Article 33
SCHEDULE 12PROTECTIVE PROVISIONS
PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS
1. For the protection of the utility undertakers referred to in this part of this Schedule, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned.
2. In this Part—
“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;
“apparatus” means—
(a)
in the case of a utility undertaker within paragraph (a) of the definition of that term, electric lines or electrical plant (as defined in the Electricity Act 1989()), belonging to or maintained by that utility undertaker;
(b)
in the case of a utility undertaker within paragraph (b) of the definition of that term, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;
(c)
in the case of a utility undertaker within paragraph (c) of the definition of that term—
(i)
mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and
(ii)
any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991();
(d)
in the case of a utility undertaker within paragraph (d) of the definition of that term—
(i)
any drain or works vested in the utility undertaker under the Water Industry Act 1991; and
(ii)
any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,
and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;
“functions” includes powers and duties;
“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and
“utility undertaker” means—
(a)
any licence holder within the meaning of Part 1 of the Electricity Act 1989;
(b)
a gas transporter within the meaning of Part 1 of the Gas Act 1986();
(c)
water undertaker within the meaning of the Water Industry Act 1991; and
(d)
a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,
for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.
3. This Part does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act.
4. Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary stopping up of streets, public rights of way and public rights of navigation), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.
5. Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not—
(a)where the utility undertaker is NGG or NGET, acquire any land interest or apparatus or override any easement and/or other interest otherwise than by agreement; or
(b)in the case of any other utility undertaker, acquire any apparatus otherwise than by agreement.
6.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).
(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.
(4) Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 41 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part.
(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.
(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.
7.—(1) Where, in accordance with the provisions of this Part, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
8.—(1) Not less than twenty-eight days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.
(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.
(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of twenty-one days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.
(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 6(2).
(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than twenty-eight days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.
(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.
9.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2).
(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part, that value being calculated after removal.
(3) If in accordance with the provisions of this Part—
(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 41 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.
(4) For the purposes of sub-paragraph (3)—
(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 6(2); and
(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.
(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.
10.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 6(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—
(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and
(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,
by reason or in consequence of any such damage or interruption.
(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.
(3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
11. Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS
12.—(1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.
(2) In this Part—
“the 2003 Act” means the Communications Act 2003();
“electronic communications apparatus” has the same meaning as set out in paragraph 5 of the electronic communications code;
“the electronic communications code” has the same meaning as set out in sections 106 to 119 and Schedule 3A of the 2003 Act();
“infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7 of that code;
“network” means—
(a)
so much of a network or infrastructure system provided by an operator as is not excluded from the application of the electronic communications code by a direction under section 106(5) of the 2003 Act; and
(b)
a network which the Secretary of State is providing or proposing to provide;
“operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act and who is an operator of a network;
13. The exercise of the powers of article 28 (statutory undertakers) is subject to Part 10 of Schedule 3A of the 2003 Act.
14.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—
(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or
(b)there is any interruption in the supply of the service provided by an operator,
the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.
(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.
(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
(4) Any difference arising between the undertaker and the operator under this part of this Schedule must be referred to and settled by arbitration under article 41 (arbitration).
15. This part of this Schedule does not apply to—
(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act; or
(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.
16. Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 3FOR THE PROTECTION OF CANAL AND RIVER TRUST
Interpretation
17.—(1) For the protection of CRT the following provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and CRT.
(2) In this Part of this Schedule—
“Code of Practice” means the Code of Practice for Works Affecting the Canal and River Trust (April 2018) or any updates or amendments thereto;
“construction”, in relation to any specified work or protective work, includes—
(a)
the execution and placing of that work; and
(b)
any relaying, renewal, or maintenance of that work as may be carried out during the period of 24 months from the completion of that work; and “construct” and “constructed” have corresponding meanings;
“CRT” means the Canal & River Trust;
“CRT’s network” means CRT’s network of waterways;
“detriment” means any damage to the waterway or any other property of CRT caused by the presence of the authorised development and, without prejudice to the generality of that meaning, includes—
(a)
any obstruction of, or interference with, or hindrance or danger to, navigation or to any use of the waterway (including towing paths);
(b)
the erosion of the bed or banks of the waterway, or the impairment of the stability of any works, lands or premises forming part of the waterway;
(c)
the deposit of materials or the siltation of the waterway so as to damage the waterway;
(d)
the pollution of the waterway;
(e)
any significant alteration in the water level of the waterway, or significant interference with the supply of water thereto, or drainage of water therefrom;
(f)
any harm to the ecology of the waterway (including any adverse impact on any site of special scientific interest comprised in CRT’s network);
(g)
any interference with the exercise by any person of rights over CRT’s network;
“the engineer” means an engineer appointed by CRT for the purpose in question;
“plans” includes sections, designs, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction) and programmes;
“practical completion” means practical completion of all of the specified work notwithstanding that items which would ordinarily be considered snagging items remain outstanding, and the expression “practically complete” and “practically completed” is to be construed accordingly;
“protective work” means a work constructed under paragraph 21(3)(a);
“specified work” means so much of Work No 4 as is situated upon, across, under, over or within 15 metres of, or may in any way affect the waterway;
“the waterway” means the Aire & Calder Navigation, and includes any works, lands or premises belonging to CRT, or under its management or control, and held or used by CRT in connection with that navigation.
(3) Where the Code of Practice applies to any works or matter that are part of the authorised development or that form part of the protective works and there is an inconsistency between these protective provisions and the Code of Practice, the part of the Code of Practice that is inconsistent with these protective provisions will not apply and these protective provisions will apply.
Powers requiring CRT’s consent
18.—(1) The undertaker must not in the exercise of the powers conferred by this Order obstruct or interfere with pedestrian or vehicular access to the waterway unless such obstruction or interference with such access is with the consent of CRT.
(2) The undertaker must not exercise any power conferred by this Order to discharge water into the waterway under article 14 (discharge of water) or in any way interfere with the supply of water to or the drainage of water from the waterway unless such exercise is with the consent of CRT, save as to surface water discharge which will not require the consent of CRT.
(3) The undertaker must not exercise the powers conferred by article 15 (authority to survey and investigate land) or section 11(3) of the 1965 Act, in relation to the waterway unless such exercise is with the consent of CRT.
(4) The undertaker must not exercise the powers conferred by this Order to temporarily stop up streets or public rights of way under article 11 (temporary stopping up of streets, public rights of way and public rights of navigation), as applied by Schedule 6 (streets to be temporarily stopped up), Part 1 of Schedule 7 (public rights of way to be temporarily stopped up) and Part 2 of Schedule 7 (public rights of navigation to be temporarily suspended) so as to divert any right of access to or any right of navigation along the waterway but such right of access may be diverted with the consent of CRT.
(5) The undertaker must not exercise the powers conferred by this Order to abstract water from the waterway if either—
(a)that abstraction substantially deviates (which for the purpose of this paragraph 18 means a deviation in angle greater than 20°) as compared to the angle of abstraction at 30 May 2017; or
(b)the rate of abstraction increases beyond the licensed levels for the existing coal-fired power station as at 30 May 2017
unless such abstraction is with the consent of CRT.
(6) The consent of CRT pursuant to sub-paragraphs (1) to (4) must not be unreasonably withheld or delayed but may be given subject to reasonable terms and conditions which in the case of article 14 (discharge of water) may include conditions—
(a)specifying the maximum volume water which may be discharged in any period; and
(b)authorising CRT on giving reasonable notice (except in an emergency, when CRT may require immediate suspension) to the undertaker to require the undertaker to suspend the discharge of water or reduce the flow of water where this is necessary by reason of any operational or environmental requirement of CRT, to the extent that any discharge of water by the undertaker is into the waterway.
(7) The consent of CRT pursuant to sub-paragraph (5) must not be unreasonably withheld or delayed but may be given subject to reasonable terms and conditions including specifying the maximum velocity of the flow of water which may be abstracted at right angles to the waterway at any time.
Fencing
19. Where so required by the engineer the undertaker must to the reasonable satisfaction of the engineer fence off a specified work or a protective work or take such other steps as the engineer may require to be taken for the purpose of separating a specified work or a protective work from the waterway, whether on a temporary or permanent basis or both.
Survey of waterway
20.—(1) Before the commencement of the initial construction of any part of the specified works and again following practical completion of the specified works the undertaker must bear the reasonable and proper cost of the carrying out by a qualified engineer (the “surveyor”), to be approved by CRT and the undertaker, of a survey including a dip-survey to measure the depth of the waterway (“the survey”) of so much of the waterway and of any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works.
(2) For the purposes of the survey the undertaker must—
(a)on being given reasonable notice (save in case of emergency, when immediate access must be afforded) afford reasonable facilities to the surveyor for access to the site of the specified works and to any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works; and
(b)supply the surveyor as soon as reasonably practicable with all such information as he may reasonably require and which the undertaker holds with regard to such existing works of the undertaker and to the specified works or the method of their construction.
(3) The reasonable costs of the survey must include the costs of any dewatering or reduction of the water level of any part of the waterway (where reasonably required) which may be effected to facilitate the carrying out of the survey and the provisions of this Part will apply with all necessary modifications to any such dewatering or reduction in the water level as though the same were specified works.
(4) Copies of the survey must be provided to both CRT and the undertaker at no cost to CRT.
Approval of plans, protective works etc.
21.—(1) The undertaker must before commencing construction of any specified work including any temporary works supply to CRT proper and sufficient plans of that work, on CRT forms, and such further particulars available to it as CRT may within 14 days of the submission of the plans reasonably require for the approval of the engineer and must not commence such construction of a specified work until plans of that work have been approved in writing by the engineer or settled by arbitration.
(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and if within 35 days after such plans (including any other particulars reasonably required under sub-paragraph (1)) have been received by CRT the engineer has not intimated his disapproval of those plans and the grounds of his disapproval he is deemed to have approved the plans as submitted.
(3) When signifying approval of the plans the engineer may specify on land held or controlled by CRT or the undertaker and subject to such works being authorised by the order or being development permitted by an Act of Parliament or general development order made under the 1990 Act—
(a)any protective work (whether temporary or permanent) which in the reasonable opinion of the engineer should be carried out before the commencement of a specified work to prevent detriment; and
(b)such other requirements as may be reasonably necessary to prevent detriment; and such protective works must be constructed by the undertaker or by CRT at the undertaker’s request with all reasonable dispatch and the undertaker must not commence the construction of a specified work until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction such consent not to be unreasonably withheld or delayed.
(4) The undertaker must pay to CRT a capitalised sum representing the reasonably increased or additional cost of maintaining and, when necessary, renewing any works, including any permanent protective works provided under sub-paragraph (3) above, and of carrying out any additional dredging of the waterway reasonably necessitated by the exercise of any of the powers under this Order but if the cost of maintaining the waterway, or of works of renewal of the waterway, is reduced in consequence of any such works, a capitalised sum representing such reasonable saving is to be set off against any sum payable by the undertaker to CRT under this paragraph.
(5) In the event that the undertaker fails to complete the construction of, or part of, the specified works CRT may, if it is reasonably required in order to avoid detriment, serve on the undertaker a notice in writing requesting that construction be completed. Any notice served under this subparagraph must state the works that are to be completed by the undertaker and lay out a reasonable timetable for the works’ completion. If the undertaker fails to comply with this notice within 35 days, CRT may construct any of the specified works, or part of such works, (together with any adjoining works) in order to complete the construction of, or part of, the specified works or make such works and the undertaker must reimburse CRT all costs, fees, charges and expenses it has reasonably incurred in carrying out such works.
Design of works
22.—(1) Without prejudice to its obligations under the foregoing provisions of this Part of this Schedule the undertaker must consult, collaborate and respond constructively to any reasonable approach, suggestion, proposal or initiative made by CRT on—
(a)the design and appearance of the specified works, including the materials to be used for their construction; and
(b)the environmental effects of those works; and must have regard to such views as may be expressed by CRT to the extent that these accord with the requirements of the local planning authority in response to such consultation pursuant in particular to the requirements imposed on CRT by section 22 (general environmental and recreational duties) of the British Waterways Act 1995() and to the interest of CRT in preserving and enhancing the environment of its waterways.
Notice of works
23. The undertaker must give to the engineer 30 days’ notice of its intention to commence the construction of any of the specified or protective works, or, in the case of repair carried out in an emergency, such notice as may be reasonably practicable so that, in particular, CRT may where appropriate arrange for the publication of notices bringing those works to the attention of users of CRT’s network.
Lighting
24. The undertaker must provide and maintain at its own expense in the vicinity of the specified or protective works such temporary lighting and such signal lights for the control of navigation as the engineer may reasonably require during the construction or failure of the specified or protective works.
Construction of specified works
25.—(1) Any specified or protective works must, when commenced, be constructed—
(a)with all reasonable dispatch in accordance with the plans approved or deemed to have been approved or settled as aforesaid and with any specifications made under paragraph 21 and paragraph 22 of this Part;
(b)under the supervision (if given) and to the reasonable satisfaction of the engineer;
(c)in such manner as to cause as little detriment as is reasonably practicable;
(d)in such manner as to cause as little inconvenience as is reasonably practicable to CRT, its officers and agents and all other persons lawfully using the waterways, except to the extent that temporary obstruction has otherwise been agreed by CRT; and
(e)in such a manner so as to ensure that no materials are discharged or deposited into the waterway otherwise than in accordance with article 14 (discharge of water).
(2) Nothing in this Order authorises the undertaker to make or maintain any permanent works in or over the waterway so as to impede or prevent (whether by reducing the width of the waterway or otherwise) the passage of any vessel which is of a kind (as to its dimensions) for which CRT is required by section 105(1)(b) and (2) of the Transport Act 1968() to maintain the waterway.
(3) Following the completion of the construction of the specified works the undertaker must restore the waterway to a condition no less satisfactory than its condition immediately prior to the commencement of those works unless otherwise agreed between the undertaker and CRT.
(4) In assessing whether the condition of the waterway is no less satisfactory than immediately prior to the works pursuant to sub-paragraph (3), CRT and the undertaker must take account of any survey issued pursuant to paragraph 20 and any other information agreed between them pursuant to this Part 3.
Prevention of pollution
26. The undertaker must not in the course of constructing a specified work or a protective work or otherwise in connection therewith do or permit anything which may result in the pollution of the waterway or the deposit of materials therein and must take such steps as the engineer may reasonably require to avoid or make good any breach of its obligations under this paragraph.
Access to work – provision of information
27.—(1) The undertaker on being given reasonable notice must—
(a)at all reasonable times allow reasonable facilities to the engineer for access to a specified work during its construction; and
(b)supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.
(2) CRT on being given reasonable notice must—
(a)at all reasonable times afford reasonable facilities to the undertaker and its agents for access to any works carried out by CRT under this Part during their construction; and
(b)supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them and the undertaker must reimburse CRT’s reasonable costs in relation to the supply of such information.
Alterations to the waterway
28.—(1) If during the construction of a specified work or a protective work or during a period of twenty four (24) months after the completion of those works any alterations or additions, either permanent or temporary, to the waterway are reasonably necessary in consequence of the construction of the specified work or the protective work in order to avoid detriment, and CRT gives to the undertaker reasonable notice of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to CRT the reasonable costs of those alterations or additions including, in respect of any such alterations or additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by CRT in maintaining, working and, when necessary, renewing any such alterations or additions.
(2) If the cost of maintaining, working or renewing the waterway is reduced in consequence of any such alterations or additions a capitalised sum representing such saving is to be set off against any sum payable by the undertaker to CRT under this paragraph.
Maintenance of works
29. If at any time after the completion of a specified work or a protective work, not being a work vested in CRT, CRT gives notice to the undertaker informing it that it reasonably considers that the state of maintenance of the work appears to be such that the work is causing or likely to cause detriment, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put the work in such state of maintenance as not to cause such detriment.
Repayment of CRT’s fees, etc.
30.—(1) The undertaker must repay to CRT in accordance with the Code of Practice all fees, costs, charges and expenses reasonably incurred by CRT—
(a)in constructing any protective works under the provisions of paragraph 21(3)(a);
(b)in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction or repair of a specified work and any protective works;
(c)in respect of the employment during the construction of the specified works or any protective works of any inspectors, watchmen and other persons whom it is reasonably necessary to appoint for inspecting, watching and lighting any waterway and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of the specified works or any protective works; and
(d)in bringing the specified works or any protective works to the notice of users of CRT’s network.
(e)in constructing and/or carrying out any measures related to any specified works or protective works which are reasonably required by CRT to ensure the safe navigation of the waterway save that nothing is to require CRT to construct and/or carry out any measures.
(2) If CRT considers that a fee, charge, cost or expense will be payable by the undertaker pursuant to sub-paragraph (1), CRT will first provide an estimate of that fee, charge, cost or expense and supporting information in relation to the estimate to the undertaker along with a proposed timescale for payment for consideration and the undertaker may, within a period of twenty-one days—
(a)provide confirmation to CRT that the estimate is agreed and pay to CRT, by the date stipulated, that fee, charge, cost or expense; or
(b)provide confirmation to CRT that the estimate is not accepted along with a revised estimate and a proposal as to how or why the undertaker considers that the estimate can be reduced and or paid at a later date.
(3) CRT must take in to account any representations made by the undertaker in accordance with this paragraph 30 and must, within twenty-one days of receipt of the information pursuant to sub-paragraph (1), confirm the amount of the fee, charge, cost or expense to be paid by the undertaker (if any) and the date by which this is to be paid.
(4) CRT must, when estimating and incurring any charge, cost or expense pursuant this paragraph 30, do so with a view to being reasonably economic and acting as if CRT were itself to fund the relevant fee, charge, cost or expense.
Costs of alterations, etc.
31. Any additional expenses which CRT may reasonably incur in altering, reconstructing or maintaining the waterway under any powers existing at the date when this Order was made by reason of the existence of a specified work must, provided that 56 days’ notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to CRT.
Making good of detriment; compensation and indemnity, etc.
32.—(1) If any detriment is be caused by the construction or failure of the specified works or the protective works if carried out by the undertaker, the undertaker (if so required by CRT) must make good such detriment and must pay to CRT all reasonable expenses to which CRT may be put, and compensation for any loss which CRT may sustain, in making good or otherwise by reason of the detriment.
(2) The undertaker must be responsible for and make good to CRT all costs, charges, damages, expenses and losses not otherwise provided for in this Part which may be occasioned to and reasonably incurred by CRT—
(a)by reason of the construction of a specified work or a protective work or the failure of such a work; or
(b)by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon the construction of a specified work or protective work; and subject to sub-paragraph (4) the undertaker must effectively indemnify and hold harmless CRT from and against all claims and demands arising out of or in connection with any of the matters referred to in paragraphs (a) and (b) (provided that CRT is not entitled to recover any consequential losses which are not reasonably foreseeable from the undertaker).
(3) The fact that any act or thing may have been done by CRT on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision or in accordance with any directions or awards of an arbitrator is not to (if it was done without negligence on the part of CRT or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this paragraph.
(4) Nothing in sub-paragraph (2) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the neglect or wilful default of CRT, its officers, servants, contractors or agents.
(5) CRT must give the undertaker reasonable notice of any such claim or demand as aforesaid and no settlement or compromise of such a claim or demand is to be made without the prior consent of the undertaker.
Arbitration
33. Any difference arising between the undertaker and CRT under this Part (other than a difference as to the meaning or construction of this Part) must be referred to and settled by arbitration in accordance with article 41 (arbitration) of this Order.
Capitalised sums
34. Any capitalised sum which is required to be paid under this Part must be calculated by multiplying the cost of the maintenance or renewal works to the waterway necessitated as a result of the operation of the authorised development by the number of times that the maintenance or renewal works will be required during the operation of the authorised development.