Search Legislation

The M25 Junction 10/A3 Wisley Interchange Development Consent Order 2022

Status:

This is the original version (as it was originally made).

Articles 35 and 44

SCHEDULE 9PROTECTIVE PROVISIONS

PART 1FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWAGE UNDERTAKERS

Application

1.  For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker concerned.

Interpretation

2.  In this Part of this Schedule—

alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989(1)), belonging to or maintained by that undertaker;

(b)

in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 1986(2) for the purposes of gas supply;

(c)

in the case of a water undertaker, mains, pipes or other apparatus belonging to or maintained by that undertaker for the purposes of water supply; and

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the undertaker under the Water Industry Act 1991(3); and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 (agreement to adopt sewers, drains or sewage disposal works at a future date) of that Act(4),

and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; and

utility undertaker” means—

(a)

any licence holder within the meaning of Part 1 of the Electricity Act 1989;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986;

(c)

a water undertaker within the meaning of the Water Industry Act 1991; and

(d)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised development, and in relation to any apparatus, means the undertaker to whom it belongs or by whom it is maintained.

On street apparatus

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.

Apparatus in stopped up streets

4.—(1) Where any street is stopped up under article 15 (permanent stopping up and restriction of use of streets and private means of access), any utility undertaker has the same powers and rights in respect of any apparatus in the street as it enjoyed immediately before the stopping up and the undertaker must grant to the utility undertaker legal easements reasonably satisfactory to the utility undertaker in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of the utility undertaker to require the removal of that apparatus under paragraph 7 or the power of the undertaker to carry out works under paragraph 9.

(2) Regardless of the temporary closure or diversion of any highway under the powers conferred by article 14 (temporary closure and restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Protective works to buildings

5.  The undertaker, in the case of the powers conferred by article 20 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.

Acquisition of land

6.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

7.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in accordance with sub-paragraphs (2) to (6).

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed the utility undertaker must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker and the undertaker or in default of agreement settled by arbitration in accordance with article 48 (arbitration).

(5) The utility undertaker must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 48, and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) If the utility undertaker fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved.

(8) For the avoidance of doubt, any deemed approval under sub-paragraph (7) does not extend to the actual undertaking of the removal works, which shall remain the sole responsibility of the utility undertaker or its contractors.

Facilities and rights for alternative apparatus

8.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction, maintenance of the utility undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker or in default of agreement settled by arbitration in accordance with article 48 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus

9.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 7(2), the undertaker must submit to the utility undertaker a plan of the works to be executed.

(2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give the utility undertaker notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.

Expenses and costs

10.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 7(2).

(2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 48 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker by virtue of sub-paragraph (1) must be reduced by the amount of that excess

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

11.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 5 or 7(2), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker.

(2) The fact that any act or thing may have been done by a utility undertaker on behalf of the undertaker or in accordance with a plan approved by a utility undertaker or in accordance with any requirement of a utility undertaker or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless a utility undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(4) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made, without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Co-operation

12.  Where in consequence of the proposed construction of any part of the authorised development, the undertaker or a utility undertaker requires the removal of apparatus under paragraph 7(2) or a utility undertaker makes requirements for the protection or alteration of apparatus under paragraph 9, the undertaker must use best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the utility undertaker’s undertaking and each utility undertaker must use its best endeavours to co-operate with the undertaker for that purpose.

13.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 2FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

14.  For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.

15.  In this Part of this Schedule—

the 2003 Act” means the Communications Act 2003(5);

electronic communications apparatus” has the same meaning as in the electronic communications code;

the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(6);

electronic communications code network” means—

(a)

so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and

(b)

an electronic communications network which the undertaker is providing or proposing to provide;

electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7(2) of that code; and

operator” means the operator of an electronic communications code network.

16.  The exercise of the powers conferred by article 35 (statutory undertakers) is subject to Part 10 (undertaker’s works affecting electronic communications apparatus) of the electronic communications code.

17.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 48 (arbitration).

(5) This Part of this Schedule does not apply to—

(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or

(b)any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development.

(6) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 3FOR THE PROTECTION OF THE ENVIRONMENT AGENCY

18.—(1) The following provisions shall apply for the protection of the Agency unless otherwise agreed in writing between the undertaker and the Agency.

(2) In this part of this Schedule—

the Agency” means the Environment Agency;

construction” includes execution, placing, altering, replacing, relaying and removal and excavation and “construct” and “constructed” are to be construed accordingly;

drainage work” means any main river and includes any land which provides or is expected to provide flood storage capacity for any main river and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence or tidal monitoring;

fishery” means any waters containing fish and fish in, or migrating to or from, such waters and the spawn, spawning ground, habitat or food of such fish;

main river” means all watercourses shown as such on the statutory main river maps held by the Agency and the Department for Environment Food and Rural Affairs including any structure or appliance for controlling or regulating the flow of water in or out of the channel;

plans” includes sections, drawings, specifications, calculations and method statements;

specified work” means so much of any work or operation authorised by this Order as is in, on, under, over or within 8 metres of a drainage work or is otherwise likely to—

(a)

affect any drainage work or the volumetric rate of flow of water in or flowing to or from any drainage work;

(b)

affect the flow, purity or quality of water in any watercourse or other surface waters or ground water;

(c)

cause obstruction to the free passage of fish or damage to any fishery;

(d)

affect the conservation, distribution or use of water resources; or

(e)

affect the conservation value of the main river and habitats in its immediate vicinity;

watercourse” includes all rivers, streams, ditches, drains, cuts, culverts, dykes, sluices, basins, sewers and passages through which water flows except a public sewer.

19.—(1) Before beginning to construct any specified work, the undertaker must submit to the Agency plans of the specified work and such further particulars available to it as the Agency may within 28 days of the receipt of the plans reasonably request.

(2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by the Agency, or determined under paragraph 28.

(3) Any approval of the Agency required under this paragraph—

(a)must not be unreasonably withheld or delayed;

(b)in the case of a refusal must be accompanied by a statement of grounds of refusal;

(c)is deemed to have been refused if it is neither given nor refused within 2 months of the submission of the plans or receipt of further particulars if such particulars have been requested by the Agency for approval and

(d)may be given subject to such reasonable requirements as the Agency may have for the protection of any drainage work or the fishery or for the protection of water resources, or for the prevention of flooding or pollution or in the discharge of its environmental duties.

(4) The Agency must use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(c).

20.  Without limiting paragraph 19, the requirements which the Agency may have under that paragraph include conditions requiring the undertaker, at its own expense, to construct such protective works, whether temporary or permanent, before or during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary—

(a)to safeguard any drainage work against damage; or

(b)to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

21.—(1) Subject to sub-paragraph (2), any specified work, and all protective works required by the Agency under paragraph 20, must be constructed—

(a)without unreasonable delay in accordance with the plans approved under this Part of this Schedule; and

(b)to the reasonable satisfaction of the Agency,

and the Agency shall be entitled by its officer to watch and inspect the construction of such works.

(2) The undertaker must give to the Agency not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is completed.

(3) If the Agency reasonably requires, the undertaker must construct all or part of the protective works so that they are in place prior to the construction of the specified work to which the protective works relate.

(4) If any part of a specified work or any protective work required by the Agency is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the Agency may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the Agency reasonably requires.

(5) Subject to sub-paragraph (6), if, within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (4) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may execute the works specified in the notice and any reasonable expenditure incurred by the Agency in so doing shall be recoverable from the undertaker.

(6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the Agency must not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (5) until the dispute has been finally determined in accordance with paragraph 28.

22.—(1) Subject to sub-paragraph (7) the undertaker must from the commencement of the construction of the specified works until the date falling 12 months from the date of completion (“the maintenance period”), maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation and on land held by the undertaker for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence.

(2) Upon the expiry of the maintenance period, the drainage work must be maintained by the highway authority of the highway to which the specified work relates.

(3) If any such drainage work which the undertaker is liable to maintain is not maintained to the reasonable satisfaction of the Agency, the Agency may by notice in writing require the person liable for maintenance to repair and restore the work, or any part of such work, or (if the person liable for maintenance so elects and the Agency in writing consents, such consent not to be unreasonably withheld or delayed), to remove the specified work and restore the site to its former condition, to such extent and within such limits as the Agency reasonably requires.

(4) Subject to sub-paragraph (6), if, within a reasonable period, being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (3) on the person liable for maintenance, the person has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the Agency may do what is necessary for such compliance and any reasonable expenditure incurred by the Agency in so doing is recoverable from that person.

(5) If there is any failure by the undertaker to obtain consent or comply with conditions imposed by the Agency in accordance with these protective provisions the Agency may serve written notice requiring the undertaker to cease all or part of the specified works and the undertaker must cease the specified works or part thereof until it has obtained the consent or complied with the condition unless the cessation of the specified works or part thereof would cause greater damage than compliance with the written notice.

(6) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (3), the Agency shall not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined in accordance with paragraph 28.

(7) This paragraph does not apply to—

(a)drainage works which are vested in the Agency, or which the Agency or another person is liable to maintain and is not proscribed by the powers of this Order from doing so; or

(b)any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule.

23.  If by reason of the construction of any specified work or of the failure of any such work, the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage must be made good by the undertaker to the reasonable satisfaction of the Agency and if the undertaker fails to do so, the Agency may make good the impairment or damage and recover any expenditure reasonably incurred by the Agency in so doing from the undertaker.

24.  If by reason of construction of the specified work the Agency’s access to flood defences or equipment maintained for flood defence purposes is materially obstructed, the undertaker must provide such alternative means of access that will allow the Agency to maintain the flood defence or use the equipment no less effectively than was possible before the obstruction within 24 hours of the undertaker becoming aware of such obstruction.

25.—(1) The undertaker must take all such measures as may be reasonably practicable to prevent any interruption of the free passage of fish in the fishery during the construction of any specified work.

(2) If by reason of—

(a)the construction of any specified work; or

(b)the failure of any such work,

damage to the fishery is caused, or the Agency has reason to expect that such damage may be caused, the Agency may serve notice on the undertaker requiring it to take such steps as may be reasonably practicable to make good the damage, or, as the case may be, to protect the fishery against such damage.

(3) If within such time as may be reasonably practicable for that purpose after the receipt of written notice from the Agency of any damage or expected damage to a fishery, the undertaker fails to take such steps as are described in sub-paragraph (2), the Agency may take those steps and any expenditure reasonably incurred by the Agency in so doing shall be recoverable from the undertaker.

(4) In any case where immediate action by the Agency is reasonably required in order to secure that the risk of damage to the fishery is avoided or reduced, the Agency may take such steps as are reasonable for the purpose, and may recover from the undertaker any expenditure reasonably incurred in so doing provided that notice specifying those steps is served on the undertaker as soon as reasonably practicable after the Agency has taken, or commenced to take, the steps specified in the notice.

26.  The undertaker must repay to the Agency all reasonable costs, charges and expenses which the Agency may reasonably incur—

(a)in the examination or approval of plans under this Part of this Schedule;

(b)in the inspection of the construction of the specified works or any protective works required by the Agency under this Part of this Schedule; and

(c)in the carrying out of any surveys or tests by the Agency which are reasonably required in connection with the construction of the specified works.

27.—(1) The undertaker must make reasonable compensation for costs and losses which may be reasonably incurred or suffered by the Agency by reason of—

(a)the construction of any specified works comprised within the authorised works; or

(b)any act or omission of the undertaker, its employees, contractors or agents or others whilst engaged upon the construction of the authorised works.

(2) For the avoidance of doubt, in sub-paragraph (1)—

costs” includes—

(a)

expenses and charges;

(b)

staff costs and overheads;

(c)

legal costs;

losses” includes physical damage.

(3) The undertaker must make reasonable compensation for liabilities, claims and demands arising out of or in connection with the authorised works or otherwise out of the matters referred to in sub-paragraph (1)(a) and (b).

(4) For the avoidance of doubt, in sub-paragraph (3)—

“claims” and “demands” include as applicable—

(a)

costs (within the meaning of sub-paragraph (2)) incurred in connection with any claim or demand;

(b)

any interest element of sums claimed or demanded;

liabilities” includes—

(a)

contractual liabilities;

(b)

tortious liabilities (including liabilities for negligence or nuisance);

(c)

liabilities to pay statutory compensation or for breach of statutory duty; and

(d)

liabilities to pay statutory penalties imposed on the basis of strict liability (but does not include liabilities to pay other statutory penalties).

(5) The Agency must give to the undertaker reasonable notice of any such claim or demand.

(6) The undertaker may at its own expense conduct all negotiations for the settlement of the same and any litigation that may arise therefrom.

(7) The Agency must not compromise or settle any such claim or make any admission which might be prejudicial to the claim without the agreement of the undertaker which agreement must not be unreasonably withheld or delayed.

(8) The Agency must, at all times take reasonable steps to prevent and mitigate any such claims, demands, proceedings, costs, damages, expenses or loss.

(9) The Agency must, at the request of the undertaker, afford all reasonable assistance for the purpose of contesting any such claim or action, and is entitled to be repaid its reasonably expenses reasonably incurred in so doing.

(10) The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved by the Agency, or to its satisfaction, or in accordance with any directions or award of an arbitrator, does not relieve the undertaker from any liability under the provisions of this Part of this Schedule.

28.  Any dispute arising between the undertaker and the Agency under this part of this Schedule will, if the parties agree, be determined by arbitration under article 48 (arbitration), but will otherwise be determined by the Secretary of State for Environment, Food and Rural Affairs or its successor and the Secretary of State for Transport or its successor acting jointly on a reference to them by the undertaker or the Agency, after notice in writing by one to the other.

PART 4FOR THE PROTECTION OF SURREY COUNTY COUNCIL IN RESPECT OF ORDINARY WATERCOURSES

29.  The following provisions of this Part of this Schedule apply for the protection of Surrey County Council unless otherwise agreed between the undertaker and Surrey County Council.

30.  In this Part of this Schedule—

construction” includes execution, placing, altering, replacing, relaying and removal and “construct” and “constructed” are to be construed accordingly;

drainage work” means an ordinary watercourse and includes any land which is expected to provide flood storage capacity for an ordinary watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage or flood defence in connection with an ordinary watercourse;

ordinary watercourse” has the same meaning as given in section 72 (interpretation) of the Land Drainage Act 1991(7);

plans” includes any information reasonably required by Surrey County Council including location details, grid references, sections, drawings, specifications, assessments and method statements; and

specified work” means any of the following works carried out in relation to any ordinary watercourse—

(a)

erecting any mill dam, weir or other similar obstruction to the flow of the watercourse, or raising or otherwise altering any such obstruction;

(b)

erecting a culvert in the watercourse; or

(c)

altering a culvert in a manner that would be likely to affect the flow of the watercourse.

Ordinary watercourses

31.—(1) Before beginning to construct any specified work, the undertaker must submit to Surrey County Council plans of the specified work, and such further particulars available to the undertaker as Surrey County Council may within 28 days of the first submission of the plans reasonably require or as otherwise agreed between the parties.

(2) The undertaker must not commence construction of the specified work until approval, unconditionally or conditionally, has been given as provided in sub-paragraph (4) of this paragraph.

(3) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by Surrey County Council, or determined under paragraph 38.

(4) Any approval of Surrey County Council required under this paragraph—

(a)must not be unreasonably withheld or delayed;

(b)is to be deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval or where further particulars are submitted under sub-paragraph (1), within 2 months of the submission of those particulars whichever is the later; and

(c)may be given subject to such reasonable requirements or conditions as Surrey County Council may make for the protection of any drainage work.

(5) Any refusal under this paragraph must be accompanied by a statement of the reasons for refusal.

32.  Without limitation on the scope of paragraph 31, the requirements or conditions which Surrey County Council may make under paragraph 31 include conditions requiring the undertaker at its own expense to construct such protective works (including any new works as well as alterations to existing works) as are reasonably necessary—

(a)to safeguard any drainage work against damage by reason of any specified work, or

(b)to secure that the efficiency of any drainage work for flood defence and land drainage purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

33.—(1) Subject to sub-paragraph (2) any specified work, and all protective works required by Surrey County Council under paragraph 32, must be constructed—

(a)without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part of this Schedule; and

(b)to the reasonable satisfaction of Surrey County Council and an officer of Surrey County Council is entitled on giving such notice as may be reasonable in the circumstances, to inspect and watch the construction of such works.

(2) The undertaker must give to Surrey County Council not less than 14 days’ notice of its intention to commence construction of any specified work and the undertaker must give to Surrey County Council notice of completion of a specified work not later than 7 days after the date of completion.

(3) If Surrey County Council reasonably requires, the undertaker must construct all or part of the protective works so that they are in place before the construction of the specified work.

(4) If any part of a specified work or any protective work required is constructed otherwise than in accordance with the requirements of this Part of this Schedule, Surrey County Council may by notice require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and Surrey County Council in writing consents, such consent not to be unreasonably withheld) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as Surrey County Council reasonably requires.

(5) Subject to sub-paragraph (6), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (4) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, Surrey County Council may execute the works specified in the notice and any expenditure reasonably incurred by it in so doing is to be recoverable from the undertaker.

(6) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, Surrey County Council must not, except in an emergency, exercise the powers conferred by sub-paragraph (5) until the dispute has been finally determined.

General

34.—(1) Subject to sub-paragraph (5), from the commencement of the construction of any specified work, the undertaker must maintain in good repair and condition and free from obstruction any drainage work which is situated within the limits of deviation and on land held by the undertaker for the purposes of or in connection with the specified work, whether the drainage work is constructed under this Order or is already in existence.

(2) If any drainage work is not maintained to the reasonable satisfaction of Surrey County Council, it may by notice require the undertaker to repair and restore the drainage work, or any part of it, or (if the undertaker so elects and Surrey County Council in writing consents, such consent not to be unreasonably withheld or delayed) to remove the specified work and restore the site to its former condition to such extent and with such limits as Surrey County Council reasonably requires.

(3) If, within a reasonable period being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the undertaker, that person has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, Surrey County Council may do what is necessary for such compliance and may recover any expenditure reasonably incurred by it in so doing from the person liable for maintenance.

(4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), Surrey County Council must not except in a case of emergency exercise the powers of sub-paragraph (3) until the dispute has been finally determined.

(5) This paragraph does not apply to—

(a)drainage works which are vested in Surrey County Council, or which Surrey County Council or another person is liable to maintain and is not prevented by this Order from so doing; and

(b)any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule provided that any obstruction is removed as soon as reasonably practicable.

35.  If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes or land drainage is impaired, or that drainage work is otherwise damaged, so as to require remedial action, such impairment or damage must be made good as soon as is reasonably practicable by the undertaker to the reasonable satisfaction of Surrey County Council and if the undertaker fails to do so, Surrey County Council may make good the same and recover from the undertaker the expense reasonably incurred by it in doing so.

36.—(1) The undertaker must repay to Surrey County Council all costs, charges and expenses which it may reasonably incur or which it may sustain—

(a)in the examination or approval of plans under this Part of this Schedule;

(b)in the inspection of the construction of a specified work or any protective works required by Surrey County Council under this Part of this Schedule; and

(c)in carrying out any reasonable surveys or tests by Surrey County Council which are reasonably required in connection with the construction of the specified work.

(2) The maximum amount payable to Surrey County Council under sub-paragraph (1)(a) to (c) is to be the same as would have been payable to Surrey County Council in accordance with the scale of charges for pre-application advice and land drainage consent applications published on Surrey County Council’s website from time to time.

37.—(1) Without limiting the other provisions of this Part of this Schedule, the undertaker must make reasonable compensation for the costs reasonably incurred by Surrey County Council from all claims, demands, proceedings, costs, damages, expenses or loss, which may be made or taken against, recovered from, or incurred by Surrey County Council by reason of—

(a)any damage to any ordinary watercourse so as to impair its efficiency for drainage work;

(b)any raising or lowering of the water table in land adjoining the authorised development or any sewers, drains and watercourses; or

(c)any flooding or increased flooding of any such lands,

caused by the construction of any specified work or any act or omission of the undertaker, its contractors, agents or employees whilst engaged on the work.

(2) Surrey County Council must give to the undertaker reasonable notice of any such claim or demand, and no settlement or compromise may be made without the agreement of the undertaker which agreement must not be unreasonably withheld or delayed.

38.  Any dispute arising between the undertaker and Surrey County Council under this Part of this Schedule is to be determined in accordance with article 48 (arbitration).

PART 5FOR THE PROTECTION OF SOUTHERN GAS NETWORKS PLC AS GAS UNDERTAKER

Application

39.  For the protection of SGN the following provisions will, unless otherwise agreed in writing between the undertaker and SGN, have effect.

Interpretation

40.  In this Part of this Schedule—

alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of SGN to enable SGN to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means any gas mains, pipes, pressure governors, ventilators, cathodic protections, cables or other apparatus belonging to or maintained by SGN for the purposes of gas distribution together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of SGN for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

commence” has the same meaning as in Part 1 of Schedule 2 (requirements) and commencement is construed to have the same meaning save that for the purposes of this Part of this Schedule the terms “commence” and “commencement” include operations consisting of non-intrusive investigations and surveys, ecological surveys and pre-construction ecological mitigation, investigations for the purpose of assessing and monitoring ground conditions and levels, erection of any temporary means of enclosure, receipt and erection of construction plant and equipment and site clearance;

deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

“facilities and rights” for construction and for maintenance include any appropriate working areas required to reasonably and safely undertake that construction or maintenance, and any necessary rights of access;

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by SGN (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, requires the undertaker to submit for SGN’s approval a ground mitigation scheme;

ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” includes the ability and right to do any of the following in relation to any apparatus or alternative apparatus of SGN including retain, lay, construct, inspect, maintain, protect, use, access, enlarge, replace, renew, remove, decommission or render unusable or remove the apparatus;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

rights” includes restrictive covenants, and in relation to decommissioned apparatus the surrender of rights, release of liabilities and transfer of decommissioned apparatus;

SGN” means Southern Gas Networks plc or its successors in title or successor bodies and/or any successor as a gas transporter within the meaning of Part 1 of the Gas Act 1986(8);

specified works” means any of the authorised development or activities (including maintenance) undertaken in association with the authorised development which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under sub-paragraph 45(2) or otherwise;

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under sub-paragraph 45(2) or otherwise;

undertaker” means the undertaker as defined in article 2.

On Street Apparatus

41.—(1) This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and SGN are regulated by the provisions of Part 3 of the 1991 Act, except for—

(a)paragraphs 42, 47, 48 and 49; and

(b)where sub-paragraph (2) applies, paragraphs 45 and 46.

(2) This sub-paragraph applies where any apparatus is diverted from an alignment within the existing adopted public highway but not wholly replaced within the existing public highway, notwithstanding that any diversion may be carried out under the provisions of Part 3 of the 1991 Act.

Apparatus of SGN in stopped up streets

42.—(1) Without prejudice to the generality of any other protection afforded to SGN elsewhere in this Order, where any street is stopped up under article 15 (permanent stopping up and restriction of use of streets and private means of access), if SGN has any apparatus in the street or accessed via that street SGN will be entitled to the same rights in respect of such apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to SGN, or procure the granting to SGN of, legal easements reasonably satisfactory to SGN in respect of such apparatus and access to it prior to the stopping up of any such street or highway but nothing in this paragraph is to affect any right of the undertaker or of SGN to require the removal of that apparatus under paragraph 45.

(2) Notwithstanding the temporary stopping up or diversion of any highway under the powers of article 14 (temporary closure and restriction of use of streets), SGN will be at liberty at all times to take all necessary access across any such stopped up highway or to execute and do all such works and things in, upon or under any such highway as it would have been entitled to do immediately before such temporary stopping up or diversion in respect of any apparatus which at the time of the stopping up or diversion was in that highway.

Protective works to buildings

43.  The undertaker must exercise the powers conferred by article 20 (protective work to buildings) so as not to obstruct or render less convenient the access to any apparatus without the written consent of SGN (such consent not to be unreasonably withheld).

Acquisition of land

44.—(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order, the undertaker may not appropriate or acquire any land interest or appropriate, acquire, extinguish or override any easement or other interest or right or apparatus of SGN otherwise than by agreement.

(2) As a condition of agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised development (or in such other timeframe as may be agreed between SGN and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of SGN or affects the provisions of any enactment or agreement regulating the relations between SGN and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as SGN reasonably requires enter into such deeds of consent and variations upon such terms and conditions as may be agreed between SGN and the undertaker acting reasonably and which must be no less favourable on the whole to SGN unless otherwise agreed by SGN, and it will be the responsibility of the undertaker to procure or secure the consent to and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised development or maintenance thereof.

(3) The undertaker and SGN agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus, including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by SGN or other enactments relied upon by SGN as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule must prevail.

(4) Any agreement or consent granted by SGN under paragraph 47 or any other paragraph of this Part of this Schedule, will not be taken to constitute agreement under sub-paragraph (1).

(5) As a condition of an agreement between the parties in sub-paragraph (1) that involves de-commissioned apparatus being left in situ the undertaker must accept a surrender of any existing easement or other interest of SGN in such decommissioned apparatus and release SGN from all liabilities in respect of such de-commissioned apparatus from the date of such surrender.

(6) Where the undertaker acquires land which is subject to any SGN right or interest (including, without limitation, easements and agreements relating to rights or other interests) and the provisions of paragraph 45 do not apply, the undertaker must, unless SGN agrees otherwise—

(a)retain any notice of SGN’s easement, right or other interest on the title to the relevant land when registering the undertaker’s title to such acquired land; and

(b)(where no such notice of SGN’s easement, right or other interest exists in relation to such acquired land or any such notice is registered only on the Land Charges Register) include (with its application to register title to the undertaker’s interest in such acquired land at the Land Registry) a notice of SGN’s easement, right or other interest in relation to such acquired land.

Removal of apparatus

45.—(1) If, in the exercise of the powers conferred by this Order including pursuant to any agreement reached in accordance with paragraph 44, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be decommissioned or removed under this Part of this Schedule and any right of SGN to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, is in operation, and the rights and facilities referred to in sub-paragraph (2) have been provided, to the reasonable satisfaction of SGN and in accordance with sub-paragraphs (2) to (5) inclusive.

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to SGN advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order SGN reasonably needs to move or remove any of its apparatus) the undertaker must afford to SGN to its satisfaction (taking into account sub-paragraph 46(1)) the necessary facilities and rights—

(a)for the construction of alternative apparatus;

(b)subsequently for the maintenance of that apparatus; and

(c)to allow access to that apparatus.

(3) If the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, SGN must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to assist the undertaker in obtaining the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation must not extend to the requirement for SGN to use its compulsory purchase powers to this end unless it (in its absolute discretion) elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between SGN and the undertaker.

(5) SGN must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the prior grant to SGN of such facilities and rights as are referred to in sub-paragraph (2) or (3), then proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to decommission or remove any apparatus required by the undertaker to be decommissioned or removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

46.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for SGN facilities and rights in land for the construction and maintenance of alternative apparatus in substitution for apparatus to be decommissioned or removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and SGN and must be no less favourable on the whole to SGN than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed unless otherwise agreed by SGN.

(2) If the facilities and rights to be afforded by the undertaker and agreed with SGN under sub-paragraph (1) in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to SGN than the facilities and rights enjoyed by it in respect of the apparatus to be decommissioned or removed then the terms and conditions to which those facilities and rights are subject in the matter will be referred to arbitration in accordance with paragraph 53 of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to SGN as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection of SGN

47.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to SGN a plan and, if reasonably required by SGN, a ground monitoring scheme in respect of those works.

(2) The plan to be submitted to SGN under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant etc.;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and

(f)any intended maintenance regimes.

(3) The undertaker must not commence any specified works until SGN has given written approval of the plan so submitted.

(4) Any approval of SGN required under sub-paragraph (3)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraph (5); and

(b)must not be unreasonably withheld or delayed and SGN must meaningfully engage with the undertaker within 28 days of the date of submission of the plan under sub-paragraph (1).

(5) SGN may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Specified works must only be executed in accordance with—

(a)the plan submitted under sub-paragraph (1), as approved or as amended from time to time by agreement between the undertaker and SGN; and

(b)all conditions imposed under sub-paragraph (4)(a), and SGN will be entitled to watch and inspect the execution of those works.

(7) Where SGN requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to SGN’s satisfaction prior to the commencement of any specified works (or any relevant part thereof) for which protective works are required prior to commencement.

(8) If SGN, in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 39 to 41 and 44 to 46 apply as if the removal of the apparatus had been required by the undertaker under sub-paragraph 45(2).

(9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(10) The undertaker is not be required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to SGN notice as soon as is reasonably practicable and a plan of those works and must comply with—

(a)the conditions imposed under sub-paragraph (4)(a) insofar as is reasonably practicable in the circumstances; and

(b)sub-paragraph (11) at all times.

(11) As soon as reasonably practicable after any ground subsidence event attributable to the authorised development the undertaker must implement an appropriate ground mitigation scheme save that SGN retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 48.

(12) In this paragraph, “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

Expenses

48.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to SGN on demand all charges, costs and expenses reasonably anticipated or incurred by SGN in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised development as are referred to in this Part of this Schedule including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by SGN in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs (including professional fees) incurred by SGN as a consequence of SGN—

(i)using its own compulsory purchase powers to acquire any necessary rights under sub-paragraph 45(3) if it elects to do so; or

(ii)exercising any compulsory purchase powers in the Order transferred to or benefitting SGN;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule; and

(g)any watching brief pursuant to sub-paragraph 47(6).

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 53 to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to SGN by virtue of sub-paragraph (1) will be reduced by the amount of that excess save where it is not possible in the circumstances (or it would be unlawful due to a statutory or regulatory change) to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to SGN in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on SGN any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

49.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works authorised by this Part of this Schedule (including without limitation relocation, diversion, decommissioning, construction, and maintenance of apparatus or alternative apparatus) or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised development) or property of SGN, or there is any interruption in any service provided, or in the supply of any goods, by SGN, or SGN becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand accompanied by an invoice or claim from SGN the cost reasonably incurred by SGN in making good such damage or restoring the supply; and

(b)indemnify SGN for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from SGN, by reason or in consequence of any such damage or interruption or SGN becoming liable to any third party as aforesaid other than arising from any default of SGN.

(2) The fact that any act or thing may have been done by SGN on behalf of the undertaker or in accordance with a plan approved by SGN or in accordance with any requirement of SGN or under its supervision including under any watching brief will not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless SGN fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of SGN, its officers, servants, contractors or agents; and

(b)any part of the authorised development carried out by SGN in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 9 (consent to transfer benefit of Order).

(4) SGN must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

Enactments and agreements

50.  Except where this Part of this Schedule provides otherwise, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and SGN in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

51.—(1) Where in consequence of the proposed construction of any of the authorised development, the undertaker or SGN requires the removal of apparatus under sub-paragraph 45(2) or SGN makes requirements for the protection or alteration of apparatus under paragraph 47, the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of SGN’s undertaking and SGN must use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever SGN’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed.

Access

52.  If in consequence of the agreement reached in accordance with sub-paragraph 44(1) or the powers conferred under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative rights and means of access to such apparatus as will enable SGN to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

53.  Save for differences or disputes arising under sub-paragraphs 45(2), 45(4) and 46(1) any difference or dispute arising between the undertaker and SGN under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and SGN, be determined by arbitration in accordance with article 48 (arbitration).

PART 6FOR THE PROTECTION OF NATIONAL GRID AS ELECTRICITY UNDERTAKER

Application

54.—(1) For the protection of National Grid the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Grid.

(2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Grid, where the benefit of this Order is transferred or granted to another person under article 9 (consent to transfer benefit of Order)—

(a)any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between National Grid and the transferee or grantee (as the case may be); and

(b)written notice of the transfer or grant must be given to National Grid on or before the date of that transfer or grant.

(3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid (but see paragraph 64(3)(b)).

Interpretation

55.  In this Part of this Schedule—

alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means any electric lines or electrical plant as defined in the Electricity Act 1989(9), belonging to or maintained by National Grid together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of National Grid for the purposes of transmission, distribution or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) (interpretation) and includes any associated development authorised by the Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Part of this Schedule;

“commence” and “commencement” in paragraph 62 and 65 includes any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment;

deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by National Grid (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, will require the undertaker to submit for National Grid’s approval a ground mitigation scheme;

ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” includes the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Grid including construct, use, repair, alter, inspect, renew or remove the apparatus;

National Grid” means National Grid Electricity Transmission Plc or any successor as a licence holder within the meaning of Part 1 of the Electricity Act 1989;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

specified works” means any of the authorised works or activities undertaken in association with the authorised works which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 60(2) or otherwise; or

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 60(2) or otherwise.

56.  Except for paragraphs 57 (apparatus of National Grid in stopped up streets), 62 (retained apparatus: protection of electricity undertaker) 63 (expenses) and 64 (indemnity) which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of National Grid, the other provisions of this Part of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus of National Grid in stopped up streets

57.—(1) Where any street is stopped up under article 15 (permanent stopping up and restriction of use of streets and private means of access), if National Grid has any apparatus in the street or accessed via that street National Grid has the same rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to National Grid, or procure the granting to National Grid of, legal easements reasonably satisfactory to National Grid in respect of such apparatus and access to it prior to the stopping up of any such street but nothing in this paragraph affects any right of the undertaker or National Grid to require the removal of that apparatus under paragraph 60 (removal of apparatus) or the power of the undertaker, subject to compliance with this sub-paragraph, to carry out works under paragraph 62 (retained apparatus: protection of electricity undertaker).

(2) Notwithstanding the temporary stopping up or diversion of any highway under the powers of article 14 (temporary closure and restriction of use of streets), National Grid is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Protective works to buildings

58.  The undertaker must exercise the powers conferred by article 20 (protective work to buildings) so as not to obstruct or render less convenient the access to any apparatus without the written consent of National Grid (such consent not to be unreasonably withheld).

Acquisition of land

59.—(1) Regardless of any provision in this Order or anything shown on the land plans, the undertaker may not acquire any interest in land or apparatus or override any easement or other interest of National Grid otherwise than by agreement.

(2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Grid and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid or affect the provisions of any enactment or agreement regulating the relations between National Grid and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid unless otherwise agreed by National Grid, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

(3) The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid and/or other enactments relied upon by National Grid as of right or other use in relation to the apparatus, then the provisions in this Part of this Schedule will prevail.

(4) Any agreement or consent granted by National Grid under paragraph 62 (retained apparatus: protection of electricity undertaker) or any other paragraph of this Part of this Schedule, is not to be taken to constitute agreement under sub-paragraph (1).

Removal of apparatus

60.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (2) to (5).

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to National Grid to its reasonable satisfaction (taking into account paragraph 61(1) (facilities and rights for alternative apparatus)) the necessary facilities and rights—

(a)for the construction of alternative apparatus in other land of or secured by, the undertaker; and

(b)subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation will not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.

(5) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

61.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Grid facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid.

(2) If the facilities and rights to be afforded by the undertaker under sub-paragraph (1) in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the matter may be referred to arbitration in accordance with paragraph 68 (arbitration) and the arbitrator must make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus: protection of electricity undertaker

62.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Grid a plan of the works to be executed and seek from National Grid details of the underground extent of their electricity tower foundations.

(2) In relation to works which will or may be situated on, over, under or within 15 metres measured in any direction of any apparatus or involve embankment works within 15 metres of any apparatus, the plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

(f)any intended maintenance regimes; and

(g)an assessment of risks of rise of earth issues.

(3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement including—

(a)details of any cable trench design including route, dimensions, clearance to pylon foundations;

(b)demonstration that pylon foundations will not be affected prior to, during and post construction;

(c)details of load bearing capacities of trenches;

(d)details of any cable installation methodology including access arrangements, jointing bays and backfill methodology;

(e)a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route;

(f)written details of the operations and maintenance regime for any cable, including frequency and method of access;

(g)an assessment of earth rise potential if reasonably required by National Grid’s engineers; and

(h)evidence that trench bearing capacity is to be designed to support overhead line construction traffic of up to 26 tonnes in weight.

(4) The undertaker must not commence any works to which sub-paragraphs (2) or (3) apply until National Grid has given written approval of the plan so submitted.

(5) Any approval of National Grid required under sub-paragraph (4)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (6) or (8); and

(b)must not be unreasonably withheld.

(6) In relation to any work to which sub-paragraphs (2) or (3) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage, for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(7) Works executed under sub-paragraphs (2) or (3) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (6), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (6) or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.

(8) Where under sub-paragraph (6) National Grid requires any protective works to be carried out by itself or by the undertaker(whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Grid’s satisfaction prior to the commencement of any specified works for which protective works are required and National Grid must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

(9) If National Grid in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 54 to 56 and 59 to 61 apply as if the removal of the apparatus had been required by the undertaker under paragraph 60(2).

(10) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(11) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances.

(12) In sub-paragraph (11) “emergency works” means works whose execution at the time when they are executed is required in order to put an end to or to prevent the occurrence of circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

Expenses

63.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid—

(i)using its own compulsory purchase powers to acquire any necessary rights under paragraph 60(3); or

(ii)exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; and

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 68 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

(5) Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

64.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand accompanied by an invoice or claim from National Grid the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and

(b)indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid other than arising from any default of National Grid.

(2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) will impose any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents; and

(b)any part of the authorised works carried out by National Grid in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 9 (consent to transfer benefit of Order).

(4) National Grid must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

(5) National Grid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

(6) National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the undertaker National Grid must provide an explanation of how the claim has been minimised, where relevant.

Enactments and agreements

65.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

66.—(1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid requires the removal of apparatus under paragraph 60(2) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 62 (retained apparatus: protection of electricity undertaker), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid shall use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever the undertaker’s or National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted under this Schedule, or agreement is required to be reached between the parties under this Part of this Schedule, it must not be unreasonably withheld or delayed.

Access

67.  If in consequence of the agreement reached in accordance with paragraph 59(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

68.  Save for differences or disputes arising under paragraphs 60(2), 60(4) and 61(1), any difference or dispute arising between the undertaker and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 48 (arbitration).

Notices

69.  Notwithstanding article 47 (service of notices), any plans submitted to National Grid by the undertaker pursuant to paragraph 62 must be sent to National Grid Plant Protection at plantprotection@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing.

(1)

1989 c. 29. The definition of “electrical plant” (in section 64) was amended by paragraphs 24 and 38(1) and (3) of Schedule 6 to the Utilities Act 2000 (c. 27).

(2)

1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45), and was further amended by section 76 of, and paragraphs 1 and 4 of Schedule 8 to the Utilities Act 2000 (c. 27), sections 149(1) and (5) and 197(9) of, and Part 1 of Schedule 23 to, the Energy Act 2004 (c. 20) and S.I. 2011/2704.

(4)

Section 102(4) was amended by section 96(1)(c) of the Water Act 2003 (c. 37). Section 104 was amended by sections 96(4) and 101(2) of, and Part 3 of Schedule 9 to, the Water Act 2003 and section 42(3) of the Flood and Water Management Act 2010 (c. 29) and section 11(1) and (2) of, and paragraphs 2 and 91 of Schedule 7 to the Water Act 2014 (c. 21).

(6)

See section 106 which was amended by section 4(3) to (9) of the Digital Economy Act 2017 (c. 30).

Back to top

Options/Help

Print Options

You have chosen to open the Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

Close

Legislation is available in different versions:

Latest Available (revised):The latest available updated version of the legislation incorporating changes made by subsequent legislation and applied by our editorial team. Changes we have not yet applied to the text, can be found in the ‘Changes to Legislation’ area.

Original (As Enacted or Made): The original version of the legislation as it stood when it was enacted or made. No changes have been applied to the text.

Close

Opening Options

Different options to open legislation in order to view more content on screen at once

Close

More Resources

Access essential accompanying documents and information for this legislation item from this tab. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as enacted version that was used for the print copy
  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • correction slips
  • links to related legislation and further information resources
Close

More Resources

Use this menu to access essential accompanying documents and information for this legislation item. Dependent on the legislation item being viewed this may include:

  • the original print PDF of the as made version that was used for the print copy
  • correction slips

Click 'View More' or select 'More Resources' tab for additional information including:

  • lists of changes made by and/or affecting this legislation item
  • confers power and blanket amendment details
  • all formats of all associated documents
  • links to related legislation and further information resources