Approval of plans, protective works etc.E+W
21.—(1) The undertaker must before commencing construction of any specified work including any temporary works supply to CRT proper and sufficient plans of that work, on CRT forms, and such further particulars available to it as CRT may within 14 days of the submission of the plans reasonably require for the approval of the engineer and must not commence such construction of a specified work until plans of that work have been approved in writing by the engineer or settled by arbitration.
(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and if within 35 days after such plans (including any other particulars reasonably required under sub-paragraph (1)) have been received by CRT the engineer has not intimated his disapproval of those plans and the grounds of his disapproval he is deemed to have approved the plans as submitted.
(3) When signifying approval of the plans the engineer may specify on land held or controlled by CRT or the undertaker and subject to such works being authorised by the order or being development permitted by an Act of Parliament or general development order made under the 1990 Act—
(a)any protective work (whether temporary or permanent) which in the reasonable opinion of the engineer should be carried out before the commencement of a specified work to prevent detriment; and
(b)such other requirements as may be reasonably necessary to prevent detriment; and such protective works must be constructed by the undertaker or by CRT at the undertaker's request with all reasonable dispatch and the undertaker must not commence the construction of a specified work until the engineer has notified the undertaker that the protective works have been completed to the engineer's reasonable satisfaction such consent not to be unreasonably withheld or delayed.
(4) The undertaker must pay to CRT a capitalised sum representing the reasonably increased or additional cost of maintaining and, when necessary, renewing any works, including any permanent protective works provided under sub-paragraph (3) above, and of carrying out any additional dredging of the waterway reasonably necessitated by the exercise of any of the powers under this Order but if the cost of maintaining the waterway, or of works of renewal of the waterway, is reduced in consequence of any such works, a capitalised sum representing such reasonable saving is to be set off against any sum payable by the undertaker to CRT under this paragraph.
(5) In the event that the undertaker fails to complete the construction of, or part of, the specified works CRT may, if it is reasonably required in order to avoid detriment, serve on the undertaker a notice in writing requesting that construction be completed. Any notice served under this subparagraph must state the works that are to be completed by the undertaker and lay out a reasonable timetable for the works' completion. If the undertaker fails to comply with this notice within 35 days, CRT may construct any of the specified works, or part of such works, (together with any adjoining works) in order to complete the construction of, or part of, the specified works or make such works and the undertaker must reimburse CRT all costs, fees, charges and expenses it has reasonably incurred in carrying out such works.