SCHEDULES
I82SCHEDULE 1AUTHORISED DEVELOPMENT
I82In the administrative areas of North Warwickshire District Council and Solihull Metropolitan Borough Council
I82A nationally significant infrastructure project as defined in sections 14 (nationally significant infrastructure projects: general) and 22 (highways) of the 2008 Act, and associated development as defined in section 115 of the 2008 Act, comprising:
I82Work No. 1 – as shown on Sheet Nos. 1, 2, 3, 5, 6 and 7 of the works plans and being the improvement of the northbound and southbound carriageways of the M42 Motorway between Junctions 5 and 7 (8.35 kilometres in length), such works including—
a
the alteration of 4 no. portal gantries above the M42 Motorway within the gantry siting locations shown as Gantry Type 1 on Sheet Nos. 1, 5 and 6 of the works plans, including the installation of new signs, signals, sign illumination, control cabinets, power and communication cable connections;
b
the construction of 5 no. portal gantries above the M42 Motorway within the gantry siting locations shown as Gantry Type 3 on Sheet Nos. 1, 2 and 5 of the works plans, including the installation of new gantry foundations, gantry structures, earthwork retaining structures, signs, signals, sign illumination, control cabinets, power and communication cable connections;
c
the construction of 9 no. cantilever gantries above the M42 Motorway within the gantry siting locations shown as Gantry Type 4 on Sheet Nos. 1, 2 and 6 of the works plans, including the installation of new gantry foundations, gantry structures, earthwork retaining structures, signs, signals, sign illumination, control cabinets, power and communication cable connections;
d
the demolition of 7 no. portal gantries above the M42 Motorway within the gantry siting locations shown as Gantry Type 5 on Sheet Nos. 1, 2, 5 and 6 of the works plans, including the removal of the gantry foundations, gantry structures, earthwork retaining structures, signs, signals, sign illumination, control cabinets, power and communication cable disconnections;
e
the demolition of 6 no. cantilever gantries above the M42 Motorway within the gantry siting locations shown as Gantry Type 6 on Sheet Nos. 1, 2 and 6 of the works plans, including the removal of the gantry foundations, gantry structures, signs, signals, sign illumination, control cabinets, power and communication cable disconnections;
f
the construction of 1 no. emergency refuge area on the northbound carriageway at the locations shown on Sheet No. 2 of the works plans;
g
the demolition of 3 no. emergency refuge areas on the northbound carriageway at the locations shown on Sheet Nos. 2 and 6 of the works plans; and
h
the demolition of 3 no. emergency refuge areas on the southbound carriageway at the locations shown on Sheet Nos. 2 and 6 of the works plans.
I82In the administrative area of Solihull Metropolitan Borough Council
I82Work No. 2 – as shown on Sheet Nos. 4 and 5 of the works plans and being the improvement of the eastbound and westbound carriageway of the A45 from a point 650 metres west of Clock Interchange to a point 715 metres east of the M42 Junction 6 (2.4 kilometres in length), such works including—
a
the alteration of 1 no. cantilever gantry above the westbound carriageway of the A45 within the gantry siting locations shown as Gantry Type 2 on Sheet No. 4 of the works plans, including the installation of new signs, signals, sign illumination, control cabinets, power and communication cable connections;
b
the construction of 2 no. cantilever gantries above the eastbound carriageway of the A45 within the gantry siting locations shown as Gantry Type 4 on Sheet No. 4 of the works plans, including the installation of new gantry foundations, gantry structure, earthwork retaining structures, signs, signals, sign illumination, control cabinets, power and communication cable connections; and
c
the demolition of 1 no. portal gantry above the eastbound carriageway of the A45 within the gantry siting locations shown as Gantry Type 5 on Sheet No. 4 of the works plans, including the removal of gantry foundations, gantry structures, signs, signals, sign illumination, control cabinets, power and communication cable disconnections.
I82Work No. 3 – as shown on Sheet No. 2 of the works plans and being the demolition of the existing Solihull Road Overbridge (65 metres in length) and the construction of a new Solihull Road Overbridge, a two lane single carriageway with a widened southern verge for future footway provision (110 metres in length). New overbridge required to facilitate slip roads to Junction 5A (Works Nos. 4 and 5). New overbridge will require Solihull Road to be raised on embankment to the east and west of the new overbridge structure for a distance of 225 metres (east) and 325 metres (west) respectively.
I82Work No. 4 – as shown on Sheet No. 2 of the works plans and being the construction of a new M42 off-slip road (850 metres in length) both in cutting and on embankment that diverges from the M42 and connects to the new Junction 5A of the M42 (Work No. 6), including the demolition of 125 metres of existing sheet pile wall to accommodate the new off slip road.
I82Work No. 5 – as shown on Sheet No. 2 of the works plans and being the construction of a new M42 on-slip road (750 metres in length) both in cutting and on embankment that merges onto the M42 from the new Junction 5A of the M42 (Work No. 6).
I82Work No. 6 – as shown on Sheet No. 2 of the works plans and being the construction of a new Junction 5A of the M42, 120 metres north of the proposed Solihull Road Overbridge (Work No. 3). Junction 5A to consist of a two lane eastern roundabout and a two lane western roundabout, both constructed on embankment. Roundabouts to be connected via a new Junction 5A overbridge (45m in length), featuring a two lane eastbound carriageway and a single lane plus hard shoulder on the western carriageway.
I82Work No. 7 – as shown on Sheet Nos. 2, 3 and 4 of the works plans and being the construction of a new 2.4 kilometre dual carriageway mainline link on both embankment and in cutting connecting Junction 5A (Work No. 6) to Clock Interchange (Work No. 20). The new mainline link to include the construction of earthwork retaining structures and to necessitate the demolition of the residential property known as “Heath End House”.
I82Work No. 8 – as shown on Sheet Nos. 2 and 3 of the works plans and being the construction of a new single lane on-slip road in cutting (690 metres in length) commencing at Barber’s Coppice Roundabout (Work No. 12) and connecting to the northbound carriageway of the proposed mainline link road (Work No. 7).
I82Work No. 9 – as shown on Sheet No. 3 of the works plans and being the construction of a new two lane off-slip road (510 metres in length) in cutting commencing at the southbound carriageway of the new mainline link road (Work No. 7) and connecting to the proposed Bickenhill Roundabout (Work No. 14).
I82Work No. 10 – as shown on Sheet Nos. 3 and 4 of the works plans and being the construction of—
a
a new single lane plus hard-shoulder northbound diverge (640 metres in length) in both cutting and on embankment from the mainline link road (Work No. 7) and joining the Airport Way connector road from the A45 Westbound (Work No. 19); and
b
a new field access to land severed by the construction of Work Nos. 7 and 10 identified as point 4/23 on Sheet 4 of the Streets, Rights of Way and Access Plans.
I82Work No. 11 – as shown on Sheet No. 2 of the works plans and being the construction of the realigned two lane single carriageway B4438 Catherine-de-Barnes Lane (240 metres in length) in both cutting and on embankment, south of Barber’s Coppice Roundabout (Work No. 12).
I82Work No. 12 – as shown on Sheet No. 2 of the works plans and being the construction of a new two lane roundabout on embankment, to be known as Barber’s Coppice Roundabout. Roundabout positioned to the east of the Birmingham Dog’s Home facility, providing connections to the realigned B4438 Catherine-de-Barnes Lane (Works Nos. 11 and 13), the new single lane northbound on-slip road to the new mainline link road at Work No. 7 (Work No. 8) and existing properties on the western arm.
I82Work No.13 – as shown on Sheet Nos. 2 and 3 of the works plans and being the construction of the realigned two lane single carriageway B4438 Catherine-de-Barnes Lane (760 metres in length) in both cutting and embankment, connecting Barber’s Coppice Roundabout (Work No. 12) with Bickenhill Roundabout (Work No. 14). New carriageway to include the construction of a new overbridge (82 metres in length) to be known as Catherine-de-Barnes South Overbridge, to provide a crossing of the new mainline link road (Work No. 7), south of the proposed realigned Shadowbrook Lane (Work No. 17). Construction of a new field access to land severed by Work No. 7 as shown at point 3/38 on Sheet 3 of the Streets, Rights of Way and Access Plans.
I82Work No. 14 – as shown on Sheet No. 3 of the works plans and being the construction of a new two lane roundabout in both cutting and on embankment, to be known as Bickenhill Roundabout. Roundabout positioned to the west of Bickenhill, providing connections to the realigned B4438 Catherine-de-Barnes Lane (Work No.13), the realigned Catherine-de-Barnes Lane (Work No. 15), the new two lane southbound off-slip road from the mainline link road (Work No. 9) and the realigned St Peters Lane (Work No. 18).
I82Work No. 15 – as shown on Sheet No. 3 of the works plans and being the construction of the realigned two lane single carriageway Catherine-de-Barnes Lane (490 metres in length) in both cutting and on embankment, connecting Bickenhill Roundabout (Work No. 14) with the T Junction of Catherine-de-Barnes Lane and St Peters Lane (Work No. 16). Construction of a new field access to land severed by Work No. 7 as shown at point 3/49 on Sheet 3 of the Streets, Rights of Way and Access Plans.
I82Work No. 16 – as shown on Sheet No. 3 of the works plans and being the construction of realigned new two lane single carriageway realigned Catherine-de-Barnes Lane (290 metres in length) and associated footway to the junction with Clock Lane. To include the construction of a new overbridge, to be known as Catherine-de-Barnes North Overbridge, to provide a crossing of the new mainline link road (Work No. 7). Works to also include tie in works to the existing St Peters Lane access to the village of Bickenhill.
I82Work No. 17 – as shown on Sheet No. 3 of the works plans and being the realignment of 125 metres of Shadowbrook Lane to connect with the realigned B4438 Catherine-de-Barnes Lane (Work No. 13).
I82Work No. 18 – as shown on Sheet No. 3 of the works plans and being the construction and realignment of 50 metres of the southern section of St Peters Lane, including revised access points in order to connect to Bickenhill Roundabout (Work No. 14).
I82Work No. 19 – as shown on Sheet No. 4 of the works plans and being the alteration of the existing Airport Way connector road linking the A45 Westbound to Airport Way, to accommodate the connection with the mainline link road at Work No. 10 and the closure of the dedicated free flow link from M42 Junction 6 to the Airport (Work No. 29).
I82Work No. 20 – as shown on Sheet No. 4 of the works plans and being improvements to the existing Clock Interchange, including the upgrade of the junction from a two to a three lane interchange, the installation of traffic signals and alterations to the on-slip and off-slip roads to accommodate the new three lane junction arrangement. Works to also include the removal of the existing footway (both 85 metres in length) on the eastern and western structures of Clock Interchange.
I82Work No. 21 – as shown on Sheet No. 4 of the works plans and being the construction of a new free flow link (762 metres in length) from the mainline link road (Work No. 7) on both embankment and in cutting to connect to the A45 Westbound carriageway, 600 metres to the west of Clock Interchange. Free flow link road to diverge from the mainline link road 150 metres to the south of Clock Interchange.
I82Work No. 22 – as shown on Sheet No. 4 of the works plans and being the realignment of the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (the realigned section of road to be 390 metres in length, constructed on embankment and in cutting) to accommodate the realignment works to Bickenhill Lane North and South (Work Nos. 23 and 24).
I82Work No. 23 – as shown on Sheet No. 4 of the works plans and being the alteration of the existing Bickenhill Lane carriageway from two lanes to three lanes northbound from Clock Interchange and associated tie in works to Bickenhill Lane Roundabout.
I82Work No. 24 – as shown on Sheet No. 4 of the works plans and being the alteration of the existing Bickenhill Lane carriageway from three lanes to four lanes southbound from Bickenhill Lane Roundabout to connect to Clock Interchange, including tie in works at Bickenhill Lane Roundabout and the removal of the existing segregated left turn lane onto the A45 Eastbound, with all four lanes to converge to a stop line at Clock Interchange.
I82Work No. 25 – as shown on Sheet No. 5 of the works plans and being improvements to M42 Junction 6 Interchange and its associated on-slips and off-slips roads, including the upgrade of the M42 Northbound off-slip to four lanes from three lanes.
I82Work No. 26 – as shown on Sheet Nos. 4, 5 and 6 of the works plans and being the construction of a new free flow single carriageway with hard shoulder link road (1610 metres in length) on both embankment and in cutting, connecting the A45 Eastbound and M42 Northbound.
I82Work No.27 – as shown on Sheet No. 5 of the works plans and being the construction of a new free flow link road (750 metres in length) with single carriageway and hard shoulder on both embankment and in cutting, connecting the M42 Southbound to the A45 Eastbound.
I82Work No. 28 – as shown on Sheet Nos. 5 and 6 of the works plans and being the construction of a new two lane diverge slip road (635 metres in length) on embankment and in cutting from the M42 Southbound, connecting to the relocated East Way Roundabout (Work No. 30).
I82Work No. 29 – as shown on Sheet No. 5 of the works plans and being the closure of the dedicated single lane free flow link from M42 Junction 6 Northbound to Airport Way.
I82Work No. 30 – as shown on Sheet No. 5 of the works plans and being the construction of the new East Way Roundabout, such works to include—
a
the removal of the existing East Way Roundabout and its associated connection from the M42 Southbound Diverge; and
b
the construction of a new East Way Roundabout on embankment to accommodate the new southbound diverge arrangement (Work No. 28). Works to include the realignment of, and associated tie in works for, each spur of the East Way carriageway and the private means of access to land south of East Way. East Way Roundabout to be relocated 115 metres north west of the existing East Way Roundabout and 80 metres to the east of the existing East Way Overbridge.
I82Work No. 31 – as shown on Sheet No. 5 of the works plans and being the alteration of Middle Bickenhill single lane one way egress to a single lane two way access and egress arrangement to maintain connectivity to Middle Bickenhill.
I82Work No. 32 – as shown on Sheet No. 2 of the works plans and being the installation of drainage attenuation and treatment systems to the south east of the new Junction 5A (Work No. 6) to accommodate the undertaker’s assets. Works to include the removal of an existing underground storage tank, the installation of a new underground storage tank with filter media, a pump station, swales and a reed bed system to provide attenuation and treatment. A new access track will be constructed off Solihull Road to the east of the existing properties to enable access to the proposed attenuation and treatment facilities for maintenance purposes between points 2/1 and 2/2 on Sheet 2 of the Streets, Rights of Way and Access Plans.
I82Work No. 33 – as shown on Sheet No. 2 of the works plans and being the installation of drainage attenuation and treatment systems to the north west of the new Junction 5A (Work No. 6) to accommodate the undertaker’s assets. Works to include the installation of an underground storage tank, pump station, reed bed and swale to provide attenuation and treatment. Access for maintenance to be constructed off the Public Right of Way M123 by 385 metres between points 2/7 and 2/3 as shown on Sheet 2 of the Streets, Rights of Way and Access Plans.
I82Work No. 34 – as shown on Sheet No. 2 of the works plans and being the installation of an attenuation system adjacent to Barber’s Coppice Roundabout (Work No. 12) to accommodate Solihull Metropolitan Borough Council assets. Works to include the installation of an underground storage tank to provide attenuation and treatment and maintenance layby.
I82Work No. 35 – as shown on Sheet No. 3 of the works plans and being the installation of drainage attenuation and treatment systems south of Clock Interchange and adjacent to Catherine-de-Barnes North Overbridge to accommodate Solihull Metropolitan Borough Council assets. Works to include the installation of an underground storage tank and swales to provide attenuation and treatment. Access for maintenance to be provided off the T-junction of St Peters Lane and the realigned Catherine-de-Barnes Lane (Work No. 16).
I82Work No. 36 – as shown on Sheet No. 4 of the works plans and being the installation of drainage attenuation and treatment systems to the South West of Clock Interchange (Work No. 20) to accommodate the undertaker’s assets. Works to include the installation of an underground storage tank with filter media, pump station and swales to provide attenuation and treatment.
I82Work No. 37 – as shown on Sheet No. 5 of the works plans and being the installation of drainage attenuation and treatment systems to the North East of Junction 6 to accommodate the undertaker’s assets. Works to include the installation of a reed bed and swales to provide attenuation and treatment. Access for maintenance to be provided to the east of the proposed East Way Roundabout (Work No. 30(b)).
I82Work No. 38 – as shown on Sheet No. 2 of the works plans and being the construction of an accommodation bridge (30 metres in length) across the new mainline link road for the redirected public right of way (Work No.46).
I82Work No. 39 – as shown on Sheet No. 4 of the works plans and being the construction of a Pedestrian Overbridge (60 metres in length) across the A45.
I82Work No. 40 – as shown on Sheet No. 4 of the works plans and being the construction of a pedestrian underpass (20 metres in length) and an associated footway/cycleway ramp (230 metres in length in total) to the east of the pedestrian underpass, to maintain connectivity on the Airport Way connector road.
I82Work No. 41 – as shown on Sheet No. 2 of the works plans and being the construction of a pedestrian footpath (440 metres in length) commencing at Barber’s Coppice Roundabout (Work No. 12) and connecting to Public Rights of Way M122 and M123, 75 metres east of the proposed Accommodation Bridge (Work No. 38).
I82Work No. 42 – as shown on Sheet No. 2 of the works plans and being the construction of a pedestrian footpath (50 metres in length) on the west of Barber’s Coppice Roundabout (Work No. 12) in order to connect the pedestrian footpath at Work No. 41 with the existing Catherine-de-Barnes footway adjacent to Birmingham Dogs Home.
I82Work No. 43 – as shown on Sheet No. 3 of the works plans and being the construction of a new footway/cycleway (790 metres in length) on the northbound carriageway of the realigned B4438 Catherine-de-Barnes Lane (Work No.13).
I82Work No. 44 – as shown on Sheet No. 4 of the work plans and being the construction of a footway/cycleway (350 metres in length) to provide a connection between the existing footway/cycleway at Clock Lane and Catherine-de-Barnes Lane and the proposed Pedestrian Underpass (Work No. 40) and Airport Way connector road (Work No.19).
I82Work No. 45 – as shown on Sheet No. 4 of the works plans and being the construction of a footway/cycleway (400 metres in length) adjacent to the proposed A45 Westbound carriageway free flow link road (Work No. 21) and connecting to the footway/cycleway routes at the Pedestrian Underpass (Work No. 40) and the Airport Way connector road (Work No. 19).
I82Work No. 46 – as shown on Sheet No. 2 of the works plans and being works to stop up the existing section of Public Right of Way M123 (120 metres in length) and redirected across the proposed Accommodation Bridge (Work No. 38).
I82Work No. 47 – as shown on Sheet No. 2 of the works plans and being works to stop up the existing section of Public Right of Way M122 (370 metres in length). East to west connectivity to be maintained via proposed footway to Barber’s Coppice Roundabout (Work No. 41).
I82Work No. 48 – as shown on Sheet No. 3 of the works plans and being works to stop up the existing section of Public Right of Way M113 (130 metres in length). Public Right of Way M113 to be reconnected to the realigned B4438 Catherine-de-Barnes Lane (Work No. 13) via the new Private Means of Access to the west of the new mainline link road (Work No. 54(b)).
I82Work No. 49 – as shown on Sheet No. 3 of the works plans and being works to stop up the existing Public Right of Way M113a (390 metres in length). Access to the B4438 Catherine-de-Barnes Lane to be maintained via Public Right of Way M113 and the new Private Means of Access to the west of the new mainline link road (Work No. 54(b)).
I82Work No. 50 – as shown on Sheet No. 3 of the works plans and being works to stop up the existing section of Public Right of Way M112 (190 metres in length). Public Right of Way M112 to be reconnected to the realigned Catherine-de-Barnes Lane (Work No. 16) via the new Private Means of Access to the west of the new mainline link road (Work No. 54(b)).
I82Work No. 51 – as shown on Sheet No. 3 of the works plans and being works to stop up the existing section of Public Right of Way M109 (100 metres in length). Public Right of Way M109 to be reconnected to the realigned Catherine-de-Barnes Lane (Work No. 16) via the new Private Means of Access to the west of the new mainline link road (Work No. 54(b)).
I82Work No. 52 – as shown on Sheet No. 3 of the works plans and being works to stop up the existing footway/cycleway situated on Catherine-de-Barnes Lane (560 metres in length).
I82Work No. 53 – as shown on Sheet No. 4 of the works plans and being works to realign the existing Public Right of Way M106 (386 metres in length) due to the construction of the new mainline link road (Work No. 7) and to connect to the existing Airport Way connector road (Work No. 19).
I82Work No. 54 – as shown on Sheet Nos. 2 and 3 of the works plans and being the construction of—
a
Private Means of Access to the property known as Four Winds and any associated tie in works; and
b
a new Private Means of Access and Public Right of Way running to the west of the new mainline link road (Work No. 7) to provide access to the Warwickshire Gaelic Athletic Association facilities (Work No. 68) and adjacent land. The Private Means of Access will be split at a point just north of the existing Warwickshire Gaelic Athletic Association facilities. The Public Right of Way will be continuous in order to mitigate any severance of Public Rights of Way M109, M112 and M113.
I82Work No. 55 – as shown on Sheet No. 2 of the works plans and being the diversion of a local high pressure gas main due to the construction of the slip roads to the new Junction 5A of the M42 (Works Nos. 4 and 5).
I82Work No. 56 – as shown on Sheet Nos. 2 and 3 of the works plans and being the diversion of a local high pressure gas main (885 metres in length) due to the construction of the new mainline link road (Work No. 7) and on-slip from Barber’s Coppice Roundabout (Work No. 8).
I82Work No. 57 – as shown on Sheet Nos. 4 and 5 of the works plans and being the diversion of a local high pressure gas main due to the construction of the A45 Eastbound to M42 Northbound free flow link (Work No. 26).
I82Work No. 58 – as shown on Sheet Nos. 4 and 5 of the works plans and being the removal or relocation of a Gas Governor situated off the North West Quadrant of Junction 6 of the M42 due to the construction of the A45 Eastbound to M42 Northbound free flow link (Work No. 26).
I82Work No. 59 – as shown on Sheet No. 4 of the works plans and being the diversion of a medium pressure gas main due to the construction of the new free flow link road from the new mainline link road at Work No. 7 to the A45 Westbound carriageway (Work No. 21).
I82Work No. 60 – as shown on Sheet No. 4 of the works plans and being the diversion of a medium pressure gas main due to the construction of the A45 Pedestrian Overbridge and its associated ramps (Work No. 39).
I82Work No. 61 – as shown on Sheet No. 4 of the works plans and being the diversion of a medium pressure gas main due to the construction of the A45 Eastbound to M42 Northbound free flow link (Work No. 26).
I82Work No. 62 – as shown on Sheet No. 2 of the works plans and being the diversion of an aqueduct pipeline running east/west to the south of the A45 corridor, due to the construction of the new mainline link road (Work No. 7), the proposed pedestrian underpass (Work No. 40) and the new single lane plus hard-shoulder northbound diverge from the new mainline link road (Work No.10), connecting to the Airport Way connector road from the A45 Westbound to Airport Way (Work No.19.
I82Work No. 63 – as shown on Sheet No. 4 of the works plans and being the diversion of an aqueduct pipeline running east/west to the south of the A45 corridor, due to the construction of the new mainline link road (Work No. 7), the proposed pedestrian underpass (Work No. 40) and the new single lane plus hard-shoulder Northbound diverge from the new mainline link road (Work No. 10), connecting to the Airport Way connector road from the A45 Westbound to Airport Way (Work No. 19).
I82Work No. 64 – as shown on Sheet Nos. 4 and 5 of the works plans and being the diversion of 132kV overground electricity cables and associated infrastructure due to the construction of the proposed A45 Eastbound to M42 Northbound free flow link road (Work No.26).
I82Work No. 65 – as shown on Sheet No. 4 of the works plans and being the diversion of 132kV overground electricity cables and associated infrastructure due to the construction of the proposed A45 Eastbound to M42 Northbound free flow link road (Work No. 26).
I82Work No. 66 – as shown on Sheet No. 2 of the works plans and being the construction of a reinforced cover slab for the existing fuel line due to the realignment of the B4438 Catherine-de-Barnes Lane (Work No. 11).
I82Work No. 67 – as shown on Sheet No. 5 of the works plans and being works to extend the existing culvert for the Hollywell Brook running underneath the M42 corridor north of Junction 6 to be extended 8 metres to the west and 33 metres to the east respectively due to the works associated with the A45 Eastbound and the M42 Northbound free flow link road (Work No. 26) and the M42 Southbound to A45 Eastbound free flow link road (Work No.27) and the two lane diverge to the proposed East Way Roundabout (Work No. 28).
I82Work No. 68 – as shown on Sheet Nos. 2 and 3 of the works plans and being alterations to the existing Warwickshire Gaelic Athletic Association facilities known as Páirc na hÉireann, including the provision of reconfigured sports pitches.
I82Work No. 69 – as shown on Sheet Nos. 3 and 4 of the works plans and being the construction of a site compound situated on land to the south of the A45 corridor between Clock Interchange and the M42 Junction 6.
I82Work No. 70 – as shown on Sheet No. 2 of the works plans and being the construction of a temporary two lane single carriageway connecting Solihull Road to the new Junction 5A of the M42 (Work No. 6), to retain connectivity during demolition works to the existing Solihull Road Overbridge (Work No. 3).
I82Work No. 71 – as shown on Sheet No. 3 of the works plans and being the construction of a temporary two lane single carriageway to the east of the existing B4438 Catherine-de-Barnes Lane to retain connectivity during the construction of the realigned B4438 Catherine-de-Barnes Lane and associated structures (Work No. 13) including a temporary realignment of access to Shadowbrook Lane.
I82Work No. 72 – as shown on Sheet No. 3 of the works plans and being the construction of a temporary two lane single carriageway to the north of the proposed Catherine-de-Barnes North Overbridge (Work No. 16) to retain connectivity during the construction of the realigned Catherine-de-Barnes Lane and associated structures (Work No. 13).
I82Work No. 73 – as shown on Sheet Nos. 3 and 4 of the works plans and being the construction of a temporary two lane single carriageway to the east of the existing B4438 Catherine-de-Barnes Lane to enable the construction of the new mainline line road (Work No. 7) and maintain connectivity during the construction of the realigned Catherine-de-Barnes Lane and associated structures (Work No. 13).
I82Work No. 74 – as shown on Sheet No. 5 of the works plans and being the construction of a temporary realignment of the access to the National Exhibition Centre along South Way during the construction of the A45 Eastbound to M42 Northbound free flow link underpass (Work No. 26).
I82Work No.75 – as shown on Sheet No. 5 of the works plans and being the construction of a temporary realignment of the egress from the National Exhibition Centre on South Way during the construction of the A45 Eastbound to M42 Northbound free flow link underpass (Work No. 26).
I82Work No. 76 – as shown on Sheet No. 3 of the works plans and being the installation of a pumped system to mitigate for the loss of surface water catchment area to the Bickenhill Meadows SSSI – Shadowbrook Meadows unit. Works to feature collection drains and chambers, a pump station and a pressured pipeline to feed replacement water to an appropriate water feature in the vicinity of the SSSI.
I82For the purposes of or in connection with the construction of any of those works, further development within the Order limits which does not give rise to any materially new or materially different environmental effects to those assessed in the environmental statement, consisting of—
a
alteration of the layout of any street permanently or temporarily, including but not limited to increasing or reducing the width of the carriageway of the street by increasing or reducing the width of any kerb, footpath, footway, cycle track or verge within the street; altering the level or increasing the width of any such kerb, footpath, footway, cycle track or verge; and reducing the width of the carriageway of the street;
b
works required for the strengthening, improvement, repair, maintenance, or reconstruction of any street;
c
ramps, steps, means of access, private means of access, non-motorised user routes or links, footpaths, footways, bridleways, equestrian tracks, cycle tracks, open to all traffic, restricted byways, laybys and crossing facilities;
d
embankments, cuttings, viaducts, bridges, aprons, abutments, shafts, foundations, retaining walls, drainage works, drainage treatment areas, ponds, lagoons, outfalls, ditches, pollution control devices, pumping stations, wing walls, firefighting system water tanks and associated plant and equipment, highway lighting, fencing and culverts;
e
street works, including breaking up or opening a street, or any sewer, drain or tunnel under it; and tunnelling or boring under a street;
f
works to place, alter, divert, relocate, protect, remove or maintain the position of apparatus (including statutory undertakers’ apparatus), services, plant and other equipment in, under or above a street, or in other land, including mains, sewers, drains, pipes, lights, cables, cofferdams, fencing and other boundary treatments;
g
works to alter the course of, or otherwise interfere with a watercourse;
h
landscaping, re-grading, re-profiling, contouring, noise barriers, works associated with the provision of ecological and archaeological mitigation and other works to mitigate any adverse effects of the construction, maintenance or operation of the authorised development;
i
works comprising settlement monitoring and mitigation measures for the benefit or protection of, or in relation to, any land, building or structure, including monitoring and safeguarding of existing infrastructure, utilities and services affected by the authorised development;
j
works to place, alter, remove or maintain road furniture;
k
site preparation works, site clearance (including fencing and other boundary treatments, vegetation removal, demolition of existing structures and the creation of alternative highways or footpaths); earthworks (including soil stripping and storage and site levelling);
l
the felling of trees and hedgerows;
m
establishment of site construction compounds and working sites, temporary structures, storage areas (including storage of excavated material and other materials), temporary vehicle parking, construction fencing, perimeter enclosure, security fencing, construction related buildings, welfare facilities, office facilities, other ancillary accommodation, construction lighting, haulage roads and other buildings, machinery, apparatus, processing plant, works and conveniences;
n
the provisions of other works including pavement works, kerbing and paved areas works, signing, signals, gantries, street lighting, road restraints, road markings works, traffic management measures including temporary roads and such other works as are associated with the construction of the authorised development; and
o
such other works, working sites, storage areas, works of demolition or works of whatever nature, as may be necessary or expedient for the purposes of, or for purposes associated with or ancillary to, the construction, operation or maintenance of the authorised development.
SCHEDULE 2REQUIREMENTS
PART 1REQUIREMENTS
InterpretationI11
In this Schedule—
“Airport safeguarding zone” means land as shown on the safeguarding map issued for the purposes of the Town and Country Planning (Safeguarded Aerodromes, Technical Sites and Military Explosives Storage Areas) Direction 2002 and certified by the Civil Aviation Authority as the safeguarding map for Birmingham Airport;
“Birmingham Airport” means the civil aerodrome authorised to operate under certificate reference UK: EGBB – 001;
“Birmingham Airport Limited” means Company No. 02078273 of Diamond House, Birmingham Airport, Birmingham B26 3QJ;
“CEMP” means the construction environmental management plan;
“contaminated land” has the same meaning as that given in section 78A of the Environmental Protection Act 199083;
“Ecological Clerk of Works” has the meaning given in the OEMP;
“HEMP” means the handover environmental management plan;
“the Manual of Contract Documents for Highway Works” means the document of that name published electronically by the strategic highway authorities for England, Scotland, Wales and Northern Ireland, or any equivalent replacement published for that document;
“OEMP” means the outline environmental management plan referred to in Schedule 13 (documents to be certified) certified by the Secretary of State as the outline environmental management plan for the purposes of this Order; and
“REAC” means the register of environmental actions and commitments set out in section 3 of the OEMP.
Time limitsI22
The authorised development must commence no later than the expiration of 5 years beginning with the date that this Order comes into force.
Detailed designI33
1
The authorised development must be designed in detail and carried out so that it is compatible with the preliminary scheme design shown on the general arrangement plans, works plans and the engineering drawings and sections unless otherwise agreed in writing by the Secretary of State following consultation with the relevant planning authority and local highway authority on matters related to their functions and provided that the Secretary of State is satisfied that any amendments to the general arrangement plans, works plans and the engineering drawings and sections showing departures from the preliminary scheme design would not give rise to any materially new or materially different environmental effects in comparison with those reported in the environmental statement.
2
The Secretary of State must not approve any amended details under sub-paragraph (1) that exceed the maximum vertical limits of deviation shown on the works plans and on the engineering drawings and sections within the Airport safeguarding zone, unless the Secretary of State, following consultation with Birmingham Airport Limited, is satisfied that a deviation in excess of those limits would not adversely affect the safety of aircraft taking off or landing at, or flying in the vicinity of, Birmingham Airport or result in significant operational limitations being imposed on Birmingham Airport.
3
Where amended details are approved by the Secretary of State under sub-paragraph (1), those details are deemed to be substituted for the corresponding general arrangement plans, works plans or engineering drawings and sections and the undertaker must make those amended details available in electronic form for inspection by members of the public.
Outline Environmental Management PlanI44
1
The authorised development must be carried out in accordance with the OEMP.
2
The undertaker must make the CEMP and the HEMP produced in accordance with the OEMP available in an electronic form suitable for inspection by members of the public.
3
The CEMP must be written in accordance with ISO14001 and must—
a
reflect the mitigation measures set out in the REAC;
b
contain a record of all sensitive environmental features that have the potential to be affected by the construction of the proposed development;
c
require adherence to any working hours set out in the REAC or, where no such hours are set, to working hours of 07:00–18:00 on Mondays to Fridays and 08:00–13:00 on Saturday except for—
i
night-time closures for bridge and gantry demolition and installation;
ii
night-time lifting operations;
iii
site clearance of vegetation adjacent to live carriageways;
iv
site clearance of signs, street furniture and lighting column adjacent to live carriageways;
v
any oversize deliveries or deliveries where daytime working would be excessively disruptive to normal traffic operation;
vi
junction and highway tie-in works;
vii
installation of temporary and permanent line markings;
viii
installation of detector loops within the M42 carriageway;
ix
removal of overhead power lines;
x
overnight traffic management measures;
xi
any emergency works;
xii
work associated with the diversion of existing utilities;
xiii
works associated with traffic management and signal changes; and
xiv
as otherwise agreed by the local authority in advance;
d
include the following management plans—
i
Dust, Noise and Nuisance Management Plan;
ii
Site Waste Management Plan;
iii
Environmental Control Plan: Invasive Species;
iv
Environmental Control Plan: General Ecology;
v
Soil Management Plan;
vi
Surface Water Management Plan;
vii
Control Of Substances Hazardous to Health, Material, Waste Storage and Refuelling Plan;
viii
Energy and Resource Use Management Plan;
ix
Materials Management Plan;
x
Contaminated Land Management Plan;
xi
Archaeological Control Plan;
xii
Pollution Prevention Plan;
xiii
Bird Strike Management Plan;
xiv
Crane Management Plan;
xv
Biodiversity Management Plan; and
xvi
Compound Management Plan.
4
No part of the authorised development is to commence until a CEMP, substantially in accordance with the OEMP, has been submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority, Birmingham Airport Limited or Natural England to the extent that it relates to matters relevant to its function.
5
The construction of the authorised development must be carried out in accordance with the approved CEMP.
6
A HEMP must be developed and completed by the end of construction, commissioning and handover stage of the authorised development, in accordance with the process set out in the approved CEMP.
7
The HEMP must address the matters set out in the approved CEMP that are relevant to the operation and maintenance of the authorised development, and must contain—
a
the environmental information needed for the future maintenance and operation of the authorised development;
b
the long-term commitments to aftercare, monitoring and maintenance activities relating to the environmental features and mitigation measures that will be required to ensure the continued long-term effectiveness of the environmental mitigation measures and the prevention of unexpected environmental impacts during the operation of the authorised development; and
c
a record of the consents, commitments and permissions resulting from liaison with statutory bodies.
8
The authorised development must be operated and maintained in accordance with the HEMP.
LandscapingI55
1
No part of the authorised development is to commence until a landscaping scheme applicable to that part has been submitted to and approved in writing by the Secretary of State, following consultation with—
a
the relevant planning authority on matters related to its functions; and
b
where that part of the authorised development is comprised in the Airport safeguarding zone, Birmingham Airport Limited on matters relevant to the safety of aircraft taking off or landing, or flying in the vicinity of, Birmingham Airport.
2
The landscaping scheme must reflect the mitigation measures set out in the REAC and must be based on the proposed landscape planting strategy (figure 8.3) and the illustrative environmental masterplan (figure 8.8) annexed to the environmental statement (application document TR010027/APP/6.1).
3
The landscaping scheme prepared under sub-paragraph (1) must include details of—
a
location, number, species mix, size and planting density of any proposed planting;
b
cultivation, importing of materials and other operations to ensure plant establishment;
c
existing trees to be retained, with measures for their protection during the construction period;
d
proposed finished ground levels; and
e
implementation timetables for all landscaping works.
4
All landscaping works must be carried out to a reasonable standard in accordance with the relevant recommendations of appropriate British Standards.
5
Any tree or shrub planted as part of the landscaping scheme that, within a period of 5 years after planting, is removed, dies or becomes in the opinion of the relevant planning authority, seriously damaged or diseased, must be replaced in the first available planting season with a specimen of the same species and size as that originally planted, unless the Secretary of State, following consultation with the relevant planning authority on matters related to its function, gives consent to a variation.
Contaminated land and groundwaterI66
1
In the event that contaminated land, including groundwater, is found at any time when carrying out the authorised development which was not previously identified in the environmental statement, it must be reported as soon as reasonably practicable to the Secretary of State, the relevant planning authority and the Environment Agency, and the undertaker must complete a risk assessment of the contamination in consultation with the relevant planning authority and the Environment Agency.
2
Where the undertaker determines that remediation of the contaminated land is necessary, a written scheme and programme for the remedial measures to be taken to render the land fit for its intended purpose must be submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority on matters related to its function and the Environment Agency.
3
Remediation must be carried out in accordance with the approved scheme.
Protected speciesI77
1
In the event that any protected species which were not previously identified in the environmental statement or nesting birds are found at any time when carrying out the authorised development the undertaker must cease the relevant parts of the relevant works and report it immediately to the Ecological Clerk of Works (ECoW).
2
The relevant parts of the relevant works must not recommence until a written scheme of protection and mitigation measures (including their design and management) has been submitted to and approved in writing by the Secretary of State after consultation with Natural England.
3
The written scheme must provide for the implementation of appropriate measures to avoid harm to breeding birds and their nests under the supervision of the ECoW.
4
The undertaker must implement the written scheme prepared under sub-paragraph (2) immediately and construction in the area specified in the written scheme must not recommence until any necessary licences are obtained to enable mitigation measures to be implemented.
Surface and foul water drainageI88
1
No part of the authorised development is to commence until for that part written details of the surface and foul water drainage system, reflecting the mitigation measures set out in the REAC and drainage strategy report including means of pollution control, have been submitted and approved in writing by the Secretary of State following consultation with the relevant planning authority on matters related to its function.
2
The surface and foul water drainage system must be constructed in accordance with the approved details, unless otherwise agreed in writing by the Secretary of State following consultation with—
a
the relevant planning authority on matters related to its function; and
b
where the part of the authorised development to which the approved details relate is within the Airport safeguarding zone, Birmingham Airport Limited.
3
The Secretary of State may only agree to amendments to the approved details under sub-paragraph (2) if the Secretary of State is satisfied that—
a
the amendments would not give rise to any materially new or materially different environmental effects in comparison with those reported in the environmental statement; or
b
in a case where Birmingham Airport Limited has been consulted under sub-paragraph (2)(b), the amendments would not adversely affect the safety of aircraft taking off or landing at, or flying in the vicinity of, Birmingham Airport.
Archaeological remainsI99
1
No part of the authorised development is to commence until for that part a written scheme for the investigation of areas of potential archaeological interest has been submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority on matters related to its function.
2
The authorised development must be carried out in accordance with the scheme referred to in sub-paragraph (1).
Traffic managementI1010
1
No part of the authorised development is to commence until a traffic management plan for that part has been submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority on matters related to its function and the Royal Mail.
2
The authorised development must be constructed in accordance with the traffic management plan referred to in sub-paragraph (1).
Amendments to approved detailsI1111
With respect to any requirement which requires the authorised development to be carried out in accordance with the details or schemes approved under this Schedule, the approved details or schemes are taken to include any amendments that may subsequently be approved in writing by the Secretary of State.
FencingI1212
Any permanent and temporary fencing and other means of enclosure for the authorised development must be constructed and installed in accordance with the Manual of Contract Documents for Highway Works except where any departures from that manual are agreed in writing by the Secretary of State in connection with the authorised development.
Bickenhill Meadows SSSII1313
1
No part of the authorised development that affects Bickenhill Meadows SSSI is to commence until a detailed Bickenhill Meadows SSSI Monitoring Management Plan has been submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority and Natural England on matters related to its function.
2
The detailed Bickenhill Meadows SSSI Monitoring Management Plan must set out—
a
the requirements for the overarching biological and hydrological monitoring programme,
b
details of the establishment and role of the SSSI Monitoring Steering Group, and
c
details of trigger points and action measures which must be taken in the event that the trigger points are met or exceeded.
3
Monitoring of Bickenhill Meadows SSSI must be carried out in accordance with the detailed Bickenhill Meadows SSSI Monitoring Management Plan.
4
Work No. 76 can only be carried out if it has been determined, in accordance with the Bickenhill Meadows SSSI Monitoring Management Plan, that the passive solution to mitigate the loss of surface water catchment area has failed.
Relocation of Work No. 35 underground storage tank and accessI1414
1
Notwithstanding the details shown on any Certified Plan listed in Schedule 13 of this Order, no part of the realignment of Catherine-de-Barnes Lane is to commence until an amended scheme for the underground storage tank and associated access (Work No.35) is submitted to and approved in writing by the Secretary of State, following consultation with the relevant planning authority on matters related to its function and the occupiers of those properties affected by the change.
2
Unless otherwise agreed in writing by the Secretary of State, the amended scheme must provide for the relocation of the underground storage tank and access from the northern to the southern side of St Peter’s Lane.
3
The authorised development must be carried out in accordance with the approved scheme referred to in sub-paragraph (1).
PART 2PROCEDURE FOR DISCHARGE OF REQUIREMENTS
Applications made under requirementsI1515
1
Where an application has been made to the Secretary of State for any consent, agreement or approval required by a requirement (including consent, agreement or approval in respect of part of a requirement) included in this Order the Secretary of State must give notice to the undertaker of the decision on the application within a period of 8 weeks beginning with—
a
the day immediately following that on which the application is received by the Secretary of State;
b
the day immediately following that on which further information has been supplied by the undertaker under paragraph 16 (further information); or
c
such longer period as may be agreed between the parties.
2
Subject to sub-paragraph (3), in the event that the Secretary of State does not determine an application within the period set out in sub-paragraph (1), the Secretary of State is taken to have granted all parts of the application (without any condition or qualification) at the end of that period.
3
Where—
a
an application has been made to the Secretary of State for any consent, agreement or approval required by a requirement included in this Order;
b
the Secretary of State does not determine such application within the period set out in sub-paragraph (1); and
c
the application is accompanied by a report from a body required to be consulted under the requirement that considers it likely that the subject matter of the application would give rise to any materially new or materially different environmental effects in comparison with those reported in the environmental statement,
the application is taken to have been refused by the Secretary of State at the end of that period.
Further informationI1616
1
In relation to any part of an application made under this Schedule, the Secretary of State has the right to request such further information from the undertaker as is necessary to enable the Secretary of State to consider the application.
2
In the event that the Secretary of State considers such further information to be necessary the Secretary of State must, within 21 business days of receipt of the application, notify the undertaker in writing specifying the further information required and (if applicable) to which part of the application it relates. In the event that the Secretary of State does not give such notification within that 21 business day period the Secretary of State is deemed to have sufficient information to consider the application and is not subsequently entitled to request further information without the prior agreement of the undertaker.
3
Where further information is requested under this paragraph in relation to part only of an application, that part is treated as separate from the remainder of the application for the purposes of calculating the time periods referred to in paragraph 15 (applications made under requirements) and in this paragraph.
4
In this paragraph, “business day” means a day other than Saturday or Sunday which is not Christmas Day, Good Friday or a bank holiday under section 1 (bank holidays) of the Banking and Financial Dealings Act 1971.
Register of requirementsI1717
1
The undertaker must, as soon as practicable following the making of this Order, establish and maintain in an electronic form suitable for inspection by members of the public a register of those requirements contained in Part 1 of this Schedule that provide for further approvals to be given by the Secretary of State.
2
The register must set out in relation to each such requirement the status of the requirement, in terms of whether any approval to be given by the Secretary of State has been applied for or given, providing an electronic link to any document containing any approved details.
3
The register must be maintained by the undertaker for a period of 3 years following completion of the authorised development.
Anticipatory steps towards compliance with any requirementI1818
If before the coming into force of this Order the undertaker or any other person has taken any steps that were intended to be steps towards compliance with any provision of Part 1 of this Schedule, those steps may be taken into account for the purpose of determining compliance with that provision if they would have been valid steps for that purpose had they been taken after this Order came into force.
I83SCHEDULE 3STREETS SUBJECT TO STREET WORKS
Sch. 3 in force at 11.6.2020, see art. 1
(1) Authority | (2) Street subject to street works |
|---|---|
Solihull Metropolitan Borough Council | A45 Coventry Road (Eastbound) |
Solihull Metropolitan Borough Council | A45 Coventry Road (Westbound) |
Solihull Metropolitan Borough Council | B4102 Solihull Road |
Solihull Metropolitan Borough Council | B4438 Catherine-de-Barnes Lane |
Solihull Metropolitan Borough Council | Friday Lane |
Solihull Metropolitan Borough Council | B4102 Hampton Lane |
Solihull Metropolitan Borough Council | Unnamed Road (Access for Four Winds/Birmingham Dogs Home/Solihull Music School) |
Solihull Metropolitan Borough Council | Shadowbrook Lane |
Solihull Metropolitan Borough Council | St Peters Lane |
Solihull Metropolitan Borough Council | Clock Lane |
Solihull Metropolitan Borough Council | Clock Interchange |
Solihull Metropolitan Borough Council | B4438 Bickenhill Lane |
Solihull Metropolitan Borough Council | Airport Way connector road |
Solihull Metropolitan Borough Council | Unnamed Road (A45 Eastbound to Bickenhill Lane free flow link) |
Solihull Metropolitan Borough Council | Entrance to Arden Hotel off the A45 Eastbound |
Solihull Metropolitan Borough Council | M42 Junction 6 Interchange / Bickenhill Interchange |
Solihull Metropolitan Borough Council | East Way |
Solihull Metropolitan Borough Council | South Way |
Solihull Metropolitan Borough Council | Middle Bickenhill Lane |
Solihull Metropolitan Borough Council | Proposed new M42 Junction 5A Northbound off slip |
Solihull Metropolitan Borough Council | Proposed new M42 Junction 5A Southbound on slip |
Solihull Metropolitan Borough Council | Proposed new Junction 5A eastern roundabout |
Solihull Metropolitan Borough Council | Proposed new Junction 5A Overbridge |
Solihull Metropolitan Borough Council | Proposed new Junction 5A western roundabout |
Solihull Metropolitan Borough Council | Proposed new Mainline Link Road |
Solihull Metropolitan Borough Council | Realigned B4438 Catherine-de-Barnes Lane |
Solihull Metropolitan Borough Council | Realigned Catherine-de-Barnes Lane |
Solihull Metropolitan Borough Council | Proposed new Barber’s Coppice roundabout |
Solihull Metropolitan Borough Council | Proposed on slip to Mainline Link Road from Barber’s Coppice Roundabout |
Solihull Metropolitan Borough Council | Proposed new Bickenhill roundabout |
Solihull Metropolitan Borough Council | Proposed off slip from Mainline Link Road to Bickenhill roundabout |
Solihull Metropolitan Borough Council | Proposed new road from Mainline Link Road to Airport Way connector road |
Solihull Metropolitan Borough Council | Proposed new free flow link from Mainline Link Road to A45 Westbound |
Solihull Metropolitan Borough Council | Proposed new free flow link from A45 Eastbound to M42 Northbound |
Solihull Metropolitan Borough Council | Proposed new free flow link from M42 Southbound to A45 Eastbound |
Solihull Metropolitan Borough Council | Proposed new off slip from M42 Southbound to new East Way roundabout |
Solihull Metropolitan Borough Council | Proposed new East Way roundabout |
Solihull Metropolitan Borough Council | Proposed new local access road from Barber’s Coppice roundabout |
SCHEDULE 4CLASSIFICATION OF ROADS, ETC.
I84PART 1SPECIAL ROADS
Sch. 4 Pt. 1 in force at 11.6.2020, see art. 1
(1) Road | (2) Extent |
|---|---|
M42 Northbound | Between point 1/1 on Sheet 1 and point 7/1 on Sheet 7 of the classification of road plans. |
M42 Southbound | Between point 7/2 on Sheet 7 and point 1/2 on Sheet 1 of the classification of road plans. |
M42 Northbound off slip Junction 5A | Between points 2/1 and 2/6 on Sheet 2 of the classification of road plans. |
M42 Southbound on slip Junction 5A | Between points 2/4 and 2/2 on Sheet 2 of the classification of road plans. |
M42 Northbound off slip Junction 6 | Between point 3/15 on Sheet 3 and point 5/2 on Sheet 5 of the classification of road plans. |
M42 Northbound on slip Junction 6 | Between points 5/19 and 5/21 on Sheet 5 of the classification of road plans. |
M42 Southbound on slip Junction 6 | Between point 5/3 on Sheet 5 and point 3/14 on Sheet 3 of the classification of road plans. |
M42 Southbound off slip Junction 6 | Between point 6/2 on Sheet 6 and point 5/14 on Sheet 5 of the classification of road plans. |
A45 Eastbound to M42 Northbound Free Flow Link | Between point 5/1 on Sheet 5 and point 6/3 on Sheet 6 on the classification of road plans. |
M42 Southbound off slip to proposed East Way Roundabout | Between point 6/1 on Sheet 6 and point 5/20 on Sheet 5 of the classification of road plans. |
M42 Southbound off slip to A45 Eastbound on slip | Between points 5/15 and 5/13 on Sheet 5 of the classification of road plans. |
I85PART 2TRUNK ROADS
Sch. 4 Pt. 2 in force at 11.6.2020, see art. 1
(1) Road | (2) Extent |
|---|---|
New Southern Junction 5A East Roundabout | Entire circulatory carriageway at point 2/8 on Sheet 2 of the classification of road plans. |
New Southern Junction 5A West Roundabout | Entire circulatory carriageway at point 2/10 on Sheet 2 of the classification of road plans. |
New Southern Junction 5A Overbridge | Overbridge at point 2/9 on Sheet 2 of the classification of road plans, providing a connection between points 2/8 and 2/10 on Sheet 2 of the classification of road plans. |
New mainline link road Northbound | Between point 2/7 on Sheet 2 and point 4/2 on Sheet 4 of the classification of road plans. |
New mainline link road Southbound | Between point 4/3 on Sheet 4 and point 2/11 on Sheet 2 of the classification of road plans. |
New mainline link road Northbound on slip off Barber’s Coppice Roundabout | Between point 2/12 on Sheet 2 and point 3/1 on Sheet 3 of the classification of road plans. |
New mainline link road Southbound off slip to Bickenhill Roundabout | Between points 3/10 and 3/8 on Sheet 3 of the classification of road plans. |
New mainline link road Northbound off slip to Airport Way connector road | Between point 3/13 on Sheet 3 and point 4/26 on Sheet 4 of the classification of road plans. |
M42 Junction 6 Interchange | Entire circulatory carriageway at point 5/4 on Sheet 5 of the classification of road plans. |
A45 Eastbound | Between points 5/12 and 5/9 on Sheet 5 of the classification of road plans. |
A45 Westbound | Between points 5/8 and 5/6 on Sheet 5 of the classification of road plans. |
A45 Westbound off slip M42 Junction 6 | Between points 5/7 and 5/5 on Sheet 5 of the classification of road plans. |
A45 Eastbound on slip M42 Junction 6 | Between points 5/23 and 5/24 on Sheet 5 of the classification of road plans. |
Coventry Road | Between points 5/25 and 5/5 on Sheet 5 of the classification of road plans. |
I86PART 3CLASSIFIED ROADS
Sch. 4 Pt. 3 in force at 11.6.2020, see art. 1
(1) Road | (2) Extent |
|---|---|
B4102 Solihull Road | Between points 2/3 and 2/5 on Sheet 2 of the classification of road plans. |
Barber’s Coppice Roundabout | Entire roundabout at point 2/14 on Sheet 2 of the classification of road plans. |
B4438 Catherine-de-Barnes Lane | Between points 2/15 and 2/13 on Sheet 2 of the classification of road plans. |
B4438 Catherine-de-Barnes Lane | Between point 2/16 on Sheet 2 and point 3/4 on Sheet 3 of the classification of road plans. |
Bickenhill Roundabout | Entire roundabout at point 3/9 on Sheet 3 of the classification of road plans. |
Clock Interchange | Entire interchange at point 4/8 on Sheet 4 of the classification of road plans. |
A45 Westbound | Between point 5/6 on Sheet 5 and point 4/24 on Sheet 4 of the classification of road plans. |
B4102 Solihull Road | Between points 2/17 and 2/18 on Sheet 2 of the classification of road plans. |
Friday Lane | Between points 2/24 and 2/25 on Sheet 2 of the classification of road plans. |
B4102 Hampton Lane | Between points 2/23 and 2/22 on Sheet 2 of the classification of road plans. |
B4438 Catherine-de-Barnes Lane | Between points 2/21 and 2/20 on Sheet 2 of the classification of road plans. |
Catherine-de-Barnes Roundabout | Entire roundabout at point 2/19 on Sheet 2 of the classification of road plans. |
Bickenhill Lane Roundabout | Entire roundabout at point 4/12 on Sheet 4 of the classification of road plans. |
Bickenhill Lane Southbound | Between points 4/11 and 4/10 on Sheet 4 of the classification of road plans. |
Bickenhill Lane Northbound | Between points 4/15 and 4/13 on Sheet 4 of the classification of road plans. |
A45 Eastbound | Between point 4/22 on Sheet 4 and point 5/12 on Sheet 5 of the classification of road plans. |
New mainline link road Northbound off slip to A45 Westbound Free Flow Link | Between points 4/1 and 4/23 on Sheet 4 of the classification of road plans. |
A45 Westbound on slip | Between points 4/2 and 4/25 on Sheet 4 of the classification of road plans. |
A45 Westbound off slip | Between points 4/5 and 4/6 on Sheet 4 of the classification of road plans. |
A45 Eastbound on slip | Between points 4/9 and 4/7 on Sheet 4 of the classification of road plans. |
A45 Eastbound off slip | Between points 4/18 and 4/16 on Sheet 4 of the classification of road plans. |
A45 Eastbound free flow link to Bickenhill Lane | Between points 4/17 and 4/14 on Sheet 4 of the classification of road plans. |
A45 Eastbound off slip | Between point 4/28 on Sheet 4 and point 5/22 on Sheet 5 of the classification of road plans |
A45 Westbound on slip | Between point 5/2 on Sheet 4 and point 4/29 on Sheet 5 of the classification of road plans. |
I87PART 4UNCLASSIFIED ROADS
Sch. 4 Pt. 4 in force at 11.6.2020, see art. 1
(1) Road | (2) Extent |
|---|---|
Shadowbrook Lane | Between points 3/2 and 3/3 on Sheet 3 of the classification of road plans. |
St Peters Lane (South) | Between points 3/6 and 3/5 on Sheet 3 of the classification of road plans. |
St Peters Lane (North) | Between points 3/11 and 3/16 on Sheet 3 of the classification of road plans. |
Catherine-de-Barnes Lane | Between point 3/16 on Sheet 3 and point 4/27 on Sheet 4 of the classification of road plans. |
A45 Westbound off slip | Between points 4/4 and 4/21 on Sheet 4 of the classification of road plans. |
A45 Eastbound on slip | Between points 4/20 and 4/19 on Sheet 4 of the classification of road plans. |
Middle Bickenhill Lane | Between points 5/10 and 5/11 on Sheet 5 of the classification of road plans. |
East Way | Between points 5/16 and 5/17 on Sheet 5 of the classification of road plans. |
Access to Birmingham Dog’s Home, Four Winds and Solihull Music School off Barber’s Coppice Roundabout | Between points 2/27 and 2/28 on Sheet 2 of the classification of road plans. |
East Way Roundabout | Entire roundabout at point 5/18 shown on Sheet 5 of the classification of road plans. |
Catherine-de-Barnes Lane | Between points 3/7 and 3/12 on Sheet 3 of the classification of road plans. |
Access off B4102 Solihull road | At point 2/29 on Sheet 3 of the classification of road plans for access to two residential properties known as Woodside and Mayfield. |
I88PART 5SPEED LIMITS
Sch. 4 Pt. 5 in force at 11.6.2020, see art. 1
(1) Road name, number and length | (2) Speed limit |
|---|---|
Proposed eastbound and westbound lanes of Solihull road, south of proposed M42 Junction 5A, comprising a length of 675 metres, shown as a dashed cyan line on Sheet 2 of the Traffic Regulation Measures, Speed Limits Plans. | 50 miles per hour |
Proposed east and west dumb-bell roundabouts (including connector road between roundabouts) for the proposed Junction 5A on the M42, comprising a length of 655 metres, shown as a dashed blue line on Sheet 2 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Proposed northbound dual carriageway mainline link road, comprising a length of 2400 metres, shown as a dashed blue line on Sheets 2, 3 and 4 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Proposed southbound dual carriageway mainline link road, comprising a length of 2400 metres, shown as a dashed blue line on Sheets 2, 3 and 4 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Part of the proposed northbound merge from Barber’s Coppice roundabout to the northbound mainline link road up to the back of nosing, comprising a length of 355 metres, shown as a dashed green line on Sheet 2 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Part of the proposed northbound merge from the back of the nosing of the northbound mainline link road to the end of the merge, comprising a length of 335 metres, shown as a dashed blue line on Sheets 2 and 3 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Proposed Barber’s Coppice roundabout, comprising a length of 190 metres, shown as a dashed green line on Sheet 2 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Proposed northbound and southbound lanes of realigned B4438 Catherine-de-Barnes Lane, south west of Barber’s Coppice roundabout, comprising a length of 240 metres, shown as a dashed cyan line on Sheet 2 of the Traffic Regulation Measures, Speed Limits Plans. | 50 miles per hour |
Proposed east and westbound lanes and north and southbound lanes of the unclassified road, west and north west of Barber’s Coppice roundabout, comprising a length of 150 metres, shown as dashed brown lines on Sheets 2 and 3 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
Proposed northbound and southbound lanes of the realigned B4438 Catherine-de-Barnes Lane, north of Barber’s Coppice roundabout and south of Bickenhill roundabout, comprising a length of 765 metres, shown as dashed green lines on Sheets 2 and 3 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Proposed eastbound and westbound lanes of the proposed Shadowbrook Lane comprising a length of 125 metres, shown as a dashed green line on Sheet 3 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Proposed Bickenhill roundabout, comprising a length of 140 metres, shown as a dashed brown line on Sheet 3 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
Proposed eastbound and westbound lanes of St Peters Lane, east of Bickenhill roundabout, comprising a length of 50 metres, shown as a dashed brown line on Sheet 3 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
Proposed southbound diverge from the southbound dual carriageway mainline link road to Bickenhill roundabout, comprising a length of 510 metres, shown as a dashed blue line on Sheet 3 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Proposed northbound and southbound lanes of the realigned Catherine-de-Barnes Lane, north of Bickenhill roundabout up to the junction with St Peters Lane north, comprising a length of 495 metres, shown as a dashed brown line on Sheet 3 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
Proposed east and westbound lanes of St Peters Lane and north and southbound lanes of the Realigned Catherine-de-Barnes Lane, comprising a length of 290 metres, shown as dashed brown lines on Sheets 3 and 4 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
Part of the proposed free flow link from the mainline link road to the Airport Way connector road, comprising a length of 490 metres, shown as dashed blue lines on Sheets 3 and 4 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Part of the proposed free flow link from the mainline link road to the Airport Way connector road, comprising a length of 150 metres, shown as a dashed green line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Part of the proposed segregated left turn lane from northbound mainline link to A45 westbound, comprising a length of 145 metres, shown as a dashed blue line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 70 miles per hour |
Part of the proposed segregated left turn lane from northbound mainline link to A45 westbound, comprising a length of 620 metres, shown as a dashed cyan line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 50 miles per hour |
Proposed A45 eastbound free flow link to Bickenhill Lane westbound, comprising a length of 390 metres, shown as a dashed green line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Realigned Bickenhill Lane northbound, comprising a length of 230 metres, shown as a dashed green line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Realigned Bickenhill Lane southbound, comprising a length of 230 metres, shown as a dashed green line on Sheet 4 of the Traffic Regulation Measures, Speed Limits Plans. | 40 miles per hour |
Proposed A45 eastbound to M42 northbound free flow link diverge up to the tip of the nosing along the M42 Junction 6 northbound on slip, comprising a length of 670 metres, shown as a dashed cyan line on Sheets 4 and 5 of the Traffic Regulation Measures, Speed Limits Plans. | 50 miles per hour |
Part of the proposed M42 southbound to A45 eastbound free flow link (merge), east of Junction 6, comprising a length of 465 metres, shown as a dashed black line on Sheet 5 of the Traffic Regulation Measures, Speed Limits Plans. | 60 miles per hour |
Proposed East Way Roundabout, including the eastern approaches/departures from the roundabout, comprising a length of 320 metres, shown as a dashed brown line on Sheet 5 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
A realigned section of the Middle Bickenhill Lane from the proposed T-junction on the East Way to the Middle Bickenhill Lane, comprising a length of 135 metres, shown as a dashed brown line on Sheet 5 of the Traffic Regulation Measures, Speed Limits Plans. | 30 miles per hour |
I89PART 6PUBLIC RIGHTS OF WAY
Sch. 4 Pt. 6 in force at 11.6.2020, see art. 1
(1) Public right of way | (2) Extent |
|---|---|
Public footpath | Between points 4/3 and 4/10 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Footway/cycleway | Between points 4/10, 4/11 and 4/13 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Public Right of Way and footway | Between points 3/16 and 3/21 and footway between points 3/19, 3/17 and 3/15 shown on the Streets, Rights of Way and Access Plans. |
Public Right of Way and footway | Between points 3/14 and 3/21 and footway between points 3/19, 3/17 and 3/13 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way and footway/cycleway | Between points 3/5 and 3/20 and footway/cycleway between points 3/20 and 3/34 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way | Between points 3/2, 3/3 and 3/5 shown on Sheet 3 of the Streets, Right of Way and Access Plans. |
Public Right of Way, footway and footway/cycleway | Between points 2/16 and 2/12 (footway/cycleway), between points 2/11 and 2/10, between points 2/5 and 2/6 (footway), between 2/10 and 2/5 (footway), between 2/5 and 2/6 (footway/cycleway) shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Footpath, footway/cycleway | Between points 2/4, 2/5 and 2/6 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Footway/cycleway | Between points 2/12 and 3/3, between points 3/3 and 3/20, between points 3/20 and 3/7, between points 3/7 and 3/6, between points 3/6 and 3/8 and between points 3/9, 3/10 and 3/11 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Footway | Between points 3/11 and 3/17, 3/19 and 3/21 and 3/23 and 3/25 shown on Sheets 3 and 4 of the Streets, Rights of Way and Access Plans. |
Footway/cycleway | Between points 4/6, 4/26 and 4/8 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Footway/cycleway | Between points 4/4, 4/5 and 4/26 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Footway | Between points 5/7 and 5/8 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
I90SCHEDULE 5STREETS TO BE TEMPORARILY STOPPED UP
Sch. 5 in force at 11.6.2020, see art. 1
(1) Street to be stopped up | (2) Extent of stopping up |
|---|---|
B4102 Solihull Road | Between points A16 and A17 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
SCHEDULE 6PERMANENT STOPPING UP OF STREETS, PUBLIC RIGHTS OF WAY AND PRIVATE MEANS OF ACCESS
I91PART 1STREETS TO BE STOPPED UP AND FOR WHICH A SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 1 in force at 11.6.2020, see art. 1
(1) Street to be stopped up | (2) Extent of stopping up | (3) New street to be substituted or provided |
|---|---|---|
B4438 Catherine-de-Barnes Lane | Existing section of public road, to be stopped up between points A/1 and A/2 and between points A/3 and A/4 shown on Sheets 2 and 3 of the Streets, Rights of Way and Access Plans. | Realigned B4438 Catherine-de-Barnes Lane between points A/5 and A/6, between points A/7 and A/8 and between points A/8 and A/9 shown on Sheets 2 and 3 of the Streets, Rights of Way and Access Plans. |
Shadowbrook Lane | Existing section of public road, to be stopped up between points A/10 and A/11 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Shadowbrook Lane between points A/12 and A/13 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
St Peters Lane Northern Junction | Existing section of public road, to be stopped up between points A/4 and A/14 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Realigned Catherine-de-Barnes Lane and St Peters Lane Northern Junction between points A/9 and A/15 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
M42 Junction 6 slip to East Way | Existing section of public road, to be stopped up between points A/23 and A/24 and between points A/25 and A/26 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. | East Way between points A/27 and A/28 and M42 Junction 6 slip to East way between points A/29 and A/30 shown on Sheets 5 and 6 of the Streets, Rights of Way and Access Plans. |
I92PART 2STREETS TO BE STOPPED UP AND FOR WHICH NO SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 2 in force at 11.6.2020, see art. 1
(1) Streets to be stopped up | (2) Extent of stopping up |
|---|---|
B4438 Catherine-de-Barnes Lane to Clock Interchange | Existing section of public road, to be stopped up between points A/18 and A/19 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
M42 Junction 6 slip to Middle Bickenhill Lane | Existing section of public road, to be stopped up between points A/20 and A/21 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
I93PART 3PUBLIC RIGHTS OF WAY TO BE STOPPED UP AND FOR WHICH A SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 3 in force at 11.6.2020, see art. 1
(1) Public right of way to be stopped up | (2) Extent of stopping up | (3) New public right of way to be substituted or provided |
|---|---|---|
Public Right of Way M106 North of Bickenhill | Public Right of Way M106 to be stopped up between points 4/3 and 4/22 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be realigned via points 4/3 and 4/10 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Public Right of Way at Clock Interchange | Public Right of Way to be stopped up between points 4/22 and 4/14 on the eastern side of Clock Interchange and between points 4/24 and 4/25 on the western side of Clock Interchange shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be provided via points 4/3 and 4/10, with a new Public Right of Way to be provided via 4/11 and 4/13 to go to point 4/14 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Public Right of Way M109 West of the existing B4438 Catherine-de-Barnes Lane | Public Right of Way M109 to be stopped up between points 3/16 and 3/15 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be realigned via points 3/16, 3/21, 3/19, 3/17 and 3/15 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way M112 West of the exiting B4438 Catherine-de-Barnes Lane | Public Right of Way M112 to be stopped up between points 3/14 and 3/13 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be realigned via points 3/14, 3/21, 3/19, 3/17 and 3/13 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way M113 West of the existing B4438 Catherine-de-Barnes Lane | Public Right of Way M113 to be stopped up between points 3/5 and 3/34 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be realigned via points 3/5, 3/20 and 3/34 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way M113a West of the existing B4438 Catherine-de-Barnes Lane | Public Right of Way M113a to be stopped up in its entirety between points 3/2 and ¾ shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Public Right of Way to be provided via points 3/2, 3/5 and 3/4 shown on Sheet 3 of the Streets, Right of Way and Access Plans. |
Public Right of Way M122 East of the existing B4438 Catherine-de-Barnes Lane | Public Right of Way M122 to be stopped up between points 2/16 and 2/6 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. | Public right of way to be aligned via points 2/16, 2/12, 2/11, 2/10, 2/5 and to 2/6 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Public Right of Way M123 north east of Catherine-de-Barnes | Existing section of Public Right of Way M123 to be stopped up between points 2/4 and 2/6 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. | A new pedestrian footpath is provided between points 2/4, 2/5 and 2/6 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Public Right of Way along the existing B4438 Catherine-de-Barnes Lane | Public Right of Way along the length of the existing B4438 Catherine-de-Barnes Lane between points 2/15 and 3/1 shown on Sheets 2 and 3 of the Streets, Rights of Way and Access Plans to be stopped up. | A new public right of way to be provided via points 2/12 and 3/3 shown on Sheets 2 and 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way adjacent to Catherine-de-Barnes Lane (B4438) | Existing section of public right of way to be stopped up between points 3/11 and 3/25 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new public right of way is provided between points 3/11 and 3/17, 3/19 and 3/21 and 3/23 and 3/25 shown on Sheets 3 and 4 of the Streets, Rights of Way and Access Plans. |
St Peters Lane north | Existing section of the public right of way between 3/18 and 3/24 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new public right of way is provided between points 3/18 and 3/17, 3/19 and 3/21 and 3/23 and 3/25 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Public Right of Way along Airport Way connector road | Existing section of public right of way, to be stopped up between points 4/6 and 4/8 and between points 4/7 and 4/8 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | A new public right of way is provided between points 4/6, 4/26 and 4/8 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Public Right of Way west of Clock Interchange | Existing section of public footway, to be stopped up between points 4/4 and 4/9 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | East west connectivity between the A45 Coventry road and Airport way connector road to be provided between points 4/4, 4/5, 4/26, 4/8 and 4/9 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Public Right of Way east of M42 Junction 6 | Existing section of public Right of Way to be stopped up between points 5/7 and 5/8 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. | A new Public Right of Way provided between points 5/7 and 5/8 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
I94PART 4PUBLIC RIGHTS OF WAY TO BE STOPPED UP AND FOR WHICH NO SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 4 in force at 11.6.2020, see art. 1
(1) Public right of way to be stopped up | (2) Extent of stopping up |
|---|---|
Public Right of Way west and north west of M42 Junction 6 | Existing section of public footway, to be stopped up between points 4/12 and 5/1 shown on Sheets 4 and 5 of the Streets, Rights of Way and Access Plans. |
Public Right of Way east of M42 Junction 6 | Existing section of public footway, to be stopped up between points 5/4 and 5/2, and between points 5/2 and 5/6 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
I95PART 5PRIVATE MEANS OF ACCESS TO BE STOPPED UP AND FOR WHICH A SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 5 in force at 11.6.2020, see art. 1
(1) Private means of access to be stopped up | (2) Extent of stopping up | (3) New private means of access to be substituted or provided |
|---|---|---|
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to land South of the residential property ‘Heath End House’. | Field Access to be stopped up at point 3/56 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Access to this field to be maintained by relocated access at 3/57 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (gate) to land associated with the Warwickshire Gaelic Athletic Association facility off the existing B4438 of Catherine-de-Barnes Lane. | Private Means of Access to Warwickshire Gaelic Athletic Association facility to be stopped up at point 3/29 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Access to the Warwickshire Gaelic Athletic Association facility to be maintained via Private Means of Access points 3/54 and 3/35 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane for land South of the Airport Way connector road and East of the New Link road. | Field Access gate at point 4/19 to be stopped up shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | Access to the land to be provided via point 3/20 on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off Solihull Road providing access to scheduled ancient woodland. | Field Access at point 2/18 to be stopped up shown on Sheet 2 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 2/19 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to the East of Birmingham Dogs Home. | Field Access at point 2/20 to be stopped up shown on Sheet 2 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 2/21 shown on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to land East off the residential property ‘Four Winds’. | Field Access at point 2/16 to be stopped up shown on Sheet 2 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 3/57 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to land to the south of the Warwickshire Gaelic Athletic Association facility. | Field Access off B4438 Catherine-de-Barnes at point 3/39 to be stopped up shown on Sheet 3 of the Streets, Right of Way and Access Plans. | Access to existing field gate is to be provided at point 3/59 off realigned Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (No.1) off the existing B4438 Catherine-de-Barnes Lane to the Warwickshire Gaelic Athletic Association facility. | Private Means of Access off B4438 Catherine-de-Barnes at point 3/54 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Private Means of Access is to be provided at point 3/54 from new Private Means of Access 3/1 off realigned Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (No.2) off the existing B4438 Catherine-de-Barnes Lane to the Warwickshire Gaelic Athletic Association facility. | Private Means of Access off B4438 Catherine-de-Barnes at point 3/34 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Private Means of Access is to be provided at point 3/35 from new Private Means of Access 3/1 off Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) (No.2) off the existing B4438 Catherine-de-Barnes Lane providing access to land opposite Bracey’s Garden Centre to the west of Catherine-de-Barnes Lane. | Field Access at point 3/40 to be stopped up shown on Sheet 3 of the Streets, Right of Way and Access Plans. | A new Field Access is to be provided at point 3/41 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to land West of Bickenhill Roundabout. | Field Access at point 3/45 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 3/46 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access off the existing B4438 Catherine-de-Barnes Lane, south of Haven Caravan Park, providing access to land adjacent to the Bickenhill Meadows SSSI First Castle Meadow unit. | Field Access at point 3/47 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 3/48 shown on Sheet 3 of the Streets, Rights of Way and Access Plans and a new Field Access for the existing landowner to be provided at point 3.37 for essential mitigation. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane 10m south of the access into the Haven Caravan Park to land previously used by Birmingham Exiles Rugby Union Football Club. | Private Means of Access at point 3/51 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided off new Private Means of Access at point 3/52 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off the existing B4438 Catherine-de-Barnes Lane providing access to ‘The Haven Caravan Park’. | Private Means of Access at point 3/55 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Private Means of Access is to be provided at point 3/22 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off St Peters Lane providing access to land South of Clock Interchange and East of the mainline link road. | Field Access at point 3/53 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | A new Field Access to land is to be provided at point 3/20 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the A45 Coventry road to the East of the Arden Hotel. | Field Access at point 4/20 to be stopped up shown on Sheet 4 of the Streets, Rights of Way and Access Plans. | A new Field Access is to be provided at point 4/21 shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
I96PART 6PRIVATE MEANS OF ACCESS TO BE STOPPED UP AND FOR WHICH NO SUBSTITUTE IS TO BE PROVIDED
Sch. 6 Pt. 6 in force at 11.6.2020, see art. 1
(1) Private means of access to be stopped up | (2) Extent of stopping up |
|---|---|
Private Means of Access off the existing B4438 Catherine-de-Barnes Lane to the residential property ‘Heath End House’. | Private Means of Access to Heath End House to be stopped up at point 3/28 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (gate) off Shadowbrook Lane to the residential property ‘Heath End House’. | Private Means of Access to Heath End House to be stopped up at point 3/31 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. Access to land to be maintained via existing Private Means of Access at point 3/32 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off the A45 to Cadent Gas local gas Governor. | Private Means of Access to Cadent Gas local gas Governor to be stopped up at point 5/13 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. This is based on current assumption that the gas Governor can be decommissioned and no new access is required. |
Private Means of Access off the M42 Junction 6 slip road to Middle Bickenhill Lane. | Private Means of Access off M42 Junction 6 slip road to Middle Bickenhill Lane at point 5/16 to be stopped up shown on Sheet 5 of the Streets, Rights of Way and Access Plans. Access to this commercial property to be maintained via existing Private Means of Access points 5/17 and 5/18 shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) (No. 1) off the existing B4438 Catherine-de-Barnes Lane providing access to land opposite Bracey’s Garden Centre to the west of Catherine-de-Barnes Lane. | Field Access at point 3/36 to be stopped up shown on Sheet 3 of the Streets, Right of Way and Access Plans. |
I97PART 7ALTERATIONS TO PRIVATE MEANS OF ACCESS
Sch. 6 Pt. 7 in force at 11.6.2020, see art. 1
(1) Private means of access to be altered | (2) Extent of alteration |
|---|---|
Private Means of Access (gate) off the existing B4438 Catherine-de-Barnes Lane providing access to the residential property ‘Four Winds’. | Private Means of Access at point 3/58 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes Lane for access to the north of the residential property ‘Four Winds’. | Field Access off B4438 Catherine-de-Barnes Lane at point 3/2 to be stopped up shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access to residential property ‘Four Winds’. | Private Means of Access to be stopped up at point 2/13 on Sheet 2 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off Shadowbrook Lane to residential property ‘Oak Tree Lodge’. | Private Means of Access at point 3/30 to be altered to suit the realignment of Shadowbrook Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off the existing B4438 Catherine-de-Barnes Lane to the residential property ‘The Dale’. | Private Means of Access at point 3/33 to be altered to suit the realignment of the B4438 Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off the existing B4438 Catherine-de-Barnes Lane to Bracey’s Nursery Garden Centre. | Private Means of Access at point 3/26 to be altered to suit the realignment of the B4438 Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off St Peters Lane to Bracey’s Nursery Garden Centre. | Private Means of Access at point 3/42 to be altered to suit the realignment of St Peters Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off St Peters Lane to land East of Bracey’s Nursery Garden Centre. | Field Access at point 3/43 to be altered to suit the realignment of St Peters Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Private Means of Access off St Peters Lane to the residential property ‘Providence Cottage’. | Private Means of Access at point 3/44 to be altered to suit the realignment of St Peters Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access (gate) off the existing B4438 Catherine-de-Barnes identified at point 3/50 shown on Sheet 3 of the Streets, Rights of Way and Access Plans. | Field Access off Catherine-de-Barnes Lane at point 3/50 to be altered to suit the realignment of the Catherine-de-Barnes Lane shown on Sheet 3 of the Streets, Rights of Way and Access Plans. |
Field Access to land between the Airport Way connector road and the A45 westbound slip road from Clock Interchange. | Field Access at point 4/17 to be realigned to point 4/18 due to the introduction of new free flow link from the new mainline link road to the A45 westbound shown on Sheet 4 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (gate) providing access to land on the North East Quadrant of the M42 Junction 6 South of East Way. | Private Means of Access at point 5/14 off East Way to be altered to suit a connection to the proposed East Way Roundabout shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (gate) to land East of Middle Bickenhill Lane and North of the A45 Coventry road. | Private Means of Access at point 5/15 off Middle Bickenhill Lane to be altered to suit the Middle Bickenhill Lane being converted to two way traffic flow shown on Sheet 5 of the Streets, Rights of Way and Access Plans. |
Private Means of Access (gate) to land north of Birmingham Dogs’ Home. | Private Means of Access to be altered between points 2/15 and 3/4 shown on Sheets 2 and 3 of the Streets, Rights of Way and Access Plans. |
SCHEDULE 7CLEARWAYS, PROHIBITIONS AND RESTRICTIONS
I98PART 1TRAFFIC REGULATION MEASURES (CLEARWAYS AND PROHIBITIONS)
Sch. 7 Pt. 1 in force at 11.6.2020, see art. 1
(1) Road name, number and length | (2) Measures |
|---|---|
Proposed east and west dumbbell roundabouts (including connector road between roundabouts) for the proposed Junction 5A on the M42, comprising a length of 655 metres, shown as a dashed blue line on Sheet 2 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Proposed northbound dual carriageway mainline link road, comprising a length of 2400 metres, shown as a dashed blue line on Sheet 2, 3 and 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Proposed southbound dual carriageway mainline link road, comprising a length of 2400 metres shown as a dashed blue line on Sheet 2, 3 and 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Proposed northbound merge from Barber’s Coppice roundabout to the northbound mainline link road, comprising a length of 690 metres, shown as a dashed blue line on Sheets 2 and 3 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Proposed southbound diverge from the southbound dual carriageway mainline link road to Bickenhill roundabout, comprising a length of 510 metres, shown as a dashed blue line on Sheet 3 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
The proposed Free Flow Link from the northbound dual carriageway mainline link road to the Airport Way connector road, comprising a length of 640 metres, shown as a dashed blue line on Sheet 3 and 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Part of proposed segregated left turn lane to A45 Westbound, comprising a length of 180 metres, shown as a dashed blue line on Sheet 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Part of proposed segregated left turn lane to A45 Westbound, comprising a length of 585 metres, shown as a dashed magenta line on Sheet 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Proposed A45 eastbound Free Flow Link to Bickenhill Lane westbound, comprising a length of 390 metres, shown as a dashed orange line on Sheet 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route |
Realigned Bickenhill Lane northbound, comprising a length of 230 metres shown as a dashed orange line on Sheet 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route |
Realigned Bickenhill Lane southbound, comprising a length of 230 metres shown as a dashed orange line on Sheet 4 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route |
A45 Eastbound to M42 northbound Free Flow Link, comprising a length of 210 metres, shown as a dashed magenta line on Sheets 4 and 5 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | Red Route Clearway (to include verges and hard strips) |
Junction 5A Western Roundabout. | Prohibition of entry from the western Roundabout of Junction 5A (Work No. 6) to the northbound diverge off the M42 (Work No. 4), as shown on Sheet 2 of the Traffic Regulation Measures (Clearways & Weight Limits) Plans |
Bickenhill Roundabout | Prohibition of entry from Bickenhill Roundabout (Work No. 14) to the southbound diverge off the mainline link road (Work No. 7), as shown on Sheet 3 of the Traffic Regulation Measures (Clearways & Weight Limits) Plans |
M42 Northbound to A45 Westbound | Prohibition of entry onto the free flow link from the M42 northbound to the A45 Westbound, as shown on Sheet 5 of Traffic Regulation Measures (Clearways & Weight Limits) Plans |
East Way Roundabout | Prohibition of entry from the relocated East Way Roundabout (Work No. 30(b)) to the southbound diverge off M42 (Work No. 28), as shown on Sheet 5 of Traffic Regulation Measures (Clearways & Weight Limits) Plans |
I99PART 2TRAFFIC REGULATION MEASURES (WEIGHT RESTRICTIONS)
Sch. 7 Pt. 2 in force at 11.6.2020, see art. 1
(1) Road name, number and length | (2) Measures |
|---|---|
Eastern Link from Bickenhill roundabout to the existing St Peters Lane south, comprising a length of 50 metres, shown as a dashed green line on Sheet 3 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | 7.5 tonne weight restriction (except for access) |
A section of St Peter’s Lane east of Catherine-de-Barnes Lane north Overbridge, comprising a length of 55m, shown as a dashed green line on Sheet 3 of the Traffic Regulation Measures, Clearways and Weight Limits Plans. | 7.5 tonne weight restriction (except for access) |
I100SCHEDULE 8LAND IN WHICH ONLY NEW RIGHTS ETC. MAY BE ACQUIRED
Sch. 8 in force at 11.6.2020, see art. 1
(1) Plot Reference Number shown on Land Plans | (2) Purpose for which rights over land may be acquired |
|---|---|
Land Plans – Sheet 2 | |
2/2c, 2/3c | To construct, operate, access and maintain a diversion to an existing local high pressure gas main (Work No. 55). |
2/3o, 2/10c, 2/29, 2/30 | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with Work No. 3). |
2/3u, 2/3ah | To construct, operate, access and maintain diversion to an existing local high pressure gas main (Work No. 56) and an existing aqueduct pipeline (Work No. 62). |
To construct, operate, access and maintain a reinforced cover slab for an existing fuel pipeline (Work No. 66) and to maintain access to the pipeline. | |
2/3aa | To access land to be used for the construction, operation and maintenance of drainage attenuation and treatment systems (Work No. 33). |
To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 56) and an existing aqueduct pipeline (Work No. 62). | |
Land Plans – Sheet 3 | |
3/4b | To access land to be used for the construction, operation and maintenance of drainage attenuation and treatment systems (Work No. 33). |
To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 56) and an existing aqueduct pipeline (Work No. 62). | |
3/4f | To access land to be used for the construction, operation and maintenance of drainage attenuation and treatment systems (Work No. 33). |
3/22a, 3/22b | To access land to be used in connection with the provision, maintenance and retention of mitigation within Bickenhill Meadows SSSI - Shadowbrook Meadows unit (Work No.76). |
3/23, 3/73d, 3/73f | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). |
3/25 | To access land to be used for the provision, maintenance and retention of mitigation in connection with Bickenhill Meadows site of special scientific interest (works associated with the authorised development). |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
3/87a | To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 57) and existing electric lines, cables, equipment and apparatus (Works Nos. 64 and 65). |
Land Plans – Sheet 4 | |
4/1c, 4/1bf, 4/3b, 4/3c, 4/3s, 4/3x, 4/3ai, 4/3aj, 4/6n, 4/6p, 4/9, 4/10, 4/158, 4/159 | To construct, operate, access and maintain a diversion to an existing medium pressure gas main (Work No. 59). |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/1d, 4/25a | To access land to be used for the construction, maintenance and retention of environmental mitigation at the existing Clock Interchange (works associated with Work No. 20). |
4/1f | To access to and over land to be used for the construction, operation and maintenance of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (Work No. 22). |
To take access to and over land to be used for the construction, operation and maintenance of alterations to the existing Bickenhill Lane carriageway (Works Nos. 23 and 24). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/1g | To take access to and over land to be used for the construction, operation and maintenance of improvements to the existing Clock Interchange (Work No. 20). |
To take access to and over land to be used for the construction, operation and maintenance of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (Work No. 22). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/1h, 4/1m, 4/1q, 4/1s, 4/1t, 4/1u, 4/1v, 4/1w, 4/1x, 4/1am, 4/1ap, 4/1as, 4/1bb, 4/3e. 4/3f, 4/3g, 4/3h, 4/3j, 4/3k, 4/3m, 4/3ab, 4/3ae, 4/4g, 4/4n, 4/4v, 4/4x, 4/6b, 4/6e, 4/6f, 4/6g, 4/6h, 4/7a, 4/11a, 4/25b, 4/25d, 4/25e, 4/25g, 4/25i, , 4/25l, 4/25m, 4/25s, 4/62, 4/66, 4/69, 4/71, 4/73, 4/76, 4/80, 4/89, 4/91, 4/93, 4/94, 4/99, 4/102, 4/106, 4/109, 4/147, 4/150, 4/151, 4/152, 4/153, 4/155 | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). |
4/1k | To construct, operate, access and maintain a diversion to an existing medium pressure gas main (Work No. 60). |
4/25o, 4/25j, 4/25p, 4/25n | To access land to be used for the construction, operation and maintenance of a pedestrian overbridge (Work No. 39 and the installation of a new gantry (Work No. 2)). |
4/1n, 4/1r, 4/82 | To access land to be used for the construction, operation and maintenance of a pedestrian overbridge (Work No. 39). |
To construct, operate, access and maintain a diversion to an existing medium pressure gas main (Work No. 60). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/lz | To take access to and over land to be used for the construction, operation and maintenance of improvements to the existing Clock Interchange (Work No. 20). |
To take access to and over land to be used for the construction, operation and maintenance of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (Work No. 22). | |
4/1ab, 4/1ac | To take access to and over land to be used for the construction, operation and maintenance of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (Work No. 22). |
4/1aq, 4/1bc | To construct, operate, access and maintain a realignment to a private means of access due to the construction of a new free flow link road at Work No. 21 (works associated with the authorised development). |
4/1az, 4/1ba | To construct, operate, access and maintain a diversion to an existing aqueduct pipeline (Work No. 63). |
4/2a, 4/3af | To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 57) and existing electric lines, cables, equipment and apparatus (Works Nos. 64 and 65). |
4/3d | To take access to and over land to be used for the construction, maintenance and retention of environmental mitigation at the existing Clock Interchange (works associated with Work No. 20). |
To take access to and over land to be used for the construction, operation and maintenance of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road (Work No. 22). | |
To take access to and over land to be used for the construction, operation and maintenance of alterations to the existing Bickenhill Lane carriageway (Works Nos. 23 and 24). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/3i, 4/3l | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with Works Nos. 2 and 20). |
4/3o, 4/3p | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with Work No. 2). |
4/3y | To access land to be used for the construction, maintenance and retention of environmental mitigation at the existing Clock Interchange (works associated with Work No. 20). |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with Work No. 21). | |
4/3ah, 4/4k, 4/4u, 4/4w, 4/25q, 4/25u, 4/149, 4/160 | To construct, operate, access and maintain a diversion to an existing aqueduct pipeline (Work No. 63). |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/6a, 4/156 | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with Work No. 21). |
To construct, operate, access and maintain a diversion to an existing medium pressure gas main (Work No. 59). | |
To construct, operate, access and maintain a diversion to an existing aqueduct pipeline (Work No. 63). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). | |
4/6d | To access land to be used for the construction, operation and maintenance of a pedestrian overbridge (Work No. 39). |
To construct, operate, access and maintain a diversion to an existing medium pressure gas main (Work No. 60). | |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (Works Nos. 56, 64 and 65). | |
4/25f | To construct, operate, access and maintain a gantry forming part of Work No. 2a |
To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 57) and existing electric lines, cables, equipment and apparatus (Works Nos. 64 and 65). | |
4/59 | To construct, operate, access and maintain a realignment to a private means of access due to the construction of a new free flow link road at Work No. 21 (works associated with the authorised development). |
To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with authorised development). | |
Land Plans – Sheet 5 | |
5/1b, 5/29h, | To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 57) and existing electric lines, cables, equipment and apparatus (Works Nos. 64 and 65). |
5/29c, 5/2h and 5/29u | Required for access to and construction of a new free flow single carriageway (Work No.26). |
To construct, operate, access and maintain diversions to an existing local high pressure gas main (Work No. 57) and existing electric lines, cables, equipment and apparatus (Works Nos. 64 and 65). | |
5/7 | To construct, operate, access and maintain diversions to existing utilities apparatus and equipment (works associated with the authorised development). |
SCHEDULE 9MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS AND IMPOSITION OF RESTRICTIVE COVENANTS
Compensation enactments
I191
The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right or the imposition of a restrictive covenant as they apply in respect of compensation for the compulsory purchase of land and interests in land.
I202
1
Without limitation on the scope of paragraph 1, the 1961 Act has effect subject to the modification set out in sub-paragraph (2).
2
For section 5A(5A) (relevant valuation date) of the 1961 Act substitute—
5A
If—
a
the acquiring authority enters on land for the purposes of exercising a right in pursuance of a notice of entry under section 11(1) of the 1965 Act (as modified by paragraph 5(5) of Schedule 9 to the M42 Junction 6 Development Consent Order 2020 (“the 2020 Order”));
b
the acquiring authority is subsequently required by a determination under paragraph 12 of Schedule 2A to the 1965 Act (as substituted by paragraph 5(8) of Schedule 9 to the 2020 Order) to acquire an interest in the land; and
c
the acquiring authority enters on and takes possession of that land,
the authority is deemed for the purposes of subsection (3)(a) to have entered on that land when it entered on that land for the purpose of exercising that right.
I213
1
Without limitation on the scope of paragraph 1, the Land Compensation Act 197384 has effect subject to the modifications set out in sub-paragraph (2).
2
In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 (measure of compensation in case of severance) of the 1965 Act as substituted by paragraph 5(3)—
a
for “land is acquired or taken from” substitute “a right or restrictive covenant over land is purchased from or imposed on”; and
b
for “acquired or taken from him” substitute “over which the right is exercisable or the restrictive covenant enforceable”.
Application of the 1965 Act
I224
Part 1 (compulsory purchase under Acquisition of Land Act 1946) of the 1965 Act as applied by section 125 (application of compulsory acquisition provisions) of the 2008 Act (and modified by article 29 (modification of Part 1 of the 1965 Act)) to the acquisition of land under article 24 (compulsory acquisition of land), applies to the compulsory acquisition of a right by the creation of a new right, or to the imposition of a restrictive covenant under article 27 (compulsory acquisition of rights and restrictive covenants)—
a
with the modifications specified in paragraph 5; and
b
with such other modifications as may be necessary.
I235
1
The modifications referred to in paragraph 4(a) are as follows.
2
References in the 1965 Act to land are, in the appropriate contexts, to be read (according to the requirements of the context) as referring to, or as including references to—
a
the right acquired or to be acquired, or the restrictive covenant imposed or to be imposed; or
b
the land over which the right is or is to be exercisable, or the restrictive covenant is or is to be enforceable.
3
For section 7 (measure of compensation in case of severance) of the 1965 Act substitute—
7
In assessing the compensation to be paid by the acquiring authority under this Act, regard must be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the restrictive covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.
4
The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—
a
section 9(4) (failure by owners to convey);
b
paragraph 10(3) of Schedule 1 (owners under incapacity);
c
paragraph 2(3) of Schedule 2 (absent and untraced owners); and
d
paragraphs 2(3) and 7(2) of Schedule 4 (common land),
are modified so as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.
5
Section 1185 (powers of entry) of the 1965 Act is modified so as to secure that, where the acquiring authority has served notice to treat in respect of any right or restrictive covenant, as well as the notice of entry required by subsection (1) of that section (as it applies to compulsory acquisition under article 24), it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant; and sections 11A86 (powers of entry; further notices of entry), 11B87 (counter-notice requiring possession to be taken on specified date), 1288 (penalty for unauthorised entry) and 1389 (entry on warrant in the event of obstruction) of the 1965 Act are modified correspondingly.
6
Section 2090 (tenants at will, etc.) of the 1965 Act applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.
7
Section 22 (interests omitted from purchase) of the 1965 Act as modified by article 29(4) is also modified so as to enable the acquiring authority in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired or enforce the restrictive covenant imposed, subject to compliance with that section as respects compensation.
8
For Schedule 2A of the 1965 Act substitute—
SCHEDULE 2ACOUNTER-NOTICE REQUIRING PURCHASE OF LAND
Introduction
1
1
This Schedule applies where an acquiring authority serves a notice to treat in respect of a right over, or restrictive covenant affecting, the whole or part of a house, building or factory and has not executed a general vesting declaration under section 4 of the Compulsory Purchase (Vesting Declarations) Act 1981 as applied by article 30 (application of the 1981 Act) of the M42 Junction 6 Development Consent Order 2020 in respect of the land to which the notice to treat relates.
2
But see article 31(3) (acquisition of subsoil or airspace only) of the M42 Junction 6 Development Consent Order 2020 which excludes the acquisition of subsoil or airspace only from this Schedule.
2
In this Schedule, “house” includes any park or garden belonging to a house.
Counter-notice requiring purchase of land
3
A person who is able to sell the house, building or factory (“the owner”) may serve a counter-notice requiring the acquiring authority to purchase the owner’s interest in the house, building or factory.
4
A counter-notice under paragraph 3 must be served within the period of 28 days beginning with the day on which the notice to treat was served.
Response to counter-notice
5
On receiving a counter-notice, the acquiring authority must decide whether to—
a
withdraw the notice to treat,
b
accept the counter-notice, or
c
refer the counter-notice to the Upper Tribunal.
6
The acquiring authority must serve notice of their decision on the owner within the period of 3 months beginning with the day on which the counter-notice is served (“the decision period”).
7
If the acquiring authority decides to refer the counter-notice to the Upper Tribunal it must do so within the decision period.
8
If the acquiring authority does not serve notice of a decision within the decision period it is to be treated as if it had served notice of a decision to withdraw the notice to treat at the end of that period.
9
If the acquiring authority serves notice of a decision to accept the counter-notice, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in the house, building or factory.
Determination by the Upper Tribunal
10
On a referral under paragraph 7, the Upper Tribunal must determine whether the acquisition of the right or the imposition of the restrictive covenant would—
a
in the case of a house, building or factory, cause material detriment to the house, building or factory, or
b
in the case of a park or garden, seriously affect the amenity or convenience of the house to which the park or garden belongs.
11
In making its determination, the Upper Tribunal must take into account—
a
the effect of the acquisition of the right or the imposition of the covenant,
b
the proposed use of the right or covenant, and
c
if the right or covenant is proposed to be acquired or imposed for works or other purposes extending to other land, the effect of the whole of the works and the use of the other land.
12
If the Upper Tribunal determines that the acquisition of the right or the imposition of the covenant would have either of the consequences described in paragraph 10, it must determine how much of the house, building or factory the acquiring authority ought to be required to take.
13
If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in that land.
14
1
If the Upper Tribunal determines that the acquiring authority ought to be required to take some or all of the house, building or factory, the acquiring authority may at any time within the period of 6 weeks beginning with the day on which the Upper Tribunal makes its determination withdraw the notice to treat in relation to that land.
2
If the acquiring authority withdraws the notice to treat under this paragraph it must pay the person on whom the notice was served compensation for any loss or expense caused by the giving and withdrawal of the notice.
3
Any dispute as to the compensation is to be determined by the Upper Tribunal.
I101SCHEDULE 10LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN
Sch. 10 in force at 11.6.2020, see art. 1
(1) Plot reference Number shown on Land Plans | (2) Purpose for which temporary possession may be taken | (3) Relevant part of the authorised development |
|---|---|---|
Land Plans – Sheet 2 | ||
2/3z, 2/58a, 2/58b, 2/59 | Required for provision of a temporary construction compound. | Works Nos. 3 ,6 and 70 |
2/52 | Temporary possession associated with the Solihull Road Overbridge and temporary alignments to ensure Solihull road remains open. | Work Nos. 3 and 70 |
2/2a | Required for the provision of temporary access to facilitate the construction works | Work Nos. 1 and 5 |
2/2c | Required for construction of a diversion to an existing local high pressure gas main; and to provide temporary access to land associated with the provision of environmental mitigation. | Work No. 55 |
2/3a | Required for construction of a new M42 off slip road and the demolition of an existing sheet pile wall. | Work No. 4 |
2/3c | Required for storage of earthworks and for the construction of a diversion to an existing local high pressure gas main. | Works Nos. 3 and 55 |
2/3d | Required for construction of a new M42 off slip road and the demolition of an existing sheet pile wall and to provide temporary access to land associated with environmental mitigation. | Work No. 4 |
2/3g, 2/3h, 2/3i, 2/3j, 2/3p, 2/3r, 2/22 | Required to provide temporary access to land associated with the provision of environmental mitigation. | Work Nos. 3, 4 and 5 |
2/3o, 2/10c, 2/29, 2/30 | Required for construction of diversions to existing utilities apparatus and equipment. | Work No. 3 |
2/3u, 2/3ah | Required for construction of diversions to an existing local high pressure gas main and an existing aqueduct pipeline; and for construction of a reinforced cover slab for an existing fuel pipeline. | Works Nos. 56, 62 and 66 |
2/3w | Required for construction of a temporary two lane single carriageway; and for the stockpiling of construction materials. | Work No. 70 |
2/3aa | Required for access to drainage attenuation and treatment systems; for construction of diversions to an existing local high pressure gas main and an existing aqueduct pipeline; and for the stockpiling of construction materials. | Works No. 33, 56 and 62 |
2/3ab | Required for construction of a temporary merge onto the M42 for construction vehicles; and for the stockpiling of construction materials. | All Works |
2/10a, 2/10b, 2/11 | Required for lining and signing works. | All Works |
2/62a | Required for construction of realigned B4438 Catherine- de- Barnes Lane. | Work No. 11 |
2/65 | Required for construction of a temporary southbound diverge for construction traffic. | All Works |
2/76a | Required for temporary access to land associated with alteration works to the existing Warwickshire Gaelic Athletic Association facilities. | Work No. 68 |
Land Plans – Sheet 3 | ||
3/3d, 3/51a, 3/57, 3/58a | Required for the stockpiling of construction materials. | All Works |
3/4b | Required for access to drainage attenuation and treatment systems; for construction of diversions to an existing local high pressure gas main and an existing aqueduct pipeline; and for the stockpiling of construction materials. | Works No. 33, 56 and 62 |
3/4f | Required for access to drainage attenuation and treatment systems; and for the stockpiling of construction materials. | Work No. 33 |
3/15a, 3/15c,3/15e | Required for temporary access to land associated with alteration works to the existing Warwickshire Gaelic Athletic Association facilities. | Work No. 68 |
3/22a, 3/22b | To access land to be used in connection with the provision, maintenance and retention of mitigation within Bickenhill Meadows SSSI – Shadowbrook Meadows unit | Work No. 76 |
3/32b, 3/32c | To access land in connection with the monitoring of the Bickenhill Meadows SSSI – Shadowbrook Meadows unit. | All Works |
3/23, 3/73f | Required for construction of diversions to existing utilities apparatus and equipment. | All Works |
3/73d | Required for construction of diversions to existing utilities apparatus and equipment. | Work No. 69 |
Required for the provision of a temporary construction compound. | All Works | |
3/25 | Required for access to land associated with the provision of environmental mitigation within the Bickenhill Meadows SSSI – Shadowbrook Meadows unit. | Work No.76 |
For construction of diversions to existing utilities apparatus and equipment. | All Works | |
3/30 | Required for access to construct a diversion to a private means of access. | Work No.17 |
3/87a, 3/87b | Required for access and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 57, 64 and 65 |
Land Plans – Sheet 4 | ||
4/1a, 4/1i, 4/1ad, 4/1af, 4/1ag, 4/1ah, 4/1ai, 4/1ak, 4/1al, 4/3r, 4/146 | Required for signage installation. | All Works |
4/1c, 4/1bf, 4/3b, 4/3c, 4/3ai, 4/3aj, 4/3s, 4/3x, 4/6n, 4/6p, 4/10 | Required for construction of a new free flow link road; and for the construction of a footway/cycleway; and for the construction of a diversion to an existing medium pressure gas main; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 21, 45 and 59 |
4/1d | Required for construction of improvements to the existing Clock Interchange; and for access to environmental mitigation to be constructed, maintained and retained at the existing Clock Interchange. | Work No. 20 |
4/1f | Required for construction of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road; and for alterations to the existing Bickenhill Lane carriageway; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 22, 23 and 24 |
4/1g | Required for access to and over land to be used for construction of improvements to the existing Clock Interchange; and for access to and over land to be used for the construction of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 20 and 22 |
4/1h, 4/3ab | Required for access to construct a new free flow link road; and for construction of a diversion to an existing medium pressure gas main; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 2, 21 and 59 |
4/1k | Required for the realignment of Public Right of Way M106; and for access and construction of a diversion to an existing medium pressure gas main. | Works Nos. 53 and 60 |
4/1m, 4/1s, 4/1x, 4/1ap, 4/1bb, 4/3f, 4/3g, 4/62, 4/71, 4/147 | Required for lining and signing works; and for construction of diversions to existing utilities apparatus and equipment. | Work No. 19 |
4/1n | Required for lining and signing works; and for access and construction of a diversion to a medium pressure gas main; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 19 and 60 |
4/1p, 4/25c | Required for access to monitor existing drainage attenuation features. | Work No.20 |
4/1q, 4/3h, 4/3k, 4/3m | Required for access to and over land to be used for construction of improvements to the existing Clock Interchange; and for construction of diversions to existing utilities apparatus and equipment. | Work No. 20 |
4/1r | Required for access to construct a pedestrian overbridge; and for construction of a diversion to a medium pressure gas main. | Works Nos. 39 and 60 |
4/1t, 4/1u | Required for signage installation and the construction of diversions to existing utilities apparatus and equipment. | Work No.2 |
4/1v, 4/1am, 4/3j, 4/3ae, 4/4n, 4/4v, 4/4x, 4/25b, 4/25d, 4/25s, 4/73, 4/76, 4/151, 4/152, 4/153 | Required for access and construction of diversions to existing utilities apparatus and equipment. | All Works |
4/1w, 4/3e; 4/3o, 4/3p, 4/6e, 4/6f, 4/6g, 4/6h, 4/25e, 4/25g, 4/25l, 4/25n, 4/66, 4/89, 4/91, 4/93, 4/94, 4/99, 4/102, 4/106, 4/109, 4/150, 4/155 | Required for lining and signing works; and for access and construction of diversions to existing utilities apparatus and equipment. | Work No. 2 |
4/1z | Required for access to and over land to be used for construction of improvements to the existing Clock Interchange; and for access to and over land to be used for the construction of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road. | Works Nos. 20 and 22 |
4/1aa, 4/1ab, 4/1ac, 4/1ax, 4/3ad | Required for temporary access to construct a realignment of the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road. | Work No. 22 |
4/1ao, 4/7b | Required for temporary access to construct alterations to the existing Bickenhill Lane carriageway; and for drainage. | Work No. 24 |
4/1aq, 4/1bc | Required for access and construction of a realignment to an existing private means of access; and for access and construction of environmental mitigation; and for monitoring of attenuation devices. | Work No. 21 |
4/1as | Required for lining and signing works; and for construction of diversions to existing utilities apparatus and equipment. | Work No. 2 |
4/1az, 4/1ba | Required for access and construction of a diversion to an existing aqueduct pipeline. | Work No. 63 |
4/2a, 4/2b, 4/2c, 4/2d, 4/3af, | Required for access and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 57, 64 and 65 |
4/25f | Required for access and construction of improvements to the eastbound and westbound carriageway of the A45; and for access and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 2, 57, 64 and 65 |
4/3d | Required for construction of improvements to the existing Clock Interchange; and for access to environmental mitigation to be constructed, maintained and retained at the existing Clock Interchange; and for construction of a realignment to the existing single carriageway A45 Eastbound to Bickenhill Lane free flow link road; and for alterations to the existing Bickenhill Lane carriageway; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 20, 22, 23 and 24 |
4/3i, 4/3l | Required for access and construction of diversions to existing utilities apparatus and equipment. | Work Nos. 2 and 20 |
4/3n | Required for temporary access to construct improvements to the existing Clock Interchange. | Work No. 20 |
4/3u, 4/3v, 4/3ag | Required for access to construct a new free flow single carriageway with hard shoulder; and for access and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 26, 57, 64 and 65 |
4/3y | Required for access and construction of improvements to the existing Clock Interchange; and for construction of a new free flow link road; and for construction of diversions to existing utilities apparatus and equipment; and for access to environmental mitigation to be constructed, maintained and retained at the existing Clock Interchange. | Works Nos. 20 and 21 |
4/3ah, 4/4u, 4/25q, 4/25u, 4/160 | Required for access to and construction of a diversion to an existing aqueduct pipeline; and for access to and construction of diversions to existing utilities apparatus and equipment. | Work No. 63 |
4/4g, 4/4k | Required for provision of a temporary construction compound, [to include, but not limited to, site offices, welfare facilities, parking provisions, storage of plant and materials, and the treatment of site generated waste]; and for the realignment of Public Right of Way M106; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 53 and 69 |
4/4w | Required for provision of a temporary construction compound, [to include, but not limited to, site offices, welfare facilities, parking provisions, storage of plant and materials, and the treatment of site generated waste]; and for access and construction of a diversion to an existing aqueduct pipeline; and for the realignment of Public Right of Way M106; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 53, 63 and 69 |
4/6a | Required for construction of a new free flow link road; and for the construction of a footway/cycleway; and for the construction of a diversion to an existing medium pressure gas main; and for construction of a diversion to an existing aqueduct pipeline; and for construction of diversions to existing utilities apparatus and equipment. | Works Nos. 21, 45, 59 and 63 |
4/6b | Required for access and construction of diversions to existing electric lines, cables, equipment and apparatus; and for access and construction of an extension to an existing culvert. | Works Nos. 57, 64 and 65 |
4/6d | Required for construction of a pedestrian overbridge; and for access and construction of a diversion to an existing medium pressure gas main; and for access and construction of an extension to an existing culvert; and for the construction of diversions to existing electric lines, cables, equipment and apparatus. | Works Nos. 39, 57, 60, 64 and 65 |
4/7a | Required for alterations to the existing Bickenhill Lane carriageway; and for the construction of diversions to existing electric lines, cables, equipment and apparatus. | Works Nos. 23 and 24 |
4/9 | Required for lining and signing works; and for access and construction of a diversion to a medium pressure gas main; and for access and construction of diversions to existing utilities apparatus and equipment. | Works Nos. 2 and 59 |
4/11b | Required for access to construct a pedestrian overbridge across the A45. | Work No. 39 |
4/25a, 4/69, 4/80 | Required for access and construction of improvements to the existing Clock Interchange; and for construction of diversions to existing utilities apparatus and equipment; and for access to environmental mitigation to be constructed, maintained and retained at the existing Clock Interchange. | Work No. 20 |
4/11a, 4/25i, 4/25m | Required for access and construction of a cantilever gantry; and for lining and signing; and for access and construction of diversions to existing utilities apparatus and equipment. | Work No. 2 |
4/25j, 4/25o and 4/25p | Required for construction of a cantilever gantry and demolition of a portal gantry; and for access and construction of a pedestrian overbridge; and for lining and signing works; and for access and construction of diversions to existing utilities equipment and apparatus. | Works Nos. 2 and 39 |
4/59 | Required for lining and signing; and for access to and construction of a new free flow link road; and for access to and construction of a realignment to a private means of access. | Works Nos. 2 and 21 |
4/82 | Required for lining and signing works; and for access to and construction of a pedestrian overbridge; and for access to and construction of a diversion to an existing medium pressure gas main; and access to and construction of diversions to existing utilities apparatus and equipment. | Works Nos. 2, 39 and 60 |
4/149 | Required for lining and signing works; and for access to and construction of a diversion to an aqueduct pipeline; and for access to and construction of diversions to existing utilities apparatus and equipment. | Works Nos. 2 and 63 |
4/156 | Required for lining and signing works; and for access to and construction of a new free flow link; and for access to and construction of a footway/cycleway; and for access to and construction of a diversion to a medium pressure gas main; and for access to and construction of diversions to existing utilities apparatus and equipment. | Works Nos. 2, 21, 45, 59 and 63 |
4/158, 4/159 | Required lining and signing in connection with Airport Way connector road; and for access to and construction of a free flow link road; and for access to and construction of a diversion to a medium pressure gas main; and for access to and construction of diversions to existing utilities apparatus and equipment. | Works Nos. 21 and 59 |
Land Plans – Sheet 5 | ||
5/1a, 5/1b | Required for access to and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 57, 64 and 65 |
5/7 | Required for lining and signing works; and for access and construction of diversions to existing utilities apparatus and equipment. | Work No. 2 |
5/29b, 5/29c, 5/29h, 5/29t, 5/29u and 5/29y | Required for access to construct a new free flow single carriageway with hard shoulder; and for access and construction of diversions to an existing local high pressure gas main and existing electric lines, cables, equipment and apparatus. | Works Nos. 26, 57, 64 and 65 |
5/29p, 5/29r | Required for removal of existing East Way Roundabout. | Work No. 30(a) |
5/62 | Required for lining and signing works. | Work No. 31 |
Land Plans – Sheet 6 | ||
6/2c | Required for access to and construction of a new free flow single carriageway. | Work No. 26 |
SCHEDULE 11FELLING OR LOPPING OF TREES AND REMOVAL OF HEDGEROWS
I102PART 1TREES IN CONSERVATION AREA
Sch. 11 Pt. 1 in force at 11.6.2020, see art. 1
The tree plan references in the table below are taken from Appendix 8.2 Arboricultural Survey [APP-128/Volume 6] of the Environmental Statement.
(1) Tree plan reference | (2) Within Conservation Area |
|---|---|
G6 | Bickenhill |
G8 | Bickenhill |
G60 | Bickenhill |
I103PART 2HEDGEROWS TO BE REMOVED OR MANAGED
Sch. 11 Pt. 2 in force at 11.6.2020, see art. 1
The hedgerow identifications in the table below are taken from Appendix 9.3 Hedgerow Report [APP-131/Volume 6] of the Environmental Statement.
(1) Hedgerow identification | (2) Important hedgerow | (3) Reason for importance |
|---|---|---|
H1 | ||
H2 | ||
H3 | ||
H4 | ||
H5 | ||
H6 | ||
H9 | ||
H10 | ||
H11 | ||
H12 | Yes | Ecological and Historical |
H13 | ||
H14 | ||
H15 | ||
H16 | Yes | Ecological and Historical |
H17 | ||
H18 | ||
H19 | Yes | Ecological |
H20 | Yes | Ecological |
H21 | ||
H22 | ||
H23 | Yes | Ecological |
H24 | Yes | Ecological |
H25 | Yes | Ecological and Historical |
H26 | Yes | Ecological |
H27 | ||
H28 | Yes | Ecological |
H29 | Yes | Ecological |
H30 | ||
H32 | ||
H33 | ||
H34 | Yes | Ecological |
H35 | Yes | Ecological and Historical |
H36 | ||
H37 | ||
H38 | Yes | Ecological |
H39 | Yes | Ecological |
H40 | Yes | Ecological |
H41 | ||
H42 | Yes | Ecological and Historical |
H43 | Yes | Ecological |
H44 | Yes | Ecological |
H45 | Yes | Ecological |
H47 | ||
H48 | ||
H49 | ||
H50 | ||
H51 | ||
H52 | Yes | Ecological and Historical |
H53 | ||
H54 | ||
H55 | ||
H56 | ||
H57 | ||
H60 | ||
H62 | ||
H63 | ||
H65 | ||
H66 | ||
H67 | ||
H71 | ||
H73 | ||
H74 | ||
H75 | ||
H76 | ||
H77 | ||
H78 | ||
H79 | ||
H80 | ||
H81 | ||
H82 | ||
H83 | ||
H84 | Yes | Historical |
H85 | ||
H86 | ||
H88 | ||
H89 | ||
H90 | ||
H93 | ||
H94 | Yes | Ecological |
H96 | Yes | Ecological |
H98 | Yes | Ecological |
H99 | ||
H101 | ||
H102 | ||
H104 | ||
H105 | Yes | Ecological |
H106 | Yes | Ecological |
H107 | Yes | Ecological |
H108 | ||
H109 | ||
H110 | ||
H111 | ||
H112 | ||
H114 | ||
H115 | ||
H116 | ||
H117 | ||
H118 | ||
H119 | Yes | Ecological |
H120 | ||
H121 | ||
H122 | ||
H123 | ||
H124 | ||
H125 | ||
H126 | ||
H127 | ||
H128 | ||
H130 | ||
H131 | ||
H132 | ||
H133 | ||
H134 | ||
H135 | Yes | Ecological |
H136 | ||
H137 |
SCHEDULE 12PROTECTIVE PROVISIONS
PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS
I241
1
For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker concerned.
2
Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and the utility undertaker concerned, where the benefit of this Order is transferred or granted to another person under article 8 (consent to transfer benefit of Order), any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between the utility undertaker concerned and the transferee or grantee (as the case may be).
3
Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to the utility undertaker concerned (but see paragraph 11(3)(b)).
I252
In this Part of this Schedule—
“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means—
- a
in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 198991), belonging to or maintained by that undertaker;
- b
in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 198692 for the purposes of gas supply;
- c
in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and
- d
in the case of a sewerage undertaker—
- i
any drain or works vested in the undertaker under the Water Industry Act 199193; and
- ii
any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 (agreement to adopt sewers, drains or sewage disposal works at a future date) of that Act94,
and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;
- i
- a
“functions” includes powers and duties;
“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;
“plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed;
“utility undertaker” means—
- a
any licence holder within the meaning of Part 1 of the Electricity Act 1989;
- b
a gas transporter within the meaning of Part 1 of the Gas Act 1986;
- c
a water undertaker within the meaning of the Water Industry Act 1991; and
- d
a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,
for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.
- a
On street apparatus
I263
This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.
Apparatus in stopped up streets
I274
1
Where any street is stopped up under article 17 (permanent stopping up, restriction of use of streets and private means of access), any utility undertaker whose apparatus is in the street has the same powers and rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to the utility undertaker legal easements reasonably satisfactory to the utility undertaker in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of the utility undertaker to require the removal of that apparatus under paragraph 7 or the power of the undertaker to carry out works under paragraph 9.
2
Regardless of the temporary stopping up or diversion of any highway under the powers conferred by article 16 (temporary stopping up and restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.
Protective works to buildings
I285
The undertaker, in the case of the powers conferred by article 22 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.
Acquisition of land
I296
Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.
Removal of apparatus
I307
1
If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (6).
2
If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
3
If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed the utility undertaker must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.
4
Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 47 (arbitration).
5
The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 47, and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.
6
Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.
Facilities and rights for alternative apparatus
I318
1
Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 47 (arbitration).
2
If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
Retained apparatus
I329
1
Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 7(2), the undertaker must submit to the utility undertaker in question a plan of the works to be executed.
2
Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.
3
Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.
4
If a utility undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).
5
Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.
6
The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.
Expenses and costs
I3310
1
Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 7(2).
2
There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal.
3
If in accordance with the provisions of this Part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 47 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
b
where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.
5
An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.
I3411
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 5 or 7(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—
a
bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and
b
make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the undertaker,
by reason or in consequence of any such damage or interruption.
2
The fact that any act or thing may have been done by a utility undertaker on behalf of the undertaker or in accordance with a plan approved by a utility undertaker or in accordance with any requirement of a utility undertaker or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1).
3
Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to—
a
any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents, or
b
any part of the authorised development carried out by a utility undertaker in the exercise of any of functions conferred by this Order pursuant to a transfer or grant under article 8 (consent to transfer benefit of Order).
4
A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
Co-operation
I3512
Where in consequence of the proposed construction of any part of the authorised development, the undertaker or a utility undertaker requires the removal of apparatus under paragraph 7(2) or a utility undertaker makes requirements for the protection or alteration of apparatus under paragraph 9, the undertaker must use best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the utility undertaker’s undertaking and each utility undertaker must use its best endeavours to co-operate with the undertaker for that purpose.
I3613
Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS
I3714
For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.
I3815
In this Part of this Schedule—
“the 2003 Act” means the Communications Act 200395;
“electronic communications apparatus” has the same meaning as in the electronic communications code;
“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act96;
“electronic communications code network” means—
- a
so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and
- b
an electronic communications network which the undertaker is providing or proposing to provide;
- a
“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;
“infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7(2) of that code; and
“operator” means the operator of an electronic communications code network.
I3916
The exercise of the powers conferred by article 35 (statutory undertakers) is subject to Part 10 (undertaker’s works affecting electronic communications apparatus) of the electronic communications code.
I4017
1
Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—
a
any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or
b
there is any interruption in the supply of the service provided by an operator,
the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.
2
Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.
3
The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
4
Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 47 (arbitration).
5
This Part of this Schedule does not apply to—
a
any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act; or
b
any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development.
6
Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
PART 3FOR THE PROTECTION OF NATIONAL GRID AS ELECTRICITY UNDERTAKER
Application
I4118
1
For the protection of National Grid as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the promoter and National Grid.
2
Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the promoter and National Grid, where the benefit of this Order is transferred or granted to another person under article 8 (consent to transfer benefit of Order)—
a
any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between National Grid and the transferee or grantee (as the case may be); and
b
written notice of the transfer or grant must be given to National Grid on or before the date of that transfer or grant.
3
Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid (but see paragraph 28(3)(b)).
Interpretation
I4219
In this Part of this Schedule—
“alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means any electric lines or electrical plant as defined in the Electricity Act 198997, belonging to or maintained by National Grid, together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of National Grid for the purposes of transmission, distribution or supply, and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;
“commence” and “commencement” in paragraph 26 of this Part of this Schedule include any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment;
“deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;
“functions” includes powers and duties;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;
“maintain” and “maintenance” have effect as if National Grid’s apparatus was “authorised development” and as if the term “maintain” includes use;
“National Grid” means National Grid Electricity Transmission Plc or any successor as licence holder within the meaning of Part 1 of the Electricity Act 1989;
“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;
“promoter” means the undertaker as defined in article 2(1) of this Order;
“specified works” means any of the authorised development which—
- a
will or may be situated within 15 metres measured in any direction of any apparatus the removal of which has not been required by the promoter under paragraph 24(2) or otherwise; or
- b
may in any way adversely affect any apparatus the removal of which has not been required by the promoter under paragraph 24(2) or otherwise.
- a
I4320
Except for paragraphs 21, 26, 27 and 28, this Part of this Schedule does not apply to apparatus in respect of which the relations between the promoter and National Grid are regulated by the provisions of Part 3 of the 1991 Act.
Apparatus of National Grid in stopped up streets
I4421
1
Where any street is stopped up under article 17 (permanent stopping up, restriction of use of streets, public rights of way and private means of access), if National Grid has any apparatus in the street or accessed via that street National Grid has the same rights in respect of that apparatus as it enjoyed immediately before the stopping up and the promoter must grant to National Grid, or procure the granting to National Grid of, legal easements reasonably satisfactory to National Grid in respect of such apparatus and access to it prior to the stopping up of any such street, but nothing in this paragraph affects any right of the promoter or National Grid to require the removal of that apparatus under paragraph 24 or the power of the promoter, subject to compliance with this sub-paragraph, to carry out works under paragraph 26.
2
Notwithstanding the temporary stopping up or diversion of any highway under the powers of article 16 (temporary stopping up and restriction of use of streets), National Grid is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.
Protective works to buildings
I4522
The promoter, in the case of the powers conferred by article 22 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of National Grid (such consent not to be unreasonably withheld).
Acquisition of land
I4623
1
Regardless of any provision in this Order or anything shown on the land plans, the promoter may not possess temporarily or acquire any interest in land or apparatus, or override any easement or other interest in land, of National Grid otherwise than by agreement.
2
As a condition of an agreement under sub-paragraph (1), prior to the carrying out of any part of the authorised development (or in such other timeframe as may be agreed between National Grid and the promoter) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid or affect the provisions of any enactment or agreement regulating the relations between National Grid and the promoter in respect of any apparatus laid or erected in land belonging to or secured by the promoter, the promoter must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the promoter acting reasonably and which must be no less favourable on the whole to National Grid unless otherwise agreed by National Grid, and it will be the responsibility of the promoter to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.
3
The promoter and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus, including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus, and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid or other enactments relied upon by National Grid as of right or other use in relation to the apparatus, then the provisions in this Schedule prevail.
4
Any agreement or consent granted by National Grid under paragraph 26 or any other paragraph of this Part of this Schedule, is not be taken to constitute agreement under sub-paragraph (1).
Removal of apparatus
I4724
1
If, in the exercise of the powers conferred by this Order, the promoter acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule, and any right of National Grid to maintain that apparatus in that land must not be extinguished, until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (2) to (5).
2
If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the promoter requires the removal of any apparatus placed in that land, it must give to National Grid advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the promoter must, subject to sub-paragraph (3), afford to National Grid to its reasonable satisfaction (taking into account paragraph 25(1)) the necessary facilities and rights—
a
for the construction of alternative apparatus in other land of, or secured by, the promoter; and
b
subsequently for the maintenance of that apparatus.
3
If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the promoter, or the promoter is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the promoter, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.
4
Any alternative apparatus to be constructed in land of or land secured by the promoter under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid and the promoter.
5
National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the promoter to be removed under the provisions of this Part of this Schedule.
Facilities and rights for alternative apparatus
I4825
1
Where, in accordance with the provisions of this Part of this Schedule, the promoter affords to or secures for National Grid facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the promoter and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid, such agreement not to be unreasonably withheld.
2
If the facilities and rights to be afforded by the promoter in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the promoter to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
Retained apparatus: protection of electricity undertaker
I4926
1
Not less than 56 days before the commencement of any specified works the promoter must submit to National Grid a plan of the works to be executed and seek from National Grid details of the underground extent of their electricity tower foundations.
2
The plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe—
a
the exact position of the works;
b
the level at which these are proposed to be constructed or renewed;
c
the manner of their construction or renewal including details of excavation, positioning of plant;
d
the position of all apparatus;
e
by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;
f
any intended maintenance regimes; and
g
an assessment of risks of rise of earth issues.
3
In relation to any specified works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement describing—
a
details of any cable trench design including route, dimensions, clearance to pylon foundations;
b
demonstration that pylon foundations will not be affected prior to, during and post construction;
c
details of load bearing capacities of trenches;
d
details of any cable installation methodology including access arrangements, jointing bays and backfill methodology;
e
a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route;
f
written details of the operations and maintenance regime for any cable, including frequency and method of access;
g
assessment of earth rise potential if reasonably required by National Grid’s engineers; and
h
evidence that trench bearing capacity is to be designed to support overhead line construction traffic of up to 26 tonnes in weight.
4
The promoter must not commence any specified works until National Grid has given written approval of the plan so submitted.
5
Any approval of National Grid required under sub-paragraph (4)—
a
may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (6); and
b
must not be unreasonably withheld.
6
National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.
7
Specified works must be executed in accordance with—
a
the plan submitted under sub-paragraph (1), as approved or as amended from time to time by agreement between the promoter and National Grid; and
b
such reasonable requirements as may be made in accordance with sub-paragraphs (6) or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.
8
Where under sub-paragraph (6) National Grid requires any protective works to be carried out by itself or by the promoter as part of the plan approved pursuant to this paragraph, such protective works (whether of a temporary or permanent nature) must be carried out to National Grid’s satisfaction prior to the commencement of any specified works for which the protective works are required and National Grid must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).
9
If National Grid in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the promoter, reasonably requires the removal of any apparatus and gives written notice to the promoter of that requirement, paragraphs 19 to 20 and 23 to 25 apply as if the removal of the apparatus had been required by the promoter under paragraph 24(2).
10
Nothing in this paragraph precludes the promoter from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.
11
The promoter is not required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraph (6) insofar as is reasonably practicable in the circumstances.
12
In sub-paragraph (11) “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.
Expenses
I5027
1
Subject to the following provisions of this paragraph, the promoter must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any specified works including without limitation—
a
any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid—
i
using its own compulsory purchase powers to acquire any necessary rights under paragraph 24(3); or
ii
exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid;
b
in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;
c
the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;
d
the approval of plans;
e
the carrying out of protective works;
f
the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.
2
There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.
3
If in accordance with the provisions of this Part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the promoter or, in default of agreement, is not determined by arbitration in accordance with paragraph 32 to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
b
where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.
5
Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.
Indemnity
I5128
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any specified works or in consequence of the construction, maintenance or failure of any of the authorised works by or on behalf of the promoter or in consequence of any act or default of the promoter (or any person employed or authorised by him) in the course of carrying out such works, including without limitation any works carried out by the promoter under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised development) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the promoter will—
a
bear and pay on demand accompanied by an invoice or claim from National Grid the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and
b
indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid other than arising from any default of National Grid.
2
The fact that any act or thing may have been done by National Grid on behalf of the promoter or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the promoter from liability under the provisions of sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.
3
Nothing in sub-paragraph (1) imposes any liability on the promoter in respect of—
a
any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents;
b
any part of the authorised development carried out by National Grid in the exercise of any functions conferred by this Order pursuant to a transfer or grant under article 8 (consent to transfer benefit of Order).
4
National Grid must give the promoter reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the promoter and considering their representations.
5
National Grid must, in respect of any matter covered by the indemnity given by the promoter in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.
6
National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the promoter National Grid must provide an explanation of how the claim has been minimised, where relevant.
Enactments and agreements
I5229
Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the promoter and National Grid in respect of any apparatus laid or erected in land belonging to the promoter on the date on which this Order is made.
Co-operation
I5330
1
Where in consequence of the proposed construction of any part of the authorised development, the promoter or National Grid requires the removal of apparatus under paragraph 24(2) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 26, the promoter must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid must use its best endeavours to co-operate with the promoter for that purpose.
2
For the avoidance of doubt whenever National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the promoter or the taking of action by the promoter, it must not be unreasonably withheld or delayed.
Access
I5431
If in consequence of the agreement reached in accordance with paragraph 23(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the promoter must provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.
Arbitration
I5532
Any difference or dispute arising between the promoter and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the promoter and National Grid, be determined by arbitration in accordance with article 47 (arbitration).
Notices
I5633
Notwithstanding article 45 (service of notices), any plans submitted to National Grid by the promoter pursuant to paragraph 26(1) must be sent to National Grid Plant Protection at plantprotection@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the promoter in writing.
PART 4FOR THE PROTECTION OF HIGH SPEED TWO (HS2) LIMITED
I5734
The following provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and the company.
I5835
In this Part of this Schedule—
“the Act limits” has the same meaning as in section 68(2) of the HS2 Act;
“the company” means; High Speed Two (HS2) Limited (company number 06791686) whose registered office is at Two Snowhill, Snow Hill Queensway, Birmingham, England, B4 6GA (HS2)) and any associated company of High Speed Two (HS2) Limited which holds property for railway purposes and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 (meaning of “subsidiary” etc.) of the Companies Act 200698) the holding company of High Speed Two (HS2) Limited, a subsidiary of High Speed Two (HS2) Limited or another subsidiary of the holding company of High Speed Two (HS2) Limited;
“company’s engineer” means the company’s Head of Construction, Engineering and Delivery or such other engineer appointed by the company (and notified to the undertaker) for the purposes of this Order;
“the HS2 Act” means the High Speed Rail (London – West Midlands) Act 201799;
“the HS2 works” means the high speed railway link to be built pursuant to the HS2 Act;
“the HS2 land” means so much of the land within the Order limits which also falls within the Act limits;
“specified work” means so much of the authorised development as is situated upon, across, under, over or within 15 metres of, or may in any way adversely affect, the HS2 land.
Regulation of powers
I5936
1
The undertaker must before commencing construction of any specified work supply to the company proper and sufficient plans of that work for the reasonable approval of the company’s engineer and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the company’s engineer or settled by arbitration.
2
The approval of the company’s engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and may be made subject to such conditions as are reasonably necessary to mitigate the impact of the specified works on the construction, commissioning, maintenance, operation or safety of the HS2 works.
3
Without limiting the scope of sub-paragraph (2), if by the end of the period of 28 days beginning with the date on which plans are supplied to the company under sub-paragraph (1), the company’s engineer has not intimated disapproval of those plans and the grounds of disapproval the undertaker may serve upon the company’s engineer written notice requiring the company’s engineer to intimate approval or disapproval within a further period of 28 days.
4
If by the end of the period of 28 days beginning with the date upon which the company’s engineer receives notice under sub-paragraph (3), the engineer has not intimated approval or disapproval, the engineer is deemed to have approved the plans as submitted.
I6037
1
Any specified work must, when commenced, be constructed—
a
without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under paragraph 36 unless otherwise agreed in writing between the company and the undertaker;
b
under the supervision (where appropriate and if given) and to the reasonable satisfaction of the company’s engineer; and
c
in such manner as to cause as little damage as is possible to the HS2 land.
2
If any such damage is caused by the carrying out of, or in consequence of the construction of, a specified work, the company may inspect the damage and either—
a
direct that the undertaker, regardless of any approval described in paragraph 36(1), make good such damage and pay to the company all reasonable expenses to which the company may be put and compensation for any costs or losses which it may sustain by reason of any such damage; or
b
except in relation to HS2 land vested in the undertaker, elect to make good such damage itself and recover from the undertaker all reasonable expenses to which the company may be put and compensation for any costs or losses which it may sustain by reason of any such damage.
3
Nothing in this Part of this Schedule imposes—
a
any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of the company or its servants, contractors or agents; or
b
any liability on the company with respect to any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractors or agents.
I6138
The undertaker must—
a
at all times afford reasonable facilities to the company’s engineer for access to a specified work during its construction; and
b
supply the company’s engineer with all such information as the company’s engineer may reasonably require with regard to a specified work or the method of constructing it.
I6239
The undertaker must repay to the company all fees, costs, charges and expenses reasonably and properly incurred by the company in respect of the approval by the company’s engineer of plans submitted by the undertaker and the supervision by the company’s engineer of the construction of a specified work.
I6340
1
Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not permanently or temporarily acquire HS2 land or any rights on, across, under or over HS2 land otherwise than by written agreement with the company.
2
The undertaker must not exercise the powers conferred by article 23 (authority to survey and investigate the land) in respect of any HS2 land otherwise than by written agreement with the company.
3
The provisions of this paragraph do not apply to any HS2 land that is vested in the undertaker.
Co-operation
I6441
1
On a monthly basis, or such other period as may be agreed, from the date this Order is made until completion of the specified works, the undertaker will provide the company with a programme of works, such programme to include—
a
the intended date of commencement of the specified work;
b
the anticipated duration of the construction of the specified work; and
c
an updated (insofar as is reasonably practicable) suite of drawings and plans for the specified work and in the absence of any such plans an estimated date of when the plans will be ready for the company to review.
2
On a monthly basis, or such other period as may be agreed, from the date this Order is made until completion of the specified works, the company will provide the undertaker with a programme of works for the HS2 works, such programme to include—
a
the intended date of commencement of any works within the Order limits;
b
the anticipated duration of the construction of such works; and
c
an updated (insofar as is reasonably practicable) suite of drawings and plans for such works and in the absence of any such plans an estimated date of when the plans will be ready for the undertaker to review.
3
The company must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by the company under this Part of this Schedule during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.
4
The undertaker must at all times afford reasonable facilities and access to the company and its agents for the purpose of the company carrying out any works to facilitate the HS2 works and must supply the company with such information as it may reasonably require with regard to such works or the method of constructing them.
Indemnity
I6542
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of the specified works the company becomes liable or incurs any increased liability to pay any amount to any third party, the undertaker will indemnify the company for any expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from the company, by reason or in consequence of the company becoming liable or its liability increasing to any third party as aforesaid other than arising from any default of the company.
2
The fact that any act or thing may have been done by the company on behalf of the undertaker or in accordance with a plan approved by the company or in accordance with any requirement of the company or under its supervision will not, unless sub-paragraph (3) applies, excuse the undertaker from liability under the provisions of sub-paragraph (1) unless the company fails to carry out and execute the works properly with due care and attention and in a skilful and workmanlike manner or in a manner that does not accord with the approved plan.
3
Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of—
a
any expenses, loss, demands, proceedings, damages, claims, penalty or costs to the extent that it is attributable to the neglect or default of the company, its officers, servants, contractors or agents;
b
any part of the authorised development carried out by the company in the exercise of any functions conferred by this Order pursuant to a transfer or grant under article 8 (consent to transfer benefit of Order).
4
The company must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.
5
The company must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.
6
The company must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within the company’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of the company’s control and if reasonably requested to do so by the undertaker the company must provide an explanation of how the claim has been minimised, where relevant.
PART 5FOR THE PROTECTION OF CADENT GAS LIMITED
Application
I6643
For the protection of Cadent the following provisions will, unless otherwise agreed in writing between the undertaker and Cadent, have effect.
Interpretation
I6744
In this Part of this Schedule—
“alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of Cadent to enable Cadent to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means any gas mains, pipes, pressure governors, ventilators, cathodic protections, cables or other apparatus belonging to or maintained by Cadent for the purposes of gas supply together with any replacement apparatus and such other apparatus constructed pursuant to this Order that becomes operational apparatus of Cadent for the purposes of transmission, distribution or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;
“Cadent” means Cadent Gas Limited and includes its successors in title or any successor as a gas transporter within the meaning of Part 1 of the Gas Act 1986100;
“commence” and “commencement” include any below ground surveys, monitoring, work operations, remedial work in respect of any contamination or other adverse ground condition, the receipt and erection of construction plant and equipment, and non-intrusive investigations for the purpose of assessing ground conditions;
“deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;
“facilities and rights” for construction and for maintenance include any appropriate working areas required to reasonably and safely undertake that construction or maintenance, and any necessary rights of access;
“functions” includes powers and duties;
“ground mitigation scheme” means a scheme approved by Cadent (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;
“ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, shall require the undertaker to submit for Cadent’s approval a ground mitigation scheme;
“ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;
“maintain” and “maintenance” have effect as if Cadent’s existing apparatus was authorised development and as if the term maintain includes protect and use;
“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;
“rights” includes restrictive covenants and, in relation to decommissioned apparatus, the surrender of rights, release of liabilities and transfer of decommissioned apparatus; and
“specified works” means any of the authorised development or activities (including maintenance) undertaken in association with the authorised development which—
- a
will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under sub-paragraph 49(2) or otherwise; or
- b
may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under sub-paragraph 49(2) or otherwise.
- a
On Street apparatus
I6845
1
This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Cadent are regulated by the provisions of Part 3 of the 1991 Act, except for—
a
paragraphs 46, 51, 52 and 53; and
b
where sub-paragraph (2) applies, paragraphs 49 and 50.
2
This sub-paragraph applies where any apparatus is diverted from an alignment within the existing adopted public highway but not wholly replaced within the existing public highway, notwithstanding that any diversion may be carried out under the provisions of Part 3 of the 1991 Act.
Apparatus of Cadent in stopped up streets
I6946
1
Where any street is stopped up under article 17 (permanent stopping up, restriction of use of streets, public rights of way and private means of access), if Cadent has any apparatus in the street or accessed via that street Cadent is entitled to the same rights in respect of such apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to Cadent, or procure the granting to Cadent of, legal easements reasonably satisfactory to Cadent in respect of such apparatus and access to it prior to the stopping up of any such street or highway, but nothing in this paragraph shall affect any right of the undertaker or of Cadent to require the removal of that apparatus under paragraph 49.
2
Notwithstanding the temporary stopping up or diversion of any highway under the powers of article 16 (temporary stopping up and restriction of use of streets), Cadent will be at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as it would have been entitled to do immediately before such temporary stopping up or diversion in respect of any apparatus which at the time of the stopping up or diversion was in that highway.
Protective works to buildings
I7047
The undertaker must exercise the powers conferred by article 22 (protective work to buildings) so as not to obstruct or render less convenient the access to any apparatus without the written consent of Cadent (such consent not to be unreasonably withheld).
Acquisition of land
I7148
1
Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not appropriate or acquire any interest in land or appropriate, acquire, extinguish or override any easement or other interest in land of Cadent otherwise than by agreement.
2
As a condition of agreement between the parties in sub-paragraph (1), prior to the carrying out or maintenance of any part of the authorised development (or in such other timeframe as may be agreed between Cadent and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of Cadent or affect the provisions of any enactment or agreement regulating the relations between Cadent and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as Cadent reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between Cadent and the undertaker acting reasonably and which must be no less favourable on the whole to Cadent unless otherwise agreed by Cadent, and it will be the responsibility of the undertaker to procure or secure the consent to and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised development or maintenance thereof.
3
The undertaker and Cadent agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus, including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by Cadent and other enactments relied upon by Cadent as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule prevail.
4
Any agreement or consent granted by Cadent under paragraph 51 or any other paragraph of this Part of this Schedule, is not to be taken to constitute agreement under sub-paragraph (1).
5
As a condition of an agreement under sub-paragraph (1) that involves de-commissioned apparatus being left in situ the undertaker must accept a surrender of any existing easement or other interest of Cadent in such decommissioned apparatus and release Cadent from all liabilities in respect of such de-commissioned apparatus from the date of such surrender.
6
Where an undertaker acquires land which is subject to any Cadent right or interest (including, without limitation, easements and agreements relating to rights or other interests) and the provisions of paragraph 49 do not apply, the undertaker must, unless Cadent agrees otherwise—
a
retain any notice of Cadent’s easement, right or other interest on the title to the relevant land when registering the undertaker’s title to such acquired land; and
b
(where no such notice of Cadent’s easement, right or other interest exists in relation to such acquired land or any such notice is registered only on the Land Charges Register) include (with its application to register title to the undertaker’s interest in such acquired land at the Land Registry) a notice of Cadent’s easement, right or other interest in relation to such acquired land.
Removal of apparatus
I7249
1
If, in the exercise of the powers conferred by this Order, including pursuant to any agreement reached in accordance with paragraph 48, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be decommissioned or removed under this Part of this Schedule and any right of Cadent to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, is in operation, and the facilities and rights referred to in sub-paragraph (2) have been provided, to the reasonable satisfaction of Cadent and in accordance with sub-paragraphs (2) to (5) inclusive.
2
If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to Cadent advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Cadent reasonably needs to move or remove any of its apparatus) the undertaker must afford to Cadent to its satisfaction (taking into account paragraph 50(1)) the necessary facilities and rights—
a
for the construction of alternative apparatus; and
b
subsequently for the maintenance of that apparatus.
3
If the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, Cadent must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to assist the undertaker in obtaining the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for Cadent to use its compulsory purchase powers to this end unless it (in its absolute discretion) elects to so do.
4
Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Cadent and the undertaker.
5
Cadent must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the prior grant to Cadent of such facilities and rights as are referred to in sub-paragraph (2) or (3), then proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to decommission or remove any apparatus required by the undertaker to be decommissioned or removed under the provisions of this Part of this Schedule.
Facilities and rights for alternative apparatus
I7350
1
Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for Cadent facilities and rights in land for the construction and maintenance of alternative apparatus in substitution for apparatus to be decommissioned or removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Cadent and must be no less favourable on the whole to Cadent than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed unless otherwise agreed by Cadent.
2
If the facilities and rights to be afforded by the undertaker and agreed with Cadent under sub-paragraph (1) in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to Cadent than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed then the terms and conditions to which those facilities and rights are subject in the matter may be referred to arbitration in accordance with paragraph 57 of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to Cadent as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
Retained apparatus: protection of Cadent
I7451
1
Not less than 56 days before the commencement of any specified works the undertaker must submit to Cadent a plan and, if reasonably required by Cadent, a ground monitoring scheme in respect of those works.
2
The plan to be submitted to Cadent under sub-paragraph (1) must include a method statement and describe—
a
the exact position of the works;
b
the level at which these are proposed to be constructed or renewed;
c
the manner of their construction or renewal including details of excavation, positioning of plant etc.;
d
the position of all apparatus;
e
by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and
f
any intended maintenance regimes.
3
The undertaker must not commence any specified works until Cadent has given written approval of the plan so submitted.
4
Any approval of Cadent given under sub-paragraph (3)—
a
may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (5); and
b
must not be unreasonably withheld or delayed and Cadent must meaningfully engage with the undertaker within 28 days of the date of submission of the plan under sub-paragraph (1).
5
Cadent may require such modifications to be made to the plan as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.
6
Specified works must only be executed in accordance with—
a
the plan submitted under sub-paragraph (1), as approved or as amended from time to time by agreement between the undertaker and Cadent; and
b
all conditions imposed under sub-paragraph (4)(a), and Cadent will be entitled to watch and inspect the execution of those works.
7
Where Cadent requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to Cadent’s satisfaction prior to the commencement of any specified works (or any relevant part thereof) for which protective works are required prior to commencement.
8
If Cadent, in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 43 to 45 and 48 to 50 apply as if the removal of the apparatus had been required by the undertaker under paragraph 49(2).
9
Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.
10
As soon as reasonably practicable after any ground subsidence event attributable to the authorised development (including such an event attributable to its maintenance)—
a
the undertaker must implement an appropriate ground mitigation scheme; and
b
Cadent retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 52.
11
The undertaker is not required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to Cadent notice as soon as is reasonably practicable and a plan of those works and must comply with the conditions imposed under sub-paragraph (4)(a) insofar as is reasonably practicable in the circumstances.
12
In this paragraph, “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.
Expenses
I7552
1
Subject to the following provisions of this paragraph, the undertaker must pay to Cadent on demand, all charges, costs and expenses reasonably anticipated or reasonably incurred by Cadent in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised development as are referred to in this Part of this Schedule including without limitation—
a
any costs reasonably incurred by or compensation properly paid by Cadent in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs (including professional fees) incurred by Cadent as a consequence of Cadent;
i
using its own compulsory purchase powers to acquire any necessary rights under paragraph 49(3) if it elects to do so; or
ii
exercising any compulsory purchase powers under this Order transferred to or benefitting Cadent;
b
in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;
c
the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;
d
the approval of plans;
e
the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;
f
the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule;
g
any watching brief pursuant to sub-paragraph 51(6).
2
There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.
3
If in accordance with the provisions of this Part of this Schedule—
a
apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
b
apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 57 to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Cadent by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances (or it would be unlawful due to a statutory or regulatory change) to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.
4
For the purposes of sub-paragraph (3)—
a
an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
b
where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.
5
An amount which apart from this sub-paragraph would be payable to Cadent in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Cadent any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.
Indemnity
I7653
1
Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works authorised by this Part of this Schedule (including without limitation relocation, diversion, decommissioning, construction and maintenance of apparatus or alternative apparatus) or in consequence of the construction, use, maintenance or failure of any of the authorised development (including works carried out under article 22 (protective work to buildings)) by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by the undertaker) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised development) or property of Cadent, or there is any interruption in any service provided, or in the supply of any goods, by Cadent, or Cadent becomes liable to pay any amount to any third party, the undertaker will—
a
bear and pay on demand accompanied by an invoice or claim from Cadent, the cost reasonably incurred by Cadent in making good such damage or restoring the supply; and
b
indemnify Cadent for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs properly incurred by or recovered from Cadent, by reason or in consequence of any such damage or interruption or Cadent becoming liable to any third party as aforesaid other than arising from any default of Cadent.
2
The fact that any act or thing may have been done by Cadent on behalf of the undertaker or in accordance with a plan approved by Cadent or in accordance with any requirement of Cadent or under its supervision including under any watching brief will not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless Cadent fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.
3
Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of—
a
any damage or interruption to the extent that it is attributable to the neglect or default of Cadent, its officers, servants, contractors or agents; and
b
any part of the authorised development carried out by Cadent in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 8;
c
any indirect or consequential loss of any third party (including but not limited to loss of use, revenue, profit, contract, production, increased cost of working or business interruption) arising from any such damage or interruption, which is not reasonably foreseeable.
4
Cadent must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.
Enactments and agreements
I7754
Except where this Part of this Schedule provides otherwise, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Cadent in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
Co-operation
I7855
1
Where in consequence of the proposed construction of any part of the authorised development, the undertaker or Cadent requires the removal of apparatus under paragraph 49(2) or Cadent makes requirements for the protection or alteration of apparatus under paragraph 51, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Cadent’s undertaking and Cadent must use its best endeavours to co-operate with the undertaker for that purpose.
2
Whenever Cadent’s consent, agreement or approval is required in relation to plans, documents or other information submitted by Cadent or the taking of action by Cadent, it must not be unreasonably withheld or delayed.
Access
I7956
If in consequence of any agreement reached in accordance with paragraph 48(1) or the powers conferred by this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative rights and means of access to such apparatus as will enable Cadent to maintain or use the apparatus no less effectively than was possible before such obstruction.
Arbitration
I8057
Save for differences or disputes arising under sub-paragraphs 49(2) and 49(4) any difference or dispute arising between the undertaker and Cadent under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and Cadent, be determined by arbitration in accordance with article 47 (arbitration).
Notices
I8158
Notwithstanding article 45 (service of notices) any plans submitted to Cadent by the undertaker pursuant to paragraph 51(1) must be sent via email to plantprotection@cadentgas.com as well as via post to Plant Protection Limited, Cadent Gas Limited, Brick Kiln Street, Hinckley, Leicestershire, LE10 ONA or such other address as Cadent may from time to time appoint instead for that purpose and notify to the undertaker in writing.
I104SCHEDULE 13CERTIFICATION OF PLANS AND DOCUMENTS, ETC.
Sch. 13 in force at 11.6.2020, see art. 1
I104The reference to a document in the table with a numbered regulation is a reference to the regulation as numbered in the Infrastructure Planning (Applications: Prescribed Forms and Procedure) Regulations 2009101
(1) Document | (2) Document Reference | (3) Version |
|---|---|---|
Book of Reference – Regulation 5(2)(d) | TR010027/APP/4.3(a) | 2 |
Classification of Road Plans – Regulation 5(2)(o) | TR010027/APP/2.7(a) | 2 |
Environmental Statement – Regulation 5(2)(a) | TR010027/APP/6.1, with updated Climate Chapter 15 (a) | 1 |
Outline Environmental Management Plan | TR010027/APP/6.11(a) | A |
Location Plan – Regulation 5(2)(o) | TR010027/APP/2.1 | 1 |
General Arrangement Plans – Regulation 5(2)(o) | TR010027/APP/2.4(a) | 2 |
Land Plans – Regulation 5(2)(i) and 5(4) | TR010027/APP/2.2(a) | 2 |
Work Plans – Regulation 5(2)(j) and 5(4) | TR010027/APP/2.3(a) | 2 |
Streets, Rights of Way and Access Plans – Regulation 5(2)(k) and 5(4) | TR010027/APP/2.5(a) | 2 |
Engineering Drawings and Sections – Regulations 5(2)(o), 5(4) and 6(2) | TR010027/APP/2.8(a) | 2 |
Crown Land Plans – Regulation 5(2)(n) and 5(4) | TR010027/APP/2.9(a) | 2 |
Sch. 1 in force at 11.6.2020, see art. 1