The Rampion Offshore Wind Farm Order 2014

PART 4 E+W+S For the protection of Southern Water Services Limited

Application E+W+S

1.  For the protection of the undertakers referred to in this Part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and the protected undertaking concerned, have effect.

Commencement Information

I1 Sch. 12 Pt. 4 para. 1 in force at 6.8.2014, see art. 1

Interpretation E+W+S

2.  In this Part of this Schedule—

“alternative apparatus” means appropriate alternative apparatus to the satisfaction of the protected undertaker to enable the protected undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means—

(a)

mains, pipes or other apparatus belonging to or maintained by the protected undertaker for the purposes of water supply; and

(b)

any drain or works vested in the protected undertaker under the Water Industry Act 1991; and

(c)

any sewer which is so vested or is the subject of a notice of intention to adopt given by the protected undertaker under section 102(4) of that Act or an agreement to adopt made by the protected undertaker under section 104 of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, across, along, over or upon land; and

“protected undertaker” means Southern Water Services Limited.

Commencement Information

I2 Sch. 12 Pt. 4 para. 2 in force at 6.8.2014, see art. 1

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the protected undertaker are regulated by the provisions of Part 3 of the 1991 Act.

Commencement Information

I3 Sch. 12 Pt. 4 para. 3 in force at 6.8.2014, see art. 1

Acquisition of land E+W+S

4.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker shall not acquire any apparatus otherwise than by agreement.

Commencement Information

I4 Sch. 12 Pt. 4 para. 4 in force at 6.8.2014, see art. 1

Removal of apparatus E+W+S

5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus shall not be removed under this Part of this Schedule and any right of a protected undertaker to maintain that apparatus in that land shall not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the protected undertaker in question.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it shall give to the protected undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a protected undertaker reasonably needs to remove any of its apparatus) the undertaker shall, subject to sub-paragraph (3), afford to the protected undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the protected undertaker in question shall, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use all reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule shall be constructed in such manner and in such line or situation as may be agreed between the protected undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 42 (arbitration).

(5) The protected undertaker in question shall, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 42 (arbitration), and after the grant to the protected undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the protected undertaker that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the protected undertaker, shall be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the protected undertaker.

(7) Nothing in sub-paragraph (6) shall authorise the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Commencement Information

I5 Sch. 12 Pt. 4 para. 5 in force at 6.8.2014, see art. 1

Facilities and rights for alternative apparatus E+W+S

6.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a protected undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights shall be granted upon such terms and conditions as may be agreed between the undertaker and the protected undertaker in question or in default of agreement settled by arbitration in accordance with article 42 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the protected undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator shall make such provision for the payment of compensation by the undertaker to that protected undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I6 Sch. 12 Pt. 4 para. 6 in force at 6.8.2014, see art. 1

Retained apparatus: protection E+W+S

7.—(1) Not less than 28 days before starting the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 5(2), the undertaker shall submit to the protected undertaker a plan, section and description of the works to be executed.

(2) Those works shall be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the protected undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the protected undertaker shall be entitled to watch and inspect the execution of those works.

(3) Any requirements made by a protected undertaker under sub-paragraph (2) shall be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a protected undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 6 shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(5) Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan, section and description.

(6) The undertaker shall not be required to comply with sub-paragraph (1) in a case of emergency but in that case it shall give to the protected undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and shall comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Commencement Information

I7 Sch. 12 Pt. 4 para. 7 in force at 6.8.2014, see art. 1

Expenses E+W+S

8.—(1) Subject to the following provisions of this paragraph, the undertaker shall repay to a protected undertaker the reasonable expenses incurred by that protected undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus (including costs or compensation payable in connection with the acquisition of land for that purpose) which may be required in consequence of the execution of any such works as are referred to in paragraph 5(2).

(2) There shall be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 42 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the protected undertaker in question by virtue of sub-paragraph (1) shall be reduced by the amount of that excess.

(4) An amount which apart from this sub-paragraph would be payable to a protected undertaker in respect of works by virtue of sub-paragraph (1) shall, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the protected undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I8 Sch. 12 Pt. 4 para. 8 in force at 6.8.2014, see art. 1

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a protected undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any protected undertaker, the undertaker shall—

(a) bear and pay the cost reasonably incurred by the protected undertaker in making good such damage or restoring the supply; and

(b) make reasonable compensation to the protected undertaker for any other expenses, loss, damages, penalty or costs incurred by the protected undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) shall impose any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of the protected undertaker, its officers, servants, contractors or agents.

(3) The protected undertaker shall give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made without the consent of the undertaker which, if it withholds such consent, shall have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I9 Sch. 12 Pt. 4 para. 9 in force at 6.8.2014, see art. 1

Enactments and agreements E+W+S

10.  Nothing in this Part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and the protected undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I10 Sch. 12 Pt. 4 para. 10 in force at 6.8.2014, see art. 1