SCHEDULE 10PROTECTIVE PROVISIONS
PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS
I11
For the protection of the utility undertakers referred to in this part of this Schedule (save for National Grid Electricity and National Grid Gas which are protected by Part 3 of this Schedule, EPN which is protected by Part 4 of this Schedule, Anglian Water which is protected by Part 5 of this Schedule and Covanta which is protected by Part 7 of this Schedule), the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned.
I22
In this part of this Schedule—
“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;
“apparatus” means—
- a
in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989 M1), belonging to or maintained by that utility undertaker;
- b
in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;
- c
in the case of a water undertaker—
- i
mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and
- ii
any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A (agreements to adopt water main or service pipe at future date) of the Water Industry Act 1991 M2);
- i
- d
in the case of a sewerage undertaker—
- i
any drain or works vested in the utility undertaker under the Water Industry Act 1991; and
- ii
any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of that Act M3 or an agreement to adopt made under section 104 of that Act,
and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;
- i
- a
“functions” includes powers and duties;
“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and
“utility undertaker” means—
- e
any licence holder within the meaning of Part 1 (electricity supply) of the Electricity Act 1989;
- f
a gas transporter within the meaning of Part 1 (gas supply) of the Gas Act 1986 M4;
- g
a water undertaker within the meaning of the Water Industry Act 1991; and
- h
a sewerage undertaker within the meaning of Part 1 (preliminary) of the Water Industry Act 1991,
- e
for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.
I33
This part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.
I44
Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary prohibition or restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.
I55
Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.
I66
1
If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker's apparatus is relocated or diverted, that apparatus must not be removed under this part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).
2
If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
3
If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.
4
Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
5
The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 41 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this part of this Schedule.
6
Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.
7
Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.
I77
1
Where, in accordance with the provisions of this part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
2
If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
I88
1
Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph (3), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.
2
Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.
3
Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.
4
If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 7 apply as if the removal of the apparatus had been required by the undertaker under paragraph 6(2).
5
Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.
6
The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.
I99
1
Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 6(2).
2
There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this part of this Schedule, that value being calculated after removal.
3
If in accordance with the provisions of this part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 41 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 6(2); and
b
where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.
5
An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1) if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.
I1010
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 6(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—
a
bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and
b
make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,
by reason or in consequence of any such damage or interruption.
2
Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.
3
A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
I1111
Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS
I1212
1
For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.
2
In this part of this Schedule—
“the 2003 Act” means the Communications Act 2003 M5;
“electronic communications apparatus” has the same meaning as set out in paragraph 5 (electronic communications apparatus, lines and structures) of the electronic communications code;
“the electronic communications code” has the same meaning as set out in sections 106 to 119 (electronic communications code) and Schedule 3A (the electronic communications code) of the 2003 Act M6;
“infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7 (infrastructure system) of that code;
“network” means—
- a
so much of a network or infrastructure system provided by an operator as is not excluded from the application of the electronic communications code by a direction under section 106(5) (application of the electronic communications code) of the 2003 Act; and
- b
a network which the Secretary of State is providing or proposing to provide;
- a
“operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act and who is an operator of a network.
I1313
The exercise of the powers of article 29 (statutory undertakers) is subject to Part 10 (undertaker's works affecting electronic communications apparatus) of Schedule 3A of the 2003 Act.
I1414
1
Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—
a
any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or
b
there is any interruption in the supply of the service provided by an operator,
the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.
2
Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.
3
The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
4
Any difference arising between the undertaker and the operator under this part of this Schedule must be referred to and settled by arbitration under article 41 (arbitration).
I1515
This part of this Schedule does not apply to—
a
any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or
b
any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.
I1616
Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 3FOR THE PROTECTION OF NATIONAL GRID
ApplicationI1717
For the protection of National Grid as referred to in this part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and National Grid, have effect.
InterpretationI1818
In this Part of this Schedule—
“alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means
- a
electric lines or electrical plant as defined in the Electricity Act 1989 M7, belonging to or maintained by National Grid;
- b
mains, pipes or other apparatus belonging to or maintained by National Grid for the purposes of gas supply;
- a
“authorised development” has the same meaning as in article 2 (interpretation) of this Order and (unless otherwise specified) for the purposes of this Schedule shall include the use and maintenance of the authorised development;
“functions” includes powers and duties;
“ground mitigation scheme” means a scheme approved by National Grid (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;
“ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, shall require the promoter to submit for the undertaker's approval a ground mitigation scheme;
“ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;
“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;
“National Grid” means either—
- a
National Grid Electricity Transmission PLC (Company No. 2366977) whose registered office is at 1-3 Strand, London, WC2N 5EH; or
- b
National Grid Gas PLC (Company No. 200600) whose registered office is at 1-3 Strand, London, WC2N 5EH,
as the context shall require.
- a
I1919
Except for paragraphs (20) (apparatus in streets subject to temporary prohibition or restriction), (24) (retained apparatus: protection of National Grid as Gas Undertaker), (25) (retained apparatus: protection of National Grid as Electricity Undertaker), (26) (expenses) and (27) (indemnity) this Schedule does not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.
Apparatus of National Grid in streets subject to temporary prohibition or restrictionI2020
1
Without prejudice to the generality of any other protection afforded to National Grid elsewhere in the Order, where any street is stopped up under article 12 (stopping up of streets), if National Grid has any apparatus in the street or accessed via that street National Grid will be entitled to the same rights in respect of such apparatus as it enjoyed immediately before the stopping up and the promoter will grant to National Grid, or will procure the granting to the National Grid of, legal easements reasonably satisfactory to the specified undertaker in respect of such apparatus and access to it prior to the stopping up of any such street or highway.
2
Notwithstanding the temporary prohibition or restriction under the powers of article 11 (temporary prohibition or restriction of use of streets), National Grid shall be at liberty at all times to take all necessary access across any such street and/or to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.
Acquisition of landI2121
1
Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order the undertaker must not acquire any land interest or apparatus or override any easement or other interest of National Grid otherwise than by agreement (such agreement not to be unreasonably withheld).
2
The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Schedule relating to the relocation and/or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid as of right or other use in relation to the apparatus then the provisions in this Schedule shall prevail.
3
Any agreement or consent granted by National Grid under paragraph 24 (retained apparatus: protection of National Grid as Gas Undertaker) or any other paragraph of this Part of this Schedule, shall not be taken to constitute agreement under sub-paragraph 21(1).
Removal of apparatusI2222
1
If, in the exercise of the agreement reached in accordance with paragraph 21 or in any other authorised manner, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this part of this Schedule and any right of National Grid to maintain that apparatus in that land shall not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (2) to (5) inclusive.
2
If, for the purpose of executing any works comprised in the authorised development in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid 56 days' advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker shall, subject to sub-paragraph (3), afford to National Grid to their satisfaction (taking into account paragraph 23(1) below) the necessary facilities and rights for—
a
the construction of alternative apparatus in other land of the undertaker; and
b
subsequently for the maintenance of that apparatus.
3
If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.
4
Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule shall be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.
5
National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this part of this Schedule.
Facilities and rights for alternative apparatusI2323
1
Where, in accordance with the provisions of this part of this Schedule, the undertaker affords to National Grid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights shall be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless agreed by National Grid.
2
If the facilities and rights to be afforded by the undertaker and agreed with National Grid under sub-paragraph (1) above in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject in the matter shall be referred to arbitration under paragraph 31 and, the arbitrator shall make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. In respect of the appointment of an arbitrator under this sub-paragraph (2), article 41 (arbitration) of the Order shall apply.
Retained apparatus: protection of National Grid as Gas UndertakerI2424
1
Not less than 56 days before the commencement of any authorised development authorised by this Order that involves activities or works specified in National Grid's “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” that are within the proximities described therein to any apparatus the removal of which has not been required by the undertaker under paragraph 22(2) or otherwise, the undertaker must submit to National Grid a plan.
2
In relation to works which will be situated on, over, under or within 15 metres measured in any direction of any apparatus to which sub-paragraph (1) applies, or (wherever situated) impose any load directly upon any such apparatus or involve embankment works within 15 metres of any such apparatus, the plan to be submitted to National Grid under sub-paragraph (1) shall show—
a
the exact position of the works;
b
the level at which these are proposed to be constructed or renewed;
c
the manner of their construction or renewal including details of excavation, positioning of plant etc.;
d
the position of all apparatus;
e
by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;
f
intended maintenance regimes; and
g
details of any ground monitoring scheme (if required in accordance with National Grid's “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22”.)
3
The undertaker must not commence any works to which sub-paragraph (1) and (2) applies until National Grid has given written approval of the plan so submitted.
4
Any approval of National Grid required under sub-paragraph (3)—
a
may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (5) or (7);
b
must not be unreasonably withheld.
5
In relation to a work to which sub-paragraphs (1) and (2) applies, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its system against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.
6
Works executed under sub-paragraphs (1) or (2) shall be executed only in accordance with the plan, submitted under sub-paragraph (1) and (2) or as relevant sub paragraph (4), as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5), (7) and/or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid shall be entitled to watch and inspect the execution of those works.
7
Where National Grid requires protective works to be carried out either themselves or by the undertaker (whether of a temporary or permanent nature) such protective works shall be carried out to National Grid's satisfaction prior to the commencement of any authorised development (or any relevant part thereof) to which sub-paragraph (1) applies and National Grid must give 56 days' notice of such works from the date of submission of a plan in line with sub-paragraph (1) or (2) (except in an emergency).
8
If National Grid in accordance with sub-paragraph (5) or (7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs (17) to (19) and (22) to (23) shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 22(2).
9
Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of any works comprising the authorised development, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.
10
The undertaker shall not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and shall—
a
comply with sub-paragraph (5), (6) and (7) insofar as is reasonably practicable in the circumstances; and
b
comply with sub-paragraph (11) at all times.
11
At all times when carrying out any works authorised under the Order comply with National Grid's policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” and the Health and Safety Executive's “HS(~G)47 Avoiding Danger from underground services”.
12
As soon as reasonably practicable after any ground subsidence event attributable to the authorised development the undertaker shall implement an appropriate ground mitigation scheme save that National Grid retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 26.
13
The plans submitted to National Grid by the undertaker pursuant to paragraph 24(1) and/or paragraph 25(1) must be sent to Spencer Jefferies at spencer.jeffries@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing.
Retained apparatus: protection of National Grid as Electricity UndertakerI2525
1
Not less than 56 days before the commencement of any authorised development under this Order that is near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 22(2) or otherwise and to which sub-paragraph (2)(i) or (2)(ii) applies, the undertaker must submit to National Grid a plan and seek from National Grid details of the underground extent of their electricity tower foundations.
2
In relation to works which will or may be situated on, over, under or within (i) 15 metres measured in any direction of any apparatus, or (ii) involve embankment works within 15 metres of any apparatus, the plan to be submitted under sub-paragraph (1) shall show—
a
the exact position of the works;
b
the level at which these are proposed to be constructed or renewed;
c
the manner of their construction or renewal including details of excavation, positioning of plant;
d
the position of all apparatus;
e
by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;
f
any intended maintenance regimes; and
g
an assessment of risks of rise of earth issues.
3
In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) shall be detailed including a method statement and describing in addition to the matters set out in sub-paragraph (2)—
a
details of any cable trench design including route, dimensions, clearance to pylon foundations;
b
demonstration that pylon foundations will not be affected prior to, during and post construction;
c
details of load bearing capacities of trenches;
d
details of cable installation methodology including access arrangements, jointing bays and backfill methodology;
e
a written management plan for high voltage hazard during construction and on-going maintenance of the cable route;
f
(written details of the operations and maintenance regime for the cable, including frequency and method of access;
g
assessment of earth rise potential if reasonably required by National Grid's engineers;
h
evidence that trench bearing capacity is to be designed to 26 tonnes to take the weight of overhead line construction traffic.
4
The undertaker must not commence any works to which sub-paragraphs (1), (2) or (3) apply until National Grid has given written approval of the plan so submitted.
5
Any approval of National Grid required under sub-paragraph (1), (2) or (3)—
a
may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (6) or (8);
b
must not be unreasonably withheld.
6
In relation to a work to which sub-paragraphs (1), (2) or (3) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its system against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.
7
Works executed under sub-paragraphs (1), (2) or (3) must be executed only in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraphs (2), (3) or (6), as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5), (6), (8) and/or (9) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid shall be entitled to watch and inspect the execution of those works.
8
Where National Grid require any protective works to be carried out either themselves or by the undertaker (whether of a temporary or permanent nature) such protective works must be carried out to National Grid's satisfaction prior to the commencement of any authorised development (or any relevant part thereof) to which sub-paragraph (1) applies and National Grid must give 56 days' notice of such works from the date of submission of a plan in line with sub-paragraphs (1), (2), (3) or (6) (except in an emergency)
9
If National Grid in accordance with sub-paragraph (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs (17) to (19) and (22) to (23) shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 22(2).
10
Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of any works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.
11
The undertaker shall not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and shall—
a
comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances; and
b
comply with sub-paragraph (12) at all times.
12
At all times when carrying out any works authorised under the Order, the undertaker must comply with National Grid's policies for development near over headlines ENA TA 43-8 and the Health and Safety Executive's guidance note 6 “Avoidance of Danger from Overhead Lines”.
13
This paragraph shall not apply to numbered work 7.
ExpensesI2626
1
Subject to the following provisions of this paragraph, the undertaker shall pay to National Grid on demand all charges, costs and expenses reasonably anticipated or incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new apparatus or alternative apparatus which may be required in consequence of the execution of any such works as are referred to in this Schedule including without limitation—
a
any costs reasonably incurred or compensation properly paid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that National Grid elects to use compulsory purchase powers to acquire any necessary rights under paragraph 22(3) all costs incurred as a result of such action;
b
in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;
c
the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;
d
the approval of plans;
e
the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;
f
the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Schedule.
2
There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.
3
If in accordance with the provisions of this part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or in default of agreement settled by arbitration in accordance with article 41 (arbitration) of the Order to be necessary, then, if such placing involves cost in the construction of works under this part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) shall be reduced by the amount of that excess save where it is not possible in the circumstances to obtain the existing type of operations, capacity, dimensions or place at the existing depth in which case full costs shall be borne by the undertaker.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus shall not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
b
where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole shall be treated as if it also had been agreed or had been so determined.
5
An amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) shall, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.
IndemnityI2727
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works (including without limitation works carried out by the undertaker under this Schedule or any subsidence resulting from any of these works), any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker shall—
a
bear and pay on demand the cost reasonably incurred by National Grid in making good such damage or restoring the supply; and
b
indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid.
2
The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid as a consequence of the authorised development or under its supervision shall not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of this sub-paragraph (1) where the undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not materially accord with the approved plan or as otherwise agreed between the undertaker and National Grid.
3
Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of—
a
any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents; and
b
any authorised development and/or any other works authorised by this Schedule carried out by National Grid as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 (benefit of order grating development consent) of the 2008 Act or under article 6 of the Order subject to the proviso that once such works become apparatus (“new apparatus”), any works yet to be executed and not falling within this sub-section 3(b) shall be subject to the full terms of this Schedule including this paragraph (27) in respect of such new apparatus.
4
National Grid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made, unless payment is required in connection with a statutory compensation scheme without first consulting the undertaker and considering their representations.
5
National Grid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph (27) applies. If requested to do so by the undertaker, National Grid shall provide an explanation of how the claim has been minimised. The undertaker shall only be liable under this paragraph (27) for claims reasonably incurred by National Grid.
Enactments and agreementsI2828
Nothing in this part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
Co-operationI2929
National Grid and the undertaker must each use their best endeavours to co-ordinate with the other party on the timing and method of execution of any works carried out under the Order or this Schedule (including, for the avoidance of doubt, pursuant to paragraph 22(2) and paragraphs (24) or (28)) in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the other party's operations.
AccessI3030
If in consequence of the agreement reached in accordance with paragraph 21(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.
ArbitrationI3131
Save for differences or disputes arising under paragraphs 22(2), 22(4), 23(1), 24 and 25 any difference or dispute arising between the undertaker and National Grid under this Schedule shall, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 41 (arbitration) of the Order.
PART 4FOR THE PROTECTION OF EPN
I3232
For the protection of EPN as referred to in this part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and EPN.
I3333
In this part of this Schedule—
“alternative apparatus” means alternative apparatus adequate to enable EPN to fulfil its statutory functions in a manner not less efficient than previously;
“apparatus” means electric lines or electrical plant (as defined in the Electricity Act 1989 M8), belonging to or maintained by EPN;
“functions” includes powers and duties;
“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and
“EPN” means Eastern Power Networks plc (Company No. 02366906) whose registered office is at Newington House, 237 Southwark Bridge Road, London SE1 6NP;
I3434
This part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and EPN are regulated by the provisions of Part 3 of the 1991 Act.
I3535
Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary prohibition or restriction of use of streets), EPN is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.
I3636
Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.
I3737
1
If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that EPN's apparatus is relocated or diverted, that apparatus must not be removed under this part of this Schedule, and any right of EPN to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of EPN in accordance with sub-paragraphs (2) to (7).
2
If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to EPN written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order EPN reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to EPN the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
3
If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, EPN must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed provided that this obligation shall not require EPN to exercise any power it may have to acquire any land or rights by compulsory purchase order.
4
Any alternative apparatus to be constructed in land of the undertaker under this part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between EPN and the undertaker or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
5
EPN must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 41 (arbitration), and after the grant to EPN of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this part of this Schedule.
6
Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to EPN that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by EPN, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of EPN.
7
Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.
I3838
1
Where, in accordance with the provisions of this part of this Schedule, the undertaker affords to EPN facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and EPN or in default of agreement settled by arbitration in accordance with article 41 (arbitration).
2
If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to EPN than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to EPN as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
I3939
1
Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 37(2), the undertaker must submit to EPN a plan, section and description of the works to be executed.
2
Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by EPN for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and EPN is entitled to watch and inspect the execution of those works.
3
Any requirements made by EPN under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.
4
If EPN in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs (32) to (38) apply as if the removal of the apparatus had been required by the undertaker under paragraph 37(2).
5
Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.
6
The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to EPN notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.
I4040
1
Subject to the following provisions of this paragraph, the undertaker must repay to EPN the reasonable expenses incurred by EPN in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 37(2).
2
There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this part of this Schedule, that value being calculated after removal.
3
If in accordance with the provisions of this part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 41 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to EPN by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 37(2); and
b
where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.
5
An amount which apart from this sub-paragraph would be payable to EPN in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on EPN any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.
I4141
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 37(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of EPN, or there is any interruption in any service provided, or in the supply of any goods, by EPN, the undertaker must—
a
bear and pay the cost reasonably incurred by EPN in making good such damage or restoring the supply; and
b
indemnify EPN for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from EPN,
by reason or in consequence of any such damage or interruption.
2
Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of EPN, its officers, servants, contractors or agents.
3
EPN must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
I4242
Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and EPN in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 5FOR THE PROTECTION OF ANGLIAN WATER
I4343
For the protection of Anglian Water, the following provisions shall, unless otherwise agreed in writing between the undertaker and Anglian Water, have effect.
I4444
In this Part of this schedule—
“alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in not less efficient a manner than previously;
“Anglian Water” means Anglian Water Services Limited;
“apparatus” means—
- a
any works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;
- b
any drain or works vested in Anglian Water under the Water Industry Act 1991; and
- c
any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of the Water Industry Act 1991 or an agreement to adopt made under section 104 (agreements to adopt a sewer, drain or sewage disposal works, at future date) of that Act M9,
and includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any sewer, drain, or works (within the meaning of section 219 (general interpretation) of that Act) and any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus.
- a
“functions” includes powers and duties;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land; and
“plan” includes sections, drawings, specifications and method statements.
I4545
This Part of this Schedule does not apply to apparatus to the extent that the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 (water supply) of the 1991 Act.
I4646
The undertaker must not interfere with, build over or near to any apparatus within the Order land or execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within the standard protection strips which are the strips of land falling the following distances to either side of the medial line of any relevant pipe or apparatus: 2.25 metres where the diameter of the pipe is less than 150 millimetres; 3 metres where the diameter of the pipe is between 150 and 450 millimetres; 4.5 metres where the diameter of the pipe is between 450 and 750 millimetres; and 6 metres where the diameter of the pipe exceeds 750 millimetres, unless otherwise agreed in writing with Anglian Water, such agreement not to be unreasonably withheld or delayed, and such provision being brought to the attention of any agent or contractor responsible for carrying out the authorised development on behalf of the undertaker.
I4747
The alteration, extension, removal or re-location of any apparatus shall not be implemented until—
a
any requirement for any permits under the Environmental Permitting (England and Wales) Regulations 2010 M10 or other legislation and any other associated consents are obtained, and any approval or agreement required from Anglian Water on alternative outfall locations as a result of such re-location are approved, such approvals from Anglian Water not to be unreasonably withheld or delayed; and
b
the undertaker has made the appropriate application required under the Water Industry Act 1991 together with a plan and section of the works proposed and Anglian Water has agreed all of the contractual documentation required under the Water Industry Act 1991, such agreement not to be unreasonably withheld or delayed; and such works to be executed only in accordance with the plan, section and description submitted and in accordance with such reasonable requirements as may be made by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it.
I4848
In the situation, where in exercise of the powers conferred by the Order, the undertaker acquires any interest in any land in which Apparatus is placed and such apparatus is to be relocated, extended, removed or altered in any way, no alteration or extension shall take place until Anglian Water has established to its reasonable satisfaction in a timely manner, contingency arrangements in order to conduct its functions for the duration of the works to relocate, extend, remove or alter the apparatus or provide alternative apparatus.
I4949
Regardless of any provision in this Order or anything shown on any plan, the undertaker must not acquire any apparatus otherwise than by agreement, and before extinguishing any existing rights for Anglian Water to use, keep, inspect, renew and maintain its apparatus in the Order land, the undertaker shall, with the agreement of Anglian Water, create a new right to use, keep, inspect, renew and maintain the apparatus that is reasonably convenient for Anglian Water such agreement not to be unreasonably withheld or delayed, and to be subject to arbitration under article 41 (arbitration).
I5050
If the undertaker is unable to create the new rights referred to in paragraph (49), Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible, use its reasonable endeavours to obtain the necessary rights.
I5151
If in consequence of the exercise of the powers conferred by the Order the access to any apparatus is materially obstructed the undertaker shall provide such alternative means of access to such apparatus as will enable Anglian Water to maintain or use the apparatus no less effectively than was possible before such obstruction.
I5252
In consequence of the exercise of the powers conferred by the Order, previously unmapped sewers, lateral drains or other apparatus are identified by the undertaker, notification of the location of such assets will immediately be given to Anglian Water and afforded the same protection of other Anglian Water assets.
I5353
If for any reason or in consequence of the construction of any of the works referred to in paragraphs 46, 47 and 48 and 52 above any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker shall—
a
bear and pay the cost reasonably incurred by Anglian Water in making good any damage or restoring the supply; and
b
make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs incurred by Anglian Water,
by reason or in consequence of any such damage or interruption.
I5454
1
Nothing in paragraph 53 imposes any liability on the undertaker in respect of any damage or interruption to the extent that it is attributable to the neglect or default of Anglian Water, its officers' servants, contractors or agents.
2
Anglian Water must give the undertaker reasonable notice of any claim or demand pursuant to paragraph 53 and must consider its representations before proceeding further in respect of the claim or demand.
3
Anglian Water must use its reasonable endeavours to mitigate in whole or in part and to minimise any claim, costs, expenses, loss, demands and penalties pursuant to paragraph 53. If requested to do so by the undertaker, Anglian Water shall provide an explanation of how the claim has been minimised
I5555
Any difference or dispute arising between the undertaker and Anglian Water under this schedule must, unless otherwise agreed in writing between the undertaker and Anglian Water, be determined by arbitration in accordance with article 41 (arbitration).
PART 6FOR THE PROTECTION OF COVANTA ROOKERY SOUTH LIMITED
I5656
For the protection of Covanta Rookery South Limited (Company No. 07094843) as referred to in this part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and Covanta.
I5757
In this part of this Schedule—
“Covanta” means Covanta Rookery South Limited (Company No. 07094843) whose registered office is at 20-22 Bedford Row London WC1R 4JS;
“the Millbrook authorised development” means the development authorised by this Order;
“the respective authorised developments” means the Rookery authorised development and the Millbrook authorised development”
“the Rookery Order” means the Rookery South (Resource Recovery Facility) Order 2011;
“Rookery limits of deviation” means the areas of the Rookery Order land in respect of which the Rookery authorised development may be constructed, in accordance with Article 3(2) of the Rookery Order;
“the Rookery Order land” means the land or any part of it shown as falling within the Rookery Order limits; and
“the Rookery authorised development” means the development authorised by the Rookery Order.
Co-operation during constructionI5858
The undertaker shall not submit written details for numbered work 2A for approval to the relevant planning authorities in accordance with requirement 5(2) (highway access) without first obtaining the written consent of Covanta in respect of the route, siting and location of numbered work 2A.
I5959
The undertaker shall not exercise powers pursuant to articles 9 (street works), 10 (construction and maintenance of new or altered means of access) or 11 (temporary prohibition or restriction of use of streets) over land within the Rookery limits of deviation without first obtaining the written consent of Covanta.
I6060
1
Wherever in this Part of this Schedule provision is made with respect to the approval or consent of Covanta, that approval or consent shall be in writing (and subject to such reasonable terms and conditions as Covanta may require), but shall not be unreasonably withheld.
2
In the event that Covanta does not respond in writing to a request for approval or consent within 28 days of receipt of such a request, Covanta is deemed to have given its consent (without any terms or conditions).
I6161
Insofar as the construction of the Millbrook authorised development is or may be undertaken concurrently with the Rookery authorised development, the undertaker shall—
a
co-operate with Covanta with a view to ensuring—
i
the co-ordination of construction programming and the carrying out of works; and
ii
that access for the purposes of constructing the respective authorised developments is maintained for the undertaker and Covanta and their respective contractors.
b
use reasonable endeavours to avoid any conflict arising between the carrying out of the respective authorised developments.
I6262
Insofar as the construction of the Millbrook authorised development gives rise to the need to modify any scheme secured by a requirement contained in Part 2 of Schedule 1 to the Rookery Order, the undertaker shall provide such assistance as is reasonably necessary to support Covanta in pursuing any such modification.
ArbitrationI6363
1
Any difference or dispute arising between the undertaker and Covanta under this Part of this Schedule shall, unless otherwise agreed in writing between the undertaker and Covanta, be referred to and settled in arbitration in accordance with the Rules at Schedule 13 of this Order, by a single arbitrator to be agreed upon by the parties within 14 days of receipt of the notice of arbitration, or if the parties fail to agree within the time period stipulated, to be appointed on application of either party (after giving written notice to the other) by the Secretary of State.
2
Article 41 (arbitration) shall not apply to any difference or dispute under any provisions of the Part of this Schedule.
PART 7FOR THE PROTECTION OF NETWORK RAIL
I6464
For the protection of Network Rail as referred to in this part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and Network Rail, have effect.
I6565
In this part of this Schedule—
“Network Rail” means Network Rail Infrastructure Limited (Company registration number 02904587) whose registered office is at 1 Eversholt Street, London, NW1 2DN and any associated company of Network Rail which holds property for railway purposes, and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 (meaning of “subsidiary” etc.) of the Companies Act 2006) the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited;
“railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993) or station lease;
I6666
1
Where under this Part Network Rail is required to give its consent, agreement or approval in respect of any matter, that consent, agreement or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute.
2
Subject to subparagraph (1) where Network Rail is asked to give its consent, agreement or approval pursuant to this Part, such consent, agreement or approval must not be unreasonably withheld but may be given subject to reasonable conditions.
I6767
The undertaker shall include provisions relating to anti-dazzle fencing in the written details of any proposed permanent fence or other means of enclosure for numbered work 2A submitted pursuant to requirement 6 of Schedule 2 such provisions to be substantially in accordance with the equivalent provisions in the approved details submitted pursuant to paragraph 11 of Schedule 2 of The Rookery South (Resource Recovery Facility) Order 2011 unless otherwise agreed by Network Rail.
I6868
1
The undertaker shall not submit the written details of any proposed permanent fence or other means of enclosure for numbered work 2A to Central Bedfordshire Council in accordance with requirement 6 of Schedule 2 (Fencing and other means of site perimeter enclosure) without having first obtained the written approval of Network Rail in accordance with subparagraph (2).
2
The undertaker shall provide Network Rail with a draft of the written details of any proposed permanent fence or other means of enclosure for numbered work 2A (including the proposed anti-dazzle fencing) for approval and Network Rail shall within a period of 28 days beginning with the date on which the written details are received by Network Rail serve written notice on the undertaker confirming that:
a
the written details are approved; or
b
the written details are approved subject to reasonable amendments as required by Network Rail; or
c
the written details are not approved and the reason for the non-approval; or
d
that further information is required in order for Network Rail to make its determination (in which case this paragraph 68(2) shall apply to such further information from the date of its receipt by Network Rail).
3
In the event that Network Rail fails to serve written notice in accordance with paragraph 68(2) within 28 days of receipt Network Rail shall be deemed to have served a notice pursuant to paragraph 68(2)(a).
4
The undertaker must include any amendments which are required by Network Rail and notified to the undertaker by Network Rail in the notice given pursuant to paragraph 68(2)(b) in the written details of any proposed permanent fence or other means of enclosure for numbered work 2A it submits to Central Bedfordshire Council in accordance with requirement 6 of Schedule 2 (Fencing and other means of site perimeter enclosure) and the undertaker shall not submit any such written details to Central Bedfordshire Council which have not been approved by Network Rail in accordance with paragraphs 68(2) or (3).
5
In deciding whether to approve the written details or request any amendments Network Rail shall take into account any fencing approved or constructed pursuant to The Rookery South (Resource Recovery Facility) Order 2011.
6
Each notice and all other information required to be sent to Network Rail under the terms of this paragraph 68 shall:
a
be sent to the Company Secretary and General Counsel at Network Rail Infrastructure Limited, 1 Eversholt Street, London, NW1 2DN via Royal Mail plc's special delivery service (or if this service is no longer being provided an appropriate recorded delivery postal service) and marked for the attention of the London North Western Route Asset Manager; and
b
contain a clear statement on its front page that Network Rail must respond within 28 days of receipt.
I6969
The undertaker shall not be obliged to construct the anti-dazzle fencing approved pursuant to requirement 6 of Schedule 2 in the event that anti-dazzle fencing has been constructed pursuant to The Rookery South (Resource Recovery Facility) Order 2011.
I7070
1
The undertaker shall not submit the construction traffic management plan to the relevant planning authorities in accordance with requirement 11 of Schedule 2 (construction traffic management plan) without having first obtained the written approval of Network Rail in accordance with subparagraph (2).
2
The undertaker shall provide Network Rail with a draft of the construction traffic management plan for approval and Network Rail shall within a period of 28 days beginning with the date on which the draft construction traffic management plan is received by Network Rail serve written notice on the undertaker confirming that:
a
the draft construction traffic management plan is approved; or
b
the draft construction traffic management plan is approved subject to reasonable amendments as required by Network Rail; or
c
the draft construction traffic management plan is not approved and the reason for the non-approval; or
d
that further information is required in order for Network Rail to make its determination (in which case this paragraph 70(2) shall apply to such further information from the date of its receipt by Network Rail).
3
In the event that Network Rail fails to serve written notice in accordance with paragraph 70(2) within 28 days of receipt Network Rail shall be deemed to have served a notice pursuant to paragraph 70(2)(a).
4
The undertaker must include any amendments which are required by Network Rail and notified to the undertaker by Network Rail in the notice given pursuant to paragraph 70(2)(b) in the draft construction traffic management plan it submits to the relevant planning authorities in accordance with requirement 11 of Schedule 2 (construction traffic management plan) and the undertaker shall not submit any such written details to the relevant planning authorities which have not been approved by Network Rail in accordance with paragraphs 70(2) or (3).
5
In deciding whether to approve the draft construction traffic management plan or request any amendments Network Rail shall take into account any funding received from any other third party in respect of upgrade works to the Green Lane level crossing (even if such upgrade works have not yet been completed by Network Rail) and any approval must not be conditional on the undertaker contributing funding towards a full barrier at Green Lane level crossing.
6
Each notice and all other information required to be sent to Network Rail under the terms of this paragraph 70 shall:
a
be sent to the Company Secretary and General Counsel at Network Rail Infrastructure Limited, 1 Eversholt Street, London, NW1 2DN via Royal Mail plc's special delivery service (or if this service is no longer being provided an appropriate recorded delivery postal service) and marked for the attention of the London North Western Route Level Crossing Manager; and
b
contain a clear statement on its front page that Network Rail must respond within 28 days of receipt.
I7171
1
Any difference or dispute arising between the undertaker and Network Rail under this Part of this Schedule shall, unless otherwise agreed in writing between the undertaker and Network Rail, be referred to and settled in arbitration in accordance with the Rules at Schedule 13 of this Order, by a single arbitrator to be agreed upon by the parties within 14 days of receipt of the notice of arbitration, or if the parties fail to agree within the time period stipulated, to be appointed on application of either party (after giving written notice to the other) by the Secretary of State.
2
Article 41 (arbitration) shall not apply to any difference or dispute under any provisions of the Part of this Schedule.
I7272
Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part I of the Railways Act 1993.