistent with it is made by that authority by order or notice under section 14 of the 1984 Act.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Marginal Citations

M19 1984 c. 27.

44 Exercise of road traffic regulation powers. S

In Part X of the M20 Road Traffic Regulation Act 1984 (general and supplementary provisions), after section 122 insert—

“122A Prospective exercise of powers.

(1) Any power under this Act to make an order or give a direction may be exercised before the road to which it relates is open for public use, so as to take effect immediately on the road’s becoming open for public use.

(2) The procedure for making an order or giving a direction applies in such a case with such modifications as may be prescribed.”.

Marginal Citations

M20 1984 c. 27.

45 Classification of traffic for purposes of special roads. S

In section 8 of the M21 Roads (Scotland) Act 1984 (classification of traffic for purposes of special roads), in subsection (3) there shall be omitted the words from “and where” to the end (which relate to the effect of a variation order on existing schemes) and after that subsection there shall be inserted—

“(4) A variation order may contain provision applying the variations made by the order to existing schemes (whether made by the Secretary of State or a local roads authority); and in the absence of such provision a variation order does not affect the classes of traffic prescribed in an existing scheme.

(5) In subsection (4) above an “existing scheme” means a scheme under section 7 made before the order comes into operation.”.

Marginal Citations

M21 1984 c. 54.

46 Special roads not necessarily to be trunk roads. S

In section 10 of the Roads (Scotland) Act 1984 (under which a special road provided by the Secretary of State becomes a trunk road), after subsection (2) there shall be inserted—

“(3) Subsections (1) and (2) above shall have effect subject to any provision of the scheme under section 7 of this Act directing that the special road in question or any part of it shall not be a trunk road; but any such provision shall not affect the power of the Secretary of State to make an order under section 5(2)(a) of this Act with respect to the special road or part.”.

47 The Roads (Scotland) Act 1984 and the interpretation of Part II. S

(1) In this Part—

• “extension toll order” means a toll order made under section 30(1) authorising the charging of tolls for a new toll period;

• “roads authority”, “local roads authority” and “special road authority” have the same meaning as in the M22 Roads (Scotland) Act 1984;

• “special road” has the same meaning as in that Act;

• “special road scheme” means a scheme under section 7 of that Act authorising the provision of a special road;

• “toll order” means an order under section 27 authorising the charging of tolls;

• “toll period” has the meaning given in section 29(1).

(2) The following provisions of the Roads (Scotland) Act 1984 apply for the purposes of this Part as if it were a part of that Act—

• sections 136 to 138 (provisions as to notices), and

• section 139 (inquiries).

(3) Where an assignation is granted jointly under section 28(1) by two or more local roads authorities references in this Part to the roads authority shall be construed—

(a) as references to each of those authorities in relation to times, circumstances and purposes before the special road scheme becomes operative, and

(b) in relation to times, circumstances and purposes after the special road scheme becomes operative, as references to the authority which in accordance with the scheme is the special road authority.

(4) Nothing in this Part shall be construed as restricting the powers of a roads authority with respect to a road subject to a toll order in respect of which an assignation has been granted under section 28(1)—

(a) as to the matters which may be provided for in the assignation or as to the making of agreements of any other description for any purpose connected with the special road, or

(b) as to the acquisition, by agreement or compulsorily, of any land which in the opinion of the authority is required, in connection with the road, for any purpose for which the authority may acquire land under Part IX of the M23 Roads (Scotland) Act 1984.

Marginal Citations

M22 1984 c. 54.

M23 1984 c. 54.

Part III U.K. Street works in England and Wales

Modifications etc. (not altering text)

C2 Pt. 3 (ss. 48-106) modified (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), arts. 3(1)(2) (with art. 38);

Pt. 3 (ss. 48-106) modified (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(1)

C3 Pt. 3 (ss. 48-106) applied (6.11.2000) by 2000 c. 26, s. 95, Sch. 6 para. 1(3); S.I. 2000/2957, art. 2(1), Sch. 1

Pt. 3 (ss. 48-106) modified (29.3.2001) by S.I. 2001/1348, art. 21(2)

Pt. 3 (ss. 48-106) amended (24.7.2001) by S.I. 2001/3627, art. 4(1)

C4 Definition in Pt. 3 (ss. 48-106) applied (1.12.1991) by Water Industry Act 1991 (c. 56, SIF 130), ss. 71-84, 162-172, 219(1), 223(2), Sch. 6 para. 6(3)(a).

C5 Definition in Pt. 3 (ss. 48-106) applied (1.12.1991) by Water Resources Act 1991 (c. 57, SIF 130), ss. 178, 221(1), 225(2), Sch. 22 para. 3(2).

C6 Pt. 3 excluded (16.3.1992) by Avon Weir Act 1992 (c. v), s. 6(3) (with s. 61(1))

C7 Pt. 3 modified (1.1.1993) by Pipelines Act 1962 (c. 58), s. 16(1) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. 3 para. 101(3); S.I. 1992/2984, art. 2(2), Sch.2)

Pt. 3 modified (27.7.1993) by 1993 c. xv, s. 4(1)

Pt. 3 (ss. 48-106) excluded (27.7.1993) by 1993 c. xv, s. 4(2)

C8 Pt. 3 applied (with modifications) (21.7.1994) by 1994 c. xv, s. 4(1)

Pt. 3 applied (21.7.1994) by 1994 c. xv, s. 45(5)(a)

Pt. 3 excluded (21.7.1994) by 1994 c. xv, s. 21(2)

Pt. 3 restricted (21.7.1994) by 1994 c. xv, s. 4(2)

C9 Pt. 3 excluded (18.12.1996) by 1996 c. 61, s. 52, Sch. 15 para. 1(3)

Pt. 3 modified (18.12.1996) by 1996 c. 61, s. 3, Sch. 3 para. 8

C10 Pt. 3 extended (28.7.1998) by 1998 c. iv, s. 3

C11 Pt. 3 applied (27.8.1998) by S.I. 1998/1936, arts. 1, 41, Sch. 10 paras. 2(8), 3(2)

Pt. 3 modified (13.1.1999) by S.I. 1998/3269, art. 4(1)

C12 Pt. 3 modified (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(1)

C13 Pt. 3 modified (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(1)(2) (with arts. 65, 66)

C14 Pt. 3 modified (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(1)(2) (with art. 51)

C15 Pt. 3 modified (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(1)(2) (with art. 47)

C16 Pt. 3 applied (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(1)

C17 Pt. 3 modified (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(7) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C18 Pt. 3 restricted (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 10(3)

C19 Pt. 3 modified (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(1)

C20 Pt. 3 modified (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(1) (with arts. 3(5), 15(3))

C21 Pt. 3 applied (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(1) (with art. 52)

C22 Pt. 3 modified (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(1)(2) (with art. 43)

C23 Pt. 3 modified (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 3

C24 Pt. 3 modified (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(1) (with arts. 19, 28, Sch. 3 para. 13(2))

C25 Pt. 3 modified (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(6) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C26 Pt. 3 modified (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(1) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C27 Pt. 3 modified (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 3 para. 8

C28 Pt. 3 excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 17 para. 1(3)

C29 Pt. 3 modified (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(1) (with art. 36(3))

C30 Pt. 3 modified (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(1)(2) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C31 Pt. 3 modified (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(1)(2)

C32 Pt. 3 modified (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(1) (with art. 51, Sch. 10 paras. 68, 85)

C33 Pt. 3 modified (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(1)

C34 Pt. 3 modified (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(1) (with art. 42(2))

C35 Pt. 3 applied (with modifications) (9.4.2013) by The Hinkley Point C (Nuclear Generating Station) Order 2013 (S.I. 2013/648), arts. 1, 9 (with arts. 48, 68, 79)

C36 Pt. 3 modified (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(1)

C37 Pt. 3 modified (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(1)(2) (with arts. 42, 43)

C38 Pt. 3 modified (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(1)(2)

C39 Pt. 3 modified (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(1)

C40 Pt. 3 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(9) (with arts. 57, 58, Sch. 11 para. 19)

C41 Pt. 3 modified (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(1)(2) (with arts. 57, 58, Sch. 11 para. 19)

C42 Pt. 3 modified (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(1)

C43 Pt. 3 restricted (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), art. 1, Sch. 12 Pt. 2 para. 3 (with arts. 12, 13, Sch. 12 Pt. 1 paras. 6(3), 19, Pt. 2 paras. 3, 6, 13, Pt. 3 para. 5, Pt. 4 para. 4, Pt. 5 para. 4)

C44 Pt. 3 modified (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(1)(2)

C45 Pt. 3 modified (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(5), 11(4)

C46 Pt. 3 modified (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(1)(2)

C47 Pt. 3 modified (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(2) (with Sch. 8 para. 45)

C48 Pt. 3 modified (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(1) (with art. 36(2))

C49 Pt. 3 modified (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(1)(2)

C50 Pt. 3 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(1) (with art. 32)

C51 Pt. 3 modified (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(2) (with art. 37)

C52 Pt. 3 modified (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(1)(2) (with arts. 4, 5(3))

C53 Pt. 3 applied (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(1) (with art. 39)

C54 Pt. 3 modified (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(2) (with art. 39)

C55 Pt. 3 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(1)(2) (with arts. 46, 47, Sch. 8 para. 2(7), Sch. 9 para. 4, Sch. 10 para. 12(2))

C56 Pt. 3 modified (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(2)

C57 Pt. 3 modified (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(1)(2) (with arts. 43, 44)

C58 Pt. 3 modified (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 4 para. 8(1) (with Sch. 4 para. 8(2))

C59 Pt. 3 excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 33 para. 1(3)

C60 Pt. 3 modified (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(1) (with art. 31)

C61 Pt. 3 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 9(1) (with art. 22)

C62 Pt. 3 modified (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(2) (with Sch. 8 para. 20)

C63 Pt. 3 modified (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(1) (with art. 32(2))

C64 Pt. 3 modified (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(1)(2) (with arts. 4, 37)

C65 Pt. 3 applied (with modifications) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(2) (with arts. 55-57, Sch. 8 para. 13)

C66 Pt. 3 modified (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(2) (with arts. 55-57, Sch. 8 para. 13)

C67 Pt. 3 applied (with modifications) (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(1)(2) (with arts. 58, 59)

C68 Pt. 3 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(1) (with arts. 24(8), 33(2))

C69 Pt. 3 modified (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(2)

C70 Pt. 3 modified (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(1) (with art. 31(2))

C71 Pt. 3 modified (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(1)(2) (with arts. 3(3), 5)

C72 Pt. 3 modified (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(1)(2)(8) (with arts. 55, 56)

C73 Pt. 3 modified (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(1) (with art. 37(2))

C74 Pt. 3 applied (with modifications) (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(1)(2) (with art. 3(1))

C75 Pt. 3 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(1)(2) (with arts. 47, 48, Sch. 10 para. 19)

C76 Pt. 3 modified (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(2) (with arts. 5, 44)

C77 Pt. 3 modified (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(1)(2) (with art. 37)

C78 Pt. 3 modified (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(1)(2) (with arts. 5, 44)

C79 Pt. 3 modified (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(1)(2) (with art. 5)

C80 Pt. 3 modified (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(1)(2)

C81 Pt. 3 modified (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(1)(2) (with art. 32, Sch. 9 para. 36)

C82 Pt. 3 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(1)

Introductory provisions E+W

48 Streets, street works and undertakers. E+W

(1) In this Part a “street” means the whole or any part of any of the following, irrespective of whether it is a thoroughfare—

(a) any highway, road, lane, footway, alley or passage,

(b) any square or court, and

(c) any land laid out as a way whether it is for the time being formed as a way or not.

Where a street passes over a bridge or through a tunnel, references in this Part to the street include that bridge or tunnel.

(2) The provisions of this Part apply to a street which is not a maintainable highway subject to such exceptions and adaptations as may be prescribed.

(3) In this Part “street works” means works of any of the following kinds (other than works for road purposes) executed in a street in pursuance of a statutory right or a street works licence—

(a) placing apparatus, or

(b) inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, changing the position of apparatus or removing it,

or works required for or incidental to any such works (including, in particular, breaking up or opening the street, or any sewer, drain or tunnel under it, or tunnelling or boring under the street).

[F20 (3A) For the purposes of subsection (3), the works that are street works by virtue of being works required for or incidental to street works of any particular kind include—

(a) reinstatement of the street, and

(b) where an undertaker has failed to comply with his duties under this Part with respect to reinstatement of the street, any remedial works.]

(4) In this Part “undertaker” in relation to street works means the person by whom the relevant statutory right is exercisable (in the capacity in which it is exercisable by him) or the licensee under the relevant street works licence, as the case may be.

(5) References in this Part to the undertaker in relation to apparatus in a street are to the person entitled, by virtue of a statutory right or a street works licence, to carry out in relation to the apparatus such works as are mentioned in subsection (3); and references to an undertaker having apparatus in the street, or to the undertaker to whom apparatus belongs, shall be construed accordingly.

Textual Amendments

F20 S. 48(3A) inserted (26.1.2009) by Local Transport Act 2008 (c. 26), ss. 124(2), 134(2)

Modifications etc. (not altering text)

C83 S. 48(3) modified (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 10(2)

C84 S. 48(3) modified (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 9(2)

C85 S. 48(3) modified (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(2) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Pt. 2 para. 6, Pt. 3 para. 5, Pt. 4 para. 4, Pt. 5 para. 4)

C86 S. 48(3) modified (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(2) (with arts. 30(4), 53)

C87 S. 48(3) applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(2)

C88 S. 48(3) modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 10(2)(3) (with art. 32)

C89 S. 48(3) modified (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(2) (with art. 39)

C90 S. 48(3) modified (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(2) (with art. 31)

C91 S. 48(3) modified (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(2) (with arts. 6, 42)

C92 S. 48(3) modified (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(2)

C93 S. 48(3) modified (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(2) (with art. 37)

C94 S. 48(3) modified (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 10(2)

C95 S. 48(3) modified (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 11(5) (with art. 32, Sch. 9 para. 36)

49 The street authority and other relevant authorities. E+W

(1) In this Part “the street authority” in relation to a street means, subject to the following provisions—

(a) if the street is a maintainable highway, the highway authority, and

(b) if the street is not a maintainable highway, the street managers.

(2) In the case of a highway for which the Secretary of State [F21 or a strategic highways company] is the highway authority but in relation to which a local highway authority acts as his [F22 or its] agent under section 6 of the M24 Highways Act 1980, the local highway authority shall be regarded as the street authority for the purposes of section 53 (the street works register) and sections 54 to 60 (advance notice and co-ordination of works).

(3) Subsection (1)(b) has effect subject to section 87 as regards the application of this Part to prospectively maintainable highways.

(4) In this Part the expression “street managers”, used in relation to a street which is not a maintainable highway, means the authority, body or person liable to the public to maintain or repair the street or, if there is none, any authority, body or person having the management or control of the street.

(5) The Secretary of State may by regulations make provision for exempting street managers from provisions of this Part which would otherwise apply to them as the street authority in relation to a street.

(6) References in this Part to the relevant authorities in relation to any works in a street are to the street authority and also—

(a) where the works include the breaking up or opening of a public sewer in the street, the sewer authority;

(b) where the street is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, that authority; and

(c) where in any other case the street is carried or crossed by a bridge, the bridge authority.

Textual Amendments

F21 Words in s. 49(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 117(a); S.I. 2015/481, reg. 2(a)

F22 Words in s. 49(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 117(b); S.I. 2015/481, reg. 2(a)

Marginal Citations

M24 1980 c. 66.

50 Street works licences. E+W

(1) The street authority may grant a licence (a “street works licence”) permitting a person—

(a) to place, or to retain, apparatus in the street, and

(b) thereafter to inspect, maintain, adjust, repair, alter or renew the apparatus, change its position or remove it,

and to execute for those purposes any works required for or incidental to such works (including, in particular, breaking up or opening the street, or any sewer, drain or tunnel under it, or tunnelling or boring under the street).

[F23 (1A) For the purposes of subsection (1), the works that are required for or incidental to works falling within paragraph (a) or (b) of that subsection include—

(a) reinstatement of the street, and

(b) where an undertaker has failed to comply with his duties under this Part with respect to reinstatement of the street, any remedial works.]

(2) A street works licence authorises the licensee to execute the works permitted by the licence without obtaining any consent which would otherwise be required to be given—

(a) by any other relevant authority in its capacity as such, or

(b) by any person in his capacity as the owner of apparatus affected by the works;

but without prejudice to the provisions of this Part as to the making of requirements by any such authority or person or as to the settlement of a plan and section and the execution of the works in accordance with them.

(3) A street works licence does not dispense the licensee from obtaining any other consent, licence or permission which may be required; and it does not authorise the installation of apparatus for the use of which the licence of the Secretary of State is required, unless and until that licence has been granted.

(4) The provisions of Schedule 3 have effect with respect to the grant of street works licences, the attachment of conditions and other matters.

(5) A street works licence may be granted—

(a) to a person on terms permitting or prohibiting its assignment, or

(b) to the owner of land and his successors in title;

and references in this Part to the licensee are to the person for the time being entitled by virtue of the licence to do anything permitted by it.

(6) Any licence, consent, permission or other authority for the execution in a street of any such works as are mentioned in subsection (1) granted or given by the street authority before the commencement of this Part has effect after the commencement of this Part as a street works licence; but subsection (2) does not apply in relation to such a licence.

This applies in particular to licences granted under section 181 of the M25 Highways Act 1980 or any corresponding earlier enactment.

(7) The works referred to in subsection (1) above do not include works for road purposes.

Textual Amendments

F23 S. 50(1A) inserted (26.1.2009) by Local Transport Act 2008 (c. 26), ss. 124(3), 134(2)

Modifications etc. (not altering text)

C96 S. 50: functions of local authority not to be responsibility of an executive of the authority (E.) (16.11.2000) by virtue of S.I. 2000/2853, reg. 2(1), Sch. 1 Table B41

Marginal Citations

M25 1980 c. 66.

51 Prohibition of unauthorised street works. E+W

(1) It is an offence for a person other than the street authority—

(a) to place apparatus in a street, or

(b) to break up or open a street, or a sewer, drain or tunnel under it, or to tunnel or bore under a street, for the purpose of placing, inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, or of changing the position of apparatus or removing it,

otherwise than in pursuance of a statutory right or a street works licence.

(2) A person committing an offence under this section is liable on summary conviction to a fine not exceeding [F24 level 5] on the standard scale.

(3) This section does not apply to works for road purposes or to emergency works of any description.

(4) If a person commits an offence under this section, the street authority may—

(a) in the case of an offence under subsection (1)(a), direct him to remove the apparatus in respect of which the offence was committed, and

(b) in any case, direct him to take such steps as appear to them necessary to reinstate the street or any sewer, drain or tunnel under it.

If he fails to comply with the direction, the authority may remove the apparatus or, as the case may be, carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F24 Words in s. 51(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C97 S. 51 modified (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 11(5) (with art. 32, Sch. 9 para. 36)

C98 S. 51(1) modified (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 10(2)

C99 S. 51(1) modified (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 9(2)

C100 S. 51(1) modified (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(2) (with arts. 30(4), 53)

C101 S. 51(1) modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 10(2)(3) (with art. 32)

C102 S. 51(1) modified (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(2) (with art. 39)

C103 S. 51(1) modified (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(2) (with art. 31)

C104 S. 51(1) modified (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(2) (with arts. 6, 42)

C105 S. 51(1) modified (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(2)

C106 S. 51(1) modified (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 10(2)

F25 52 Emergency works. E+W

(1) In this Part “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

(2) Where works comprise items some of which fall within the preceding definition, the expression “emergency works” shall be taken to include such of the items as do not fall within that definition as cannot reasonably be severed from those that do.

(3) Where in any civil or criminal proceedings brought by virtue of any provision of this Part the question arises whether works were emergency works, it is for the person alleging that they were to prove it.

Textual Amendments

F25 Definition in s. 52 extended (1.12.1991) by Water Resources Act 1991 (c. 57, SIF 130), ss. 78(5), 225(2) (with ss. 16(6), 179, 222(3), Sch. 22 para. 1, Sch. 23 para. 6)

Modifications etc. (not altering text)

C107 S. 52 excluded (27.11.1992) by S.I. 1992/2984, art. 5

The street works register E+W

53 The street works register. E+W

(1) A street authority shall keep a register showing with respect to each street for which they are responsible such information as may be prescribed with respect to the street works, and such other descriptions of works as may be prescribed, executed or proposed to be executed in the street.

(2) The register shall contain such other information, and shall be kept in such form and manner, as may be prescribed.

(3) The authority shall make the register available for inspection, at all reasonable hours and free of charge—

(a) so far as it relates to restricted information, by any person having authority to execute works of any description in the street, or otherwise appearing to the authority to have a sufficient interest, and

(b) so far as it relates to information which is not restricted, by any person.

The Secretary of State may make provision by regulations as to the information which is restricted for the purposes of this subsection.

(4) The Secretary of State may make arrangements for the duties of street authorities under this section to be discharged by means of one or more central registers kept by a person appointed in pursuance of the arrangements.

[F26 (4A) In subsection (4) “central register” means a register covering the areas of two or more street authorities.]

(5) If such arrangements are made the Secretary of State may require street authorities to participate in and make contributions towards the cost of the arrangements.

[F27 (5A) In particular the Secretary of State may require a street authority to share information in their possession with a person appointed to keep a central register which discharges the duties of that authority under this section.]

(6) The Secretary of State may by regulations make provision with respect to any register kept in pursuance of this section—

(a) requiring the registration of such information as may be prescribed, and

(b) requiring the payment of such fee as may be prescribed in respect of the registration of information of any prescribed description;

and the regulations may contain provision as to the person responsible for securing the registration of the information and the person liable to pay the fee.

Textual Amendments

F26 S. 53(4A) inserted (29.6.2020 for E.) by Traffic Management Act 2004 (c. 18), ss. 45(3), 99(1); S.I. 2020/659, art. 2

F27 S. 53(5A) inserted (29.6.2020 for E.) by Traffic Management Act 2004 (c. 18), ss. 45(4), 99(1); S.I. 2020/659, art. 2

Modifications etc. (not altering text)

C108 S. 53: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(a)

C109 S. 53 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(a) (with reg. 35)

C110 S. 53 modified (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) Regulations 2008 (S.I. 2008/101), regs. 1, 13 (with reg. 19)

C111 S. 53 modified (E.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (England) Regulations 2007 (S.I. 2007/1951), regs. 1(1), 13(2)(a) (with reg. 19)

C112 S. 53 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(a)

C113 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C114 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C115 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C116 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C117 S. 53 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C118 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C119 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C120 S. 53 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C121 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C122 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C123 S. 53 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C124 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C125 S. 53 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C126 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C127 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C128 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C129 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C130 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C131 S. 53 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C132 S. 53 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C133 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C134 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C135 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C136 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C137 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C138 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C139 S. 53 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C140 S. 53 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C141 S. 53 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C142 S. 53 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch., Appendix D

C143 S. 53 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch., Appendix D

C144 S. 53 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch., Appendix D

C145 S. 53 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch., Appendix D

C146 S. 53 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch., Appendix D

C147 S. 53 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch., Appendix D

C148 S. 53 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix B

C149 S. 53 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C150 S. 53 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C151 S. 53 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix B

C152 S. 53 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C153 S. 53 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C154 S. 53 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C155 S. 53 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C156 S. 53 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C157 S. 53 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C158 S. 53 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C159 S. 53 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C160 S. 53 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C161 S. 53 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C162 S. 53 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C163 S. 53 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C164 S. 53 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C165 S. 53 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C166 S. 53 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C167 S. 53 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C168 S. 53 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C169 S. 53 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C170 S. 53 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C171 S. 53 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch. Appendix B

C172 S. 53 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C173 S. 53 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C174 S. 53 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C175 S. 53 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C176 S. 53 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C177 S. 53 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C178 S. 53 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C179 S. 53 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C180 S. 53 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C181 S. 53 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C182 S. 53 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch. Appendix B

C183 S. 53 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C184 S. 53 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C185 S. 53 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C186 S. 53 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C187 S. 53 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C188 S. 53 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C189 S. 53 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C190 S. 53 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C191 S. 53 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C192 S. 53 disapplied (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C193 S. 53 applied (13.7.2016) by Housing and Planning Act 2016 (c. 22), ss. 175(3)(4), 216(3); S.I. 2016/733, reg. 3(h)

C194 S. 53 modified (1.4.2020) by S.I. 2007/3372, Pt. 8A (as inserted by The Street and Road Works (Amendments Relating to Electronic Communications) (England) Regulations 2020 (S.I. 2020/122), regs. 1(2), 5(7))

Commencement Information

I2 S. 53 wholly in force: s. 53(1)-(3) in force at 28.11.1992 see s. 170(1) and S.I. 1992/2984, art. 2(1), Sch. 1; s. 53(4)-(6) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

Notice and co-ordination of works E+W

54 Advance notice of certain works. E+W

(1) In such cases as may be prescribed an undertaker proposing to execute street works shall give the prescribed advance notice of the works to the street authority.

(2) Different periods of notice may be prescribed for different descriptions of works.

(3) The notice shall [F28 state the date on which it is proposed to begin the works and shall contain such other] information as may be prescribed.

(4) After giving advance notice under this section an undertaker shall comply with such requirements as may be prescribed, or imposed by the street authority, as to the providing of information and other procedural steps to be taken for the purpose of co-ordinating the proposed works with other works of any description proposed to be executed in the street.

[F29 (4A) If an undertaker who has given advance notice under this section has not, before the starting date specified in the notice, given to the street authority a notice under section 55 in respect of the works, he shall within such period as may be prescribed give to that authority a notice containing such information as may be prescribed.

(4B) An advance notice under this section shall cease to have effect in relation to the proposed works (so that subsection (1) applies again in relation to the works) if those works are not substantially begun before the end of such period beginning with the starting date specified in the notice as may be prescribed, or such further period as the street authority may allow.

(4C) Different periods may be prescribed under subsection (4B) for different descriptions of works.]

(5) An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F30 level 4] on the standard scale.

Textual Amendments

F28 Words in s. 54(3) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(1)(a), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

F29 S. 54(4A)-(4C) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(1)(b), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

F30 Words in s. 54(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C195 S. 54 modified (27.11.1992) by S.I. 1992/2984, art. 3(1)

C196 S. 54 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 54 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)(4)

S. 54 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 54 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 54 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

C197 S. 54 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

C198 S. 54 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 54 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 54 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 54 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 54 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 54 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)(4)

S. 54 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 54 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 54 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C199 S. 54 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38)

S. 54 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 54 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C200 S. 54 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C201 S. 54 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C202 S. 54 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C203 S. 54 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C204 S. 54 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)-(5) (with art. 51)

C205 S. 54 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C206 S. 54 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)-(5) (with art. 47)

C207 S. 54 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C208 S. 54 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C209 Ss. 54, 55 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C210 S. 54 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C211 S. 54 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C212 S. 54 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C213 S. 54 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C214 S. 54 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)-(6) (with art. 43)

C215 S. 54 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C216 S. 54 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C217 S. 54 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2)(3) (with arts. 46-48, Sch. 6 para. 23)

C218 S. 54 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C219 S. 54 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)-(4) (with arts. 19, 28, Sch. 3 para. 13(2))

C220 S. 54 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(b) (with reg. 35)

C221 S. 54 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)-(5) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C222 S. 54 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)-(4) (with art. 36(3))

C223 S. 54 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(b)

C224 S. 54 applied (with modifications) (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)-(6) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C225 S. 54 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)-(6)

C226 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C227 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C228 S. 54 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C229 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C230 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C231 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C232 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C233 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C234 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C235 S. 54 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C236 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C237 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C238 S. 54 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C239 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C240 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C241 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C242 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C243 S. 54 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C244 S. 54 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C245 S. 54 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C246 S. 54 applied (with modifications) (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4

C247 S. 54 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3)(4) (with art. 51, Sch. 10 paras. 68, 85)

C248 S. 54 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(4)

C249 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C250 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C251 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C252 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C253 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C254 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C255 S. 54 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C256 S. 54 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C257 S. 54 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C258 S. 54 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch., Appendix D

C259 S. 54 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch., Appendix D

C260 S. 54 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch., Appendix D

C261 S. 54 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch., Appendix D

C262 S. 54 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch., Appendix D

C263 S. 54 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch., Appendix D

C264 S. 54 applied (with modifications) (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2)(3) (with art. 26(2))

C265 S. 54 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix B

C266 S. 54 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix B

C267 S. 54 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch., Appendix B

C268 S. 54 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix B

C269 S. 54 applied (with modifications) (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)-(4) (with art. 35(2))

C270 S. 54 applied (with modifications) (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)-(4) (with art. 42(2))

C271 S. 54 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C272 S. 54 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C273 S. 54 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C275 S. 54 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C277 S. 54 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C278 S. 54 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C279 S. 54 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C280 S. 54 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C281 S. 54 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C282 S. 54 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C283 S. 54 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C284 S. 54 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C285 S. 54 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C286 S. 54 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C289 S. 54 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)-(3)

C290 S. 54 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)-(5)

C291 S. 54 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C292 S. 54 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C293 S. 54 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)-(6) (with arts. 42, 43)

C294 S. 54 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C295 S. 54 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C296 S. 54 modified (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(6)

C297 S. 54 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C298 S. 54 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)-(4) (with arts. 27(2), 39, Sch. 10 para. 4)

C299 S. 54 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)-(4)

C300 S. 54 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)-(6) (with arts. 57, 58, Sch. 11 para. 19)

C301 S. 54 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C302 S. 54 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)-(5) (with art. 34(2))

C303 S. 54 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix B

C304 S. 54 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)-(4)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C307 S. 54 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C308 S. 54 modified (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(5) (with art. 31(2))

C309 S. 54 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)-(6)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C312 S. 54 applied (with modifications) (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)-(4) (with art. 33)

C313 S. 54 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)-(6)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C315 S. 54 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C317 S. 54 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)-(6) (with Sch. 8 para. 45)

C318 S. 54 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)-(3) (with arts. 37, 38)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C320 S. 54 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C321 S. 54 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C322 S. 54 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C323 S. 54 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C325 S. 54 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C326 S. 54 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)-(6)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C328 S. 54 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C329 S. 54 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C330 S. 54 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C331 S. 54 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C333 S. 54 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch. Appendix B

C334 S. 54 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C335 S. 54 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C336 S. 54 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C337 S. 54 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C338 S. 54 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C339 S. 54 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C340 S. 54 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C341 S. 54 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C342 S. 54 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C343 S. 54 disapplied (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C352 S. 54 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)(6)

C353 S. 54 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)-(4) (with art. 32)

C354 S. 54 applied (with modifications) (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)-(6) (with art. 37)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C356 S. 54 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)-(6) (with arts. 4, 5(3))

C357 S. 54 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)-(5) (with art. 39)

C358 S. 54 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)-(5) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C362 S. 54 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(a)(3) (with arts. 37, 38)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C364 S. 54 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)-(6)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C367 S. 54 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(4) (with art. 37)

C368 S. 54 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(a) (with art. 37)

C369 S. 54 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)-(6) (with arts. 43, 44)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C371 S. 54 applied (with modifications) (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(a)(4) (with art. 31)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C375 S. 54 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(4) (with art. 22)

C376 S. 54 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(a) (with art. 22)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C378 S. 54 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)-(6) (with Sch. 8 para. 20)

C379 S. 54 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)-(5) (with art. 32(2))

C380 S. 54 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)-(6) (with arts. 4, 37)

C381 S. 54 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)-(6) (with arts. 55-57, Sch. 8 para. 13)

C382 S. 54 applied (with modifications) (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)-(6) (with arts. 58, 59)

C383 S. 54 applied (with modifications) (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)-(5) (with arts. 24(8), 33(2))

C384 S. 54 applied (with modifications) (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)-(6)

C385 S. 54 applied (with modifications) (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)-(6) (with arts. 3(3), 5)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C387 S. 54 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)-(6) (with arts. 55, 56)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C391 S. 54 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)-(5) (with art. 37(2))

C392 S. 54 applied (with modifications) (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(a)(6) (with art. 3(1))

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C394 S. 54 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)-(5) (with arts. 47, 48, Sch. 10 para. 19)

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C396 S. 54 applied (with modifications) (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5)(6) (with arts. 5, 44)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C398 S. 54 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)-(6) (with arts. 51, 57)

C399 S. 54 applied (with modifications) (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with arts. 13(6), 37)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C401 S. 54 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 9(6), 44)

C402 S. 54 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)-(6) (with art. 5)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C404 S. 54 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)(6)

C405 S. 54 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(a)(6) (with art. 32, Sch. 9 para. 36)

C406 S. 54(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(b)

55 Notice of starting date of works. E+W

(1) An undertaker proposing to begin to execute street works involving—

(a) breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the street,

shall give not less than 7 working days’ notice (or such other notice as may be prescribed) to the street authority, to any other relevant authority and to any other person having apparatus in the street which is likely to be affected by the works.

(2) Different periods of notice may be prescribed for different descriptions of works, [F31 or in cases where the undertaker has been given notice under section 58(1),] and cases may be prescribed in which no notice is required.

(3) The notice shall state the date on which it is proposed to begin the works and shall contain such other information as may be prescribed.

(4) Where notice is required to be given under this section, the works shall not be begun without notice or before the end of the notice period, except with the consent of those to whom notice is required to be given.

(5) An undertaker who begins to execute any works in contravention of this section commits an offence and is liable on summary conviction to a fine not exceeding [F32 level 4] on the standard scale.

(6) In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of—

(i) a relevant authority, or

(ii) the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

(7) A notice under this section shall cease to have effect if the works to which it relates are not substantially begun before the end of the period of 7 working days (or such other period as may be prescribed) beginning with the starting date specified in the notice, or such further period as may be allowed by those to whom notice is required to be given.

[F33 (8) If a notice under this section ceases to have effect the undertaker shall, within such period as may be prescribed, give a notice containing such information as may be prescribed to those to whom the notice under this section was required to be given.

(9) An undertaker who fails to give notice in accordance with subsection (8) commits an offence and is liable on summary conviction to a fine not exceeding level 4 on the standard scale.]

Textual Amendments

F31 Words in s. 55(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(9), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F32 Words in s. 55(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F33 S. 55(8)(9) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E. in so far as not already in force, 1.4.2008 for W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

Modifications etc. (not altering text)

C209 Ss. 54, 55 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C407 S. 55 modified (27.11.1992) by S.I. 1992/2984, art.4

S. 55 modified (E.W.) (1. 1. 1993) by Local Government (Miscellaneous Provisions) Act 1976 (c. 57), s. 15(4) (as substituted by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 106; S.I. 1992/2984, art. 2(2), Sch.2)

S. 55 modified (E.W.) (1. 1. 1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7) (as substituted by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2984, art. 2(2), Sch.2)

C408 S. 55 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 55 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)(4)

S. 55 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 55 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 55 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 55 applied with modifications (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

C409 S. 55 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 55 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 55 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 55 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 55 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 55 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)(4)

S. 55 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 55 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 55 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C410 S. 55 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38)

S. 55 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 55 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C411 S. 55 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C412 S. 55 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C413 S. 55 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C414 S. 55 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)-(5) (with art. 51)

C415 S. 55 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C416 S. 55 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)-(5) (with art. 47)

C417 S. 55 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C418 S. 55 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C419 S. 55 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C420 S. 55 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C421 S. 55 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C422 S. 55 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C423 S. 55 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)-(6) (with art. 43)

C424 S. 55 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C425 S. 55 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C426 S. 55 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2)(3) (with arts. 46-48, Sch. 6 para. 23)

C427 S. 55 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C428 S. 55 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)-(4) (with arts. 19, 28, Sch. 3 para. 13(2))

C429 S. 55 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(c) (with reg. 35)

C430 S. 55 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)-(5) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C431 S. 55 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)-(4) (with art. 36(3))

C432 S. 55 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(c)

C433 S. 55 applied (with modifications) (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)-(6) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C434 S. 55 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)-(6)

C435 S. 55 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C436 S. 55 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C437 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C438 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C439 S. 55 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C440 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C441 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C442 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C443 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C444 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C445 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C446 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C447 S. 55 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C448 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C449 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C450 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C451 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C452 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C453 S. 55 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C454 S. 55 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C455 S. 55 applied (with modifications) (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4

C456 S. 55 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3)(4) (with art. 51, Sch. 10 paras. 68, 85)

C457 S. 55 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(4)

C458 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C459 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C460 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C461 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C462 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C463 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C464 S. 55 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C465 S. 55 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C466 S. 55 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C467 S. 55 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch., Appendix D

C468 S. 55 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch., Appendix D

C469 S. 55 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch., Appendix D

C470 S. 55 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch., Appendix D

C471 S. 55 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch., Appendix D

C472 S. 55 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch., Appendix D

C473 S. 55 applied (with modifications) (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2)(3) (with art. 26(2))

C474 S. 55 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix B

C475 S. 55 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix B

C476 S. 55 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix B

C477 S. 55 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix B

C478 S. 55 applied (with modifications) (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)-(4) (with art. 35(2))

C479 S. 55 applied (with modifications) (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)-(4) (with art. 42(2))

C480 S. 55 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C481 S. 55 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C482 S. 55 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C483 S. 55 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C484 S. 55 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C485 S. 55 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch., Appendix C

C486 S. 55 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C487 S. 55 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C488 S. 55 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C489 S. 55 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C490 S. 55 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch., Appendix C

C491 S. 55 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C492 S. 55 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C493 S. 55 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C494 S. 55 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)-(3)

C495 S. 55 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)-(5)

C496 S. 55 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C497 S. 55 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C498 S. 55 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)-(6) (with arts. 42, 43)

C499 S. 55 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C500 S. 55 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C501 S. 55 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C502 S. 55 modified (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(6)

C503 S. 55 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)-(4) (with arts. 27(2), 39, Sch. 10 para. 4)

C504 S. 55 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)-(4)

C505 S. 55 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)-(6) (with arts. 57, 58, Sch. 11 para. 19)

C506 S. 55 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C507 S. 55 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)-(5) (with art. 34(2))

C508 S. 55 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix B

C509 S. 55 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)-(4)

C510 S. 55 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C511 S. 55 modified (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(5) (with art. 31(2))

C512 S. 55 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)-(6)

C513 S. 55 applied (with modifications) (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)-(4) (with art. 33)

C514 S. 55 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)-(6)

C515 S. 55 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C516 S. 55 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)-(6) (with Sch. 8 para. 45)

C517 S. 55 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)-(3) (with arts. 37, 38)

C518 S. 55 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C519 S. 55 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C520 S. 55 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C521 S. 55 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C522 S. 55 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C523 S. 55 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)-(6)

C524 S. 55 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C525 S. 55 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C526 S. 55 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C527 S. 55 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C528 S. 55 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C529 S. 55 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch. Appendix B

C530 S. 55 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C531 S. 55 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C532 S. 55 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C533 S. 55 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C534 S. 55 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C535 S. 55 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C536 S. 55 disapplied (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C537 S. 55 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C538 S. 55 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C539 S. 55 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)(6)

C540 S. 55 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)-(4) (with art. 32)

C541 S. 55 applied (with modifications) (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)-(6) (with art. 37)

C542 S. 55 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)-(6) (with arts. 4, 5(3))

C543 S. 55 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)-(5) (with art. 39)

C544 S. 55 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)-(5) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C545 S. 55 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(b)(3) (with arts. 37, 38)

C546 S. 55 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)-(6)

C547 S. 55 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(b) (with art. 37)

C548 S. 55 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(4) (with art. 37)

C549 S. 55 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)-(6) (with arts. 43, 44)

C550 S. 55 applied (with modifications) (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(b)(4) (with art. 31)

C551 S. 55 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(b) (with art. 22)

C552 S. 55 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(4) (with art. 22)

C553 S. 55 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)-(6) (with Sch. 8 para. 20)

C554 S. 55 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)-(5) (with art. 32(2))

C555 S. 55 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)-(6) (with arts. 4, 37)

C556 S. 55 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)-(6) (with arts. 55-57, Sch. 8 para. 13)

C557 S. 55 applied (with modifications) (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)-(6) (with arts. 58, 59)

C558 S. 55 applied (with modifications) (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)-(5) (with arts. 24(8), 33(2))

C559 S. 55 applied (with modifications) (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)-(6)

C560 S. 55 applied (with modifications) (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)-(6) (with arts. 3(3), 5)

C561 S. 55 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)-(6) (with arts. 55, 56)

C562 S. 55 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)-(5) (with art. 37(2))

C563 S. 55 applied (with modifications) (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(b)(6) (with art. 3(1))

C564 S. 55 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)-(5) (with arts. 47, 48, Sch. 10 para. 19)

C565 S. 55 applied (with modifications) (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5)(6) (with arts. 5, 44)

C566 S. 55 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)-(6) (with arts. 51, 57)

C567 S. 55 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with arts. 13(6), 37)

C568 S. 55 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 9(6), 44)

C569 S. 55 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(a)(h) (with arts. 9(3), 37)

C570 S. 55 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(a)(3) (with arts. 41, 42, Sch. 16 para. 66)

C571 S. 55 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)-(6) (with art. 5)

C572 S. 55 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)(6)

C573 S. 55 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(b)(6) (with art. 32, Sch. 9 para. 36)

C574 S. 55 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(a)(3) (with arts. 9(3), 40, 41, Sch. 9 Pt. 5 para. 18)

C575 S. 55(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(c)

Commencement Information

I3 S. 55 wholly in force: s. 55 in force for the purpose of making regulations at 28.11.1992, and for all other purposes at 1.1.1993, see s. 170 and S.I. 1992/2984, art. 2, Schs. 1, 2

56 Power to give directions as to timing of street works. E+W

(1) If it appears to the street authority—

(a) that proposed street works are likely to cause serious disruption to traffic, and

(b) that the disruption would be avoided or reduced if the works were carried out only at certain times [F34 or on certain days (or at certain times on certain days)],

the authority may give the undertaker such directions as may be appropriate as to the times [F34 or days (or both)] when the works may or may not be carried out.

[F35 (1A) Where it appears to a street authority—

(a) that subsisting street works are causing or are likely to cause serious disruption to traffic, and

(b) that the disruption would be avoided or reduced if the works were to continue to be carried out only at certain times or on certain days (or at certain times on certain days),

the authority may give the undertaker such directions as may be appropriate as to the times or days (or both) when the works may or may not continue to be carried out.]

(2) The procedure for giving a direction shall be prescribed by the Secretary of State.

(3) An undertaker who executes works in contravention of a direction under this section commits an offence and is liable on summary conviction to a fine not exceeding [F36 level 5] on the standard scale.

[F37 (3A) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a direction under this section.]

(4) The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the exercise by street authorities of the power conferred by this section; and in exercising that power a street authority shall have regard to the code of practice.

Textual Amendments

F34 Words in s. 56(1)(b) inserted (4.1.2005 for E., 1.4.2008 for W.) by Traffic Management Act 2004 (c. 18), ss. 43(2), 99(1); S.I. 2004/3110, art. 2(b); S.I. 2007/3174, art. 2, Sch.

F35 S. 56(1A) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 43(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 4); S.I. 2007/3174, art. 2, Sch. (with art. 5)

F36 Words in s. 56(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F37 S. 56(3A) inserted (4.1.2005 for E., 1.4.2008 for W.) by Traffic Management Act 2004 (c. 18), ss. 43(4), 99(1); S.I. 2004/3110, art. 2(b); S.I. 2007/3174, art. 2, Sch.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C576 S. 56 excluded (11.11.1996) by S.I. 1996/2714, art. 4(1)

S. 56 excluded (27.8.1998) by S.I. 1998/1936, art. 4(1)

S. 56 excluded (21.5.1997) by S.I. 1997/1266, art. 5(1)

S. 56 excluded (24.7.2001) by S.I. 2001/3627, art. 4(2)

C577 S. 56 excluded (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(2)

S. 56 excluded (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(1)

C578 S. 56 excluded (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(2)

C579 S. 56 excluded (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(3) (with arts. 65, 66)

C580 S. 56 excluded (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(2)

C581 S. 56 excluded (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(8) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C582 S. 56 excluded (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(2) (with arts. 3(5), 15(3))

C583 S. 56 excluded (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(2) (with art. 52)

C584 S. 56 excluded (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(3) (with art. 43)

C585 S. 56 excluded (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(2) (with arts. 3(3)(6), 12(3))

C586 S. 56 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(d) (with reg. 35)

C587 S. 56 excluded (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(2) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C588 S. 56 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(d)

C589 S. 56 excluded (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(3) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C590 S. 56 excluded (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(3)

C591 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C592 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C593 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C594 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C595 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C596 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C597 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C598 S. 56 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C599 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C600 S. 56 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C601 S. 56 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C602 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C603 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C604 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C605 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C606 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C607 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C608 S. 56 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C609 S. 56 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C610 S. 56 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C611 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C612 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C613 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C614 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C615 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C616 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C617 S. 56 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C618 S. 56 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C619 S. 56 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C620 S. 56 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch., Appendix D

C621 S. 56 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch., Appendix D

C622 S. 56 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C623 S. 56 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C624 S. 56 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch., Appendix D

C625 S. 56 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch., Appendix D

C626 S. 56 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch., Appendix B

C627 S. 56 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix B

C628 S. 56 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix B

C629 S. 56 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix B

C630 S. 56 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C631 S. 56 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C632 S. 56 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C633 S. 56 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C634 S. 56 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C635 S. 56 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C636 S. 56 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C637 S. 56 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C638 S. 56 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C639 S. 56 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C640 S. 56 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C641 S. 56 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C642 S. 56 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C643 S. 56 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C644 S. 56 excluded (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(2)

C645 S. 56 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C646 S. 56 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C647 S. 56 excluded (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(3) (with arts. 42, 43)

C648 S. 56 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C649 S. 56 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C650 S. 56 excluded (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(3)

C651 S. 56 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C652 S. 56 excluded (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(3) (with arts. 57, 58, Sch. 11 para. 19)

C653 S. 56 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C654 S. 56 excluded (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(2) (with art. 34(2))

C655 S. 56 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix B

C656 S. 56 excluded (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(2) (with art. 31(2))

C657 S. 56 excluded (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(3)

C658 S. 56 excluded (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(3)

C659 S. 56 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C660 S. 56 excluded (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(3) (with Sch. 8 para. 45)

C661 S. 56 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C662 S. 56 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C663 S. 56 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C664 S. 56 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C665 S. 56 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C666 S. 56 excluded (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(3)

C667 S. 56 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C668 S. 56 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C669 S. 56 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C670 S. 56 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C671 S. 56 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C672 S. 56 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C673 S. 56 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C674 S. 56 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch. Appendix B

C675 S. 56 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C676 S. 56 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C677 S. 56 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C678 S. 56 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C679 S. 56 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C680 S. 56 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C681 S. 56 excluded (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(3)

C682 S. 56 excluded (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(3) (with art. 37)

C683 S. 56 excluded (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(3) (with arts. 4, 5(3))

C684 S. 56 excluded (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(3)

C685 S. 56 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(c) (with art. 37)

C686 S. 56 excluded (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(3) (with arts. 43, 44)

C687 S. 56 excluded (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(3) (with Sch. 8 para. 20)

C688 S. 56 excluded (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(2) (with art. 32(2))

C689 S. 56 excluded (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(3) (with arts. 4, 37)

C690 S. 56 excluded (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(3) (with arts. 55-57, Sch. 8 para. 13)

C691 S. 56 excluded (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(3) (with arts. 58, 59)

C692 S. 56 excluded (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(2) (with arts. 24(8), 33(2))

C693 S. 56 excluded (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(3)

C694 S. 56 excluded (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(3) (with arts. 3(3), 5)

C695 S. 56 excluded (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(3) (with arts. 55, 56)

C696 S. 56 excluded (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(2) (with art. 37(2))

C697 S. 56 excluded (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(3)(a) (with art. 3(1))

C698 S. 56 excluded (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(3) (with arts. 5, 44)

C699 S. 56 excluded (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(3) (with arts. 51, 57)

C700 S. 56 excluded (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(3) (with art. 37)

C701 S. 56 excluded (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(3) (with arts. 5, 44)

C702 S. 56 excluded (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(3) (with art. 5)

C703 S. 56 excluded (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(3)

C704 S. 56 excluded (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(3)(a) (with art. 32, Sch. 9 para. 36)

C705 S. 56(1)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(d)

C706 S. 56(1)(1A) excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(1)

C707 S. 56(1)(1A) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(1)

C708 S. 56(1)(1A) excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(1) (with Sch. 24 para. 2(16))

C709 S. 56(1)(1A) excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(1) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C710 S. 56(1)(1A) restricted (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(1)

[F38 56A Power to give directions as to placing of apparatus E+W

(1) Where—

(a) an undertaker is proposing to execute street works consisting of the placing of apparatus in a street (“street A”),

(b) placing the apparatus in street A is likely to cause disruption to traffic, and

(c) it appears to the street authority that—

(i) there is another street (“street B”) in which the apparatus could be placed, and

(ii) the conditions in subsection (2) are satisfied,

the authority may by direction require the undertaker not to place the apparatus in street A (but may not require him to place the apparatus in street B).

(2) The conditions referred to in subsection (1)(c) are that—

(a) disruption to traffic would be avoided or reduced if the apparatus were to be placed in street B;

(b) placing the apparatus in street B would be a reasonable way of achieving the purpose for which the apparatus is to be placed; and

(c) it is reasonable to require the undertaker not to place the apparatus in street A.

(3) A direction under this section may be varied or revoked by a further such direction.

(4) The procedure for giving a direction under this section shall be prescribed by the Secretary of State.

(5) The Secretary of State may by regulations make provision for appeals against directions under this section, including provision as to the persons who may determine appeals and the procedure to be followed on an appeal.

(6) An undertaker who executes works in contravention of a direction under this section commits an offence and is liable on summary conviction to a fine not exceeding level 5 on the standard scale.

(7) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a direction under this section.

(8) The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the exercise by street authorities of the power conferred by this section; and in exercising that power a street authority shall have regard to the code of practice.]

Textual Amendments

F38 S. 56A inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 44, 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 4); S.I. 2007/3174, art. 2, Sch. (with art. 5)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C711 S. 56A excluded (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(3) (with arts. 65, 66)

C712 S. 56A excluded (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(3) (with art. 43)

C713 S. 56A excluded (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(2) (with arts. 3(3)(6), 12(3))

C714 S. 56A excluded (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(2) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C715 S. 56A excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(2)

C716 S. 56A excluded (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(3) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C717 S. 56A excluded (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(3)

C718 S. 56A excluded (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(2)

C719 S. 56A excluded (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(3) (with arts. 42, 43)

C720 S. 56A excluded (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(3)

C721 S. 56A excluded (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(3) (with arts. 57, 58, Sch. 11 para. 19)

C722 S. 56A excluded (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(2) (with art. 34(2))

C723 S. 56A excluded (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(2) (with art. 31(2))

C724 S. 56A excluded (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(3)

C725 S. 56A excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(2)

C726 S. 56A excluded (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(3)

C727 S. 56A excluded (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(3) (with Sch. 8 para. 45)

C728 S. 56A excluded (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(3)

C729 S. 56A excluded (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(3)

C730 S. 56A excluded (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(3) (with art. 37)

C731 S. 56A excluded (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(3) (with arts. 4, 5(3))

C732 S. 56A excluded (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(3)

C733 S. 56A excluded (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(3) (with arts. 43, 44)

C734 S. 56A excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(2) (with Sch. 24 para. 2(16))

C735 S. 56A excluded (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(3) (with Sch. 8 para. 20)

C736 S. 56A excluded (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(2) (with art. 32(2))

C737 S. 56A excluded (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(3) (with arts. 4, 37)

C738 S. 56A excluded (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(3) (with arts. 55-57, Sch. 8 para. 13)

C739 S. 56A excluded (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(3) (with arts. 58, 59)

C740 S. 56A excluded (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(2) (with arts. 24(8), 33(2))

C741 S. 56A excluded (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(3)

C742 S. 56A excluded (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(3) (with arts. 3(3), 5)

C743 S. 56A excluded (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(3) (with arts. 55, 56)

C744 S. 56A excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(2) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C745 S. 56A excluded (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(2) (with art. 37(2))

C746 S. 56A excluded (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(3)(b) (with art. 3(1))

C747 S. 56A excluded (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(3) (with arts. 5, 44)

C748 S. 56A excluded (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(3) (with arts. 51, 57)

C749 S. 56A excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(2)

C750 S. 56A excluded (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(3) (with art. 37)

C751 S. 56A excluded (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(3) (with arts. 5, 44)

C752 S. 56A excluded (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(3) (with art. 5)

C753 S. 56A excluded (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(3)

C754 S. 56A excluded (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(3)(b) (with art. 32, Sch. 9 para. 36)

57 Notice of emergency works. E+W

(1) Nothing in section 54 (advance notice), section 55 (notice of starting date) or section 56 (directions as to timing of works) [F39 or paragraph 2(1)(d) or 3(1) of Schedule 3A (notification of proposed works or directions as to timings of works)] affects the right of an undertaker to execute emergency works.

(2) An undertaker executing emergency works shall, if the works are of a kind in respect of which notice is [F40 (or would, but for paragraph 2(6) of Schedule 3A, be)] required by section 55, give notice as soon as reasonably practicable, and in any event within two hours (or such other period as may be prescribed) of the works being begun, to the persons to whom notice would be required to be given under that section.

(3) The notice shall state his intention or, as the case may be, the fact that he has begun to execute the works and shall contain such other information as may be prescribed.

(4) An undertaker who fails to give notice in accordance with this section commits an offence and is liable on summary conviction to a fine not exceeding [F41 level 4] on the standard scale.

(5) In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of—

(i) a relevant authority, or

(ii) the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F39 Words in s. 57(1) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 52(3)(a), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F40 Words in s. 57(2) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 52(3)(b), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F41 Words in s. 57(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C755 S. 57 modified (27.11.1992) by S.I. 1992/2984, art. 5

C756 S. 57 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 57 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 57 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 57 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

C757 S. 57 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 57 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C758 S. 57 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C759 S. 57 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C760 S. 57 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C761 S. 57 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C762 S. 57 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C763 S. 57 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C764 S. 57 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C765 S. 57 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C766 S. 57 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C767 S. 57 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(e) (with reg. 35)

C768 S. 57 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C769 S. 57 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C770 S. 57 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(e)

C771 S. 57 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C772 S. 57 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C773 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C774 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C775 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C776 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C777 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C778 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C779 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C780 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C781 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C782 S. 57 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C783 S. 57 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C784 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C785 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C786 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C787 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C788 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C789 S. 57 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C790 S. 57 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C791 S. 57 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C792 S. 57 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C793 S. 57 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C794 S. 57 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C795 S. 57 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C796 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C797 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C798 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C799 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C800 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C801 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C802 S. 57 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C803 S. 57 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C804 S. 57 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C805 S. 57 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C806 S. 57 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C807 S. 57 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C808 S. 57 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C809 S. 57 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C810 S. 57 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C811 S. 57 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C812 S. 57 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix B

C813 S. 57 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix B

C814 S. 57 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix B

C815 S. 57 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix B

C816 S. 57 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C817 S. 57 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C818 S. 57 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C819 S. 57 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C820 S. 57 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C821 S. 57 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C822 S. 57 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch., Appendix C

C823 S. 57 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C824 S. 57 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C825 S. 57 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C826 S. 57 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C827 S. 57 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C828 S. 57 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C829 S. 57 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C830 S. 57 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch., Appendix C

C831 S. 57 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C832 S. 57 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C833 S. 57 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C834 S. 57 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C835 S. 57 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A,

C836 S. 57 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C837 S. 57 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C838 S. 57 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C839 S. 57 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C840 S. 57 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C841 S. 57 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C842 S. 57 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C843 S. 57 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C844 S. 57 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C845 S. 57 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix B

C846 S. 57 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C847 S. 57 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C848 S. 57 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C849 S. 57 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C850 S. 57 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C851 S. 57 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C852 S. 57 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C853 S. 57 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C854 S. 57 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C855 S. 57 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C856 S. 57 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C857 S. 57 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C858 S. 57 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C859 S. 57 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C860 S. 57 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C861 S. 57 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C862 S. 57 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C863 S. 57 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C864 S. 57 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C865 S. 57 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix B

C866 S. 57 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C867 S. 57 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C868 S. 57 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C869 S. 57 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C870 S. 57 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C871 S. 57 disapplied (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C872 S. 57 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C873 S. 57 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C874 S. 57 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C875 S. 57 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C876 S. 57 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C877 S. 57 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C878 S. 57 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C879 S. 57 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C880 S. 57 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(c) (with arts. 37, 38)

C881 S. 57 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C882 S. 57 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(d) (with art. 37)

C883 S. 57 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C884 S. 57 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(c) (with art. 31)

C885 S. 57 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(c) (with art. 22)

C886 S. 57 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C887 S. 57 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C888 S. 57 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)-(6) (with arts. 4, 37)

C889 S. 57 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C890 S. 57 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C891 S. 57 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C892 S. 57 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C893 S. 57 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C894 S. 57 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C895 S. 57 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C896 S. 57 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(c) (with art. 3(1))

C897 S. 57 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C898 S. 57 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C899 S. 57 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C900 S. 57 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C901 S. 57 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C902 S. 57 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(b)(h) (with art. 37)

C903 S. 57 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(b) (with arts. 41, 42, Sch. 16 para. 66)

C904 S. 57 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C905 S. 57 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C906 S. 57 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(c) (with art. 32, Sch. 9 para. 36)

C907 S. 57 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(b) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

58 Restriction on works following substantial road works. E+W

(1) Where it is proposed to carry out substantial road works in a highway, the street authority may by notice in accordance with this section restrict the execution of street works during the [F42 prescribed period] following the completion of those works.

For this purpose substantial road works means works for road purposes, or such works together with other works, of such description as may be prescribed.

(2) The notice shall be published in the prescribed [F43 form and] manner and shall specify the nature and location of the proposed works, the date (not being less than [F44 such period as may be prescribed] after the notice is published, or first published) on which it is proposed to begin the works, and the extent of the restriction.

(3) A copy of the notice shall be given to each of the following—

(a) where there is a public sewer in the part of the highway to which the restriction relates, to the sewer authority,

(b) where the part of the highway to which the restriction relates is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, to that authority,

(c) where in any other case the part of the highway to which the restriction relates is carried or crossed by a bridge, to the bridge authority,

(d) any person who has given notice under section 54 (advance notice of certain works) of his intention to execute street works in the part of the highway to which the restriction relates, F45 ...

(e) any other person having apparatus in the part of the highway to which the restriction relates; [F46 and

(f) any other person of a prescribed description;]

but a failure to do so does not affect the validity of the restriction imposed by the notice.

(4) A notice ceases to be effective if the works to which it relates are not substantially begun [F47 within such period as may be prescribed].

(5) An undertaker shall not in contravention of a restriction imposed by a notice under this section break up or open the part of the highway to which the restriction relates, except—

(a) to execute emergency works,

(b) with the consent of the street authority, or

(c) in such other cases as may be prescribed.

(6) If he does—

(a) he commits an offence and is liable on summary conviction to a fine not exceeding [F48 level 5] on the standard scale, and

(b) [F49 if he is convicted of an offence under this subsection] he is liable to reimburse the street authority any costs reasonably incurred by them in reinstating the highway.

(7) The consent of the street authority under subsection (5)(b) shall not be unreasonably withheld; and any question whether the withholding of consent is unreasonable shall be settled [F50 in the prescribed manner].

[F51 (7A) Regulations under subsection (7) may in particular make provision for the question referred to in that subsection to be settled—

(a) by arbitration;

(b) by a person designated by the Secretary of State on appeal by the undertaker.]

(8) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a restriction imposed by a notice under this section.

Textual Amendments

F42 Words in s. 58(1) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F43 Words in s. 58(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F44 Words in s. 58(2) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F45 Word in s. 58(3) repealed (29.6.2007 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 51(4), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F46 S. 58(3)(f) and word inserted (29.6.2007 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 51(4), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F47 Words in s. 58(4) substituted for s. 58(4)(a)(b) (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(5), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F48 Words in s. 58(6)(a) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F49 Words in s. 58(6)(b) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 51(6), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F50 Words in s. 58(7) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(7), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

F51 S. 58(7A) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 51(8), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 6); S.I. 2007/3174, art. 2, Sch. (with art. 7)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C908 S. 58 restricted (27.11.1992) by S.I. 1992/2984, art. 6

C909 S. 58 excluded (11.11.1996) by S.I. 1996/2714, art. 4(1)

S. 58 excluded (27.8.1998) by S.I. 1998/1936, art. 4(1)

S. 58 excluded (21.5.1997) by S.I. 1997/1266, art. 5(1)

S. 58 excluded (24.7.2001) by S.I. 2001/3627, art. 4(2)

S. 58: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(e)

C910 S. 58 excluded (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(2);

S. 58 excluded (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(1)

C911 S. 58 excluded (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(2)

C912 S. 58 excluded (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(3) (with arts. 65, 66)

C913 S. 58 excluded (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(2)

C914 S. 58 excluded (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(8) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C915 S. 58 excluded (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(2) (with arts. 3(5), 15(3))

C916 S. 58 excluded (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(2) (with art. 52)

C917 S. 58 excluded (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(3) (with art. 43)

C918 S. 58 excluded (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(2) (with arts. 3(3)(6), 12(3))

C919 S. 58 modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(2) (with reg. 35)

C920 S. 58 excluded (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(2) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C921 S. 58 modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(2)

C922 S. 58 excluded (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(3) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C923 S. 58 excluded (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(3)

C924 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C925 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C926 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C927 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C928 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C929 S. 58 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C930 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C931 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C932 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B, Appendix B

C933 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C934 S. 58 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C935 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C936 S. 58 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C937 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C938 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C939 S. 58 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C940 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C941 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C942 S. 58 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C943 S. 58 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C944 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C945 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C946 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C947 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C948 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C949 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C950 S. 58 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C951 S. 58 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C952 S. 58 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C953 S. 58 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C954 S. 58 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C955 S. 58 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C956 S. 58 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C957 S. 58 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C958 S. 58 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C959 S. 58 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix C

C960 S. 58 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C961 S. 58 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C962 S. 58 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C963 S. 58 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C964 S. 58 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C965 S. 58 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C966 S. 58 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C967 S. 58 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C968 S. 58 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C969 S. 58 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C970 S. 58 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch., Appendix C

C971 S. 58 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C972 S. 58 modified (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C973 S. 58 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C974 S. 58 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C975 S. 58 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C976 S. 58 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C977 S. 58 excluded (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(2)

C978 S. 58 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C979 S. 58 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C980 S. 58 excluded (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(3) (with arts. 42, 43)

C981 S. 58 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C982 S. 58 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C983 S. 58 excluded (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(3)

C984 S. 58 excluded (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(3) (with arts. 57, 58, Sch. 11 para. 19)

C985 S. 58 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C986 S. 58 excluded (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(2) (with art. 34(2))

C987 S. 58 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C988 S. 58 excluded (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(2) (with art. 31(2))

C989 S. 58 excluded (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(3)

C990 S. 58 excluded (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(3)

C991 S. 58 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C992 S. 58 excluded (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(3) (with Sch. 8 para. 45)

C993 S. 58 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C994 S. 58 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C995 S. 58 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C996 S. 58 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C997 S. 58 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C998 S. 58 excluded (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(3)

C999 S. 58 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C1000 S. 58 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1001 S. 58 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C1002 S. 58 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1003 S. 58 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1004 S. 58 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C1005 S. 58 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C1006 S. 58 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1007 S. 58 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1 (with Sch. para. 2.7.2)

C1008 S. 58 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1009 S. 58 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1010 S. 58 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C1011 S. 58 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1012 S. 58 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C1013 S. 58 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1014 S. 58 excluded (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(3)

C1015 S. 58 excluded (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(3) (with art. 37)

C1016 S. 58 excluded (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(3) (with arts. 4, 5(3))

C1017 S. 58 excluded (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(3)

C1018 S. 58 excluded (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(3) (with arts. 43, 44)

C1019 S. 58 excluded (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(3) (with Sch. 8 para. 20)

C1020 S. 58 excluded (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(2) (with art. 32(2))

C1021 S. 58 excluded (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(3) (with arts. 4, 37)

C1022 S. 58 excluded (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(3) (with arts. 55-57, Sch. 8 para. 13)

C1023 S. 58 excluded (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(3) (with arts. 58, 59)

C1024 S. 58 excluded (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(2) (with arts. 24(8), 33(2))

C1025 S. 58 excluded (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(3)

C1026 S. 58 excluded (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(3) (with arts. 3(3), 5)

C1027 S. 58 excluded (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(3) (with arts. 55, 56)

C1028 S. 58 excluded (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(2) (with art. 37(2))

C1029 S. 58 excluded (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(3)(c) (with art. 3(1))

C1030 S. 58 excluded (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(3) (with arts. 5, 44)

C1031 S. 58 excluded (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(3) (with arts. 51, 57)

C1032 S. 58 excluded (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(3) (with art. 37)

C1033 S. 58 excluded (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(3) (with arts. 5, 44)

C1034 S. 58 excluded (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(3) (with art. 5)

C1035 S. 58 excluded (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(3)

C1036 S. 58 excluded (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(3)(c) (with art. 32, Sch. 9 para. 36)

C1037 S. 58(1) restricted (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(3)

C1038 S. 58(1) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(3)

C1039 S. 58(1) restricted (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(3) (with Sch. 24 para. 2(16))

C1040 S. 58(1) restricted (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(3)

[F52 58A Restriction on works following substantial street works E+W

Schedule 3A shall have effect.]

Textual Amendments

F52 S. 58A inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 52(1), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 7); S.I. 2007/3174, art. 2, Sch. (with art. 8)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1041 S. 58A excluded (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(3) (with arts. 65, 66)

C1042 S. 58A excluded (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(3) (with art. 43)

C1043 S. 58A excluded (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(2) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1044 S. 58A excluded (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(3) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1045 S. 58A excluded (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(3)

C1046 S. 58A modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C1047 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C1048 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C1049 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C1050 S. 58A modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C1051 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C1052 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C1053 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C1054 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C1055 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C1056 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C1057 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C1058 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C1059 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B, Appendix B

C1060 S. 58A modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C1061 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C1062 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C1063 S. 58A modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C1064 S. 58A modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C1065 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C1066 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C1067 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C1068 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C1069 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C1070 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C1071 S. 58A modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C1072 S. 58A modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C1073 S. 58A modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C1074 S. 58A modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C1075 S. 58A modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C1076 S. 58A modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C1077 S. 58A modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C1078 S. 58A modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C1079 S. 58A modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C1080 S. 58A modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C1081 S. 58A modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C1082 S. 58A modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C1083 S. 58A modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch., Appendix C

C1084 S. 58A modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C1085 S. 58A modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C1086 S. 58A modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C1087 S. 58A modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C1088 S. 58A modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C1089 S. 58A modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch., Appendix C

C1090 S. 58A modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C1091 S. 58A modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C1092 S. 58A modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C1093 S. 58A modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C1094 S. 58A modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C1095 S. 58A modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch., Appendix C

C1096 S. 58A modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C1097 S. 58A excluded (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(3) (with arts. 42, 43)

C1098 S. 58A excluded (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(3)

C1099 S. 58A excluded (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(3) (with arts. 57, 58, Sch. 11 para. 19)

C1100 S. 58A modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C1101 S. 58A excluded (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(2) (with art. 34(2))

C1102 S. 58A modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C1103 S. 58A excluded (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(3)

C1104 S. 58A excluded (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(3)

C1105 S. 58A modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C1106 S. 58A excluded (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(3) (with Sch. 8 para. 45)

C1107 S. 58A modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C1108 S. 58A modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C1109 S. 58A modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch., Appendix E

C1110 S. 58A excluded (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(3)

C1111 S. 58A modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1112 S. 58A modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1113 S. 58A modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1114 S. 58A modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1115 S. 58A modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C1116 S. 58A modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C1117 S. 58A modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1118 S. 58A modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C1119 S. 58A modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. 1 para. 2.8.2Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1120 S. 58A modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C1121 S. 58A modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1122 S. 58A modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1123 S. 58A excluded (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(3)

C1124 S. 58A excluded (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(3) (with art. 37)

C1125 S. 58A excluded (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(3) (with arts. 4, 5(3))

C1126 S. 58A excluded (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(3)

C1127 S. 58A excluded (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(3) (with arts. 43, 44)

C1128 S. 58A excluded (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(3) (with Sch. 8 para. 20)

C1129 S. 58A excluded (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(3) (with arts. 4, 37)

C1130 S. 58A excluded (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(3) (with arts. 55-57, Sch. 8 para. 13)

C1131 S. 58A excluded (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(3) (with arts. 58, 59)

C1132 S. 58A excluded (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(3)

C1133 S. 58A excluded (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(3) (with arts. 3(3), 5)

C1134 S. 58A excluded (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(3) (with arts. 55, 56)

C1135 S. 58A excluded (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(3)(d) (with art. 3(1))

C1136 S. 58A excluded (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(3) (with arts. 5, 44)

C1137 S. 58A excluded (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(3) (with arts. 51, 57)

C1138 S. 58A excluded (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(3) (with art. 37)

C1139 S. 58A excluded (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(3) (with arts. 5, 44)

C1140 S. 58A excluded (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(3) (with art. 5)

C1141 S. 58A excluded (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(3)

C1142 S. 58A excluded (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(3)(d) (with art. 32, Sch. 9 para. 36)

59 General duty of street authority to co-ordinate works. E+W

(1) A street authority shall use their best endeavours to co-ordinate the execution of works of all kinds (including works for road purposes) [F53 and the carrying out of relevant activities] in the streets for which they are responsible—

(a) in the interests of safety,

(b) to minimise the inconvenience to persons using the street (having regard, in particular, to the needs of people with a disability), and

(c) to protect the structure of the street and the integrity of apparatus in it.

(2) That duty extends to co-ordination with other street authorities where works [F54 or relevant activities] in a street for which one authority are responsible affect streets for which other authorities are responsible.

(3) The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned above; and in discharging their general duty of co-ordination a street authority shall have regard to any such code of practice.

(4) If it appears to the Secretary of State that a street authority are not properly discharging their general duty of co-ordination, he may direct the authority to supply him with such information as he considers necessary to enable him to decide whether that is the case and if so what action to take.

The direction shall specify the information to be provided and the period within which it is to be provided.

(5) If after the end of that period (whether or not the direction has been complied with) it appears to the Secretary of State that the authority are not properly discharging their general duty of co-ordination, he may direct the authority to take such steps as he considers appropriate for the purpose of discharging that duty.

The direction shall specify the steps to be taken and the period within which they are to be taken, and may include a requirement to make a report or periodic reports to the Secretary of State as to what steps have been taken and the results of taking them.

(6) A direction under this section may be varied or revoked by a further direction.

[F55 (7) In this section “relevant activities” means any activity, other than the execution of works in the street or the use of the street by traffic (including pedestrians), which—

(a) involves the temporary occupation or use of space in a street;

(b) is subject to regulation by the street authority by virtue of provision made by or under any Act other than this Act; and

(c) is prescribed by regulations made by the Secretary of State.]

Textual Amendments

F53 Words in s. 59(1) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(2), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F54 Words in s. 59(2) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(3), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F55 S. 59(7) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes) by Traffic Management Act 2004 (c. 18), ss. 42(4), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1143 S. 59 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 59 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 59 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 59 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 59 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 59 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 59 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 59 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 59 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 59 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 59: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(c)

S. 59 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 59 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 59 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 59 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 59 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1144 S. 59 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38);

S. 59 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 59 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1145 S. 59 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1146 S. 59 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1147 S. 59 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1148 S. 59 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1149 S. 59 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)(4) (with art. 51)

C1150 S. 59 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C1151 S. 59 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)(4) (with art. 47)

C1152 S. 59 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1153 S. 59 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1154 Ss. 59, 60 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1155 S. 59 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1156 S. 59 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1157 S. 59 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1158 S. 59 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C1159 S. 59 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1160 S. 59 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1161 S. 59 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1162 S. 59 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1163 S. 59 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1164 S. 59 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)(3) (with arts. 19, 28, Sch. 3 para. 13(2))

C1165 S. 59 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1166 S. 59 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1167 S. 59 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1168 S. 59 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1169 S. 59 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1170 S. 59 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1171 S. 59 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1172 S. 59 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1173 S. 59 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1174 S. 59 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1175 S. 59 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1176 S. 59 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1177 S. 59 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1178 S. 59 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1179 S. 59 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1180 S. 59 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1181 S. 59 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1182 S. 59 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1183 S. 59 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1184 S. 59 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1185 S. 59 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1186 S. 59 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1187 S. 59 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1188 S. 59 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1189 S. 59 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1190 S. 59 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1191 S. 59 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1192 S. 59 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1193 S. 59 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1194 S. 59 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1195 S. 59 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1196 S. 59 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)(4) (with art. 39)

C1197 S. 59 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1198 S. 59 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(d) (with arts. 37, 38)

C1199 S. 59 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1200 S. 59 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(e) (with art. 37)

C1201 S. 59 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1202 S. 59 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(d) (with art. 31)

C1203 S. 59 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(d) (with art. 22)

C1204 S. 59 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1205 S. 59 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1206 S. 59 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1207 S. 59 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1208 S. 59 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1209 S. 59 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C1210 S. 59 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1211 S. 59 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C1212 S. 59 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1213 S. 59 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1214 S. 59 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C1215 S. 59 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(d) (with art. 3(1))

C1216 S. 59 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C1217 S. 59 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1218 S. 59 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1219 S. 59 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1220 S. 59 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1221 S. 59 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1222 S. 59 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1223 S. 59 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(d) (with art. 32, Sch. 9 para. 36)

C1224 S. 59 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C1225 S. 59 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

Commencement Information

I4 S. 59 wholly in force: s. 59(1)(2)(4)-(6) in force at 1.1.1993, see s. 170 and S.I. 1992/2984, art. 2(2), Sch. 2; s. 59(3) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

60 General duty of undertakers to co-operate. E+W

(1) An undertaker shall as regards the execution of street works use his best endeavours to co-operate with the street authority and with other undertakers—

(a) in the interests of safety,

(b) to minimise the inconvenience to persons using the street (having regard, in particular, to the needs of people with a disability), and

(c) to protect the structure of the street and the integrity of apparatus in it.

(2) The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with his duty under that subsection, and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that duty.

(3) An undertaker who fails to comply with his duty under subsection (1) commits an offence and is liable on summary conviction to a fine not exceeding [F56 level 5] on the standard scale.

Textual Amendments

F56 Words in s. 60(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1154 Ss. 59, 60 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1226 S. 60 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 60 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 60 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 60 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 60 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 60 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 60 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 60 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 60 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 60 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 60 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 60 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 60 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 60 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 60 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1227 S. 60 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38);

S. 60 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 60 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1228 S. 60 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1229 S. 60 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1230 S. 60 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1231 S. 60 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1232 S. 60 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)(4) (with art. 51)

C1233 S. 60 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C1234 S. 60 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)(4) (with art. 47)

C1235 S. 60 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1236 S. 60 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1237 S. 60 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1238 S. 60 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1239 S. 60 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1240 S. 60 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C1241 S. 60 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1242 S. 60 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1243 S. 60 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1244 S. 60 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1245 S. 60 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1246 S. 60 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)(3) (with arts. 19, 28, Sch. 3 para. 13(2))

C1247 S. 60 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1248 S. 60 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1249 S. 60 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1250 S. 60 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1251 S. 60 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1252 S. 60 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1253 S. 60 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1254 S. 60 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1255 S. 60 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1256 S. 60 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1257 S. 60 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1258 S. 60 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1259 S. 60 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1260 S. 60 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1261 S. 60 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1262 S. 60 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1263 S. 60 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1264 S. 60 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1265 S. 60 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1266 S. 60 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1267 S. 60 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1268 S. 60 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1269 S. 60 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1270 S. 60 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1271 S. 60 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1272 S. 60 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1273 S. 60 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1274 S. 60 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1275 S. 60 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1276 S. 60 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1277 S. 60 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1278 S. 60 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)(4) (with art. 39)

C1279 S. 60 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1280 S. 60 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(e) (with arts. 37, 38)

C1281 S. 60 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1282 S. 60 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(f) (with art. 37)

C1283 S. 60 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1284 S. 60 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(e) (with art. 31)

C1285 S. 60 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(e) (with art. 22)

C1286 S. 60 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1287 S. 60 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1288 S. 60 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1289 S. 60 applied (with modifications) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1290 S. 60 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1291 S. 60 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C1292 S. 60 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1293 S. 60 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C1294 S. 60 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1295 S. 60 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1296 S. 60 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C1297 S. 60 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(e) (with art. 3(1))

C1298 S. 60 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C1299 S. 60 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1300 S. 60 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1301 S. 60 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1302 S. 60 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1303 S. 60 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(c)(h) (with art. 37)

C1304 S. 60 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(c) (with arts. 41, 42, Sch. 16 para. 66)

C1305 S. 60 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1306 S. 60 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1307 S. 60 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(e) (with art. 32, Sch. 9 para. 36)

C1308 S. 60 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C1309 S. 60 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

C1310 S. 60 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(c) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

C1311 S. 60(1): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(g)

Commencement Information

I5 S. 60 wholly in force: s. 60(1)(3) in force at 1.1.1993 see s. 170 and S.I. 1992/2984, art. 2(2), Sch. 2; s. 60(2) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

Streets subject to special controls E+W

61 Protected streets. E+W

(1) The consent of the street authority is required for the placing of apparatus by an undertaker in a protected street, except as mentioned below.

The following are “protected streets” for this purpose—

(a) any highway or proposed highway which is a special road in accordance with section 16 of the M26 Highways Act 1980, and

(b) any street designated by the street authority as protected.

(2) Consent is not required for the placing of apparatus—

(a) by way of renewal of existing apparatus, or

(b) in pursuance of a street works licence,

unless, in the latter case, the licence was granted before the street became a protected street.

(3) The street authority may require the payment of—

(a) a reasonable fee in respect of the legal or other expenses incurred in connection with the giving of their consent under this section, and

(b) an annual fee of a reasonable amount for administering the consent;

and any such fee is recoverable from the undertaker.

This shall not be construed as affecting any right of the authority where they own the land on which the street is situated to grant for such consideration as they think fit the right to place anything in, under or over the land.

(4) Where the apparatus is to be placed crossing the protected street and not running along it, the street authority shall not withhold their consent unless there are special reasons for doing so.

(5) Consent to the placing of apparatus in a protected street may be given subject to conditions; and the street authority may agree to contribute to the expenses incurred by the undertaker in complying with the conditions.

(6) Any dispute between a street authority and an undertaker as to the withholding of consent, the imposition of conditions, or the making of contributions shall be settled by arbitration.

(7) An undertaker having a statutory duty to afford a supply or service shall not be regarded as in breach of that duty if, or to the extent that, it is not reasonably practicable to afford a supply or service by reason of anything done by the street authority in exercise of their functions under this section.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1312 S. 61 modified (27.11.1992) by S.I. 1992/2984, art. 7

S. 61: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(h)

C1313 S. 61 modified (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 20 (with art. 52)

C1314 S. 61 excluded (E.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (England) Regulations 2007 (S.I. 2007/1951), regs. 1(1), 13(2)(b) (with reg. 19)

C1315 S. 61 excluded (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) Regulations 2008 (S.I. 2008/101), regs. 1, 13 (with reg. 19)

C1316 S. 61(1) excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(4)

C1317 S. 61(1) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(4)

C1318 S. 61(1) excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(4) (with Sch. 24 para. 2(16))

C1319 S. 61(1) excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(4) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C1320 S. 61(1) excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(4)

C1321 S. 61(3) excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(7)

Marginal Citations

M26 1980 c. 66.

62 Supplementary provisions as to designation of protected streets. E+W

(1) The Secretary of State may prescribe—

(a) the criteria for designating a street as protected,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a street authority as to the streets for the time being so designated by them.

(2) Where a street has been designated as protected the street authority may direct an undertaker to remove or change the position of apparatus placed in the street at a time when it was not so designated.

The authority shall indemnify the undertaker in respect of his reasonable expenses in complying with such a direction.

(3) Where a designation is withdrawn the street authority may give such directions as they consider appropriate as to—

(a) the continuance in force of any conditions subject to which consent was given for the placing of apparatus in the street, and

(b) the continuance of entitlement to any contributions in respect of the expenses of an undertaker in complying with such conditions.

(4) Where a designation is made or withdrawn the street authority may give such directions as they consider appropriate with respect to works in progress in the street when the designation comes into force or ceases to have effect.

(5) Any dispute between a street authority and an undertaker as to the exercise by the authority of their powers under subsection (2), (3) or (4) shall be settled by arbitration.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1322 S. 62(2) excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(5)

C1323 S. 62(2) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(5)

C1324 S. 62(2) excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(5) (with Sch. 24 para. 2(16))

C1325 S. 62(2) excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(5) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C1326 S. 62(2) excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(5)

C1327 S. 62(4) excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(6)

C1328 S. 62(4) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(6)

C1329 S. 62(4) excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(6) (with Sch. 24 para. 2(16))

C1330 S. 62(4) excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(6) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C1331 S. 62(4) excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(6)

63 Streets with special engineering difficulties. E+W

(1) The provisions of Schedule 4 have effect for requiring the settlement of a plan and section of street works to be executed in a street designated by the street authority as having special engineering difficulties.

(2) The Secretary of State may prescribe—

(a) the criteria for designating a street as having special engineering difficulties,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a street authority as to the streets for the time being so designated by them.

(3) Where [F57 a strategic highways company or] a local highway authority are asked to designate a street as having special engineering difficulties—

(a) by a transport authority on the ground of the proximity of the street to a structure belonging to, or under the management or control of, the authority, or

(b) by an undertaker having apparatus in the street,

and decline to do so, the transport authority or undertaker may appeal to the Secretary of State who may direct that the street be designated.

(4) The designation of a street as having special engineering difficulties shall not be withdrawn except after consultation with any transport authority or undertaker at whose request the designation was made; and a designation made in pursuance of a direction by the Secretary of State shall not be withdrawn except with his consent.

[F58 (5) In addition to criteria for designation prescribed under subsection (2)(a), Schedule 3 to the Flood and Water Management Act 2010 requires designation in certain circumstances (relating to sustainable drainage systems).]

Textual Amendments

F57 Words in s. 63(3) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 118; S.I. 2015/481, reg. 2(a)

F58 S. 63(5) inserted (2.5.2018 for W. for specified purposes, 7.1.2019 for W. in so far as not already in force) by Flood and Water Management Act 2010 (c. 29), s. 49(3), Sch. 3 para. 27 (with s. 49(1)(6)); S.I. 2018/557, arts. 2(b), 3(b)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1332 S. 63(1) excluded (22.7.2008) by Crossrail Act 2008 (c. 18), Sch. 14 para. 14(7)

C1333 S. 63(1) excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(7)

C1334 S. 63(1) excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(7) (with Sch. 24 para. 2(16))

C1335 S. 63(1) excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(7) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

64 Traffic-sensitive streets. E+W

(1) Regulations made for the purposes of section 54, 55 or 57 (notices required to be given in respect of street works) [F59 or paragraph 2 of Schedule 3A] may make special provision in relation to street works in a street designated by the street authority as traffic-sensitive.

(2) The Secretary of State may prescribe—

(a) the criteria for designating a street as traffic-sensitive,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a street authority as to the streets for the time being so designated by them.

(3) If it appears to the street authority that the prescribed criteria are met only at certain times or on certain dates, a limited designation may be made accordingly.

In such a case the reference in subsection (1) to the execution of works in a street designated as traffic-sensitive shall be construed as a reference to works so executed at those times or on those dates.

[F60 (4) Where any council of a London borough or the Common Council of the City of London are asked by the Traffic Director for London to designate a street as a traffic-sensitive street and they decline to do so, the Director may appeal to the Secretary of State who may direct that the street be designated.]

Textual Amendments

F59 Words in s. 64(1) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 52(4), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F60 S. 64(4) added (10.4.1998) by Road Traffic Act 1991 (c. 40, SIF 107:1), s. 81, Sch. 7 para.12; S.I. 1998/967, art. 2(1)(a)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1336 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C1337 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C1338 S. 64 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C1339 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C1340 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C1341 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C1342 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C1343 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C1344 S. 64 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C1345 S. 64 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C1346 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C1347 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C1348 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C1349 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C1350 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C1351 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C1352 S. 64 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C1353 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C1354 S. 64 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C1355 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C1356 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C1357 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C1358 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C1359 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C1360 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C1361 S. 64 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C1362 S. 64 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C1363 S. 64 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C1364 S. 64 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C1365 S. 64 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C1366 S. 64 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C1367 S. 64 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C1368 S. 64 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C1369 S. 64 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C1370 S. 64 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix C

C1371 S. 64 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix C

C1372 S. 64 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch., Appendix C

C1373 S. 64 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C1374 S. 64 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C1375 S. 64 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C1376 S. 64 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C1377 S. 64 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C1378 S. 64 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C1379 S. 64 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C1380 S. 64 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C1381 S. 64 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C1382 S. 64 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C1383 S. 64 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch., Appendix E

C1384 S. 64 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1385 S. 64 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1386 S. 64 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C1387 S. 64 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1388 S. 64 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C1389 S. 64 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1390 S. 64 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C1391 S. 64 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C1392 S. 64 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C1393 S. 64 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1394 S. 64 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1395 S. 64 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

General requirements as to execution of street works E+W

65 Safety measures. E+W

(1) An undertaker executing street works shall secure—

(a) that any part of the street which is broken up or open, or is obstructed by plant or materials used or deposited in connection with the works, is adequately guarded and lit, and

(b) that such traffic signs are placed and maintained, and where necessary operated, as are reasonably required for the guidance or direction of persons using the street,

having regard, in particular, to the needs of people with a disability.

(2) In discharging in relation to a highway his duty with respect to the placing, maintenance or operation of traffic signs, an undertaker shall comply with any directions given by the traffic authority.

The power of the traffic authority to give directions under this subsection is exercisable subject to any directions given by the Secretary of State under section 65 of the M27 Road Traffic Regulation Act 1984.

(3) The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with that subsection; and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that subsection.

(4) An undertaker who fails to comply with subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F61 level 5] on the standard scale.

(5) If it appears to the street authority that an undertaker has failed to comply with subsection (1) or (2), they may take such steps as appear to them necessary and may recover from the undertaker the costs reasonably incurred by them in doing so.

(6) If a person without lawful authority or excuse—

(a) takes down, alters or removes any fence, barrier, traffic sign or light erected or placed in pursuance of subsection (1) or (2) above, or

(b) extinguishes a light so placed,

he commits an offence and is liable on summary conviction to a fine not exceeding [F62 level 5] on the standard scale.

Textual Amendments

F61 Words in s. 65(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

F62 Words in s. 65(6) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1396 S. 65 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1397 S. 65 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(g) (with art. 37)

C1398 S. 65(2)(5): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 paras. 1(i), 2

Commencement Information

I6 S. 65 wholly in force: s. 65(1)(2)(4)-(6) in force at 1.4.1993 see s. 170(1) and S.I. 1992/2984, art. 2(3), Sch. 3; s. 65(3) in force at 14.7.1992 by S.I. 1992/1686, art. 2, Sch.

Marginal Citations

M27 1984 c. 27.

66 Avoidance of unnecessary delay or obstruction. E+W

(1) An undertaker executing street works which involve—

(a) breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the street,

shall carry on and complete the works with all such dispatch as is reasonably practicable.

(2) An undertaker who fails to do so commits an offence and is liable on summary conviction to a fine not exceeding [F63 level 5] on the standard scale.

(3) Where an undertaker executing any street works creates an obstruction in a street to a greater extent or for a longer period than is reasonably necessary, the street authority may by notice require him to take such reasonable steps as are specified in the notice to mitigate or discontinue the obstruction.

(4) If the undertaker fails to comply with such a notice within 24 hours of receiving it, or any longer period specified in the notice, the authority may take the necessary steps and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F63 Words in s. 66(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1399 S. 66 excluded (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 36(f) (with reg. 35)

C1400 S. 66 disapplied (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 36(f)

C1401 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C1402 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C1403 S. 66 disapplied (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C1404 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C1405 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C1406 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C1407 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C1408 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C1409 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C1410 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C1411 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C1412 S. 66 disapplied (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C1413 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C1414 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C1415 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C1416 S. 66 disapplied (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C1417 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C1418 S. 66 disapplied (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C1419 S. 66 disapplied (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B, Appendix B

C1420 S. 66 disapplied (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C1421 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C1422 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C1423 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C1424 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C1425 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C1426 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C1427 S. 66 disapplied (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C1428 S. 66 disapplied (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C1429 S. 66 disapplied (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C1430 S. 66 disapplied (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C1431 S. 66 disapplied (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C1432 S. 66 disapplied (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C1433 S. 66 disapplied (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C1434 S. 66 disapplied (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C1435 S. 66 disapplied (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C1436 S. 66 disapplied (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix B

C1437 S. 66 disapplied (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix B

C1438 S. 66 disapplied (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix B

C1439 S. 66 disapplied (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix B

C1440 S. 66 disapplied (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C1441 S. 66 disapplied (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C1442 S. 66 disapplied (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C1443 S. 66 disapplied (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C1444 S. 66 disapplied (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C1445 S. 66 disapplied (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C1446 S. 66 disapplied (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C1447 S. 66 disapplied (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C1448 S. 66 disapplied (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C1449 S. 66 disapplied (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C1450 S. 66 disapplied (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C1451 S. 66 disapplied (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C1452 S. 66 disapplied (29.4.2013) by The Traffic Management (Trafford Borough Council) Permit Scheme Order 2013 (S.I. 2013/807), arts. 1, 2, Sch. Appendix C

C1453 S. 66 disapplied (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C1454 S. 66 disapplied (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C1455 S. 66 disapplied (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C1456 S. 66 disapplied (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C1457 S. 66 disapplied (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C1458 S. 66 disapplied (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C1459 S. 66 disapplied (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix B

C1460 S. 66 disapplied (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C1461 S. 66 disapplied (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C1462 S. 66 disapplied (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C1463 S. 66 disapplied (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C1464 S. 66 disapplied (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C1465 S. 66 disapplied (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C1466 S. 66 disapplied (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C1467 S. 66 disapplied (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1468 S. 66 disapplied (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C1469 S. 66 disapplied (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1470 S. 66 disapplied (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1471 S. 66 disapplied (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix B

C1472 S. 66 disapplied (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1473 S. 66 disapplied (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix B

C1474 S. 66 disapplied (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C1475 S. 66 disapplied (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C1476 S. 66 disapplied (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C1477 S. 66 disapplied (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1478 S. 66 disapplied (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1479 S. 66 disapplied (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C1480 S. 66 disapplied (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C1481 S. 66(3)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(j)

67 Qualifications of supervisors and operatives. E+W

(1) It is the duty of an undertaker executing street works involving—

(a) breaking up the street, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the street,

to secure that, except in such cases as may be prescribed, the execution of the works is supervised by a person having a prescribed qualification as a supervisor.

(2) It is the duty of an undertaker executing street works involving—

(a) breaking up or opening the street, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the street,

to secure that, except in such cases as may be prescribed, there is on site at all times when any such works are in progress at least one person having a prescribed qualification as a trained operative.

(3) An undertaker who fails to comply with his duty under subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F64 level 5] on the standard scale.

(4) Regulations made by the Secretary of State for the purposes of this section may include provision with respect to—

(a) the approval of bodies conferring qualifications (and the withdrawal of such approval), and

(b) the circumstances in which a qualification may be conferred.

Textual Amendments

F64 Words in s. 67(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1482 S. 67 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1483 S. 67 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(h) (with art. 37)

C1484 S. 67(2) excluded (E.) (6.4.2017) by The Street Works (Qualifications of Operatives and Supervisors) (England) Regulations 2016 (S.I. 2016/1147), regs. 1(c), 14(2) (with reg. 14(1))

68 Facilities to be afforded to street authority. E+W

(1) An undertaker executing street works shall afford the street authority reasonable facilities for ascertaining whether he is complying with his duties under this Part.

(2) An undertaker who fails to afford the street authority such facilities commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F65 level 4] on the standard scale.

Textual Amendments

F65 Words in s. 68(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1485 S. 68 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 68 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 68 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 68 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

C1486 S. 68 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 68 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1487 S. 68 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1488 S. 68 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1489 S. 68 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1490 Ss. 68, 69 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1491 S. 68 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1492 S. 68 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1493 S. 68 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1494 S. 68 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1495 S. 68 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1496 S. 68 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1497 S. 68 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1498 S. 68 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1499 S. 68 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1500 S. 68 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1501 S. 68 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1502 S. 68 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1503 S. 68 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1504 S. 68 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1505 S. 68 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1506 S. 68 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1507 S. 68 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1508 S. 68 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1509 S. 68 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1510 S. 68 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1511 S. 68 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1512 S. 68 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1513 S. 68 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1514 S. 68 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1515 S. 68 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1516 S. 68 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1517 S. 68 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1518 S. 68 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1519 S. 68 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1520 S. 68 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1521 S. 68 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1522 S. 68 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1523 S. 68 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1524 S. 68 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1525 S. 68 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1526 S. 68 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1527 S. 68 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1528 S. 68 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(f) (with arts. 37, 38)

C1529 S. 68 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1530 S. 68 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(i) (with art. 37)

C1531 S. 68 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1532 S. 68 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(f) (with art. 31)

C1533 S. 68 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(f) (with art. 22)

C1534 S. 68 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1535 S. 68 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1536 S. 68 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1537 S. 68 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1538 S. 68 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1539 S. 68 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C1540 S. 68 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1541 S. 68 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C1542 S. 68 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1543 S. 68 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1544 S. 68 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C1545 S. 68 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(f) (with art. 3(1))

C1546 S. 68 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C1547 S. 68 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1548 S. 68 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1549 S. 68 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1550 S. 68 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1551 S. 68 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(d)(h) (with art. 37)

C1552 S. 68 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(d) (with arts. 41, 42, Sch. 16 para. 66)

C1553 S. 68 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1554 S. 68 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1555 S. 68 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(f) (with art. 32, Sch. 9 para. 36)

C1556 S. 68 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C1557 S. 68 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

C1558 S. 68 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(d) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

C1559 S. 68: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(k)

69 Works likely to affect other apparatus in the street. E+W

(1) Where street works are likely to affect another person’s apparatus in the street, the undertaker executing the works shall take all reasonably practicable steps—

(a) to give the person to whom the apparatus belongs reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by him which is reasonably necessary for the protection of the apparatus or for securing access to it.

(2) An undertaker who fails to comply with subsection (1) commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F66 level 4] on the standard scale.

(3) In proceedings against a person for such an offence it is a defence for him to show that the failure was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F66 Words in s. 69(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1490 Ss. 68, 69 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1560 S. 69 excluded (27.11.1992) by S.I. 1992/2984, art. 8

C1561 S. 69 modified (1.1.1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7)(as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2984, art. 2(2), Sch.2)

S. 69 modified (1.1.1993) by Local Government (Miscellaneous Provisions) Act 1976 (c. 57), s. 15(4) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 106; S.I. 1992/2984, art. 2(2), Sch.2)

C1562 S. 69 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 69 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 69 applied (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 69 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 69 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 69 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 69 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 69 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 69 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 69 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 69 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 69 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 69 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 69 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 69 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1563 S. 69 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38);

S. 69 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 69 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1564 S. 69 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1565 S. 69 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1566 S. 69 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1567 S. 69 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1568 S. 69 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)(4) (with art. 51)

C1569 S. 69 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C1570 S. 69 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)(4) (with art. 47)

C1571 S. 69 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1572 S. 69 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1573 S. 69 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1574 S. 69 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1575 S. 69 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1576 S. 69 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C1577 S. 69 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1578 S. 69 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1579 S. 69 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1580 S. 69 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1581 S. 69 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1582 S. 69 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)(3) (with arts. 19, 28, Sch. 3 para. 13(2))

C1583 S. 69 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1584 S. 69 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1585 S. 69 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1586 S. 69 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1587 S. 69 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C1588 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C1589 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C1590 S. 69 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C1591 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C1592 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C1593 S. 69 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C1594 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C1595 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C1596 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C1597 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C1598 S. 69 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C1599 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C1600 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C1601 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C1602 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C1603 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C1604 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C1605 S. 69 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C1606 S. 69 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1607 S. 69 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1608 S. 69 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1609 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C1610 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C1611 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C1612 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C1613 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C1614 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C1615 S. 69 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C1616 S. 69 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C1617 S. 69 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C1618 S. 69 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C1619 S. 69 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C1620 S. 69 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C1621 S. 69 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C1622 S. 69 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C1623 S. 69 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C1624 S. 69 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1625 S. 69 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch., Appendix C

C1626 S. 69 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C1627 S. 69 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C1628 S. 69 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C1629 S. 69 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1630 S. 69 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1631 S. 69 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C1632 S. 69 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C1633 S. 69 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C1634 S. 69 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C1635 S. 69 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1636 S. 69 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1637 S. 69 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1638 S. 69 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1639 S. 69 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1640 S. 69 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1641 S. 69 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1642 S. 69 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C1643 S. 69 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1644 S. 69 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C1645 S. 69 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1646 S. 69 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1647 S. 69 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1648 S. 69 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1649 S. 69 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1650 S. 69 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C1651 S. 69 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1652 S. 69 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1653 S. 69 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C1654 S. 69 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C1655 S. 69 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch., Appendix E

C1656 S. 69 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1657 S. 69 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1658 S. 69 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1659 S. 69 extended (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1660 S. 69 extended (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1661 S. 69 extended (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C1662 S. 69 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C1663 S. 69 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C1664 S. 69 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C1665 S. 69 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C1666 S. 69 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1667 S. 69 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1668 S. 69 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C1669 S. 69 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1670 S. 69 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1671 S. 69 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1672 S. 69 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1673 S. 69 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1674 S. 69 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)(4) (with art. 39)

C1675 S. 69 applied (13.7.2016) by Housing and Planning Act 2016 (c. 22), ss. 175(3)(4), 216(3); S.I. 2016/733, reg. 3(h)

C1676 S. 69 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1677 S. 69 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(g) (with arts. 37, 38)

C1678 S. 69 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1679 S. 69 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(j) (with art. 37)

C1680 S. 69 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1681 S. 69 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(g) (with art. 31)

C1682 S. 69 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(g) (with art. 22)

C1683 S. 69 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1684 S. 69 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1685 S. 69 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1686 S. 69 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1687 S. 69 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1688 S. 69 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C1689 S. 69 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1690 S. 69 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C1691 S. 69 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1692 S. 69 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1693 S. 69 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(g) (with art. 3(1))

C1694 S. 69 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C1695 S. 69 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1696 S. 69 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1697 S. 69 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1698 S. 69 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1699 S. 69 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(e)(h) (with art. 37)

C1700 S. 69 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(e) (with arts. 41, 42, Sch. 16 para. 66)

C1701 S. 69 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1702 S. 69 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1703 S. 69 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(g) (with art. 32, Sch. 9 para. 36)

C1704 S. 69 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C1705 S. 69 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

C1706 S. 69 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(e) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

Reinstatement E+W

70 Duty of undertaker to reinstate. E+W

(1) It is the duty of the undertaker by whom street works are executed to reinstate the street.

[F67 (1A) The reinstatement required by subsection (1) may be permanent or interim.]

(2) He shall begin the reinstatement as soon after the completion of any part of the street works as is reasonably practicable and shall carry on and complete the reinstatement with all such dispatch as is reasonably practicable.

[F68 (3) He shall within [F69 10] working days from the date on which the reinstatement is completed give notice to the street authority of that completion—

(a) stating whether the reinstatement is permanent or interim; and

(b) giving such other information about the reinstatement as may be prescribed.

(4) If the reinstatement is interim, he shall complete the permanent reinstatement of the street as soon as reasonably practicable, and in any event within 6 months from the date on which the interim reinstatement was completed.

(4A) He shall, within [F70 10] working days from the date on which the permanent reinstatement required by subsection (4) is completed, give notice to the street authority of that completion, giving such other information about the reinstatement as may be prescribed.

(4B) The Secretary of State may by regulations modify the period specified in subsection (3), (4) or (4A).]

(5) The permanent reinstatement of the street shall include, in particular, the reinstatement of features designed to assist people with a disability.

(6) An undertaker who fails to comply with any provision of this section commits an offence and is liable on summary conviction—

[F71 (a) in the case of an offence consisting of a failure to comply with subsection (3) or (4A), to a fine not exceeding level 4 on the standard scale; and

(b) in any other case, to a fine not exceeding level 5 on that scale.]

(7) In proceedings against a person for an offence of failing to comply with subsection (2) it is a defence for him to show that any delay in reinstating the street was in order to avoid hindering the execution of other works, or other parts of the same works, to be undertaken immediately or shortly thereafter.

Textual Amendments

F67 S. 70(1A) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 54(2), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 8); S.I. 2007/3174, art. 2, Sch. (with art. 9)

F68 S. 70(3)-(4B) substituted for s. 70(3)(4) (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 54(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 8); S.I. 2007/3174, art. 2, Sch. (with art. 9)

F69 Word in s. 70(3) substituted (E.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (England) Regulations 2007 (S.I. 2007/1951), regs. 1(1), 17 (with reg. 19); and word in s. 70(3) substituted (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) Regulations 2008 (S.I. 2008/101), regs. 1, 17(2) (with reg. 19)

F70 Word in s. 70(4A) substituted (E.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (England) Regulations 2007 (S.I. 2007/1951), regs. 1(1), 17 (with reg. 19); and word in s. 70(4A) substituted (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) Regulations 2008 (S.I. 2008/101), regs. 1, 17(2) (with reg. 19)

F71 S. 70(6)(a)(b) substituted for words in s. 70(6) (4.10.2004 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 40(3), 99(1); S.I. 2004/2380, art. 2(d)(ii) (with art. 3); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1707 S. 70 excluded (27.11.1992) by S.I. 1992/2984, art. 9

C1708 S. 70 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1709 S. 70 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(k) (with art. 37)

C1710 S. 70(3) modified (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) (No 2) Regulations 2008 (S.I. 2008/540), regs. 1, 17(2)

C1711 S. 70(4A) modified (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) (No 2) Regulations 2008 (S.I. 2008/540), regs. 1, 17(2)

Commencement Information

I7 S. 70 wholly in force: s.70(1)-(3)(5)-(7) in force at 1.1.1993 see s. 170(1) and S.I. 1992/2984, art. 2(2), Sch. 2; s. 70(4) in force at 14.7.1992, see s. 170 and S.I. 1992/1686, art. 2, Sch.

71 Materials, workmanship and standard of reinstatement. E+W

(1) An undertaker executing street works shall in reinstating the street comply with such requirements as may be prescribed as to the specification of materials to be used and the standards of workmanship to be observed.

(2) He shall also ensure that the reinstatement conforms to such performance standards as may be prescribed—

(a) in the case of interim reinstatement, until permanent reinstatement is effected, and

(b) in the case of permanent reinstatement, for the prescribed period after the completion of the reinstatement.

This obligation is extended in certain cases and restricted in others by the provisions of section 73 as to cases where a reinstatement is affected by subsequent works.

(3) Regulations made for the purposes of this section may make different provision in relation to different classes of excavation and different descriptions of street, and in relation to interim and permanent reinstatement.

(4) The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsections (1) and (2); and regulations made for the purposes of this section may provide that—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with his duties under this section; and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with those duties.

(5) An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F72 level 5] on the standard scale.

Textual Amendments

F72 Words in s. 71(5) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1712 S. 71 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1713 S. 71 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1714 S. 71 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(l) (with art. 37)

C1715 S. 71 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(h) (with art. 22)

72 Powers of street authority in relation to reinstatement. E+W

(1) The street authority may carry out such investigatory works as appear to them to be necessary to ascertain whether an undertaker has complied with his duties under this Part with respect to reinstatement.

If such a failure is disclosed, the undertaker shall bear the cost of the investigatory works; if not, the street authority shall bear the cost of the investigatory works and of any necessary reinstatement.

(2) Where an undertaker has failed to comply with his duties under this Part with respect to reinstatement, he shall bear the cost of—

(a) a joint inspection with the street authority to determine the nature of the failure and what remedial works need to be undertaken,

(b) an inspection by the authority of the remedial works in progress, and

(c) an inspection by the authority when the remedial works have been completed.

(3) The street authority may by notice require an undertaker who has failed to comply with his duties under this Part with respect to reinstatement to carry out the necessary remedial works within such period of not less than 7 working days as may be specified in the notice.

If he fails to comply with the notice, the authority may carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

(4) If it appears to the street authority that a failure by an undertaker to comply with his duties under this Part as to reinstatement is causing danger to users of the street, the authority may carry out the necessary works without first giving notice and may recover from him the costs reasonably incurred by them in doing so.

They shall, however, give notice to him as soon as reasonably practicable stating their reasons for taking immediate action.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1716 S. 72: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(m)

C1717 S. 72 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1718 S. 72 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(m) (with art. 37)

C1719 S. 72 applied (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(8) (with arts. 43, 44)

73 Reinstatement affected by subsequent works. E+W

(1) The provisions of this section apply in relation to an undertaker’s duty under section 71(2) to ensure that a reinstatement conforms to the prescribed performance standards for the requisite period; and references to responsibility for a reinstatement and to the period of that responsibility shall be construed accordingly.

(2) Where a reinstatement is affected by remedial works executed by the undertaker in order to comply with his duties under this Part with respect to reinstatement and the extent of the works exceeds that prescribed, the subsequent reinstatement shall be treated as a new reinstatement as regards the period of his responsibility.

(3) Where the street authority carry out investigatory works in pursuance of section 72(1) and the investigation does not disclose any failure by the undertaker to comply with his duties under this Part with respect to reinstatement, then, to the extent that the original reinstatement has been disturbed by the investigatory works, the responsibility of the undertaker for the reinstatement shall cease.

(4) Where a reinstatement is affected by remedial works executed by the street authority in exercise of their powers under section 72(3) or (4) (powers to act in default of undertaker)—

(a) the undertaker is responsible for the subsequent reinstatement carried out by the authority, and

(b) if the extent of the works exceeds that prescribed, the subsequent reinstatement shall be treated as a new reinstatement as regards the period of his responsibility.

(5) The following provisions apply where a reinstatement is affected by subsequent works in the street otherwise than as mentioned above.

(6) If the reinstatement is dug out to any extent in the course of the subsequent works, the responsibility of the undertaker for the reinstatement shall cease to that extent.

(7) If in any other case the reinstatement ceases to conform to the prescribed performance standards by reason of the subsequent works, the responsibility of the undertaker for the reinstatement is transferred to the person executing the subsequent works; and the provisions of this Part apply in relation to him as they would have applied in relation to the undertaker.

(8) Where there are successive subsequent works affecting a reinstatement, then as between earlier and later works—

(a) subsections (6) and (7) apply in relation to the cessation or transfer of the responsibility of the person for the time being responsible for the reinstatement; and

(b) if the reinstatement ceases to conform to the prescribed performance standards by reason of the works or any of them, it shall be presumed until the contrary is proved that this was caused by the later or last of the works.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1720 S. 73 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1721 S. 73 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(n) (with art. 37)

C1722 S. 73(5)-(8) extended (27.11.1992) by S.I. 1992/2984, art. 11

[F73 Inspections U.K.

Textual Amendments

F73 S. 73F and cross-heading inserted (6.4.2015 for E.) by Traffic Management Act 2004 (c. 18), ss. 59, 99(1); S.I. 2015/199, art. 2

73F Guidance about street authority inspections U.K.

(1) The Secretary of State may issue or approve guidance to street authorities about any matter relating to the exercise by them of any power to carry out inspections of street works.

(2) In exercising their powers to carry out such inspections a street authority shall have regard to any guidance issued or approved under this section.

(3) In this section any reference to inspections includes the carrying out of investigatory works.]

Modifications etc. (not altering text)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Charges, fees and contributions payable by undertakers E+W

74 Charge for occupation of the highway where works unreasonably prolonged. E+W

(1) The Secretary of State may make provision by regulations requiring an undertaker executing street works in a maintainable highway to pay a charge to the highway authority where—

(a) the duration of the works exceeds such period as may be prescribed, and

(b) the works are not completed within a reasonable period.

(2) For this purpose “a reasonable period” means such period as is agreed by the authority and the undertaker to be reasonable or, in default of such agreement, is determined by arbitration to be reasonable, for completion of the works in question.

In default of agreement, the authority’s view as to what is a reasonable period shall be acted upon pending the decision of the arbitrator.

[F74 (2A) The regulations may prescribe exemptions from the requirement to pay charges.]

(3) The regulations may provide that if an undertaker has reason to believe that the duration of works will exceed the prescribed period he [F75 shall give to the authority, in such manner as may be prescribed, notice containing] an estimate of their likely duration—

(a) in the case of works in connection with the initial placing of apparatus in the street in pursuance of a street works licence, together with his application for the licence,

(b) in the case of other works (not being emergency works), together with his notice under section 55 (notice of starting date) [F76 or notification under paragraph 2(1)(d) of Schedule 3A (notification of proposed works)], or

(c) in the case of emergency works, as soon as reasonably practicable after the works are begun,

and that the period stated in an estimate [F77 contained in a notice given to an authority in such manner] shall be taken to be agreed by the authority to be reasonable unless they give notice, in such manner and within such period as may be prescribed, objecting to the estimate.

(4) The regulations may also provide that if it appears to the undertaker that by reason of matters not previously foreseen or reasonably foreseeable the duration of the works—

(a) is likely to exceed the prescribed period,

(b) is likely to exceed the period stated in his previous estimate, or

(c) is likely to exceed the period previously agreed or determined to be a reasonable period,

he [F78 shall give to the authority, in such manner as may be prescribed, notice containing] an estimate or revised estimate accordingly, and that if he does so any previous estimate, agreement or determination shall cease to have effect and the period stated in the new estimate shall be taken to be agreed by the authority to be reasonable unless they give notice, in such manner and within such period as may be prescribed, objecting to the estimate.

(5) The amount of the charge shall be determined in such manner as may be prescribed by reference to the time taken to complete the works and the extent to which the surface of the highway is affected by the works.

Different rates of charge may be prescribed according to the place and time at which the works are executed and such other factors as appear to the Secretary of State to be relevant.

[F79 (5A) The regulations may—

(a) prescribe more than one rate of charge in respect of the same description of works, and

(b) provide that charges are to be paid in respect of any works of that description at the rate which appears to the highway authority to be appropriate in relation to those works.

(5B) The regulations may make provision for the determination of the duration of works for the purposes of the regulations.

(5C) And they may, in particular, make provision for works to be treated as beginning or ending on the giving of, or as stated in, a notice given by the undertaker to the highway authority, in the prescribed manner, in accordance with a requirement imposed by the regulations.]

(6) The regulations may make provision as to the time and manner of making payment of any charge.

(7) The regulations shall provide that a highway authority may reduce the amount, or waive payment, of a [F80 charge -

(a) in any particular case,

(b) in such classes of case as they may decide or as may be prescribed, or

(c) in all cases or in all cases other than a particular case or such class of case as they may decide or as may be prescribed.]

[F81 (7A) The regulations may make provision as to—

(a) the application by [F82 strategic highways companies or] local highway authorities of sums paid by way of charges, and

(b) the keeping of accounts, and the preparation and publication of statements of account, relating to sums paid by way of charges.

(7B) The regulations may create in respect of any failure to give a notice required by the regulations a criminal offence triable summarily and punishable with a fine not exceeding [F83 level 4] on the standard scale.]

(8) The first regulations for the purposes of this section shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament; subsequent regulations shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Textual Amendments

F74 S. 74(2A) inserted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(2); S.I. 2001/57, art. 3, Sch. 2 Pt. I, (as amended by S.I. 2001/115, art. 2(5))

F75 Words in s. 74(3) substituted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(3)(a); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F76 Words in s. 74(3)(b) inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 52(5), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F77 Words in s. 74(3) substituted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(3)(b); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F78 Words in s. 74(4) substituted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(4); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F79 S. 74(5A)-(5C) inserted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(5); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F80 Words in s. 74(7) substituted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(6); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F81 S. 74(7A)(7B) inserted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 256(7); S.I. 2001/57, art. 3 Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F82 Words in s. 74(7A)(a) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 119; S.I. 2015/481, reg. 2(a)

F83 Words in s. 74(7B) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(4), 99(1); S.I. 2004/2380, art. 2(d)(iii) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1723 S. 74 modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(4) (with reg. 35)

C1724 S. 74 modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(4)

C1725 S. 74 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C1726 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C1727 S. 74 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C1728 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C1729 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C1730 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C1731 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C1732 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C1733 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch., Appendix B

C1734 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C1735 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C1736 S. 74 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C1737 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C1738 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C1739 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C1740 S. 74 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C1741 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C1742 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C1743 S. 74 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C1744 S. 74 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C1745 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C1746 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C1747 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C1748 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C1749 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C1750 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C1751 S. 74 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C1752 S. 74 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C1753 S. 74 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch. Appendix B

C1754 S. 74 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C1755 S. 74 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C1756 S. 74 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C1757 S. 74 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C1758 S. 74 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C1759 S. 74 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C1760 S. 74 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C1761 S. 74 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch., Appendix C

C1762 S. 74 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix C

C1763 S. 74 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix C

C1764 S. 74 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C1765 S. 74 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C1766 S. 74 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C1767 S. 74 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C1768 S. 74 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C1769 S. 74 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C1770 S. 74 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C1771 S. 74 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C1772 S. 74 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C1773 S. 74 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C1774 S. 74 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C1775 S. 74 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C1776 S. 74 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C1777 S. 74 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C1778 S. 74 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A,

C1779 S. 74 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C1780 S. 74 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C1781 S. 74 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C1782 S. 74 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C1783 S. 74 excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(9)

C1784 S. 74 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C1785 S. 74 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C1786 S. 74 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C1787 S. 74 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C1788 S. 74 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C1789 S. 74 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C1790 S. 74 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C1791 S. 74 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C1792 S. 74 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C1793 S. 74 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C1794 S. 74 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C1795 S. 74 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C1796 S. 74 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C1797 S. 74 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C1798 S. 74 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1799 S. 74 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1 (with Sch. para. 2.7.2)

C1800 S. 74 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1 (with Sch. para. 2.8.2)

C1801 S. 74 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C1802 S. 74 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C1803 S. 74 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C1804 S. 74 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C1805 S. 74 excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(9) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C1806 S. 74 excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(9)

[74A F84 Charge determined by reference to duration of works. E+W

(1) The Secretary of State may make provision by regulations requiring an undertaker executing street works in a maintainable highway to pay to the highway authority a charge determined, in the prescribed manner, by reference to the duration of the works.

(2) The regulations shall not require charges to be paid to [F85 a strategic highways company or] a local highway authority unless the Secretary of State has approved it for the purposes of the regulations by order made by statutory instrument.

(3) The regulations may prescribe exemptions from the requirement to pay charges.

(4) The regulations may prescribe different rates of charge according to—

(a) the extent to which the surface of the highway is affected by the works,

(b) the place and time at which the works are executed, and

(c) such other factors as appear to the Secretary of State to be relevant.

(5) The regulations may—

(a) prescribe more than one rate of charge in respect of the same description of works, and

(b) provide that charges are to be paid in respect of any works of that description at the rate which appears to the highway authority to be appropriate in relation to those works.

(6) The regulations may make provision for the determination of the duration of works for the purposes of the regulations.

(7) And they may, in particular, make provision for works to be treated as beginning or ending on the giving of, or as stated in, a notice given by the undertaker to the highway authority, in the prescribed manner, in accordance with a requirement imposed by the regulations.

(8) The regulations may make provision as to the time and manner of making payment of charges.

(9) The regulations shall provide that a highway authority may reduce the amount, or waive payment, of a charge—

(a) in any particular case,

(b) in such classes of case as they may decide or as may be prescribed, or

(c) in all cases or in all cases other than a particular case or such class of case as they may decide or as may be prescribed.

(10) The regulations may make provision as to—

(a) the application by [F86 strategic highways companies or] local highway authorities of sums paid by way of charges, and

(b) the keeping of accounts, and the preparation and publication of statements of account, relating to sums paid by way of charges.

(11) The regulations may create in respect of any failure to give a notice required by the regulations a criminal offence triable summarily and punishable with a fine not exceeding [F87 level 4] on the standard scale.

(12) The regulations may require disputes of any prescribed description to be referred to an arbitrator appointed in accordance with the regulations.

(13) The first regulations under this section shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament; subsequent regulations shall be subject to annulment in pursuance of a resolution of either House of Parliament.]

Textual Amendments

F84 Ss. 74A, 74B inserted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 255(1); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

F85 Words in s. 74A(2) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 120(2); S.I. 2015/481, reg. 2(a)

F86 Words in s. 74A(10)(a) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 120(3); S.I. 2015/481, reg. 2(a)

F87 Words in s. 74A(11) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(4), 99(1); S.I. 2004/2380, art. 2(d)(iii) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1807 S. 74A excluded (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), art. 1, Sch. 19 Pt. 1 para. 4(9)

C1808 S. 74A excluded (23.2.2017) by High Speed Rail (London - West Midlands) Act 2017 (c. 7), s. 70(1), Sch. 24 para. 2(9) (with Sch. 24 para. 2(16))

C1809 S. 74A excluded (30.10.2019) by The Northampton Gateway Rail Freight Interchange Order 2019 (S.I. 2019/1358), art. 1, Sch. 14 para. 3(9) (with art. 45(7), Sch. 13 Pt. 1 para. 19)

C1810 S. 74A excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 14 para. 3(9)

F88 74B Regulations under sections 74 and 74A. E+W

Nothing shall be taken to prevent the imposition of charges by both regulations under sections 74 and regulations under section 74A in respect of the execution of the same works at the same time.

Textual Amendments

F88 Ss. 74A, 74B inserted (1.2.2001 subject to transitional provision and saving in Sch. 2 Pt. II of the commencing S.I.) by 2000 c. 38, s. 255(1); S.I. 2001/57, art. 3, Sch. 2 Pt. I (as amended by S.I. 2001/115, art. 2(5))

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

75 Inspection fees. E+W

(1) An undertaker executing street works shall, subject to the provisions of any scheme under this section, pay to the street authority the prescribed fee in respect of each inspection of the works carried out by the authority.

(2) Different fees may be prescribed according to the nature or extent of the excavation or other works, the place where they are executed and such other factors as appear to the Secretary of State to be relevant.

(3) The Secretary of State may by regulations make a scheme under which undertakers pay the prescribed fee only in respect of such proportion or number of excavations or other works as may be determined in accordance with the scheme.

(4) The scheme may make provision—

(a) as to the periods and areas by reference to which the proportion or number is to be determined, and

(b) as to the intervals at which an account is to be struck between an undertaker and a street authority and any necessary payment or repayment made;

and different provision may be made for different descriptions of undertaker and different descriptions of street authority.

(5) Nothing in this section applies in relation to inspections in respect of which the undertaker is obliged to bear the cost under section 72(2) (inspections consequent on his failure to comply with his duties as to reinstatement).

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1811 S. 75 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 75 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 75 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 75: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 1(n)

S. 75 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

C1812 S. 75 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 75 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1813 S. 75 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1814 S. 75 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1815 S. 75 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1816 S. 75 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1817 S. 75 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1818 S. 75 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1819 S. 75 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1820 S. 75 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1821 S. 75 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1822 S. 75 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1823 S. 75 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1824 S. 75 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1825 S. 75 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1826 S. 75 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1827 S. 75 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1828 S. 75 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1829 S. 75 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1830 S. 75 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1831 S. 75 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1832 S. 75 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1833 S. 75 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1834 S. 75 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(o) (with art. 37)

C1835 S. 75 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1836 S. 75 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1837 S. 75 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1838 S. 75 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1839 S. 75 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1840 S. 75 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1841 S. 75 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(h) (with art. 3(1))

C1842 S. 75 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1843 S. 75 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1844 S. 75 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1845 S. 75 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1846 S. 75 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1847 S. 75 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1848 S. 75 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(h) (with art. 32, Sch. 9 para. 36)

76 Liability for cost of temporary traffic regulation. E+W

(1) Where by reason of street works—

(a) the traffic authority makes an order or issues a notice under section 14 of the M28 Road Traffic Regulation Act 1984 (temporary prohibition or restriction of traffic), or

(b) a concessionaire issues a notice under that section by virtue of section 3(4) of this Act,

the authority or concessionaire may recover from the undertaker the whole of the costs incurred by them in connection with or in consequence of the order or notice.

(2) Those costs shall be taken to include, in particular, the cost to the authority or concessionaire—

(a) of complying with any requirement to notify the public of any matter in connection with the making, issuing or operation of the order or notice, and

(b) of providing traffic signs in connection with the prohibition or restriction of traffic by the order or notice.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1849 S. 76 applied (27.8.1998) by S.I. 1998/1936, art. 4(3)

S. 76 applied (13.1.1999) by S.I. 1998/3269, art. 4(2)(3)

S. 76 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 76 applied (10.2.1997) by S.I. 1997/264, art. 8(6)(7)

S. 76 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 76 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 76 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 76 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 76 applied (with modifications) (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 76 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 76 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 76 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 76 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 76 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 76 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1850 S. 76 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38)

S. 76 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 76 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1851 S. 76 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1852 S. 76 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1853 S. 76 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1854 S. 76 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1855 S. 76 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)(4) (with art. 51)

C1856 S. 76 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C1857 S. 76 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)(4) (with art. 47)

C1858 S. 76 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1859 S. 76 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1860 Ss. 76, 77 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1861 S. 76 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1862 S. 76 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1863 S. 76 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1864 S. 76 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C1865 S. 76 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1866 S. 76 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1867 S. 76 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1868 S. 76 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1869 S. 76 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1870 S. 76 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)(3) (with arts. 19, 28, Sch. 3 para. 13(2))

C1871 S. 76 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1872 S. 76 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1873 S. 76 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1874 S. 76 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1875 S. 76 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1876 S. 76 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1877 S. 76 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1878 S. 76 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1879 S. 76 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1880 S. 76 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1881 S. 76 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1882 S. 76 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1883 S. 76 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1884 S. 76 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1885 S. 76 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1886 S. 76 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1887 S. 76 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1888 S. 76 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1889 S. 76 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1890 S. 76 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1891 S. 76 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1892 S. 76 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1893 S. 76 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1894 S. 76 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1895 S. 76 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1896 S. 76 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1897 S. 76 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1898 S. 76 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1899 S. 76 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1900 S. 76 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1901 S. 76 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1902 S. 76 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)(4) (with art. 39)

C1903 S. 76 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1904 S. 76 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(h) (with arts. 37, 38)

C1905 S. 76 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1906 S. 76 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(p) (with art. 37)

C1907 S. 76 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1908 S. 76 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(h) (with art. 31)

C1909 S. 76 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(i) (with art. 22)

C1910 S. 76 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1911 S. 76 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1912 S. 76 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1913 S. 76 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1914 S. 76 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C1915 S. 76 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C1916 S. 76 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C1917 S. 76 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C1918 S. 76 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C1919 S. 76 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C1920 S. 76 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C1921 S. 76 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(i) (with art. 3(1))

C1922 S. 76 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C1923 S. 76 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C1924 S. 76 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C1925 S. 76 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C1926 S. 76 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C1927 S. 76 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(f)(h) (with art. 37)

C1928 S. 76 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(f) (with arts. 41, 42, Sch. 16 para. 66)

C1929 S. 76 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C1930 S. 76 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C1931 S. 76 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(i) (with art. 32, Sch. 9 para. 36)

C1932 S. 76 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C1933 S. 76 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

C1934 S. 76 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(f) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

Marginal Citations

M28 1984 c. 27.

77 Liability for cost of use of alternative route. E+W

(1) Where by reason of street works the use of a highway is restricted or prohibited and the diverted traffic uses as an alternative route a highway of a lower classification, the undertaker shall indemnify the highway authority for the latter highway in respect of costs reasonably incurred by them—

(a) in strengthening the highway, so far as that is done with a view to and is necessary for the purposes of its use by the diverted traffic; or

(b) in making good any damage to the highway occurring in consequence of the use by it of the diverted traffic.

(2) For this purpose the order of classification of highways, from higher to lower, is as follows:

1	Trunk roads.
2	Principal roads.
3	Other classified roads.
4	Other highways.

As to principal and other classified roads, see sections 12 and 13 of the M29 Highways Act 1980.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C1860 Ss. 76, 77 applied (with modifications) (8.10.2005) by The Leicestershire County Council (Ashby de la Zouch Canal Extension) Order 2005 (S.I. 2005/2786), arts. 1, 9(2)(3)

C1935 S. 77 applied (4.4.1996) by S.I. 1996/937, art. 8(4)(5)

S. 77 applied (13.1.99) by S.I. 1998/3269, art. 4(2)(3)

S. 77 applied (27.8.98) by S.I. 1998/1936, art. 4(3)

S. 77 applied (21.5.1997) by S.I. 1997/1266, art. 5(2)(3)

S. 77 applied (10.2.1997) by S.I. 1996/264, art. 8(6)(7)

S. 77 applied (with modifications) (30.4.1999) by S.I. 1999/1306, art. 8(4)(5)

S. 77 applied (with modifications) (21.7.1999) by S.I. 1999/2129, art. 8(5)(6)

S. 77 applied (with modifications) (20.8.1999) by S.I. 1999/2336, art. 9(5)(6)(8)

S. 77 applied (with modifications) (23.8.1999) by S.I. 1999/2981, art. 7(5)(6)

S. 77 applied modifications (11.11.1996) by S.I. 1996/2714, art. 4(2)(3)

S. 77 applied (with modifications) (29.3.2001) by S.I. 2001/1348, art. 21(3)-(5)

S. 77 applied (with modifications) (29.3.2001) by S.I. 2001/1347, art. 3(3)

S. 77 applied (with modifications) (18.7.2001) by S.I. 2001/2870, art. 10(6)

S. 77 applied (with modifications) (24.7.2001) by S.I. 2001/3627, art. 4(3)(4)

S. 77 applied (with modifications) (9.11.2001) by S.I. 2001/3682, art. 8(6)

C1936 S. 77 applied (with modifications) (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 9(4)(5) (with art. 38);

S. 77 applied (with modifications) (30.4.2002) by The Docklands Light Railway (Silvertown and London City Airport Extension) Order 2002 (S.I. 2002/1066), art. 3(3)(4);

S. 77 applied (with modifications) (31.5.2002) by The Greater Manchester (Light Rapid Transit System) (Trafford Depot) Order 2002 (S.I. 2002/1327), art. 3(3)

C1937 S. 77 applied (with modifications) (28.4.2003) by The Network Rail (West Coast Main Line) Order 2003 (S.I. 2003/1075), arts. 1, 13(6)(7)(8) (with art. 40)

C1938 S. 77 applied (with modifications) (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), arts. 1, 3(3)(4)

C1939 S. 77 applied (with modifications) (19.11.2004) by The Scarweather Sands Offshore Wind Farm Order 2004 (S.I. 2004/3054), arts. 1, 6(4)(5) (with art. 38)

C1940 S. 77 applied (with modifications) (11.2.2005) by The Merseytram (Liverpool City Centre to Kirkby) Order 2005 (S.I. 2005/120), arts. 1, 4(4)(5) (with arts. 65, 66)

C1941 S. 77 applied (with modifications) (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), art. 3(3)(4) (with art. 51)

C1942 S. 77 applied (with modifications) (4.5.2005) by The Telford Railfreight Terminal (Donnington) Order 2005 (S.I. 2005/1163), arts. 1, 12(7)

C1943 S. 77 applied (with modifications) (22.7.2005) by The Midland Metro (Birmingham City Centre Extension, etc.) Order 2005 (S.I. 2005/1794), arts. 1, 3(3)(4) (with art. 47)

C1944 S. 77 applied (with modifications) (3.8.2005) by The Greater Manchester (Leigh Busway) Order 2005 (S.I. 2005/1918), arts. 1, 3(3)(4)

C1945 S. 77 applied (with modifications) (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), arts. 1, 8(9)(10) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C1946 S. 77 applied (with modifications) (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), arts. 1, 3(4) (with arts. 3(5), 15(3))

C1947 S. 77 applied (with modifications) (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), arts. 1, 3(3)(4) (with art. 52)

C1948 S. 77 applied (with modifications) (3.7.2006) by The Port of Blyth (Battleship Wharf Railway) Order 2006 (S.I. 2006/1518), arts. 1, 4

C1949 S. 77 applied (with modifications) (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), arts. 1, 9(5)(6) (with art. 40, Sch. 7 para. 12)

C1950 S. 77 applied (with modifications) (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), arts. 1, 3(4)(5) (with art. 43)

C1951 S. 77 applied (with modifications) (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), arts. 1, 16(6)(7) (with arts. 34, 35(2))

C1952 S. 77 applied (with modifications) (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), arts. 1, 10(5)(6)

C1953 S. 77 applied (with modifications) (19.3.2007) by The Ouseburn Barrage Order 2007 (S.I. 2007/608), arts. 1, 8(2) (with arts. 46-48, Sch. 6 para. 23)

C1954 S. 77 applied (with modifications) (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), arts. 1, 3(4)(5) (with arts. 3(6), 12(3))

C1955 S. 77 applied (with modifications) (28.9.2007) by The London Gateway Logistics and Commercial Centre Order 2007 (S.I. 2007/2657), arts. 1, 3(2)(3) (with arts. 19, 28, Sch. 3 para. 13(2))

C1956 S. 77 applied (with modifications) (16.5.2008) by The London Gateway Port Harbour Empowerment Order 2008 (S.I. 2008/1261), arts. 1, 6(3)(4) (with arts. 41(1), 45, 54(2), 55, 56, 57, 58(6))

C1957 S. 77 applied (with modifications) (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), arts. 1, 4(2)(3) (with art. 36(3))

C1958 S. 77 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(4)(5) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C1959 S. 77 applied (with modifications) (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), arts. 1, 3(4)(5)

C1960 S. 77 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), arts. 1, 4(1)(2)

C1961 S. 77 applied (with modifications) (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), arts. 1, 3(2)(3) (with art. 51, Sch. 10 paras. 68, 85)

C1962 S. 77 applied (with modifications) (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), arts. 1, 4(2)-(3)

C1963 S. 77 applied (26.9.2012) by The Network Rail (Ipswich Chord) Order 2012 (S.I. 2012/2284), arts. 1, 10(2) (with art. 26(2))

C1964 S. 77 applied (6.11.2012) by The Network Rail (North Doncaster Chord) Order 2012 (S.I. 2012/2635), arts. 1, 14(2)(3) (with art. 35(2))

C1965 S. 77 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), arts. 1, 4(2)(3) (with art. 42(2))

C1966 S. 77 applied (with modifications) (21.8.2013) by The Croxley Rail Link Order 2013 (S.I. 2013/1967), arts. 1, 4(1)(2)

C1967 S. 77 applied (with modifications) (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), arts. 1, 3(3)(4)

C1968 S. 77 applied (with modifications) (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(4)(5) (with arts. 42, 43)

C1969 S. 77 applied (20.11.2013) by The M1 Junction 10a (Grade Separation) Order 2013 (S.I. 2013/2808), arts. 1, 8(4)(5)

C1970 S. 77 applied (with modifications) (21.11.2013) by The Network Rail (Redditch Branch Enhancement) Order 2013 (S.I. 2013/2809), arts. 1, 10(2)(3) (with arts. 27(2), 39, Sch. 10 para. 4)

C1971 S. 77 applied (with modifications) (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(4)(5) (with arts. 57, 58, Sch. 11 para. 19)

C1972 S. 77 applied (with modifications) (9.1.2014) by The National Grid (King’s Lynn B Power Station Connection) Order 2013 (S.I. 2013/3200), arts. 1, 9(2)(3)

C1973 S. 77 applied (with modifications) (21.4.2014) by The Network Rail (Norton Bridge Area Improvements) Order 2014 (S.I. 2014/909), arts. 1, 12(3)(4) (with art. 34(2))

C1974 S. 77 applied (with modifications) (7.5.2014) by The National Grid (North London Reinforcement Project) Order 2014 (S.I. 2014/1052), arts. 1, 13(2)(3)

C1975 S. 77 applied (with modifications) (19.8.2014) by The Network Rail (Huyton) Order 2014 (S.I. 2014/2027), arts. 1, 4(4) (with art. 31(2))

C1976 S. 77 applied (with modifications) (18.9.2014) by The A556 (Knutsford to Bowdon Improvement) Development Consent Order 2014 (S.I. 2014/2269), arts. 1, 8(4)(5)

C1977 S. 77 applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

C1978 S. 77 applied (with modifications) (21.10.2014) by The Central Bedfordshire Council (Woodside Link Houghton Regis) Development Consent Order 2014 (S.I. 2014/2637), arts. 1, 8(4)(5)

C1979 S. 77 applied (with modifications) (15.12.2014) by The London Underground (Northern Line Extension) Order 2014 (S.I. 2014/3102), arts. 1, 3(4)(5) (with Sch. 8 para. 45)

C1980 S. 77 applied (with modifications) (31.12.2014) by The Hornsea One Offshore Wind Farm Order 2014 (S.I. 2014/3331), arts. 1, 7(1)(2) (with arts. 37, 38)

C1981 S. 77 applied (with modifications) (25.2.2015) by The A160/A180 (Port of Immingham Improvement) Development Consent Order 2015 (S.I. 2015/129), arts. 1, 9(4)(5)

C1982 S. 77 applied (with modifications) (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), arts. 1, 4(2)(3) (with art. 36(2))

C1983 S. 77 applied (with modifications) (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), arts. 1, 4(4)(5)

C1984 S. 77 modified (9.2.2016) by The National Grid (Hinkley Point C Connection Project) Order 2016 (S.I. 2016/49), arts. 1, 11(2)(3) (with art. 32)

C1985 S. 77 applied (18.2.2016) by The A19/A1058 Coast Road (Junction Improvement) Development Consent Order 2016 (S.I. 2016/73), arts. 1, 8(4)(5) (with art. 37)

C1986 S. 77 applied (with modifications) (1.6.2016) by The A14 Cambridge to Huntingdon Improvement Scheme Development Consent Order 2016 (S.I. 2016/547), arts. 1, 10(4)(5) (with arts. 4, 5(3))

C1987 S. 77 applied (with modifications) (14.6.2016) by The Midland Metro (Birmingham City Centre Extension, etc.) (Land Acquisition and Variation) Order 2016 (S.I. 2016/545), arts. 1, 3(3)(4) (with art. 39)

C1988 S. 77 applied (with modifications) (2.8.2016) by The Midland Metro (Wolverhampton City Centre Extension) Order 2016 (S.I. 2016/684), arts. 1, 5(3)(4) (with arts. 46, 47, Sch. 9 para. 4, Sch. 10 para. 12(2))

C1989 S. 77 applied (with modifications) (7.9.2016) by The Hornsea Two Offshore Wind Farm Order 2016 (S.I. 2016/844), arts. 1(2), 10(2)(i) (with arts. 37, 38)

C1990 S. 77 applied (with modifications) (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 9(4)(5)

C1991 S. 77 applied (28.10.2016) by The Brechfa Forest Wind Farm Connection Order 2016 (S.I. 2016/987), arts. 1, 8(3)(q) (with art. 37)

C1992 S. 77 applied (with modifications) (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(4)(5) (with arts. 43, 44)

C1993 S. 77 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 12(2)(3)(i) (with art. 31)

C1994 S. 77 applied (with modifications) (24.8.2017) by The National Grid (Richborough Connection Project) Development Consent Order 2017 (S.I. 2017/817), arts. 1, 11(3)(j) (with art. 22)

C1995 S. 77 applied (with modifications) (5.9.2017) by The London Overground (Barking Riverside Extension) Order 2017 (S.I. 2017/830), arts. 1, 3(4)(5) (with Sch. 8 para. 20)

C1996 S. 77 applied (with modifications) (19.12.2017) by The Network Rail (Buxton Sidings Extension) Order 2017 (S.I. 2017/1150), arts. 1, 4(3)(4) (with art. 32(2))

C1997 S. 77 applied (22.12.2017) by The M20 Junction 10a Development Consent Order 2017 (S.I. 2017/1202), arts. 1, 11(4)(5) (with arts. 4, 37)

C1998 S. 77 applied (with modifcations) (2.1.2018) by The Boston Barrier Order 2017 (S.I. 2017/1329), arts. 1, 3(4)(5) (with arts. 55-57, Sch. 8 para. 13)

C1999 S. 77 applied (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(4)(5) (with arts. 5(7), 58, 59)

C2000 S. 77 applied (18.4.2018) by The Network Rail (Hope Valley Capacity) Order 2018 (S.I. 2018/446), arts. 1, 4(3)(4) (with arts. 24(8), 33(2))

C2001 S. 77 applied (31.5.2018) by The Silvertown Tunnel Order 2018 (S.I. 2018/574), arts. 1(2), 7(4)(5)

C2002 S. 77 applied (with modifications) (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), arts. 1, 4(2)(3) (with art. 31(2))

C2003 S. 77 applied (3.10.2018) by The A19/A184 Testo's Junction Alteration Development Consent Order 2018 (S.I. 2018/994), arts. 1, 9(4)(5) (with arts. 3(3), 5)

C2004 S. 77 applied (with modifications) (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 9(4)(5) (with arts. 55, 56)

C2005 S. 77 applied (with modifications) (25.2.2020) by The Network Rail (East West Rail) (Bicester to Bedford Improvements) Order 2020 (S.I. 2020/114), arts. 1, 4(3)(4) (with art. 37(2))

C2006 S. 77 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 12(4)(5)(j) (with art. 3(1))

C2007 S. 77 applied (with modifications) (4.3.2020) by The Midland Metro (Birmingham Eastside Extension) Order 2020 (S.I. 2020/141), arts. 1, 5(3)(4) (with arts. 47, 48, Sch. 10 para. 19)

C2008 S. 77 applied (30.4.2020) by The A585 Windy Harbour to Skippool Highway Development Consent Order 2020 (S.I. 2020/402), arts. 1, 9(4)(5) (with arts. 5, 44)

C2009 S. 77 applied (with modifications) (21.5.2020) by The Lake Lothing (Lowestoft) Third Crossing Order 2020 (S.I. 2020/474), arts. 1, 7(4)(5) (with arts. 51, 57)

C2010 S. 77 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 13(4)(5) (with art. 37)

C2011 S. 77 applied (with modifications) (18.6.2020) by The A63 (Castle Street Improvement, Hull) Development Consent Order 2020 (S.I. 2020/556), arts. 1, 9(4)(5) (with arts. 5, 44)

C2012 S. 77 applied (with modifications) (19.6.2020) by The Cleve Hill Solar Park Order 2020 (S.I. 2020/547), arts. 1, 9(2)(g)(h) (with art. 37)

C2013 S. 77 applied (with modifications) (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), arts. 1, 14(2)(g) (with arts. 41, 42, Sch. 16 para. 66)

C2014 S. 77 applied (with modifications) (6.8.2020) by The A19 Downhill Lane Junction Development Consent Order 2020 (S.I. 2020/746), arts. 1, 9(4)(5) (with art. 5)

C2015 S. 77 applied (with modifications) (15.10.2020) by The Great Yarmouth Third River Crossing Development Consent Order 2020 (S.I. 2020/1075), arts. 1, 11(5)

C2016 S. 77 applied (with modifications) (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), arts. 1, 12(4)(5)(j) (with art. 32, Sch. 9 para. 36)

C2017 S. 77 applied (31.12.2020) by The Network Rail (Cambridgeshire Level Crossing Reduction) Order 2020 (S.I. 2020/1485), arts. 1, 3(2)(3)

C2018 S. 77 applied (with modifications) (19.1.2021) by The Network Rail (Suffolk Level Crossing Reduction) Order 2020 (S.I. 2020/1663), arts. 1, 3(2)(3)

C2019 S. 77 applied (with modifications) (22.1.2021) by The Hornsea Three Offshore Wind Farm Order 2020 (S.I. 2020/1656), arts. 1, 9(2)(g) (with arts. 40, 41, Sch. 9 Pt. 5 para. 18)

Marginal Citations

M29 1980 c. 66.

78 Contributions to costs of making good long-term damage. E+W

(1) The Secretary of State may make provision by regulations requiring an undertaker executing street works to contribute to the costs incurred or likely to be incurred by the street authority or, in the case of a road subject to a concession within the meaning of Part I of this Act, by the concessionaire, in works of reconstruction or re-surfacing of the street.

(2) The regulations may provide—

(a) for a contribution to the cost of particular remedial works, or

(b) for a general contribution calculated in such manner as may be prescribed.

(3) In the former case the regulations may contain provision for apportioning the liability where the need for the remedial works is attributable to works executed by more than one person.

(4) In the latter case the regulations may provide for the amount of the contribution to vary according to the nature of the street, the description and extent of the works and such other factors as appear to the Secretary of State to be relevant.

(5) The first regulations under this section shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament; subsequent regulations shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Duties and liabilities of undertakers with respect to apparatus E+W

79 Records of location of apparatus. E+W

(1) An undertaker shall, except in such cases as may be prescribed, record the location of every item of apparatus belonging to him as soon as reasonably practicable after—

(a) placing it in the street or altering its position,

(b) locating it in the street in the course of executing any other works, or

(c) being informed of its location under section 80 below,

stating the nature of the apparatus and (if known) whether it is for the time being in use.

(2) The records shall be kept up to date and shall be kept in such form and manner as may be prescribed.

(3) An undertaker shall make his records available for inspection, at all reasonable hours and free of charge, by any person having authority to execute works of any description in the street or otherwise appearing to the undertaker to have a sufficient interest.

(4) If an undertaker fails to comply with his duties under this section—

(a) he commits an offence and is liable on summary conviction to a fine not exceeding [F89 level 5] on the standard scale; and

(b) he is liable to compensate any person in respect of damage or loss incurred by him in consequence of the failure.

(5) In criminal or civil proceedings arising out of any such failure it is a defence for the undertaker to show that all reasonable care was taken by him, and by his contractors and by persons in his employ or that of his contractors, to secure that no such failure occurred.

(6) An order under section 102 (power to make consequential amendments, repeals, &c.) relating to an enactment or instrument containing provision for the keeping of records of apparatus which appears to the Secretary of State to be superseded by or otherwise inconsistent with the provisions of this section—

(a) shall not be subject to the procedure provided for in Schedule 5, and

(b) may make such transitional and other provision as appears to the Secretary of State appropriate for applying in relation to records compiled under that enactment or instrument the provisions of subsections (2) to (5) above and section 80 below.

Textual Amendments

F89 Words in s. 79(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2020 S. 79(1) excluded (E.) (1.5.2003) by The Street Works (Records) (England) Regulations 2002 (S.I. 2002/3217), regs. 1(1), 5

C2021 S. 79(1) restricted (W.) (1.12.2005) by Street Works (Records) (Wales) Regulations 2005 (S.I. 2005/1812), regs. 1(1), 5

Commencement Information

I8 S. 79 partly in force; s. 79 not in force at Royal Assent, see s. 170

S. 79(1)(a)(b)(2)-(6) in force for E. at 1.5.2003 by S.I. 2002/3267, art. 2

I9 S. 79(1)(a)(b)(2)-(6) in force for W. at 23.7.2004 by S.I. 2004/1780, art. 2

80 Duty to inform undertakers of location of apparatus. E+W

(1) A person executing works of any description in the street who finds apparatus belonging to an undertaker which is not marked, or is wrongly marked, on the records made available by the undertaker, shall take such steps as are reasonably practicable to inform the undertaker to whom the apparatus belongs of its location and (so far as appears from external inspection) its nature and whether it is in use.

(2) Where a person executing works of any description in the street finds apparatus which does not belong to him and is unable, after taking such steps as are reasonably practicable, to ascertain to whom the apparatus belongs, he shall—

(a) if he is an undertaker, note on the records kept by him under section 79(1) (in such manner as may be prescribed) the location of the apparatus he has found and its general description; and

(b) in any other case, inform the street authority of the location and general description of the apparatus he has found.

(3) Subsections (1) and (2) have effect subject to such exceptions as may be prescribed.

(4) A person who fails to comply with subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F90 level 4] on the standard scale.

Textual Amendments

F90 Words in s. 80(4) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2022 S. 80 modified (E.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (England) Regulations 2007 (S.I. 2007/1951), regs. 1(1), 13(2)(a) (with reg. 19)

C2023 S. 80 modified (W.) (1.4.2008) by The Street Works (Registers, Notices, Directions and Designations) (Wales) Regulations 2008 (S.I. 2008/101), regs. 1, 13 (with reg. 19)

81 Duty to maintain apparatus. E+W

(1) An undertaker having apparatus in the street shall secure that the apparatus is maintained to the reasonable satisfaction of—

(a) the street authority, as regards the safety and convenience of persons using the street (having regard, in particular, to the needs of people with a disability), the structure of the street and the integrity of apparatus of the authority in the street, and

(b) any other relevant authority, as regards any land, structure or apparatus of theirs;

and he shall afford reasonable facilities to each such authority for ascertaining whether it is so maintained.

(2) For this purpose maintenance means the carrying out of such works as are necessary to keep the apparatus in efficient working condition (including periodic renewal where appropriate); and includes works rendered necessary by other works in the street, other than major highway, bridge or transport works (as to which, see sections 84 and 85 below).

(3) If an undertaker fails to give a relevant authority the facilities required by this section—

(a) the street authority may in such cases as may be prescribed, and

(b) any other relevant authority may in any case,

execute such works as are needed to enable them to inspect the apparatus in question, including any necessary breaking up or opening of the street.

(4) If an undertaker fails to secure that apparatus is maintained to the reasonable satisfaction of a relevant authority in accordance with this section—

(a) the street authority may in such cases as may be prescribed, and

(b) any other relevant authority may in any case,

execute any emergency works needed in consequence of the failure.

(5) The provisions of this Part apply in relation to works executed by a relevant authority under subsection (3) or (4) as if they were executed by the undertaker; and the undertaker shall indemnify the authority in respect of the costs reasonably incurred by them in executing the works.

(6) A relevant authority who execute or propose to execute any works under subsection (3) or (4) shall give notice to any other relevant authority as soon as reasonably practicable stating the general nature of the works.

(7) Nothing in subsection (3) or (4) shall be construed as excluding any other means of securing compliance with the duties imposed by subsection (1).

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2024 S. 81: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 paras. 1(o), 3(a)

Commencement Information

I10 S. 81 wholly in force: s. 81(1)(2)(5)-(7) in force at 1.1.1993, see s. 170(1) and S.I. 1992/2984, art. 2(2), Sch. 2; s. 81(3)(4) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

82 Liability for damage or loss caused. E+W

(1) An undertaker shall compensate—

(a) the street authority or any other relevant authority in respect of any damage or loss suffered by the authority in their capacity as such, and

(b) any other person having apparatus in the street in respect of any expense reasonably incurred in making good damage to that apparatus,

as a result of the execution by the undertaker of street works or any event of a kind mentioned in subsection (2).

(2) The events referred to in subsection (1) are any explosion, ignition, discharge or other event occurring to gas, electricity, water or any other thing required for the purposes of a supply or service afforded by an undertaker which—

(a) at the time of or immediately before the event in question was in apparatus of the undertaker in the street, or

(b) had been in such apparatus before that event and had escaped therefrom in circumstances which contributed to its occurrence.

(3) The liability of an undertaker under this section arises—

(a) whether or not the damage or loss is attributable to negligence on his part or on the part of any person for whom he is responsible, and

(b) notwithstanding that he is acting in pursuance of a statutory duty.

(4) However, his liability under this section does not extend to damage or loss which is attributable to misconduct or negligence on the part of—

(a) the person suffering the damage or loss, or any person for whom he is responsible, or

(b) a third party, that is, a person for whom neither the undertaker nor the person suffering the damage or loss is responsible.

(5) For the purposes of this section the persons for whom a person is responsible are his contractors and any person in his employ or that of his contractors.

88.(6) Nothing in this section shall be taken as exonerating an undertaker from any liability to which he would otherwise be subject.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2025 S. 82 modified (1. 1. 1993) by Local Government (Miscellaneous Provisions) Act 1976 (c. 57), s. 15(4) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 106; S.I. 1992/2984, art. 2(2), Sch.2)

S. 82 modified (1. 1. 1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2984, art. 2(2), Sch.2)

C2026 S. 82 applied (13.7.2016) by Housing and Planning Act 2016 (c. 22), ss. 175(3)(4), 216(3); S.I. 2016/733, reg. 3(h)

C2027 S. 82(1): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 paras. 1(p), 3(b)

C2028 S. 82(2) applied (2.10.2014) by The Clocaenog Forest Wind Farm Order 2014 (S.I. 2014/2441), arts. 1, 13(2)(3) (with art. 33)

Apparatus affected by highway, bridge or transport works E+W

83 Works for road purposes likely to affect apparatus in the street. E+W

(1) This section applies to works for road purposes other than major highway works (as to which see section 84 below).

(2) Where works to which this section applies are likely to affect apparatus in the street, the authority executing the works shall take all reasonably practicable steps—

(a) to give the person to whom the apparatus belongs reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by him which is reasonably necessary for the protection of the apparatus or for securing access to it.

(3) An authority who fail to comply with subsection (2) commit an offence in respect of each failure and are liable on summary conviction to a fine not exceeding [F91 level 4] on the standard scale.

(4) In proceedings against an authority for such an offence it is a defence for them to show that the failure was attributable—

(a) to their not knowing the position, or not knowing of the existence, of a person’s apparatus, or

(b) to their not knowing the identity or address of the person to whom any apparatus belongs,

and that their ignorance was not due to any negligence on their part or to any failure to make inquiries which they ought reasonably to have made.

Textual Amendments

F91 Words in s. 83(3) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2029 S. 83: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 4(a)

C2030 S. 83: functions made exercisable concurrently (8.5.2017) by The West Midlands Combined Authority (Functions and Amendment) Order 2017 (S.I. 2017/510), arts. 1(2), 9(1)(a)(2)

84 Measures necessary where apparatus affected by major works. E+W

(1) Where an undertaker’s apparatus in a street is or may be affected by major highway works, major bridge works or major transport works, the highway, bridge or transport authority concerned and the undertaker shall take such steps as are reasonably required—

(a) to identify any measures needing to be taken in relation to the apparatus in consequence of, or in order to facilitate, the execution of the authority’s works,

(b) to settle a specification of the necessary measures and determine by whom they are to be taken, and

(c) to co-ordinate the taking of those measures and the execution of the authority’s works,

so as to secure the efficient implementation of the necessary work and the avoidance of unnecessary delay.

(2) The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the matters mentioned in subsection (1) and the steps to be taken by the authority and the undertaker.

(3) Any dispute between the authority and the undertaker as to any of the matters mentioned in subsection (1) shall, in default of agreement, be settled by arbitration.

(4) If the authority or the undertaker fails to comply with an agreement between them as to any of those matters, or with the decision of the arbitrator under subsection (3), the authority or undertaker shall be liable to compensate the other in respect of any loss or damage resulting from the failure.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2031 S. 84: functions made exercisable concurrently (8.5.2017) by The West Midlands Combined Authority (Functions and Amendment) Order 2017 (S.I. 2017/510), arts. 1(2), 9(1)(a)(2)

C2032 S. 84(1)(3)(4) excluded (27.11.1992) by S.I. 1992/2984, art. 10

S. 84(1)(3)(4): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 4(b)

Commencement Information

I11 S. 84 wholly in force: s. 84(1)(3)(4) in force at 1.1.1993 see s. 170(1) and S.I. 1992/2984, art. 2(2), Sch. 2; s. 84(2) in force at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

85 Sharing of cost of necessary measures. E+W

(1) Where an undertaker’s apparatus in a street is affected by major highway works, major bridge works or major transport works, the allowable costs of the measures needing to be taken in relation to the apparatus in consequence of the works, or in order to facilitate their execution, shall be borne by the highway, bridge or transport authority concerned and the undertaker in such manner as may be prescribed.

(2) The regulations may make provision as to the costs allowable for this purpose.

Provision may, in particular, be made for disallowing costs of the undertaker—

(a) where the apparatus in question was placed in the street after the authority had given the undertaker the prescribed notice of their intention to execute the works, or

(b) in respect of measures taken to remedy matters for which the authority were not to blame,

and for allowing only such costs of either party as are not recoverable from a third party.

(3) Where the authority have a right to recover from a third party their costs in taking measures in relation to undertaker’s apparatus but in accordance with section 84 it is determined that the measures should be taken by the undertaker, the right of the authority includes a right to recover the undertaker’s costs in taking those measures and they shall account to the undertaker for any sum received.

(4) The regulations shall provide for the allowable costs to be borne by the authority and the undertaker in such proportions as may be prescribed.

Different proportions may be prescribed for different cases or classes of case.

(5) The regulations may require the undertaker to give credit for any financial benefit to him from the betterment or deferment of renewal of the apparatus resulting from the measures taken.

(6) The regulations may make provision as to the time and manner of making any payment required under this section.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2033 S. 85 excluded (27.11.1992) by S.I. 1992/2984, art. 10

C2034 S. 85 applied (18.12.1996) by 1996 c. 61, s. 52, Sch. 15 Pt. 4 para. 4(8)(a)

S. 85 applied (10.2.1997) by S.I. 1997/264, art. 28, Sch. 9 para. 2(7)(a)

S. 85 applied (9.11.2001) by S.I. 2001/3682, art. 33 Sch. 9 para. 2(7)(a)

S. 85 applied (9.11.2001) by S.I. 2001/3682, art. 34, Sch. 10 para. 9(5)(a) (with Sch. 10 para. 12)

C2035 S. 85 applied (2.4.2004) by The Docklands Light Railway (Woolwich Arsenal Extension) Order 2004 (S.I. 2004/757), art. 1, Sch. 12 para. 2(8)(a)

C2036 S. 85 applied (22.3.2005) by The Midland Metro (Wednesbury to Brierley Hill and Miscellaneous Amendments) Order 2005 (S.I. 2005/927), Sch. 10 para. 2(7)(a) (with art. 51)

C2037 S. 85 applied (26.8.2005) by The River Tyne (Tunnels) Order 2005 (S.I. 2005/2222), art. 1, Sch. 11 para. 7(a) (with arts. 45(1), 48, Sch. 10 paras. 21, 29)

C2038 S. 85 applied (25.11.2005) by The Docklands Light Railway (Capacity Enhancement) Order 2005 (S.I. 2005/3105), art. 1, Sch. 9 para. 2(8) (with arts. 3(5), 15(3))

C2039 S. 85 applied (11.1.2006) by The Cambridgeshire Guided Busway Order 2005 (S.I. 2005/3523), art. 1, Sch. 10 para. 2(8) (with art. 52)

C2040 S. 85 applied (14.9.2006) by The Borough of Poole (Poole Harbour Opening Bridges) Order 2006 (S.I. 2006/2310), art. 1, Sch. 8 para. 2(7) (with art. 40, Sch. 7 para. 12)

C2041 S. 85 applied (22.11.2006) by The Docklands Light Railway (Stratford International Extension) Order 2006 (S.I. 2006/2905), art. 1, Sch. 11 para. 2(8) (with art. 43)

C2042 S. 85 applied (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), art. 1, Sch. 10 para. 10(5)(a) (with arts. 34, 35(2), Sch. 10 para. 13)

C2043 S. 85 applied (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), art. 1, Sch. 9 para. 2(7) (with arts. 34, 35(2))

C2044 S. 85 applied (13.12.2006) by The Luton Dunstable Translink Order 2006 (S.I. 2006/3118), art. 1, Sch. 10 para. 2(7)

C2045 S. 85 applied (13.12.2006) by The Network Rail (Thameslink 2000) Order 2006 (S.I. 2006/3117), art. 1, Sch. 10 para. 21(8)(a) (with arts. 34, 35(2), Sch. 10 para. 26)

C2046 S. 85 applied (23.8.2007) by The Docklands Light Railway (Capacity Enhancement and 2012 Games Preparation) Order 2007 (S.I. 2007/2297), art. 1, Sch. 8 para. 2(8) (with arts. 3(6), 12(3))

C2047 S. 85 applied (14.10.2008) by The Felixstowe Branch Line and Ipswich Yard Improvement Order 2008 (S.I. 2008/2512), art. 1, Sch. 9 para. 2(7)(a) (with art. 36(3))

C2048 S. 85 applied (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), art. 1, Sch. 11 para. 2(8)(a) (with Sch. 13 para. 14(2), Sch. 14 para. 19)

C2049 S. 85 applied (18.9.2009) by The London Underground (Victoria Station Upgrade) Order 2009 (S.I. 2009/2364), art. 1, Sch. 8 para. 2(7)(a)

C2050 S. 85 applied (20.7.2010) by The Network Rail (Nuneaton North Chord) Order 2010 (S.I. 2010/1721), art. 1, Sch. 8 para. 2(7)(a)

C2051 S. 85 applied (1.2.2011) by The River Mersey (Mersey Gateway Bridge) Order 2011 (S.I. 2011/41), art. 1, Sch. 9 para. 2(7)(a) (with art. 51, Sch. 10 paras. 68, 85)

C2052 S. 85 applied (21.4.2011) by The Network Rail (Hitchin (Cambridge Junction)) Order 2011 (S.I. 2011/1072), art. 1, Sch. 11 para. 2(7)(a)

C2053 S. 85 applied (13.11.2012) by The Chiltern Railways (Bicester to Oxford Improvements) Order 2012 (S.I. 2012/2679), art. 1, Sch. 13 para. 2(7)(a) (with art. 42(2))

C2054 S. 85 applied (28.3.2013) by The Network Rail (Seaham Level Crossing) Order 2013 (S.I. 2013/533), art. 1, Sch. para. 2(7)(a)

C2055 S. 85 applied (22.8.2013) by The Leeds Railway Station (Southern Entrance) Order 2013 (S.I. 2013/1933), art. 1, Sch. 12 para. 2(7)(a)

C2056 S. 85 applied (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), art. 1, Sch. 9 para. 2(8)(a) (with arts. 57, 58, Sch. 11 para. 19)

C2057 S. 85 applied (21.4.2015) by The Network Rail (Ordsall Chord) Order 2015 (S.I. 2015/780), art. 1, Sch. 11 para. 7(a) (with art. 36(2))

C2058 S. 85 applied (12.1.2016) by The London Underground (Bank Station Capacity Upgrade) Order 2015 (S.I. 2015/2044), art. 1, Sch. 10 para. 2(7)(a)

C2059 S. 85: functions made exercisable concurrently (8.5.2017) by The West Midlands Combined Authority (Functions and Amendment) Order 2017 (S.I. 2017/510), arts. 1(2), 9(1)(a)(2)

C2060 S. 85 applied (24.8.2018) by The Network Rail (Werrington Grade Separation) Order 2018 (S.I. 2018/923), art. 1, Sch. 11 para. 2(7) (with art. 31(2))

C2061 S. 85 applied (13.3.2019) by The Port of Tilbury (Expansion) Order 2019 (S.I. 2019/359), arts. 1, 35(7)(a) (with arts. 55, 56)

C2062 S. 85 excluded (25.5.2020) by The West Midlands Rail Freight Interchange Order 2020 (S.I. 2020/511), art. 1, Sch. 13 Pt. 8 para. 3(3)

C2063 S. 85 excluded (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), art. 1, Sch. 16 para. 30(3) (with arts. 41, 42, Sch. 16 para. 66)

C2064 S. 85 excluded (22.7.2020) by The Norfolk Vanguard Offshore Wind Farm Order 2020 (S.I. 2020/706), art. 1, Sch. 16 para. 14(2) (with arts. 41, 42, Sch. 16 para. 66)

C2065 S. 85 excluded (29.10.2020) by The Southampton to London Pipeline Development Consent Order 2020 (S.I. 2020/1099), art. 1, Sch. 9 para. 122(3) (with art. 32, Sch. 9 para. 36)

C2066 S. 85(1)(3): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 4(c)

Provisions with respect to particular authorities and undertakings E+W

86 Highway authorities, highways and related matters. E+W

(1) In this Part—

• “highway authority” and “local highway authority” have the same meaning as in the M30 Highways Act 1980; and

• “maintainable highway” means a highway which for the purposes of that Act is maintainable at the public expense.

[F92 (1A) In this Part, “strategic highways company” means a company for the time being appointed under Part 1 of the Infrastructure Act 2015.]

(2) In this Part “works for road purposes” means works of any of the following descriptions executed in relation to a highway—

(a) works for the maintenance of the highway,

(b) any works under powers conferred by Part V of the Highways Act 1980 (improvement),

(c) the erection, maintenance, alteration or removal of traffic signs on or near the highway, or

(d) the construction of a crossing for vehicles across a footway or grass verge or the strengthening or adaptation of a footway for use as a crossing for vehicles,

or works of any corresponding description executed in relation to a street which is not a highway.

(3) In this Part “major highway works” means works of any of the following descriptions executed by the highway authority in relation to a highway which consists of or includes a carriageway—

(a) reconstruction or widening of the highway,

(b) works carried out in exercise of the powers conferred by section 64 of the Highways Act 1980 (dual carriageways and roundabouts),

(c) substantial alteration of the level of the highway,

(d) provision, alteration of the position or width, or substantial alteration in the level of a carriageway, footway or cycle track in the highway,

(e) the construction or removal of a road hump within the meaning of section 90F of the Highways Act 1980,

(f) works carried out in exercise of the powers conferred by section 184 of the Highways Act 1980 (vehicle crossings over footways and verges),

(g) provision of a cattle-grid in the highway or works ancillary thereto, or

(h) tunnelling or boring under the highway.

(4) Works executed under section 184(9) of the Highways Act 1980 by a person other than the highway authority shall also be treated for the purposes of this Part as major highway works; and in relation to such works the references in sections 84 and 85 to the highway authority shall be construed as references to him.

Textual Amendments

F92 S. 86(1A) inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 121; S.I. 2015/481, reg. 2(a)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2067 S. 86(3) extended (13.1.1999) by S.I. 1998/3269 art. 4(1)(a)

C2068 S. 86(3) applied (14.3.2002) by The Chester Guided Busway Order 2002 (S.I. 2002/412), art. 3(1)(a) (with art. 38)

Marginal Citations

M30 1980 c. 66.

87 Prospectively maintainable highways. E+W

(1) Where a local highway authority are satisfied that a street in their area (whether a highway or not) is likely to become a maintainable highway, they may make a declaration to that effect.

(2) The declaration shall be a local land charge.

(3) The provisions of this Part apply to a street in respect of which such a declaration has been made and registered as a local land charge as they apply to a maintainable highway.

(4) In relation to street works in such a street, the street authority—

(a) shall secure the performance by undertakers of their duties under this Part, and shall exercise their powers under this Part, in such manner as is reasonably required for the protection of the street managers; and

(b) shall comply with any reasonable request as to securing performance of those duties, or as to the exercise of those powers, which may be made by the street managers.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

88 Bridges, bridge authorities and related matters. E+W

(1) In this Part—

(a) references to a bridge include so much of any street as gives access to the bridge and any embankment, retaining wall or other work or substance supporting or protecting that part of the street; and

(b) “bridge authority” means the authority, body or person in whom a bridge is vested.

(2) In this Part “major bridge works” means works for the replacement, reconstruction or substantial alteration of a bridge.

(3) Where a street is carried or crossed by a bridge, any statutory right to place apparatus in the street includes the right to place apparatus in, and attach apparatus to, the structure of the bridge; and other rights to execute works in relation to the apparatus extend accordingly.

References in this Part to apparatus in the street include apparatus so placed or attached.

(4) An undertaker proposing to execute street works affecting the structure of a bridge shall consult the bridge authority before giving notice under section 55 (notice of starting date) [F93 , or making a notification under paragraph 2(1)(d) of Schedule 3A (notification of proposed works),] in relation to the works.

(5) An undertaker executing such works shall take all reasonably practicable steps—

(a) to give the bridge authority reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by them which is reasonably necessary for the protection of the bridge or for securing access to it.

(6) An undertaker who fails to comply with subsection (4) or (5) commits an offence in respect of each failure and is liable on summary conviction—

[F94 (a) in the case of an offence consisting of a failure to take all reasonably practicable steps to comply with subsection (5)(a), to a fine not exceeding level 4 on the standard scale; and

(b) in any other case, to a fine not exceeding level 5 on that scale.]

(7) Subsections (4) to (6) do not apply to works in relation to which Schedule 4 applies (works in streets with special engineering difficulties).

Textual Amendments

F93 Words in s. 88(4) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 52(6), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F94 S. 88(6)(a)(b) substituted for words in s. 88(6) (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(5), 99(1); S.I. 2004/2380, art. 2(d)(iii) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2069 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C2070 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C2071 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C2072 S. 88 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C2073 S. 88 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C2074 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C2075 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C2076 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C2077 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C2078 S. 88 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C2079 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C2080 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C2081 S. 88 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C2082 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C2083 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C2084 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C2085 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C2086 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C2087 S. 88 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C2088 S. 88 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C2089 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C2090 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C2091 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C2092 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C2093 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C2094 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C2095 S. 88 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C2096 S. 88 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C2097 S. 88 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch., Appendix B

C2098 S. 88 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C2099 S. 88 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C2100 S. 88 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C2101 S. 88 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C2102 S. 88 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch., Appendix D

C2103 S. 88 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C2104 S. 88 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch., Appendix C

C2105 S. 88 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C2106 S. 88 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C2107 S. 88 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C2108 S. 88 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C2109 S. 88 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C2110 S. 88 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C2111 S. 88 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C2112 S. 88 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C2113 S. 88 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C2114 S. 88 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C2115 S. 88 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C2116 S. 88 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C2117 S. 88 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C2118 S. 88 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C2119 S. 88 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C2120 S. 88 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C2121 S. 88 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C2122 S. 88 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C2123 S. 88 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C2124 S. 88 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C2125 S. 88 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C2126 S. 88 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C2127 S. 88 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C2128 S. 88 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C2129 S. 88 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C2130 S. 88 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C2131 S. 88 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C2132 S. 88 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C2133 S. 88 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C2134 S. 88 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C2135 S. 88 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C2136 S. 88 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C2137 S. 88 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C2138 S. 88 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C2139 S. 88 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C2140 S. 88 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C2141 S. 88 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C2142 S. 88 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C2143 S. 88 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C2144 S. 88 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C2145 S. 88 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C2146 S. 88 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C2147 S. 88 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C2148 S. 88(4)(5): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para.4(d)

C2149 S. 88(4) modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(5) (with reg. 35)

C2150 S. 88(4) modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(5)

89 Public sewers, sewer authorities and related matters. E+W

(1) In this Part—

(a) “sewer” and “public sewer” have the same meaning as in [F95 the M31 Water Industry Act 1991], and

(b) “sewer authority”, in relation to a public sewer, means the sewerage undertaker within the meaning of that Act in whom the sewer is vested.

(2) An undertaker proposing to execute street works affecting a public sewer shall consult the sewer authority before giving notice under section 55 (notice of starting date) [F96 , or making a notification under paragraph 2(1)(d) of Schedule 3A (notification of proposed works),] in relation to the works.

(3) References in this Part to apparatus include a sewer, drain or tunnel.

(4) References to the undertaker in relation to such apparatus, or in relation to street works in connection with such apparatus, shall be construed—

(a) in the case of a public sewer, as references to the sewer authority, and

(b) in any other case, as references to the authority, body or person having the management or control of the sewer, drain or tunnel.

(5) Section 69 (provisions as to works likely to affect other apparatus in the street) does not apply by virtue of subsection (3) above in relation to works likely to affect a public sewer if, or to the extent that, Schedule 4 (works in streets with special engineering difficulties) applies.

Textual Amendments

F95 Words in s. 89(1) substituted (1.12.1991) by Water Consolidation (Consequential Provisions) Act 1991 (c. 60, SIF 130), ss. 2(1), 4(2), Sch. 1 para. 57(1)

F96 Words in s. 89(2) inserted (1.4.2008) by Traffic Management Act 2004 (c. 18), ss. 52(7), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2151 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C2152 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C2153 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C2154 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C2155 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C2156 S. 89 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C2157 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C2158 S. 89 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B, Appendix B

C2159 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C2160 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C2161 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C2162 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C2163 S. 89 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C2164 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C2165 S. 89 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C2166 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C2167 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C2168 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C2169 S. 89 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C2170 S. 89 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C2171 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C2172 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C2173 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C2174 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C2175 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C2176 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch., Appendix B

C2177 S. 89 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C2178 S. 89 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C2179 S. 89 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch., Appendix B

C2180 S. 89 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C2181 S. 89 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C2182 S. 89 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C2183 S. 89 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C2184 S. 89 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C2185 S. 89 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C2186 S. 89 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch., Appendix C

C2187 S. 89 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch., Appendix C

C2188 S. 89 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch., Appendix C

C2189 S. 89 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C2190 S. 89 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C2191 S. 89 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C2192 S. 89 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C2193 S. 89 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C2194 S. 89 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C2195 S. 89 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C2196 S. 89 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C2197 S. 89 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C2198 S. 89 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C2199 S. 89 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C2200 S. 89 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C2201 S. 89 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C2202 S. 89 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C2203 S. 89 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C2204 S. 89 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C2205 S. 89 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C2206 S. 89 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C2207 S. 89 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C2208 S. 89 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C2209 S. 89 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C2210 S. 89 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C2211 S. 89 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C2212 S. 89 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C2213 S. 89 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C2214 S. 89 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C2215 S. 89 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C2216 S. 89 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C2217 S. 89 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C2218 S. 89 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C2219 S. 89 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C2220 S. 89 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C2221 S. 89 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C2222 S. 89 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C2223 S. 89 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C2224 S. 89 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C2225 S. 89 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C2226 S. 89 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C2227 S. 89 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C2228 S. 89 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C2229 S. 89 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C2230 S. 89(2) modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(6) (with reg. 35)

C2231 S. 89(2) modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(6)

Marginal Citations

M31 1991 c. 56

90 Provisions as to reinstatement of sewers, drains or tunnels. E+W

(1) The duties of an undertaker under this Part with respect to reinstatement of the street extend, in the case of street works which involve breaking up or opening a sewer, drain or tunnel, to the reinstatement of the sewer, drain or tunnel.

(2) The responsible authority may by notice require an undertaker who has failed to comply with his duties under this Part with respect to reinstatement to carry out the necessary remedial works within such period of not less than 7 working days as may be specified in the notice.

If he fails to comply with the notice, the authority may carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

(3) If it appears to the responsible authority that a failure by an undertaker to comply with his duties under this Part as to reinstatement is causing danger to users of the street, the authority may carry out the necessary works without first giving notice and may recover from him the costs reasonably incurred by them in doing so.

They shall, however, give notice to him as soon as reasonably practicable stating their reasons for taking immediate action.

(4) The responsible authority for the purposes of this section is—

(a) in the case of a public sewer, the sewer authority, and

(b) in the case of any other sewer, drain or tunnel, the authority, body or person having the management or control of it.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2232 S. 90: functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para. 5

C2233 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Islington) Permit Scheme Order 2009 (S.I. 2009/3180), art. 1, Sch. Appendix B

C2234 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Hammersmith and Fulham) Permit Scheme Order 2009 (S.I. 2009/3168), art. 1, Sch. Appendix B

C2235 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Brent) Permit Scheme Order 2009 (S.I. 2009/3142), art. 1, Sch. Appendix B

C2236 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Croydon) Permit Scheme Order 2009 (S.I. 2009/3158), art. 1, Sch. Appendix B

C2237 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Lewisham) Permit Scheme Order 2009 (S.I. 2009/3171), art. 1, Sch. Appendix B

C2238 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Hounslow) Permit Scheme Order 2009 (S.I. 2009/3178), art. 1, Sch. Appendix B

C2239 S. 90 modified (11.1.2010) by The Traffic Management (City of Westminster) Permit Scheme Order 2009 (S.I. 2009/3187), art. 1, Sch. Appendix B

C2240 S. 90 modified (11.1.2010) by The Traffic Management (Transport for London) Permit Scheme Order 2009 (S.I. 2009/3186), art. 1, Sch. Appendix B

C2241 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Bromley) Permit Scheme Order 2009 (S.I. 2009/3148), art. 1, Sch. Appendix B

C2242 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Ealing) Permit Scheme Order 2009 (S.I. 2009/3163), art. 1, Sch. Appendix B

C2243 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Haringey) Permit Scheme Order 2009 (S.I. 2009/3169), art. 1, Sch. Appendix B

C2244 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Barnet) Permit Scheme Order 2009 (S.I. 2009/3141), art. 1, Sch. Appendix B

C2245 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Hackney) Permit Scheme Order 2009 (S.I. 2009/3167), art. 1, Sch. Appendix B

C2246 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Enfield) Permit Scheme Order 2009 (S.I. 2009/3165), art. 1, Sch. Appendix B

C2247 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Camden) Permit Scheme Order 2009 (S.I. 2009/3149), art. 1, Sch. Appendix B

C2248 S. 90 modified (11.1.2010) by The Traffic Management (Royal Borough of Kensington and Chelsea) Permit Scheme Order 2009 (S.I. 2009/3170), art. 1, Sch. Appendix B

C2249 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Redbridge) Permit Scheme Order 2009 (S.I. 2009/3179), art. 1, Sch. Appendix B

C2250 S. 90 modified (11.1.2010) by The Traffic Management (City of London Corporation) Permit Scheme Order 2009 (S.I. 2009/3162), art. 1, Sch. Appendix B

C2251 S. 90 modified (11.1.2010) by The Traffic Management (London Borough of Wandsworth) Permit Scheme Order 2009 (S.I. 2009/3189), art. 1, Sch. Appendix B

C2252 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Waltham Forest) Permit Scheme Order 2011 (S.I. 2011/1959), art. 1, Sch. Appendix B

C2253 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Lambeth) Permit Scheme Order 2011 (S.I. 2011/1958), art. 1, Sch. Appendix B

C2254 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Richmond upon Thames) Permit Scheme Order 2011 (S.I. 2011/1960), art. 1, Sch. Appendix B

C2255 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Greenwich) Permit Scheme Order 2011 (S.I. 2011/1956), art. 1, Sch. Appendix B

C2256 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Southwark) Permit Scheme Order 2011 (S.I. 2011/1957), art. 1, Sch. Appendix B

C2257 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Harrow) Permit Scheme Order 2011 (S.I. 2011/1961), art. 1, Sch. Appendix B

C2258 S. 90 modified (5.9.2011) by The Traffic Management (London Borough of Newham) Permit Scheme Order 2011 (S.I. 2011/1962), art. 1, Sch. Appendix B

C2259 S. 90 modified (28.11.2011) by The Traffic Management (London Borough of Barking and Dagenham) Permit Scheme Order 2011 (S.I. 2011/2599), art. 1, Sch., Appendix B

C2260 S. 90 modified (28.11.2011) by The Traffic Management (London Borough of Hillingdon) Permit Scheme Order 2011 (S.I. 2011/2600), art. 1, Sch., Appendix B

C2261 S. 90 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C2262 S. 90 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C2263 S. 90 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C2264 S. 90 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C2265 S. 90 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C2266 S. 90 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C2267 S. 90 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C2268 S. 90 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix C

C2269 S. 90 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch. Appendix C

C2270 S. 90 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch., Appendix C

C2271 S. 90 modified (14.1.2013) by The Traffic Management (London Borough of Tower Hamlets) Permit Scheme Order 2012 (S.I. 2012/3107), arts. 1, 2, Sch. Appendix B

C2272 S. 90 modified (14.1.2013) by The Traffic Management (London Borough of Sutton) Permit Scheme Order 2012 (S.I. 2012/3106), arts. 1, 2, Sch. Appendix B

C2273 S. 90 modified (18.2.2013) by The Traffic Management (London Borough of Bexley) Permit Scheme Order 2012 (S.I. 2012/3102), arts. 1, 2, Sch. Appendix B

C2274 S. 90 modified (1.3.2013) by The Traffic Management (Royal Borough of Kingston upon Thames) Permit Scheme Order 2012 (S.I. 2012/3104), arts. 1, 2, Sch. Appendix B1

C2275 S. 90 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C2276 S. 90 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C2277 S. 90 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C2278 S. 90 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C2279 S. 90 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C2280 S. 90 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch., Appendix E

C2281 S. 90 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C2282 S. 90 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C2283 S. 90 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C2284 S. 90 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C2285 S. 90 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C2286 S. 90 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C2287 S. 90 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C2288 S. 90 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C2289 S. 90 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C2290 S. 90 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C2291 S. 90 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C2292 S. 90 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

91 Transport authorities, transport undertakings and related matters. E+W

(1) In this Part—

(a) “transport authority” means the authority, body or person having the control or management of a transport undertaking; and

(b) “transport undertaking” means a railway, tramway, dock, harbour, pier, canal or inland navigation undertaking of which the activities, or some of the activities, are carried on under statutory authority.

(2) In this Part “major transport works” means substantial works required for the purposes of a transport undertaking and executed in property held or used for the purposes of the undertaking.

(3) References in this Part to a street which crosses or is crossed by property held or used for the purposes of a transport undertaking extend to cases in which the street and the property in question are at different levels.

But the transport authority shall not be treated as a relevant authority as regards undertakers’ works in such a street where the property in question consists only of—

(a) subsoil of the street which is held by the transport authority but is not used, and has not been adapted for use, for the purposes of the transport undertaking, or

(b) property underground at such a depth that there is no reasonable possibility of the works affecting it.

(4) The provisions of this Part relating to a street which crosses or is crossed by property held or used for the purposes of a transport undertaking apply to a street which is or forms part of a towing-path or other way running along a canal or inland navigation, provided the path or way is held or used, or the subsoil of it is held, for the purposes of the canal or inland navigation undertaking.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

92 Special precautions as to displaying of lights. E+W

(1) An undertaker executing street works in a street which crosses, or is crossed by, or is in the vicinity of, a railway, tramway, dock, harbour, pier, canal or inland navigation, shall comply with any reasonable requirements imposed by the transport authority concerned with respect to the displaying of lights so as to avoid any risk of their—

(a) being mistaken for any signal light or other light used for controlling, directing or securing the safety of traffic thereon, or

(b) being a hindrance to the ready interpretation of any such signal or other light.

(2) An undertaker who fails to comply with any such requirement commits an offence and is liable on summary conviction to a fine not exceeding [F97 level 5] on the standard scale.

(3) In proceedings for such an offence it is a defence for the undertaker to show that all reasonable care was taken by him, and by his contractors and by persons in his employ or that of his contractors, to secure that no such failure occurred.

Textual Amendments

F97 Words in s. 92(2) substituted (4.10.2004 for E., 26.11.2007 for W.) by Traffic Management Act 2004 (c. 18), ss. 40(1)(2), 99(1), Sch. 1; S.I. 2004/2380, art. 2(d)(i) (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 4)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

93 Works affecting level crossings or tramways. E+W

(1) This section applies to street works at a crossing of a railway on the level or which affect a tramway.

In this section “the relevant transport authority” means the authority having the management of the railway or tramway undertaking concerned.

(2) An undertaker proposing to begin to execute works to which this section applies shall give the prescribed notice to the relevant transport authority notwithstanding that such notice is not required under section 55 (notice of starting date).

The provisions of subsections (2) to [F98 (9)] of that section (contents of notice, when works may be begun, &c.) apply in relation to the notice required by this subsection as in relation to a notice under subsection (1) of that section.

(3) An undertaker executing works to which this section applies shall comply with any reasonable requirements made by the relevant transport authority—

(a) for securing the safety of persons employed in connection with the works, or

(b) for securing that interference with traffic on the railway or tramway caused by the execution of the works is reduced so far as is practicable;

and, except where submission of a plan and section is required, he shall defer beginning the works for such further period as the relevant transport authority may reasonably request as needed for formulating their requirements under this subsection or making their traffic arrangements.

(4) Nothing in subsection (2) or (3) affects the right of an undertaker to execute emergency works.

(5) An undertaker executing emergency works shall give notice to the relevant transport authority as soon as reasonably practicable of his intention or, as the case may be, of his having begun to do so notwithstanding that such notice is not required by section 57 (notice of emergency works).

The provisions of subsections (3) and (4) of that section (contents of notice and penalty for failure to give notice) apply in relation to the notice required by this subsection as in relation to a notice under subsection (2) of that section.

Textual Amendments

F98 Word in s. 93(2) substituted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 1.4.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 49(3), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 5); S.I. 2007/3174, art. 2, Sch. (with art. 6)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2293 S. 93 modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(7) (with reg. 35)

C2294 S. 93 modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(7)

C2295 S. 93 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C2296 S. 93 modified (12.6.2012) by The Traffic Management (The Council of the Borough of Kirklees) Permit Scheme Order 2012 (S.I. 2012/1286), arts. 1, 2, Sch. Appendix D

C2297 S. 93 modified (12.6.2012) by The Traffic Management (Barnsley Metropolitan Borough Council) Permit Scheme Order 2012 (S.I. 2012/1289), arts. 1, 2, Sch. Appendix D

C2298 S. 93 modified (12.6.2012) by The Traffic Management (Rotherham Borough Council) Permit Scheme Order 2012 (S.I. 2012/1284), arts. 1, 2, Sch. Appendix D

C2299 S. 93 modified (12.6.2012) by The Traffic Management (Sheffield City Council) Permit Scheme Order 2012 (S.I. 2012/1294), arts. 1, 2, Sch. Appendix D

C2300 S. 93 modified (12.6.2012) by The Traffic Management (Doncaster Borough Council) Permit Scheme Order 2012 (S.I. 2012/1282), arts. 1, 2, Sch. Appendix D

C2301 S. 93 modified (12.6.2012) by The Traffic Management (Leeds City Council) Permit Scheme Order 2012 (S.I. 2012/1295), arts. 1, 2, Sch. Appendix D

C2302 S. 93 modified (5.11.2012) by The Traffic Management (Bedford Borough Council) Permit Scheme Order 2012 (S.I. 2012/2541), arts. 1, 2, Sch. Appendix C

C2303 S. 93 modified (5.11.2012) by The Traffic Management (Hertfordshire County Council) Permit Scheme Order 2012 (S.I. 2012/2549), arts. 1, 2, Sch. Appendix C

C2304 S. 93 modified (5.11.2012) by The Traffic Management (Southend-On-Sea Borough Council) Permit Scheme Order 2012 (S.I. 2012/2548), arts. 1, 2, Sch., Appendix C

C2305 S. 93 modified (5.11.2012) by The Traffic Management (Luton Borough Council) Permit Scheme Order 2012 (S.I. 2012/2547), arts. 1, 2, Sch. Appendix C

C2306 S. 93 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C2307 S. 93 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C2308 S. 93 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C2309 S. 93 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C2310 S. 93 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C2311 S. 93 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C2312 S. 93 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C2313 S. 93 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C2314 S. 93 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C2315 S. 93 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C2316 S. 93 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C2317 S. 93 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C2318 S. 93 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C2319 S. 93 modified (1.4.2014) by The Traffic Management (Shropshire Council) Permit Scheme Order 2014 (S.I. 2014/466), arts. 1, 2, Sch., Appendix B

C2320 S. 93 modified (6.5.2014) by The Traffic Management (Norfolk County Council) Permit Scheme Order 2014 (S.I. 2014/941), arts. 1, 2, Sch., Appendix C

C2321 S. 93 modified (3.11.2014) by The Traffic Management (Cheshire East Borough Council) Permit Scheme Order 2014 (S.I. 2014/2460), art. 1, Sch. Appendix B

C2322 S. 93 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C2323 S. 93 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C2324 S. 93 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C2325 S. 93 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C2326 S. 93 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C2327 S. 93 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C2328 S. 93 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C2329 S. 93 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C2330 S. 93 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C2331 S. 93 modified (16.3.2015) by The Traffic Management (Warwickshire County Council) Permit Scheme Order 2014 (S.I. 2014/3310), arts. 1, 2, Sch. para. 17.2, Appendix B

C2332 S. 93 modified (16.3.2015) by The Traffic Management (Nottingham City Council) Permit Scheme Order 2015 (S.I. 2015/39), arts. 1, 2, Sch. 1 Appendix C

C2333 S. 93 modified (16.3.2015) by The Traffic Management (Essex County Council) Permit Scheme Order 2015 (S.I. 2015/37), arts. 1, 2, Sch., Appendix C

C2334 S. 93 modified (16.3.2015) by The Traffic Management (Coventry City Council) Permit Scheme Order 2014 (S.I. 2014/3311), arts. 1, 2, Sch. para. 17.2, Appendix B

C2335 S. 93 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C2336 S. 93 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C2337 S. 93 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C2338 S. 93 modified (31.3.2015) by The Traffic Management (City of Bradford Metropolitan District Council) Permit Scheme Order 2015 (S.I. 2015/330), arts. 1, 2, Sch., Appendix D

C2339 S. 93 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

C2340 S. 93 modified (31.3.2015) by The Traffic Management (Borough Council of Calderdale) Permit Scheme Order 2015 (S.I. 2015/328), arts. 1, 2, Sch., Appendix D

C2341 S. 93 modified (31.3.2015) by The Traffic Management (Council of the City of Wakefield MDC) Permit Scheme Order 2015 (S.I. 2015/293), arts. 1, 2, Sch., Appendix D

C2342 S. 93(3) modified (9.6.2009) by The Nottingham Express Transit System Order 2009 (S.I. 2009/1300), arts. 1, 4(9) (with Sch. 13 para. 14(2), Sch. 14 para. 19, Sch. 16)

C2343 S. 93(3) modified (6.11.2013) by The Transport for Greater Manchester (Light Rapid Transit System) (Second City Crossing) Order 2013 (S.I. 2013/2587), arts. 1, 4(9) (with arts. 42, 43)

C2344 S. 93(3) modified (9.1.2014) by The Ashton Vale to Temple Meads and Bristol City Centre Rapid Transit Order 2013 (S.I. 2013/3244), arts. 1, 4(10) (with arts. 57, 58, Sch. 11 para. 19)

C2345 S. 93(3) modified (24.11.2016) by The Transport for Greater Manchester (Light Rapid Transit System) (Trafford Park Extension) Order 2016 (S.I. 2016/1035), arts. 1, 4(9) (with arts. 43, 44)

C2346 S. 93(3) modified (4.1.2018) by The Blackpool Tramway (Blackpool North Extension) Order 2017 (S.I. 2017/1214), arts. 1, 5(9) (with arts. 58, 59)

Power of street authority or district council to undertake street works E+W

94 Power of street authority or district council to undertake street works. E+W

(1) A street authority or district council may enter into an agreement with an undertaker for the execution by the authority or council on behalf of the undertaker of any street works.

[F99 (1A) In subsection (1), the reference to a district council, is to be read, in relation to Wales, as a reference to a county council or a county borough council.]

(2) The agreement may contain such terms as to payment and otherwise as the parties consider appropriate.

(3) Nothing in this section shall be construed as derogating from any powers exercisable by the authority or council apart from this section.

(4) This section shall cease to have effect upon such day as the Secretary of State may appoint by order made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Textual Amendments

F99 S. 94(1A) inserted (1.4.1996) by 1994 c. 19 ss. 22(1), Sch. 7 Pt. I para. 32(1) (with ss. 54(5)(7), 55(5), Sch. 17 paras. 22(1), 23(2)); 1996/396, art. 3, Sch. 1

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2347 S. 94(1)(2): functions of a local authority made exercisable by, or by employees of, such person as may be authorised in that behalf by the local highway authority whose function it is (23.7.1999) by S.I. 1999/2106, art. 2, Sch. 2 para.

Supplementary provisions E+W

95 Offences. E+W

(1) Any provision of this Part imposing criminal liability in respect of any matter is without prejudice to any civil liability in respect of the same matter.

(2) Where a failure to comply with a duty imposed by this Part is continued after conviction, the person in default commits a further offence.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

[F100 95A Fixed penalties for certain offences under this Part E+W

(1) Any offence under this Part relating to any street works which is listed in the first column of Schedule 4A (and described in general terms in the second column) is a fixed penalty offence for the purposes of this Part.

(2) Offences listed in that Schedule which are committed by virtue of section 166 (offences by bodies corporate and Scottish partnerships) are not fixed penalty offences.

(3) The Secretary of State may by order modify that Schedule so as to provide for offences under this Part relating to any street works to become (or cease to be) fixed penalty offences.

(4) Such an order may not be made unless a draft of the order has been laid before and approved by resolution of each House of Parliament.

(5) Schedule 4B (which makes provision about fixed penalties for fixed penalty offences) has effect.]

Textual Amendments

F100 S. 95A inserted (29.6.2007 for E. for specified purposes, 26.11.2007 for W. for specified purposes, 12.5.2008 for E.W. in so far as not already in force) by Traffic Management Act 2004 (c. 18), ss. 41(1), 99(1); S.I. 2007/1890, art. 2, Sch. (with art. 3); S.I. 2007/3174, art. 2, Sch. (with art. 3)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2348 S. 95A(1) excluded (W.) (12.5.2008) by The Street Works (Fixed Penalty) (Wales) Regulations 2008 (S.I. 2008/102), regs. 1, 3

C2349 S. 95A(1) excluded (E.) (12.5.2008) by The Street Works (Fixed Penalty) (England) Regulations 2007 (S.I. 2007/1952), regs. 1(1), 3

96 Recovery of costs or expenses. E+W

(1) Any provision of this Part enabling an authority, body or person to recover the costs or expenses of taking any action shall be taken to include the relevant administrative expenses of that authority, body or person including an appropriate sum in respect of general staff costs and overheads.

The Secretary of State may prescribe the basis on which such amounts are to be calculated; and different provision may be made for different cases or descriptions of case.

(2) Where a right to payment enuring for the benefit of a person is conferred in respect of the same matter—

(a) both under this Part and under any enactment or agreement passed or made before the commencement of this Part, or

(b) by two or more provisions of this Part,

a payment made in discharge of any of those rights shall be treated as being made in or towards satisfaction of the other or others.

(3) Where under any provision of this Part a person is entitled in certain circumstances to recover costs or expenses incurred by him in executing works or taking other steps, any dispute as to the existence of those circumstances or as to the amount recoverable shall be determined by arbitration.

This applies whether the provision is expressed as conferring a right to recover, or as imposing a liability to reimburse or indemnify or to bear the cost, but does not apply in relation to a provision expressed as providing for the charging of a fee or conferring a right to compensation or in relation to section 78 (contributions to cost of making good long-term damage to the street).

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

97 Service of notices and other documents. E+W

(1) Notices required or authorised to be given for the purposes of this Part shall be given in the prescribed form.

(2) The Secretary of State may make provision by regulations as to the manner of service of notices and other documents required or authorised to be served for the purposes of this Part.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

98 Reckoning of periods. E+W

(1) In reckoning for the purposes of this Part a period expressed as a period from or before a given date, that date shall be excluded.

(2) For the purposes of this Part a working day means a day other than a Saturday, Sunday, Christmas Day, Good Friday or a bank holiday; and a notice given after 4.30 p.m. on a working day shall be treated as given on the next working day.

(3) In subsection (2) a “bank holiday” means a day which is a bank holiday under the M32 Banking and Financial Dealings Act 1971 in the locality in which the street in question is situated.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Marginal Citations

M32 1971 c. 80.

99 Arbitration. E+W

Any matter which under this Part is to be settled by arbitration shall be referred to a single arbitrator appointed by agreement between the parties concerned or, in default of agreement, by the President of the Institution of Civil Engineers.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

100 Agreements inconsistent with the provisions of this Part. E+W

(1) An agreement which purports to make provision regulating the execution of street works is of no effect to the extent that it is inconsistent with the provisions of this Part.

(2) This does not affect an agreement for the waiver or variation of a right conferred on a relevant authority by any of the provisions of this Part which is made after the right has accrued and is not inconsistent with the future operation of those provisions.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

101 Effect of this Part on certain existing special enactments or instruments. E+W

(1) Any special enactment passed or made before the commencement of this Part which makes or authorises the making of provision regulating the execution of street works in a manner inconsistent with the provisions of this Part shall cease to have effect; and unless a contrary intention appears no enactment passed or made after the commencement of this Part shall be construed as making or authorising the making of any such provision.

This subsection does not apply to any provision as to the obtaining of consent for the execution of the works or for any other purpose.

(2) Any special enactment passed or made before the commencement of this Part which requires the consent of a relevant authority (in its capacity as such) to the execution of street works shall cease to have effect, except as mentioned below; and unless a contrary intention appears no special enactment passed or made after the commencement of this Part shall be construed as requiring such consent.

This subsection does not apply to a consent requirement so far as it relates to—

(a) works above the surface of the highway, or

(b) works outside the limits of supply of an undertaker in relation to whom such limits are imposed.

(3) A provision made by way of condition imposed on the giving of a consent for the execution of street works is of no effect in so far as it would have been so by virtue of section 100 if it had been made by an agreement.

(4) If it appears to the Secretary of State—

(a) that by the operation of subsection (1) a person has been or will be deprived of some protection afforded by a special enactment and that corresponding protection is in all the circumstances required, or

(b) that a requirement of consent imposed by a special enactment should be saved from the operation of subsection (2), either as regards all works to which the requirement extends or as regards any description of such works, or

(c) that conditions of any descriptions should be rendered valid notwithstanding subsection (3), or

(d) that uncertainty or obscurity has resulted or is likely to result from the operation on a special enactment of the general provisions of subsection (1), (2) or (3),

he may by order make such provision as he considers appropriate for affording such protection, saving the requirement, rendering the conditions valid or modifying the special enactment, as the case may be.

(5) An order under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament; and the provisions of Schedule 5 have effect with respect to the procedure for making such an order.

(6) The provisions of this section apply in relation to an instrument having effect under or by virtue of an enactment as in relation to an enactment; and references to a special enactment shall be construed accordingly.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

102 Effect of this Part on other existing enactments or instruments. E+W

(1) The Secretary of State may by order make such provision amending, repealing, or preserving the effect of, any enactment passed or made before the commencement of this Part (not being a special enactment to which section 101(1), (2) or (3) applies) as appears to him appropriate in consequence of the provisions of this Part.

(2) Subject to any order under this section and (in the case of a public general Act) to any express amendment made by this Act, any such enactment which proceeds by reference to any provision of the M33 Public Utilities Street Works Act 1950, or any other provision repealed by this Act in consequence of this Part, shall continue to have effect as if the provision referred to had not been repealed.

(3) An order under this section may, in particular, make provision in relation to—

(a) enactments providing for the keeping of records of apparatus, and

(b) enactments providing for the giving of notice of proposed street works.

(4) An order under this section may contain such transitional provisions and savings as appear to the Secretary of State to be appropriate.

(5) An order under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

(6) Except as mentioned in section 79(6), the provisions of Schedule 5 have effect with respect to the making of an order under this section in relation to a special enactment.

(7) The provisions of this section apply in relation to an instrument having effect under or by virtue of an enactment as in relation to an enactment; and references to a special enactment shall be construed accordingly.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Marginal Citations

M33 1950 c. 39.

103 Former controlled land. E+W

(1) The following provisions apply with respect to land (not forming part of a street) in which immediately before the commencement of this Part there is apparatus placed by virtue of Schedule 1 to the Public Utilities Street Works Act 1950 (authorisation of works in certain land abutting the highway).

(2) If any person having a sufficient interest in the land gives notice to the undertaker that he objects to the continuance of the powers and rights over the land given by that Schedule, those powers and rights shall cease to have effect at the end of the period of six months from the date on which the notice was given.

For this purpose a person has a sufficient interest in the land if he is an owner, lessee or occupier of the land having an interest greater than that of tenant for a year or from year to year.

(3) The street authority shall indemnify the undertaker in respect of the costs reasonably incurred by him in or in connection with—

(a) the removal of apparatus rendered necessary by the cessation of his powers and rights under this section, and

(b) the execution of any works, or taking of any other measures, rendered necessary for the purposes of the supply or service for which the apparatus was used.

(4) Where the land becomes part of the street after the commencement of this Part, any consent which would have been required for the placing of the apparatus in the street had it been placed there immediately after the land in question became part of the street shall be deemed to have been given unconditionally.

(5) Subject to any exercise of the right conferred by subsection (2), the rights and powers of the undertaker under Schedule 1 to the M34 Public Utilities Street Works Act 1950 continue unaffected by the repeal of that Act.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Marginal Citations

M34 1950 c. 39.

104 Meaning of “prescribed” and regulations generally. E+W

(1) In this Part “prescribed” means prescribed by the Secretary of State by regulations, which may (unless the context otherwise requires) make different provision for different cases.

(2) Regulations under this Part shall be made by statutory instrument which, unless provision to the contrary is made, shall be subject to annulment in pursuance of a resolution of either House of Parliament.

(3) Regulations under this Part may provide for references in the regulations to any specified document to operate as references to that document as revised or re-issued from time to time.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

105 Minor definitions. E+W

(1) In this Part—

• “apparatus” includes any structure for the lodging therein of apparatus or for gaining access to apparatus;

• “carriageway” and “footway” have the same meaning as in the M35 Highways Act 1980;

• “enactment” includes an enactment contained in subordinate legislation within the meaning of the M36 Interpretation Act 1978;

• “in”, in a context referring to works, apparatus or other property in a street or other place includes a reference to works, apparatus or other property under, over, across, along or upon it;

• “railway” includes a light railway other than one in the nature of a tramway (see the definition of “tramway” below);

• “reinstatement” includes making good;

• “special enactment” means an enactment which is not a public general enactment, and includes—

  (a)

  any Act for confirming a provisional order,

  (b)

  any provision of a public general Act in relation to the passing of which any of the Standing Orders of the House of Lords or the House of Commons relating to Private Business applied, and

  (c)

  any enactment to the extent that it is incorporated or applied for the purposes of a special enactment;

• “statutory right” means a right (whether expressed as a right, a power or otherwise) conferred by an enactment (whenever passed or made), other than a right exercisable by virtue of a street works licence;

• “traffic” includes pedestrians and animals;

• “traffic authority” and “traffic sign” have the same meaning as in the M37 Road Traffic Regulation Act 1984;

• “tramway” means a system, mainly or exclusively for the carriage of passengers, using vehicles guided, or powered by energy transmitted, by rails or other fixed apparatus installed exclusively or mainly in a street.

(2) A right to execute works which extends both to a street and to other land is included in references in this Part to a right to execute works in a street in so far as it extends to the street.

(3) A right to execute works which extends to part of the street but not the whole is included in references in this Part to a right to execute works in a street; and in relation to such a right references in this Part to the street in which it is exercisable shall be construed as references to the part to which the right extends.

(4) For the purposes of this Part apparatus shall be regarded as affected by works if the effect of the works is to prevent or restrict access to the apparatus (for example, by laying other apparatus above or adjacent to it).

(5) Section 28 of the M38 Chronically Sick and Disabled Persons Act 1970 (power to define “disability” and other expressions) applies in relation to the provisions of this Part as to the provisions of that Act.

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

C2350 S. 105 modified (E.) (1.4.2008) by The Traffic Management Permit Scheme (England) Regulations 2007 (S.I. 2007/3372), regs. 1(1), 37(8) (with reg. 35)

C2351 S. 105 modified (W.) (1.6.2009) by The Traffic Management Permit Scheme (Wales) Regulations 2009 (S.I. 2009/1267), regs. 1, 37(8)

C2352 S. 105 modified (25.1.2010) by The Traffic Management (Kent County Council) Permit Scheme Order 2009 (S.I. 2009/3188), art. 1, Sch. Appendix B

C2353 S. 105 modified (29.4.2013) by The Traffic Management (Salford City Council) Permit Scheme Order 2013 (S.I. 2013/810), arts. 1, 2, Sch. Appendix C

C2354 S. 105 modified (29.4.2013) by The Traffic Management (Oldham Borough Council) Permit Scheme Order 2013 (S.I. 2013/808), arts. 1, 2, Sch. Appendix C

C2355 S. 105 modified (29.4.2013) by The Traffic Management (Rochdale Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/809), arts. 1, 2, Sch. Appendix C

C2356 S. 105 modified (29.4.2013) by The Traffic Management (Bury Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/814), arts. 1, 2, Sch. Appendix C

C2357 S. 105 modified (29.4.2013) by The Traffic Management (The Council of the City of Manchester) Permit Scheme Order 2013 (S.I. 2013/811), arts. 1, 2, Sch. Appendix C

C2358 S. 105 modified (29.4.2013) by The Traffic Management (Tameside Metropolitan Borough Council) Permit Scheme Order 2013 (S.I. 2013/806), arts. 1, 2, Sch. Appendix C

C2359 S. 105 modified (29.4.2013) by The Traffic Management (Wigan Borough Council) Permit Scheme Order 2013 (S.I. 2013/812), arts. 1, 2, Sch. Appendix C

C2360 S. 105 modified (29.4.2013) by The Traffic Management (The Metropolitan Borough Council of Stockport) Permit Scheme Order 2013 (S.I. 2013/805), arts. 1, 2, Sch. Appendix C

C2361 S. 105 modified (29.4.2013) by The Traffic Management (The Borough Council of Bolton) Permit Scheme Order 2013 (S.I. 2013/813), arts. 1, 2, Sch. Appendix C

C2362 S. 105 modified (1.10.2013) by The Traffic Management (Derby City Council) Permit Scheme Order 2013 (S.I. 2013/1781), arts. 1, 2, Sch. para. 2.4

C2363 S. 105 modified (4.11.2013) by The Traffic Management (Buckinghamshire County Council) Permit Scheme Order 2013 (S.I. 2013/2398), art. 1, Sch. para. 1.5, Appendix A

C2364 S. 105 modified (11.11.2013) by The Traffic Management (East Sussex County Council) Permit Scheme Order 2013 (S.I. 2013/2399), arts. 1, 2, Sch. para. 2.12.2

C2365 S. 105 modified (11.11.2013) by The Traffic Management (Surrey County Council) Permit Scheme Order 2013 (S.I. 2013/2389), arts. 1, 2, Sch. para. 2.12.2

C2366 S. 105 modified (19.1.2015) by The Traffic Management (Wokingham Borough Council) Permit Scheme Order 2014 (S.I. 2014/3105), arts. 1, 2, Sch. para. 2.12.2

C2367 S. 105 modified (2.2.2015) by The Traffic Management (Warrington Borough Council) Permit Scheme Order 2014 (S.I. 2014/3108), arts. 1, 2, Sch. para. 1.8

C2368 S. 105 modified (2.2.2015) by The Traffic Management (Cheshire West and Chester Borough Council) Permit Scheme Order 2014 (S.I. 2014/3106), arts. 1, 2, Sch. para. 1.8

C2369 S. 105 modified (2.2.2015) by The Traffic Management (Sefton Metropolitan Borough Council) Permit Scheme Order 2014 (S.I. 2014/3107), arts. 1, 2, Sch. para. 1.9

C2370 S. 105 modified (9.2.2015) by The Traffic Management (North Tyneside Council) Permit Scheme Order 2014 (S.I. 2014/3109), arts. 1, 2, Sch. para. 1.5, Appendix E

C2371 S. 105 modified (1.3.2015) by The Traffic Management (West Berkshire Council) Permit Scheme Order 2014 (S.I. 2014/3110), arts. 1, 2, Sch. para. 2.12.2

C2372 S. 105 modified (2.3.2015) by The Traffic Management (Knowsley Metropolitan Borough Council) Permit Scheme Order 2015 (S.I. 2015/34), arts. 1, 2, Sch. para. 1.8

C2373 S. 105 modified (4.3.2015) by The Traffic Management (Slough Borough Council) Permit Scheme Order 2014 (S.I. 2014/3112), arts. 1, 2, Sch. para. 2.12.2

C2374 S. 105 modified (9.3.2015) by The Traffic Management (Lancashire County Council) Permit Scheme Order 2015 (S.I. 2015/38), arts. 1, 2, Sch. para. 1.8

C2375 S. 105 modified (30.3.2015) by The Traffic Management (Brighton and Hove City Council) Permit Scheme Order 2015 (S.I. 2015/90), art. 1, Sch. para. 2.8.1

C2376 S. 105 modified (30.3.2015) by The Traffic Management (Southampton City Council) Permit Scheme Order 2015 (S.I. 2015/105), art. 1, Sch. para. 2.8.1

C2377 S. 105 modified (30.3.2015) by The Traffic Management (Milton Keynes Council) Permit Scheme Order 2015 (S.I. 2015/91), art. 1, Sch. para. 2.7.1

C2378 S. 105 modified (31.3.2015) by The Traffic Management (Derbyshire County Council) Permit Scheme Order 2015 (S.I. 2015/107), art. 1, Sch. para. 3.5

Marginal Citations

M35 1980 c. 66.

M36 1978 c. 30.

M37 1984 c. 27.

M38 1970 c. 44.

106 Index of defined expressions. E+W

The expressions listed below are defined or otherwise fall to be construed for the purposes of this Part in accordance with the provisions indicated—

affected by (in relation to apparatus and works)	section 105(4)
apparatus	sections 89(3) and 105(1)
arbitration	section 99
bridge	section 88(1)(a)
bridge authority	section 88(1)(b)
carriageway	section 105(1)
costs	section 96
disability	(see section 105(5))
emergency works	section 52
enactment	section 105(1)
expenses	section 96
[F101 fixed penalty offence	section 95A(1)]
footway	section 105(1)
highway authority	section 86(1)
in (in a context referring to works, apparatus or other property in a street)	section 105(1)
licensee (in relation to a street works licence)	section 50(3)
local highway authority	section 86(1)
maintainable highway	section 86(1)
major bridge works	section 88(2)
major highway works	section 86(3)
major transport works	section 91(2)
notice	section 97
prescribed	section 104
public sewer	section 89(1)(a)
railway	section 105(1)
reinstatement	section 105(1) (and see sections 70(5) and 90(1))
relevant authority (in relation to street works)	section 49(6) (and see section 91(3))
sewer	section 89(1)(a)
sewer authority	section 89(1)(b)
special enactment	section 105(1)
statutory right	section 105(1)
[F102 strategic highways company]	[F103 section 86(1A)]
street	section 48(1)
street authority	section 49(1)
street managers	section 49(4)
street works	section 48(3) (and see section 105(2) and (3))
street works licence	section 50(1)
traffic	section 105(1)
traffic authority	section 105(1)
traffic sign	section 105(1)
tramway	section 105(1)
transport authority	section 91(1)(a)
transport undertaking	section 91(1)(b)
undertaker (in relation to street works or apparatus)	sections 48(4) and(5) and 89(4)
working day	section 98(2)
works for road purposes	section 86(2).

Textual Amendments

F101 Words in s. 106 inserted (12.5.2008) by Traffic Management Act 2004 (c. 18), ss. 41(2), 99(1); S.I. 2007/1890, art. 2, Sch.; S.I. 2007/3174, art. 2, Sch.

F102 Words in s. 106 inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 122(a); S.I. 2015/481, reg. 2(a)

F103 Words in s. 106 inserted (5.3.2015) by Infrastructure Act 2015 (c. 7), s. 57(1), Sch. 1 para. 122(b); S.I. 2015/481, reg. 2(a)

Modifications etc. (not altering text)

C274 Ss. 54-106 applied (28.2.2013) by The Rookery South (Resource Recovery Facility) Order 2011 2013 (S.I. 2013/680), art. 10(3)

C276 Ss. 54-106 applied (9.4.2013) by The Lancashire County Council (Torrisholme to the M6 Link (A683 Completion of Heysham to M6 Link Road)) Order 2013 (S.I. 2013/675), arts. 1, 9(2)

C287 Ss. 54-106 applied (15.6.2013) by The Galloper Wind Farm Order 2013 (S.I. 2013/1203), arts. 1, 13(3) (with arts. 11, 12)

C288 Ss. 54-106 applied (15.8.2013) by The North Blyth Biomass Power Station Order 2013 (S.I. 2013/1873), arts. 1, 9(3) (with art. 30)

C305 Ss. 54-106 applied (7.7.2014) by The East Anglia ONE Offshore Wind Farm Order 2014 (S.I. 2014/1599), arts. 1, 8(3) (with arts. 37, 38, Sch. 9 para. 19)

C306 Ss. 54-106 applied (6.8.2014) by The Rampion Offshore Wind Farm Order 2014 (S.I. 2014/1873), arts. 1, 15(3) (with arts. 7(6), 12, 13, Sch. 12 Pt. 1 para. 19, Sch. 12 Pt. 2 para. 6, sch. 12 Pt. 3 para. 5, Sch. 12 Pt. 4 para. 4, Sch. 12 Pt. 5 para. 4)

C310 Ss. 54-106 applied (24.9.2014) by The Thames Water Utilities Limited (Thames Tideway Tunnel) Order 2014 (S.I. 2014/2384), arts. 1, 10(4), 11(5) (with arts. 55, 56)

C311 Ss. 54-106 applied (2.10.2014) by The North Killingholme (Generating Station) Order 2014 (S.I. 2014/2434), arts. 1, 9(3) (with arts. 6, 9(4), 13, Sch. 8 Pt. 1 para. 6, Sch. 8 Pt. 3 paras. 4(3), 6, 17, Sch. 8 Pt. 5 para. 9)

C314 Ss. 54-106 applied (29.10.2014) by The Able Marine Energy Park Development Consent Order 2014 (S.I. 2014/2935), art. 15(3) (with arts. 30(4), 53)

C316 Ss. 54-106 applied (28.11.2014) by The Walney Extension Offshore Wind Farm Order 2014 (S.I. 2014/2950), arts. 1, 10(3) (with arts. 38, 39)

C319 Ss. 54-106 applied (7.1.2015) by The Willington C Gas Pipeline Order 2014 (S.I. 2014/3328), arts. 1, 10(3)

C324 Ss. 54-106 applied (2.2.2015) by The Northumberland County Council (A1 – South East Northumberland Link Road (Morpeth Northern Bypass)) Development Consent Order 2015 (S.I. 2015/23), arts. 1, 9(2)

C327 Ss. 54-106 applied (26.2.2015) by The Cornwall Council (A30 Temple to Higher Carblake Improvement) Order 2015 (S.I. 2015/147), arts. 1, 9(3)

C332 Ss. 54-106 applied (11.3.2015) by The Dogger Bank Creyke Beck Offshore Wind Farm Order 2015 (S.I. 2015/318), arts. 1, 13(3) (with arts. 8(5), 35, 40, 41, Sch. 12 Pt. 1 paras. 4, 9(2), 10, Pt. 2 paras. 4(2)(3), 19, Pt. 4 paras. 3, 4, 16)

C344 Ss. 54-106 applied (1.4.2015) by The Knottingley Power Plant Order 2015 (S.I. 2015/680), arts. 1, 10(3) (with art. 7(6), Sch. 8 para. 10)

C345 Ss. 54-106 applied (23.6.2015) by The Norfolk County Council (Norwich Northern Distributor Road (A1067 to A47(T))) Order 2015 (S.I. 2015/1347), arts. 1, 9(2)

C346 Ss. 54-106 applied (30.6.2015) by The Swansea Bay Tidal Generating Station Order 2015 (S.I. 2015/1386), arts. 1, 9(3) (with arts. 51, 53)

C347 Ss. 54-106 applied (7.8.2015) by The Preesall Underground Gas Storage Facility Order 2015 (S.I. 2015/1561), arts. 1, 9(3) (with art. 44)

C348 Ss. 54-106 applied (14.8.2015) by The Progress Power (Gas Fired Power Station) Order 2015 (S.I. 2015/1570), arts. 1, 10(3)

C349 Ss. 54-106 applied (26.8.2015) by The Dogger Bank Teesside A and B Offshore Wind Farm Order 2015 (S.I. 2015/1592), arts. 1, 14(3) (with arts. 35, 40, 41)

C350 Ss. 54-106 applied (19.11.2015) by The Ferrybridge Multifuel 2 Power Station Order 2015 (S.I. 2015/1832), arts. 1(2), 9(3)

C351 Ss. 54-106 applied (30.12.2015) by The Port Talbot Steelworks Generating Station Order 2015 (S.I. 2015/1984), arts. 1, 9(3) (with art. 26)

C355 Ss. 54-106 applied (with modifications) (25.3.2016) by The Thorpe Marsh Gas Pipeline Order 2016 (S.I. 2016/297), arts. 1, 12(3) (with art. 39)

C359 Ss. 54-106 applied (2.8.2016) by The Meaford Gas Fired Generating Station Order 2016 (S.I. 2016/779), arts. 1, 11(3)

C360 Ss. 54-106 applied (10.8.2016) by The York Potash Harbour Facilities Order 2016 (S.I. 2016/772), arts. 1, 10(3) (with arts. 35, 36)

C361 Ss. 54-106 applied (19.8.2016) by The North Wales Wind Farms Connection Order 2016 (S.I. 2016/818), arts. 1, 10(5) (with art. 35)

C363 Ss. 54-106 applied (with modifications) (15.9.2016) by The River Humber Gas Pipeline Replacement Order 2016 (S.I. 2016/853), arts. 1, 11(3) (with art. 43)

C365 Ss. 54-106 applied (23.9.2016) by The M4 Motorway (Junctions 3 to 12) (Smart Motorway) Development Consent Order 2016 (S.I. 2016/863), arts. 1, 11(3)

C366 Ss. 54-106 applied (27.9.2016) by The Triton Knoll Electrical System Order 2016 (S.I. 2016/880), arts. 1(2), 8(3) (with arts. 39, 40, Sch. 8 para. 19)

C370 Ss. 54-106 applied (18.3.2017) by The North London Heat and Power Generating Station Order 2017 (S.I. 2017/215), arts. 1, 10(3)

C372 Ss. 54-106 applied (29.3.2017) by The Glyn Rhonwy Pumped Storage Generating Station Order 2017 (S.I. 2017/330), arts. 1, 10(3) (with art. 31)

C373 Ss. 54-106 applied (5.4.2017) by The Keuper Underground Gas Storage Facility Order 2017 (S.I. 2017/433), arts. 1, 10(4)

C374 Ss. 54-106 applied (8.8.2017) by The Wrexham Gas Fired Generating Station Order 2017 (S.I. 2017/766), arts. 1, 10(3)

C377 Ss. 54-106 applied (29.8.2017) by The East Anglia THREE Offshore Wind Farm Order 2017 (S.I. 2017/826), arts. 1, 8(3) (with arts. 5(9), 36, 37, Sch. 8 para. 34)

C386 Ss. 54-106 applied (12.10.2018) by The Eggborough Gas Fired Generating Station Order 2018 (S.I. 2018/1020), arts. 1, 8(3) (with arts. 6, 42)

C388 Ss. 54-106 applied (3.4.2019) by The Millbrook Gas Fired Generating Station Order 2019 (S.I. 2019/578), arts. 1, 9(3)

C389 Ss. 54-106 applied (10.10.2019) by The Abergelli Power Gas Fired Generating Station Order 2019 (S.I. 2019/1268), arts. 1, 9(3)

C390 Ss. 54-106 applied (25.10.2019) by The Drax Power (Generating Stations) Order 2019 (S.I. 2019/1315), arts. 1, 9(3)

C393 Ss. 54-106 applied (27.2.2020) by The A30 Chiverton to Carland Cross Development Consent Order 2020 (S.I. 2020/121), arts. 1, 11(3) (with art. 3(1))

C395 Ss. 54-106 applied (14.4.2020) by The Reinforcement to the North Shropshire Electricity Distribution Network Order 2020 (S.I. 2020/325), arts. 1, 10(4) (with art. 7)

C397 Ss. 54-106 applied (1.5.2020) by The Riverside Energy Park Order 2020 (S.I. 2020/419), arts. 1, 11(3) (with art. 7)

C400 Ss. 54-106 applied (11.6.2020) by The M42 Junction 6 Development Consent Order 2020 (S.I. 2020/528), arts. 1, 12(3) (with art. 37)

C403 Ss. 54-106 applied (1.9.2020) by The Immingham Open Cycle Gas Turbine Order 2020 (S.I. 2020/847), arts. 1, 9(3) (with Sch. 9 para. 144)

Part IV U.K. Road works in Scotland

Modifications etc. (not altering text)

C2379 Pt. 4 (ss. 107-165) modified (1.1.1993) by Pipelines Act 1962 (c. 58), s. 16(1) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 101(3); S.I. 1992/2990, art. 2(2), Sch.2)

C2380 Pt. 4 modified (15.1.2007) by Glasgow Airport Rail Link Act 2007 (asp 1), s. 7 (with s. 50)

C2381 Pt. 4 modified (19.4.2007) by Edinburgh Airport Rail Link Act 2007 (asp 16), s. 12 (with ss. 52, 60)

C2382 Pt. 4 modified (8.5.2007) by Airdrie Bathgate Railway and Linked Improvements Act 2007 (asp 19), s. 13 (with ss. 48, 59)

C2383 Pt. 4 excluded (1.6.2010) by The Network Rail (Waverley Steps) Order 2010 (S.S.I. 2010/188), arts. 1, 38(6)

C2384 Pt. 4 modified (11.4.2017) by The Network Rail (Glasgow Queen Street Station) Order 2017 (S.S.I. 2017/100), arts. 1, 8 (with art. 37)

Introductory provisions S

107 Roads, road works and undertakers. S

(1) In this Part a “road” means any way (other than a substitute road made under section 74(1) of the M39 Roads (Scotland) Act 1984 or a waterway) whether or not there is over it a public right of passage and whether or not it is for the time being formed as a way; and the expression includes a square or court, and any part of a road.

(2) Where a road passes over a bridge or through a tunnel, references in this Part to the road include that bridge or tunnel.

(3) In this Part “road works” means works for any purposes other than roads purposes, being works of any of the following kinds executed in a road in pursuance of a statutory right or with permission granted under section 109—

(a) placing apparatus, or

(b) inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, changing the position of apparatus or removing it,

or works required for or incidental to any such works (including, in particular, breaking up or opening the road, or any sewer, drain or tunnel under it, or tunnelling or boring under the road).

(4) In this Part “undertaker” in relation to road works means the person by whom the relevant statutory right is exercisable (in the capacity in which it is exercisable by him) or a person having permission under section 109 to execute road works, as the case may be.

(5) References in this Part to the undertaker in relation to apparatus in a road are to the person entitled, by virtue of a statutory right or a permission granted under section 109, to carry out in relation to the apparatus such works as are mentioned in subsection (3); and references to an undertaker having apparatus in the road, or to the undertaker to whom apparatus belongs, shall be construed accordingly.

Marginal Citations

M39 1984 c. 54.

108 The road works authority and other relevant authorities. S

(1) In this Part “the road works authority” in relation to a road means, subject to the following provisions—

(a) if the road is a public road, the roads authority, and

(b) if the road is not a public road, the road managers.

(2) In the case of a road for which the Secretary of State is the roads authority but in relation to which a local roads authority acts as his agent under section 4 of the Roads (Scotland) Act 1984, the local roads authority shall be regarded as the road works authority for the purposes of section [F104 112B (duty to enter certain information in Scottish Road Works Register)] (the road works register) and sections 113 to 119 (advance notice and co-ordination of works).

(3) Subsection (1)(b) has effect subject to section 146 as regards the application of this Part to prospective public roads.

(4) In this Part the expression “road managers”, used in relation to a road which is not a public road, means the authority, body or person liable to the public to maintain or repair the road or, if there is none, any authority, body or person having the management or control of the road.

(5) The Secretary of State may by regulations make provision for exempting road managers from provisions of this Part which would otherwise apply to them as the road works authority in relation to a road.

(6) References in this Part to the relevant authorities in relation to any road works are to the roads authority and also—

(a) where the works include the breaking up or opening in the road of [F105 a public sewer, Scottish Water;]

(b) where the road is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, that authority; and

(c) where in any other case the road, not being a public road, is carried or crossed by a bridge, the bridge authority.

Textual Amendments

F104 Words in s. 108(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F105 Words in s. 108(6)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp. 3), s. 71, Sch. 7 para. 21(2) (with s. 67); S.S.I. 2002/118, art. 2

109 Permission to execute road works. S

(1) A road works authority may grant permission in writing, subject to such reasonable conditions as they consider appropriate, to persons to whom this section applies—

(a) to place, or to retain, apparatus in a road, and

(b) thereafter to inspect, maintain, adjust, repair, alter or renew the apparatus, change its position or remove it,

and to execute for those purposes any works required for or incidental to such works (including, in particular, breaking up or opening the road, or any sewer, drain or tunnel under it, or tunnelling or boring under the road).

(2) A person to whom permission has been granted under this section to execute works may do so without obtaining any consent which would otherwise be required to be given—

(a) by any other relevant authority in its capacity as such, or

(b) by any person in his capacity as the owner of apparatus affected by the works;

but without prejudice to the provisions of this Part as to the making of requirements by any such authority or person or as to the settlement of a plan and section and the execution of the works in accordance with them.

(3) The granting of permission under this section to a person does not dispense that person from obtaining any other consent, licence or permission which may be required; and it does not authorise the installation of apparatus for the use of which the licence of the Secretary of State is required unless and until that licence has been granted.

(4) This section applies to persons who are described in one or more of the following paragraphs—

(a) persons of a prescribed class,

(b) persons carrying out works of a prescribed class,

(c) persons carrying out works in a prescribed area.

(5) The conditions referred to in subsection (1) may include conditions as to—

(a) the payment of fees,

(b) the future cessation or withdrawal of the permission, and

(c) indemnification of the authority against claims arising out of what is permitted.

(6) Before granting permission under this section the road works authority shall give not less than 10 working days’ notice to each of the following—

(a) where the works are likely to affect [F106 a public sewer, Scottish Water;]

(b) where the works are to be executed in a part of a road which is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, to that authority,

(c) where in any other case the part of the road in which the works are to be executed is carried or crossed by a bridge, to the bridge authority,

(d) to any person who has given notice under section 113 (advance notice of certain works) of his intention to execute road works which are likely to be affected by the works to which the permission relates, and

(e) to any person having apparatus in the road which is likely to be affected by the works;

but a failure to do so does not affect the validity of the permission.

(7) Where permission has been granted under section 61 of the M40 Roads (Scotland) Act 1984 in respect of apparatus and the road works authority consider that permission could be granted under this section in respect of that apparatus, they may cancel the permission granted under section 61 of the 1984 Act and, if they cancel that permission, they shall substitute for it permission granted in accordance with subsection (1) above.

(8) The works referred to in subsection (1) above do not include works for road purposes.

Textual Amendments

F106 Words in s. 109(6)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp. 3), s. 71, Sch. 7 para. 21(3) (with s. 67); S.S.I. 2002/118, art. 2

Modifications etc. (not altering text)

C2385 S. 109: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(a)

Marginal Citations

M40 1984 c. 54.

110 Prohibition of unauthorised road works. S

(1) It is an offence for a person other than the road works authority—

(a) to place apparatus in a road, or

(b) to break up or open a road, or a sewer, drain or tunnel under it, or to tunnel or bore under a road, for the purpose of placing, inspecting, maintaining, adjusting, repairing, altering or renewing apparatus, or of changing the position of apparatus or removing it,

otherwise than in pursuance of a statutory right or in accordance with a permission granted under section 109.

(2) A person committing an offence under this section is liable on summary conviction to a fine not exceeding [F107 level 5] on the standard scale.

(3) This section does not apply to—

(a) works for which consent or permission has been given under the Roads (Scotland) Act 1984 by a roads authority,

(b) works for road purposes, or

(c) emergency works of any description.

(4) If a person commits an offence under this section, the road works authority may—

(a) in the case of an offence under subsection (1)(a), direct him to remove the apparatus in respect of which the offence was committed, and

(b) in any case, direct him to take such steps as appear to them necessary to reinstate the road or any sewer, drain or tunnel under it.

If he fails to comply with the direction, the authority may remove the apparatus or, as the case may be, carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F107 Words in s. 110(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

111 Emergency works. S

(1) In this Part “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

(2) Where works comprise items some of which fall within the preceding definition, the expression “emergency works” shall be taken to include such of the items as do not fall within that definition as cannot reasonably be severed from those that do.

(3) Where in any civil or criminal proceedings brought by virtue of any provision of this Part the question arises whether works were emergency works, it is for the person alleging that they were to prove it.

Modifications etc. (not altering text)

C2386 S. 111 excluded (28.11.1992) by S.I. 1992/2990, art. 5

The road works register S

F108 112 The road works register. S

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Textual Amendments

F108 Ss. 112A, 112B substituted for s. 112 (29.2.2008 for specified purposes, 1.4.2008 in so far as not already in force) by Transport (Scotland) Act 2005 (asp 12), ss. 19(1), 54(2); S.S.I. 2008/15, art. 2(1)(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

[F108 112A The Scottish Road Works Register S

(1) The Scottish Road Works Commissioner (in this Part, “the Commissioner”) shall keep a register, to be known as the Scottish Road Works Register (in this Part, “the SRWR”).

(2) The SRWR shall be kept in such form and manner as may be prescribed.

(3) The Commissioner shall make arrangements so as to enable any person who is required, by a provision of this Act, to enter particulars, information or a notice in the SRWR, to have access to the SRWR for that purpose.

(4) The Scottish Ministers may by regulations—

(a) provide that the payment to the Commissioner of the prescribed fee is a condition of access to the SRWR as mentioned in subsection (3) (and different fees may be prescribed for access for different purposes), and

(b) make other provision as to the payment to the Commissioner by such persons as are prescribed of such amounts as are prescribed.

(5) Amounts received by the Commissioner under subsection (4) are to be applied by the Commissioner to the keeping of the SRWR.

(6) The Commissioner shall make the SRWR available, at all reasonable times and free of charge, for inspection—

(a) so far as it relates to restricted information, by any person having authority to execute works of any description in the road in respect of which that restricted information is kept in the SRWR or who, not being a person having that authority, nevertheless appears to the Commissioner to have a sufficient interest in that information,

(b) so far as it relates to information which is not restricted, by any person.

(7) In subsection (6), “restricted” information is information of a prescribed description.

Textual Amendments

F108 Ss. 112A, 112B substituted for s. 112 (29.2.2008 for specified purposes, 1.4.2008 in so far as not already in force) by Transport (Scotland) Act 2005 (asp 12), ss. 19(1), 54(2); S.S.I. 2008/15, art. 2(1)(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

112B Duty to enter certain information in the Scottish Road Works Register S

(1) A road works authority shall enter in the SRWR such particulars of each road for which the authority are responsible as may be prescribed.

(2) A road works authority proposing to execute works in any such road shall, not later than such time before the date proposed for the start of the works as may be prescribed, enter in the SRWR such information relating to that matter (including such information about the start of the works) as may be prescribed.

(3) A road works authority which has—

(a) under section 109, granted permission as regards apparatus and works,

(b) under section 115, given directions as to the timing of works, or

(c) under section 115A, given directions as to the placing of apparatus,

shall enter in the SRWR such information relating to that matter as may be prescribed.

(4) A local roads authority proposing to execute works in roads in pursuance of section 1 of the Roads (Scotland) Act 1984 (c. 54) (management and maintenance of certain public roads) shall enter in the SRWR such information relating to that matter as may be prescribed.

(5) If the Scottish Ministers (as roads authority) propose to execute works in roads under section 2 of that Act (management and maintenance of trunk, special and certain other public roads) they shall enter in the SRWR such information relating to that matter as may be prescribed.

(6) On the completion of works of the kind referred to in subsection (4) or (5) the roads authority which executed them shall enter in the SRWR such information about their completion as may be prescribed.

(7) A roads authority which has—

(a) under subsection (2) of section 56 of the Roads (Scotland) Act 1984 (c. 54), given an applicant for consent for road works or excavations notice of affected statutory undertakers,

(b) under subsection (8) of that section, given notification of unlawful works removed or unlawful excavations filled in,

(c) under section 58(1) of that Act, given permission for the occupation of part of a road for the deposit of materials or for the erection of staging or scaffolding projecting over part of a road,

(d) under section 61(1) of that Act, given permission for the placing, leaving, retention, maintenance, repair or reinstatement of apparatus in or under a road or the breaking open of or having access to the road,

(e) under section 85 of that Act, given permission for the deposit of a skip on a road for which a road works authority are responsible,

(f) under subsection (2) of section 86 of that Act, required the removal or repositioning of a skip deposited on such a road or removed or repositioned such a skip,

(g) become aware that a constable has, under subsection (1) of that section, required or caused the removal or repositioning of such a skip,

(h) given notice under—

(i) section 87 of that Act requiring the removal of a structure from a road for which a road works authority are responsible and (where considered requisite under that section) the reinstatement of the road, or

(ii) section 88 of that Act requiring the removal or alteration of a projection affecting such a road,

(i) under section 90 of that Act, given consent for the fixing or placing of an overhead bridge, beam, rail or other apparatus along or across such a road,

(j) under section 91 of that Act, served notice requiring work to be done or carried out work in relation to such a road, or

(k) under section 92 of that Act, given consent to the planting of a tree or shrub near a carriageway or required its removal, where the carriageway is, or is part of, such a road,

shall enter in the SRWR such information relating to that matter as may be prescribed.

(8) Information to be entered in the SRWR under this section shall be entered in such form and manner as may be prescribed.]

Textual Amendments

F108 Ss. 112A, 112B substituted for s. 112 (29.2.2008 for specified purposes, 1.4.2008 in so far as not already in force) by Transport (Scotland) Act 2005 (asp 12), ss. 19(1), 54(2); S.S.I. 2008/15, art. 2(1)(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

Notice and co-ordination of works S

113 Advance notice of certain works. S

(1) In such cases as may be prescribed an undertaker proposing to execute road works shall give the prescribed advance notice of the works F109 ....

(2) Different periods of notice may be prescribed for different descriptions of works.

[F110 (3A) For the purposes of subsection (1) an undertaker gives notice by entering in the SRWR such information as may be prescribed.]

(4) After giving advance notice under this section an undertaker shall comply with such requirements as may be prescribed, or imposed by the road works authority, as to the providing of information and other procedural steps to be taken for the purpose of co-ordinating the proposed works with other works of any description proposed to be executed in the road.

(5) An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F111 level 4] on the standard scale.

Textual Amendments

F109 Words in s. 113(1) repealed (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(3)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F110 S. 113(3A) substituted for s. 113(3) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(3)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F111 Words in s. 113(5) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2387 S. 113 modified (28.11.1992) by S.I. 1992/2990, art. 3(1)

C2388 S. 113 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2389 S. 113 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

114 Notice of starting date of works. S

(1) An undertaker proposing to begin to execute road works involving—

(a) breaking up or opening the road, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the road,

shall give not less than 7 working days’ notice (or such other notice as may be prescribed) F112 ...

(2) Different periods of notice may be prescribed for different descriptions of works [F113 or in cases where the undertaker has been given notice under section 117(1)], and cases may be prescribed in which no notice is required.

[F114 (3A) For the purposes of subsection (1) an undertaker gives notice by—

(a) giving to any relevant authority (not being the road works authority) and to any other person having apparatus in the road which is likely to be affected by the works a notice—

(i) stating the date on which it is proposed to begin the works, and

(ii) containing such other information as may be prescribed, and

(b) entering in the SRWR a copy of that notice.]

(4) Where notice is required to be given under this section, the works shall not be begun without notice or before the end of the notice period, except with the consent of those to whom notice is required to be given.

(5) An undertaker who begins to execute any works in contravention of this section commits an offence and is liable on summary conviction to a fine not exceeding [F115 level 4] on the standard scale.

(6) In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of—

(i) a relevant authority, or

(ii) the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

(7) A notice under this section shall cease to have effect if the works to which it relates are not substantially begun before the end of the period of seven working days (or such other period as may be prescribed) beginning with the starting date specified in the notice, or such further period as may be allowed by those to whom notice is required to be given.

Textual Amendments

F112 Words in s. 114(1) repealed (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(4)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F113 Words in s. 114(2) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 22(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F114 S. 114(3A) substituted for s. 114(3) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(4)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (with art. 3) (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F115 Words in s. 114(5) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2390 S. 114 modified (28.11.1992) by S.I. 1992/2990, art.4

S. 114 modified (1. 1. 1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2990, art. 2(2), Sch.2)

C2391 S. 114 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2392 S. 114 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

Commencement Information

I12 S. 114 wholly in force: s. 114 in force for the purpose of making regulations at 30.11.1992 and for all other purposes at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(1)(2), Schs. 1, 2

115 Power to give directions as to timing of works. S

(1) If it appears to the road works authority—

(a) that proposed road works are likely to cause serious disruption to traffic, and

(b) that the disruption would be avoided or reduced if the works were carried out only at certain times [F116 or on certain days (or at certain times on certain days)],

the authority may give the undertaker such directions as may be appropriate as to the times [F117 or days (or both)] when the works may or may not be carried out.

[F118 (1A) If it appears to a road works authority—

(a) that subsisting road works are causing or are likely to cause serious disruption to traffic, and

(b) that the disruption would be avoided or reduced if the works were to continue to be carried out only at certain times or on certain days (or at certain times on certain days),

the authority may give the undertaker such directions as may be appropriate as to the times or days (or both) when the works may or may not continue to be carried out.]

(2) The procedure for giving a direction shall be prescribed by the Secretary of State.

[F119 (2A) The Scottish Ministers shall by regulations make provision for appeals against directions under this section, including provision as to the procedure to be followed on an appeal.]

(3) An undertaker who executes works in contravention of a direction under this section commits an offence and is liable on summary conviction to a fine not exceeding [F120 level 5] on the standard scale.

[F121 (3A) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, the failure is attributable to a direction under this section.]

(4) The Secretary of State [F122 shall] issue or approve for the purpose of this section a code of practice giving practical guidance as to the exercise by road works authorities of the power conferred by this section; and in exercising that power a road works authority shall have regard to the code of practice.

Textual Amendments

F116 Words in s. 115(1)(b) added (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(2)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F117 Words in s. 115(1) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(2)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F118 S. 115(1A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(3), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F119 S. 115(2A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(4), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F120 Words in s. 115(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

F121 S. 115(3A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(5), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F122 Word in s. 115(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 20(6), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2393 S. 115: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(c)

[F123 115A Power to give directions as to placing of apparatus S

(1) Where—

(a) an undertaker is proposing to execute road works consisting of the placing of apparatus in a road (the “proposed road”),

(b) placing the apparatus in the proposed road is likely to cause disruption to traffic, and

(c) it appears to the road works authority that—

(i) there is another road in which the apparatus could be placed (the “other road”), and

(ii) the conditions in subsection (2) are satisfied,

the authority may by directions require the undertaker not to place the apparatus in the proposed road (but shall not require the undertaker to place the apparatus in the other road).

(2) The conditions referred to in subsection (1)(c)(ii) are that—

(a) disruption to traffic would be avoided or reduced if the apparatus were to be placed in the other road,

(b) placing the apparatus in the other road would be a reasonable way of achieving the purpose for which the apparatus is to be placed, and

(c) it is reasonable to require the undertaker not to place the apparatus in the proposed road.

(3) Directions under this section may be varied or revoked by further such directions.

(4) The procedure for giving directions under this section shall be as prescribed.

(5) The Scottish Ministers shall by regulations make provision for appeals against directions under this section, including provision as to the procedure to be followed on an appeal.

(6) An undertaker who executes works in contravention of directions under this section commits an offence and is liable on summary conviction to a fine not exceeding level 5 on the standard scale.

(7) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, the failure is attributable to a direction under this section.

(8) The Scottish Ministers shall issue or approve for the purposes of this section a code of practice giving practical guidance as to the exercise by road works authorities of the power conferred by this section; and in exercising that power a road works authority shall have regard to the code of practice.]

Textual Amendments

F123 S. 115A inserted (S.) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 21(1), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

116 Notice of emergency works. S

(1) Nothing in section 113 (advance notice), section 114 (notice of starting date) F124 ... section 115 (directions as to timing of works) [F125 or section 115A (power to give directions as to placing of apparatus)] affects the right of an undertaker to execute emergency works.

(2) An undertaker executing emergency works shall, if the works are of a kind in respect of which notice is required by section 114, give notice as soon as reasonably practicable, and in any event within two hours (or such other period as may be prescribed) of the works being begun F126 ....

[F127 (3A) For the purposes of subsection (2) an undertaker gives notice by—

(a) giving to each person to whom notice would be required to be given under section 114 a notice—

(i) stating the undertaker's intention, or as the case may be, the fact that he has begun to execute the works, and

(ii) containing such other information as may be prescribed, and

(b) entering in the SRWR a copy of that notice.]

(4) An undertaker who fails to give notice in accordance with this section commits an offence and is liable on summary conviction to a fine not exceeding [F128 level 4] on the standard scale.

(5) In proceedings against a person for such an offence it is a defence for him to show that the contravention was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of—

(i) a relevant authority, or

(ii) the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F124 Word in s. 116(1) repealed (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 21(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F125 Words in s. 116(1) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 21(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F126 Words in s. 116(2) repealed (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(5)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F127 S. 116(3A) substituted for s. 116(3) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(5)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F128 Words in s. 116(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2394 S. 116 modified (28.11.1992) by S.I. 1992/2990, art. 5

117 Restriction on works following substantial works carried out for road purposes. S

(1) Where it is proposed to carry out substantial works in a road, the road works authority may by notice in accordance with this section restrict the execution of road works during the twelve months following the completion of those works.

For this purpose substantial works means works for road purposes, or such works together with other works, of such description as may be prescribed.

(2) The notice shall be [F129 entered in the SRWR] and shall specify the nature and location of the proposed works, the date (not being less than three months after the notice is [F130 so entered], or first [F130 so entered]) on which it is proposed to begin the works, and the extent of the restriction.

(3) A copy of the notice shall be given to each of the following—

(a) where there is [F131 a public sewer] in the part of the road to which the restriction relates, to [F132 Scottish Water]

(b) where the part of the road to which the restriction relates is carried or crossed by a bridge vested in a transport authority, or crosses or is crossed by any other property held or used for the purposes of a transport authority, to that authority,

(c) where in any other case the part of the road to which the restriction relates is carried or crossed by a bridge, to the bridge authority,

(d) any person who has given notice under section 113 (advance notice of certain works) of his intention to execute road works in the part of the road to which the restriction relates, and

(e) any other person having apparatus in the part of the road to which the restriction relates;

but a failure to do so does not affect the validity of the restriction imposed by the notice.

(4) A notice ceases to be effective if the works to which it relates are not substantially begun—

(a) on or within one month from the date specified in the notice, or

(b) where road works are in progress in the part of the road to which the restriction relates on that date, within one month from the completion of those works.

(5) An undertaker shall not in contravention of a restriction imposed by a notice under this section break up or open the part of the road to which the restriction relates, except—

(a) to execute emergency works,

(b) with the consent of the road works authority, or

(c) in such other cases as may be prescribed.

(6) If he does—

(a) he commits an offence and is liable on summary conviction to a fine not exceeding [F133 level 5] on the standard scale, and

(b) [F134 if convicted of an offence under this subsection,] he is liable to reimburse the road works authority any costs reasonably incurred by them in reinstating the road.

(7) The consent of the road works authority under subsection (5)(b) shall not be unreasonably withheld; and any question whether the withholding of consent is unreasonable shall be settled [F135 in the prescribed manner].

(8) An undertaker shall be taken not to have failed to fulfil any statutory duty to afford a supply or service if, or to the extent that, his failure is attributable to a restriction imposed by a notice under this section.

[F136 (9) The Scottish Ministers may issue or approve for the purposes of this section a code of practice giving practical guidance as to the performance by road works authorities of their functions under this section; and in carrying out those functions a road works authority shall have regard to the code of practice.]

Textual Amendments

F129 Words in s. 117(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(6)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F130 Words in s. 117(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 19(6)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F131 Words in s. 117(3)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(4)(a) (with s. 67); S.S.I. 2002/118, art. 2

F132 Words in s. 117(3)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(4)(b) (with s. 67); S.S.I. 2002/118, art. 2

F133 Words in s. 117(6) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

F134 Words in s. 117(6)(b) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 22(1)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F135 Words in s. 117(7) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F136 S. 117(9) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 22(1)(c), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2395 S. 117 restricted (28.11.1992) by S.I. 1992/2990, art. 6

C2396 S. 117: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(e)

118 General duty of road works authority to co-ordinate works. S

(1) A road works authority shall use their best endeavours to co-ordinate the execution of works of all kinds (including works for road purposes) in the roads for which they are responsible—

(a) in the interests of safety,

(b) to minimise the inconvenience to persons using the road (having regard, in particular, to the needs of people with a disability), and

(c) to protect the structure of the road and the integrity of apparatus in it.

(2) That duty extends to co-ordination with other road works authorities where works in a road for which one authority are responsible affect roads for which other authorities are responsible.

[F137 (2A) In discharging their duty under this section, a road works authority shall have regard to all information in the SRWR which relates to the functions of the authority.

(2B) A road works authority shall, so as to maximise the utility of that information for the purposes of subsection (2A)—

(a) assist the Commissioner in complying with the duty imposed by subsection (1) of section 112A (as read with subsection (2) of that section), and

(b) keep that information under surveillance.]

(3) The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned above; and in discharging their general duty of co-ordination [F138 and the specific duties imposed by subsections (2) to (2B)] a road works authority shall have regard to any such code of practice.

[F139 (3A) In discharging all the duties referred to in subsection (3), a road works authority shall have regard also to such guidance as is contained in the practice referred to in section 17(4)(b) of the Transport (Scotland) Act 2005 (asp 12).]

(4) If it appears to the [F140 Commissioner] that a road works authority are not properly discharging their general duty of co-ordination, he may direct the authority to supply him with such information as he considers necessary to enable him to decide whether that is the case and if so what action to take.

The direction shall specify the information to be provided and the period within which it is to be provided.

(5) If after the end of that period (whether or not the direction has been complied with) it appears to the [F141 Commissioner] that the authority are not properly discharging their general duty of co-ordination, he may direct the authority to take such steps as he considers appropriate for the purpose of discharging that duty.

The direction shall specify the steps to be taken and the period within which they are to be taken, and may include a requirement to make a report or periodic reports to the [F141 Commissioner] as to what steps have been taken and the results of taking them.

(6) A direction under this section may be varied or revoked by a further direction.

Textual Amendments

F137 S. 118(2A)(2B) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 23(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1 (as amended (5.3.2008) by S.S.I. 2008/90, art. 2)

F138 Words in s. 118(3) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 23(3), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F139 S. 118(3A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 23(4), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F140 Words in s. 118(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 23(5), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F141 Words in s. 118(5) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 23(5), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2397 S. 118: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(e)

C2398 S. 118 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2399 S. 118 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

Commencement Information

I13 S. 118 wholly in force; s. 118(1)(2)(4)-(6) in force at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2; s. 118(3) in force at 14.7.1992 by S.I. 1992/1671, art. 2, Sch.

119 General duty of undertakers to co-operate. S

(1) An undertaker shall as regards the execution of road works use his best endeavours to co-operate with the road works authority and with other undertakers—

(a) in the interests of safety,

(b) to minimise the inconvenience to persons using the road (having regard, in particular, to the needs of people with a disability), and

(c) to protect the structure of the road and the integrity of apparatus in it.

[F142 (1A) In discharging the duty under this section, an undertaker shall have regard to all information in the SRWR about matters which might affect, or be affected by, works being or proposed to be carried out by the undertaker.

(1B) An undertaker shall, so as to maximise the utility of that information for the purposes of subsection (1A)—

(a) assist the Commissioner in complying with the duty imposed by subsection (1) of section 112A (as read with subsection (2) of that section), and

(b) keep that information under surveillance.

(1C) In subsections (1A) and (1B), “undertaker” does not include a person having permission under section 109 to execute road works.]

(2) The Secretary of State shall issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with his duty under that subsection, and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that duty.

[F143 (2A) In discharging the duties imposed by subsections (1) to (1B), an undertaker shall—

(a) comply with any direction in that respect given to the undertaker by the Commissioner, and

(b) have regard to such guidance as is contained in the practice referred to in section 17(4)(b) of the Transport (Scotland) Act 2005 (asp 12),

and paragraphs (a) and (b) of subsection (2) shall apply in relation to any such direction as they apply in relation to the code of practice referred to in that subsection.

(2B) If it appears to the Commissioner that an undertaker is not properly complying with his duty under subsection (1), he may direct the undertaker to supply him with such information as he considers necessary to enable him to decide whether that is the case and, if so, what action to take.

The direction shall specify the information to be provided and the period within which it is to be provided.]

F144 (3) . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

[F145 (4) A direction under this section may be varied or revoked by a further direction.]

Textual Amendments

F142 S. 119(1A)-(1C) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 24(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F143 S. 119(2A)(2B) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 24(3), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F144 S. 119(3) repealed (1.10.2007) by Transport (Scotland) Act 2005 (asp 12), ss. 25(1), 54(2); S.S.I. 2007/409, art. 2

F145 S. 119(4) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 24(4), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Commencement Information

I14 S. 119 wholly in force: s. 119(1)(3) in force at 1.1.1993 see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2; s. 119(2) in force at 14.7.1992 by S.I. 1992/1671, art. 2, Sch.

[F146 119A Enforcement of sections 118 and 119: imposition of penalties S

(1) The Scottish Ministers may, by regulations, make provision for or in connection with—

(a) the imposition by the Commissioner of penalties on road works authorities and undertakers who fail to comply with duties imposed on them by sections 118 and 119 respectively,

(b) the payment of such penalties.

(2) The regulations may include provision for or in connection with—

(a) the notification and enforcement of penalties,

(b) the level of penalties,

(c) appeals against the imposition of penalties including the appointment of persons to hear and determine such appeals.]

Textual Amendments

F146 S. 119A inserted (S.) (1.10.2007) by Transport (Scotland) Act 2005 (asp 12), ss. 25(2), 54(2); S.S.I. 2007/409, art. 2

Roads subject to special controls S

120 Protected roads. S

(1) The consent of the road works authority is required for the placing of apparatus by an undertaker in a protected road, except as mentioned below.

The following are “protected roads” for this purpose—

(a) any road or proposed road which is a special road in accordance with section 7 of the M41 Roads (Scotland) Act 1984, and

(b) any road designated by the road works authority as protected.

(2) Consent is not required for the placing of apparatus—

(a) by way of renewal of existing apparatus, or

(b) in pursuance of a permission granted under section 109 of this Act (permission to execute road works) or section 61 of the M42 Roads (Scotland) Act 1984 (permission to place and maintain apparatus under a road), except where the permission was granted before the road became a protected road.

(3) The road works authority may require the payment of—

(a) a reasonable fee in respect of the legal or other expenses incurred in connection with the giving of their consent under this section, and

(b) an annual fee of a reasonable amount for administering the consent;

and any such fee is recoverable from the undertaker.

This shall not be construed as affecting any right of the authority where they own the land on which the road is situated to grant, subject to such terms and conditions as they think fit, the right to place anything in, under or over the land.

(4) Where the apparatus is to be placed crossing the protected road and not running along it, the road works authority shall not withhold their consent unless there are special reasons for doing so.

(5) Consent to the placing of apparatus in a protected road may be given subject to conditions; and the road works authority may agree to contribute to the expenses incurred by the undertaker in complying with the conditions.

(6) Any dispute between a road works authority and an undertaker as to the withholding of consent, the imposition of conditions, or the making of contributions shall be settled [F147 in the prescribed manner].

(7) An undertaker having a statutory duty to afford a supply or service shall not be regarded as in breach of that duty if, or to the extent that, it is not reasonably practicable to afford a supply or service by reason of anything done by the road works authority in exercise of their functions in relation to a protected road.

Textual Amendments

F147 Words in s. 120(6) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2400 S. 120 modified (28.11.1992) by S.I. 1992/2990, art.7

Marginal Citations

M41 1984 c. 54.

M42 1984 c. 54.

121 Supplementary provisions as to designation of protected roads. S

(1) The Secretary of State may prescribe—

(a) the criteria for designating a road as protected,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a road works authority as to the roads for the time being designated by them.

(2) Where a road has been designated as protected the road works authority may direct an undertaker to remove or change the position of apparatus placed in the road at a time when it was not so designated.

The authority shall indemnify the undertaker in respect of his reasonable expenses in complying with such a direction.

(3) Where a designation is withdrawn the road works authority may give such directions as they consider appropriate as to—

(a) the continuance in force of any conditions subject to which consent was given for the placing of apparatus in the road, and

(b) the continuance of entitlement to any contributions in respect of the expenses of an undertaker in complying with such conditions.

(4) Where a designation is made or withdrawn the road works authority may give such directions as they consider appropriate with respect to works in progress in the road when the designation comes into force or ceases to have effect.

(5) Any dispute between a road works authority and an undertaker as to the exercise by the authority of their powers under subsection (2), (3) or (4) shall be settled [F148 in the prescribed manner].

(6) Where a road has been designated as protected, the roads authority shall indicate that it has been so designated in the list of public roads which they are obliged to maintain by virtue of section 1 or 2 of the M43 Roads (Scotland) Act 1984.

Textual Amendments

F148 Words in s. 121(5) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(c), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Marginal Citations

M43 1984 c. 54.

122 Roads with special engineering difficulties. S

(1) The provisions of Schedule 6 have effect for requiring the settlement of a plan and section of road works to be executed in a road designated by the road works authority as having special engineering difficulties.

(2) The Secretary of State may prescribe—

(a) the criteria for designating a road as having special engineering difficulties,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a road works authority as to the roads for the time being so designated by them.

(3) Where a local roads authority are asked to designate a road as having special engineering difficulties—

(a) by a transport authority on the ground of the proximity of the road to a structure belonging to, or under the management or control of, the authority, or

(b) by an undertaker having apparatus in the road,

and decline to do so, the transport authority or undertaker may appeal to the Secretary of State who may direct that the road be designated.

(4) The designation of a road as having special engineering difficulties shall not be withdrawn except after consultation with any transport authority or undertaker at whose request the designation was made; and a designation made in pursuance of a direction by the Secretary of State shall not be withdrawn except with his consent.

(5) Where a road has been designated as having special engineering difficulties, the roads authority shall indicate that it has been so designated in the list of public roads which they are obliged to maintain by virtue of section 1 or 2 of the Roads (Scotland) Act 1984.

Modifications etc. (not altering text)

C2401 S. 122: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(f)

123 Traffic-sensitive roads. S

(1) Regulations made for the purposes of section 113, 114 or 116 (notices required to be given in respect of road works) may make special provision in relation to road works in a road designated by the road works authority as traffic-sensitive.

(2) The Secretary of State may prescribe—

(a) the criteria for designating a road as traffic-sensitive,

(b) the procedure for making or withdrawing such a designation, and

(c) the information to be made available by a road works authority as to the roads for the time being so designated by them.

(3) If it appears to the road works authority that the prescribed criteria are met only at certain times or on certain dates, a limited designation may be made accordingly.

In such a case the reference in subsection (1) to the execution of works in a road designated as traffic-sensitive shall be construed as a reference to works so executed at those times or on those dates.

(4) Where a road has been designated as traffic-sensitive, the roads authority shall indicate that it has been so designated in the list of public roads which they are obliged to maintain by virtue of section 1 or 2 of the M44 Roads (Scotland) Act 1984.

Modifications etc. (not altering text)

C2402 S. 123: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(g)

Marginal Citations

M44 1984 c. 54.

General requirements as to execution of road works S

124 Safety measures. S

(1) An undertaker executing road works shall secure—

(a) that any part of the road which is broken up or open, or is obstructed by plant or materials used or deposited in connection with the works, is adequately guarded and lit, and

(b) that such traffic signs are placed and maintained, and where necessary operated, as are reasonably required for the guidance or direction of persons using the road, and in accordance with section 120 of the Roads (Scotland) Act 1984 (duty to have regard to the needs of people with a disability).

(2) In discharging in relation to a road his duty with respect to the placing, maintenance or operation of traffic signs, an undertaker shall comply with any directions given by the traffic authority.

The power of the traffic authority to give directions under this subsection is exercisable subject to any directions given by the Secretary of State under section 65 of the M45 Road Traffic Regulation Act 1984.

(3) The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsection (1); and—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with that subsection; and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with that subsection.

(4) An undertaker who fails to comply with subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F149 level 5] on the standard scale.

(5) If it appears to the road works authority that an undertaker has failed to comply with subsection (1) or (2), they may take such steps as appear to them necessary and may recover from the undertaker the costs reasonably incurred by them in doing so.

(6) If a person without lawful authority or excuse—

(a) takes down, alters or removes any fence, barrier, traffic sign or light erected or placed in pursuance of subsection (1) or (2) above, or

(b) extinguishes a light so placed,

he commits an offence and is liable on summary conviction to a fine not exceeding [F150 level 5] on the standard scale.

Textual Amendments

F149 Words in s. 124(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

F150 Words in s. 124(6) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Commencement Information

I15 S. 124 wholly in force: s. 124(3) in force at 14.7.1992 by S. I. 1992/1671, art. 2, Sch.; s. 124(1)(2)(4)-(6) in force at 1.4.1993 by S.I. 1992/2990, art. 2(3), Sch. 3

Marginal Citations

M45 1984 c. 27.

125 Avoidance of unnecessary delay or obstruction. S

(1) An undertaker executing road works which involve—

(a) breaking up or opening the road, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the road,

shall carry on and complete the works with all such dispatch as is reasonably practicable.

(2) An undertaker who fails to do so commits an offence and is liable on summary conviction to a fine not exceeding [F151 level 5] on the standard scale.

(3) Where an undertaker executing any road works creates an obstruction in a road to a greater extent or for a longer period than is reasonably necessary, the road works authority may by notice require him to take such reasonable steps as are specified in the notice to mitigate or discontinue the obstruction.

(4) If the undertaker fails to comply with such a notice within 24 hours of receiving it, or such longer period as the authority may specify, the authority may take the necessary steps and recover from him the costs reasonably incurred by them in doing so.

Textual Amendments

F151 Words in s. 125(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

126 Qualifications of supervisors and operatives. S

(1) It is the duty of an undertaker executing road works involving—

(a) breaking up the road, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the road,

to secure that, except in such cases as may be prescribed, the execution of the works is supervised by a person having a prescribed qualification as a supervisor.

[F152 (1A) A road works authority may (unless the case is one excepted from subsection (1)) by notice require an undertaker executing road works—

(a) to notify them of the name of—

(i) the person who is currently the qualified supervisor required under subsection (1), and

(ii) each person who has previously been the qualified supervisor so required, and

(b) to provide them with such evidence of the requisite qualification of the person or, as the case may be, each person named as may be prescribed.]

(2) It is the duty of an undertaker executing road works involving—

(a) breaking up or opening the road, or any sewer, drain or tunnel under it, or

(b) tunnelling or boring under the road,

to secure that, except in such cases as may be prescribed, there is on site at all times when any such works are in progress at least one person having a prescribed qualification as a trained operative.

[F153 (2A) A road works authority may (unless the case is one excepted from subsection (2)) by notice require an undertaker executing road works—

(a) to notify them of the name of—

(i) a person whose presence on site at any time specified in the notice (being a time when the works were in progress) enabled the undertaker to comply with his duty under subsection (2), or

(ii) each person whose presence on site during the progress of the works enabled the undertaker to comply with his duty under subsection (2), and

(b) to provide them such evidence of the requisite qualification of the or, as the case may be, each person named as may be prescribed.

(2B) A notice under subsection (1A) or (2A) may be given at any time while the works are being executed or within such period after their completion as may be prescribed.

(2C) The undertaker shall comply with a notice under subsection (1A) or (2A) within such period and in such way as may be prescribed.]

(3) An undertaker who fails to comply with his duty under subsection (1) [F154 , (2) or (2C)] commits an offence and is liable on summary conviction to a fine not exceeding [F155 level 5] on the standard scale.

(4) Regulations made by the Secretary of State for the purposes of this section may include provision with respect to—

(a) the approval of bodies conferring qualifications (and the withdrawal of such approval), and

(b) the circumstances in which a qualification may be conferred [F156 and

(c) the form of any document to be issued by an approved body to certify or otherwise show that a qualification has been conferred on any person].

Textual Amendments

F152 S. 126(1A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 26(2), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F153 S. 126(2A)-(2C) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 26(3), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F154 Words in s. 126(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 26(4), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F155 Words in s. 126(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

F156 S. 126(4)(c) and word inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 26(5), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

[F157 126A Duty of authorities, undertakers etc. to ensure competence of employees etc. S

Each of the authorities and other persons set out in the first column below shall use their or, as the case may be, his best endeavours to ensure that each of that authority's or, as the case may be, that person's employees or agents whose duty it is to carry out for that authority or person a function conferred on that authority or person by or under an enactment set out relative to that authority or person in the second column below is competent to perform that duty—

A road works authority	Section 112B(1) and (3) of this Act; section 18 of the Transport (Scotland) Act 2005 (asp 12) (duty to provide Scottish Road Works Commissioner with certain information).
A roads authority	Section 112B(4) to (7) of this Act.
An undertaker	Sections 113(1), 114(1) and 116(2) of this Act; section 18 of the Transport (Scotland) Act 2005 (asp 12) (duty to provide Scottish Road Works Commissioner with certain information).]

Textual Amendments

F157 S. 126A inserted (S.) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 27, 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

127 Facilities to be afforded to road works authority. S

(1) An undertaker executing road works shall afford the road works authority reasonable facilities for ascertaining whether he is complying with his duties under this Part.

(2) An undertaker who fails to afford the road works authority such facilities commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F158 level 4] on the standard scale.

Textual Amendments

F158 Words in s. 127(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

128 Works likely to affect other apparatus in the road. S

(1) Where road works are likely to affect another person’s apparatus in the road, the undertaker executing the works shall take all reasonably practicable steps—

(a) to give the person to whom the apparatus belongs reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by him which is reasonably necessary for the protection of the apparatus or for securing access to it.

(2) An undertaker who fails to comply with subsection (1) commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F159 level 4] on the standard scale.

(3) In proceedings against a person for such an offence it is a defence for him to show that the failure was attributable—

(a) to his not knowing the position, or not knowing of the existence, of another person’s apparatus, or

(b) to his not knowing the identity or address of the person to whom any apparatus belongs,

and that his ignorance was not due to any negligence on his part or to any failure to make inquiries which he ought reasonably to have made.

Textual Amendments

F159 Words in s. 128(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2403 S. 128 excluded (28.11.1992) by S.I. 1992/2990, art. 8

C2404 S. 128 modified (1. 1. 1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2990, art. 2(2), Sch.2)

C2405 S. 128 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2406 S. 128 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

Reinstatement S

129 Duty of undertaker to reinstate. S

(1) It is the duty of the undertaker by whom road works are executed to reinstate the road.

(2) He shall begin the reinstatement as soon after the completion of any part of the road works as is reasonably practicable and shall carry on and complete the reinstatement with all such dispatch as is reasonably practicable.

(3) He shall before the end of the next working day after the day on which the reinstatement is completed [F160 give the required notice] that he has completed the reinstatement of the road, stating whether the reinstatement is permanent or interim.

(4) If it is interim, he shall complete the permanent reinstatement of the road as soon as reasonably practicable and in any event within six months (or such other period as may be prescribed) from the date on which the interim reinstatement was completed; and he shall [F161 give the required notice] when he has done so.

(5) The permanent reinstatement of the road shall include, in particular, the reinstatement of features designed to assist people with a disability.

[F162 (5A) For the purposes of subsection (3) or (4) an undertaker gives the required notice by—

(a) giving to the Commissioner a notice containing such information as may be prescribed, and

(b) entering in the SRWR a copy of that notice.]

(6) An undertaker who fails to comply with any provision of this section commits an offence and is liable on summary conviction to a fine not exceeding [F163 level 5] on the standard scale.

(7) In proceedings against a person for an offence of failing to comply with subsection (2) it is a defence for him to show that any delay in reinstating the road was in order to avoid hindering the execution of other works, or other parts of the same works, to be undertaken immediately or shortly thereafter.

Textual Amendments

F160 Words in s. 129(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 28(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F161 Words in s. 129(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 28(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F162 S. 129(5A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 28(c), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F163 Words in s. 129(6) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2407 S. 129 excluded (28.11.1992) by S.I. 1992/2990, art. 9

Commencement Information

I16 S. 129 wholly in force: s. 129(1)-(3)(5)-(7) in force at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2; s. 129(4) in force at 14.7.1992 by S. I. 1992/1671, art. 2, Sch.

130 Materials, workmanship and standard of reinstatement. S

(1) An undertaker executing road works shall in reinstating the road comply with such requirements as may be prescribed as to the specification of materials to be used and the standards of workmanship to be observed.

(2) He shall also ensure that the reinstatement conforms to such performance standards as may be prescribed—

(a) in the case of interim reinstatement, until permanent reinstatement is effected, and

(b) in the case of permanent reinstatement, for the prescribed period after the completion of the reinstatement.

This obligation is extended in certain cases and restricted in others by the provisions of section 132 as to cases where a reinstatement is affected by subsequent works.

(3) Regulations made for the purposes of this section may make different provision in relation to different classes of excavation and different descriptions of road, and in relation to interim and permanent reinstatement.

(4) The Secretary of State may issue or approve for the purposes of this section codes of practice giving practical guidance as to the matters mentioned in subsections (1) and (2); and regulations made for the purposes of this section may provide that—

(a) so far as an undertaker complies with such a code of practice he shall be taken to comply with his duties under this section; and

(b) a failure in any respect to comply with any such code is evidence of failure in that respect to comply with those duties.

(5) An undertaker who fails to comply with his duties under this section commits an offence and is liable on summary conviction to a fine not exceeding [F164 level 5] on the standard scale.

Textual Amendments

F164 Words in s. 130(5) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

131 Powers of road works authority in relation to reinstatement. S

(1) The road works authority may carry out such investigatory works as appear to them to be necessary to ascertain whether an undertaker has complied with his duties under this Part with respect to reinstatement.

If such a failure is disclosed, the undertaker shall bear the cost of the investigatory works; if not, the road works authority shall bear the cost of the investigatory works and of any necessary reinstatement.

(2) Where an undertaker has failed to comply with his duties under this Part with respect to reinstatement, he shall bear the cost of—

(a) a joint inspection with the road works authority to determine the nature of the failure and what remedial works need to be undertaken,

(b) an inspection by the authority of the remedial works in progress, and

(c) an inspection by the authority when the remedial works have been completed.

(3) The road works authority may by notice require an undertaker who has failed to comply with his duties under this Part with respect to reinstatement to carry out the necessary remedial works within such period [F165 , not being shorter than such period as may be prescribed,] as may be specified in the notice.

If he fails to comply with the notice, the authority may carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

[F166 (3A) Different minimum periods may be prescribed under subsection (3) for different descriptions of remedial works; and cases may be so prescribed in which no minimum period applies.]

(4) If it appears to the road works authority that a failure by an undertaker to comply with his duties under this Part as to reinstatement is causing danger to users of the road, the authority may carry out the necessary works without first giving notice and may recover from him the costs reasonably incurred by them in doing so.

They shall, however, give notice to him as soon as reasonably practicable stating their reasons for taking immediate action.

Textual Amendments

F165 Words in s. 131(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 29(1)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F166 S. 131(3A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 29(1)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2408 S. 131: power to contract out functions of the Secretary of State conferred (16.3.1996) by S.I. 1996/878, art. 2, Sch. para. 6(h)

132 Reinstatement affected by subsequent works. S

(1) The provisions of this section apply in relation to an undertaker’s duty under section 130(2) to ensure that a reinstatement conforms to the prescribed performance standards for the requisite period; and references to responsibility for a reinstatement and to the period of that responsibility shall be construed accordingly.

(2) Where a reinstatement is affected by remedial works executed by the undertaker in order to comply with his duties under this Part with respect to reinstatement and the extent of the works exceeds that prescribed, the subsequent reinstatement shall be treated as a new reinstatement as regards the period of his responsibility.

(3) Where the road works authority carry out investigatory works in pursuance of section 131(1) and the investigation does not disclose any failure by the undertaker to comply with his duties under this Part with respect to reinstatement, then, to the extent that the original reinstatement has been disturbed by the investigatory works, the responsibility of the undertaker for the reinstatement shall cease.

(4) Where a reinstatement is affected by remedial works executed by the road works authority in exercise of their powers under section 131(3) or (4) (powers to act in default of undertaker)—

(a) the undertaker is responsible for the subsequent reinstatement carried out by the authority, and

(b) if the extent of the works exceeds that prescribed, the subsequent reinstatement shall be treated as a new reinstatement as regards the period of his responsibility.

(5) The following provisions apply where a reinstatement is affected by subsequent works in the road otherwise than as mentioned above.

(6) If the reinstatement is dug out to any extent in the course of the subsequent works, the responsibility of the undertaker for the reinstatement shall cease to that extent.

(7) If in any other case the reinstatement ceases to conform to the prescribed performance standards by reason of the subsequent works, the responsibility of the undertaker for the reinstatement is transferred to the person executing the subsequent works; and the provisions of this Part apply in relation to him as they would have applied in relation to the undertaker.

(8) Where there are successive subsequent works affecting a reinstatement, then as between earlier and later works—

(a) subsections (6) and (7) apply in relation to the cessation or transfer of the responsibility of the person for the time being responsible for the reinstatement; and

(b) if the reinstatement ceases to conform to the prescribed performance standards by reason of the works or any of them, it shall be presumed until the contrary is proved that this was caused by the later or last of the works.

Modifications etc. (not altering text)

C2409 S. 132(5)-(8) extended (28.11.1992) by S.I. 1992/2990, art.11

Charges, fees and contributions payable by undertakers S

133 Charge for occupation of the road where works unreasonably prolonged. S

(1) The Secretary of State may make provision by regulations requiring an undertaker executing road works in a public road to pay a charge to the roads authority where—

(a) the duration of the works exceeds such period as may be prescribed, and

(b) the works are not completed within a reasonable period.

(2) For this purpose “a reasonable period” means such period as is agreed by the authority and the undertaker to be reasonable or, in default of such agreement, is determined [F167 in the prescribed manner] to be reasonable, for completion of the works in question.

In default of agreement, the authority’s view as to what is a reasonable period shall be acted upon pending the decision of the arbiter.

(3) The regulations may provide that if an undertaker has reason to believe that the duration of works will exceed the prescribed period he may submit to the authority an estimate of their likely duration—

(a) in the case of works in connection with the initial placing of apparatus in the road in pursuance of a permission granted under section 109 (permission to execute road works), together with his application for permission,

(b) in the case of other works (not being emergency works), together with his notice under section 114 (notice of starting date), or

(c) in the case of emergency works, as soon as reasonably practicable after the works are begun,

and that the period stated in an estimate so submitted shall be taken to be agreed by the authority to be reasonable unless they give notice, in such manner and within such period as may be prescribed, objecting to the estimate.

(4) The regulations may also provide that if it appears to the undertaker that by reason of matters not previously foreseen or reasonably foreseeable the duration of the works—

(a) is likely to exceed the prescribed period,

(b) is likely to exceed the period stated in his previous estimate, or

(c) is likely to exceed the period previously agreed or determined to be a reasonable period,

he may submit an estimate or revised estimate accordingly, and that if he does so any previous estimate, agreement or determination shall cease to have effect and the period stated in the new estimate shall be taken to be agreed by the authority to be reasonable unless they give notice, in such manner and within such period as may be prescribed, objecting to the estimate.

(5) The amount of the charge shall be determined in such manner as may be prescribed by reference to the time taken to complete the works and the extent to which the surface of the road is affected by the works.

Different rates of charge may be prescribed according to the place and time at which the works are executed and such other factors as appear to the Secretary of State to be relevant.

(6) The regulations may make provision as to the time and manner of making payment of any charge.

(7) The regulations shall provide that a roads authority may reduce the amount, or waive payment, of a charge in any particular case, in such classes of case as they may decide or as may be prescribed, or generally.

(8) The first regulations for the purposes of this section shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament; subsequent regulations shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Textual Amendments

F167 Words in s. 133(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(d), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

134 Inspection fees. S

(1) An undertaker executing road works shall, subject to the provisions of any scheme under this section, pay to the road works authority the prescribed fee in respect of each inspection of the works carried out by the authority.

(2) Different fees may be prescribed according to the nature or extent of the excavation or other works, the place where they are executed and such other factors as appear to the Secretary of State to be relevant.

(3) The Secretary of State may by regulations make a scheme under which undertakers pay the prescribed fee only in respect of such proportion or number of excavations or other works as may be determined in accordance with the scheme.

(4) The scheme may make provision—

(a) as to the periods and areas by reference to which the proportion or number is to be determined, and

(b) as to the intervals at which an account is to be struck between an undertaker and a road works authority and any necessary payment or repayment made;

and different provision may be made for different descriptions of undertaker and different descriptions of road works authority.

(5) Nothing in this section applies in relation to inspections in respect of which the undertaker is obliged to bear the cost under section 131(2) (inspections consequent on his failure to comply with his duties as to reinstatement).

135 Liability for cost of temporary traffic regulation. S

(1) Where by reason of road works—

(a) the traffic authority makes an order or issues a notice under section 14 of the M46 Road Traffic Regulation Act 1984 (temporary prohibition or restriction of traffic), or

(b) a concessionaire issues a notice under that section by virtue of section 43(4) of this Act,

the authority or concessionaire may recover from the undertaker the whole of the costs incurred by them in connection with or in consequence of the order or notice.

(2) Those costs shall be taken to include, in particular, the cost to the authority or concessionaire—

(a) of complying with any requirement to notify the public of any matter in connection with the making, issuing or operation of the order or notice, and

(b) of providing traffic signs in connection with the prohibition or restriction of traffic by the order or notice.

Modifications etc. (not altering text)

C2410 S. 135 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2411 S. 135 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

Marginal Citations

M46 1984 c. 27.

136 Liability for cost of use of alternative route. S

(1) Where by reason of road works the use of a road is restricted or prohibited and the diverted traffic uses as an alternative route a road of a lower classification, the undertaker shall indemnify the roads authority for the latter road in respect of costs reasonably incurred by them—

(a) in strengthening the road, so far as that is done with a view to and is necessary for the purposes of its use by the diverted traffic; or

(b) in making good any damage to the road occurring in consequence of the use by it of the diverted traffic.

(2) For this purpose the order of classification of roads, from higher to lower, is as follows:

1	Trunk roads.
2	Principal roads.
3	Other classified roads.
4	Other roads.

(3) In this section, “trunk road” and “classified road” have the meanings given by section 151 of the M47 Roads (Scotland) Act 1984 and “principal road” refers to a road classified as such by the Secretary of State under section 11 of that Act.

Modifications etc. (not altering text)

C2412 S. 136 applied (with modifications) (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), s. 7(6)(7) (with s. 75)

C2413 S. 136 applied (with modifications) (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), s. 7(6)(7) (with ss. 76, 84)

Marginal Citations

M47 1984 c. 54.

137 Contributions to costs of making good long-term damage. S

(1) The Secretary of State may make provision by regulations requiring an undertaker executing road works to contribute to the costs incurred or likely to be incurred by a road works authority in works of reconstruction or re-surfacing of the road.

(2) The regulations may provide—

(a) for a contribution to the cost of particular remedial works, or

(b) for a general contribution calculated in such manner as may be prescribed.

(3) In the former case the regulations may contain provision for apportioning the liability where the need for the remedial works is attributable to works executed by more than one person.

(4) In the latter case the regulations may provide for the amount of the contribution to vary according to the nature of the road, the description and extent of the works and such other factors as appear to the Secretary of State to be relevant.

(5) The first regulations under this section shall not be made unless a draft of them has been laid before and approved by a resolution of each House of Parliament; subsequent regulations shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Duties and liabilities of undertakers with respect to apparatus S

Prospective

138 Records of location of apparatus. S

(1) An undertaker shall, except in such cases as may be prescribed, record the location of every item of apparatus belonging to him as soon as reasonably practicable after—

(a) placing it in the road or altering its position,

(b) locating it in the road in the course of executing any other works, or

(c) being informed of its location under section 139 below,

stating the nature of the apparatus and (if known) whether it is for the time being in use.

(2) The records shall be kept up to date and shall be kept in such form and manner as may be prescribed.

(3) An undertaker shall make his records available for inspection, at all reasonable hours and free of charge, by any person having authority to execute works of any description in the road or otherwise appearing to the undertaker to have a sufficient interest.

(4) If an undertaker fails to comply with his duties under this section—

(a) he commits an offence and is liable on summary conviction to a fine not exceeding [F168 level 5] on the standard scale; and

(b) he is liable to compensate any person in respect of damage or loss incurred by him in consequence of the failure.

(5) In criminal or civil proceedings arising out of any such failure it is a defence for the undertaker to show that all reasonable care was taken by him, and by his contractors and by persons in his employ or that of his contractors, to secure that no such failure occurred.

(6) An order under section 161 (power to make consequential amendments, repeals, &c.) relating to an enactment or instrument containing provision for the keeping of records of apparatus which appears to the Secretary of State to be superseded by or otherwise inconsistent with the provisions of this section—

(a) shall not be subject to the procedure provided for in Schedule 7, and

(b) may make such transitional and other provision as appears to the Secretary of State appropriate for applying in relation to records compiled under that enactment or instrument the provisions of subsections (2) to (5) above and section 139 below.

Textual Amendments

F168 Words in s. 138(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Prospective

139 Duty to inform undertakers of location of apparatus. S

(1) A person executing works of any description in the road who finds apparatus belonging to an undertaker which is not marked, or is wrongly marked, on the records made available by the undertaker, shall take such steps as are reasonably practicable to inform the undertaker to whom the apparatus belongs of its location and (so far as appears from external inspection) its nature and whether it is in use.

(2) Where a person executing works of any description in the road finds apparatus which does not belong to him and is unable, after taking such steps as are reasonably practicable, to ascertain to whom the apparatus belongs, he shall—

(a) if he is an undertaker, note on the records kept by him under section 138(1) (in such manner as may be prescribed) the location of the apparatus he has found and its general description; and

(b) in any other case, inform the road works authority of the location and general description of the apparatus he has found.

(3) Subsections (1) and (2) have effect subject to such exceptions as may be prescribed.

(4) A person who fails to comply with subsection (1) or (2) commits an offence and is liable on summary conviction to a fine not exceeding [F169 level 4] on the standard scale.

Textual Amendments

F169 Words in s. 139(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

140 Duty to maintain apparatus. S

(1) An undertaker having apparatus in the road shall secure that the apparatus is maintained to the reasonable satisfaction of—

(a) the road works authority, as regards the safety and convenience of persons using the road (having regard, in particular, to the needs of people with a disability), the structure of the road and the integrity of apparatus of the authority in the road, and

(b) any other relevant authority, as regards any land, structure or apparatus of theirs;

and he shall afford reasonable facilities to each such authority for ascertaining whether it is so maintained.

(2) For this purpose maintenance means the carrying out of such works as are necessary to keep the apparatus in efficient working condition (including periodic renewal where appropriate); and includes works rendered necessary by other works in the road, other than major works for road purposes, major bridge works or major transport works (as to which, see sections 143 and 144 below).

(3) If an undertaker fails to give a relevant authority the facilities required by this section—

(a) the road works authority may in such cases as may be prescribed, and

(b) any other relevant authority may in any case,

execute such works as are needed to enable them to inspect the apparatus in question, including any necessary breaking up or opening of the road.

(4) If an undertaker fails to secure that apparatus is maintained to the reasonable satisfaction of a relevant authority in accordance with this section—

(a) the road works authority may in such cases as may be prescribed, and

(b) any other relevant authority may in any case,

execute any emergency works needed in consequence of the failure.

(5) The provisions of this Part apply in relation to works executed by a relevant authority under subsection (3) or (4) as if they were executed by the undertaker; and the undertaker shall indemnify the authority in respect of the costs reasonably incurred by them in executing the works.

(6) A relevant authority who execute or propose to execute any works under subsection (3) or (4) shall give notice to any other relevant authority as soon as reasonably practicable stating the general nature of the works.

(7) Nothing in subsection (3) or (4) shall be construed as excluding any other means of securing compliance with the duties imposed by subsection (1).

Commencement Information

I17 S. 140 wholly in force: s. 140(1)(2)(5)-(7) in force at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2; s. 140(3)(4) in force at 14.7.1992 by S. I. 1992/1671, art. 2, Sch.

141 Liability for damage or loss caused. S

(1) An undertaker shall compensate—

(a) the road works authority or any other relevant authority in respect of any damage or loss suffered by the authority in their capacity as such, and

(b) any other person having apparatus in the road in respect of any expense reasonably incurred in making good damage to that apparatus,

as a result of the execution by the undertaker of road works or any event of a kind mentioned in subsection (2) below.

(2) The events referred to in subsection (1) are any explosion, ignition, discharge or other event occurring to gas, electricity, water or other thing required for the purposes of a supply or service afforded by an undertaker which—

(a) at the time of or immediately before the event in question was in apparatus of the undertaker in the road, or

(b) had been in such apparatus before that event and had escaped therefrom in circumstances which contributed to its occurrence.

(3) The liability of an undertaker under this section arises—

(a) whether or not the damage or loss is attributable to negligence on his part or on the part of any person for whom he is responsible, and

(b) notwithstanding that he is acting in pursuance of a statutory duty.

(4) However, his liability under this section does not extend to damage or loss which is attributable to misconduct or negligence on the part of—

(a) the person suffering the damage or loss, or any person for whom he is responsible, or

(b) a third party, that is, a person for whom neither the undertaker nor the person suffering the damage or loss is responsible.

(5) For the purposes of this section the persons for whom a person is responsible are his contractors and any person in his employ or that of his contractors.

(6) Nothing in this section shall be taken as exonerating an undertaker from any liability to which he would otherwise be subject.

Modifications etc. (not altering text)

C2414 S. 141 modified (1. 1. 1993) by Local Government, Planning and Land Act 1980 (c. 65), s. 167(7) (as substituted (1.1.1993) by New Roads and Street Works Act 1991 (c. 22), s. 168(1), Sch. 8 Pt. IV para. 109; S.I. 1992/2990, art. 2(2), Sch.2)

Apparatus affected by road, bridge or transport works S

142 Works for road purposes likely to affect apparatus in the road. S

(1) This section applies to works for road purposes other than major works for road purposes (as to which see section 143 below).

(2) Where works to which this section applies are likely to affect apparatus in the road, the authority executing the works shall take all reasonably practicable steps—

(a) to give the person to whom the apparatus belongs reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by him which is reasonably necessary for the protection of the apparatus or for securing access to it.

(3) An authority who fail to comply with subsection (2) commit an offence in respect of each failure and are liable on summary conviction to a fine not exceeding [F170 level 4] on the standard scale.

(4) In proceedings against an authority for such an offence it is a defence for them to show that the failure was attributable—

(a) to their not knowing the position, or not knowing of the existence, of a person’s apparatus, or

(b) to their not knowing the identity or address of the person to whom any apparatus belongs,

and that their ignorance was not due to any negligence on their part or to any failure to make inquiries which they ought reasonably to have made.

Textual Amendments

F170 Words in s. 142(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2415 S. 142 applied (18.12.1996) by 1996 c. xii, s. 1, Sch. para. 11

C2416 Ss. 142-144 modified (18.3.2011) by Forth Crossing Act 2011 (asp 2), ss. 58, 80(2) (with ss. 69, 78); S.S.I. 2011/38, art. 2, sch.

143 Measures necessary where apparatus affected by major works. S

(1) Where an undertaker’s apparatus in a road is or may be affected by major works for roads purposes, major bridge works or major transport works, the roads, bridge or transport authority concerned and the undertaker shall take such steps as are reasonably required—

(a) to identify any measures needing to be taken in relation to the apparatus in consequence of, or in order to facilitate, the execution of the authority’s works,

(b) to settle a specification of the necessary measures and determine by whom they are to be taken, and

(c) to co-ordinate the taking of those measures and the execution of the authority’s works,

so as to secure the efficient implementation of the necessary work and the avoidance of unnecessary delay.

(2) The Secretary of State may issue or approve for the purposes of this section a code of practice giving practical guidance as to the matters mentioned in subsection (1) and the steps to be taken by the authority and the undertaker.

(3) Any dispute between the authority and the undertaker as to any of the matters mentioned in subsection (1) shall, in default of agreement, be settled [F171 in the prescribed manner].

(4) If the authority or the undertaker fails to comply with an agreement between them as to any of those matters, or with the decision [F172 made] under subsection (3) [F173 in settlement of a dispute], the authority or undertaker shall be liable to compensate the other in respect of any loss or damage resulting from the failure.

Textual Amendments

F171 Words in s. 143(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(e), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F172 Word in s. 143(4) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(3)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F173 Words in s. 143(4) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(3)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Modifications etc. (not altering text)

C2416 Ss. 142-144 modified (18.3.2011) by Forth Crossing Act 2011 (asp 2), ss. 58, 80(2) (with ss. 69, 78); S.S.I. 2011/38, art. 2, sch.

C2417 S. 143 applied (18.12.1996) by 1996 c. xii, s. 1, Sch. para. 11

C2418 S. 143(1)(3)(4) excluded (28.11.1992) by S.I. 1992/2990, art.10

Commencement Information

I18 S. 143 wholly in force; s. 143(1)(3)(4) in force at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2; s. 143(2) in force at 14.7.1992 by S.I. 1992/1671, art. 2, Sch.

144 Sharing of cost of necessary measures. S

(1) Where an undertaker’s apparatus in a road is affected by major works for roads purposes, major bridge works or major transport works, the allowable costs of the measures needing to be taken in relation to the apparatus in consequence of the works, or in order to facilitate their execution, shall be borne by the roads, bridge or transport authority concerned and the undertaker in such manner as may be prescribed.

(2) The regulations may make provision as to the costs allowable for this purpose.

Provision may, in particular, be made for disallowing costs of the undertaker—

(a) where the apparatus in question was placed in the road after the authority had given the undertaker the prescribed notice of their intention to execute the works, or

(b) in respect of measures taken to remedy matters for which the authority were not to blame,

and for allowing only such costs of either party as are not recoverable from a third party.

(3) Where the authority have a right to recover from a third party their costs in taking measures in relation to undertaker’s apparatus but in accordance with section 143 it is determined that the measures should be taken by the undertaker, the right of the authority includes a right to recover the undertaker’s costs in taking those measures and they shall account to the undertaker for any sum received.

(4) The regulations shall provide for the allowable costs to be borne by the authority and the undertaker in such proportions as may be prescribed.

Different proportions may be prescribed for different cases or classes of case.

(5) The regulations may require the undertaker to give credit for any financial benefit to him from the betterment or deferment of renewal of the apparatus resulting from the measures taken.

(6) The regulations may make provision as to the time and manner of making any payment required under this section.

Modifications etc. (not altering text)

C2416 Ss. 142-144 modified (18.3.2011) by Forth Crossing Act 2011 (asp 2), ss. 58, 80(2) (with ss. 69, 78); S.S.I. 2011/38, art. 2, sch.

C2419 S. 144 excluded (28.11.1992) by S.I. 1992/2990, art. 10

C2420 S. 144 applied (18.12.1996) by 1996 c. xii, s. 1, Sch. para. 11

C2421 S. 144 applied (27.4.2006) by Edinburgh Tram (Line Two) Act 2006 (asp 6), sch. 9 para. 2(3)(a) (with s. 75)

C2422 S. 144 applied (8.5.2006) by Edinburgh Tram (Line One) Act 2006 (asp 7), sch. 9 para. 2(3)(a) (with ss. 76, 84)

C2423 S. 144 applied (1.6.2010) by The Network Rail (Waverley Steps) Order 2010 (S.S.I. 2010/188), art. 1, sch. 7 para. 2(4)(a)

C2424 S. 144 applied (18.3.2011) by Forth Crossing Act 2011 (asp 2), ss. 61(3), 80(2) (with ss. 69, 78); S.S.I. 2011/38, art. 2, sch.

Provisions with respect to particular authorities and undertakings S

145 Roads authorities, roads and related matters. S

(1) In this Part—

• “roads authority” and “local roads authority” have the same meaning as in section 151 of the M48 Roads (Scotland) Act 1984; and

• “public road” means a road which a roads authority have a duty to maintain.

(2) In this Part “works for road purposes” means—

(a) works for the maintenance of a road,

(b) works for any purpose falling within the definition of “improvement” in section 151 of that Act,

(c) the erection, maintenance, alteration or removal of traffic signs, or

(d) the construction of a crossing for vehicles across a footway or the strengthening or adaptation of a footway for use as a crossing for vehicles.

(3) In this Part “major works for roads purposes” means works of any of the following descriptions executed by the roads authority in relation to a road which consists of or includes a carriageway—

(a) reconstruction or widening of the road,

(b) substantial alteration of the level of the road,

(c) provision, alteration of the position or width, or substantial alteration in the level of a carriageway, footpath or cycle track in the road,

(d) the construction or removal of a road hump within the meaning of section 40 of the M49 Roads (Scotland) Act 1984,

(e) works carried out in exercise of the powers conferred by section 63 of the Roads (Scotland) Act 1984 (new access over verges and footways),

(f) provision of a cattle-grid in the road or works ancillary thereto, or

(g) tunnelling or boring under the road.

Marginal Citations

M48 1984 c. 54.

M49 1984 c. 54.

146 Prospective public roads. S

(1) Subject to subsection (2), where a local roads authority are satisfied that a road in their area which is not a public road is likely to become a public road, they may make a declaration to that effect.

(2) Subsection (1) does not apply to a road which is under the management or control of a transport authority.

(3) The provisions of this Part apply to a road in respect of which such a declaration has been made as they apply to a public road.

(4) In relation to road works in such a road, the road works authority—

(a) shall secure the performance by undertakers of their duties under this Part, and shall exercise their powers under this Part, in such manner as is reasonably required for the protection of the road managers; and

(b) shall comply with any reasonable request as to securing performance of those duties, or as to the exercise of those powers, which may be made by the road managers.

147 Bridges, bridge authorities and related matters. S

(1) In this Part—

(a) references to a bridge include so much of any road as gives access to the bridge and any embankment, retaining wall or other work or substance supporting or protecting that part of the road; and

(b) “bridge authority” means the authority, body or person in whom a bridge is vested.

(2) In this Part “major bridge works” means works for the replacement, reconstruction or substantial alteration of a bridge.

(3) Where a road is carried or crossed by a bridge, any statutory right to place apparatus in the road includes the right to place apparatus in, and attach apparatus to, the structure of the bridge; and other rights to execute works in relation to the apparatus extend accordingly.

References in this Part to apparatus in the road include apparatus so placed or attached.

(4) An undertaker proposing to execute road works affecting the structure of a bridge shall consult the bridge authority before giving notice under section 114 (notice of starting date) in relation to the works.

(5) An undertaker executing such works shall take all reasonably practicable steps—

(a) to give the bridge authority reasonable facilities for monitoring the execution of the works, and

(b) to comply with any requirement made by them which is reasonably necesssary for the protection of the bridge or for securing access to it.

(6) An undertaker who fails to comply with any requirement of subsection (4) or (5) commits an offence in respect of each failure and is liable on summary conviction to a fine not exceeding [F174 level 5] on the standard scale.

(7) Subsections (4) to (6) do not apply to works in relation to which Schedule 6 applies (works in roads with special engineering difficulties).

Textual Amendments

F174 Words in s. 147(6) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), s. 54(2), sch. 3; S.S.I. 2008/15, art. 2(2), sch. 1

148 Sewers. S

(1) An undertaker proposing to execute road works affecting [F175 a public sewer] shall consult [F176 Scottish Water] before giving notice under section 114 (notice of starting date) in relation to the works.

(2) References in this Part to apparatus include a sewer, drain or tunnel.

[F177 (3) References in this Part to an undertaker having apparatus shall, where the apparatus is a sewer, drain or tunnel, be construed—

(a) in the case of apparatus vested in [F178 Scottish Water], as references to that [F179 body]; and

(b) in any other case, as references to the authority, body or person having the management or control of the apparatus.]

(4) Section 128 (provisions as to works likely to affect other apparatus in the road) does not apply by virtue of subsection (2) above in relation to works likely to affect [F180 a public sewer] if, or to the extent that, Schedule 6 (works in roads with special engineering difficulties) applies.

Textual Amendments

F175 Words in s. 148(1) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(5)(a) (with s. 67); S.S.I. 2002/118, art. 2

F176 Words in s. 148(1) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(5)(b) (with s. 67); S.S.I. 2002/118, art. 2

F177 S. 148(3) substituted (1.4.1996) by 1994 c. 39, s. 180(1), Sch. 13 para. 168(4)(b); S.I. 1996/323 art. 4(c)

F178 Words in s. 148(3)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(5)(b) (with s. 67); S.S.I. 2002/118, art. 2

F179 Word in s. 148(3)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(5)(b) (with s. 67); S.S.I. 2002/118, art. 2

F180 Words in s. 148(4) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(5)(c) (with s. 67); S.S.I. 2002/118, art. 2

149 Provisions as to reinstatement of sewers, drains or tunnels. S

(1) The duties of an undertaker under this Part with respect to reinstatement of the road extend, in the case of road works which involve breaking up or opening a sewer, drain or tunnel under the road, to the reinstatement of the sewer, drain or tunnel.

(2) The responsible authority may by notice require an undertaker who has failed to comply with his duties under this Part with respect to reinstatement to carry out the necessary remedial works within such period [F181 , not being shorter than such period as may be prescribed,] as may be specified in the notice.

If he fails to comply with the notice, the authority may carry out the necessary works and recover from him the costs reasonably incurred by them in doing so.

[F182 (2A) Different minimum periods may be prescribed under subsection (2) for different descriptions of remedial works; and cases may be so prescribed in which no minimum period applies.]

(3) If it appears to the responsible authority that a failure by an undertaker to comply with his duties under this Part as to reinstatement is causing danger to users of the road, the authority may carry out the necessary works without first giving notice and may recover from him the costs reasonably incurred by them in doing so.

They shall, however, give notice to him as soon as reasonably practicable stating their reasons for taking immediate action.

(4) The responsible authority for the purposes of this section is—

(a) in the case of [F183 a public sewer, Scottish Water], and

(b) in the case of any other sewer, drain or tunnel, the authority, body or person having the management or control of it.

Textual Amendments

F181 Words in s. 149(2) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 29(2)(a), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F182 S. 149(2A) inserted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 29(2)(b), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

F183 Words in s. 149(4)(a) substituted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(6) (with s. 67); S.S.I. 2002/118, art. 2

150 Transport authorities, transport undertakings and related matters. S

(1) In this Part—

(a) “transport authority” means the authority, body or person having the control or management of a transport undertaking; and

(b) “transport undertaking” means a railway, tramway, dock, harbour, pier, canal or inland navigation undertaking of which the activities, or some of the activities, are carried on under statutory authority.

(2) In this Part “major transport works” means substantial works required for the purposes of a transport undertaking and executed in property held or used for the purposes of the undertaking.

(3) References in this Part to a road which crosses or is crossed by property held or used for the purposes of a transport undertaking extend to cases in which the road and the property in question are at different levels.

But the transport authority shall not be treated as a relevant authority as regards undertakers’ works in such a road where the property in question consists only of—

(a) subsoil of the road which is held by the transport authority but is not used, and has not been adapted for use, for the purposes of the undertaking, or

(b) property underground at such a depth that there is no reasonable possibility of the works affecting it.

(4) The provisions of this Part relating to a road which crosses or is crossed by property held or used for the purposes of a transport undertaking apply to a road which is or forms part of a towing-path or other way running along a canal or inland navigation, provided the path or way is held or used, or the subsoil of it is held, for the purposes of the canal or inland navigation undertaking.

151 Special precautions as to displaying of lights. S

(1) An undertaker executing road works in a road which crosses, or is crossed by, or is in the vicinity of, a railway, tramway, dock, harbour, pier, canal or inland navigation, shall comply with any reasonable requirements imposed by the transport authority concerned with respect to the displaying of lights so as to avoid any risk of their—

(a) being mistaken for any signal light or other light used for controlling, directing or securing the safety of traffic thereon, or

(b) being a hindrance to the ready interpretation of any such signal or other light.

(2) An undertaker who fails to comply with any such requirement commits an offence and is liable on summary conviction to a fine not exceeding level 3 on the standard scale.

(3) In proceedings for such an offence it is a defence for the undertaker to show that all reasonable care was taken by him, and by his contractors and by persons in his employ or that of his contractors, to secure that no such failure occurred.

152 Works affecting level crossings or tramways. S

(1) This section applies to road works at a crossing of a railway on the level or which affect a tramway.

In this section “the relevant transport authority” means the authority having the management of the railway or tramway undertaking concerned.

(2) An undertaker proposing to begin to execute works to which this section applies shall give the prescribed notice to the relevant transport authority notwithstanding that such notice is not required under section 114 (notice of starting date).

The provisions of subsections (2) to (7) of that section (contents of notice, when works may be begun, &c.) apply in relation to the notice required by this subsection as in relation to a notice under subsection (1) of that section.

(3) An undertaker executing works to which this section applies shall comply with any reasonable requirements made by the relevant transport authority—

(a) for securing the safety of persons employed in connection with the works, or

(b) for securing that interference with traffic on the railway or tramway caused by the execution of the works is reduced so far as is practicable;

and, except where submission of a plan and section is required, he shall defer beginning the works for such further period as the relevant transport authority may reasonably request as needed for formulating their requirements under this subsection or making their traffic arrangements.

(4) Nothing in subsection (2) or (3) affects the right of an undertaker to execute emergency works.

(5) An undertaker executing emergency works shall give notice to the relevant transport authority as soon as reasonably practicable of his intention or, as the case may be, of his having begun to do so notwithstanding that such notice is not required by section 116 (notice of emergency works).

The provisions of subsections (3) and (4) of that section (contents of notice and penalty for failure to give notice) apply in relation to the notice required by this subsection as in relation to a notice under subsection (2) of that section.

Power of road works authority or district council to undertake road works S

153 Power of road works authority or district council to undertake road works. S

(1) A road works authority [F184 or district council] may enter into an agreement with an undertaker for the execution by the authority [F184 or council]on behalf of the undertaker of any road works.

(2) The agreement may contain such terms as to payment and otherwise as the parties consider appropriate.

(3) Nothing in this section shall be construed as derogating from any powers exercisable by the authority [F184 or council]apart from this section.

(4) This section shall cease to have effect upon such day as the Secretary of State may appoint by order made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Textual Amendments

F184 Words in s. 153(1) and (3) ceased to have effect (1.4.1996) by virtue of 1994 c. 39, s. 180(1)(2), Sch. 13 para. 168(5), Sch. 14; S.I. 1996/323 art. 4(c)(d)

Supplementary provisions S

154 Offences. S

(1) Any provision of this Part imposing criminal liability in respect of any matter is without prejudice to any civil liability in respect of the same matter.

(2) Where a failure to comply with a duty imposed by this Part is continued after conviction, the person in default commits a further offence.

[F185 154A Fixed penalties for certain offences under this Part S

(1) Any offence under this Part relating to road works which is listed in the first column of Schedule 6A (and described in general terms in the second column) is a fixed penalty offence for the purposes of this Part.

(2) Offences listed in that Schedule which are committed by virtue of section 166 (offences by bodies corporate and partnerships) are not fixed penalty offences.

(3) The Scottish Ministers may by order made by statutory instrument modify that Schedule so as to provide for offences under this Part relating to road works to become (or cease to be) fixed penalty offences.

(4) No such order shall be made unless a draft of the statutory instrument containing it has been laid before and approved by resolution of the Scottish Parliament.

(5) Schedule 6B (which makes provision about fixed penalties for fixed penalty offences) has effect.]

Textual Amendments

F185 S. 154A inserted (S.) (1.10.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 34(1), 54(2); S.S.I. 2008/15, art. 2(3), sch. 2

Modifications etc. (not altering text)

C2425 S. 154A(5) restricted (1.10.2008) by The Road Works (Fixed Penalty) (Scotland) Regulations 2008 (S.S.I. 2008/244), regs. 1, 3

155 Recovery of costs or expenses. S

(1) Any provision of this Part enabling an authority, body or person to recover the costs or expenses of taking any action shall be taken to include the relevant administrative expenses of that authority, body or person including an appropriate sum in respect of general staff costs and overheads.

The Secretary of State may prescribe the basis on which such amounts are to be calculated; and different provision may be made for different cases or descriptions of case.

(2) Where a right to payment enuring for the benefit of a person is conferred in respect of the same matter—

(a) both under this Part and under any enactment or agreement passed or made before the commencement of this Part, or

(b) by two or more provisions of this Part,

a payment made in discharge of any of those rights shall be treated as being made in or towards satisfaction of the other or others.

(3) Where under any provision of this Part a person is entitled in certain circumstances to recover costs or expenses incurred by him in executing works or taking other steps, any dispute as to the existence of those circumstances or as to the amount recoverable shall be determined [F186 in the prescribed manner].

This applies whether the provision is expressed as conferring a right to recover, or as imposing a liability to reimburse or indemnify or to bear the cost, but does not apply in relation to a provision expressed as providing for the charging of a fee or conferring a right to compensation or in relation to section 137 (contribution to the cost of making good long-term damage to the road).

Textual Amendments

F186 Words in s. 155(3) substituted (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(1)(2)(f), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

Commencement Information

I19 S. 155 wholly in force at 1.1.1993, see s. 170 and S.I. 1992/2990, art. 2(2), Sch. 2

156 Service of notices and other documents. S

(1) Notices required or authorised to be given for the purposes of this Part shall be given in the prescribed form.

(2) The Secretary of State may make provision by regulations as to the manner of service of notices and other documents required or authorised to be served for the purposes of this Part.

[F187 (3) References in this section to notices authorised to be given or served for the purposes of this Part include reference to notices under Schedule 8B to the Roads (Scotland) Act 1984 (c. 54) (fixed penalties for certain offences under that Act).]

Textual Amendments

F187 S. 156(3) inserted (1.10.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 37(4), 54(2); S.S.I. 2008/15, art. 2(3), sch. 2

157 Reckoning of periods. S

(1) In reckoning for the purposes of this Part a period expressed as a period from or before a given date, that date shall be excluded.

(2) For the purposes of this Part a working day means a day other than a Saturday, Sunday, Christmas Day, Good Friday or a bank holiday; and a notice given after 4.30 p.m. on a working day shall be treated as given on the next working day.

(3) In subsection (2) a “bank holiday” means a day which is a bank holiday under the M50 Banking and Financial Dealings Act 1971 in the locality in which the road in question is situated.

Marginal Citations

M50 1971 c. 80.

[F188 157A Regulations prescribing manner of settlement of disputes S

Regulations under this Part prescribing the manner in which any question or dispute is to be settled may in particular make provision for the question or, as the case may be, dispute to be settled—

(a) by the Commissioner, or

(b) by arbitration.]

Textual Amendments

F188 S. 157A inserted (S.) (1.4.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 36(4), 54(2); S.S.I. 2008/15, art. 2(2), sch. 1

158 Arbitration. S

(1) Any matter which under this Part is to be settled by arbitration shall be referred for determination by a single arbiter appointed by agreement between the parties concerned or, in default of agreement, by the sheriff.

(2) In any arbitration in accordance with subsection (1) the arbiter may, and if so directed by the Court of Session shall, state a case for the decision of the Court on any question of law arising in the arbitration; and the decision of the Court shall be final unless the Court or the [F189 Supreme Court] give leave to appeal to the [F189 Supreme Court] against the decision.

(3) Leave under subsection (2) may be given on such terms as to expenses or otherwise as the Court or the [F189 Supreme Court] may determine.

Textual Amendments

F189 Words in s. 158(2)(3) substituted (1.10.2009) by Constitutional Reform Act 2005 (c. 4), s. 148(1), Sch. 9 para. 53; S.I. 2009/1604, art. 2(d)

159 Agreements inconsistent with the provisions of this Part. S

(1) An agreement which purports to make provision regulating the execution of road works is of no effect to the extent that it is inconsistent with the provisions of this Part.

(2) This does not affect an agreement for the waiver or variation of a right conferred on a relevant authority by any of the provisions of this Part which is made after the right has accrued and is not inconsistent with the future operation of those provisions.

160 Effect of this Part on certain existing special enactments or instruments. S

(1) Any special enactment passed or made before the commencement of this Part which makes or authorises the making of provision regulating the execution of road works in a manner inconsistent with the provisions of this Part shall cease to have effect; and unless a contrary intention appears no enactment passed or made after the commencement of this Part shall be construed as making or authorising the making of any such provision.

This subsection does not apply to any provision as to the obtaining of consent for the execution of the works or for any other purpose.

(2) Any special enactment passed or made before the commencement of this Part which requires the consent of a relevant authority (in its capacity as such) to the execution of road works shall cease to have effect, except as mentioned below; and unless a contrary intention appears no special enactment passed or made after the commencement of this Part shall be construed as requiring such consent.

This subsection does not apply to a consent requirement so far as it relates to—

(a) works above the surface level of the road, or

(b) works outside the limits of supply of an undertaker in relation to whom such limits are imposed.

(3) A provision made by way of condition imposed on the giving of a consent for the execution of road works is of no effect in so far as it would have been so by virtue of section 159 if it had been made by an agreement.

(4) If it appears to the Secretary of State—

(a) that by the operation of subsection (1) a person has been or will be deprived of some protection afforded by a special enactment and that corresponding protection is in all the circumstances required, or

(b) that a requirement of consent imposed by a special enactment should be saved from the operation of subsection (2), either as regards all works to which the requirement extends or as regards any description of such works, or

(c) that conditions of any descriptions should be rendered valid notwithstanding subsection (3), or

(d) that uncertainty or obscurity has resulted or is likely to result from the operation on a special enactment of the general provisions of subsection (1), (2) or (3),

he may by order make such provision as he considers appropriate for affording such protection, saving the requirement, rendering the conditions valid or modifying the special enactment, as the case may be.

(5) An order under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament; and the provisions of Schedule 7 have effect with respect to the procedure for making such an order.

(6) The provisions of this section apply in relation to an instrument having effect under or by virtue of an enactment as in relation to an enactment; and references to a special enactment shall be construed accordingly.

161 Effect of this Part on other existing enactments or instruments. S

(1) The Secretary of State may by order make such provision amending, repealing, or preserving the effect of, any enactment passed or made before the commencement of this Part (not being a special enactment to which section 160(1), (2) or (3) applies) as appears to him appropriate in consequence of the provisions of this Part.

(2) Subject to any order under this section and (in the case of a public general Act) to any express amendment made by this Act, any such enactment which proceeds by reference to any provision of the M51 Public Utilities Street Works Act 1950, or any other provision repealed by this Act in consequence of this Part, shall continue to have effect as if the provision referred to had not been repealed.

(3) An order under this section may, in particular, make provision in relation to—

(a) enactments providing for the keeping of records of apparatus, and

(b) enactments providing for the giving of notice of proposed road works.

(4) An order under this section may contain such transitional provisions and savings as appear to the Secretary of State to be appropriate.

(5) An order under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

(6) Except as mentioned in section 138(6), the provisions of Schedule 7 have effect with respect to the making of an order under this section in relation to a special enactment.

(7) The provisions of this section apply in relation to an instrument having effect under or by virtue of an enactment as in relation to an enactment; and references to a special enactment shall be construed accordingly.

Marginal Citations

M51 1950 c. 39.

162 Former controlled land. S

(1) The following provisions apply with respect to land (not forming part of a road) in which immediately before the commencement of this Part there is apparatus placed by virtue of Schedule 1 to the M52 Public Utilities Street Works Act 1950 (authorisation of works in certain land abutting a road).

(2) If any person having a sufficient interest in the land gives notice to the undertaker that he objects to the continuance of the powers and rights over the land given by that Schedule, those powers and rights shall cease to have effect at the end of the period of six months from the date on which the notice was given.

For this purpose a person has a sufficient interest in the land if he is an owner, lessee or occupier of the land having an interest greater than that of tenant for a year or from year to year.

(3) The road works authority shall indemnify the undertaker in respect of the costs reasonably incurred by him in or in connection with—

(a) any removal of apparatus rendered necessary by the cessation of his powers and rights under this section, and

(b) the execution of any works or taking of any other measures rendered necessary thereby for the purposes of the supply or service for which apparatus whose removal is rendered necessary was used.

(4) Where the land becomes part of the road after the commencement of this Part, any consent which would have been required for the placing of the apparatus in the road had it been placed there immediately after the land in question became part of the road shall be deemed to have been given unconditionally.

(5) Subject to any exercise of the right conferred by subsection (2), the rights and powers of the undertaker under Schedule 1 to the Public Utilities Street Works Act 1950 continue unaffected by the repeal of that Act.

Marginal Citations

M52 1950 c. 39.

163 Meaning of “prescribed” and regulations generally. S

(1) In this Part “prescribed” means prescribed by the Secretary of State by regulations, which may (unless the context otherwise requires) make different provision for different cases.

(2) Regulations under this Part shall be made by statutory instrument which, unless provision to the contrary is made, shall be subject to annulment in pursuance of a resolution of either House of Parliament.

(3) Regulations under this Part may provide for references in the regulations to any specified document to operate as references to that document as revised or re-issued from time to time.

[F190 163A Consultation on regulations and codes of practice S

(1) Before—

(a) making, amending or revoking regulations under or for the purposes of any provision of this Part, or

(b) issuing, amending or revoking a code of practice under or for the purposes of any such provision or approving any such code of practice or its amendment or revocation,

the Scottish Ministers shall consult the persons and authorities set out in subsection (2).

(2) Those persons and authorities are such—

(a) persons considered by the Scottish Ministers to be representative of the interests of undertakers,

(b) road works authorities,

(c) other persons,

as the Scottish Ministers think appropriate.]

Textual Amendments

F190 S. 163A inserted (S.) (1.10.2007) by Transport (Scotland) Act 2005 (asp 12), ss. 39, 54(2); S.S.I. 2007/409, art. 2

164 Minor definitions. S

(1) In this Part—

• “apparatus” includes any structure for the lodging therein of apparatus or for gaining access to apparatus;

• “carriageway” and “footway” have the same meaning as in the M53 Roads (Scotland) Act 1984;

• “enactment” includes an enactment contained in subordinate legislation within the meaning of the M54 Interpretation Act 1978.

• “in”, in a context referring to works, apparatus or other property in a road or other place includes a reference to works, apparatus or other property under, over, across, along or upon it;

• [F191 “public sewer” has the same meaning as in the Sewerage (Scotland) Act 1968;]

• “railway” includes a light railway other than one in the nature of a tramway (see the definition of “tramway” below);

• “reinstatement” includes making good;

• F192 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

• “special enactment” means an enactment which is not a public general enactment, and includes—

  (a)

  any Act for confirming a provisional order,

  (b)

  any provision of a public general Act in relation to the passing of which any of the Standing Orders of the House of Lords or the House of Commons relating to Private Business applied, and

  (c)

  any enactment to the extent that it is incorporated or applied for the purposes of a special enactment;

• “statutory right” means a right (whether expressed as a right, a power or otherwise) conferred by an enactment (whenever passed or made), other than a right exercisable by virtue of a permission granted under section 109;

• “traffic” includes pedestrians and animals;

• “traffic authority” and “traffic sign” have the same meaning as in the M55 Road Traffic Regulation Act 1984;

• “tramway” means a system, mainly or exclusively for the carriage of passengers, using vehicles guided, or powered by energy transmitted, by rails or other fixed apparatus installed exclusively or mainly in a road.

(2) A right to execute works which extends both to a road and to other land is included in references in this Part to a right to execute works in a road in so far as it extends to the road.

(3) A right to execute works which extends to part of the road but not the whole is included in references in this Part to a right to execute works in a road; and in relation to such a right references in this Part to the road in which it is exercisable shall be construed as references to the part to which the right extends.

(4) For the purposes of this Part apparatus shall be regarded as affected by works if the effect of the works is to prevent or restrict access to the apparatus (for example, by laying other apparatus above or adjacent to it).

(5) Section 28 of the M56 Chronically Sick and Disabled Persons Act 1970 (power to define “disability” and other expressions) applies in relation to the provisions of this Part as to the provisions of that Act.

Textual Amendments

F191 Words in s. 164(1) inserted (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(7)(a) (with s. 67); S.S.I. 2002/118, art. 2

F192 Words in s. 164(1) repealed (1.4.2002) by Water Industry (Scotland) Act 2002 (asp 3), s. 71, Sch. 7 para. 21(7)(b) (with s. 67); S.S.I. 2002/118, art. 2

Marginal Citations

M53 1984 c. 54.

M54 1978 c. 30.

M55 1984 c. 27.

M56 1970 c. 44.

165 Index of defined expressions. S

The expressions listed below are defined or otherwise fall to be construed for the purposes of this Part in accordance with the provisions indicated—

affected by (in relation to apparatus and works)	section 164(4)
apparatus	section 148(2) and 164
arbitration	section 158
bridge	section 147(1)(a)
bridge authority	section 147(1)(b)
carriageway	section 164
[F193 the Commissioner	section 112A(1)]
costs	section 155
disability	(see section 164(4))
emergency works	section 111
enactment	section 164
expenses	section 155
[F194 fixed penalty offence	section 154A(1)]
footway	section 164
in (in a context referring to works, apparatus or other property in a road)	section 164
local roads authority	section 145(1)
major bridge works	section 147(2)
major works for roads purposes	section 145(3)
major transport works	section 150(2)
notice	section 156
prescribed	section 163
public road	section 145(1)
railway	section 164
reinstatement	section 164 (and see sections 129(5) and 149(1))
relevant authority (in relation to road works)	section 108(6) (and see section 150(3))
road	section 107(1)
road managers	section 108(4)
road works	section 107(3) (and see section 164(2) and (3))
road works authority	section 108(1)
roads authority	section 145(1)
special enactment	section 164(1)
[F195 the SRWR	section 112A(1)]
statutory right	section 164(1)
traffic	section 164(1)
traffic authority	section 164(1)
traffic sign	section 164(1)
tramway	section 164(1)
transport authority	section 150(1)(a)
transport undertaking	section 150(1)(b)
undertaker (in relation to road works or apparatus)	sections 107(4) and (5) and 148(3)
working day	section 157(2)
works for road purposes	section 145(2).

Textual Amendments

F193 Words in s. 165 inserted (29.2.2008 for specified purposes, 1.4.2008 in so far as not already in force) by Transport (Scotland) Act 2005 (asp 12), ss. 19(7)(a), 54(2); S.S.I. 2008/15, art. 2(1)(2), sch. 1

F194 Words in s. 165 inserted (1.10.2008) by Transport (Scotland) Act 2005 (asp 12), ss. 34(2), 54(2); S.S.I. 2008/15, art. 2(3), sch. 2

F195 Words in s. 165 inserted (29.2.2008 for specified purposes, 1.4.2008 in so far as not already in force) by Transport (Scotland) Act 2005 (asp 12), ss. 19(7)(b), 54(2); S.S.I. 2008/15, art. 2(1)(2), sch. 1

Part V U.K. General

166 Offences by bodies corporate or Scottish partnerships. E+W+S

(1) Where an offence under this Act committed by a body corporate is proved to have been committed with the consent or connivance of, or to be attributable to any neglect on the part of, a director, manager, secretary or other similar officer of the body, or a person purporting to act in any such capacity, he as well as the body corporate is guilty of the offence and liable to be proceeded against and punished accordingly.

In relation to a body corporate whose affairs are managed by its members “director” means a member of the body corporate.

(2) Where an offence under this Act is committed in Scotland by a Scottish partnership and is proved to have been committed with the consent or connivance of, or to be attributable to any neglect on the part of, a partner, he as well as the partnership is guilty of the offence and liable to be proceeded against and punished accordingly.

Commencement Information

I20 S. 166 wholly in force; s. 166(1)(2) in force (S.) at 21.10.1991 so far as relates to offences committed under Pt. II see s. 170(1) and S.I. 1991/2286, art. 2(1), Sch. 1; s. 166(1) in force (E.W.) at 1.11.1991 see s. 170 and S.I. 1991/2288, art. 3, Sch.; s. 166 wholly in force at 1.1. 1993 by S.I. 1992/2990, art. 2(2), Sch. 2

167 Crown application. E+W+S

(1) The provisions of section 327 of the M57 Highways Act 1980 (application of Act to Crown land) apply in relation to the provisions of Part I of this Act (new roads in England and Wales) as in relation to the provisions of that Act; and the provisions of section 146 of the M58 Roads (Scotland) Act 1984 (application of Act to Crown land) apply in relation to the provisions of Part II of this Act (new roads in Scotland) as in relation to the provisions of that Act.

(2) Subject to any regulations under subsection (3), th136.e provisions of Parts I and II of this Act have effect in relation to persons in the public service of the Crown, vehicles belonging to, or used for the purposes of, a Minister of the Crown or Government department [F196 or as respects Part II of this Act any part of the Scottish Administration] and things done, or omitted to be done, in connection with such vehicles by such persons as they have effect in relation to other persons or vehicles.

(3) The Secretary of State may by regulations provide that in their application in relation to—

(a) vehicles belonging to the Crown and used for naval, military or air force purposes,

(b) vehicles used for the purposes of any such body, contingent or detachment of the forces of any country as is a visiting force for the purposes of any of the provisions of the M59 Visiting Forces Act 1952, or

(c) vehicles used for the purposes of any headquarters or organisation designated by an Order in Council under section 1 of the M60 International Headquarters and Defence Organisations Act 1964,

the provisions of Parts I and II of this Act shall have effect subject to such modifications as may be prescribed.

For this purpose “modifications” includes additions, omissions and alterations.

[F197 The power to make regulations in terms of this subsection does not extend to the Scottish Ministers.]

(4) The provisions of Parts III and IV of this Act (street works in England and Wales and road works in Scotland) bind the Crown.

(5) Nothing in subsection (4) shall be construed as authorising the bringing of proceedings for a criminal offence against a person acting on behalf of the Crown.

(6) Regulations under this section shall be made by statutory instrument which shall be subject to annulment in pursuance of a resolution of either House of Parliament.

Textual Amendments

F196 Words in s. 167(2) inserted (1.7.1999) by S.I. 1999/1820, art. 4, Sch. 2 Pt. I para. 103; S.I. 1998/3178, art. 3

F197 Words in s. 167(3) inserted (1.7.1999) by S.I. 1999/1820, art. 4, Sch. 2 Pt. I para. 103; S.I. 1998/3178, art. 3

Commencement Information

I21 S. 167 wholly in force; s. 167(1)(2)(3)(6) in force (S.) at 21.10.1991 so far as relating to Pt. II see s. 170(1) and S.I. 1991/2286, art. 2(1), Sch. 1; s. 167(1)(2)(3)(6) in force (E.W.) at 01.11.1991 by S.I. 1991/2288, art. 3, Sch.; s. 167(4)(5) in force (in so far as these subsections relate to the provisions of Pt. IV) at 14.7.1992 by S.I. 1992/1671, art. 2, Sch.; and s. 167(4)(5) in force (so far as they relate to England and Wales) at 14.7.1992 by S.I. 1992/1686, art. 3, Sch.

Marginal Citations

M57 1980 c. 66.

M58 1984 c. 54.

M59 1952 c. 67.

M60 1964 c. 5.

168 Minor and consequential amendments and repeals. U.K.

(1) The enactments specified in Schedule 8 have effect with the amendments specified there which are minor amendments and amendments consequential on the provisions of this Act.

In that Schedule—

• Part I contains amendments of the M61 Highways Act 1980,

• Part II contains amendments of the M62 Road Traffic Regulation Act 1984,

• Part III contains amendments of the M63 Roads (Scotland) Act 1984, and

• Part IV contains amendments of other enactments.

(2) The enactments mentioned in Schedule 9 are repealed to the extent specified there.

Commencement Information

I22 S. 168 partly in force (S.) at 1.11.1991 see s. 170(1) and S.I. 1991/2286, art. 2(2), Sch. 2; s. 168 partly in force (E.W.) at 1.1.1993 see s. 170(1) and S.I. 1992/2984, art. 2(2), Sch. 2; s. 168 partly in force (S.) at 1.1.1993 see s. 170(1) and S.I. 1992/2990, art. 2(2), Sch. 2

Marginal Citations

M61 1980 c. 66.

M62 1984 c. 27.

M63 1984 c. 54.

169 Extent. U.K.

(1) The following provisions of this Act extend to England and Wales—

• Part I (new roads in England and Wales),

• Part III (street works in England and Wales),

• the provisions of Schedule 8 (minor and consequential amendments) and Schedule 9 (repeals) so far as relating to enactments which extend to England and Wales, and

• the other provisions of this Part so far as relating to the above provisions.

(2) The following provisions of this Act extend to Scotland—

• Part II (new roads in Scotland),

• Part IV (road works in Scotland),

• the provisions of Schedule 8 (minor and consequential amendments) and Schedule 9 (repeals) so far as relating to enactments which extend to Scotland, and

• the other provisions of this Part so far as relating to the above provisions.

(3) The following provisions of this Act extend to Northern Ireland—

• the provisions of Schedule 8 (minor and consequential amendments) and Schedule 9 (repeals) so far as relating to enactments which extend to Northern Ireland, and

• the other provisions of this Part so far as relating to the above provisions.

Commencement Information

I23 S. 169 partly in force; s. 169(1) in force at 1.11.1991, see s. 170 and S.I. 1991/2288, art. 3, Sch.

s. 169(2) in force at 14.7.1992, see s. 170(1) and S.I. 1992/1671, art. 2, Sch.

170 Commencement. U.K.

(1) The provisions of this Act come into force on such day as the Secretary of State may appoint by order made by statutory instrument; and different days may be appointed for different provisions and different purposes.

(2) An order bringing into force any provision may contain such transitional provisions and savings as appear to the Secretary of State to be necessary or expedient.

Subordinate Legislation Made

P1 S. 170 power partly exercised: different dates appointed for specified provisions by S.I. 1991/2286

P2 S. 170 power partly exercised: 1.11.1991 appointed by S.I.1991/2288;

S. 170 power partly exercised: 14.7.1992 appointed for specified provisions by S.I. 1992/1671 and by S.I. 1992/1686;

S. 170 power partly exercised: different dates appointed for specified provisions by S.I. 1992/2984 and by S.I. 1992/2990;

S. 170 power partly exercised: 1.5.2003 appointed for specified provisions by {S.I. 2002/3267}

171 Short title. U.K.

This Act may be cited as the New Roads and Street Works Act 1991.