Search Legislation

The Millbrook Gas Fired Generating Station Order 2019

Changes over time for: PART 5

 Help about opening options

Alternative versions:

Status:

Point in time view as at 03/04/2019.

Changes to legislation:

There are currently no known outstanding effects for the The Millbrook Gas Fired Generating Station Order 2019, PART 5 . Help about Changes to Legislation

Close

Changes to Legislation

Revised legislation carried on this site may not be fully up to date. At the current time any known changes or effects made by subsequent legislation have been applied to the text of the legislation you are viewing by the editorial team. Please see ‘Frequently Asked Questions’ for details regarding the timescales for which new effects are identified and recorded on this site.

PART 5 E+W+SFOR THE PROTECTION OF ANGLIAN WATER

43.  For the protection of Anglian Water, the following provisions shall, unless otherwise agreed in writing between the undertaker and Anglian Water, have effect.E+W+S

Commencement Information

I1Sch. 10 para. 43 in force at 3.4.2019, see art. 1

44.  In this Part of this schedule—E+W+S

alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in not less efficient a manner than previously;

Anglian Water” means Anglian Water Services Limited;

apparatus” means—

(a)

any works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;

(b)

any drain or works vested in Anglian Water under the Water Industry Act 1991; and

(c)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of the Water Industry Act 1991 or an agreement to adopt made under section 104 (agreements to adopt a sewer, drain or sewage disposal works, at future date) of that Act M1,

and includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any sewer, drain, or works (within the meaning of section 219 (general interpretation) of that Act) and any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus.

functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land; and

plan” includes sections, drawings, specifications and method statements.

Commencement Information

I2Sch. 10 para. 44 in force at 3.4.2019, see art. 1

Marginal Citations

M11991 c.56. Section 102(4) was amended by paragraph 90 of Schedule 7 to the Water Act 2014 (c.21) and section 96(1)(c) of the Water Act 2003 (c.37); Section 104 was amended by section 96(4)(a), (b), (c), (e) and (f), and paragraph 1 of Schedule 9(3) to the Water Act 2003 (c.37), section 42(3) of the Flood and Water Management Act 2010 and by sections 11(2)(a), 11(2)(b) and 11(2)(c) of the Water Act 2014 (c.21).

45.  This Part of this Schedule does not apply to apparatus to the extent that the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 (water supply) of the 1991 Act.E+W+S

Commencement Information

I3Sch. 10 para. 45 in force at 3.4.2019, see art. 1

46.  The undertaker must not interfere with, build over or near to any apparatus within the Order land or execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within the standard protection strips which are the strips of land falling the following distances to either side of the medial line of any relevant pipe or apparatus: 2.25 metres where the diameter of the pipe is less than 150 millimetres; 3 metres where the diameter of the pipe is between 150 and 450 millimetres; 4.5 metres where the diameter of the pipe is between 450 and 750 millimetres; and 6 metres where the diameter of the pipe exceeds 750 millimetres, unless otherwise agreed in writing with Anglian Water, such agreement not to be unreasonably withheld or delayed, and such provision being brought to the attention of any agent or contractor responsible for carrying out the authorised development on behalf of the undertaker.E+W+S

Commencement Information

I4Sch. 10 para. 46 in force at 3.4.2019, see art. 1

47.  The alteration, extension, removal or re-location of any apparatus shall not be implemented until—E+W+S

(a)any requirement for any permits under the Environmental Permitting (England and Wales) Regulations 2010 M2 or other legislation and any other associated consents are obtained, and any approval or agreement required from Anglian Water on alternative outfall locations as a result of such re-location are approved, such approvals from Anglian Water not to be unreasonably withheld or delayed; and

(b)the undertaker has made the appropriate application required under the Water Industry Act 1991 together with a plan and section of the works proposed and Anglian Water has agreed all of the contractual documentation required under the Water Industry Act 1991, such agreement not to be unreasonably withheld or delayed; and such works to be executed only in accordance with the plan, section and description submitted and in accordance with such reasonable requirements as may be made by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it.

Commencement Information

I5Sch. 10 para. 47 in force at 3.4.2019, see art. 1

Marginal Citations

48.  In the situation, where in exercise of the powers conferred by the Order, the undertaker acquires any interest in any land in which Apparatus is placed and such apparatus is to be relocated, extended, removed or altered in any way, no alteration or extension shall take place until Anglian Water has established to its reasonable satisfaction in a timely manner, contingency arrangements in order to conduct its functions for the duration of the works to relocate, extend, remove or alter the apparatus or provide alternative apparatus.E+W+S

Commencement Information

I6Sch. 10 para. 48 in force at 3.4.2019, see art. 1

49.  Regardless of any provision in this Order or anything shown on any plan, the undertaker must not acquire any apparatus otherwise than by agreement, and before extinguishing any existing rights for Anglian Water to use, keep, inspect, renew and maintain its apparatus in the Order land, the undertaker shall, with the agreement of Anglian Water, create a new right to use, keep, inspect, renew and maintain the apparatus that is reasonably convenient for Anglian Water such agreement not to be unreasonably withheld or delayed, and to be subject to arbitration under article 41 (arbitration).E+W+S

Commencement Information

I7Sch. 10 para. 49 in force at 3.4.2019, see art. 1

50.  If the undertaker is unable to create the new rights referred to in paragraph (49), Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible, use its reasonable endeavours to obtain the necessary rights.E+W+S

Commencement Information

I8Sch. 10 para. 50 in force at 3.4.2019, see art. 1

51.  If in consequence of the exercise of the powers conferred by the Order the access to any apparatus is materially obstructed the undertaker shall provide such alternative means of access to such apparatus as will enable Anglian Water to maintain or use the apparatus no less effectively than was possible before such obstruction.E+W+S

Commencement Information

I9Sch. 10 para. 51 in force at 3.4.2019, see art. 1

52.  In consequence of the exercise of the powers conferred by the Order, previously unmapped sewers, lateral drains or other apparatus are identified by the undertaker, notification of the location of such assets will immediately be given to Anglian Water and afforded the same protection of other Anglian Water assets.E+W+S

Commencement Information

I10Sch. 10 para. 52 in force at 3.4.2019, see art. 1

53.  If for any reason or in consequence of the construction of any of the works referred to in paragraphs 46, 47 and 48 and 52 above any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker shall—E+W+S

(a)bear and pay the cost reasonably incurred by Anglian Water in making good any damage or restoring the supply; and

(b)make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs incurred by Anglian Water,

by reason or in consequence of any such damage or interruption.

Commencement Information

I11Sch. 10 para. 53 in force at 3.4.2019, see art. 1

54.—(1) Nothing in paragraph 53 imposes any liability on the undertaker in respect of any damage or interruption to the extent that it is attributable to the neglect or default of Anglian Water, its officers' servants, contractors or agents.E+W+S

(2) Anglian Water must give the undertaker reasonable notice of any claim or demand pursuant to paragraph 53 and must consider its representations before proceeding further in respect of the claim or demand.

(3) Anglian Water must use its reasonable endeavours to mitigate in whole or in part and to minimise any claim, costs, expenses, loss, demands and penalties pursuant to paragraph 53. If requested to do so by the undertaker, Anglian Water shall provide an explanation of how the claim has been minimised

Commencement Information

I12Sch. 10 para. 54 in force at 3.4.2019, see art. 1

55.  Any difference or dispute arising between the undertaker and Anglian Water under this schedule must, unless otherwise agreed in writing between the undertaker and Anglian Water, be determined by arbitration in accordance with article 41 (arbitration).E+W+S

Commencement Information

I13Sch. 10 para. 55 in force at 3.4.2019, see art. 1

Back to top

Options/Help

Print Options

You have chosen to open The Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open The Whole Instrument as a PDF

The Whole Instrument you have selected contains over 200 provisions and might take some time to download.

Would you like to continue?

You have chosen to open the Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open Schedules only

The Schedules you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made): The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Point in Time: This becomes available after navigating to view revised legislation as it stood at a certain point in time via Advanced Features > Show Timeline of Changes or via a point in time advanced search.

Close

See additional information alongside the content

Geographical Extent: Indicates the geographical area that this provision applies to. For further information see ‘Frequently Asked Questions’.

Show Timeline of Changes: See how this legislation has or could change over time. Turning this feature on will show extra navigation options to go to these specific points in time. Return to the latest available version by using the controls above in the What Version box.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources
Close

Timeline of Changes

This timeline shows the different points in time where a change occurred. The dates will coincide with the earliest date on which the change (e.g an insertion, a repeal or a substitution) that was applied came into force. The first date in the timeline will usually be the earliest date when the provision came into force. In some cases the first date is 01/02/1991 (or for Northern Ireland legislation 01/01/2006). This date is our basedate. No versions before this date are available. For further information see the Editorial Practice Guide and Glossary under Help.

Close

More Resources

Use this menu to access essential accompanying documents and information for this legislation item. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as made version that was used for the print copy
  • correction slips

Click 'View More' or select 'More Resources' tab for additional information including:

  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • links to related legislation and further information resources