1. For the protection of Northern Powergrid referred to in this Part of this Schedule the following provisions must, unless otherwise agreed in writing between the undertaker and the affected undertaking concerned, have effect.
Commencement Information
I1Sch. 9 Pt. 9 para. 1 in force at 3.8.2023, see art. 1
2. In this Part of this Schedule—
“alternative apparatus” means alternative apparatus adequate to enable Northern Powergrid to fulfil its statutory functions in a manner no less efficient than previously;
“apparatus” means electric lines or electrical plant (as defined in the 1989 Act), belonging to or maintained by Northern Powergrid;
“functions” includes powers and duties;
“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over or upon land; and
“Northern Powergrid” means Northern Powergrid (Yorkshire) PLC (Company Number 04112320) whose registered address is Lloyds Court, 78 Grey Street, Newcastle upon Tyne, NE1 6AF.
Commencement Information
I2Sch. 9 Pt. 9 para. 2 in force at 3.8.2023, see art. 1
3. This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the Northern Powergrid are regulated by the provisions of Part 3 of the 1991 Act.
Commencement Information
I3Sch. 9 Pt. 9 para. 3 in force at 3.8.2023, see art. 1
4.—(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference, the undertaker shall not acquire any apparatus or override any easement or other interest of Northern Powergrid or acquire any land or other interest of Northern Powergrid or create any new rights over the same otherwise than by agreement of the relevant Northern Powergrid such agreement not to be unreasonably withheld or delayed (having regard to Northern Powergrid’s existing and future requirements for such land or interests).
(2) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference, the undertaker shall not interfere with any communications cables or equipment used by Northern Powergrid in relation to its apparatus or acquire or interfere with any rights or interests supporting the use, maintenance or renewal of such equipment otherwise than by agreement of Northern Powergrid (such agreement not to be unreasonably withheld or delayed).
Commencement Information
I4Sch. 9 Pt. 9 para. 4 in force at 3.8.2023, see art. 1
5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of Northern Powergrid to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of Northern Powergrid.
(2) If, for the purpose of executing any works in, on or under any land purchased, held, or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to Northern Powergrid 56 days advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Northern Powergrid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Northern Powergrid the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.
(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed—
(a)the undertaker must in the first instance use reasonable endeavours to acquire all necessary land interests or rights as Northern Powergrid may reasonably require for the relocation and construction of alternative apparatus and must use reasonable endeavours to procure all necessary rights to access and maintain Northern Powergrid’s apparatus and alternative apparatus thereafter the terms of such access and maintenance to be agreed by Northern Powergrid (acting reasonably); and
(b)in the event the undertaker is not able to procure the necessary land interests or rights referred to in sub-paragraph (3)(a) Northern Powergrid must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for Northern Powergrid to use its compulsory purchase powers to this end unless it elects to do so.
(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Northern Powergrid and the undertaker or in default of agreement settled by arbitration in accordance with article 39 (arbitration).
(5) Northern Powergrid must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 39 (arbitration) and after the grant to Northern Powergrid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.
Commencement Information
I5Sch. 9 Pt. 9 para. 5 in force at 3.8.2023, see art. 1
6.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Northern Powergrid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Northern Powergrid or in default of agreement settled by arbitration in accordance with article 39 (arbitration).
(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Northern Powergrid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Northern Powergrid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.
Commencement Information
I6Sch. 9 Pt. 9 para. 6 in force at 3.8.2023, see art. 1
7.—(1) Not less than 56 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are within 15 metres of, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 5, the undertaker must submit to Northern Powergrid a plan, section and description of the works to be executed.
(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Northern Powergrid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Northern Powergrid is entitled to watch and inspect the execution of those works.
(3) Any requirements made by Northern Powergrid under sub-paragraph (2) must be made within a period of 49 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.
(4) If Northern Powergrid in accordance with sub-paragraph (2) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5.
(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 35 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.
(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to Northern Powergrid notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.
Commencement Information
I7Sch. 9 Pt. 9 para. 7 in force at 3.8.2023, see art. 1
8.—(1) Save where otherwise agreed in writing between Northern Powergrid and the undertaker and subject to the following provisions of this paragraph, the undertaker must repay to Northern Powergrid within 30 days of receipt of an itemised invoice or claim all charges costs and expenses reasonably incurred by Northern Powergrid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as authorised by this Order including without limitation—
(a)any costs reasonably incurred or compensation properly paid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that Northern Powergrid elects to use compulsory purchase powers to acquire any necessary rights under paragraph 7(3) all costs incurred as a result of such action;
(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;
(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;
(d)the approval of plans;
(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;
(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Schedule.
(2) If in accordance with the provisions of this Part of this Schedule—
(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or
(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,
and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 39 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Northern Powergrid by virtue of sub-paragraph (1) must be reduced by the amount of that excess save where it is not possible in the circumstances to obtain the existing type of operations, capacity, dimensions or place at the existing depth in which case full costs shall be borne by the undertaker.
(3) For the purposes of sub-paragraph (2)—
(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and
(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.
Commencement Information
I8Sch. 9 Pt. 9 para. 8 in force at 3.8.2023, see art. 1
9.—(1) Subject to sub-paragraphs (2) to (5), if by reason or in consequence of the construction of any such works referred to in this Part of this Schedule, or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by it) in the course of carrying out such works, including without limitation works carried out by the undertaker or Northern Powergrid under this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Northern Powergrid, or there is any interruption in any service provided, or in the supply of any goods, by Northern Powergrid, or Northern Powergrid becomes liable to pay any amount to a third party the undertaker must—
(a)bear and pay the cost reasonably incurred by Northern Powergrid in making good such damage or restoring the supply; and
(b)indemnify Northern Powergrid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from Northern Powergrid, by reason or in consequence of any such damage or interruption or Northern Powergrid becoming liable to any third party.
(2) The fact that any act or thing may have been done by Northern Powergrid on behalf of the undertaker or in accordance with a plan approved by Northern Powergrid or in accordance with any requirement of Northern Powergrid as a consequence of the authorised development or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (2) where the undertaker fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not materially accord with the approved plan or as otherwise agreed between the undertaker and Northern Powergrid.
(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to—
(a)any damage or interruption to the extent that it is attributable to the act, neglect or default of Northern Powergrid, its officers, servants, contractors or agents; or
(b)any authorised development and/or any other works authorised by this Part of this Schedule carried out by Northern Powergrid as an assignee, transferee or lessee of the undertaker with the benefit of the Order subject to the proviso that once such works become apparatus (“new apparatus”) any works yet to be executed by the undertaker and not falling within this paragraph 9(3)(b) will be subject to the full terms of this Part of this Schedule including this paragraph 9 in respect of such new apparatus.
(4) Northern Powergrid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise may be made without the consent of the undertaker which, if it withholds such consent, shall have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.
(5) Northern Powergrid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands and penalties to which the indemnity under sub-paragraph (1) applies. If request to do so by the undertaker, Northern Powergrid must provide an explanation of how the claim has been minimised. The undertaker is only liable under sub-paragraph (1) for claim reasonably incurred by Northern Powergrid.
Commencement Information
I9Sch. 9 Pt. 9 para. 9 in force at 3.8.2023, see art. 1
10. Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Northern Powergrid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.
Commencement Information
I10Sch. 9 Pt. 9 para. 10 in force at 3.8.2023, see art. 1
11. Where in consequence of the proposed construction of any of the authorised development, the undertaker or Northern Powergrid requires the removal of apparatus under paragraph 5(2) or otherwise or Northern Powergrid makes requirements for the protection or alteration of apparatus under paragraph 7, the undertaker shall use its best endeavours to co-ordinate the execution of the works in the interests of safety and the need to ensure the safe and efficient operation of Northern Powergrid’s undertaking taking into account the undertaker’s desire for the efficient and economic execution of the authorised development and the undertaker and Northern Powergrid shall use best endeavours to co-operate with each other for those purposes.
Commencement Information
I11Sch. 9 Pt. 9 para. 11 in force at 3.8.2023, see art. 1
12. If in consequence of an agreement reached in accordance with paragraph 4(1) or the powers granted under this Order the access to any apparatus or alternative apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus or alternative apparatus as will enable Northern Powergrid to maintain or use the said apparatus no less effectively than was possible before such obstruction.
Commencement Information
I12Sch. 9 Pt. 9 para. 12 in force at 3.8.2023, see art. 1
13. The plans submitted to Northern Powergrid by the undertaker pursuant to this Part of the Schedule must be sent to Northern Powergrid at property@northernpowergrid.com or such other address as Northern Powergrid may from time to time appoint instead for that purpose and notify to the undertaker in writing.
Commencement Information
I13Sch. 9 Pt. 9 para. 13 in force at 3.8.2023, see art. 1