Search Legislation

The A47 Wansford to Sutton Development Consent Order 2023

 Help about what version

What Version

 Help about advanced features

Advanced Features

 Help about opening options

Opening OptionsExpand opening options

Changes to legislation:

There are currently no known outstanding effects for the The A47 Wansford to Sutton Development Consent Order 2023, SCHEDULE 9. Help about Changes to Legislation

Articles 36 and 46

SCHEDULE 9E+W+SPROTECTIVE PROVISIONS

PART 1E+W+SFOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWAGE UNDERTAKERS

1.  For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions have effect, unless otherwise identified in another Part of this Schedule or agreed in writing between the undertaker and the utility undertaker concerned.E+W+S

Commencement Information

I1Sch. 9 para. 1 in force at 10.3.2023, see art. 1

2.  In this Part of this Schedule—E+W+S

alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989(1)), belonging to or maintained by that utility undertaker;

(b)

in that case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter within the meaning of Part 1 of the Gas Act 1986(2) for the purposes of gas supply;

(c)

in the case of water undertaker, mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the utility undertaker under the Water Industry Act 1991(3); and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4)(4) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 (agreement to adopt sewers, drains or sewage disposal works at future date) of that Act(5),

and includes a sludge main, disposal main (within the meaning of section 219 (general interpretation)(6) of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land;

“plan” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; and

utility undertaker” means—

(a)

any licence holder within the meaning of Part 1 (electricity supply) of the Electricity Act 1989;

(b)

a gas transporter within the meaning of Part 1 (gas supply) of the Gas Act 1986;

(c)

a water undertaker within the meaning of the Water Industry Act 1991; and

(d)

a sewerage undertaker within the meaning of Part 1 (preliminary) of the Water Industry Act 1991,

for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

Commencement Information

I2Sch. 9 para. 2 in force at 10.3.2023, see art. 1

On street apparatusE+W+S

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.

Commencement Information

I3Sch. 9 para. 3 in force at 10.3.2023, see art. 1

Apparatus in stopped up streetsE+W+S

4.—(1) Where any street is stopped up under article 17 (permanent stopping up and restriction of use of streets and private means of access), any utility undertaker whose apparatus is in the street has the same powers and rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to the utility undertaker legal easements reasonably satisfactory to the utility undertaker in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of the utility undertaker to require the removal of that apparatus under paragraph 7 (removal of apparatus) or the power of the undertaker to carry out works under paragraph 9 (retained apparatus).

(2) Regardless of the temporary alteration, diversion, prohibition and restriction of the use of streets under the powers conferred by article 16 (temporary stopping up and restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such stopped up highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Commencement Information

I4Sch. 9 para. 4 in force at 10.3.2023, see art. 1

Protective works to buildingsE+W+S

5.  The undertaker, in the case of the powers conferred by article 22 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.

Commencement Information

I5Sch. 9 para. 5 in force at 10.3.2023, see art. 1

Acquisition of landE+W+S

6.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Commencement Information

I6Sch. 9 para. 6 in force at 10.3.2023, see art. 1

Removal of apparatusE+W+S

7.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (6).

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 49 (arbitration).

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 49 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that the undertaker desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

Commencement Information

I7Sch. 9 para. 7 in force at 10.3.2023, see art. 1

Facilities and rights for alternative apparatusE+W+S

8.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 49 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I8Sch. 9 para. 8 in force at 10.3.2023, see art. 1

Retained apparatusE+W+S

9.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 7(2) (removal of apparatus), the undertaker must submit to the utility undertaker in question a plan of the works to be executed.

(2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) are to be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

(4) If a utility undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 3 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

(6) The undertaker is not required to comply with sub-paragraph (5) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances.

(7) In relation to works which will or may be situated on, over, under or within 10 metres measured in any direction of any electricity apparatus, or involve embankment works within 10 metres of any electricity apparatus, the plan to be submitted to the utility undertaker under sub-paragraph (1) must be detailed, include a method statement and describe—

(a)the exact position of the works;

(b)the level at which they are proposed to be constructed or renewed;

(c)the manner of their construction or renewal;

(d)the position of all electricity apparatus; and

(e)by way of detailed drawings, every alteration proposed to be made to such apparatus.

Commencement Information

I9Sch. 9 para. 9 in force at 10.3.2023, see art. 1

Expenses and costsE+W+S

10.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker all expenses reasonably incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 7(2) (removal of apparatus).

(2) The value of any apparatus removed under the provisions of this Part of this Schedule must be deducted from any sum payable under sub-paragraph, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 49 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Commencement Information

I10Sch. 9 para. 10 in force at 10.3.2023, see art. 1

11.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 5 (protective work to buildings) or 7(2) (removal of apparatus) any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

(2) The fact that any act or thing may have been done by a utility undertaker on behalf of the undertaker or in accordance with a plan approved by a utility undertaker or in accordance with any requirement of a utility undertaker or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1).

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(4) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker and, if such consent is withheld, has the sole conduct of any settlement or compromise of any proceedings necessary to resist the claim or demand.

Commencement Information

I11Sch. 9 para. 11 in force at 10.3.2023, see art. 1

CooperationE+W+S

12.  Where in consequence of the proposed construction of any part of the authorised development, the undertaker or a utility undertaker requires the removal of apparatus under paragraph 7(2) (removal of apparatus) or a utility undertaker makes requirements for the protection or alteration of apparatus under paragraph 9 (retained apparatus), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of the utility undertaker’s undertaking and each utility undertaker must use its best endeavours to co- operate with the undertaker for that purpose.

Commencement Information

I12Sch. 9 para. 12 in force at 10.3.2023, see art. 1

13.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I13Sch. 9 para. 13 in force at 10.3.2023, see art. 1

PART 2E+W+SFOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

14.  For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.E+W+S

Commencement Information

I14Sch. 9 para. 14 in force at 10.3.2023, see art. 1

15.  In this Part of this Schedule—E+W+S

the 2003 Act” means the Communications Act 2003(7);

electronic communications apparatus” has the same meaning as in the electronic communications code;

the electronic communications code” has the same meaning as in Chapter 1 (electronic communications, networks and services) of Part 2 of the 2003 Act(8);

electronic communications code network” means—

(a)

so much of an electronic communications network or infrastructure system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 (application of the electronic communications code) of the 2003 Act; and

(b)

an electronic communications network which the undertaker is providing or proposing to provide;

electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7(2) of that code; and

operator” means the operator of an electronic communications code network.

Commencement Information

I15Sch. 9 para. 15 in force at 10.3.2023, see art. 1

16.  The exercise of the powers conferred by article 36 (statutory undertakers) is subject to Part 10 (undertakers’ works affecting electronic communications apparatus) of the electronic communications code.E+W+S

Commencement Information

I16Sch. 9 para. 16 in force at 10.3.2023, see art. 1

17.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—E+W+S

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this Part of this Schedule must be referred to and settled by arbitration under article 49 (arbitration).

(5) This Part of this Schedule does not apply to—

(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act; or

(b)any damages, or any interruptions, caused by electro-magnetic interference arising from the construction or use of the authorised development.

(6) Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I17Sch. 9 para. 17 in force at 10.3.2023, see art. 1

PART 3E+W+SFOR THE PROTECTION OF ANGLIAN WATER

ApplicationE+W+S

18.  For the protection of Anglian Water, the following provisions have effect, unless otherwise agreed in writing between the undertaker and Anglian Water.

Commencement Information

I18Sch. 9 para. 18 in force at 10.3.2023, see art. 1

InterpretationE+W+S

19.  In this part of this Schedule—

alternative apparatus” means alternative apparatus adequate to enable Anglian Water to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means—

(a)

any works, mains, pipes or other apparatus belonging to or maintained by Anglian Water for the purposes of water supply and sewerage;

(b)

any drain or works vested in Anglian Water under The Water Industry Act 1991,

(c)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) (adoption of sewers and disposal works) of that Act or an agreement to adopt made under section 104 (agreements to adopt sewer, drain or sewage disposal works, at future date) of that Act; and

(d)

includes a sludge main, disposal main or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus

and for the purpose of this definition, where words are defined by section 219 (general interpretation) of the Water Industry Act 1991 they shall be taken to have the same meaning.

functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed.

Commencement Information

I19Sch. 9 para. 19 in force at 10.3.2023, see art. 1

On street apparatusE+W+S

20.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Anglian Water are regulated by the provisions of Part 3 of the 1991 Act.

Commencement Information

I20Sch. 9 para. 20 in force at 10.3.2023, see art. 1

Schedule of apparatusE+W+S

21.—(1) Before commencement of any work set out in Schedule 1 to divert any apparatus the undertaker will provide Anglian Water with a schedule of apparatus which will be diverted as part of the authorised development setting out for each piece of apparatus whether those works are to be undertaken under this Schedule or under the 1991 Act and, where a diversion is to be carried out partly under this Schedule and partly under the 1991 Act, details of which part of the diversion is to be carried out under which power.

(2) The undertaker may from time to time provide to Anglian Water amendments to the schedule referred to in sub-paragraph (1).

(3) No amendment may be submitted under sub-paragraph (2) in respect of apparatus which is to be diverted as part of a work set out in Schedule 1, or which comprises such a work, after that work has commenced.

Commencement Information

I21Sch. 9 para. 21 in force at 10.3.2023, see art. 1

Apparatus in stopped up streetsE+W+S

22.—(1) Where any street is stopped up under article 17 (permanent stopping up and restriction of use of streets and private means of access), where Anglian Water has apparatus in the street or accessed by virtue of that street, it has the same powers and rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to Anglian Water legal easements reasonably satisfactory to Anglian Water in respect of such apparatus and access to it, but nothing in this paragraph affects any right of the undertaker or of Anglian Water to require the removal of that apparatus under paragraph 25 (removal of apparatus) or the power of the undertaker to carry out works under paragraph 27 (retained apparatus).

(2) Regardless of the temporary alteration, diversion or prohibition of the use of or restriction of the use of any highway under the powers conferred by article 16 (temporary stopping up and restriction of use of streets), Anglian Water is at liberty at all times to take all necessary access across any such altered, diverted, prohibited or restricted highway and to execute and do all such works and things in, upon or under any such highway as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the alteration, diversion or prohibition of use of or restriction of use was in that highway.

Commencement Information

I22Sch. 9 para. 22 in force at 10.3.2023, see art. 1

Protective works to buildingsE+W+S

23.  The undertaker, in the case of the powers conferred by article 22 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus.

Commencement Information

I23Sch. 9 para. 23 in force at 10.3.2023, see art. 1

Acquisition of landE+W+S

24.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Commencement Information

I24Sch. 9 para. 24 in force at 10.3.2023, see art. 1

Removal of apparatusE+W+S

25.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that Anglian Water’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Anglian Water to maintain that apparatus in that land must not (without the prior written consent of Anglian Water) be extinguished, until—

(a)alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Anglian Water in accordance with sub-paragraphs (2) to (8); and

(b)facilities and rights have been secured for that alternative apparatus in accordance with paragraph 26 (facilities and rights for alternative apparatus).

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Anglian Water 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order an undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Anglian Water the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed Anglian Water must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Anglian Water and the undertaker or in default of agreement settled by arbitration in accordance with [F1article 49] (arbitration).

(5) Anglian Water must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with [F2article 49] (arbitration), and after the grant to Anglian Water of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if Anglian Water gives notice in writing to the undertaker that it desires the undertaker to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, or to the extent that Anglian Water fails to proceed with that work in accordance with sub-paragraph (5) or the undertaker and Anglian Water otherwise agree, that work, instead of being executed by Anglian Water, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of Anglian Water.

(7) Notice under sub-paragraph (6) that Anglian Water desires the undertaker to execute any work, or part of any work, must be given within 14 days of agreement under sub-paragraph (4) or, in default of agreement, within 14 days of the date of settlement by arbitration under sub-paragraph (4).

(8) If Anglian Water fails either reasonably to approve, or to provide reasons for its failure to approve along with an indication of what would be required to make acceptable, any proposed details relating to required removal works under sub-paragraph (2) within 28 days of receiving a notice of the required works from the undertaker, then such details are deemed to have been approved. For the avoidance of doubt, any such “deemed consent” does not extend to the actual undertaking of the removal works, which shall remain the sole responsibility of Anglian Water or its contractors.

(9) Whenever alternative apparatus is to be or is being substituted for existing apparatus, the undertaker shall, before taking or requiring any further step in such substitution works, use best endeavours to comply with Anglian Water’s reasonable requests for a reasonable period of time to enable Anglian Water to—

(a)make network contingency arrangements; or

(b)bring such matters as it may consider reasonably necessary to the attention of end users of the utility in question.

Textual Amendments

Commencement Information

I25Sch. 9 para. 25 in force at 10.3.2023, see art. 1

Facilities and rights for alternative apparatusE+W+S

26.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Anglian Water facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and Anglian Water or in default of agreement settled by arbitration in accordance with article 49 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Anglian Water than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Anglian Water as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

(3) Such facilities and rights as are set out in this paragraph are deemed to include any statutory permits granted to the undertaker in respect of the apparatus in question, whether under the Environmental Permitting (England and Wales) Regulations 2016 or other legislation.

Commencement Information

I26Sch. 9 para. 26 in force at 10.3.2023, see art. 1

Retained apparatusE+W+S

27.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus (or any means of access to it) the removal of which has not been required by the undertaker under paragraph 25(2) (removal of apparatus), the undertaker must submit to Anglian Water a plan of the works to be executed.

(2) Those works must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Anglian Water for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Anglian Water is entitled to watch and inspect the execution of those works.

(3) Any requirements made by Anglian Water under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan under sub-paragraph (1) is submitted to it.

(4) If Anglian Water, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, sub-paragraphs (1) to (3) and (6) to (7) apply as if the removal of the apparatus had been required by the undertaker under paragraph 25(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case must give to Anglian Water notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (3) in so far as is reasonably practicable in the circumstances and will keep the impact of those emergency works on Anglian Water’s apparatus, on the operation of its water and sewerage network and on end-users of the services Anglian Water provides to a minimum.

(7) For the purposes of sub-paragraph (1), works are deemed to be in land near Anglian Water’s apparatus (where it is a pipe) if those works fall within the following distances measured from the medial line of such apparatus—

(a)2.25 metres where the diameter of the pipe is less than 150 millimetres;

(b)3 metres where the diameter of the pipe is between 150 and 450 millimetres;

(c)4.5 metres where the diameter of the pipe is between 451 and 750 millimetres; and

(d)6 metres where the diameter of the pipe exceeds 750 millimetres.

Commencement Information

I27Sch. 9 para. 27 in force at 10.3.2023, see art. 1

Expenses and costsE+W+S

28.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to Anglian Water all expenses reasonably incurred by Anglian Water in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in this Part of the Schedule.

(2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with [F3article 49] (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Anglian Water by virtue of sub-paragraph (1) must be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to Anglian Water in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on Anglian Water any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Textual Amendments

Commencement Information

I28Sch. 9 para. 28 in force at 10.3.2023, see art. 1

29.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any such works referred to in paragraphs 23 (protective work to buildings) or 25(2) (removal of apparatus), or by reason of any subsidence resulting from such development or works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Anglian Water, or there is any interruption in any service provided, or in the supply of any goods, by Anglian Water, the undertaker must—

(a)bear and pay the cost reasonably incurred by Anglian Water in making good such damage or restoring the supply; and

(b)make reasonable compensation to Anglian Water for any other expenses, loss, damages, penalty or costs incurred by the undertaker, by reason or in consequence of any such damage or interruption.

(2) The fact that any act or thing may have been done by Anglian Water on behalf of the undertaker or in accordance with a plan approved by Anglian Water or in accordance with any requirement of Anglian Water or under its supervision does not, subject to sub-paragraph (3), excuse the undertaker from liability under the provisions of sub-paragraph (1) unless Anglian Water fails to carry out and execute the works properly with due care and attention and in a skilful and professional like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Anglian Water, its officers, servants, contractors or agents.

(4) Anglian Water must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made, without the consent of the undertaker (such consent not to be unreasonably withheld or delayed) who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I29Sch. 9 para. 29 in force at 10.3.2023, see art. 1

CooperationE+W+S

30.  Where in consequence of the proposed construction of any of the authorised development, the undertaker or Anglian Water requires the removal of apparatus under paragraph 25(2) (removal of apparatus) or Anglian Water makes requirements for the protection or alteration of apparatus under paragraph 27 (retained apparatus), the undertaker must use all reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of Anglian Water’s undertaking and Anglian Water must use all reasonable endeavours to co-operate with the undertaker for that purpose.

Commencement Information

I30Sch. 9 para. 30 in force at 10.3.2023, see art. 1

31.  Where the undertaker identifies any apparatus which may belong to or be maintainable by Anglian Water but which does not appear on any statutory map kept for the purpose by Anglian Water, it shall inform Anglian Water of the existence and location of the apparatus as soon as reasonably practicable.

Commencement Information

I31Sch. 9 para. 31 in force at 10.3.2023, see art. 1

32.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Anglian Water in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I32Sch. 9 para. 32 in force at 10.3.2023, see art. 1

33.  Any time period in which an action must be taken in this part of the Schedule may be amended by written agreement between the undertaker and Anglian Water.

Commencement Information

I33Sch. 9 para. 33 in force at 10.3.2023, see art. 1

PART 4E+W+SFOR THE PROTECTION OF NGG AS GAS UNDERTAKER

ApplicationE+W+S

34.—(1) For the protection of National Grid as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Grid.

(2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and NGG, where the benefit of this Order is transferred or granted to another person under article 10 (consent to transfer benefit of Order)—

(a)any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between NGG and the transferee or grantee (as the case may be); and

(b)written notice of the transfer or grant must be given to NGG on or before the date of that transfer or grant.

(3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to NGG (but see paragraph 44(3)(b)).

Commencement Information

I34Sch. 9 para. 34 in force at 10.3.2023, see art. 1

InterpretationE+W+S

35.  In this Part of this Schedule—

1991 Act” means the New Roads and Street Works Act 1991;

alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of NGG to enable NGG to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means any gas mains, pipes, pressure governors, ventilators, cathodic protections, cables or other apparatus belonging to or maintained by NGG for the purposes of gas supply together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of NGG for the purposes of transmission, distribution or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) (interpretation) of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule;

“commence” and “commencement” in paragraph 42 (retained apparatus: protection of gas undertaker) of this Part of this Schedule includes any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment,

deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by NGG (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, requires the undertaker to submit for NGG’s approval a ground mitigation scheme;

ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” includes the ability and right to do any of the following in relation to any apparatus or alternative apparatus of NGG including construct, use, repair, alter, inspect, renew or remove the apparatus;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

specified works” means any of the authorised works or activities undertaken in association with the authorised works which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 40(2) (removal of apparatus) or otherwise; or

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 40(2) or otherwise.

Commencement Information

I35Sch. 9 para. 35 in force at 10.3.2023, see art. 1

36.  Except for paragraphs 37 (apparatus of NGG in stopped up streets), 42 (retained apparatus: protection of gas undertaker), 43 (expenses) and 44 (indemnity) of this Part of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of NGG, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and NGG are regulated by the provisions of Part 3 of the 1991 Act.

Commencement Information

I36Sch. 9 para. 36 in force at 10.3.2023, see art. 1

Apparatus of NGG in stopped up streetsE+W+S

37.—(1) Where any street is stopped up under article 17 (permanent stopping up and restriction of use of streets and private means of access), if NGG has any apparatus in the street or accessed via that street NGG has the same rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to NGG, or procure the granting to NGG of, legal easements reasonably satisfactory to NGG in respect of such apparatus and access to it prior to the stopping up of any such street but nothing in this paragraph affects any right of the undertaker or NGG to require the removal of that apparatus under paragraph 40 (removal of apparatus) or the power of the undertaker, subject to compliance with this sub-paragraph, to carry out works under paragraph 42 (retained apparatus: protection of gas undertaker).

(2) Notwithstanding the temporary alteration, diversion or restriction of any highway under the powers of article 16 (temporary stopping up and restriction of use of streets), NGG will be at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the alteration, diversion or restriction was in that street.

Commencement Information

I37Sch. 9 para. 37 in force at 10.3.2023, see art. 1

Protective works to buildingsE+W+S

38.  The undertaker must exercise the powers conferred by article 22 (protective work to buildings) so as not to obstruct or render less convenient the access to any apparatus without the written consent of NGG (such consent not to be unreasonably withheld).

Commencement Information

I38Sch. 9 para. 38 in force at 10.3.2023, see art. 1

Acquisition of landE+W+S

39.—(1) Regardless of any provision in this Order or anything shown on the land plans, the undertaker may not acquire any interest in land or apparatus or override any easement or other interest of NGG otherwise than by agreement.

(2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between NGG and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of NGG or affect the provisions of any enactment or agreement regulating the relations between NGG and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as NGG reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between NGG and the undertaker acting reasonably and which must be no less favourable on the whole to NGG unless otherwise agreed by NGG, and it will be the responsibility of the undertaker to procure and secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

(3) The undertaker and NGG agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by NGG or other enactments relied upon by NGG as of right or other use in relation to the apparatus, then the provisions in this Schedule prevail.

(4) Any agreement or consent granted by NGG under paragraph 42 (retained apparatus: protection of gas undertaker) or any other paragraph of this Part of this Schedule, is not to be taken to constitute agreement under sub-paragraph (1).

Commencement Information

I39Sch. 9 para. 39 in force at 10.3.2023, see art. 1

Removal of apparatusE+W+S

40.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of NGG to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of NGG in accordance with sub-paragraphs (2) to (5).

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to NGG advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order NGG reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to NGG to its reasonable satisfaction (taking into account paragraph 41(1)) the necessary facilities and rights—

(a)for the construction of alternative apparatus in other land of, or secured by, the undertaker; and

(b)subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, NGG must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for NGG to use its compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between NGG and the undertaker.

(5) NGG must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to NGG of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Commencement Information

I40Sch. 9 para. 40 in force at 10.3.2023, see art. 1

Facilities and rights for alternative apparatusE+W+S

41.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for NGG facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and NGG and must be no less favourable on the whole to NGG than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by NGG.

(2) If the facilities and rights to be afforded by the undertaker under sub-paragraph (1) above in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to NGG than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the matter may be referred to arbitration in accordance with paragraph 48 (arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to NGG as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I41Sch. 9 para. 41 in force at 10.3.2023, see art. 1

Retained apparatus: protection of gas undertakerE+W+S

42.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to NGG a plan and, if reasonably required by NGG, a ground monitoring scheme in respect of those works.

(2) The plan to be submitted to NGG under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant etc;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and

(f)any intended maintenance regimes.

(3) The undertaker must not commence any specified works until NGG has given written approval of the plan so submitted.

(4) Any approval of NGG required under sub-paragraph (3)

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (5) or (7); and,

(b)must not be unreasonably withheld or delayed.

(5) NGG may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Specified works must only be executed in accordance with—

(a)the plan, submitted under sub-paragraph (1), as approved or as amended from time to time by agreement between the undertaker and NGG; and

(b)such reasonable requirements as may be made in accordance with sub-paragraphs (5) or (7) by NGG for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and NGG will be entitled to watch and inspect the execution of those works.

(7) Where under sub-paragraph (6) NGG requires any protective works to be carried out by itself or by the undertaker such protective works (whether of a temporary or permanent nature) must be carried out to NGG’s satisfaction prior to the commencement of any specified works for which protective works are required and NGG must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

(8) If NGG in accordance with sub-paragraphs (5) or (7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 34 to 36 and 39 to 41 apply as if the removal of the apparatus had been required by the undertaker under paragraph 40(2) (removal of apparatus).

(9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(10) As soon as reasonably practicable after any ground subsidence event attributable to the authorised works—

(a)the undertaker must implement an appropriate ground mitigation scheme; and

(b)NGG retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 43 (expenses).

(11) The undertaker is not be required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to NGG notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (5), (6) and (7) insofar as is reasonably practicable in the circumstances.

(12) In sub-paragraph (11), “emergency works” means works whose execution at the time when they are executed is required in order to put an end to, or to prevent the occurrence of, circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

Commencement Information

I42Sch. 9 para. 42 in force at 10.3.2023, see art. 1

ExpensesE+W+S

43.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to NGG within 30 days of receipt of an itemised invoice or claim from NGG all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by NGG in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by NGG in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by NGG as a consequence of NGG—

(i)using its own compulsory purchase powers to acquire any necessary rights under paragraph 40(3) (removal of apparatus); or

(ii)exercising any compulsory purchase powers in the Order transferred to or benefitting NGG;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 48 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to NGG by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

(5) Any amount which apart from this sub-paragraph would be payable to NGG in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on NGG any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I43Sch. 9 para. 43 in force at 10.3.2023, see art. 1

IndemnityE+W+S

44.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of NGG, or there is any interruption in any service provided, or in the supply of any goods, by NGG, or NGG becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand accompanied by an invoice or claim from NGG the cost reasonably and properly incurred by NGG in making good such damage or restoring the supply; and

(b)indemnify NGG for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from NGG, by reason or in consequence of any such damage or interruption or NGG becoming liable to any third party as aforesaid other than arising from any default of NGG.

(2) The fact that any act or thing may have been done by NGG on behalf of the undertaker or in accordance with a plan approved by NGG or in accordance with any requirement of NGG or under its supervision will not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless NGG fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of NGG, its officers, servants, contractors or agents;

(b)any part of the authorised works carried out by NGG in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 10 (consent to transfer benefit of Order).

(4) NGG must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

(5) NGG must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

(6) NGG must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within NGG’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of NGG’s control and if reasonably requested to do so by the undertaker NGG must provide an explanation of how the claim has been minimised, where relevant.

Commencement Information

I44Sch. 9 para. 44 in force at 10.3.2023, see art. 1

Enactments and agreementsE+W+S

45.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and NGG in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I45Sch. 9 para. 45 in force at 10.3.2023, see art. 1

Co-operationE+W+S

46.—(1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or NGG requires the removal of apparatus under paragraph 40(2) (removal of apparatus) or NGG makes requirements for the protection or alteration of apparatus under paragraph 42 (retained apparatus: protection of gas undertaker), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of NGG’s undertaking and NGG must use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever the undertaker’s or NGG’s consent, agreement or approval is required in relation to plans, documents or other information submitted under this schedule, or agreement is required to be reached between the parties under this schedule, it must not be unreasonably withheld or delayed.

Commencement Information

I46Sch. 9 para. 46 in force at 10.3.2023, see art. 1

AccessE+W+S

47.  If in consequence of the agreement reached in accordance with paragraph 39(1) (acquisition of land) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable NGG to maintain or use the apparatus no less effectively than was possible before such obstruction.

Commencement Information

I47Sch. 9 para. 47 in force at 10.3.2023, see art. 1

ArbitrationE+W+S

48.  Save for differences or disputes arising under [F4paragraphs 40 (removal of apparatus) and 41] (facilities and rights for alternative apparatus), any difference or dispute arising between the undertaker and NGG under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and NGG, be determined by arbitration in accordance with article 49 (arbitration).

Textual Amendments

Commencement Information

I48Sch. 9 para. 48 in force at 10.3.2023, see art. 1

NoticesE+W+S

49.  Notwithstanding article 48 (service of notices), any plans submitted to NGG by the undertaker pursuant to paragraph 42 (retained apparatus: protection of gas undertaker) must be sent to https://lsbud.co.uk/ and National Grid Plant Protection at assetprotection@nationalgrid.com or such other address as NGG may from time to time appoint instead for that purpose and notify to the undertaker in writing.

Commencement Information

I49Sch. 9 para. 49 in force at 10.3.2023, see art. 1

PART 5E+W+SFOR THE PROTECTION OF NATIONAL GRID ELECTRICITY TRANSMISSION PLC AS ELECTRICITY UNDERTAKER

ApplicationE+W+S

50.—(1) For the protection of National Grid as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Grid.

(2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Grid, where the benefit of this Order is transferred or granted to another person under article 10 (consent to transfer benefit of Order)—

(a)any agreement of the type mentioned in sub-paragraph (1) has effect as if it had been made between National Grid and the transferee or grantee (as the case may be); and

(b)written notice of the transfer or grant must be given to National Grid on or before the date of that transfer or grant.

(3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid (but see paragraph 60(3)(b)).

Commencement Information

I50Sch. 9 para. 50 in force at 10.3.2023, see art. 1

InterpretationE+W+S

51.  In this Part of this Schedule—

alternative apparatus” means appropriate alternative apparatus to the reasonable satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means any electric lines or electrical plant as defined in the Electricity Act 1989, belonging to or maintained by National Grid together with any replacement apparatus and such other apparatus constructed pursuant to the Order that becomes operational apparatus of National Grid for the purposes of transmission, distribution or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) (interpretation) of this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule;

“commence” and “commencement” in paragraph 58 (retained apparatus: protection of electricity undertaker) of this Part of this Schedule includes any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment,

deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by National Grid (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” includes the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Grid including construct, use, repair, alter, inspect, renew or remove the apparatus;

National Grid” means National Grid Electricity Transmission Plc (company number 02366977), whose registered office is 1-3 Strand, London, WC2N 5EH or any successor as a licence holder within the meaning of Part 1 of the Electricity Act ;

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

specified works” means any of the authorised works or activities undertaken in association with the authorised works which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 56(2) (removal of apparatus) or otherwise; or

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 56(2) or otherwise.

Commencement Information

I51Sch. 9 para. 51 in force at 10.3.2023, see art. 1

52.  Except for [F5paragraphs 53] (apparatus of National Grid in stopped up streets), 58 (retained apparatus: protection of electricity undertaker), 59 (expenses) and 60 (indemnity) of this Schedule which will apply in respect of the exercise of all or any powers under the Order affecting the rights and apparatus of National Grid, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.

Textual Amendments

Commencement Information

I52Sch. 9 para. 52 in force at 10.3.2023, see art. 1

Apparatus of National Grid in stopped up streetsE+W+S

53.—(1) Where any street is stopped up under article 17 (permanent stopping up and restriction of use of streets and private means of access), if National Grid has any apparatus in the street or accessed via that street National Grid has the same rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to National Grid, or procure the granting to National Grid of, legal easements reasonably satisfactory to National Grid in respect of such apparatus and access to it prior to the stopping up of any such street but nothing in this paragraph affects any right of the undertaker or National Grid to require the removal of that apparatus under paragraph 56 (removal of apparatus) or the power of the undertaker, subject to compliance with this sub-paragraph, to carry out works under paragraph 58 (retained apparatus: protection of electricity undertaker).

(2) Notwithstanding the temporary alteration, diversion or restriction of any highway under the powers of article 16 (temporary stopping up and restriction of use of streets), National Grid will be at liberty at all times to take all necessary access across any such stopped up street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the alteration, diversion or restriction was in that street.

Commencement Information

I53Sch. 9 para. 53 in force at 10.3.2023, see art. 1

Protective works to buildingsE+W+S

54.  The undertaker must exercise the powers conferred by article 22 (protective work to buildings) so as not to obstruct or render less convenient the access to any apparatus without the written consent of National Grid (such consent not to be unreasonably withheld)

Commencement Information

I54Sch. 9 para. 54 in force at 10.3.2023, see art. 1

Acquisition of landE+W+S

55.—(1) Regardless of any provision in this Order or anything shown on the land plans, the undertaker may not acquire any interest in land or apparatus or override any easement or other interest of National Grid otherwise than by agreement.

(2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Grid and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid or affect the provisions of any enactment or agreement regulating the relations between National Grid and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid unless otherwise agreed by National Grid, and it will be the responsibility of the undertaker to procure and secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

(3) The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid or other enactments relied upon by National Grid as of right or other use in relation to the apparatus, then the provisions in this Schedule prevail.

(4) Any agreement or consent granted by National Grid under paragraph 58 (retained apparatus: protection of electricity undertaker) or any other paragraph of this Part of this Schedule, is not to be taken to constitute agreement under sub-paragraph (1).

Commencement Information

I55Sch. 9 para. 55 in force at 10.3.2023, see art. 1

Removal of apparatusE+W+S

56.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraph (2) to (5).

(2) If, for the purpose of executing any works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to National Grid to its reasonable satisfaction (taking into account paragraph 57(1)) the necessary facilities and rights—

(a)for the construction of alternative apparatus in other land of, or secured by, the undertaker; and

(b)subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation does not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.

(5) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Commencement Information

I56Sch. 9 para. 56 in force at 10.3.2023, see art. 1

Facilities and rights for alternative apparatusE+W+S

57.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Grid facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid.

(2) If the facilities and rights to be afforded by the undertaker under paragraph (1) above in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the matter may be referred to arbitration in accordance with paragraph 64 (arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I57Sch. 9 para. 57 in force at 10.3.2023, see art. 1

Retained apparatus: protection of electricity undertakerE+W+S

58.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Grid a plan of the works to be executed and seek from National Grid details of the underground extent of their electricity tower foundations.

(2) In relation to works which will or may be situated on, over, under or within (i) 15 metres measured in any direction of any apparatus, or (ii) involve embankment works within 15 metres of any apparatus, the plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

(f)any intended maintenance regimes; and

(g)an assessment of risks of rise of earth issues.

(3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement describing—

(a)details of any cable trench design including route, dimensions, clearance to pylon foundations;

(b)demonstration that pylon foundations will not be affected prior to, during and post construction;

(c)details of load bearing capacities of trenches;

(d)details of any cable installation methodology including access arrangements, jointing bays and backfill methodology;

(e)a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route;

(f)written details of the operations and maintenance regime for any cable, including frequency and method of access;

(g)assessment of earth rise potential if reasonably required by National Grid’s engineers; and

(h)evidence that trench bearing capacity is to be designed to support overhead line construction traffic of up to 26 tonnes in weight.

(4) The undertaker must not commence any works to which sub-paragraphs (2) or (3) apply until National Grid has given written approval of the plan so submitted.

(5) Any approval of National Grid required under sub-paragraphs (4)

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (6) or (8); and,

(b)must not be unreasonably withheld.

(6) In relation to any work to which sub-paragraphs (2) or (3) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage, for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(7) Works executed under sub-paragraphs (2) or (3) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (6), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (6) or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.

(8) Where under sub-paragraph (6) National Grid requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Grid’s satisfaction prior to the commencement of any specified works for which protective works are required and National Grid must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

(9) If National Grid in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 50 to 52 and 55 to 57 apply as if the removal of the apparatus had been required by the undertaker under paragraph 56(2) (removal of apparatus).

(10) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

(11) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances.

(12) In sub-paragraph (11)emergency works” means works whose execution at the time when they are executed is required in order to put an end to or to prevent the occurrence of circumstances then existing or imminent (or which the person responsible for the works believes on reasonable grounds to be existing or imminent) which are likely to cause danger to persons or property.

Commencement Information

I58Sch. 9 para. 58 in force at 10.3.2023, see art. 1

ExpensesE+W+S

59.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid—

(i)using its own compulsory purchase powers to acquire any necessary rights under paragraph 56(3) (removal of apparatus); or

(ii)exercising any compulsory purchase powers in the Order transferred to or benefitting National Grid;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 64 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

(5) Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I59Sch. 9 para. 59 in force at 10.3.2023, see art. 1

IndemnityE+W+S

60.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand accompanied by an invoice or claim from National Grid the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and

(b)indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid other than arising from any default of National Grid.

(2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents;

(b)any part of the authorised works carried out by National Grid in the exercise of any functions conferred by this Order pursuant to a grant or transfer under article 10 (consent to transfer benefit of Order).

(4) National Grid must give the undertaker reasonable notice of any such third party claim or demand and no settlement, admission of liability or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

(5) National Grid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

(6) National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the undertaker National Grid must provide an explanation of how the claim has been minimised, where relevant.

Commencement Information

I60Sch. 9 para. 60 in force at 10.3.2023, see art. 1

Enactments and agreementsE+W+S

61.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I61Sch. 9 para. 61 in force at 10.3.2023, see art. 1

Co-operationE+W+S

62.—(1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid requires the removal of apparatus under paragraph 56(2) (removal of apparatus) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 58 (retained apparatus: protection of electricity undertaker), the undertaker must use its best endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid must use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever the undertaker’s or National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted under this schedule, or agreement is required to be reached between the parties under this schedule, it must not be unreasonably withheld or delayed.

Commencement Information

I62Sch. 9 para. 62 in force at 10.3.2023, see art. 1

AccessE+W+S

63.  If in consequence of the agreement reached in accordance with paragraph 55(1) (acquisition of land) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Commencement Information

I63Sch. 9 para. 63 in force at 10.3.2023, see art. 1

ArbitrationE+W+S

64.  Save for differences or disputes arising under paragraphs 56(2) and (4) (removal of apparatus), and 57(1) (facilities and rights for alternative apparatus), any difference or dispute arising between the undertaker and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 49 (arbitration).

Commencement Information

I64Sch. 9 para. 64 in force at 10.3.2023, see art. 1

NoticesE+W+S

65.  Notwithstanding article 48 (service of notices), any plans submitted to National Grid by the undertaker pursuant to paragraph 58 (retained apparatus: protection of electricity undertaker) must be sent to https://lsbud.co.uk/ and National Grid Plant Protection at plantprotection@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing.

Commencement Information

I65Sch. 9 para. 65 in force at 10.3.2023, see art. 1

PART 6E+W+SFOR THE PROTECTION OF NATIONAL GRID ELECTRICITY DISTRIBUTION (EAST MIDLANDS) PLC AS ELECTRICITY UNDERTAKER

ApplicationE+W+S

66.  For the protection of NGED the following provisions have effect, unless otherwise agreed in writing between the undertaker and NGED.

Commencement Information

I66Sch. 9 para. 66 in force at 10.3.2023, see art. 1

InterpretationE+W+S

67.  In this Part—

alternative apparatus” means alternative apparatus adequate to enable NGED to fulfil its statutory functions in a manner not less efficient than previously and where the context requires includes any part of such alternative apparatus;

alternative rights” means all and any necessary legal easements, leases, consents, or permissions required by NGED in order to permit or authorise a diversion and to permit or authorise NGED to lay, keep, operate, maintain, adjust, repair, alter, relay, renew, supplement, inspect, examine, test and remove the alternative apparatus;

apparatus” means electric lines or electrical plant as defined in the Electricity Act 1989, belonging to or maintained by NGED;

diversion” means an alteration to the NGED Network in order to enable or facilitate the authorised development;

functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land;

NGED Network” means NGED’s distribution network operated pursuant to its distribution licence issued pursuant to section 6(9) of the Electricity Act 1989;

“plan” or “plans” includes all designs, drawings, specifications, method statements, programmes, calculations, risk assessments and other documents that are reasonably necessary to properly and sufficiently describe and assess the works to be executed; and

specified work” means so much of any of the authorised development that is carried out within 6 metres of any apparatus.

Commencement Information

I67Sch. 9 para. 67 in force at 10.3.2023, see art. 1

Precedence of 1991 Act in respect of apparatus in streetsE+W+S

68.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and NGED are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.

Commencement Information

I68Sch. 9 para. 68 in force at 10.3.2023, see art. 1

No acquisition except by agreementE+W+S

69.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Commencement Information

I69Sch. 9 para. 69 in force at 10.3.2023, see art. 1

Removal of apparatusE+W+S

70.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or requires that apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule and any right of NGED to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, alternative rights acquired or granted for the alternative apparatus and the alternative apparatus is in operation and access to it has been provided if necessary to the reasonable satisfaction of NGED in accordance with sub-paragraphs (2) to (10) or with such alternative or supplementary provisions as the undertaker and NGED may agree between them.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to NGED written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed.

(3) If as a consequence of the exercise of any of the powers conferred by this Order NGED reasonably needs to remove or divert any of its apparatus and the removal of that apparatus has not been required by the undertaker under sub-paragraph (2) then NGED must give to the undertaker written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and this Part has effect as if the removal or diversion of such apparatus had been required by the undertaker under sub-paragraph (2).

(4) If as a consequence of the removal or diversion of apparatus under sub-paragraph (2) or (3) alternative apparatus is to be constructed in land owned or controlled by the undertaker then the undertaker must afford to NGED the necessary facilities and alternative rights for the construction of alternative apparatus in the other land owned or controlled by the undertaker.

(5) If the undertaker or NGED requires to remove or divert any apparatus placed within the Order land and alternative apparatus is to be constructed in land not owned or controlled by the undertaker as a consequence of the removal or diversion of apparatus then NGED shall use its reasonable endeavours to obtain alternative rights in the land in which the alternative apparatus is to be constructed.

(6) If alternative apparatus is to be constructed in land not owned or controlled by the undertaker and NGED is unable to obtain such alternative rights as are mentioned in sub-paragraph (5), the undertaker and NGED shall consider whether there is an alternative engineering solution that can achieve the diversion without the need for the use of compulsory powers. Should such an alternative engineering solution not be practicable and deliverable in a reasonable timescale and at a reasonable cost (which shall be determined by the undertaker acting reasonably), NGED shall on the transfer of the benefit of the necessary provisions of this Order to NGED use the powers of compulsory acquisition set out in this Order or the Electricity Act 1989 to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed in accordance with a timetable agreed between NGED and the undertaker.

(7) Any alternative apparatus required pursuant to sub-paragraphs (2) or (3) must be constructed in such manner and in such line or situation as may be agreed between NGED and the undertaker or in default of agreement settled in accordance with paragraph 75 (expert determination).

(8) NGED must, after the alternative apparatus to be provided or constructed has been agreed or settled pursuant to paragraph 75 (expert determination), and after the acquisition by or grant to NGED of any such facilities and alternative rights as are referred to in sub-paragraphs (2) to (6), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required to be removed under the provisions of this Part of this Schedule.

(9) Regardless of anything in sub-paragraph (8), if the undertaker gives notice in writing to NGED that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by NGED, must be executed by the undertaker—

(a)in accordance with plans and specifications and in such line or situation agreed between the undertaker and NGED, or, in default of agreement, determined in accordance with paragraph 75 (expert determination); and

(b)without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of NGED.

(10) Nothing in sub-paragraph (9) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus or alternative apparatus, or execute any filling around the apparatus or alternative apparatus (where the apparatus or alternative apparatus is laid in a trench) within 600 millimetres of the point of connection or disconnection.

Commencement Information

I70Sch. 9 para. 70 in force at 10.3.2023, see art. 1

Facilities and rights for alternative apparatusE+W+S

71.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to NGED facilities and alternative rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and alternative rights are to be granted upon such terms and conditions as may be agreed between the undertaker and NGED or in default of agreement settled in accordance with paragraph 75 (expert determination).

(2) In settling those terms and conditions in respect of alternative apparatus to be constructed in the land of the undertaker, the expert must—

(a)give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the authorised development and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of the undertaker;

(b)have regard to the terms and conditions, if any, applicable to the apparatus for which the alternative apparatus is to be substituted;

(c)have regard to NGED’s ability to fulfil its service obligations and comply with its licence conditions; and

(d)have regard to the standard form rights NGED ordinarily secures for the type of alternative apparatus to be constructed in the circumstances similar to the authorised development.

(3) If the facilities and alternative rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and alternative rights are to be granted, are in the opinion of the expert less favourable on the whole to NGED than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the expert must make such provision for the payment of compensation by the undertaker to NGED as appears to the expert to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I71Sch. 9 para. 71 in force at 10.3.2023, see art. 1

Retained apparatusE+W+S

72.—(1) Not less than 60 days before the undertaker intends to start the execution of any specified work where the removal of the apparatus in question has not been required under paragraph 70 (removal of apparatus), the undertaker must submit to NGED a plan of the specified works to be executed. Any submission must note the time limits imposed on NGED under sub-paragraph (3).

(2) Subject to sub-paragraph (3) the undertaker must not commence any specified works to which sub-paragraph (1) applies until NGED has identified any reasonable requirements it has for the alteration or protection of the apparatus, or for securing access to it.

(3) If by the expiry of 60 days beginning with the date on which a plan under sub-paragraph (1) is submitted NGED has not advised the undertaker in writing of any reasonable requirements for the alteration or protection of the apparatus, or for securing access to it, it shall be deemed not to have any such requirements and the undertaker shall be at liberty to proceed with the works.

(4) The works referred to in sub-paragraph (1) must be executed only in accordance with the plan submitted under sub-paragraph (1) and in accordance with any reasonable requirements as may be notified in writing in accordance with sub-paragraph (2) by NGED and NGED shall be entitled to watch and inspect the execution of those works.

(5) At all times when carrying out the authorised development the undertaker shall comply with NGED’s Avoidance of Danger from Electricity Overhead Lines and Underground Cables (2014), the Energy Network Association’s A Guide to the Safe Use of Mechanical Plant in the Vicinity of Electricity Overhead Lines (undated), the Health and Safety Executive’s GS6 Avoiding Danger from Overhead Power Lines and the Health and Safety Executive’s HSG47 Avoiding Danger from Underground Services (Third Addition) (2014) as the same may be replaced from time to time.

(6) If NGED, in accordance with sub–paragraph (2) and in consequence of the works proposed by the undertaker, reasonably requires the removal or diversion of any apparatus and gives written notice to the undertaker of that requirement, this Part of this Schedule applies as if the removal or diversion of the apparatus had been required by the undertaker under paragraph 70(2) (removal of apparatus).

(7) Nothing in this paragraph prevents the undertaker from submitting at any time or from time to time, but in no case less than 60 days before commencing the execution of any works, a new plan instead of the plan previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan.

(8) The undertaker is not required to comply with sub–paragraph (1) in a case of emergency but in that case it must give to NGED notice as soon as is reasonably practicable and a plan of those works as soon as reasonably practicable subsequently and must comply with any reasonable requirements stipulated by NGED under sub-paragraph (2) and with sub–paragraphs (4) and (5) in so far as is reasonably practicable in the circumstances. Nothing in this sub-paragraph prevents NGED from exercising its rights under sub-paragraph (6).

Commencement Information

I72Sch. 9 para. 72 in force at 10.3.2023, see art. 1

Expenses and costsE+W+S

73.—(1) Subject to the following provisions of this paragraph, the undertaker must pay to NGED the proper and reasonable expenses reasonably incurred by NGED in, or in connection with, the inspection, removal, diversion, alteration or protection of any apparatus, the construction of any alternative apparatus and the acquisition or grant of alternative rights for the alternative apparatus, arising as a result of the powers conferred upon the undertaker pursuant to this Order.

(2) The value of any apparatus removed under the provisions of this Part of this Schedule must be deducted from any sum payable under sub-paragraph (1), that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule NGED requires that alternative apparatus of better type, of greater capacity, of greater dimensions or at a greater depth is necessary in substitution for existing apparatus which for NGED’s network requirements is over and above what is necessary as a consequence of and for the purpose of the authorised development, NGED shall reduce the cost of such additional requirements from the amount payable by the undertaker pursuant to sub-paragraph (1).

(4) For the purposes of sub–paragraph (3)

(a)an extension of apparatus to a length greater than the length of existing apparatus must not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole must be treated as if it also had been agreed or had been so determined.

(5) Any amount which, apart from this sub-paragraph would be payable to NGED in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on NGED any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Commencement Information

I73Sch. 9 para. 73 in force at 10.3.2023, see art. 1

74.—(1) Subject to sub-paragraph (2), if by reason or in consequence of the construction of any specified work or any subsidence resulting from any of those works any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of NGED the undertaker is to—

(a)bear and pay the cost reasonably incurred by NGED in making good such damage or restoring the supply; and

(b)reimburse NGED for any other expenses, loss, damages, penalty or costs reasonably and properly incurred by NGED, by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of NGED, its officers, servants, contractors or agents.

(3) NGED must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, is to have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) NGED’s liability to the undertaker for negligence or breach of contract, in respect of each diversion, shall be limited to the value of that diversion and NGED shall not otherwise be liable to the undertaker for any losses or costs incurred by the undertaker resulting from delays to the authorised development as a result of its failure to undertake works to deliver any alternative apparatus.

Commencement Information

I74Sch. 9 para. 74 in force at 10.3.2023, see art. 1

Expert determinationE+W+S

75.—(1) Article 49 (arbitration) applies to any difference as to the legal interpretation of this Part of this Schedule and as provided for in sub–paragraph (7).

(2) Save as provided for in sub–paragraph (1) or sub–paragraph (7) any difference under this Part of this Schedule must be referred to and settled by a single independent and suitable person who holds appropriate professional qualifications and is a member of a professional body relevant to the matter in dispute acting as an expert, such person to be agreed by the differing parties or, in the absence of agreement, identified by the President of the Institution of Civil Engineers or the President of the Institution of RICS or the President of the Institution of Engineering and Technology (as relevant and agreed between NGED and the undertaker, both acting reasonably and without delay).

(3) All parties involved in settling any difference must use best endeavours to do so within 14 days from the date of a dispute first being notified in writing by one party to the other and in the absence of the difference being settled within that period the expert must be appointed within 21 days of the notification of the dispute.

(4) The costs and fees of the expert and the costs of NGED and the undertaker are payable by the parties in such proportions as the expert may determine. In the absence of such determination the costs and fees of the expert are payable equally by the parties who shall each bear their own costs.

(5) The expert must—

(a)invite the parties to make submission to the expert in writing and copied to the other party to be received by the expert within 14 days of the expert’s appointment;

(b)permit a party to comment on the submissions made by the other party within 7 days of receipt of the submissions;

(c)issue a decision within 14 days of receipt of the submissions under sub-paragraph (b); and

(d)give reasons for the decision.

(6) The expert must consider where relevant—

(a)the development outcome sought by the undertaker;

(b)the ability of the undertaker to achieve its outcome in a timely and cost-effective manner;

(c)the nature of the power sought to be exercised by the undertaker;

(d)the effectiveness, cost and reasonableness of proposals for mitigation arising from any party;

(e)NGED’s service obligations and licence conditions; and

(f)any other important and relevant consideration.

(7) Any determination by the expert is final and binding, except in the case of manifest error in which case the difference that has been subject to expert determination may be referred to and settled by arbitration under article 49 (arbitration).

Commencement Information

I75Sch. 9 para. 75 in force at 10.3.2023, see art. 1

(1)

1989 c. 29. The definition of “electricity plant” (in section 64) was amended by section 108 of, and paragraphs 24 and 38(1) and (3) of Schedule 6 to, the Utilities Act 2000 (c. 27).

(2)

1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45) and was further amended by sections 3(2) and 76 of, and paragraphs 1 and 4 of Schedule 6, and Schedule 8 to, the Utilities Act 2000, sections 149(1) and (5) and 197(9) of, and Part 1 of Schedule 23 to, the Energy Act 2004 (c. 20) and S.I. 2011/2704.

(4)

Section 102(4) was amended by section 96(1)(c) of the Water Act 2003 (c. 37).

(5)

Section 104 was amended by sections 96(4) and 101(2) of, and Part 3 of Schedule 9 to, the Water Act 2003; section 42(3) of the Flood and Water Management Act 2010 (c. 29); and sections 11(1) and (2) and 56 of, and paragraphs 2 and 91 of Schedule 7 to, the Water Act 2014 (c. 21).

(6)

There are amendments to section 219 which are not relevant to this Order.

(8)

See section 106 of the 2003 Act, which was amended by section 4(3) to (9) of the Digital Economy Act 2017 (c. 30). See also Schedule 3A to the 2003 Act, which was inserted by section 4 of, and Schedule 1 to, the Digital Economy Act.

(9)

There are amendments to section 6 which are not relevant to this Order.

Back to top

Options/Help

You have chosen to open the Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?