The Walney Extension Offshore Wind Farm Order 2014

Article 3

SCHEDULE 1 E+W AUTHORISED PROJECT

PART 1 E+W Authorised Development

1.  A nationally significant infrastructure project as defined in sections 14 and 15 of the 2008 Act on the bed of the Irish Sea approximately 19 kilometres off the Isle of Walney coast and partly within the Renewable Energy Zone, comprising— E+W

• Work No. 1 –

  (a)

  an offshore wind turbine generating station with a gross electrical output capacity of up to 750MW comprising up to 207 wind turbine generators with rotating blades, each fixed to the seabed by one of two foundation types, namely monopile foundation or jacket structure (in conjunction with suction caissons or steel piles), and situated within the coordinates for the Order limits seaward of MHWS and further comprising (b) below;

  (b)

  a network of subsea inter-array cables laid within the Order limits seaward of MHWS between the WTGs and Work No. 2(a), for the transmission of electricity and electronic communications between these different structures, including up to twenty cable crossings;

  and associated development within the meaning of section 115(2) of the 2008 Act comprising—

• Work No. 2 –

  (a)

  up to three offshore substation platforms fixed to the seabed within the Order limits seaward of MHWS by one of two foundation types, namely [F1 monopile] foundations or jacket structure (in conjunction with suction caissons or steel piles), and further comprising (b) below;

  (b)

  offshore connection works consisting of up to five export cable systems between Work No. 2(a) and Work No. 3A for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid along routes within the Order limits seaward of MHWS;

• Work No. 3A – offshore connection works consisting of up to five export cable systems between Work No. 2 and Work No. 3B for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid along routes within the Order limits seaward of MHWS, including up to seventy cable crossings;

• In the county of Lancashire, district of City of Lancaster

  Work No. 3B – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid underground from MLW at Middleton Sands to Work No. 6, together with a new temporary access track and a new temporary horizontal directional drilling compound to the west of the saltmarsh, and a new temporary construction working site and a new temporary access track between the existing sea defence and Work No. 6;

• Work No. 4 – a new temporary vehicular access track to the south east of Potts Corner and between Work No. 3B and Work No. 5;

• Work No. 5 – modifications to and upgrading of an existing vehicular access track running in a north westerly direction from Work No. 4 to the adopted highway on Carr Lane, together with modifications to the junction of the upgraded vehicular access track and the adopted highway at Carr Lane;

• Work No. 6 – onshore connection works located to the north east of the existing sea defence consisting of—

  (a)

  up to five export cable systems for the transmission of electricity and electronic communications connecting Work No. 3B to Work No. 8 each consisting of—

  (i)

  a single subsea cable and one cable duct; or

  (ii)

  three onshore cables and three cable ducts, and up to two fibre optic cables and up to two fibre optic cable ducts;

  (b)

  up to five transition joint bays;

  (c)

  up to ten pits for the fibre optic joints and link boxes with associated cables;

  (d)

  a new temporary horizontal directional drilling compound;

  (e)

  a new temporary construction working site; and

  (f)

  a new temporary access track;

• Work No. 7 – a new temporary construction working site and a new temporary access track to the north east of the existing sea defence and adjoining Work No. 3B and Work No. 6 and Work No. 8;

• Work No. 8 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications connecting Work No. 6 to Work No. 12, passing through an existing access track to Middleton Lake, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with new temporary construction working sites and a new temporary vehicular access track;

• Work No. 9 – a new temporary vehicular access running from a point on Carr Lane south of Middle Brows in an easterly direction to the point at which Work No. 9 abuts Work No. 11 and another new temporary vehicular access running in a southerly direction and then south easterly direction from that point to Work No. 8 at a point north east of Work No. 6, including new temporary construction working sites and modifications to the adopted highway on Carr Lane to create a new temporary junction with the temporary access track;

• Work No. 10 – a new temporary vehicular access running from a point on Carr Lane north of Middle Brows in a southerly direction to the point at which Work No. 10 abuts Work No. 9, including new temporary construction working sites and modifications to the adopted highway on Carr Lane to create a new temporary junction with the temporary access track;

• Work No. 11 – a new temporary vehicular access running in an easterly direction from the point at which Work No. 9 abuts Work No. 11 to the point at which Work No. 11 abuts Work No. 8, including new temporary construction working sites;

• Work No. 12 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications connecting Work No. 8 to Work No. 13, passing through Trunk Dyke West and an existing public right of way known as Footpath (3) located to the west of Marsh Lea Farm, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with new temporary construction working sites and a new temporary vehicular access track;

• Work No. 13 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 12 passing through the existing access track to the north of Marsh Lea Farm and then in a north easterly direction, passing through Trunk Dyke East and an existing public right of way known as Footpath (1), and then in a northerly direction, passing through an existing public right of way known as Footpath (5), and continuing to Work No. 14, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with new temporary construction working site and a new temporary vehicular access track;

• Work No. 14 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 13 passing through land known as Middleton Playing Fields and then through Middleton Road to Work No. 15, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with new temporary construction working sites and a new temporary horizontal directional drilling compound and a new temporary vehicular access track, and modifications to the adopted highway on Middleton Road to create a new temporary junction with the new temporary access track to the south of Middleton Road;

• Work No. 15 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 14 at a point adjacent to Middleton Road in a north westerly direction to Work No. 18 each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with new temporary construction working sites and a new temporary horizontal directional drilling compound and a new temporary vehicular access track, and modifications to the adopted highway on Middleton Road to create a new temporary junction with the temporary access track to the north of Middleton Road;

• Work No. 16 – a new temporary construction working site and a new temporary vehicular access track to the north of Middleton Road and adjoining Work No. 15;

• Work No. 17 – a new temporary construction working site to the east of Middleton Business Park and adjoining Work No. 15;

• Work No. 18 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 15 in a northerly direction to Work No. 22 each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with a new temporary horizontal directional drilling compound and new temporary construction working sites and new temporary vehicular access tracks, to the south of the A683 Heysham – Morecambe Bypass;

• Work No. 19 – modifications to Imperial Road to create a new temporary access to and junction with the new temporary vehicular access tracks comprised in Work No. 18;

• Work No. 20 – a new temporary vehicular access track from Work No. 18 running in an easterly direction to Work No. 21;

• Work No. 21 – a new temporary vehicular access track running in a northerly direction from Work No. 20 to the adopted highway of the A683 Heysham – Morecambe Bypass, together with modifications to the A683 Heysham – Morecambe Bypass to create a new junction with the new temporary vehicular access track;

• Work No. 22 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 18 in a northerly direction passing through the A683 Heysham – Morecambe Bypass to Work No. 23, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, laid underground;

• Work No. 23 – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications running from Work No. 22 to Work No. 25, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, and up to ten cable jointing bays, and up to ten pits for the fibre optic joints and link boxes, with associated cables, laid underground, together with landscaping and a new temporary horizontal directional drilling compound and new temporary construction working sites and a new temporary vehicular access track, to the north of the A683 Heysham – Morecambe Bypass;

• Work No. 24 – a new temporary construction working site and a new temporary vehicular access track to the north of the A683 Heysham – Morecambe Bypass and adjoining Work No. 23 and Work No. 25;

• Work No. 25 – an electrical substation compound and adjoining apparatus and facilities including (but not limited to) offices, administration and services facilities, security accommodation, parking areas, private access road, hardstanding and landscaping to the north of the A683 Heysham – Morecambe Bypass;

• Work No. 26 – onshore connection works consisting of up to two 400kV export cable systems for the transmission of electricity and electronic communications running from the new electrical substation compound at Work No. 25 in a north westerly direction to Work No. 27, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, laid underground, together with a new temporary construction working site to the north west of Work No. 23, landscaping, and a new permanent vehicular access road between Work No. 25 and the roundabout at the junction of the A683 Heysham – Morecambe Bypass and Imperial Road and modifications to that roundabout to create a new junction with the new permanent vehicular access road;

• Work No. 27 – onshore connection works consisting of up to two 400kV export cable systems for the transmission of electricity and electronic communications running from Work No. 26 in a north westerly direction to a new National Grid substation to the north west of the junction of the A683 Heysham – Morecambe Bypass and Imperial Road, each consisting of three onshore cables and three cable ducts, as well as up to two fibre optic cables and up to two fibre optic cable ducts, laid underground, together with landscaping, and a new temporary construction working site and a new temporary vehicular access track to the north west of Work No. 26;

  and in connection with such Work Nos. 1 to 3A and to the extent that they do not otherwise form part of any such work, further associated development comprising such other works as may be necessary or expedient for the purposes of or in connection with the relevant part of the authorised development and which fall within the scope of the work assessed by the environmental statement, including—

  (a)

  scour protection around the foundations of the offshore structures;

  (b)

  cable protection measures such as the placement of rock and/or concrete mattresses, with or without frond devices; and

  (c)

  the removal of material from the seabed required for the construction of Work Nos. 1 to 3A and the disposal of up to 750,300m³ of inert material of natural origin within the Disposal Site produced during construction drilling and seabed preparation for foundation works;

  and in connection with such Work Nos. 3B to 27 and to the extent that they do not otherwise form part of any such work, further associated development comprising such other works as may be necessary or expedient for the purposes of or in connection with the relevant part of the authorised development and which fall within the scope of the work assessed by the environmental statement, including—

  (d)

  ramps, means of access and footpaths;

  (e)

  bunds, embankments, swales, landscaping, fencing and boundary treatments;

  (f)

  habitat creation;

  (g)

  jointing bays, cable ducts, cable protection, joint protection, manholes, kiosks, marker posts, underground cable marker, tiles and tape, and lighting and other works associated with cable laying;

  (h)

  works for the provision of apparatus including cabling, water supply works, foul drainage provision, surface water management systems and culverting;

  (i)

  works to alter the position of apparatus, including mains, sewers, drains and cables;

  (j)

  works to alter the course of, or otherwise interfere with, non-navigable rivers, streams or watercourses;

  (k)

  landscaping and other works to mitigate any adverse effects of the construction, maintenance or operation of the authorised project;

  (l)

  works for the benefit or protection of land affected by the authorised project;

  (m)

  working sites in connection with the construction of the authorised project, construction lay down areas and compounds, storage compounds and their restoration.

Textual Amendments

F1 Word in Sch. 1 Pt. 1 para. 1 substituted (25.4.2015) by The Walney Extension Offshore Wind Farm (Correction) Order 2015 (S.I. 2015/1270), art. 1, Sch.

Commencement Information

I1 Sch. 1 Pt. 1 para. 1 in force at 28.11.2014, see art. 1

2.—(1) With the exception of the area described in sub-paragraph (2), the Order limits for that part of the authorised development which is seaward of MHWS are specified by the grid coordinates in the table below, and more particularly on the Order limits and grid coordinates plan. E+W

(2) The excepted area referred to in sub-paragraph (1) is the area bounded by the grid coordinates referenced by Point IDs 205 to 248 (inclusive) in the table below, and does not form part of the Order limits.

Co-ordinates for the Order limits seaward of MHWS

Point ID	Longitude (DMS)	Latitude (DMS)	Point ID	Longitude (DMS)	Latitude (DMS)
WGS 1984
1	2° 53′ 33.318″ W	54° 0′ 21.420″ N	2	2° 53′ 50.369″ W	54° 0′ 16.174″ N
3	2° 54′ 45.902″ W	54° 0′ 14.698″ N	4	2° 55′ 17.251″ W	54° 0′ 13.861″ N
5	2° 55′ 22.300″ W	54° 0′ 13.726″ N	6	2° 56′ 22.346″ W	54° 0′ 12.116″ N
7	2° 56′ 23.311″ W	54° 0′ 10.132″ N	8	2° 57′ 26.162″ W	54° 0′ 7.954″ N
9	2° 57′ 57.264″ W	53° 59′ 51.821″ N	10	2° 58′ 29.297″ W	53° 59′ 35.200″ N
11	2° 58′ 32.508″ W	53° 59′ 31.262″ N	12	2° 59′ 30.192″ W	53° 58′ 59.300″ N
13	3° 0′ 18.112″ W	53° 58′ 29.037″ N	14	3° 1′ 5.141″ W	53° 58′ 9.023″ N
15	3° 1′ 5.593″ W	53° 58′ 9.261″ N	16	3° 2′ 3.897″ W	53° 57′ 44.946″ N
17	3° 2′ 59.503″ W	53° 57′ 18.713″ N	18	3° 3′0.453″ W	53° 57′ 18.477″ N
19	3° 3′ 13.251″ W	53° 57′ 12.731″ N	20	3° 3′16.700″ W	53° 57′ 14.441″ N
21	3° 3′ 18.769″ W	53° 57′ 13.927″ N	22	3° 5′ 43.813″ W	53° 56′ 27.606″ N
23	3° 5′ 54.544″ W	53° 56′ 24.869″ N	24	3° 6′ 42.395″ W	53° 56′ 12.659″ N
25	3° 7′ 8.784″ W	53° 56′ 6.470″ N	26	3° 8′13.711″ W	53° 55′ 44.826″ N
27	3° 8′ 13.737″ W	53° 55′ 45.023″ N	28	3° 9′ 13.690″ W	53° 55′ 23.693″ N
29	3° 9′ 48.444″ W	53° 55′ 9.265″ N	30	3° 10′ 37.024″ W	53° 54′ 48.620″ N
31	3° 10′ 49.239″ W	53° 54′ 42.972″ N	32	3° 12′ 22.668″ W	53° 53′ 59.742″ N
33	3° 12′ 23.270″ W	53° 54′ 0.247″ N	34	3° 12′ 49.670″ W	53° 54′ 2.654″ N
35	3° 12′ 52.456″ W	53° 54′ 2.687″ N	36	3° 17′ 6.270″ W	53° 54′ 28.567″ N
37	3° 26′ 26.669″ W	53° 55′ 25.214″ N	38	3° 26′ 37.660″ W	53° 55′ 26.317″ N
39	3° 27′ 3.079″ W	53° 55′ 28.867″ N	40	3° 27′ 18.555″ W	53° 55′ 30.418″ N
41	3° 29′ 50.937″ W	53° 55′ 45.664″ N	42	3° 30′ 3.624″ W	53° 55′ 43.059″ N
43	3° 30′ 30.452″ W	53° 55′ 54.247″ N	44	3° 30′ 29.997″ W	53° 55′ 54.544″ N
45	3° 34′ 7.698″ W	53° 57′ 35.322″ N	46	3° 34′ 7.209″ W	53° 57′ 35.365″ N
47	3° 37′ 35.577″ W	53° 59′ 11.544″ N	48	3° 37′ 34.781″ W	53° 59′ 11.548″ N
49	3° 41′ 30.681″ W	54° 1′ 0.522″ N	50	3° 41′ 29.995″ W	54° 1′ 0.584″ N
51	3° 44′ 18.958″ W	54° 2′ 18.969″ N	52	3° 44′ 18.798″ W	54° 2′ 19.017″ N
53	3° 47′ 22.145″ W	54° 3′ 41.872″ N	54	3° 47′ 27.048″ W	54° 3′ 41.853″ N
55	3° 50′ 7.591″ W	54° 4′ 20.464″ N	56	3° 50′ 30.606″ W	54° 4′ 27.329″ N
57	3° 52′ 35.173″ W	54° 5′ 4.454″ N	58	3° 52′ 35.893″ W	54° 5′ 27.530″ N
59	3° 52′ 30.274″ W	54° 5′ 34.138″ N	60	3° 52′ 18.993″ W	54° 5′ 47.403″ N
61	3° 52′ 14.971″ W	54° 5′ 52.133″ N	62	3° 52′ 14.528″ W	54° 5′ 52.628″ N
63	3° 52′ 13.616″ W	54° 5′ 53.649″ N	64	3° 52′ 13.582″ W	54° 5′ 53.687″ N
65	3° 52′ 13.580″ W	54° 5′ 53.689″ N	66	3° 52′ 13.579″ W	54° 5′ 53.690″ N
67	3° 52′ 13.577″ W	54° 5′ 53.693″ N	68	3° 52′ 13.576″ W	54° 5′ 53.693″ N
69	3° 52′ 13.576″ W	54° 5′ 53.694″ N	70	3° 52′ 13.657″ W	54° 5′ 53.720″ N
71	3° 52′ 28.915″ W	54° 5′ 58.451″ N	72	3° 55′ 6.038″ W	54° 6′ 47.128″ N
73	3° 55′ 8.026″ W	54° 8′ 10.360″ N	74	3° 53′ 41.626″ W	54° 7′ 56.485″ N
75	3° 53′ 37.752″ W	54° 7′ 56.773″ N	76	3° 49′ 34.856″ W	54° 9′ 30.726″ N
77	3° 39′ 20.455″ W	54° 6′ 19.663″ N	78	3° 40′ 10.211″ W	54° 5′ 35.819″ N
79	3° 40′ 2.050″ W	54° 5′ 24.439″ N	80	3° 39′ 34.391″ W	54° 4′ 45.872″ N
81	3° 39′ 20.491″ W	54° 4′ 26.490″ N	82	3° 39′ 4.540″ W	54° 4′ 8.303″ N
83	3° 38′ 34.710″ W	54° 3′ 34.297″ N	84	3° 37′ 28.711″ W	54° 3′ 26.435″ N
85	3° 36′ 6.282″ W	54° 3′ 7.704″ N	86	3° 35′ 29.688″ W	54° 2′ 56.515″ N
87	3° 35′ 2.285″ W	54° 2′ 48.138″ N	88	3° 34′ 25.262″ W	54° 2′ 33.068″ N
89	3° 33′ 48.240″ W	54° 2′ 17.999″ N	90	3° 33′ 48.186″ W	54° 2′ 17.988″ N
91	3° 32′ 51.202″ W	54° 1′ 46.816″ N	92	3° 31′ 58.620″ W	54° 1′ 8.425″ N
93	3° 31′ 33.298″ W	54° 0′ 44.201″ N	94	3° 34′ 3.925″ W	54° 0′ 13.597″ N
95	3° 37′ 57.802″ W	54° 1′ 26.958″ N	96	3° 38′ 35.961″ W	54° 1′ 38.908″ N
97	3° 38′ 37.941″ W	54° 1′ 39.528″ N	98	3° 38′ 38.113″ W	54° 1′ 39.582″ N
99	3° 38′ 38.136″ W	54° 1′ 39.589″ N	100	3° 38′ 38.137″ W	54° 1′ 39.589″ N
101	3° 38′ 38.136″ W	54° 1′ 39.588″ N	102	3° 38′ 38.136″ W	54° 1′ 39.585″ N
103	3° 38′ 38.135″ W	54° 1′ 39.557″ N	104	3° 38′ 38.135″ W	54° 1′ 39.550″ N
105	3° 38′ 37.814″ W	54° 1′ 32.453″ N	106	3° 38′ 37.736″ W	54° 1′ 30.739″ N
107	3° 38′ 35.483″ W	54° 0′ 40.901″ N	108	3° 38′ 34.329″ W	54° 0′ 15.381″ N
109	3° 36′ 18.089″ W	53° 59′ 12.083″ N	110	3° 36′ 18.013″ W	53° 59′ 12.112″ N
111	3° 32′ 54.558″ W	53° 57′ 37.375″ N	112	3° 29′ 43.507″ W	53° 56′7.888″ N
113	3° 23′ 28.273″ W	53° 55′ 30.504″ N	114	3° 21′ 22.439″ W	53° 55′17.891″ N
115	3° 17′ 6.328″ W	53° 54′ 52.098″ N	116	3° 16′ 51.776″ W	53° 54′ 50.628″ N
117	3° 13′ 19.548″ W	53° 54′ 29.125″ N	118	3° 13′ 21.515″ W	53° 54′ 27.216″ N
119	3° 12′ 52.745″ W	53° 54′ 16.308″ N	120	3° 12′ 37.818″ W	53° 54′ 24.884″ N
121	3° 12′ 30.762″ W	53° 54′ 24.167″ N	122	3° 11′ 53.533″ W	53° 54′ 41.184″ N
123	3° 11′ 46.361″ W	53° 54′ 44.462″ N	124	3° 8′ 17.617″ W	53° 56′ 19.742″ N
125	3° 8′ 3.775″ W	53° 56′ 24.509″ N	126	3° 5′ 36.260″ W	53° 56′ 54.770″ N
127	3° 5′ 33.104″ W	53° 56′ 55.897″ N	128	3° 3′ 59.223″ W	53° 57′29.379″ N
129	3° 3′ 35.027″ W	53° 57′ 41.707″ N	130	3° 3′ 12.770″ W	53° 57′ 54.699″ N
131	3° 3′ 1.921″ W	53° 58′ 1.031″ N	132	3° 2′ 50.675″ W	53° 58′6.814″ N
133	3° 2′ 29.445″ W	53° 58′ 18.224″ N	134	3° 2′ 26.366″ W	53° 58′ 19.879″ N
135	3° 2′ 18.381″ W	53° 58′ 21.914″ N	136	3° 1′ 57.695″ W	53° 58′ 29.947″ N
137	3° 0′ 59.498″ W	53° 58′ 54.481″ N	138	3° 0′ 17.205″ W	53° 59′ 21.263″ N
139	2° 59′ 50.041″ W	53° 59′ 23.845″ N	140	2° 59′ 48.659″ W	53° 59′ 21.447″ N
141	2° 58′ 39.981″ W	53° 59′ 56.787″ N	142	2° 58′ 22.348″ W	54° 0′ 6.797″ N
143	2° 58′ 17.509″ W	54° 0′ 9.544″ N	144	2° 57′ 52.475″ W	54° 0′ 21.929″ N
145	2° 57′ 40.585″ W	54° 0′ 27.810″ N	146	2° 56′ 43.833″ W	54° 0′ 27.583″ N
147	2° 56′ 36.086″ W	54° 0′ 27.798″ N	148	2° 55′ 33.076″ W	54° 0′ 29.540″ N
149	2° 55′ 24.257″ W	54° 0′ 29.783″ N	150	2° 55′ 17.716″ W	54° 0′ 29.964″ N
151	2° 54′ 28.827″ W	54° 0′ 31.307″ N	152	2° 54′ 28.613″ W	54° 0′ 31.313″ N
153	2° 54′ 7.050″ W	54° 0′ 31.904″ N	154	2° 54′ 0.064″ W	54° 0′ 32.095″ N
155	2° 53′ 50.559″ W	54° 0′ 24.974″ N	156	2° 53′ 50.558″ W	54° 0′ 24.973″ N
157	2° 53′ 50.137″ W	54° 0′ 24.658″ N	158	2° 53′ 48.738″ W	54° 0′ 24.687″ N
159	2° 53′ 48.373″ W	54° 0′ 24.694″ N	160	2° 53′ 48.071″ W	54° 0′ 24.700″ N
161	2° 53′ 47.607″ W	54° 0′ 24.710″ N	162	2° 53′ 47.270″ W	54° 0′ 24.717″ N
163	2° 53′ 47.131″ W	54° 0′ 24.720″ N	164	2° 53′ 47.070″ W	54° 0′ 24.721″ N
165	2° 53′ 46.869″ W	54° 0′ 24.725″ N	166	2° 53′ 46.825″ W	54° 0′ 24.727″ N
167	2° 53′ 46.705″ W	54° 0′ 24.884″ N	168	2° 53′ 46.472″ W	54° 0′ 25.188″ N
169	2° 53′ 46.283″ W	54° 0′ 25.434″ N	170	2° 53′ 46.208″ W	54° 0′ 25.533″ N
171	2° 53′ 46.115″ W	54° 0′ 25.654″ N	172	2° 53′ 46.079″ W	54° 0′ 25.739″ N
173	2° 53′ 46.067″ W	54° 0′ 25.826″ N	174	2° 53′ 46.070″ W	54° 0′ 25.856″ N
175	2° 53′ 46.077″ W	54° 0′ 25.912″ N	176	2° 53′ 46.001″ W	54° 0′ 25.898″ N
177	2° 53′ 45.896″ W	54° 0′ 25.878″ N	178	2° 53′ 45.062″ W	54° 0′ 25.722″ N
179	2° 53′ 44.966″ W	54° 0′ 25.704″ N	180	2° 53′ 44.992″ W	54° 0′ 25.694″ N
181	2° 53′ 45.026″ W	54° 0′ 25.674″ N	182	2° 53′ 45.054″ W	54° 0′ 25.651″ N
183	2° 53′ 45.075″ W	54° 0′ 25.626″ N	184	2° 53′ 45.088″ W	54° 0′ 25.599″ N
185	2° 53′ 45.109″ W	54° 0′ 25.475″ N	186	2° 53′ 45.182″ W	54° 0′ 25.230″ N
187	2° 53′ 45.198″ W	54° 0′ 25.196″ N	188	2° 53′ 45.235″ W	54° 0′ 25.110″ N
189	2° 53′ 45.288″ W	54° 0′ 24.990″ N	190	2° 53′ 45.326″ W	54° 0′ 24.924″ N
191	2° 53′ 45.329″ W	54° 0′ 24.887″ N	192	2° 53′ 45.322″ W	54° 0′ 24.851″ N
193	2° 53′ 45.304″ W	54° 0′ 24.817″ N	194	2° 53′ 45.296″ W	54° 0′ 24.807″ N
195	2° 53′ 45.319″ W	54° 0′ 24.782″ N	196	2° 53′ 43.200″ W	54° 0′ 24.861″ N
197	2° 53′ 41.929″ W	54° 0′ 24.908″ N	198	2° 53′ 41.759″ W	54° 0′ 24.839″ N
199	2° 53′ 39.885″ W	54° 0′ 23.983″ N	200	2° 53′ 38.298″ W	54° 0′ 23.259″ N
201	2° 53′ 36.899″ W	54° 0′ 22.822″ N	202	2° 53′ 36.045″ W	54° 0′ 22.555″ N
203	2° 53′ 33.360″ W	54° 0′ 21.439″ N	204	2° 53′ 33.318″ W	54° 0′ 21.420″ N
205	3° 39′ 19.856″ W	54° 1′ 37.228″ N	206	3° 39′ 21.169″ W	54° 1′ 49.244″ N
207	3° 39′ 21.192″ W	54° 1′ 49.459″ N	208	3° 39′ 21.278″ W	54° 1′ 50.249″ N
209	3° 39′ 21.133″ W	54° 1′ 51.295″ N	210	3° 39′ 21.034″ W	54° 1′ 52.010″ N
211	3° 39′ 20.950″ W	54° 1′ 52.614″ N	212	3° 39′ 20.930″ W	54° 1′ 52.757″ N
213	3° 39′ 20.929″ W	54° 1′ 52.759″ N	214	3° 39′ 20.908″ W	54° 1′ 52.914″ N
215	3° 39′ 20.901″ W	54° 1′ 52.961″ N	216	3° 39′ 20.898″ W	54° 1′ 52.975″ N
217	3° 39′ 52.373″ W	54° 2′ 2.823″ N	218	3° 40′ 23.852″ W	54° 2′ 12.668″ N
219	3° 41′ 8.463″ W	54° 2′ 26.615″ N	220	3° 41′ 44.621″ W	54° 2′ 37.914″ N
221	3° 43′ 41.800″ W	54° 3′ 14.498″ N	222	3° 44′ 20.928″ W	54° 3′ 26.703″ N
223	3° 45′ 34.687″ W	54° 3′ 49.695″ N	224	3° 46′ 13.432″ W	54° 4′ 1.765″ N
225	3° 46′ 27.742″ W	54° 4′ 6.221″ N	226	3° 46′ 38.749″ W	54° 4′ 9.648″ N
227	3° 46′ 41.500″ W	54° 4′ 10.505″ N	228	3° 46′ 41.511″ W	54° 4′ 10.509″ N
229	3° 46′ 42.021″ W	54° 4′ 10.667″ N	230	3° 46′ 42.055″ W	54° 4′ 10.678″ N
231	3° 46′ 42.083″ W	54° 4′ 10.687″ N	232	3° 46′ 42.129″ W	54° 4′ 10.701″ N
233	3° 46′ 42.131″ W	54° 4′ 10.702″ N	234	3° 46′ 42.133″ W	54° 4′ 10.700″ N
235	3° 46′ 42.350″ W	54° 4′ 10.523″ N	236	3° 46′ 42.387″ W	54° 4′ 10.493″ N
237	3° 46′ 47.070″ W	54° 4′ 6.690″ N	238	3° 46′ 44.487″ W	54° 4′ 5.765″ N
239	3° 46′ 37.064″ W	54° 4′ 3.106″ N	240	3° 46′ 37.384″ W	54° 4′ 2.806″ N
241	3° 46′ 29.940″ W	54° 3′ 56.941″ N	242	3° 46′ 1.601″ W	54° 3′ 43.699″ N
243	3° 43′ 26.327″ W	54° 2′ 31.067″ N	244	3° 43′ 26.226″ W	54° 2′ 31.104″ N
245	3° 42′ 11.229″ W	54° 1′ 56.313″ N	246	3° 39′ 57.975″ W	54° 0′ 54.425″ N
247	3° 39′ 12.895″ W	54° 0′ 33.467″ N	248	3° 39′ 19.856″ W	54° 1′ 37.228″ N

Commencement Information

I2 Sch. 1 Pt. 1 para. 2 in force at 28.11.2014, see art. 1

PART 2 E+W Ancillary Works

Commencement Information

I3 Sch. 1 Pt. 2 in force at 28.11.2014, see art. 1

Works within the Order limits which fall within the scope of works assessed in the environmental statement comprising—

(a) temporary landing places, moorings or other means of accommodating vessels in the construction and/or maintenance of the authorised development;

(b) buoys, beacons, fenders and other navigational warning or ship impact protection works; and

(c) temporary works for the benefit or protection of land or structures affected by the authorised development.

PART 3 E+W Requirements

Time limits E+W

1.  The authorised development shall commence no later than the expiration of five years beginning with the date this Order comes into force.

Commencement Information

I4 Sch. 1 Pt. 3 para. 1 in force at 28.11.2014, see art. 1

Detailed offshore design parameters E+W

2.—(1) Subject to sub-paragraph (2), no wind turbine generator forming part of the authorised development shall—

(a) exceed a height of 222 metres when measured from MHWS to the highest point of the rotating blade of the WTG;

(b) exceed a height of 122 metres to the height of the centreline of the generator shaft forming part of the WTG nacelle when measured from MHWS;

(c) exceed a rotor diameter of 200 metres, or have a rotor diameter of less than 120 metres;

(d) be less than 737 metres from the nearest WTG in either direction perpendicular to the approximate prevailing wind direction (crosswind) or be less than 737 metres from the nearest WTG in either direction which is in line with the approximate prevailing wind direction (downwind);

(e) have a distance of less than 22 metres between the lowest point of the rotating blade of the WTG and MHWS.

(2) References to the location of a wind turbine generator are references to the centre point of that WTG.

Commencement Information

I5 Sch. 1 Pt. 3 para. 2 in force at 28.11.2014, see art. 1

3.—(1) The total number of offshore substations forming part of the authorised development shall not exceed three.

(2) The dimensions of any offshore substation forming part of the authorised development (excluding any towers, helipads, masts and cranes) shall not exceed 75 metres in height when measured from LAT, 50 metres in length and 50 metres in width.

Commencement Information

I6 Sch. 1 Pt. 3 para. 3 in force at 28.11.2014, see art. 1

4.—(1) The number of cable systems forming part of the authorised development laid in the cable corridor forming part of the Order limits between reference point AA and reference point BB and reference point CC shown on the works plans shall not exceed five.

(2) The total length of the cables comprising Work No. 1(b) shall not exceed 270 kilometres.

(3) The total length of the cables comprising Work No. 3A shall not exceed 480 kilometres.

Commencement Information

I7 Sch. 1 Pt. 3 para. 4 in force at 28.11.2014, see art. 1

5.—(1) The total number of [F2 monopile] foundations forming part of the authorised development shall not exceed 207 and no monopile foundation for use with any wind turbine generator or offshore substation forming part of the authorised development shall have a diameter greater than 9 metres.

(2) No jacket structure for use with any wind turbine generator forming part of the authorised development shall have—

(a) a width spacing between each leg at the level of the seabed of more than 40 metres and at the level of LAT which is greater than 20 metres;

(b) more than four legs;

(c) a leg diameter of more than 3 metres;

(d) more than one pile per leg;

(e) a pile diameter of more than 3 metres;

(f) more than one suction caisson per leg;

(g) a suction caisson diameter of greater than 10 metres.

(3) No jacket structure for use with any offshore substation forming part of the authorised development, when used in conjunction with steel piles or suction caissons, shall have—

(a) a width spacing between each leg at the level of the seabed of more than 70 metres and at the level of LAT which is greater than 40 metres;

(b) more than 4 legs;

(c) a leg diameter of more than 4 metres;

(d) more than four piles per leg;

(e) a pile diameter of more than 3.5 metres;

(f) more than three suction caissons per leg;

(g) a suction caisson diameter of greater than 25 metres each.

Textual Amendments

F2 Word in Sch. 1 Pt. 3 para. 5 substituted (25.4.2015) by The Walney Extension Offshore Wind Farm (Correction) Order 2015 (S.I. 2015/1270), art. 1, Sch.

Commencement Information

I8 Sch. 1 Pt. 3 para. 5 in force at 28.11.2014, see art. 1

6.  The total volume of scour protection for use with WTGs within Work No. 1(a) shall not exceed 2,277,000m³.

Commencement Information

I9 Sch. 1 Pt. 3 para. 6 in force at 28.11.2014, see art. 1

7.  The total volume of scour protection for use with the offshore substation platforms within Work No. 2(a) shall not exceed 125,100m³.

Commencement Information

I10 Sch. 1 Pt. 3 para. 7 in force at 28.11.2014, see art. 1

8.  The total volume of cable protection (excluding cable crossings) included within Work No. 1(b) shall not exceed 27,000m³ with a maximum footprint of 35,000m².

Commencement Information

I11 Sch. 1 Pt. 3 para. 8 in force at 28.11.2014, see art. 1

9.  The total volume of cable protection associated with cable crossings included within Work No. 1(b) shall not exceed 64,328m³ with a maximum footprint of 74,480m².

Commencement Information

I12 Sch. 1 Pt. 3 para. 9 in force at 28.11.2014, see art. 1

10.  The total volume of cable protection (excluding cable crossings) for Work No. 3A shall not exceed 109,650m³ with a maximum footprint of 142,139m².

Commencement Information

I13 Sch. 1 Pt. 3 para. 10 in force at 28.11.2014, see art. 1

11.  The total volume of cable protection associated with cable crossings included within Work No. 3A shall not exceed 125,955m³ with a maximum footprint of 144,548m².

Commencement Information

I14 Sch. 1 Pt. 3 para. 11 in force at 28.11.2014, see art. 1

Air traffic services at Warton Aerodrome E+W

12.—(1) No construction of any wind turbine generator forming part of the authorised development shall commence until the Secretary of State, having consulted with the Ministry of Defence and the Operator, confirms in writing that he is satisfied that appropriate mitigation will be implemented and maintained for the life of the authorised development and that arrangements have been put in place with the Operator to ensure that such appropriate mitigation is implemented.

(2) For the purposes of this Requirement—

“appropriate mitigation” means measures to prevent or remove any adverse impacts which the operation of the authorised development will have on the Operator’s ability to provide safe and efficient air traffic services for Warton Aerodrome during the life of the authorised development;

“approved mitigation” means the appropriate mitigation measures agreed with the Ministry of Defence and the Operator at the time the Secretary of State confirms in writing that he is satisfied in accordance with sub-paragraph (1);

“Ministry of Defence” means as represented by Defence Infrastructure Organisation – Safeguarding, Kingston Road, Sutton Coldfield, B75 7RL or any successor body;

“Operator” means BAE Systems (Operations) Limited incorporated under the Companies Act 2006 (Company Number 01996687) whose registered office is Warwick House, PO Box 87, Farnborough Aerospace Centre, Farnborough, Hants, GU14 6YU or such other organisation as is licensed from time to time under sections 5 and 6 of the Transport Act 2000 to provide air traffic services for Warton Aerodrome.

(3) The undertaker shall thereafter comply with all other obligations contained within the approved mitigation for the life of the authorised development.

Commencement Information

I15 Sch. 1 Pt. 3 para. 12 in force at 28.11.2014, see art. 1

Primary surveillance radars at St Annes and Lowther Hill E+W

13.—(1) No construction of any wind turbine generator forming part of the authorised development shall commence until the Secretary of State, having consulted with the Operator, confirms in writing that he is satisfied that a primary radar mitigation scheme will be implemented in order to avoid the impact of the development on the primary radar of the Operator located at St Annes and Lowther Hill and on associated air traffic management operations.

(2) No construction of any wind turbine generator forming part of the authorised development shall commence until the Operator has confirmed to the Secretary of State that an approved primary radar mitigation scheme has been implemented and the development shall thereafter be operated fully in accordance with such approved scheme.

(3) For the purposes of this Requirement—

“Operator” means NATS (En Route) plc, incorporated under the Companies Act 2006 (4129273) whose registered office is 4000 Parkway, Whiteley, Fareham, Hampshire, PO15 7FL or such other organisation licensed from time to time under sections 5 and 6 of the Transport Act 2000 to provide air traffic services to the relevant managed area (within the meaning of section 40 of that Act);

“primary radar mitigation scheme” means a scheme agreed with the Operator which sets out the measures to prevent or remove any adverse impacts which the operation of the proposed development will have on the Operator’s ability to provide safe and efficient air traffic management services from the St Annes and Lowther Hill primary radars.

Commencement Information

I16 Sch. 1 Pt. 3 para. 13 in force at 28.11.2014, see art. 1

Offshore decommissioning E+W

14.  No part of the authorised development seaward of MHWS shall commence until a written decommissioning programme in compliance with any notice served upon the undertaker by the Secretary of State pursuant to section 105(2) of the 2004 Act has been submitted to the Secretary of State for approval. The undertaker must consult the MMO, Natural England and the relevant planning authority on the proposed decommissioning activity no less than four months prior to submission of the proposed decommissioning programme to the Secretary of State.

Commencement Information

I17 Sch. 1 Pt. 3 para. 14 in force at 28.11.2014, see art. 1

Stages of authorised development onshore E+W

15.—(1) The connection works shall not be commenced until a written scheme setting out all the stages of the connection works has been submitted to and approved by the relevant planning authority.

(2) The scheme shall be implemented as approved.

Commencement Information

I18 Sch. 1 Pt. 3 para. 15 in force at 28.11.2014, see art. 1

Detailed design approval onshore E+W

16.—(1) No stage of the connection works shall commence until details of the layout, scale, levels and external appearance of that stage have been submitted to and approved by the relevant planning authority. The connection works must be carried out in accordance with the approved details.

(2) Any works approved by the relevant planning authority under sub-paragraph (1) must accord with the plans (or relevant parts of plans) listed in Requirement 17 and the principles set out in the design and access statement and be within the Order limits.

(3) The connection works and maintenance thereof comprised within the area of onshore cable corridor between points XX and YY shown on the works plans for Work No. 3B shall—

(a) only be undertaken by means of horizontal directional drilling from construction working sites located west of point XX and/or east of point YY;

(b) comprise a horizontal directional drilling entry/exit point no less than 50 metres west of point XX on the works plans for Work No. 3B;

(c) comprise a horizontal directional drilling entry/exit point no less than 20 metres east of point YY on the works plans for Work No. 3B; and

(d) not involve the placing or transportation of any plant, apparatus, cables, cable ducts or any other materials required for the carrying out of the connection works on or over that land, provided that the undertaker may place or transport (by hand and on foot only) such equipment and/or means of enclosure, on or over that land, as may be required to—

(i) contain and/or remove fluid used in the horizontal directional drilling process including the placing of hoses along the northern Order limit between points XX and YY shown on the works plans for Work No. 3B as approved by the relevant planning authority, in consultation with Natural England and the MMO; and

(ii) mitigate the horizontal directional drilling process in accordance with the environmental management and monitoring plan approved pursuant to this Requirement.

(4) The connection works comprised in Work Nos. 3A and 3B between points XX and YY shown on the works plans must not be commenced until an environmental management and monitoring plan has been approved by the relevant planning authority, in consultation with Natural England and the MMO. The environmental management and monitoring plan must be submitted for approval at least four months prior to the commencement of those connection works, or within such other timescale as agreed with the relevant planning authority.

(5) The environmental management and monitoring plan must include details of the location, method and timing of surveys of the land within the Order limits between points XX and YY shown on the works plans to—

(a) establish the pre-construction baseline condition of the saltmarsh and the distribution of the Lycia zonaria britannica (Belted Beauty Moth) in that location; and

(b) record within a five year period following completion of construction the ecological recovery of the saltmarsh and the distribution of the Lycia zonaria britannica (Belted Beauty Moth) in that location and, if applicable, any receptor site to which the Lycia zonaria britannica (Belted Beauty Moth) has been translocated.

(6) The environmental management and monitoring plan must include details of the methodology for undertaking the connection works comprised in Work Nos. 3A and 3B between points XX and YY shown on the works plans by horizontal directional drilling, and mitigation measures relating thereto, including—

(a) details of the equipment required to contain and/or remove fluid used in the horizontal directional drilling process;

(b) details of means of enclosure to be deployed (if any);

(c) the use of a drill bit of no less than 12.25 inches;

(d) the use of a real time downhole annular pressure monitor;

(e) details of how the length of each drill path will be minimised;

(f) details of the training of personnel to be employed in relation to the horizontal directional drilling and/or mitigation measures;

(g) the employment of an Ecological Clerk of Works and scope of duties relating to that role;

(h) details of how the number of trips made between points XX and YY shown on the works plans will be minimised;

(i) details of the methodology and location of suitable receptor sites associated with the translocation of the Lycia zonaria britannica (Belted Beauty Moth), should such translocation be required by the relevant planning authority, having consulted with Natural England and the MMO;

(j) details of the methodology for preventing birds from nesting above the alignment of each horizontal directional drill, such methodology may include visual and/or sound deterrents, and/or physical barriers; and

(k) details of how the connection works will be maintained (if applicable).

(7) The environmental management and monitoring plan must be implemented as approved, except to the extent that any changes to the plan are agreed by the relevant planning authority, in consultation with Natural England and the MMO, and provided that the undertaker shall not be required to carry out the post-construction monitoring of the ecological recovery of the saltmarsh in sub-paragraph (5)(b) in the event that no fluid used in the horizontal directional drilling process is released into the saltmarsh between points XX and YY shown on the works plans.

(8) No part of Work No. 6 shall—

(a) comprise more than five transition joint bays;

(b) comprise a transition joint bay having a length greater than 14 metres and a width greater than 4 metres and a depth of greater than 2 metres;

(c) comprise more than ten pits for the fibre optic joints and link boxes;

(d) comprise a fibre optic joint pit having a length greater than 1.5 metres and a width greater than 1.5 metres and a depth of greater than 2 metres;

(e) comprise a link box pit having a length greater than 1.5 metres and a width greater than 1.5 metres and a depth of greater than 2 metres;

(f) comprise a combined pit for the fibre optic joint and link box having a length greater than 3 metres and a width greater than 3 metres and a depth of greater than 2 metres.

(9) The total footprint of Work No. 6 shall not exceed 100 metres in length and 100 metres in width.

(10) No part of the onshore cable corridor occupied by the connection works shall—

(a) comprise more than two cable trenches, each having a width greater than 3.6 metres or a depth greater than 3 metres;

(b) comprise more than fifteen horizontal directional drill holes;

(c) comprise horizontal directional drill holes at a depth greater than 40 metres below existing ground level.

(11) The onshore cable corridor shall comprise—

(a) no more than 25 cable jointing bays, each having a length no greater than 10 metres and a width no greater than 3 metres and a depth of no greater than 2 metres;

(b) no more than 50 pits for the fibre optic joints and link boxes;

(c) a fibre optic joint pit having a length no greater than 1.5 metres and a width no greater than 1.5 metres and a depth of no greater than 2 metres;

(d) a link box pit having a length no greater than 1.5 metres and a width no greater than 1.5 metres and a depth of no greater than 2 metres;

(e) a combined pit for the fibre optic joint and link box having a length no greater than 3 metres and a width no greater than 3 metres and a depth of no greater than 2 metres.

(12) No building(s) forming part of Work No. 25 shall exceed—

(a) a height of 15 metres above developmental ground level or 21 metres above AOD;

(b) a total footprint of 170 metres in length and 170 metres in width, unless otherwise agreed by the relevant planning authority.

(13) The developmental ground level of the building(s) forming part of Work No. 25 must not be lower than 5.1 metres AOD or higher than 6 metres above AOD, unless otherwise agreed by the relevant planning authority.

(14) The fenced compound comprised in Work No. 25 must not exceed 170 metres by 170 metres.

(15) No external equipment or apparatus comprised in Work No. 25 shall exceed 23 metres above developmental ground level or 29 metres above AOD.

Commencement Information

I19 Sch. 1 Pt. 3 para. 16 in force at 28.11.2014, see art. 1

17.  The connection works must be carried out in accordance with the plans submitted with the application for this Order, or subsequently in connection with the examination of this Order, and certified by the Secretary of State unless otherwise agreed by the relevant planning authority.

Commencement Information

I20 Sch. 1 Pt. 3 para. 17 in force at 28.11.2014, see art. 1

Provision of landscaping E+W

18.—(1) The works comprising Work No. 25 must not commence until a written landscaping scheme and associated work programme (which accords with the principles set out in the CoCP and the design and access statement) has been submitted to and approved by the relevant planning authority.

(2) The landscaping scheme must include details of all proposed hard and soft landscaping works, including—

(a) location, number, species, size and planting density of any proposed planting, including any trees;

(b) pre-cultivation, cultivation and other operations to ensure plant establishment;

(c) the type, storage, and handling of imported materials;

(d) proposed finished ground levels;

(e) hard surfacing materials;

(f) vehicular and pedestrian access, parking and circulation areas;

(g) minor structures, such as furniture, refuse or other storage units, signage and lighting;

(h) proposed and existing functional services above and below ground, including drainage, power and communications cables and pipelines, manholes and supports;

(i) details of existing trees to be retained, with measures for their protection during the construction period;

(j) retained historic landscape features and proposals for restoration, where relevant;

(k) implementation timetables for all landscaping works; and

(l) future maintenance regimes.

Commencement Information

I21 Sch. 1 Pt. 3 para. 18 in force at 28.11.2014, see art. 1

Implementation and maintenance of landscaping E+W

19.—(1) All landscaping works, including replacement planting carried out in accordance with sub-paragraph (2), must be carried out in accordance with a landscaping scheme approved under Requirement 18 and to a standard in accordance with the relevant recommendations of appropriate British Standards or other recognised codes of good practice.

(2) Any tree or shrub planted as part of any landscaping scheme approved under Requirement 18 that, within a period of five years after planting, is removed, dies or becomes, in the opinion of the relevant planning authority, seriously damaged or diseased, must be replaced in the first available planting season with a specimen of the same species and size as that originally planted, unless otherwise agreed by the relevant planning authority.

Commencement Information

I22 Sch. 1 Pt. 3 para. 19 in force at 28.11.2014, see art. 1

Highway accesses E+W

20.—(1) No stage of the connection works shall commence until written details of the siting, design, levels and layout of any new permanent or temporary means of access to a highway to be used by vehicular traffic, or any alteration to an existing means of access to a highway used by vehicular traffic, for that stage, has, after consultation with the highway authority, been submitted to and approved by the relevant planning authority. The written details submitted must be in accordance with the General Arrangement Drawings.

(2) The highway accesses for each stage must be constructed in accordance with the approved details.

Commencement Information

I23 Sch. 1 Pt. 3 para. 20 in force at 28.11.2014, see art. 1

Public Access Strategy E+W

21.  All connection works must be undertaken in accordance with the principles set out in the Public Access Strategy unless otherwise agreed by the relevant planning authority.

Commencement Information

I24 Sch. 1 Pt. 3 para. 21 in force at 28.11.2014, see art. 1

Public rights of way E+W

22.—(1) No stage of the connection works shall commence until a public rights of way diversion and closure scheme for that stage which accords with the principles of the Public Access Strategy, has, after consultation with the highway authority, been submitted to and approved by the relevant planning authority and that scheme shall include a programme for the temporary closure and re-opening of the public rights of way specified at Schedule 4 (public rights of way to be temporarily stopped up).

(2) Each stage of the connection works must be carried out in accordance with the approved scheme.

Commencement Information

I25 Sch. 1 Pt. 3 para. 22 in force at 28.11.2014, see art. 1

Fencing and other means of enclosure E+W

23.—(1) No stage of the connection works shall commence until written details of all proposed permanent and temporary fences, walls or other means of enclosure for the relevant stage have been submitted to and approved by the relevant planning authority.

(2) All fencing must be erected in accordance with the approved details.

(3) All construction sites must remain securely fenced at all times during construction of the connection works.

(4) Any temporary fencing must be removed on completion of the connection works.

(5) Any approved permanent fencing in relation to Work No. 25 must be completed before the relevant work is brought into use.

Commencement Information

I26 Sch. 1 Pt. 3 para. 23 in force at 28.11.2014, see art. 1

Surface and foul water drainage E+W

24.—(1) No stage of the connection works shall commence until for that stage written details of the surface and (if any) foul water drainage system (including means of pollution control) have, after consultation with the relevant sewerage and drainage authorities and the Environment Agency, been submitted to and approved by the relevant planning authority.

(2) The surface and foul water drainage system for each stage must be constructed in accordance with the approved details.

Commencement Information

I27 Sch. 1 Pt. 3 para. 24 in force at 28.11.2014, see art. 1

Contaminated land and contaminated groundwater E+W

25.—(1) No stage of the connection works shall commence until a written scheme to deal with the contamination of any land comprised in that stage, including groundwater, within the Order limits which is likely to cause significant harm to persons or pollution of controlled waters or the environment has, after consultation with the relevant planning authority and the Environment Agency, been submitted to and approved by the relevant planning authority.

(2) The scheme must include a desk study and assessment report, informed as necessary by an intrusive site investigation, prepared by a specialist consultant approved by the relevant planning authority, to identify the extent of any contamination within the Order limits and mitigation measures to be undertaken to limit impacts arising from the potential release of contaminants.

(3) Such remediation as may be identified in the approved scheme must be carried out in accordance with the approved scheme.

(4) If during the construction of the connection works further contamination not previously identified is found to be present at the site then no further work shall be carried out on that part of the site until—

(a) a risk assessment has been carried out and the results of the risk assessment have been provided to the relevant planning authority; and

(b) such additional mitigation measures (if any) as may be identified by the risk assessment have been incorporated into the approved scheme.

Commencement Information

I28 Sch. 1 Pt. 3 para. 25 in force at 28.11.2014, see art. 1

Archaeology onshore E+W

26.—(1) No stage of the connection works shall commence until in relation to that stage a written scheme for the investigation of areas of archaeological interest has been submitted to and approved by the relevant planning authority.

(2) The scheme must identify areas where field work and/or a watching brief are required, and the measures to be taken to protect, record or preserve any significant archaeological remains that may be found, including—

(a) a programme of auger survey to determine the extent and depth of the peat basin in Site 30 (as identified in Chart 27.1 of the environmental statement), followed by an assessment of the core samples;

(b) a targeted programme of evaluation to focus the approach to ‘strip, map and record’ on the land comprised within the Order limits north of the A683, which is not occupied by former railway sidings;

(c) a watching brief during all archaeologically relevant ground works of land comprised within the Order limits south of the A683; and

(d) a programme of post-fieldwork assessment, analysis, reporting and archiving.

(3) Any archaeological works or watching brief carried out under the approved scheme must be by a suitably qualified person or body approved by the relevant planning authority.

(4) Any archaeological works or watching brief for each stage must be carried out in accordance with the approved scheme.

Commencement Information

I29 Sch. 1 Pt. 3 para. 26 in force at 28.11.2014, see art. 1

Code of Construction Practice (CoCP) E+W

27.  All connection works must be undertaken in accordance with the principles set out in the CoCP unless otherwise agreed by the relevant planning authority.

Commencement Information

I30 Sch. 1 Pt. 3 para. 27 in force at 28.11.2014, see art. 1

Construction and environmental management plan E+W

28.—(1) No stage of the connection works shall commence until a construction and environmental management plan (CEMP) for that stage has been submitted to and approved by the relevant planning authority, in consultation with Natural England.

(2) The CEMP must be submitted to the relevant planning authority and Natural England at least four months prior to the commencement of the relevant stage of the connection works.

(3) The CEMP must cover all the subject areas set out in the certified CoCP and any other matters the relevant planning authority, having consulted with Natural England, reasonably requires.

(4) The CEMP for each stage must be implemented as approved.

Commencement Information

I31 Sch. 1 Pt. 3 para. 28 in force at 28.11.2014, see art. 1

Emergency response plan E+W

29.—(1) No stage of the connection works shall commence until an emergency response plan relating to the construction and operation of that stage of the relevant works has been submitted for approval by the relevant planning authority after consultation with the Heysham Power Station Emergency Planning Consultative Committee (of which the relevant planning authority is a member) for the nuclear site licences at Heysham Power Station.

(2) The emergency response plan must be carried out as approved in relation to the relevant stage of the relevant works, except to the extent that any changes to the plan are agreed by the relevant planning authority after consultation with the Emergency Planning Consultative Committee.

Commencement Information

I32 Sch. 1 Pt. 3 para. 29 in force at 28.11.2014, see art. 1

European protected species E+W

30.—(1) No stage of the connection works shall commence until—

(a) the methodology for the preconstruction survey work required to establish whether a European protected species is present on any of the land affected, or likely to be affected, by the relevant stage or in any of the trees to be lopped or felled as part of the relevant stage, has been submitted to and approved by the relevant planning authority in consultation with Natural England; and

(b) the preconstruction survey work for that stage has been carried out in accordance with the approved methodology.

(2) Where a European protected species is shown to be present the relevant stage of the connection works shall not begin until, after consultation with Natural England, a scheme of protection and mitigation measures has been submitted to and approved by the relevant planning authority. The relevant works must be carried out in accordance with the approved scheme.

(3) “European protected species” has the same meaning as in regulations 40 and 44 of the Conservation of Habitats and Species Regulations 2010(1).

Commencement Information

I33 Sch. 1 Pt. 3 para. 30 in force at 28.11.2014, see art. 1

Construction Traffic Management Plan E+W

31.—(1) No stage of the connection works shall commence until a construction traffic management plan (CTMP) for that stage has been submitted to and approved by the relevant planning authority, in consultation with the highway authority, in accordance with the Outline CTMP.

(2) The CTMP for each stage must be implemented as approved.

Commencement Information

I34 Sch. 1 Pt. 3 para. 31 in force at 28.11.2014, see art. 1

Port Construction Traffic Management Plan (Port CTMP) E+W

32.—(1) No authorised development or part of the authorised development shall commence until a port construction traffic management plan (Port CTMP) for the port-related traffic, to and from the selected base port or ports for offshore construction and/or operation of the authorised development, has been submitted to and approved by the relevant planning authority.

(2) The Port CTMP must not be submitted to the relevant planning authority for approval until the undertaker has consulted with the relevant planning authority, adjacent planning authority and relevant highway authority in relation to the terms of the Port CTMP, a transport assessment, air quality assessment and offshore construction travel plan relating to the port-related traffic to and from the selected base port or ports for offshore construction and/or operation of the authorised development, unless otherwise agreed with the relevant planning authority.

(3) When the Port CTMP is submitted to the relevant planning authority it must be accompanied by a transport assessment, air quality assessment and offshore construction travel plan relating to the port-related traffic to and from the selected base port or ports for offshore construction and/or operation of the authorised development, unless otherwise agreed with the relevant planning authority.

(4) If the transport assessment and air quality assessment submitted with the Port CTMP identify likely significant effects in terms of transport and/or air quality, the Port CTMP must include details of the measures required to mitigate those likely significant effects and a programme for the implementation of those measures.

(5) The Port CTMP must, unless otherwise agreed with the relevant planning authority, set out the particulars of—

(a) the proposed vehicle routeing plans;

(b) the proposed scheduling and timing of vehicle movements;

(c) the details of the port handling facilities for deliveries, including a parking management plan for heavy goods vehicles and construction workers’ vehicles;

(d) the swept path analysis of the proposed vehicle routes;

(e) the scope of surveys to be carried out to record the condition of the public highway, including proposed highway inspection regimes, and the proposed highway maintenance scheme to remediate damage to the highway (if any) that may be caused by construction vehicles;

(f) the details of any highway works proposed; and

(g) the details of any traffic management proposed.

(6) The relevant planning authority must not—

(a) approve the Port CTMP unless and until it has consulted with and had regard to the representations of the adjacent planning authority and relevant highway authority in relation to any or all of the Port CTMP, the transport assessment, the air quality assessment and the offshore construction travel plan; or

(b) grant any other approval, or waive any obligation of the undertaker, under the terms of this Requirement unless and until it has consulted with and had regard to the representations of the adjacent planning authority and relevant highway authority.

(7) The Port CTMP must be implemented as approved at all times specified within the Port CTMP during the offshore construction and/or operation of the authorised development.

(8) For the purposes of this Requirement—

“adjacent planning authority” means the planning authority or authorities whose administrative area(s) is/are adjacent to the administrative area(s) in which the selected base port(s) is/are located;

“air quality assessment” means a document that accords with the principles of Environmental Protection UK Guidance “Development Control: Planning for Air Quality” and “Technical Guidance LAQM.TG(09)” published by the Department for Environment, Food and Rural Affairs and agreed with the relevant planning authority for the area required to be assessed;

“base ports” means the port or ports used for construction and/or operation of the authorised development;

“offshore construction travel plan” means a document which outlines the management of the travel requirements associated with the offshore construction of the authorised development, including a programme of measures aimed at encouraging more sustainable travel, with an emphasis on reducing single occupancy car use;

“parking management plan” means a document which sets out the parking arrangements at the selected base ports for vehicles associated with the offshore construction of the authorised development and how these will be managed to ensure impacts associated with unauthorised parking on the public highway are adequately mitigated;

“relevant highway authority” means the highway authority or authorities—

(a)

in whose administrative areas the selected base ports are located; and/or

(b)

whose administrative areas are adjacent to that/those areas; and/or

(c)

the Highways Agency;

“relevant planning authority” means the planning authority or authorities in whose administrative areas the selected base ports are located;

“selected base port” or “ports” means a base port or ports situated in England; and

“transport assessment” means a document that accords with the principles set out in the Transport Statement and the national guidance given in the Guidance on Transport Assessment (2007) published by the Department for Transport and Department for Communities and Local Government, and includes an assessment of those vehicle routes agreed with the relevant highway authority or authorities.

Commencement Information

I35 Sch. 1 Pt. 3 para. 32 in force at 28.11.2014, see art. 1

Construction hours E+W

33.—(1) Construction work for the connection works and any construction-related traffic movements to or from the site of the relevant works must not take place other than between 0700 hours and 1900 hours Monday to Friday, 0700 hours and 1400 hours on Saturdays, with no activity on Sundays or bank holidays, save—

(a) where continuous periods of operation are required, such as concrete pouring and drilling;

(b) for the delivery of abnormal loads to the relevant works, which may cause congestion on the local road network;

(c) where works are being carried out on the foreshore;

or unless otherwise agreed with the relevant planning authority in accordance with sub-paragraph (2).

(2) All construction operations which are to be undertaken outside the hours specified in sub-paragraph (1) must be agreed with the relevant planning authority in advance, and shall be carried out within the agreed times.

Commencement Information

I36 Sch. 1 Pt. 3 para. 33 in force at 28.11.2014, see art. 1

Control of noise during construction E+W

34.—(1) No stage of the connection works shall commence until a Construction Noise Management Plan (CNMP) for that stage has been submitted to and approved by the relevant planning authority.

(2) The CNMP must set out the particulars of—

(a) the construction works, and the method by which they are to be carried out;

(b) the noise attenuation and mitigation measures to be taken to minimise noise resulting from the construction works, including any noise limits;

(c) a scheme for monitoring the noise during the construction works to ensure compliance with the noise limits and effectiveness of the attenuation and mitigation measures.

(3) The CNMP for each stage must be implemented as approved.

Commencement Information

I37 Sch. 1 Pt. 3 para. 34 in force at 28.11.2014, see art. 1

Control of noise during operational phase E+W

35.—(1) The noise emanating from the operation of Work No. 25 (including transformers, cooling fans, switch gear and power lines) (including any relevant penalties for tonal or impulsive noise in accordance with section 8 of BS4142:1997) must not exceed the following levels by reference to the specified points marked on the Noise Monitoring Location Plan—

(a) 35dB(A) when measured at Mossgate Park (R1); and

(b) 35dB(A) when measured at Borrans Lane Static Homes (R2).

(2) Noise measurements shall be expressed as 5 minute L(A)eq values.

(3) All standby generator testing in relation to the connection works must be undertaken during the hours of 0900 to 1700 on Mondays to Saturdays, and not at all on Sundays or bank holidays, unless otherwise agreed with the relevant planning authority.

Commencement Information

I38 Sch. 1 Pt. 3 para. 35 in force at 28.11.2014, see art. 1

Control of air quality E+W

36.—(1) No stage of the connection works shall commence until a Construction Phase Air Quality Management Plan (AQMP) for that stage has been submitted to and approved by the relevant planning authority.

(2) The AQMP must cover all the subject areas set out in the certified CoCP and any other matters the relevant planning authority reasonably requires.

(3) The AQMP for each stage must be implemented as approved.

Commencement Information

I39 Sch. 1 Pt. 3 para. 36 in force at 28.11.2014, see art. 1

Control of artificial light emissions E+W

37.—(1) No stage of the connection works shall commence until a written scheme for the management and mitigation of artificial light emissions during the construction and/or operation of the relevant stage has been submitted to and approved by the relevant planning authority, in consultation with Natural England.

(2) The scheme for the management and mitigation of artificial light emissions for each stage must be implemented as approved.

Commencement Information

I40 Sch. 1 Pt. 3 para. 37 in force at 28.11.2014, see art. 1

Flood risk E+W

38.—(1) No stage of the connection works shall commence until a written scheme for the mitigation of flood risk during the construction and/or operation of the relevant stage has been submitted to and, after consultation with the Environment Agency and the Lead Local Flood Authority, approved by the relevant planning authority.

(2) The scheme referred to in sub-paragraph (1) shall be prepared in accordance with the principles set out in the environmental statement and the flood risk assessment annexed thereto.

(3) The scheme of flood risk mitigation for each stage must be implemented as approved.

Commencement Information

I41 Sch. 1 Pt. 3 para. 38 in force at 28.11.2014, see art. 1

Restoration of land used temporarily for construction E+W

39.  Any land landward of mean low water level within the Order limits which is used temporarily for construction of the connection works, and not incorporated in permanent works or approved landscaping, must be reinstated to its former condition, or such condition as the relevant planning authority may approve, within six months of completion of the onshore works, or such other period as the relevant planning authority may approve.

Commencement Information

I42 Sch. 1 Pt. 3 para. 39 in force at 28.11.2014, see art. 1

Onshore decommissioning E+W

40.—(1) Upon the cessation of commercial operation of the onshore substation [F3 comprised] in Work No. 25, a written scheme for the demolition and removal of that substation, and the final proposed condition of the relevant land, including a proposed timetable, must be submitted to and approved by the relevant planning authority, in consultation with Natural England.

(2) The scheme for decommissioning shall be implemented as approved.

Textual Amendments

F3 Word in Sch. 1 Pt. 3 para. 40 substituted (25.4.2015) by The Walney Extension Offshore Wind Farm (Correction) Order 2015 (S.I. 2015/1270), art. 1, Sch.

Commencement Information

I43 Sch. 1 Pt. 3 para. 40 in force at 28.11.2014, see art. 1

Requirement for written approval E+W

41.  Where under any of the above Requirements the approval or agreement of the Secretary of State, the relevant planning authority or another person or body is required, notification of such approval or agreement must be given in writing.

Commencement Information

I44 Sch. 1 Pt. 3 para. 41 in force at 28.11.2014, see art. 1

Amendments to approved details E+W

42.—(1) With respect to any Requirement which requires the authorised development to be carried out in accordance with the details approved by the relevant planning authority or another approval authority as specified in the Requirement (the “discharging authority”), the approved details must be carried out as approved unless an amendment or variation is agreed in advance by the discharging authority, in accordance with sub-paragraph (2), and in consultation with any body specified in the relevant Requirement.

(2) Where any Requirement specifies “unless otherwise agreed” by the discharging authority such agreement shall not be given except in relation to immaterial changes where it has been demonstrated to the satisfaction of the discharging authority that the agreement sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

(3) The approved details shall include any amendments that may subsequently be agreed by the discharging authority.

Commencement Information

I45 Sch. 1 Pt. 3 para. 42 in force at 28.11.2014, see art. 1

Article 10

SCHEDULE 2 E+W STREETS SUBJECT TO STREET WORKS

Commencement Information

I46 Sch. 2 in force at 28.11.2014, see art. 1

(1) Area	(2) Streets subject to street works
In the County of Lancashire, District of City of Lancaster	A683 Lancaster Morecambe Bypass at reference points A – B (works to highway to create access) on the street works plan
In the County of Lancashire, District of City of Lancaster	A683 Lancaster Morecambe Bypass at reference points C – D (works to highway to install onshore cable systems) on the street works plan
In the County of Lancashire, District of City of Lancaster	A683 Lancaster Morecambe Bypass at reference points E – F (works to highway to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Imperial Road at reference point G – H (works to road to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Middleton Road at reference points I – J (works to highway to create access to construction working site and to install onshore cable systems) on the street works plan
In the County of Lancashire, District of City of Lancaster	Middleton Road at reference points K – L (works to highway to create access to construction working site and to install onshore cable systems) on the street works plan
In the County of Lancashire, District of City of Lancaster	Carr Lane at reference points M – N (works to highway to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Carr Lane at reference points O – P (works to highway to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Track leading east from Carr Lane at New Brows Farm at reference points Q – R (works to track to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Track leading south to Middleton Lake at New Brows Farm between reference points S and T (works to track to create access to construction working site) on the street works plan
In the County of Lancashire, District of City of Lancaster	Carr Lane and track leading east from Carr Lane at Potts Corner between reference points U – V and W – X (works to highway and track to create access to construction working site) on the street works plan

Article 11

SCHEDULE 3 E+W STREETS TO BE TEMPORARILY STOPPED UP

Commencement Information

I47 Sch. 3 in force at 28.11.2014, see art. 1

(1) Area	(2) Street to be temporarily stopped up	(3) Extent of temporary stopping up
In the County of Lancashire, District of City of Lancaster	A683 Lancaster Morecambe Bypass	For approximately 167 metres within the area shown hatched black on the street works plan
In the County of Lancashire, District of City of Lancaster	Imperial Road	For approximately 69 metres within the area shown hatched black on the street works plan
In the County of Lancashire, District of City of Lancaster	Middleton Road	For approximately 51 metres within the area shown hatched black on the street works plan
In the County of Lancashire, District of City of Lancaster	Track at Potts Corner leading east from Carr Lane alongside the sea defence	For approximately 111 metres within the area shown hatched black on the street works plan

Article 12

SCHEDULE 4 E+W PUBLIC RIGHTS OF WAY TO BE TEMPORARILY STOPPED UP

Commencement Information

I48 Sch. 4 in force at 28.11.2014, see art. 1

(1) Area	(2) Footpath to be temporarily stopped up	(3) Extent of temporary stopping up
In the County of Lancashire, District of City of Lancaster	(1)	For approximately 40 metres between the reference points 1(i) and 1(ii) on the public rights of way plan
In the County of Lancashire, District of City of Lancaster	(3)	For approximately 57 metres between the reference points 3(i) and 3(ii) on the public rights of way plan
In the County of Lancashire, District of City of Lancaster	(5)	For approximately 42 metres between the reference points 5(i) and 5(ii) on the public rights of way plan
In the County of Lancashire, District of City of Lancaster	(6/11)	For approximately 102 metres between the reference points 6/11(i) and 6/11(ii) on the public rights of way plan

Article 13

SCHEDULE 5 E+W ACCESS TO WORKS

Commencement Information

I49 Sch. 5 in force at 28.11.2014, see art. 1

(1) Area	(2) Description of Access
In the County of Lancashire, District of City of Lancaster	Vehicular access from the A683 Lancaster Morecambe Bypass to the north at reference points A – B on the street works plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from the A683 Lancaster Morecambe Bypass to the south at reference points E – F on the street works plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from Imperial Road to the east at reference point G – H on the public rights of way plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from Middleton Road to the north at reference points I – J on the street works plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from Middleton Road at reference points K – L to the south on the public rights of way plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from Carr Lane to the south at reference points M – N on the street works plan
In the County of Lancashire, District of City of Lancaster	Vehicular access from Carr Lane to the east at reference points O – P on the street works plan
In the County of Lancashire, District of City of Lancaster	Carr Lane and track leading east from Carr Lane at Potts Corner between reference points U – V and W – X on the street works plan

Article 21(2)

SCHEDULE 6 E+W LAND IN WHICH ONLY NEW RIGHTS ETC., MAY BE ACQUIRED

Commencement Information

I50 Sch. 6 in force at 28.11.2014, see art. 1

(1) Number of land shown on land plans	(2) Purpose for which rights may be acquired
1	1. The right to enter and remain upon the land for the purposes of operation, maintenance and decommissioning of the authorised project and to: (a) adjust, alter, construct, test, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, jointing bays, earthing measures, cathodic protection, cross bonding pits, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) enter and be upon the land and remain with or without plant, vehicles, machinery, apparatus and equipment which is ancillary to the purposes of transmitting electricity along the cables; (c) retain and use the cables for the purpose of the transmission of electricity; (d) pass and re-pass with or without vehicles plant and machinery for the purposes of surveying and for adjusting, altering, constructing, using, maintaining, repairing, renewing, upgrading, inspecting, removing and replacing the cables; (e) place and to use plant, machinery, structures and temporary structures within the land for the maintenance, repairing, renewing, upgrading, inspecting, removal and replacing the cables; (f) erect, maintain and remove fencing for site safety and protection of the works consented under this order and create secure works compounds; (g) maintain, use, improve, repair, replace, extend, inspect, adjust, alter, renew, test or cleanse and remove temporary or permanent drainage and manage water flows in existing drains, watercourses and culverts; (h) alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (i) maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (j) store and stockpile materials (including excavated material) within the Order land; (k) use or resort to horizontal directional drilling for the renewal, repair, upgrading, or replacement of the cables; (l) lay out temporary paths for public use; erect temporary signage and measures to effect public safety; (m) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (n) carry out environmental or ecological mitigation or enhancement works. 2. A restrictive covenant over the land for the benefit of the remainder of the Order land to: (a) prevent anything to be done in or upon the Order land or any part thereof for the purpose of the erection of any buildings or construction erection or works of any kind (including the foundations or footings thereto); (b) prevent anything to be done by way of hard surfacing of the Order land with concrete of any kind or with any other material or surface whatsoever without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed surfacing would not cause damage to relevant part of the authorised project nor make it materially more difficult or expensive to maintain the authorised project); (c) prevent anything to be done by way of excavation of any kind of the Order land nor any activities which increase or decrease ground cover or soil levels in any manner whatsoever without the consent in writing of the undertaker save as are reasonably required for agricultural activities; (d) prevent the planting or growing within the Order land any trees, shrubs or underwood without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed trees, shrubs or underwood would not cause damage to the relevant part of the authorised project nor make it materially more difficult or expensive to access the relevant part of the authorised project).
2 6-10 41	1. The right to enter and remain upon the land for the purposes of operation, maintenance and decommissioning of the authorised project and to: (a) adjust, alter, construct, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, and other apparatus, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) retain and use the cables for the purpose of the transmission of electricity; (c) alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (d) maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (e) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (f) carry out environmental or ecological mitigation or enhancement works. 2. A restrictive covenant over the land for the benefit of the remainder of the Order land to: (a) prevent anything to be done in or upon the Order land or any part thereof for the purpose of the erection of any buildings or construction erection or works of any kind (including the foundations or footings thereto); (b) prevent anything to be done by way of hard surfacing of the Order land with concrete of any kind or with any other material or surface whatsoever without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed surfacing would not cause damage to relevant part of the authorised project nor make it materially more difficult or expensive to maintain the authorised project); (c) prevent anything to be done by way of excavation of any kind of the Order land nor any activities which increase or decrease ground cover or soil levels in any manner whatsoever without the consent in writing of the undertaker save as are reasonably required for agricultural activities; (d) prevent the planting or growing within the Order land any trees, shrubs or underwood without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed trees, shrubs or underwood would not cause damage to the relevant part of the authorised project nor make it materially more difficult or expensive to access the relevant part of the authorised project).
11 14-18 29-40 42 44 46 47 50 64	1. The right to enter and remain upon the land for the purposes of construction, installation, operation, maintenance and decommissioning of the authorised project and to: (a) lay down, install, adjust, alter, construct, test, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, jointing bays, earthing measures, cathodic protection, cross bonding pits, manhole covers and other apparatus, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) enter and be upon the land and remain with or without plant, vehicles, machinery, apparatus and equipment which is ancillary to the purposes of transmitting electricity along the cables; (c) retain and use the cables for the purpose of the transmission of electricity; (d) pass and re-pass with or without vehicles plant and machinery for the purposes of surveying and for laying down, installing, adjusting, altering, constructing, using, maintaining, repairing, renewing, upgrading, inspecting, removing and replacing the cables; (e) place and to use plant, machinery, structures and temporary structures within the land for the installation, construction, maintenance, repairing, renewing, upgrading, inspecting, removal and replacing the cables; (f) erect, maintain and remove fencing for site safety and protection of the works consented under this order and create secure works compounds; (g) construct, lay down, use, maintain and remove temporary access roads including any necessary temporary bridging of statutory undertaker’s apparatus, other apparatus, conduits, water courses and drains; (h) effect access to the highway; (i) install, maintain, replace, renew and remove cable marker posts to identify the location of the cables (subject to an obligation to minimise interference with future use and operations within the land); (j) fell, lop or cut or coppice trees or remove roots of trees or hedges or shrubs; (k) install, maintain, use, improve, repair, replace, extend, inspect, adjust, alter, renew, test or cleanse and remove temporary or permanent drainage and manage water flows in existing drains, watercourses and culverts; (l) install, alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (m) install, maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (n) remove fences, hedges, or other barriers within the land during any period during which construction, maintenance, repair upgrading, improvement or renewal of the cables are being carried out, or for the exercise of the power to access the cables, (subject to the prior erection of any temporary stock proof fencing as is reasonably required and the replacement or re-instatement of the original fences, hedges, or other barriers following the exercise of the rights); (o) store and stockpile materials (including excavated material) within the Order land; (p) use or resort to horizontal directional drilling for the installation, renewal, repair, upgrading, or replacement of the cables; (q) lay out temporary paths for public use; (r) erect temporary signage and measures to effect public safety; (s) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (t) carry out environmental or ecological mitigation or enhancement works. 2. A restrictive covenant over the land for the benefit of the remainder of the Order land to: (a) prevent anything to be done in or upon the Order land or any part thereof for the purpose of the erection of any buildings or construction erection or works of any kind (including the foundations or footings thereto); (b)prevent anything to be done by way of hard surfacing of the Order land with concrete of any kind or with any other material or surface whatsoever without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed surfacing would not cause damage to relevant part of the authorised project nor make it materially more difficult or expensive to maintain the authorised project); (c) prevent anything to be done by way of excavation of any kind of the Order land nor any activities which increase or decrease ground cover or soil levels in any manner whatsoever without the consent in writing of the undertaker save as are reasonably required for agricultural activities; (d) prevent the planting or growing within the Order land any trees, shrubs or underwood without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed trees, shrubs or underwood would not cause damage to the relevant part of the authorised project nor make it materially more difficult or expensive to access the relevant part of the authorised project).
12	1. The right to enter and remain upon the land for the purposes of construction, installation, operation, maintenance and decommissioning of the authorised project and to: (a) lay down, install, adjust, alter, construct, test, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, jointing bays, earthing measures, cathodic protection, cross bonding pits, manhole covers and other apparatus, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) enter and be upon the land and remain with or without plant, vehicles, machinery, apparatus and equipment which is ancillary to the purposes of transmitting electricity along the cables; (c) retain and use the cables for the purpose of the transmission of electricity; (d) lay down, install, adjust, alter, construct, use, maintain, repair, renew, upgrade, inspect, remove and replace underground transition jointing bays and associated pits for the connection of offshore cables to onshore cables; (e) pass and re-pass with or without vehicles plant and machinery for the purposes of surveying and for laying down, installing, adjusting, altering, constructing, using, maintaining, repairing, renewing, upgrading, inspecting, removing and replacing the cables; (f) place and to use plant, machinery, structures and temporary structures within the land for the installation, construction, maintenance, repairing, renewing, upgrading, inspecting, removal and replacing the cables; (g) erect, maintain and remove fencing for site safety and protection of the works consented under this order and create secure works compounds; (h) construct, lay down, use, maintain and remove temporary access roads including any necessary temporary bridging of statutory undertaker’s apparatus, other apparatus, conduits, water courses and drains; (i) install, maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (j) effect access to the highway; (k) install, maintain, replace, renew and remove cable marker posts to identify the location of the cables (subject to an obligation to minimise interference with future use and operations within the land); (l) fell, lop or cut or coppice trees or remove roots of trees or hedges or shrubs; (m) install, maintain, use, improve, repair, replace, extend, inspect, adjust, alter, renew, test or cleanse and remove temporary or permanent drainage and manage water flows in existing drains, watercourses and culverts; (n) install, alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (o) remove fences, hedges, or other barriers within the land during any period during which construction, maintenance, repair upgrading, improvement or renewal of the cables are being carried out, or for the exercise of the power to access the cables, (subject to the prior erection of any temporary stock proof fencing as is reasonably required and the replacement or re-instatement of the original fences, hedges, or other barriers following the exercise of the rights); (p) store and stockpile materials (including excavated material) within the Order land; (q) use or resort to horizontal directional drilling for the installation, renewal, repair, upgrading, or replacement of the cables; (r) lay out temporary paths for public use; (s) erect temporary signage and measures to effect public safety; (t) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (u) carry out environmental or ecological mitigation or enhancement works. 2. A restrictive covenant over the land for the benefit of the remainder of the Order land to: (a) prevent anything to be done in or upon the Order land or any part thereof for the purpose of the erection of any buildings or construction erection or works of any kind (including the foundations or footings thereto); (b) prevent anything to be done by way of hard surfacing of the Order land with concrete of any kind or with any other material or surface whatsoever without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed surfacing would not cause damage to relevant part of the authorised project nor make it materially more difficult or expensive to maintain the authorised project); (c) prevent anything to be done by way of excavation of any kind of the Order land nor any activities which increase or decrease ground cover or soil levels in any manner whatsoever without the consent in writing of the undertaker save as are reasonably required for agricultural activities; (d) prevent the planting or growing within the Order land any trees, shrubs or underwood without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed trees, shrubs or underwood would not cause damage to the relevant part of the authorised project nor make it materially more difficult or expensive to access the relevant part of the authorised project).
43 59	1. The right to enter and remain upon the land for the purposes of construction, installation, operation, maintenance and decommissioning of the authorised project and to: (a) lay down, install, adjust, alter, construct, test, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, earthing measures, cathodic protection, manhole covers and other apparatus, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) enter and be upon the land and remain with or without plant, vehicles, machinery, apparatus and equipment which is ancillary to the purposes of transmitting electricity along the cables; (c) retain and use the cables for the purpose of the transmission of electricity; (d) pass and re-pass with or without vehicles plant and machinery for the purposes of surveying and for laying down, installing, adjusting, altering, constructing, using, maintaining, repairing, renewing, upgrading, inspecting, removing and replacing the cables; (e) place and to use plant, machinery, structures and temporary structures within the land for the installation, construction, maintenance, repairing, renewing, upgrading, inspecting, removal and replacing the cables; (f) erect, maintain and remove fencing for site safety and protection of the works consented under this order and create secure works compounds; (g) construct, lay down, use, maintain and remove temporary access roads including any necessary temporary bridging of statutory undertaker’s apparatus, other apparatus, conduits, water courses and drains; (h) effect access to the highway; (i) fell, lop or cut or coppice trees or remove roots of trees or hedges or shrubs; (j) install, maintain, use, improve, repair, replace, extend, inspect, adjust, alter, renew, test or cleanse and remove temporary or permanent drainage and manage water flows in existing drains, watercourses and culverts; (k) install, alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (l) install, maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (m) remove fences, hedges, or other barriers within the land during any period during which construction, maintenance, repair upgrading, improvement or renewal of the cables are being carried out, or for the exercise of the power to access the cables, (subject to the prior erection of any temporary stock proof fencing as is reasonably required and the replacement or re-instatement of the original fences, hedges, or other barriers following the exercise of the rights); (n) use or resort to horizontal directional drilling for the installation, renewal, repair, upgrading, or replacement of the cables; (o) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (p) carry out environmental or ecological mitigation or enhancement works.
60 63	1. The right to enter and remain upon the land for the purposes of construction, installation, operation, maintenance and decommissioning of the authorised project and to: (a) lay down, install, adjust, alter, construct, test, use, maintain, repair, renew, upgrade, inspect, remove and replace underground electricity cables together with such telemetry and fibre optic lines, ducting, jointing bays, earthing measures, cathodic protection, cross bonding pits, manhole covers and other apparatus, protection measures, safety measures and other equipment which is ancillary to the purposes of transmitting electricity along such electricity cables (which collectively shall be referred as the “cables”); (b) enter and be upon the land and remain with or without plant, vehicles, machinery, apparatus and equipment which is ancillary to the purposes of transmitting electricity along the cables; (c) retain and use the cables for the purpose of the transmission of electricity; (d) pass and re-pass with or without vehicles plant and machinery for the purposes of surveying and for laying down, installing, adjusting, altering, constructing, using, maintaining, repairing, renewing, upgrading, inspecting, removing and replacing the cables; (e) place and to use plant, machinery, structures and temporary structures within the land for the installation, construction, maintenance, repairing, renewing, upgrading, inspecting, removal and replacing the cables; (f) erect, maintain and remove fencing for site safety and protection of the works consented under this order and create secure works compounds; (g) construct, lay down, use, maintain and remove temporary access roads including any necessary temporary bridging of water courses and drains; (h) construct, lay down, use, and maintain a permanent access road including any necessary bridging of water courses and drains (i) effect access to the highway; (j) install, maintain, use, improve, repair, replace, extend, inspect, adjust, alter, renew, test or cleanse and remove temporary or permanent drainage and manage water flows in existing drains, watercourses and culverts; (k) install, alter, re-lay, maintain, protect, adjust or remove pipes, cables or conduits or apparatus (including the pipes, cables or conduits or apparatus of statutory undertakers); (l) install, maintain, use, improve, repair, replace and remove conduits, service media and associated apparatus for electricity, gas and telecommunications as well as conduits, service media and apparatus for the purposes of water supply and drainage; (m) install, maintain, replace, renew and remove cable marker posts to identify the location of the cables (subject to an obligation to minimise interference with future use and operations within the land); (n) remove fences, hedges, or other barriers within the land during any period during which construction, maintenance, repair upgrading, improvement or renewal of the cables are being carried out, or for the exercise of the power to access the cables, (subject to the prior erection of any temporary stock proof fencing as is reasonably required and the replacement or re-instatement of the original fences, hedges, or other barriers following the exercise of the rights) (o) store and stockpile materials (including excavated material) within the Order land; (p) use or resort to horizontal directional drilling for the installation, renewal, repair, upgrading, or replacement of the cables; (q) lay out temporary paths for public use; (r) erect temporary signage and measures to effect public safety; (s) enter for the purposes of ecological and for environmental surveys and for the erection, maintenance and removal of noise alleviation measures as well as barriers for the protection of fauna; and (t) carry out environmental or ecological mitigation or enhancement works. 2. A restrictive covenant over the land for the benefit of the remainder of the Order land to: (a) prevent anything to be done in or upon the Order land or any part thereof for the purpose of the erection of any buildings or construction erection or works of any kind (including the foundations or footings thereto); (b) prevent anything to be done by way of hard surfacing of the Order land with concrete of any kind or with any other material or surface whatsoever without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed surfacing would not cause damage to relevant part of the authorised project nor make it materially more difficult or expensive to maintain the authorised project); (c) prevent anything to be done by way of excavation of any kind of the Order land nor any activities which increase or decrease ground cover or soil levels in any manner whatsoever without the consent in writing of the undertaker save as are reasonably required for agricultural activities; (d) prevent the planting or growing within the Order land any trees, shrubs or underwood without the consent in writing of the undertaker (such consent not to be unreasonably withheld or delayed if the proposed trees, shrubs or underwood would not cause damage to the relevant part of the authorised project nor make it materially more difficult or expensive to access the relevant part of the authorised project).

Article 21(4)

SCHEDULE 7 E+W MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS

Compensation enactments E+W

1.  The enactments for the time being in force with respect to compensation for the compulsory purchase of land shall apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right or the imposition of a restrictive covenant as they apply as respects compensation on the compulsory purchase of land and interests in land.

Commencement Information

I51 Sch. 7 para. 1 in force at 28.11.2014, see art. 1

2.—(1) Without prejudice to the generality of paragraph 1, the Land Compensation Act 1973(2) shall have effect subject to the modifications set out in sub-paragraphs (2) and (3). E+W

(2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 of the 1965 Act as substituted by paragraph 4—

(a) for the words “land is acquired or taken” there shall be substituted the words “a right or restrictive covenant over land is purchased from or imposed on”; and

(b) for the words “acquired or taken from him” there shall be substituted the words “over which the right is exercisable or the restrictive covenant enforceable”.

(3) In section 58(1) (determination of material detriment where part of house etc. proposed for compulsory acquisition), as it applies to determinations under section 8 of the 1965 Act as substituted by paragraph 5—

(a) for the word “part” in paragraphs (a) and (b) there shall be substituted the words “a right over or restrictive covenant affecting land consisting”;

(b) for the word “severance” there shall be substituted the words “right or restrictive covenant over or affecting the whole of the house, building or manufactory or of the house and the park or garden”;

(c) for the words “part proposed” there shall be substituted the words “right or restrictive covenant proposed”; and

(d) for the words “part is” there shall be substituted the words “right or restrictive covenant is”.

Commencement Information

I52 Sch. 7 para. 2 in force at 28.11.2014, see art. 1

Application of the 1965 Act E+W

3.—(1) The 1965 Act shall have effect with the modifications necessary to make it apply to the compulsory acquisition under this Order of a right by the creation of a new right, or to the imposition under this Order of a restrictive covenant, as it applies to the compulsory acquisition under this Order of land, so that, in appropriate contexts, references in that Act to land are read (according to the requirements of the particular context) as referring to, or as including references to—

(a) the right acquired or to be acquired; or

(b) the land over which the right is or is to be exercisable.

(2) Without prejudice to the generality of sub-paragraph (1), Part 1 of the 1965 Act shall apply in relation to the compulsory acquisition under this Order of a right by the creation of a new right with the modifications specified in the following provisions of this Schedule.

Commencement Information

I53 Sch. 7 para. 3 in force at 28.11.2014, see art. 1

4.  For section 7 of the 1965 Act (measure of compensation) there shall be substituted the following section— E+W

“7.   In assessing the compensation to be paid by the acquiring authority under this Act, regard shall be had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.”.

Commencement Information

I54 Sch. 7 para. 4 in force at 28.11.2014, see art. 1

5.  For section 8 of the 1965 Act (provisions as to divided land) there shall be substituted the following section— E+W

“8.— (1) Where in consequence of the service on a person under section 5 of this Act of a notice to treat in respect of a right over land consisting of a house, building or manufactory or of a park or garden belonging to a house (“the relevant land”)—

(a) a question of disputed compensation in respect of the purchase of the right or the imposition of the restrictive covenant would apart from this section fall to be determined by the Upper Tribunal (“the tribunal”); and

(b) before the tribunal has determined that question the tribunal is satisfied that the person has an interest in the whole of the relevant land and is able and willing to sell that land and—

(i) where that land consists of a house, building or manufactory, that the right cannot be purchased or the restrictive covenant imposed without material detriment to that land; or

(ii) where that land consists of such a park or garden, that the right cannot be purchased or the restrictive covenant imposed without seriously affecting the amenity or convenience of the house to which that land belongs,

the Walney Extension Offshore Wind Farm Order 2014 (“the Order”) shall, in relation to that person, cease to authorise the purchase of the right and be deemed to authorise the purchase of that person’s interest in the whole of the relevant land including, where the land consists of such a park or garden, the house to which it belongs, and the notice shall be deemed to have been served in respect of that interest on such date as the tribunal directs.

(2) Any question as to the extent of the land in which the Order is deemed to authorise the purchase of an interest by virtue of subsection (1) of this section shall be determined by the tribunal.

(3) Where in consequence of a determination of the tribunal that it is satisfied as mentioned in subsection (1) of this section the Order is deemed by virtue of that subsection to authorise the purchase of an interest in land, the acquiring authority may, at any time within the period of 6 weeks beginning with the date of the determination, withdraw the notice to treat in consequence of which the determination was made; but nothing in this subsection prejudices any other power of the authority to withdraw the notice.”.

Commencement Information

I55 Sch. 7 para. 5 in force at 28.11.2014, see art. 1

6.  The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say— E+W

(a) section 9(4) (failure by owners to convey);

(b) paragraph 10(3) of Schedule 1 (owners under incapacity);

(c) paragraph 2(3) of Schedule 2 (absent and untraced owners); and

(d) paragraphs 2(3) and 7(2) of Schedule 4 (common land);

shall be so modified as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.

Commencement Information

I56 Sch. 7 para. 6 in force at 28.11.2014, see art. 1

7.  Section 11 of the 1965 Act (powers of entry) shall be so modified as to secure that, as from the date on which the acquiring authority has served notice to treat in respect of any right it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant (which shall be deemed for this purpose to have been created on the date of service of the notice); and sections 12 (penalty for unauthorised entry) and 13 (entry on warrant in the event of obstruction) of the 1965 Act shall be modified correspondingly. E+W

Commencement Information

I57 Sch. 7 para. 7 in force at 28.11.2014, see art. 1

8.  Section 20 of the 1965 Act (protection for interests of tenants at will, etc.) shall apply with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order of that land, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question. E+W

Commencement Information

I58 Sch. 7 para. 8 in force at 28.11.2014, see art. 1

9.  Section 22 of the 1965 Act (protection of acquiring authority’s possession where by inadvertence an estate, right or interest has not been got in) shall be so modified as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right acquired, subject to compliance with that section as respects compensation. E+W

Commencement Information

I59 Sch. 7 para. 9 in force at 28.11.2014, see art. 1

Article 27

SCHEDULE 8 E+W LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN

Commencement Information

I60 Sch. 8 in force at 28.11.2014, see art. 1

(1) Area	(2) Number of land shown on land plans	(3) Purpose for which temporary possession may be taken	(4) Relevant part of the authorised project
In the County of Lancashire, District of City of Lancaster	1, 11, 12, 14-18, 29-42, 44, 46, 47, 50, 60, 63-64	(a) the construction and the carrying out of the authorised project; (b) construction working site for construction and the carrying out of the authorised project; (c) the laying of temporary haul roads and improvements to tracks; (d) access for construction and the carrying out of the authorised project	Work No: 3B, 6, 8, 12, 13, 14, 15, 18, 23, 26 and 27
In the County of Lancashire, District of City of Lancaster	43, 59	(a) the construction and the carrying out of the authorised project; (b) modifications to roads; (c) access for construction and the carrying out of the authorised project	Work No: 14 and 22
In the County of Lancashire, District of City of Lancaster	2, 6-10	(a) the construction and the carrying out of the authorised project	Work No: 3B
In the County of Lancashire, District of City of Lancaster	13, 21, 45, 48, 49, 51, 56, 58, 62	(a) construction working site for construction and the carrying out of the authorised project; (b) the laying of temporary haul roads and improvements to tracks; (c) access for the carrying out of the authorised project;	Work No: 7, 9, 11, 15, 16, 17, 18 and 24
In the County of Lancashire, District of City of Lancaster	3, 4, 19, 20, 24, 26-28, 52-54	(a) the laying of temporary haul roads and improvements to tracks; (b) access for the carrying out of the authorised project	Work No: 4, 5, 9, 10, 20 and 21
In the County of Lancashire, District of City of Lancaster	5, 22, 23, 25, 55, 57	(a) modifications to roads; (b) access for the carrying out of the authorised project	Work No: 9, 10, 19 and 21

Article 37

SCHEDULE 9 E+W DEEMED GENERATOR ASSETS MARINE LICENCE UNDER THE MARINE AND COASTAL ACCESS ACT 2009

PART 1 E+W Licensed Marine Activities

Interpretation E+W

1.—(1) In this licence—

“the 2004 Act” means the Energy Act 2004;

“the 2008 Act” means the Planning Act 2008;

“the 2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works described in paragraph 2(2) of Part 1 of this licence;

“Annex I Habitat” means any benthic habitat type listed in Annex 1 of the EU Council Directive 92/43/EEC on the Conservation of Natural Habitats and of Wild Fauna and Flora(3);

“authorised deposits” means the substances and articles specified in paragraph 2(4) of Part 1 of this licence;

“authorised development” means the works described in paragraph 2(2) of Part 1 of this licence or any part of those works;

“cable crossings” means the crossing of existing subsea cables by the inter-array and/or export cables authorised by the Order together with cable protection;

“cable ducts” means conduits for the installation of cables;

“cable protection” means physical measures for the protection of cables including concrete mattresses, with or without frond devices, and/or rock placement;

“cables” shall include direct lay cables and/or cables laid in cable ducts and shall include fibre optic cables either within the cable or laid alongside;

“cable systems” means the three electrical cables and their respective accessories including cable joints and terminations, with an operating voltage of up to 400kV, necessary to transmit the power between two electrical nodes within the authorised development, and for the offshore element of the cable corridor, comprising subsea export cables, the three cables shall be bundled together as one cable system, and for the onshore element of the cable corridor, the cable system shall comprise three separate onshore cables, each containing a single conductor, and the cable system may also include one or more auxiliary cables (normally fibre optic cables) for the purpose of control, monitoring, protection or general communications;

“Cefas” means the Centre for Environment, Fisheries and Aquaculture Science;

“commence” means the first carrying out of any part of the licensed activities, save for pre-construction surveys and/or monitoring and the words “commencement” and “commenced” shall be construed accordingly;

“debris” means any material left on the seabed as a result of the licensed works;

“Disposal Site” means the designated disposal site identified as IS215 Walney bounded by the Order limits described in paragraph 2(3) of Part 1 of this licence, which are shown on the Order limits and grid coordinates plan;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of the 2009 Act;

“the environmental statement” means the document certified as the environmental statement by the Secretary of State for the purposes of the Order and submitted with the application on 28th June 2013 together with any supplementary or further environmental information submitted to the Examining authority as part of the examination of the application for the Order;

“frond devices” means flow energy dissipation devices, which reduce current velocity and turbulence and encourage settlement of sediment;

“Greenwich Mean Time” or “GMT” means the time measured from the Greenwich Meridian Line at the Royal Observatory in Greenwich;

“Hydrographic Office” means the United Kingdom Hydrographic Office of Admiralty Way, Taunton, Somerset, TA1 2DN;

“inter-array cable” means the network of offshore subsea cables connecting the WTGs in Work No. 1 with the offshore substations in Work No. 2(a);

“jacket structure” means a lattice type structure constructed of steel, which may include scour protection and additional equipment such as, J-tubes, corrosion protection systems and access platforms;

“JNCC” means the Joint Nature Conservation Committee;

“the Kingfisher Fortnightly Bulletin” means the bulletin produced by Kingfisher Information Services at the Sea Fish Industry Authority or such other alternative publication approved by the MMO;

“LAT” means lowest astronomical tide;

“the licence conditions” means the conditions set out in Part 2 of this licence;

“licensed activities” means the activities below MHWS specified in Part 1 of this licence;

“maintain” includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development, and any derivative of “maintain” shall be construed accordingly;

“major storm event” means a greater than 1 in 10 year wave event within the Order limits seaward of MHWS, measured by reference to the height of waves recorded at the nearest wave buoy to the authorised development as agreed with the MMO, and the WaveNet data published by Cefas, or such other means of measurement as may be agreed with the MMO;

“the Marine Management Organisation” or “MMO” means the body created under the 2009 Act which is responsible for the monitoring and enforcement of this licence;

“the Maritime and Coastguard Agency” or “MCA” means the executive agency of the Department for Transport;

“mean high water springs” or “MHWS” means the highest level which spring tides reach on average over a period of time;

“mean low water” or “MLW” means the average height of all low water above Chart Datum;

“monopile foundation” means a steel cylindrical pile, driven, vibrated and/or drilled into the seabed and may include scour protection and additional equipment such as, J-tubes, corrosion protection systems and access platforms;

“Natural England” means the body established by section 1 of the Natural Environment and Rural Communities Act 2006;

“notice to mariners” includes any notice to mariners which may be issued by the undertaker, Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore substation platform” means a platform with one or more decks, whether open or fully clad, accommodating medium to high voltage electrical power transformers, medium and/or high voltage switch gear, fire fighting facilities, workshop facilities, helicopter landing facilities, potable water storage, black water separation equipment, instrumentation, metering equipment, control systems, standby electrical generation equipment, auxiliary and uninterruptible power supply systems, emergency accommodation including mess facilities, control hub, drainage facilities, access equipment, marking and lighting and other associated equipment and facilities;

“the Order” means the Walney Extension Offshore Wind Farm Order 2014;

“the Order limits” means the limits shown on the Order limits and grid coordinates plan within which the authorised project may be carried out, whose grid coordinates seaward of MHWS are set out in paragraph 2(3) of Part 1 of this licence;

“the Order limits and grid coordinates plan” means the plan certified as the Order limits and grid coordinates plan by the Secretary of State for the purposes of the Order;

“relevant planning authority” means Lancaster City Council;

“Renewable Energy Zone” means the areas of the sea designated under the Renewable Energy Zone (Designation of Area) Order 2004;

“Schedule of Offshore Maintenance Activities” means the document certified as the Schedule of Offshore Maintenance Activities by the Secretary of State for the purposes of the Order;

“scour protection” means measures to prevent loss of seabed sediment around any structure placed in or on the seabed by use of protective aprons, mattresses with or without frond devices, or rock and gravel placement;

“suction caisson” means a steel cylindrical structure attached to the leg(s) of a jacket structure which partially or fully penetrates the seabed and remains in place using its own weight and hydrostatic pressure differential, and may include scour protection and additional equipment such as J-Tubes;

“transition piece” means the metal structure attached to the top of the foundation where the base of the wind turbine generator is connected and may include additional equipment such as J-Tubes, corrosion protection systems, boat access systems, access platform(s), craneage, and associated equipment;

“Trinity House” means the Corporation of Trinity House of Deptford Strond;

“undertaker” means in respect of any provision of this licence, DONG Energy Walney Extension (UK) Limited;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water and which is at the time in, on or over water;

“VHF” means very high frequency;

“wind turbine generator” or “wind turbine” or “WTG” means a structure comprising a tower, rotor system with three blades, nacelle and ancillary electrical and other equipment which may include lighting, J-tubes, access and rest platforms, access ladders, access lift, boat access systems, corrosion protection systems, fenders and maintenance equipment, heli-hoist platform and other associated equipment, fixed to a foundation or transition piece;

“Work No. 2(a)” means up to three offshore substation platforms fixed to the seabed within the Order limits seaward of MHWS by one of two foundation types, namely monopole foundation or jacket structure (in conjunction with suction caissons or steel piles); and

“the works plan” means the plans certified as the works plans by the Secretary of State for the purposes of the Order.

(2) References in this licence to any statute, order, regulation or similar instrument shall be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a) all times shall be taken to be Greenwich Mean Time; and

(b) all co-ordinates shall be taken to be latitude and longitude degrees, minutes and seconds.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence shall be—

Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle upon Tyne

NE4 7YH

Tel: [phone]

Email: [e-mail];

Marine Management Organisation – Whitehaven office

Fish Hall

North Harbour

North Shore

Whitehaven

Cumbria

CA28 7XY

Tel: [phone]

Email: [e-mail];

Trinity House

Tower Hill

London

EC3N 4DH

Tel: [phone];

The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset

TA1 2DN

Tel: [phone];

Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton

SO15 1EG

Tel: [phone];

Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk

NR33 0HT

Tel: [phone];

JNCC

Inverdee House

Baxter Street

Aberdeen

AB11 9QA;

Natural England

Foundry House

3 Millsands

Riverside Exchange

Sheffield

S3 8NH

Tel: [phone];

Natural England – North West Regional Office

Juniper House

Murley Moss

Oxenholme Road

Kendal

Cumbria

LA9 7RL

Tel: [phone].

Commencement Information

I61 Sch. 9 Pt. 1 para. 1 in force at 28.11.2014, see art. 1

Details of licensed marine activities E+W

2.—(1) Subject to the licence conditions, this licence authorises the undertaker (and any agent or contractor acting on their behalf) to carry out the following licensable marine activities under section 66(1) of the 2009 Act—

(a) the deposit at sea of the substances and articles specified in sub-paragraph (4) below;

(b) the construction of the works set out in sub-paragraph (2) below in or over the sea and/or on or under the sea bed; and

(c) the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation.

(2) Such activities are authorised in relation to the construction, maintenance and operation of—

Work No. 1 –

(a) an offshore wind turbine generating station with a gross electrical output capacity of up to 750MW comprising up to 207 wind turbine generators with rotating blades, each fixed to the seabed by one of two foundation types, namely monopile foundation or jacket structure (in conjunction with suction caissons or steel piles), and situated within the coordinates for the Order limits seaward of MHWS and further comprising (b) below;

(b) a network of subsea inter-array cables laid within the Order limits seaward of MHWS between the WTGs and Work No. 2(a), for the transmission of electricity and electronic communications between these different structures, including up to twenty cable crossings;

and in connection with such Work No. 1 and to the extent that they do not otherwise form part of any such Works, associated development within the meaning of section 115(2) of the 2008 Act comprising such other works as may be necessary or expedient for the purposes of or in connection with the relevant part of the authorised development and which fall within the scope of the work assessed by the environmental statement, including—

(c) scour protection around the foundations of the offshore structures;

(d) cable protection measures such as the placement of rock and/or concrete mattresses, with or without frond devices;

(e) the removal of material from the seabed required for the construction of Work No. 1 and the disposal of up to 600,300m³ of inert material of natural origin within the Disposal Site produced during construction drilling and seabed preparation for foundation works;

and in connection with Work No. 1 such ancillary works which fall within the scope of the work assessed by the environmental statement, including—

(f) creation of temporary landing places, moorings or other means of accommodating vessels in the construction and/or maintenance of the authorised development;

(g) buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) The grid coordinates for that part of the authorised development comprising Work No. 1 are specified below and more particularly on the Order limits and coordinates plan—

Point ID	Longitude (DMS)	Latitude (DMS)	Point ID	Longitude (DMS)	Latitude (DMS)
WGS 1984
69	3° 52′ 13.576″ W	54° 5′ 53.694″ N	70	3° 52′ 13.657″ W	54° 5′ 53.720″ N
71	3° 52′ 28.915″ W	54° 5′ 58.451″ N	72	3° 55′ 6.038″ W	54° 6′ 47.128″ N
73	3° 55′ 8.026″ W	54° 8′ 10.360″ N	74	3° 53′ 41.626″ W	54° 7′ 56.485″ N
75	3° 53′ 37.752″ W	54° 7′ 56.773″ N	76	3° 49′ 34.856″ W	54° 9′ 30.726″ N
77	3° 39′ 20.455″ W	54° 6′ 19.663″ N	78	3° 40′ 10.211″ W	54° 5′ 35.819″ N
79	3° 40′ 2.050″ W	54° 5′ 24.439″ N	80	3° 39′ 34.391″ W	54° 4′ 45.872″ N
81	3° 39′ 20.491″ W	54° 4′ 26.490″ N	82	3° 39′ 4.540″ W	54° 4′ 8.303″ N
83	3° 38′ 34.710″ W	54° 3′ 34.297″ N	84	3° 37′ 28.711″ W	54° 3′ 26.435″ N
85	3° 36′ 6.282″ W	54° 3′ 7.704″ N	86	3° 35′ 29.688″ W	54° 2′ 56.515″ N
87	3° 35′ 2.285″ W	54° 2′ 48.138″ N	88	3° 34′ 25.262″ W	54° 2′ 33.068″ N
89	3° 33′ 48.240″ W	54° 2′ 17.999″ N	90	3° 33′ 48.186″ W	54° 2′ 17.988″ N
91	3° 32′ 51.202″ W	54° 1′ 46.816″ N	92	3° 31′ 58.620″ W	54° 1′ 8.425″ N
93	3° 31′ 33.298″ W	54° 0′ 44.201″ N	94	3° 34′ 3.925″ W	54° 0′ 13.597″ N
95	3° 37′ 57.802″ W	54° 1′ 26.958″ N	96	3° 38′ 35.961″ W	54° 1′ 38.908″ N
97	3° 38′ 37.941″ W	54° 1′ 39.528″ N	98	3° 38′ 38.113″ W	54° 1′ 39.582″ N
99	3° 38′ 38.136″ W	54° 1′ 39.589″ N	100	3° 38′ 38.137″ W	54° 1′ 39.589″ N
216	3° 39′ 20.898″ W	54° 1′ 52.975″ N	217	3° 39′ 52.373″ W	54° 2′ 2.823″ N
218	3° 40′ 23.852″ W	54° 2′ 12.668″ N	219	3° 41′ 8.463″ W	54° 2′ 26.615″ N
220	3° 41′ 44.621″ W	54° 2′ 37.914″ N	221	3° 43′ 41.800″ W	54° 3′ 14.498″ N
222	3° 44′ 20.928″ W	54° 3′ 26.703″ N	223	3° 45′ 34.687″ W	54° 3′ 49.695″ N
224	3° 46′ 13.432″ W	54° 4′ 1.765″ N	225	3° 46′ 27.742″ W	54° 4′ 6.221″ N
226	3° 46′ 38.749″ W	54° 4′ 9.648″ N	227	3° 46′ 41.500″ W	54° 4′ 10.505″ N
228	3° 46′ 41.511″ W	54° 4′ 10.509″ N	229	3° 46′ 42.021″ W	54° 4′ 10.667″ N
230	3° 46′ 42.055″ W	54° 4′ 10.678″ N	231	3° 46′ 42.083″ W	54° 4′ 10.687″ N
232	3° 46′ 42.129″ W	54° 4′ 10.701″ N	233	3° 46′ 42.131″ W	54° 4′ 10.702″ N

(4) The substances or articles authorised for deposit at sea are—

(a) iron, steel, copper and aluminium;

(b) stone and rock;

(c) concrete;

(d) plastic/synthetic;

(e) material extracted from within the Order limits seaward of MHWS during construction drilling and/or seabed preparation for foundation works; and

(f) marine coatings, other chemicals and timber.

(5) The provisions of section 72 of the 2009 Act shall apply to this licence, save that the provisions of section 72(7) relating to the transfer of the licence shall only apply to a transfer not falling within article 5 of the Order.

Commencement Information

I62 Sch. 9 Pt. 1 para. 2 in force at 28.11.2014, see art. 1

Maintenance of authorised project E+W

3.—(1) The undertaker may at any time maintain the authorised development, except to the extent that an agreement made under this licence provides otherwise. No maintenance works whose likely effects on the environment are not assessed in the environmental statement shall take effect, unless otherwise approved by the MMO. The Schedule of Offshore Maintenance Activities identifies those offshore maintenance activities that have been assessed in the environmental statement.

(2) Where the MMO’s approval is required under sub-paragraph (1), such approval must only be given in relation to immaterial changes where it has been demonstrated to the satisfaction of the discharging authority that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I63 Sch. 9 Pt. 1 para. 3 in force at 28.11.2014, see art. 1

Duration E+W

4.  This licence shall remain in force until the authorised development has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the 2004 Act, including any modification to the programme under section 108, and the completion of such programme has been confirmed by the Secretary of State in writing.

Commencement Information

I64 Sch. 9 Pt. 1 para. 4 in force at 28.11.2014, see art. 1

PART 2 E+W Licence Conditions

Design parameters for wind turbines E+W

1.—(1) Subject to sub-paragraph (2), no wind turbine generator forming part of the authorised development shall—

(a) exceed a height of 222 metres when measured from MHWS to the highest point of the rotating blade of the WTG;

(b) exceed a height of 122 metres to the height of the centreline of the generator shaft forming part of the WTG nacelle when measured from MHWS;

(c) exceed a rotor diameter of 200 metres, or have a rotor diameter of less than 120 metres;

(d) be less than 737 metres from the nearest WTG in either direction perpendicular to the approximate prevailing wind direction (crosswind) or be less than 737 metres from the nearest WTG in either direction which is in line with the approximate prevailing wind direction (downwind); and

(e) have a distance of less than 22 metres between the lowest point of the rotating blade of the WTG and MHWS.

(2) References to the location of a wind turbine generator are references to the centre point of that turbine.

Commencement Information

I65 Sch. 9 Pt. 2 para. 1 in force at 28.11.2014, see art. 1

Design Parameters for WTG foundations E+W

2.—(1) The total number of monopole foundations forming part of the authorised development shall not exceed 207 and no monopile foundation for use with any WTG or offshore substation forming part of the authorised development shall have a diameter greater than 9 metres.

(2) No jacket structure for use with any WTG forming part of the authorised development shall have—

(a) a width spacing between each leg at the level of the seabed of more than 40 metres and at the level of LAT which is greater than 20 metres;

(b) more than four legs;

(c) a leg diameter of more than 3 metres;

(d) more than one pile per leg;

(e) a pile diameter of more than 3 metres;

(f) more than one suction caisson per leg; and

(g) a suction caisson diameter of greater than 10 metres.

Commencement Information

I66 Sch. 9 Pt. 2 para. 2 in force at 28.11.2014, see art. 1

Design parameters for inter-array cables E+W

3.  The total length of the cables comprising Work No. 1(b) shall not exceed 270 kilometres.

Commencement Information

I67 Sch. 9 Pt. 2 para. 3 in force at 28.11.2014, see art. 1

Design parameters for other deposits E+W

4.—(1) The total volume of scour protection for use with WTGs within Work No. 1 shall not exceed 2,277,000m³.

(2) The total volume of cable protection (excluding cable crossings) included within Work No. 1(b) shall not exceed 27,000m³ with a maximum footprint of 35,000m².

(3) The total volume of cable protection associated with cable crossings included within Work No. 1(b) shall not exceed 64,328m³. The total footprint of this cable protection shall not exceed 74,480m².

Commencement Information

I68 Sch. 9 Pt. 2 para. 4 in force at 28.11.2014, see art. 1

Notifications and inspections E+W

5.—(1) The undertaker must ensure that—

(a) a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i) all agents and contractors notified to the MMO in accordance with condition 6 of this licence; and

(ii) the masters and transport managers responsible for the vessels notified to the MMO in accordance with condition 6 of this licence;

(b) within 28 days of receipt of a copy of this licence those persons referred to at sub-paragraph (i) above must provide a completed confirmation form to the MMO confirming their understanding of the terms and conditions of this licence.

(2) Only those persons and vessels notified to the MMO in accordance with condition 6 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection by an enforcement officer at all reasonable times at the following locations—

(a) the undertaker’s registered address;

(b) any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits and works; and

(c) on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made or authorised works undertaken.

(4) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or the ancillary works or vessels to facilitate any inspection that the MMO or Trinity House considers necessary to meet any mandatory health and safety requirements or inspect the works during construction and operation of the authorised development.

(5) The undertaker must inform the MMO marine licensing team and the coastal MMO office specified in paragraph 1(4)(a) above, and the Hydrographic Office, the MCA, and Trinity House, in writing at least five working days prior to the commencement of the licensed activities or any part of them.

(6) The undertaker must publish in the Kingfisher Fortnightly Bulletin details of the vessel routes, timings and locations relating to the construction of the authorised development, or relevant part, at least five working days prior to the commencement of the licensed activities or any part of them.

(7) The undertaker must ensure that a notice to mariners is issued at least ten days prior to the commencement of Work No. 1 advising of the start date of those licensed activities and the expected vessel routes from the local service ports to the turbine locations.

(8) The undertaker must ensure that the notices to mariners are agreed with the MMO and the MCA in accordance with the construction programme approved under licence condition 11(1)(a). Such notices must be—

(a) updated and reissued at regular intervals; and

(b) supplemented with VHF radio broadcasts.

Copies of all notices must be provided to the MMO.

Commencement Information

I69 Sch. 9 Pt. 2 para. 5 in force at 28.11.2014, see art. 1

Reporting of engaged agents, contractors and vessels E+W

6.—(1) The undertaker must provide the following information to the MMO—

(a) the name and function of any agent or contractor appointed to engage in the licensed activities, at least five working days prior to the commencement of the licensed activities or any part of them; and

(b) each week during the construction of the authorised development a completed Hydrographic Note H102 listing the vessels to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO in writing at least five working days prior to the agent, contractor or vessel engaging in the licensed activities.

Commencement Information

I70 Sch. 9 Pt. 2 para. 6 in force at 28.11.2014, see art. 1

Equipment and operation of vessels engaged in licensed activities E+W

7.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of such activities in accordance with the conditions of this licence and must comply with sub-paragraphs (2) to (5) below.

(2) All motor powered vessels must be fitted with the following equipment—

(a) electronic positioning aid to provide navigational data;

(b) radar;

(c) echo sounder;

(d) multi-channel VHF, and

no vessel shall engage in the licensed activities until all such equipment is fully operational.

(3) All vessels’ names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All vessels must exhibit signals in accordance with the requirements of the International Regulations for the Prevention of Collisions at Sea.

(5) All communication on VHF working frequencies must be in English.

Commencement Information

I71 Sch. 9 Pt. 2 para. 7 in force at 28.11.2014, see art. 1

Chemicals, drilling and debris E+W

8.—(1) All chemicals used in the construction of the authorised development must be selected from the List of Notified Chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002(4), unless otherwise agreed by the MMO.

(2) All protective coatings and paints must be suitable for use in the marine environment. Details of such coatings and paints and how they will be used must be submitted to the MMO as part of the construction method statement required under condition 11(1)(c).

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110 per cent of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences.

(5) The undertaker must ensure that only inert material of natural origin, produced during construction drilling and seabed preparation for foundation works shall be disposed of within the Disposal Site.

(6) The undertaker must inform the MMO of the location and quantities of inert material disposed of each month under this licence, by submission of a disposal return by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(7) The undertaker must notify the MMO within 48 hours of the completion of the final disposal of inert material at the Disposal Site.

(8) The undertaker must ensure that any debris arising from the construction of the authorised development or temporary works placed below MHWS are removed on completion of the construction of the authorised development, unless otherwise agreed with the MMO.

(9) At least two months prior to the commencement of the licensed activities the undertaker must submit to the MMO a transportation audit sheet covering the construction of the authorised development. No works shall commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a) loading facilities;

(b) vessels;

(c) equipment;

(d) shipment routes;

(e) working schedules; and

(f) all components and materials to be used in the construction of the authorised development.

(10) The audit sheet must be maintained throughout the construction of the authorised development and any changes notified immediately in writing to the MMO. The audit sheet will be made available for inspection by the MMO within 12 hours of the undertaker’s receipt of a request made by the MMO.

(11) In the event that the MMO becomes aware that any of the materials on the audit sheet cannot be accounted for it shall require the undertaker in writing to carry out a side scan sonar survey to plot all obstructions across the relevant areas within the Order limits seaward of MHWS where construction works and related activities have been carried out. Local fishermen must be invited to send a representative to be present during the survey. Any new obstructions that the MMO reasonably concludes are associated with the authorised development must be removed, as directed by the MMO in writing, at the undertaker’s expense.

Commencement Information

I72 Sch. 9 Pt. 2 para. 8 in force at 28.11.2014, see art. 1

Force majeure E+W

9.  If, due to stress of weather or any other cause the master of a vessel determines that it is necessary to deposit the authorised substances and/or articles within or outside of the Order limits seaward of MHWS because the safety of human life and/or of the vessel is threatened full details of the circumstances of the deposit must be notified to the MMO within 48 hours, and the undertaker must—

(a) as soon as reasonably practicable following such notification, submit a method statement and programme for the removal of the deposit; and

(b) undertake the removal of the deposit in accordance with the approved method statement and programme, unless otherwise agreed with the MMO.

Commencement Information

I73 Sch. 9 Pt. 2 para. 9 in force at 28.11.2014, see art. 1

Seasonal restrictions in respect of fish spawning E+W

10.—(1) The undertaker must ensure that no percussive piling activity takes place during the cod spawning period from 15th February to 31st March (inclusive) of any year.

(2) The undertaker must ensure that no percussive piling activity takes place during the herring spawning period from 15th September to 15th November (inclusive) for any year, within such areas as agreed with the MMO prior to the commencement of construction. The undertaker must provide to the MMO the results of noise modelling prepared to an agreed methodology to inform the selection of such areas.

Commencement Information

I74 Sch. 9 Pt. 2 para. 10 in force at 28.11.2014, see art. 1

Pre-construction plans and documentation E+W

11.—(1) The licensed activities shall not commence until the following have been submitted to and approved by the MMO and, in relation to paragraphs (a) to (g), (j) and (k), following consultation with Natural England. Each programme, statement, plan, protocol, scheme or other detail required to be approved under this condition must be submitted to the MMO for approval at least four months prior to the commencement of works, except where otherwise stated or unless otherwise agreed by the MMO—

(a) a construction and monitoring programme to include details of—

(i) the proposed construction start date;

(ii) timings for mobilisation of plant, delivery of materials and installation works;

(iii) proposed pre-construction surveys/monitoring, baseline reporting format and content, construction surveys/monitoring, post-construction surveys/monitoring and related reporting in accordance with licence conditions 12 to 14;

(iv) a design plan at a scale of between 1:25,000 and 1:50,000, including detailed representation on the most suitable scaled Admiralty Chart, as agreed with the MMO, in consultation with Trinity House, the MCA and Natural England, which shows any archaeological exclusion zones identified under paragraph (h), and any exclusion zones and/or micrositing requirements identified in any mitigation scheme pursuant to paragraph (j); and

(v) proposed timings for the disposal of material produced during construction drilling and seabed preparation for foundation works;

(b) a plan to be agreed with the MMO in consultation with Trinity House and the MCA setting out proposed details of the authorised development, specifying the—

(i) number, specification(s) and dimensions of each WTG;

(ii) number, dimensions and foundation type(s) and depth for each WTG;

(iii) the grid coordinates of the centre point of the proposed location for each WTG;

(iv) proposed layout of all cables; and

(v) the proposed location(s) for the disposal of material produced during construction drilling and seabed preparation for foundation works;

(c) a construction method statement in accordance with the construction methods assessed in the environmental statement and including details of—

(i) foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii) turbine installation, including any seabed preparation and scour protection;

(iii) cable installation, including cable protection;

(iv) protective coatings and paints as required under condition 8(2);

(v) contractors;

(vi) vessels and vessel transit corridors;

(vii) ancillary works; and

(viii) drilling methods and disposal of material produced during construction drilling and seabed preparation for foundation works;

(d) a project environmental management and monitoring plan to include details of—

(i) a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised development in relation to all activities carried out below MHWS;

(ii) a chemical risk assessment to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii) a method statement for the taking of sediment samples;

(iv) waste management and disposal arrangements including a protocol covering potential finds of objects associated with the legacy of disposal at sea of material from the nuclear industry; and

(v) the appointment and responsibilities of a fisheries liaison officer and an environmental liaison officer;

(e) a scour protection management plan providing details of the need, type, sources, quantity and installation methods for scour protection;

(f) a marine mammal mitigation protocol, including a requirement for a soft start procedure, when driven or part-driven pile foundations are used;

(g) cable specification and installation plan in accordance with the methodology assessed in the environmental statement, to include—

(i) technical specification of cable systems, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice; and

(ii) a detailed cable laying plan for the Order limits seaward of MHWS, incorporating geotechnical data and a cable burial risk assessment to inform cable burial depths and cable laying techniques, including contingency measures, in the event cable burial is not achieved by the methods proposed in that plan;

(h) a written scheme of archaeological investigation in relation to the Order limits in accordance with industry good practice and developed in consultation with English Heritage to include—

(i) details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii) a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver or remotely operated vehicle investigations;

(iii) a programme for the analysis and reporting of survey data, and timing, which is to be submitted to the MMO within four months of the survey being completed, unless otherwise agreed with the MMO;

(iv) details of any mitigation including, where necessary, archaeological exclusion zones;

(v) details of monitoring during and post construction, including a conservation programme for finds and publication of reports, developed in consultation with English Heritage, associated with the consented development;

(vi) details of methods for archiving of archaeological material; and

(vii) a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised development;

(i) a written scheme, developed in consultation with the Ministry of Defence, detailing any potential survey and/or construction vessel transit through, or temporary presence within, the Eskmeals firing range (Danger Areas D406 and D406B) associated with the construction of the authorised development and a communications protocol between the undertaker and the Ministry of Defence’s range controllers relating thereto;

(j) a mitigation scheme for any Annex I Habitat identified by the survey referred to in condition 12(2)(a);

(k) an offshore operations and maintenance plan that must be submitted to the MMO at least four months prior to commencement of the operation of the licensed activities and include provision for the review and resubmission of that plan every three years during the operational phase. The offshore operations and maintenance plan must include details of—

(i) information on the presence of Annex I Habitat as identified in condition 12(2)(a);

(ii) information on, including likely schedule of, corrective and preventative maintenance activities proposed during the operation of the licensed activities, as identified in the environmental statement and Schedule of Offshore Maintenance Activities;

(iii) a summary of the environmental impact of the activities listed under sub-paragraph (ii), as identified in the environmental statement and Schedule of Offshore Maintenance Activities, and having regard to sub-paragraph (i); and

(iv) the anticipated maintenance activities that exceed the frequency and/or scope of licensable activities identified in the environmental statement and Schedule of Offshore Maintenance Activities, and the proposed approach to the licensing of these activities,

and each programme, statement, plan, protocol, scheme or other detail required to be approved under this condition must be submitted to the MMO for approval at least four months prior to the commencement of works, except where otherwise stated or unless otherwise agreed by the MMO.

(2) The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Monuments Record, in accordance with the Online AccesS to the Index of archaeological investigationS (OASIS) system.

(3) The licensed activities must be carried out in accordance with any programme, statement, plan, protocol, scheme or other details approved under this licence condition, unless otherwise agreed by the MMO.

Commencement Information

I75 Sch. 9 Pt. 2 para. 11 in force at 28.11.2014, see art. 1

Pre-construction surveying and monitoring E+W

12.—(1) The undertaker must, in discharging condition 11(1)(a) submit details for approval by the MMO in consultation with Natural England of proposed pre-construction surveys, including methodologies and timings, and a proposed format and content for a pre-construction baseline report at least 4 months prior to surveys commencing.

(2) The pre-construction surveys referred to in sub-paragraph (1) must unless otherwise agreed with the MMO have due regard to the need to undertake—

(a) surveys to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex I Habitat) inside the area(s) within the Order limits seaward of MHWS in which it is proposed to carry out construction works;

(b) a high resolution swath-bathymetry survey and side-scan sonar survey of the areas within the Order limits seaward of MHWS in which it is proposed to carry out construction works, including a 500 metre buffer area around the site of each work inclusive of seabed anomalies or sites of historic or archaeological interest that lie within that 500 metre buffer; and

(c) debris surveys, including a side scan sonar survey, across the area(s) within the Order limits seaward of MHWS in which it is proposed to carry out construction works.

(3) The undertaker must carry out the surveys agreed under sub-paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed by the MMO.

(4) The undertaker must not commence construction until the baseline report has been agreed by the MMO.

Commencement Information

I76 Sch. 9 Pt. 2 para. 12 in force at 28.11.2014, see art. 1

Construction monitoring E+W

13.—(1) The undertaker must, in discharging condition 11(1)(a), submit details for approval by the MMO in consultation with Natural England of any proposed surveys or monitoring, including methodologies and timings, to be carried out during the construction of the authorised development.

(2) A scheme for noise monitoring must be submitted for approval by the MMO prior to the commencement of any piling activity, which scheme must include details for measurements of noise generated at a minimum of four piling locations.

(3) The undertaker must carry out the surveys approved under sub-paragraph (1), including any further noise monitoring required in writing by the MMO, and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed with the MMO.

(4) The results of the initial noise measurements provided in accordance with sub-paragraph (3) must be provided to the MMO within six weeks of the installation of the first monitored pile approved pursuant to sub-paragraph (1), unless otherwise agreed with the MMO.

(5) Unless otherwise agreed with the undertaker, within 6 weeks of the submission of results of the initial noise measurements provided in accordance with sub-paragraph (3) the MMO must, having regard to those results, determine whether or not any further noise monitoring is required and confirm this to the undertaker.

Commencement Information

I77 Sch. 9 Pt. 2 para. 13 in force at 28.11.2014, see art. 1

Post construction monitoring E+W

14.—(1) The undertaker must, in discharging condition 11(1)(a), submit details for approval by the MMO in consultation with Natural England of proposed post-construction surveys, including methodologies and timings, and proposed format, content and timings for providing reports on the results. Subject to receipt of specific proposals, it is expected that acceptable post-construction surveys will comprise, in outline—

(a) surveys of any benthic communities/benthos constituting Annex I Habitat inside the area(s) within the Order limits seaward of MHWS in which construction works were carried out; and

(b) high resolution swath-bathymetric surveys of such representative areas within the Order limits seaward of MHWS as may be agreed with the MMO in which construction works were carried out to assess any changes to bed form morphology and such further monitoring as may be agreed to ensure that the cables have been buried.

(2) Following the completion of the authorised development, the undertaker must carry out the surveys referred to in sub-paragraph (1) for three years, which may be non-consecutive years, and provide reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed with the MMO following consultation with Natural England.

(3) If a major storm event occurs at any time between the completion of the authorised development and the completion of the third year of surveys required under sub-paragraph (2), the undertaker must carry out a side scan sonar and bathymetry survey within the Order limits seaward of MHWS in which the construction works were carried out, in accordance with such timetable as may be agreed with the MMO following consultation with Natural England.

Commencement Information

I78 Sch. 9 Pt. 2 para. 14 in force at 28.11.2014, see art. 1

Offshore Decommissioning E+W

15.  No part of the authorised development seaward of MHWS shall commence until a written decommissioning programme in compliance with any notice served upon the undertaker by the Secretary of State pursuant to section 105(2) of the 2004 Act has been submitted to the Secretary of State for approval. The undertaker must consult the MMO, Natural England and the relevant planning authority on the proposed decommissioning activity no less than four months prior to submission of the proposed decommissioning programme to the Secretary of State.

Commencement Information

I79 Sch. 9 Pt. 2 para. 15 in force at 28.11.2014, see art. 1

Offshore Safety Management E+W

16.—(1) No authorised development seaward of MHWS shall commence until the MMO, in consultation with the MCA, has given written approval of a plan for an active safety management system which includes an emergency response and co-operation plan (ERCoP) for the construction, operation and decommissioning phases of the authorised development in accordance with the MCA’s recommendations in MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

(2) No authorised development seaward of MHWS shall commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and adequately addressed all MCA recommendations as appropriate to the authorised development contained within the document MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” and its annexes.

(3) The active safety management system and ERCoP must be implemented as approved unless otherwise agreed by the MMO in consultation with the MCA.

Commencement Information

I80 Sch. 9 Pt. 2 para. 16 in force at 28.11.2014, see art. 1

Aids to navigation E+W

17.—(1) The undertaker must at or near the authorised development during the whole period of the construction, operation, alteration, replacement or decommissioning of the authorised development seaward of MHWS exhibit such lights, marks, sounds, signals and other aids to navigation, and to take such other steps for the prevention of danger to navigation, as Trinity House may from time to time direct.

(2) The undertaker must provide information to the Hydrographic Office on the position and nature of works to facilitate the issuing of notices and warnings to mariners.

(3) The undertaker must keep the Hydrographic Office, the MCA, Trinity House and the MMO informed of progress with the authorised development and will provide—

(a) notice of commencement within 24 hours of commencement having occurred;

(b) as soon as reasonably practicable notification of the provision of any aids to navigation required by the licence conditions;

(c) reports on the working condition of aids to navigation as requested by Trinity House;

(d) notice to Trinity House and the MMO of any failure of aids to navigation, and the plans for remedying such failures, as soon as practicable and within 24 hours of such failure being identified;

(e) notification of completion within 2 weeks of completion of the authorised development.

(4) The undertaker must paint yellow (colour code RAL 1023) all structures to be constructed as part of the authorised development seaward of MHWS from at least HAT to a height directed by Trinity House. Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

(5) The undertaker must exhibit such lights, with such shape, colour and character as are required by Air Navigation Order 2009, or as directed by the CAA, and must notify the CAA and the MMO of any failure of those lights and the timescales in which such failure will be remedied, as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

Commencement Information

I81 Sch. 9 Pt. 2 para. 17 in force at 28.11.2014, see art. 1

Provision against danger to navigation E+W

18.  In case of damage to, or destruction or decay of, the authorised development seaward of MHWS or any part thereof the undertaker must as soon as reasonably practicable notify Trinity House and must lay down such buoys, exhibit such lights and take such other steps for preventing danger to navigation as Trinity House may from time to time direct.

Commencement Information

I82 Sch. 9 Pt. 2 para. 18 in force at 28.11.2014, see art. 1

Requirement for written approval E+W

19.  With respect to any condition of this licence which requires the licensed activities to be carried out in accordance with any details approved by the MMO, notification of such approval must be given in writing.

Commencement Information

I83 Sch. 9 Pt. 2 para. 19 in force at 28.11.2014, see art. 1

Amendments to approved details E+W

20.—(1) With respect to any condition which requires the licensed activities to be carried out in accordance with the details approved by the MMO, the approved details shall be carried out as approved unless an amendment or variation is agreed in advance by the MMO pursuant to the relevant condition, in accordance with sub-paragraph (2), and in consultation with any body specified in the relevant condition.

(2) Where any condition specifies “unless otherwise agreed” by the MMO such agreement shall not be given except in relation to immaterial changes where it has been demonstrated to the satisfaction of the MMO that the agreement sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

(3) The approved details shall be taken to include any amendments that may subsequently be approved by the MMO.

Commencement Information

I84 Sch. 9 Pt. 2 para. 20 in force at 28.11.2014, see art. 1

Article 37

SCHEDULE 10 E+W DEEMED TRANSMISSION ASSETS MARINE LICENCE UNDER THE MARINE AND COASTAL ACCESS ACT 2009

PART 1 E+W Licensed Marine Activities

Interpretation E+W

1.—(1) In this licence—

“the 2004 Act” means the Energy Act 2004;

“the 2008 Act” means the Planning Act 2008;

“the 2009 Act” means the Marine and Coastal Access Act 2009;

“ancillary works” means the ancillary works authorised by paragraph 2(2) of Part 1 of this licence;

“Annex I Habitat” means any benthic habitat type listed in Annex 1 of the EU Council Directive 92/43/EEC on the Conservation of Natural Habitats and of Wild Fauna and Flora;

“authorised deposits” means the substances and articles specified in paragraph 2(4) of Part 1 of this licence;

“authorised development” means the works described in paragraph 2(2) of Part 1 of this licence or any part of those works;

“CAA” means the Civil Aviation Authority constituted by the Civil Aviation Act 1982;

“cable crossings” means the crossing of existing subsea cables by the inter-array and/or export cables authorised by the Order together with cable protection;

“cable ducts” means conduits for the installation of cables;

“cable protection” means physical measures for the protection of cables including concrete mattresses, with or without frond devices, and/or rock placement;

“cables” shall include direct lay cables and/or cables laid in cable ducts and shall include fibre optic cables either within the cable or laid alongside;

“cable systems” means the three electrical cables and their respective accessories including cable joints and terminations, with an operating voltage of up to 400kV, necessary to transmit the power between two electrical nodes within the authorised development, and for the offshore element of the cable corridor, comprising subsea export cables, the three cables shall be bundled together as one cable system, and for the onshore element of the cable corridor, the cable system shall comprise three separate onshore cables, each containing a single conductor, and the cable system may also include one or more auxiliary cables (normally fibre optic cables) for the purpose of control, monitoring, protection or general communications;

“Cefas” means the Centre for Environment, Fisheries and Aquaculture Science;

“commence” means the first carrying out of any part of the licensed activities, save for pre-construction surveys and/or monitoring and the words “commencement” and “commenced” shall be construed accordingly;

“debris” means any material left on the seabed as a result of the licensed works;

“Disposal Site” means the designated disposal site identified as IS215 Walney bounded by the Order limits within Point IDs 69 to 100 (inclusively) and Point IDs 216 to 233 (inclusively) described in the table that follows paragraph 2(4) of Part 1 of this licence, which are shown on the Order limits and grid coordinates plan;

“enforcement officer” means a person authorised to carry out enforcement duties under Chapter 3 of the 2009 Act;

“the environmental statement” means the document certified as the environmental statement by the Secretary of State for the purposes of the Order and submitted with the application on 28th June 2013 together with any supplementary or further environmental information submitted to the Examining authority as part of the examination of the application for the Order;

“frond devices” means flow energy dissipation devices, which reduce current velocity and turbulence and encourage settlement of sediment;

“Greenwich Mean Time” or means the time measured from the Greenwich Meridian Line at the Royal Observatory in Greenwich;

“High Tide” means the state of the tide when it reaches its highest level during a tidal cycle, as may be published from time to time on the United Kingdom Hydrograph Office Admiralty EasyTide Website, or such other publication as may be approved by the MMO;

“Hydrographic Office” means the United Kingdom Hydrographic Office of Admiralty Way, Taunton, Somerset, TA1 2DN;

“inter-array cable” means the network of offshore subsea cables connecting the WTGs in Work No. 1 with the offshore substations in Work No. 2(a);

“Inter-tidal Area” means the area of land between MLW and MHWS at Middleton Sands, Heysham;

“jacket structure” means a lattice type structure constructed of steel, which may include scour protection and additional equipment such as, J-tubes, corrosion protection systems and access platform(s);

“JNCC” means the Joint Nature Conservation Committee;

“the Kingfisher Fortnightly Bulletin” means the bulletin produced by Kingfisher Information Services at the Sea Fish Industry Authority or such other alternative publication approved by the MMO;

“LAT” means lowest astronomical tide;

“the licence conditions” means the conditions set out in Part 2 of this licence;

“licensed activities” means the activities below MHWS specified in Part 1 of this licence;

“maintain” includes inspect, repair, adjust, alter, remove, reconstruct and replace any of the authorised development and any derivative of “maintain” shall be construed accordingly;

“major storm event” means a greater than 1 in 10 year wave event within the Order limits seaward of MHWS, measured by reference to the height of waves recorded at the nearest wave buoy to the authorised development as agreed with the MMO, and the WaveNet data published by Cefas, or such other means of measurement as may be agreed with the MMO;

“the Marine Management Organisation” or “MMO” means the body created under the 2009 Act which is responsible for the monitoring and enforcement of this licence;

“the Maritime and Coastguard Agency” or “MCA” means the executive agency of the Department for Transport;

“mean high water springs” or “MHWS” means the highest level which spring tides reach on average over a period of time;

“mean low water” or “MLW” means the average height of all low water above Chart Datum;

“monopile foundation” means a steel cylindrical pile, driven, vibrated and/or drilled into the seabed and may include scour protection and additional equipment such as, J-tubes, corrosion protection systems and access platforms;

“Natural England” means the body established by section 1 of the Natural Environment and Rural Communities Act 2006;

“notice to mariners” includes any notice to mariners which may be issued by the undertaker, Admiralty, Trinity House, Queen’s harbourmasters, government departments and harbour and pilotage authorities;

“offshore substation platform” means a platform with one or more decks, whether open or fully clad, accommodating medium to high voltage electrical power transformers, medium and/or high voltage switch gear, fire fighting facilities, workshop facilities, helicopter landing facilities, potable water storage, black water separation equipment, instrumentation, metering equipment, control systems, standby electrical generation equipment, auxiliary and uninterruptible power supply systems, emergency accommodation including mess facilities, control hub, drainage facilities, access equipment, marking and lighting and other associated equipment and facilities;

“the Order” means the Walney Extension Offshore Wind Farm Order 2014;

“the Order limits” means the limits shown on the Order limits and grid coordinates plan within which the authorised project may be carried out, whose grid coordinates seaward of MHWS are set out in paragraph 2 of Part 1 of Schedule 1 (authorised project) of the Order;

“the Order limits and grid coordinates plan” means the plan certified as the Order limits and grid coordinates plan by the Secretary of State for the purposes of the Order;

“relevant planning authority” means Lancaster City Council or any successor to its statutory functions;

“Renewable Energy Zone” means the areas of the sea designated under the Renewable Energy Zone (Designation of Area) Order 2004;

“Schedule of Offshore Maintenance Activities” means the document certified as the Schedule of Offshore Maintenance Activities by the Secretary of State for the purposes of the Order;

“scour protection” means measures to prevent loss of seabed sediment around any structure placed in or on the seabed by use of protective aprons, mattresses with or without frond devices, or rock and gravel placement;

“suction caisson” means a steel cylindrical structure attached to the leg(s) of a jacket structure which partially or fully penetrates the seabed and remains in place using its own weight and hydrostatic pressure differential, and may include scour protection and additional equipment such as J-Tubes;

“transition piece” means the metal structure attached to the top of the foundation where the base of the wind turbine generator is connected and may include additional equipment such as J-Tubes, corrosion protection systems, boat access systems, access platform(s), craneage, and associated equipment;

“Trinity House” means the Corporation of Trinity House of Deptford Strond or any successor to its statutory functions;

“undertaker” means in respect of any provision of this licence, DONG Energy Walney Extension (UK) Limited;

“vessel” means every description of vessel, however propelled or moved, and includes a non-displacement craft, a personal watercraft, a seaplane on the surface of the water, a hydrofoil vessel, a hovercraft or any other amphibious vehicle and any other thing constructed or adapted for movement through, in, on or over water and which is at the time in, on or over water;

“VHF” means very high frequency;

“wind turbine generator” or “wind turbine” or “WTG” means a structure comprising a tower, rotor system with three blades, nacelle and ancillary electrical and other equipment which may include lighting, J-tube(s), access and rest platforms, access ladders, access lift, boat access systems, corrosion protection systems, fenders and maintenance equipment, heli-hoist platform and other associated equipment, fixed to a foundation or transition piece;

“Work No.” means that part of the authorised development with the corresponding number specified in paragraph 2(2) of Part 1 of this licence;

“Work No. 1”—

(a)

an offshore wind turbine generating station with a gross electrical output capacity of up to 750MW comprising up to 207 wind turbine generators with rotating blades, each fixed to the seabed by one of two foundation types, namely monopile foundation or jacket structure (in conjunction with suction caissons or steel piles), and situated within the coordinates for the Order limits seaward of MHWS and further comprising

(b)

a network of subsea inter-array cables laid within the Order limits seaward of MHWS between the WTGs and Work No. 2(a), for the transmission of electricity and electronic communications between these different structures, including up to twenty cable crossings; and

“the works plan” means the plans certified as the works plans by the Secretary of State for the purposes of the Order.

(2) References in this licence to any statute, order, regulation or similar instrument shall be construed as a reference to the statute, order, regulation or instrument as amended by any subsequent statute, order, regulation or instrument or as contained in any subsequent re-enactment.

(3) Unless otherwise indicated—

(a) all times shall be taken to be Greenwich Mean Time; and

(b) all co-ordinates shall be taken to be latitude and longitude degrees, minutes and seconds.

(4) Except where otherwise notified in writing by the relevant organisation, the primary point of contact with the organisations listed below and the address for returns and correspondence shall be—

Marine Management Organisation

Marine Licensing Team

Lancaster House

Hampshire Court

Newcastle upon Tyne

NE4 7YH

Tel: [phone]

Email: [e-mail];

Marine Management Organisation – Whitehaven office

Fish Hall

North Harbour

North Shore

Whitehaven

Cumbria

CA28 7XY

Tel: [phone]

Email: ;

Trinity House

Tower Hill

London

EC3N 4DH

Tel: [phone];

The United Kingdom Hydrographic Office

Admiralty Way

Taunton

Somerset

TA1 2DN

Tel: [phone];

Maritime and Coastguard Agency

Navigation Safety Branch

Bay 2/04

Spring Place

105 Commercial Road

Southampton

SO15 1EG

Tel: [phone];

Centre for Environment, Fisheries and Aquaculture Science

Pakefield Road

Lowestoft

Suffolk

NR33 0HT

Tel: [phone];

JNCC

Inverdee House

Baxter Street

Aberdeen

AB11 9QA;

Natural England

Foundry House

3 Millsands

Riverside Exchange

Sheffield

S3 8NH

Tel: [phone];

Natural England – North West Regional Office

Juniper House

Murley Moss

Oxenholme Road

Kendal

Cumbria

LA9 7RL

Tel: [phone].

Commencement Information

I85 Sch. 10 Pt. 1 para. 1 in force at 28.11.2014, see art. 1

Details of licensed marine activities E+W

2.—(1) Subject to the licence conditions, this licence authorises the undertaker (and any agent or contractor acting on their behalf) to carry out the following licensable marine activities under section 66(1) of the 2009 Act—

(a) the deposit at sea of the substances and articles specified in sub-paragraph (5) below;

(b) the construction of the works set out in sub-paragraph (2) below in or over the sea and/or on or under the sea bed; and

(c) the removal of sediment samples for the purposes of informing environmental monitoring under this licence during pre-construction, construction and operation.

(2) Such activities are authorised in relation to the construction, maintenance and operation of—

Work No. 2 –

(a) up to three offshore substation platforms fixed to the seabed within the Order limits seaward of MHWS by one of two foundation types, namely monopole foundation or jacket structure (in conjunction with suction caissons or steel piles), and further comprising (b) below;

(b) offshore connection works consisting of up to five export cable systems between Work No. 2(a) and Work No. 3A for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid along routes within the Order limits seaward of MHWS;

Work No. 3A – offshore connection works consisting of up to five export cable systems between Work No. 2 and Work No. 3B for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid along routes within the Order limits seaward of MHWS, including up to seventy cable crossings;

Work No. 3B – onshore connection works consisting of up to five export cable systems for the transmission of electricity and electronic communications each consisting of a single subsea cable and one cable duct laid underground, together with a new temporary access track and a new temporary horizontal directional drilling compound to the west of the saltmarsh, in the Inter-tidal Area;

and in connection with such Work Nos. 2 and 3A and 3B and to the extent that they do not otherwise form part of any such Works, associated development within the meaning of section 115(2) of the 2008 Act comprising such other works as may be necessary or expedient for the purposes of or in connection with the relevant part of the authorised development and which fall within the scope of the work assessed by the environmental statement, including—

(a) scour protection around the foundations of the offshore structures;

(b) cable protection measures such as the placement of rock and/or concrete mattresses, with or without frond devices;

(c) the removal of material from the seabed required for the construction of Work Nos. 2 and 3A and 3B and the disposal of up to 150,000m³ of inert material of natural origin within the Disposal Site produced during construction drilling and seabed preparation for foundation works

and in connection with Work Nos. 2 and 3A and 3B such ancillary works which fall within the scope of the work assessed by the environmental statement, including—

(d) creation of temporary landing places, moorings or other means of accommodating vessels in the construction and/or maintenance of the authorised development;

(e) buoys, beacons, fenders and other navigational warning or ship impact protection works.

(3) With the exception of the area described in sub-paragraph (4), the Order limits for that part of the authorised development which is seaward of MHWS including Work Nos. 2 and 3A and 3B are specified by grid coordinates in the table below and more particularly on the Order limits and grid coordinates plan.

(4) The excepted area referred to in sub-paragraph (3) is the area bounded by the grid coordinates referenced by Point IDs 205 to 248 (inclusive) specified in the table below, and does not form part of the Order limits.

Point ID	Longitude (DMS)	Latitude (DMS)	Point ID	Longitude (DMS)		Latitude (DMS)
WGS 1984
1	2° 53′ 33.318″ W	54° 0′ 21.420″ N	2	2° 53′ 50.369″ W	54° 0′ 16.174″ N
3	2° 54′ 45.902″ W	54° 0′ 14.698″ N	4	2° 55′ 17.251″ W	54° 0′ 13.861″ N
5	2° 55′ 22.300″ W	54° 0′ 13.726″ N	6	2° 56′ 22.346″ W	54° 0′ 12.116″ N
7	2° 56′ 23.311″ W	54° 0′ 10.132″ N	8	2° 57′ 26.162″ W	54° 0′ 7.954″ N
9	2° 57′ 57.264″ W	53° 59′ 51.821″ N	10	2° 58′ 29.297″ W	53° 59′ 35.200″ N
11	2° 58′ 32.508″ W	53° 59′ 31.262″ N	12	2° 59′ 30.192″ W	53° 58′ 59.300″ N
13	3° 0′ 18.112″ W	53° 58′ 29.037″ N	14	3° 1′ 5.141″ W	53° 58′ 9.023″ N
15	3° 1′ 5.593″ W	53° 58′ 9.261″ N	16	3° 2′ 3.897″ W	53° 57′ 44.946″ N
17	3° 2′ 59.503″ W	53° 57′ 18.713″ N	18	3° 3′0.453″ W	53° 57′ 18.477″ N
19	3° 3′ 13.251″ W	53° 57′ 12.731″ N	20	3° 3′16.700″ W	53° 57′ 14.441″ N
21	3° 3′ 18.769″ W	53° 57′ 13.927″ N	22	3° 5′ 43.813″ W	53° 56′ 27.606″ N
23	3° 5′ 54.544″ W	53° 56′ 24.869″ N	24	3° 6′ 42.395″ W	53° 56′ 12.659″ N
25	3° 7′ 8.784″ W	53° 56′ 6.470″ N	26	3° 8′13.711″ W	53° 55′ 44.826″ N
27	3° 8′ 13.737″ W	53° 55′ 45.023″ N	28	3° 9′ 13.690″ W	53° 55′ 23.693″ N
29	3° 9′ 48.444″ W	53° 55′ 9.265″ N	30	3° 10′ 37.024″ W	53° 54′ 48.620″ N
31	3° 10′ 49.239″ W	53° 54′ 42.972″ N	32	3° 12′ 22.668″ W	53° 53′ 59.742″ N
33	3° 12′ 23.270″ W	53° 54′ 0.247″ N	34	3° 12′ 49.670″ W	53° 54′ 2.654″ N
35	3° 12′ 52.456″ W	53° 54′ 2.687″ N	36	3° 17′ 6.270″ W	53° 54′ 28.567″ N
37	3° 26′ 26.669″ W	53° 55′ 25.214″ N	38	3° 26′ 37.660″ W	53° 55′ 26.317″ N
39	3° 27′ 3.079″ W	53° 55′ 28.867″ N	40	3° 27′ 18.555″ W	53° 55′ 30.418″ N
41	3° 29′ 50.937″ W	53° 55′ 45.664″ N	42	3° 30′ 3.624″ W	53° 55′ 43.059″ N
43	3° 30′ 30.452″ W	53° 55′ 54.247″ N	44	3° 30′ 29.997″ W	53° 55′ 54.544″ N
45	3° 34′ 7.698″ W	53° 57′ 35.322″ N	46	3° 34′ 7.209″ W	53° 57′ 35.365″ N
47	3° 37′ 35.577″ W	53° 59′ 11.544″ N	48	3° 37′ 34.781″ W	53° 59′ 11.548″ N
49	3° 41′ 30.681″ W	54° 1′ 0.522″ N	50	3° 41′ 29.995″ W	54° 1′ 0.584″ N
51	3° 44′ 18.958″ W	54° 2′ 18.969″ N	52	3° 44′ 18.798″ W	54° 2′ 19.017″ N
53	3° 47′ 22.145″ W	54° 3′ 41.872″ N	54	3° 47′ 27.048″ W	54° 3′ 41.853″ N
55	3° 50′ 7.591″ W	54° 4′ 20.464″ N	56	3° 50′ 30.606″ W	54° 4′ 27.329″ N
57	3° 52′ 35.173″ W	54° 5′ 4.454″ N	58	3° 52′ 35.893″ W	54° 5′ 27.530″ N
59	3° 52′ 30.274″ W	54° 5′ 34.138″ N	60	3° 52′ 18.993″ W	54° 5′ 47.403″ N
61	3° 52′ 14.971″ W	54° 5′ 52.133″ N	62	3° 52′ 14.528″ W	54° 5′ 52.628″ N
63	3° 52′ 13.616″ W	54° 5′ 53.649″ N	64	3° 52′ 13.582″ W	54° 5′ 53.687″ N
65	3° 52′ 13.580″ W	54° 5′ 53.689″ N	66	3° 52′ 13.579″ W	54° 5′ 53.690″ N
67	3° 52′ 13.577″ W	54° 5′ 53.693″ N	68	3° 52′ 13.576″ W	54° 5′ 53.693″ N
69	3° 52′ 13.576″ W	54° 5′ 53.694″ N	70	3° 52′ 13.657″ W	54° 5′ 53.720″ N
71	3° 52′ 28.915″ W	54° 5′ 58.451″ N	72	3° 55′ 6.038″ W	54° 6′ 47.128″ N
73	3° 55′ 8.026″ W	54° 8′ 10.360″ N	74	3° 53′ 41.626″ W	54° 7′ 56.485″ N
75	3° 53′ 37.752″ W	54° 7′ 56.773″ N	76	3° 49′ 34.856″ W	54° 9′ 30.726″ N
77	3° 39′ 20.455″ W	54° 6′ 19.663″ N	78	3° 40′ 10.211″ W	54° 5′ 35.819″ N
79	3° 40′ 2.050″ W	54° 5′ 24.439″ N	80	3° 39′ 34.391″ W	54° 4′ 45.872″ N
81	3° 39′ 20.491″ W	54° 4′ 26.490″ N	82	3° 39′ 4.540″ W	54° 4′ 8.303″ N
83	3° 38′ 34.710″ W	54° 3′ 34.297″ N	84	3° 37′ 28.711″ W	54° 3′ 26.435″ N
85	3° 36′ 6.282″ W	54° 3′ 7.704″ N	86	3° 35′ 29.688″ W	54° 2′ 56.515″ N
87	3° 35′ 2.285″ W	54° 2′ 48.138″ N	88	3° 34′ 25.262″ W	54° 2′ 33.068″ N
89	3° 33′ 48.240″ W	54° 2′ 17.999″ N	90	3° 33′ 48.186″ W	54° 2′ 17.988″ N
91	3° 32′ 51.202″ W	54° 1′ 46.816″ N	92	3° 31′ 58.620″ W	54° 1′ 8.425″ N
93	3° 31′ 33.298″ W	54° 0′ 44.201″ N	94	3° 34′ 3.925″ W	54° 0′ 13.597″ N
95	3° 37′ 57.802″ W	54° 1′ 26.958″ N	96	3° 38′ 35.961″ W	54° 1′ 38.908″ N
97	3° 38′ 37.941″ W	54° 1′ 39.528″ N	98	3° 38′ 38.113″ W	54° 1′ 39.582″ N
99	3° 38′ 38.136″ W	54° 1′ 39.589″ N	100	3° 38′ 38.137″ W	54° 1′ 39.589″ N
101	3° 38′ 38.136″ W	54° 1′ 39.588″ N	102	3° 38′ 38.136″ W	54° 1′ 39.585″ N
103	3° 38′ 38.135″ W	54° 1′ 39.557″ N	104	3° 38′ 38.135″ W	54° 1′ 39.550″ N
105	3° 38′ 37.814″ W	54° 1′ 32.453″ N	106	3° 38′ 37.736″ W	54° 1′ 30.739″ N
107	3° 38′ 35.483″ W	54° 0′ 40.901″ N	108	3° 38′ 34.329″ W	54° 0′ 15.381″ N
109	3° 36′ 18.089″ W	53° 59′ 12.083″ N	110	3° 36′ 18.013″ W	53° 59′ 12.112″ N
111	3° 32′ 54.558″ W	53° 57′ 37.375″ N	112	3° 29′ 43.507″ W	53° 56′7.888″ N
113	3° 23′ 28.273″ W	53° 55′ 30.504″ N	114	3° 21′ 22.439″ W	53° 55′17.891″ N
115	3° 17′ 6.328″ W	53° 54′ 52.098″ N	116	3° 16′ 51.776″ W	53° 54′ 50.628″ N
117	3° 13′ 19.548″ W	53° 54′ 29.125″ N	118	3° 13′ 21.515″ W	53° 54′ 27.216″ N
119	3° 12′ 52.745″ W	53° 54′ 16.308″ N	120	3° 12′ 37.818″ W	53° 54′ 24.884″ N
121	3° 12′ 30.762″ W	53° 54′ 24.167″ N	122	3° 11′ 53.533″ W	53° 54′ 41.184″ N
123	3° 11′ 46.361″ W	53° 54′ 44.462″ N	124	3° 8′ 17.617″ W	53° 56′ 19.742″ N
125	3° 8′ 3.775″ W	53° 56′ 24.509″ N	126	3° 5′ 36.260″ W	53° 56′ 54.770″ N
127	3° 5′ 33.104″ W	53° 56′ 55.897″ N	128	3° 3′ 59.223″ W	53° 57′29.379″ N
129	3° 3′ 35.027″ W	53° 57′ 41.707″ N	130	3° 3′ 12.770″ W	53° 57′ 54.699″ N
131	3° 3′ 1.921″ W	53° 58′ 1.031″ N	132	3° 2′ 50.675″ W	53° 58′6.814″ N
133	3° 2′ 29.445″ W	53° 58′ 18.224″ N	134	3° 2′ 26.366″ W	53° 58′ 19.879″ N
135	3° 2′ 18.381″ W	53° 58′ 21.914″ N	136	3° 1′ 57.695″ W	53° 58′ 29.947″ N
137	3° 0′ 59.498″ W	53° 58′ 54.481″ N	138	3° 0′ 17.205″ W	53° 59′ 21.263″ N
139	2° 59′ 50.041″ W	53° 59′ 23.845″ N	140	2° 59′ 48.659″ W	53° 59′ 21.447″ N
141	2° 58′ 39.981″ W	53° 59′ 56.787″ N	142	2° 58′ 22.348″ W	54° 0′ 6.797″ N
143	2° 58′ 17.509″ W	54° 0′ 9.544″ N	144	2° 57′ 52.475″ W	54° 0′ 21.929″ N
145	2° 57′ 40.585″ W	54° 0′ 27.810″ N	146	2° 56′ 43.833″ W	54° 0′ 27.583″ N
147	2° 56′ 36.086″ W	54° 0′ 27.798″ N	148	2° 55′ 33.076″ W	54° 0′ 29.540″ N
149	2° 55′ 24.257″ W	54° 0′ 29.783″ N	150	2° 55′ 17.716″ W	54° 0′ 29.964″ N
151	2° 54′ 28.827″ W	54° 0′ 31.307″ N	152	2° 54′ 28.613″ W	54° 0′ 31.313″ N
153	2° 54′ 7.050″ W	54° 0′ 31.904″ N	154	2° 54′ 0.064″ W	54° 0′ 32.095″ N
155	2° 53′ 50.559″ W	54° 0′ 24.974″ N	156	2° 53′ 50.558″ W	54° 0′ 24.973″ N
157	2° 53′ 50.137″ W	54° 0′ 24.658″ N	158	2° 53′ 48.738″ W	54° 0′ 24.687″ N
159	2° 53′ 48.373″ W	54° 0′ 24.694″ N	160	2° 53′ 48.071″ W	54° 0′ 24.700″ N
161	2° 53′ 47.607″ W	54° 0′ 24.710″ N	162	2° 53′ 47.270″ W	54° 0′ 24.717″ N
163	2° 53′ 47.131″ W	54° 0′ 24.720″ N	164	2° 53′ 47.070″ W	54° 0′ 24.721″ N
165	2° 53′ 46.869″ W	54° 0′ 24.725″ N	166	2° 53′ 46.825″ W	54° 0′ 24.727″ N
167	2° 53′ 46.705″ W	54° 0′ 24.884″ N	168	2° 53′ 46.472″ W	54° 0′ 25.188″ N
169	2° 53′ 46.283″ W	54° 0′ 25.434″ N	170	2° 53′ 46.208″ W	54° 0′ 25.533″ N
171	2° 53′ 46.115″ W	54° 0′ 25.654″ N	172	2° 53′ 46.079″ W	54° 0′ 25.739″ N
173	2° 53′ 46.067″ W	54° 0′ 25.826″ N	174	2° 53′ 46.070″ W	54° 0′ 25.856″ N
175	2° 53′ 46.077″ W	54° 0′ 25.912″ N	176	2° 53′ 46.001″ W	54° 0′ 25.898″ N
177	2° 53′ 45.896″ W	54° 0′ 25.878″ N	178	2° 53′ 45.062″ W	54° 0′ 25.722″ N
179	2° 53′ 44.966″ W	54° 0′ 25.704″ N	180	2° 53′ 44.992″ W	54° 0′ 25.694″ N
181	2° 53′ 45.026″ W	54° 0′ 25.674″ N	182	2° 53′ 45.054″ W	54° 0′ 25.651″ N
183	2° 53′ 45.075″ W	54° 0′ 25.626″ N	184	2° 53′ 45.088″ W	54° 0′ 25.599″ N
185	2° 53′ 45.109″ W	54° 0′ 25.475″ N	186	2° 53′ 45.182″ W	54° 0′ 25.230″ N
187	2° 53′ 45.198″ W	54° 0′ 25.196″ N	188	2° 53′ 45.235″ W	54° 0′ 25.110″ N
189	2° 53′ 45.288″ W	54° 0′ 24.990″ N	190	2° 53′ 45.326″ W	54° 0′ 24.924″ N
191	2° 53′ 45.329″ W	54° 0′ 24.887″ N	192	2° 53′ 45.322″ W	54° 0′ 24.851″ N
193	2° 53′ 45.304″ W	54° 0′ 24.817″ N	194	2° 53′ 45.296″ W	54° 0′ 24.807″ N
195	2° 53′ 45.319″ W	54° 0′ 24.782″ N	196	2° 53′ 43.200″ W	54° 0′ 24.861″ N
197	2° 53′ 41.929″ W	54° 0′ 24.908″ N	198	2° 53′ 41.759″ W	54° 0′ 24.839″ N
199	2° 53′ 39.885″ W	54° 0′ 23.983″ N	200	2° 53′ 38.298″ W	54° 0′ 23.259″ N
201	2° 53′ 36.899″ W	54° 0′ 22.822″ N	202	2° 53′ 36.045″ W	54° 0′ 22.555″ N
203	2° 53′ 33.360″ W	54° 0′ 21.439″ N	204	2° 53′ 33.318″ W	54° 0′ 21.420″ N
205	3° 39′ 19.856″ W	54° 1′ 37.228″ N	206	3° 39′ 21.169″ W	54° 1′ 49.244″ N
207	3° 39′ 21.192″ W	54° 1′ 49.459″ N	208	3° 39′ 21.278″ W	54° 1′ 50.249″ N
209	3° 39′ 21.133″ W	54° 1′ 51.295″ N	210	3° 39′ 21.034″ W	54° 1′ 52.010″ N
211	3° 39′ 20.950″ W	54° 1′ 52.614″ N	212	3° 39′ 20.930″ W	54° 1′ 52.757″ N
213	3° 39′ 20.929″ W	54° 1′ 52.759″ N	214	3° 39′ 20.908″ W	54° 1′ 52.914″ N
215	3° 39′ 20.901″ W	54° 1′ 52.961″ N	216	3° 39′ 20.898″ W	54° 1′ 52.975″ N
217	3° 39′ 52.373″ W	54° 2′ 2.823″ N	218	3° 40′ 23.852″ W	54° 2′ 12.668″ N
219	3° 41′ 8.463″ W	54° 2′ 26.615″ N	220	3° 41′ 44.621″ W	54° 2′ 37.914″ N
221	3° 43′ 41.800″ W	54° 3′ 14.498″ N	222	3° 44′ 20.928″ W	54° 3′ 26.703″ N
223	3° 45′ 34.687″ W	54° 3′ 49.695″ N	224	3° 46′ 13.432″ W	54° 4′ 1.765″ N
225	3° 46′ 27.742″ W	54° 4′ 6.221″ N	226	3° 46′ 38.749″ W	54° 4′ 9.648″ N
227	3° 46′ 41.500″ W	54° 4′ 10.505″ N	228	3° 46′ 41.511″ W	54° 4′ 10.509″ N
229	3° 46′ 42.021″ W	54° 4′ 10.667″ N	230	3° 46′ 42.055″ W	54° 4′ 10.678″ N
231	3° 46′ 42.083″ W	54° 4′ 10.687″ N	232	3° 46′ 42.129″ W	54° 4′ 10.701″ N
233	3° 46′ 42.131″ W	54° 4′ 10.702″ N	234	3° 46′ 42.133″ W	54° 4′ 10.700″ N
235	3° 46′ 42.350″ W	54° 4′ 10.523″ N	236	3° 46′ 42.387″ W	54° 4′ 10.493″ N
237	3° 46′ 47.070″ W	54° 4′ 6.690″ N	238	3° 46′ 44.487″ W	54° 4′ 5.765″ N
239	3° 46′ 37.064″ W	54° 4′ 3.106″ N	240	3° 46′ 37.384″ W	54° 4′ 2.806″ N
241	3° 46′ 29.940″ W	54° 3′ 56.941″ N	242	3° 46′ 1.601″ W	54° 3′ 43.699″ N
243	3° 43′ 26.327″ W	54° 2′ 31.067″ N	244	3° 43′ 26.226″ W	54° 2′ 31.104″ N
245	3° 42′ 11.229″ W	54° 1′ 56.313″ N	246	3° 39′ 57.975″ W	54° 0′ 54.425″ N
247	3° 39′ 12.895″ W	54° 0′ 33.467″ N	248	3° 39′ 19.856″ W	54° 1′ 37.228″ N

(5) The substances or articles authorised for deposit at sea are—

(a) iron, steel, copper and aluminium;

(b) stone and rock;

(c) concrete;

(d) plastic/synthetic;

(e) material extracted from within the Order limits seaward of MHWS during construction drilling and/or seabed preparation for foundation works; and

(f) marine coatings, other chemicals and timber.

(6) The provisions of section 72 of the 2009 Act shall apply to this licence, save that the provisions of section 72(7) relating to the transfer of the licence shall only apply to a transfer not falling within article 5 of the Order.

Commencement Information

I86 Sch. 10 Pt. 1 para. 2 in force at 28.11.2014, see art. 1

Maintenance of authorised project E+W

3.—(1) The undertaker may at any time maintain the authorised development, except to the extent that an agreement made under this licence provides otherwise. No maintenance works whose likely effects on the environment are not assessed in the environmental statement shall take effect, unless otherwise approved by the MMO. The Schedule of Offshore Maintenance Activities identifies those offshore maintenance activities that have been assessed in the environmental statement.

(2) Where the MMO’s approval is required under sub-paragraph (1), such approval must only be given in relation to immaterial changes where it has been demonstrated to the satisfaction of the discharging authority that the approval sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Commencement Information

I87 Sch. 10 Pt. 1 para. 3 in force at 28.11.2014, see art. 1

Duration E+W

4.  This licence shall remain in force until the authorised development has been decommissioned in accordance with a programme approved by the Secretary of State under section 106 of the 2004 Act, including any modification to the programme under section 108, and the completion of such programme has been confirmed by the Secretary of State in writing.

Commencement Information

I88 Sch. 10 Pt. 1 para. 4 in force at 28.11.2014, see art. 1

PART 2 E+W Licence Conditions

Design parameters for offshore substation platforms and export cable systems E+W

1.—(1) The total number of offshore substations forming part of the authorised development shall not exceed three.

(2) The dimensions of any offshore substation forming part of the authorised development (excluding any towers, helipads, masts and cranes) shall not exceed 75 metres in height when measured from LAT, 50 metres in length and 50 metres in width.

(3) No jacket structure for use with any offshore substation forming part of the authorised development, when used in conjunction with steel piles or suction caissons, shall have—

(a) a width spacing between each leg at the level of the seabed of more than 70 metres and at the level of LAT which is greater than 40 metres;

(b) more than 4 legs;

(c) a leg diameter of more than 4 metres;

(d) more than four piles per leg;

(e) a pile diameter of more than 3.5 metres;

(f) more than three suction caissons per leg;

(g) a suction caisson diameter of greater than 25 metres each.

(4) The number of cable systems forming part of the authorised development laid in the cable corridor forming part of the Order limits between reference point AA and reference point BB and reference point CC shown on the works plans shall not exceed five.

(5) The total length of the cables comprising Work No. 3A shall not exceed 480 kilometres.

Commencement Information

I89 Sch. 10 Pt. 2 para. 1 in force at 28.11.2014, see art. 1

Design parameters for other deposits E+W

2.—(1) The total volume of scour protection for use with the offshore substation platforms in Work No. 2(a) shall not exceed 125,100m³.

(2) The total volume of cable protection (excluding cable crossings) within Work No. 3A shall not exceed 109,650m³ with a maximum footprint of 142,139m².

(3) The total volume of cable protection associated with cable crossings included within Work No. 3A shall not exceed 125,955m³ with a maximum footprint of 144,548m².

Commencement Information

I90 Sch. 10 Pt. 2 para. 2 in force at 28.11.2014, see art. 1

Notifications and inspections E+W

3.—(1) The undertaker must ensure that—

(a) a copy of this licence and any subsequent amendments or revisions to it are provided to—

(i) all agents and contractors notified to the MMO in accordance with condition 4 of this licence; and

(ii) the masters and transport managers responsible for the vessels notified to the MMO in accordance with the condition 4 of this licence;

(b) within 28 days of receipt of a copy of this licence those persons referred to at sub-paragraph (i) above must provide a completed confirmation form to the MMO confirming their understanding of the terms and conditions of this licence.

(2) Only those persons and vessels notified to the MMO in accordance with condition 4 are permitted to carry out the licensed activities.

(3) Copies of this licence must also be available for inspection by an enforcement officer at all reasonable times at the following locations—

(a) the undertaker’s registered address;

(b) any site office located at or adjacent to the construction site and used by the undertaker or its agents and contractors responsible for the loading, transportation or deposit of the authorised deposits and works; and

(c) on board each vessel or at the office of any transport manager with responsibility for vessels from which authorised deposits are to be made or authorised works undertaken.

(4) The undertaker must provide access, and if necessary appropriate transportation, to the offshore construction site or the ancillary works or vessels to facilitate any inspection that the MMO or Trinity House considers necessary to meet any mandatory health and safety requirements or inspect the works during construction and operation of the authorised development.

(5) The undertaker must inform the MMO marine licensing team and the coastal MMO office specified in paragraph 1(4)(a) above, and the Hydrographic Office, the MCA, and Trinity House, in writing at least five working days prior to the commencement of the licensed activities or any part of them.

(6) The undertaker must publish in the Kingfisher Fortnightly Bulletin details of the vessel routes, timings and locations relating to the construction of the authorised development, or relevant part, at least five working days prior to the commencement of the licensed activities or any part of them.

(7) The undertaker must ensure that a notice to mariners is issued at least ten days prior to the commencement of Work Nos. 2 and 3A and 3B advising of the start date of those licensed activities and the expected vessel routes from the local service ports to the areas in which those works are to be carried out.

(8) The undertaker must ensure that the notices to mariners are agreed with the MMO and the MCA in accordance with the construction programme approved under licence condition 9(1)(a). Such notices must be—

(a) updated and reissued at regular intervals; and

(b) supplemented with VHF radio broadcasts.

Copies of all notices must be provided to the MMO.

Commencement Information

I91 Sch. 10 Pt. 2 para. 3 in force at 28.11.2014, see art. 1

Reporting of engaged agents, contractors and vessels E+W

4.—(1) The undertaker must provide the following information to the MMO—

(a) the name and function of any agent or contractor appointed to engage in the licensed activities, at least five working days prior to the commencement of the licensed activities or any part of them; and

(b) each week during the construction of the authorised development a completed Hydrographic Note H102 listing the vessels to be used in relation to the licensed activities.

(2) Any changes to the supplied details must be notified to the MMO in writing at least five working days prior to the agent, contractor or vessel engaging in the licensed activities.

Commencement Information

I92 Sch. 10 Pt. 2 para. 4 in force at 28.11.2014, see art. 1

Equipment and operation of vessels engaged in licensed activities E+W

5.—(1) All vessels employed to perform the licensed activities must be constructed and equipped to be capable of the proper performance of such activities in accordance with the conditions of this licence and must comply with sub-paragraphs (2) to (5) below.

(2) All motor powered vessels must be fitted with the following equipment—

(a) electronic positioning aid to provide navigational data;

(b) radar;

(c) echo sounder;

(d) multi-channel VHF, and

no vessel shall engage in the licensed activities until all such equipment is fully operational.

(3) All vessels’ names or identification must be clearly marked on the hull or superstructure of the vessel.

(4) All vessels must exhibit signals in accordance with the requirements of the International Regulations for the Prevention of Collisions at Sea.

(5) All communication on VHF working frequencies must be in English.

Commencement Information

I93 Sch. 10 Pt. 2 para. 5 in force at 28.11.2014, see art. 1

Chemicals, drilling and debris E+W

6.—(1) All chemicals used in the construction of the authorised development must be selected from the List of Notified Chemicals approved for use by the offshore oil and gas industry under the Offshore Chemicals Regulations 2002, unless otherwise agreed by the MMO.

(2) All protective coatings and paints must be suitable for use in the marine environment. Details of such coatings and paints and how they will be used must be submitted to the MMO as part of the construction method statement required under condition 9(1)(c).

(3) The storage, handling, transport and use of fuels, lubricants, chemicals and other substances must be undertaken so as to prevent releases into the marine environment including bunding of 110 per cent of the total volume of all reservoirs and containers.

(4) Where foundation drilling works are proposed, in the event that any system other than water based mud is proposed, the MMO’s written approval in relation to the proposed disposal of any arisings must be obtained before the drilling commences.

(5) The undertaker must ensure that only inert material of natural origin, produced during construction drilling and seabed preparation for foundation works shall be disposed of within the Disposal Site.

(6) The undertaker must inform the MMO of the location and quantities of inert material disposed of each month under this licence, by submission of a disposal return by 31st January each year for disposals occurring during the months July to December inclusive of the preceding year, and by 31st July each year for disposals occurring during the months January to June inclusive of that year.

(7) The undertaker must notify the MMO within 48 hours of the completion of the final disposal of inert material at the Disposal Site.

(8) The undertaker must ensure that any debris arising from the construction of the authorised development or temporary works placed below MHWS are removed on completion of the construction of the authorised development, unless otherwise agreed with the MMO.

(9) At least two months prior to the commencement of the licensed activities the undertaker must submit to the MMO a transportation audit sheet covering the construction of the authorised development. No works shall commence until the audit sheet content has been agreed with the MMO. The audit sheet must include details of—

(a) loading facilities;

(b) vessels;

(c) equipment;

(d) shipment routes;

(e) working schedules; and

(f) all components and materials to be used in the construction of the authorised development.

(10) The audit sheet must be maintained throughout the construction of the authorised development and any changes notified immediately in writing to the MMO. The audit sheet will be made available for inspection by the MMO within 12 hours of the undertaker’s receipt of a request made by the MMO.

(11) In the event that the MMO becomes aware that any of the materials on the audit sheet cannot be accounted for it must require the undertaker in writing to carry out a side scan sonar survey to plot all obstructions across the relevant areas within the Order limits seaward of MHWS where construction works and related activities have been carried out. Local fishermen must be invited to send a representative to be present during the survey. Any new obstructions that the MMO reasonably concludes are associated with the authorised development must be removed, as directed by the MMO in writing, at the undertaker’s expense.

Commencement Information

I94 Sch. 10 Pt. 2 para. 6 in force at 28.11.2014, see art. 1

Force majeure E+W

7.  If, due to stress of weather or any other cause the master of a vessel determines that it is necessary to deposit the authorised substances and/or articles within or outside of the Order limits seaward of MHWS because the safety of human life and/or of the vessel is threatened full details of the circumstances of the deposit must be notified to the MMO within 48 hours, and the undertaker must—

(a) as soon as reasonably practicable following such notification, submit a method statement and programme for the removal of the deposit; and

(b) undertake the removal of the deposit in accordance with the approved method statement and programme, unless otherwise agreed with the MMO.

Commencement Information

I95 Sch. 10 Pt. 2 para. 7 in force at 28.11.2014, see art. 1

Restrictions on works in the Inter-tidal Area E+W

8.—(1) The undertaker must not construct or install those licensable activities comprised in Work Nos. 3A and 3B in the Inter-tidal Area—

(a) between 1st October and 31st March (inclusive); and

(b) the period of time commencing two hours before High Tide and ending two hours after High Tide between 1st April and 14th April (inclusive), unless otherwise approved by the MMO, in consultation with Natural England.

(2) Those licensable activities comprised in Work Nos. 3A and 3B between points XX and YY shown on the works plans must—

(a) only be undertaken by means of horizontal directional drilling from construction working sites located west of point XX and/or east of point YY;

(b) comprise a horizontal directional drilling entry/exit point no less than 50 metres west of point XX on the works plans; and

(c) not involve the placing or transportation of any plant, apparatus, cables, cable ducts or any other materials required for the carrying out of the connection works on or over that land, provided that the undertaker may place or transport (by hand and on foot only) such equipment and/or means of enclosure, on or over that land, as may be required to—

(i) contain and/or remove fluid used in the horizontal directional drilling process including the placing of hoses along the northern Order limit between points XX and YY shown on the works plans for Work No. 3B as approved pursuant to Requirement 16 of Part 3 of Schedule 1 to the Order; and

(ii) mitigate the horizontal directional drilling process in accordance with environmental management and monitoring plan approved pursuant to Requirement 16 of Part 3 of Schedule 1 to the Order.

(3) The connection works comprised in Work Nos. 3A and 3B between points XX and YY shown on the works plans must not be commenced until an environmental management and monitoring plan has been approved pursuant to Requirement 16 of Part 3 of Schedule 1 to the Order. The environmental management and monitoring plan must be submitted for approval at least four months prior to the commencement of those connection works, or within such other timescale as agreed pursuant to Requirement 16 of Part 3 of Schedule 1 to the Order.

(4) The environmental management and monitoring plan must include details of the location, method and timing of surveys of the land within the Order limits between points XX and YY shown on the works plans to—

(a) establish the pre-construction baseline condition of the saltmarsh and the distribution of the Lycia zonaria britannica (Belted Beauty Moth) in that location; and

(b) record within a five year period following completion of construction the ecological recovery of the saltmarsh and the distribution of the Lycia zonaria britannica (Belted Beauty Moth) in that location and, if applicable, any receptor site to which the Lycia zonaria britannica (Belted Beauty Moth) has been translocated.

(5) The environmental management and monitoring plan must include details of the methodology for undertaking the connection works comprised in Work Nos. 3A and 3B between points XX and YY shown on the works plans by horizontal directional drilling, and mitigation measures relating thereto, including—

(a) details of the equipment required to contain and/or remove fluid used in the horizontal directional drilling process;

(b) details of means of enclosure to be deployed (if any);

(c) the use of a drill bit of no less than 12.25 inches;

(d) the use of a real time downhole annular pressure monitor;

(e) details of how the length of each drill path will be minimised;

(f) details of the training of personnel to be employed in relation to the horizontal directional drilling and/or mitigation measures;

(g) the employment of an Ecological Clerk of Works and scope of duties relating to that role;

(h) details of how the number of trips made between points XX and YY shown on the works plans will be minimised;

(i) details of the methodology and location of suitable receptor sites associated with the translocation of the Lycia zonaria britannica (Belted Beauty Moth), should such translocation be required by the relevant planning authority, having consulted with Natural England and the MMO;

(j) details of the methodology for preventing birds from nesting above the alignment of each horizontal directional drill, such methodology may include visual and/or sound deterrents, and/or physical barriers; and

(k) details of how the connection works will be maintained (if applicable).

(6) The environmental management and monitoring plan must be implemented as approved, unless otherwise approved pursuant to Requirement 16 of Part 3 of Schedule 1 to the Order, and provided that the undertaker shall not be required to carry out the post-construction monitoring of the ecological recovery of the saltmarsh in sub-paragraph (4)(b) in the event that no fluid used in the horizontal directional drilling process is released into the saltmarsh between points XX and YY shown on the works plans.

Commencement Information

I96 Sch. 10 Pt. 2 para. 8 in force at 28.11.2014, see art. 1

Seasonal restrictions in respect of fish spawning E+W

9.—(1) The undertaker must ensure that no percussive piling activity takes place during the cod spawning period from 15th February to 31st March (inclusive) of any year.

(2) The undertaker must ensure that no percussive piling activity takes place during the herring spawning period from 15th September to 15th November (inclusive) for any year, within such areas as agreed with the MMO prior to the commencement of construction. The undertaker must provide to the MMO the results of noise modelling prepared to an agreed methodology to inform the selection of such areas.

Commencement Information

I97 Sch. 10 Pt. 2 para. 9 in force at 28.11.2014, see art. 1

Pre-construction plans and documentation E+W

10.—(1) The licensed activities must not commence until the following have been submitted to and approved by the MMO and, in relation to paragraphs (a) to (g), (i) and (j), following consultation with Natural England—

(a) a construction and monitoring programme to include details of—

(i) the proposed construction start date;

(ii) timings for mobilisation of plant, delivery of materials and installation works;

(iii) proposed pre-construction surveys/monitoring, baseline reporting format and content, construction surveys/monitoring, post-construction surveys/monitoring and related reporting in accordance with licence conditions 10 and 11;

(iv) a design plan at a scale of between 1:25,000 and 1:50,000, including detailed representation on the most suitable scaled Admiralty Chart, as agreed with the MMO, in consultation with Trinity House, the MCA and Natural England, which shows any archaeological exclusion zones identified under paragraph (h), and any exclusion zones and/or micrositing requirements identified in any mitigation scheme pursuant to paragraph (i); and

(v) proposed timings for the disposal of material produced during construction drilling and seabed preparation for foundation works;

(b) a plan to be agreed with the MMO in consultation with Trinity House and the MCA setting out proposed details of the authorised development, specifying the—

(i) number, dimensions and foundation type(s) and depth for each offshore substation platform;

(ii) the grid coordinates of the centre point of each offshore substation platform;

(iii) proposed layout of all cables; and

(iv) the proposed location(s) for the disposal of material produced during construction drilling and seabed preparation for foundation works;

(c) a construction method statement in accordance with the construction methods assessed in the environmental statement and including details of—

(i) foundation installation, including any seabed preparation, drilling and disposal of arisings methods;

(ii) offshore substation installation, including any seabed preparation and scour protection;

(iii) cable installation, including cable protection, the method and specification for seabed reinstatement relating to open cut trenches excavated in the Inter-tidal Area, and the method and frequency of post-construction surveys required to monitor physical and biological recovery of the seabed following such reinstatement;

(iv) protective coatings and paints as required under condition 6(2);

(v) contractors;

(vi) vessels and vessel transit corridors;

(vii) ancillary works; and

(viii) drilling methods and disposal of material produced during construction drilling and seabed preparation for foundation works;

(d) a project environmental management and monitoring plan to include details of—

(i) a marine pollution contingency plan to address the risks, methods and procedures to deal with any spills and collision incidents during construction and operation of the authorised development in relation to all activities carried out below MHWS and Work Nos. 4 to 7 (inclusive);

(ii) a chemical risk assessment to include information regarding how and when chemicals are to be used, stored and transported in accordance with recognised best practice guidance;

(iii) a method statement for the taking of sediment samples;

(iv) waste management and disposal arrangements including a protocol covering potential finds of objects associated with the legacy of disposal at sea of material from the nuclear industry; and

(v) the appointment and responsibilities of a fisheries liaison officer and an environmental liaison officer;

(e) a scour protection management plan providing details of the need, type, sources, quantity and installation methods for scour protection;

(f) a marine mammal mitigation protocol, including a requirement for a soft start procedure, when driven or part-driven pile foundations are used;

(g) cable specification and installation plan in accordance with the methodology assessed in the environmental statement, to include—

(i) technical specification of off-shore cables, including a desk-based assessment of attenuation of electro-magnetic field strengths, shielding and cable burial depth in accordance with industry good practice; and

(ii) a detailed cable laying plan for the Order limits seaward of MHWS, incorporating geotechnical data and a cable burial risk assessment to inform cable burial depths and cable laying techniques, including contingency measures, in the event cable burial is not achieved by the methods proposed in that plan;

(h) a written scheme of archaeological investigation in relation to the Order limits in accordance with industry good practice and developed in consultation with English Heritage, and where applicable, the relevant local authority, to include—

(i) details of responsibilities of the undertaker, archaeological consultant and contractor;

(ii) a methodology for any further site investigation including any specifications for geophysical, geotechnical and diver or remotely operated vehicle investigations;

(iii) a programme for the analysis and reporting of survey data, and timing, which is to be submitted to the MMO within four months of the survey being completed, unless otherwise agreed with the MMO;

(iv) details of any mitigation including, where necessary, archaeological exclusion zones;

(v) details of monitoring during and post construction, including a conservation programme for finds and publication of reports, developed in consultation with English Heritage, associated with the consented development;

(vi) details of methods for archiving of archaeological material; and

(vii) a reporting and recording protocol, including reporting of any wreck or wreck material during construction, operation and decommissioning of the authorised development;

(i) a mitigation scheme for any Annex I Habitat identified by the survey referred to in condition 10(2)(a);

(j) an offshore operations and maintenance plan that must be submitted to the MMO at least four months prior to commencement of the operation of the licensed activities and include provision for the review and resubmission of that plan every three years during the operational phase. The offshore operations and maintenance plan must include details of—

(i) information on the presence of Annex I Habitat as identified in condition 10(2)(a);

(ii) information on, including likely schedule of, corrective and preventative maintenance activities proposed during the operation of the licensed activities, as identified in the environmental statement and Schedule of Offshore Maintenance Activities;

(iii) a summary of the environmental impact of the activities listed under sub-paragraph (ii), as identified in the environmental statement and Schedule of Offshore Maintenance Activities, and having regard to sub-paragraph (i); and

(iv) the anticipated maintenance activities that exceed the frequency and/or scope of licensable activities identified in the environmental statement and Schedule of Offshore Maintenance Activities, and the proposed approach to the licensing of these activities.

and each programme, statement, plan, protocol, scheme or other detail required to be approved under this condition must be submitted to the MMO for approval at least four months prior to the commencement of works, except where otherwise stated or unless otherwise agreed by the MMO.

(2) The undertaker must ensure that a copy of any agreed archaeological report is deposited with the National Monuments Record, in accordance with the Online AccesS to the Index of archaeological investigationS (OASIS) system.

(3) The licensed activities must be carried out in accordance with any programme, statement, plan, protocol, scheme or other details approved under this licence condition, unless otherwise agreed by the MMO.

Commencement Information

I98 Sch. 10 Pt. 2 para. 10 in force at 28.11.2014, see art. 1

Pre-construction surveying and monitoring E+W

11.—(1) The undertaker must, in discharging condition 10(1)(a) submit details for approval by the MMO in consultation with Natural England of proposed pre-construction surveys, including methodologies and timings, and a proposed format and content for a pre-construction baseline report at least 4 months prior to surveys commencing.

(2) The pre-construction surveys referred to in sub-paragraph (1) must unless otherwise agreed with the MMO have due regard to the need to undertake—

(a) surveys to determine the location, extent and composition of any benthic habitats of conservation, ecological and/or economic importance (including Annex I Habitat) inside the area(s) within the Order limits seaward of MHWS in which it is proposed to carry out construction works;

(b) a high resolution swath-bathymetry survey and side-scan sonar survey of the areas within the Order limits seaward of MHWS in which it is proposed to carry out construction works, including a 500 metre buffer area around the site of each work inclusive of seabed anomalies or sites of historic or archaeological interest that lie within that 500 metre buffer;

(c) debris surveys, including a side scan sonar survey, across the area(s) within the Order limits seaward of MHWS in which it is proposed to carry out construction works; and

(d) surveys of the baseline environment of the Inter-tidal Area within the Order limits seaward of MHWS in which it is proposed to carry out construction works.

(3) The undertaker must carry out the surveys agreed under sub-paragraph (1) and provide the baseline report to the MMO in the agreed format in accordance with the agreed timetable, unless otherwise agreed by the MMO.

(4) The undertaker must not commence construction until the baseline report has been agreed by the MMO.

Commencement Information

I99 Sch. 10 Pt. 2 para. 11 in force at 28.11.2014, see art. 1

Construction monitoring E+W

12.—(1) The undertaker must, in discharging condition 10(1)(a), submit details for approval by the MMO in consultation with Natural England of proposed surveys or monitoring, including methodologies and timings, to be carried out during the construction of the authorised development.

(2) A scheme for noise monitoring must be submitted for approval by the MMO prior to the commencement of any piling activity, which scheme must include details for measurements of noise generated at a minimum of three piling locations.

(3) The undertaker must carry out the surveys approved under sub-paragraph (1), including any further noise monitoring required in writing by the MMO, and provide the agreed reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed with the MMO.

(4) The results of the initial noise measurements provided in accordance with sub-paragraph (3) must be provided to the MMO within six weeks of the installation of the first monitored pile approved pursuant to sub-paragraph (1), unless otherwise agreed with the MMO.

(5) Unless otherwise agreed with the undertaker, within 6 weeks of the submission of results of the initial noise measurements provided in accordance with sub-paragraph (3) the MMO must, having regard to those results, determine whether or not any further noise monitoring is required and confirm this to the undertaker.

Commencement Information

I100 Sch. 10 Pt. 2 para. 12 in force at 28.11.2014, see art. 1

Post construction monitoring E+W

13.—(1) The undertaker must, in discharging condition 10(1)(a), submit details for approval by the MMO in consultation with Natural England of proposed post-construction surveys, including methodologies and timings, and proposed format, content and timings for providing reports on the results. Subject to receipt of specific proposals, it is expected that acceptable post-construction surveys will comprise, in outline—

(a) a survey of any benthic communities/benthos constituting Annex I Habitat inside the area(s) within the Order limits seaward of MHWS in which construction works were carried out;

(b) high resolution swath-bathymetric surveys to assess any changes to bed form morphology, and to ensure that the cables have been buried, to be undertaken as follows—

(i) the first survey shall be undertaken across the entirety of the area within the Order limits seaward of MHWS in which construction works were carried out; and

(ii) any subsequent surveys shall be undertaken across such representative areas within the Order limits seaward of MHWS as may be agreed with the MMO, and such further monitoring as may be agreed with the MMO; and

(c) surveys of the Inter-tidal Area within the Order limits seaward of MHWS in which construction works were carried out, to determine the extent and success of physical and biological recovery following cable installation.

(2) Following the completion of the authorised development, the undertaker must carry out the surveys referred to in sub-paragraph (1) for three years, which may be non-consecutive years, and provide reports in the agreed format in accordance with the agreed timetable, unless otherwise agreed with the MMO following consultation with Natural England.

(3) If a major storm event occurs at any time between the completion of the authorised development and the completion of the third year of surveys required under sub-paragraph (2), the undertaker must carry out a side scan sonar and bathymetry survey within the Order limits seaward of MHWS in which the construction works were carried out, in accordance with such timetable as may be agreed with the MMO following consultation with Natural England.

Commencement Information

I101 Sch. 10 Pt. 2 para. 13 in force at 28.11.2014, see art. 1

Offshore Decommissioning E+W

14.  No part of the authorised development seaward of MHWS shall commence until a written decommissioning programme in compliance with any notice served upon the undertaker by the Secretary of State pursuant to section 105(2) of the 2004 Act has been submitted to the Secretary of State for approval. The undertaker must consult the MMO, Natural England and the relevant planning authority on the proposed decommissioning activity no less than four months prior to submission of the proposed decommissioning programme to the Secretary of State.

Commencement Information

I102 Sch. 10 Pt. 2 para. 14 in force at 28.11.2014, see art. 1

Offshore Safety Management E+W

15.—(1) No authorised development seaward of MHWS shall commence until the MMO, in consultation with the MCA, has given written approval of a plan for an active safety management system which includes an emergency response and co-operation plan (ERCoP) for the construction, operation and decommissioning phases of the authorised development in accordance with the MCA’s recommendations in MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues”.

(2) No authorised development seaward of MHWS shall commence until the MMO, in consultation with the MCA, has confirmed in writing that the undertaker has taken into account and adequately addressed all MCA recommendations as appropriate to the authorised development contained within the document MGN 371 “Offshore Renewable Energy Installations (OREIs) – Guidance on UK Navigational Practice, Safety and Emergency Response Issues” and its annexes.

(3) The active safety management system and ERCoP must be implemented as approved unless otherwise agreed by the MMO in consultation with the MCA.

Commencement Information

I103 Sch. 10 Pt. 2 para. 15 in force at 28.11.2014, see art. 1

Aids to navigation E+W

16.—(1) The undertaker must at or near the authorised development during the whole period of the construction, operation, alteration, replacement or decommissioning of the authorised development seaward of MHWS exhibit such lights, marks, sounds, signals and other aids to navigation, and to take such other steps for the prevention of danger to navigation, as Trinity House may from time to time direct.

(2) The undertaker must provide information to the Hydrographic Office on the position and nature of works to facilitate the issuing of notices and warnings to mariners.

(3) The undertaker must keep the Hydrographic Office, the MCA, Trinity House and the MMO informed of progress with the authorised development and will provide—

(a) at least 24 hours’ notice of commencement within 24 hours of commencement having occurred;

(b) as soon as reasonably practicable notification of the provision of any aids to navigation required by the licence conditions;

(c) reports on the working condition of aids to navigation as requested by Trinity House;

(d) notice to Trinity House and the MMO of any failure of aids to navigation, and the plans for remedying such failures, as soon as practicable and within 24 hours of such failure being identified;

(e) notification of completion within 2 weeks of completion of the authorised development.

(4) The undertaker must paint yellow (colour code RAL 1023) all structures to be constructed as part of the authorised development seaward of MHWS from at least HAT to a height directed by Trinity House. Unless the MMO otherwise directs, the undertaker must paint the remainder of the structures submarine grey (colour code RAL 7035).

(5) The undertaker must exhibit such lights, with such shape, colour and character as are required by Air Navigation Order 2009, or as directed by the CAA, and must notify the CAA and the MMO of any failure of those lights and the timescales in which such failure will be remedied, as soon as possible and no later than 24 hours following the undertaker becoming aware of any such failure.

Commencement Information

I104 Sch. 10 Pt. 2 para. 16 in force at 28.11.2014, see art. 1

Provision against danger to navigation E+W

17.  In case of damage to, or destruction or decay of, the authorised development seaward of MHWS or any part thereof the undertaker must as soon as reasonably practicable notify Trinity House and must lay down such buoys, exhibit such lights and take such other steps for preventing danger to navigation as Trinity House may from time to time direct.

Commencement Information

I105 Sch. 10 Pt. 2 para. 17 in force at 28.11.2014, see art. 1

Requirement for written approval E+W

18.  With respect to any condition of this licence which requires the licensed activities to be carried out in accordance with any details approved by the MMO, notification of such approval must be given in writing.

Commencement Information

I106 Sch. 10 Pt. 2 para. 18 in force at 28.11.2014, see art. 1

Amendments to approved details E+W

19.—(1) With respect to any condition which requires the licensed activities to be carried out in accordance with the details approved by the MMO, the approved details shall be carried out as approved unless an amendment or variation is agreed in advance by the MMO pursuant to the relevant condition, in accordance with sub-paragraph (2) and in consultation with any body specified in the relevant condition.

(2) Where any condition specifies “unless otherwise agreed” by the MMO such agreement shall not be given except in relation to immaterial changes where it has been demonstrated to the satisfaction of the MMO that the agreement sought is unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

(3) The approved details shall be taken to include any amendments that may subsequently be approved by the MMO.

Commencement Information

I107 Sch. 10 Pt. 2 para. 19 in force at 28.11.2014, see art. 1

Article 33(4)

SCHEDULE 11 E+W REMOVAL OF IMPORTANT HEDGEROWS

Commencement Information

I108 Sch. 11 in force at 28.11.2014, see art. 1

(1) Area	(2) Reference of hedgerow
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 1 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 2 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 3 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 4 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 5 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 6 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 7 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 8 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 9 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 12 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 13 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 14 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 15 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 16 on the Hedgerow Plan
In the County of Lancashire, District of City of Lancaster	The important hedgerow marked 18 on the Hedgerow Plan

Article 41

SCHEDULE 12 E+W PROTECTIVE PROVISIONS

PART 1 E+W Protection for Environment Agency

1.—(1) The following provisions shall apply for the protection of the drainage authority unless otherwise agreed in writing between the undertaker and the drainage authority. E+W

(2) In this Part of this Schedule—

“construction” includes execution, placing, altering, replacing, relaying and removal and “construct” and “constructed” shall be construed accordingly;

“drainage authority” means the Environment Agency;

“drainage work” means any watercourse and includes any land which provides or is expected to provide flood storage capacity for any watercourse and any bank, wall, embankment or other structure, or any appliance, constructed or used for land drainage, flood defence or tidal monitoring;

“the fishery” means any waters containing fish and the spawn, habitat or food of such fish;

“plans” includes sections, drawings, specifications and method statements;

“specified work” means so much of the authorised development as is in, on, under, over or within 16 metres of a drainage work or is otherwise likely to affect any drainage work;

“watercourse” includes all rivers, streams, ditches, drains, cuts, culverts, dykes, sluices, sewers and passages through which water flows except a public sewer.

Commencement Information

I109 Sch. 12 Pt. 1 para. 1 in force at 28.11.2014, see art. 1

2.—(1) Before beginning to construct any specified work, the undertaker shall submit to the drainage authority plans of the specified work and such further particulars available to it as the drainage authority may within 28 days of the submission of the plans reasonably require. E+W

(2) Any such specified work shall not be constructed except in accordance with such plans as may be approved in writing by the drainage authority, or determined under paragraph 11.

(3) Any approval of the drainage authority required under this paragraph—

(a) shall not be unreasonably withheld or delayed;

(b) shall be deemed to have been given if it is neither given nor refused within 2 months of the submission of the plans for approval and, in the case of a refusal, accompanied by a statement of the grounds of refusal; and

(c) may be given subject to such reasonable requirements as the drainage authority may make for the protection of any drainage work or the fishery or for the protection of water resources for the prevention of pollution or in the discharge of its environmental duties.

(4) The drainage authority shall use its reasonable endeavours to respond to the submission of any plans before the expiration of the period mentioned in sub-paragraph (3)(b).

Commencement Information

I110 Sch. 12 Pt. 1 para. 2 in force at 28.11.2014, see art. 1

3.  Without limiting the scope of paragraph 2, the requirements which the drainage authority may make under that paragraph include conditions requiring the undertaker at its own expense to construct such protective works, whether temporary or permanent, during the construction of the specified works (including the provision of flood banks, walls or embankments or other new works and the strengthening, repair or renewal of existing banks, walls or embankments) as are reasonably necessary— E+W

(a) to safeguard any drainage work against damage; or

(b) to secure that its efficiency for flood defence purposes is not impaired and that the risk of flooding is not otherwise increased,

by reason of any specified work.

Commencement Information

I111 Sch. 12 Pt. 1 para. 3 in force at 28.11.2014, see art. 1

4.—(1) Subject to sub-paragraph (2), any specified work, and all protective works required by the drainage authority under paragraph 3, shall be constructed— E+W

(a) without unreasonable delay in accordance with the plans approved or deemed to have been approved or settled under this Part of this Schedule; and

(b) to the reasonable satisfaction of the drainage authority,

and an officer of the drainage authority shall be entitled to watch and inspect the construction of such works.

(2) The undertaker shall give to the drainage authority not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is brought into use.

(3) If any part of a specified work or any protective work required by the drainage authority is constructed otherwise than in accordance with the requirements of this Part of this Schedule, the drainage authority may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as the drainage authority reasonably requires.

(4) Subject to sub-paragraph (5), if within a reasonable period, being not less than 28 days from the date when a notice under sub-paragraph (3) is served upon the undertaker, it has failed to begin taking steps to comply with the requirements of the notice and subsequently to make reasonably expeditious progress towards their implementation, the drainage authority may execute the works specified in the notice and any expenditure incurred by it in so doing shall be recoverable from the undertaker.

(5) In the event of any dispute as to whether sub-paragraph (3) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, the drainage authority shall not except in emergency exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined.

Commencement Information

I112 Sch. 12 Pt. 1 para. 4 in force at 28.11.2014, see art. 1

5.—(1) Subject to sub-paragraph (5) the undertaker shall from the commencement of the construction of the specified works maintain in good repair and condition and free from obstruction any drainage work which is situated within the Order limits on land held by the undertaker for the purposes of or in connection with the specified works, whether or not the drainage work is constructed under the powers conferred by this Order or is already in existence. E+W

(2) If any such drainage work which the undertaker is liable to maintain is not maintained to the reasonable satisfaction of the drainage authority, the drainage authority may by notice in writing require the undertaker to repair and restore the work, or any part of such work, or (if the undertaker so elects and the drainage authority in writing consents, such consent not to be unreasonably withheld or delayed), to remove the work and restore the site to its former condition, to such extent and within such limits as the drainage authority reasonably requires.

(3) If, within a reasonable period being not less than 28 days beginning with the date on which a notice in respect of any drainage work is served under sub-paragraph (2) on the undertaker, the undertaker has failed to begin taking steps to comply with the reasonable requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, the drainage authority may do what is necessary for such compliance and may recover any expenditure reasonably incurred by it in so doing from the undertaker.

(4) In the event of any dispute as to the reasonableness of any requirement of a notice served under sub-paragraph (2), the drainage authority shall not except in a case of emergency exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined.

(5) This paragraph does not apply to—

(a) drainage works which are vested in the drainage authority, or which the drainage authority or another person is liable to maintain and is not prescribed by the powers of the Order from doing so; and

(b) any obstruction of a drainage work for the purpose of a work or operation authorised by this Order and carried out in accordance with the provisions of this Part of this Schedule.

Commencement Information

I113 Sch. 12 Pt. 1 para. 5 in force at 28.11.2014, see art. 1

6.  If by reason of the construction of any specified work or of the failure of any such work the efficiency of any drainage work for flood defence purposes is impaired, or that drainage work is otherwise damaged, such impairment or damage shall be made good by the undertaker to the reasonable satisfaction of the drainage authority and if the undertaker fails to do so, the drainage authority may make good the impairment or damage and recover from the undertaker the expense reasonably incurred by it in doing so. E+W

Commencement Information

I114 Sch. 12 Pt. 1 para. 6 in force at 28.11.2014, see art. 1

7.—(1) The undertaker shall take all such measures as may be reasonably practicable to prevent any interruption of the free passage of fish in the fishery during the construction of any specified work. E+W

(2) If by reason of—

(a) the construction of any specified work; or

(b) the failure of any such work,

damage to the fishery is caused, or the drainage authority has reason to expect that such damage may be caused, the drainage authority may serve notice on the undertaker requiring it to take such steps as may be reasonably practicable to make good the damage, or, as the case may be, to protect the fishery against such damage.

(3) If within such time as may be reasonably practicable for that purpose after the receipt of written notice from the drainage authority of any damage or expected damage to a fishery, the undertaker fails to take such steps as are described in sub-paragraph (2), the drainage authority may take those steps and may recover from the undertaker the expense reasonably incurred by it in doing so.

(4) In any case where immediate action by the drainage authority is reasonably required in order to secure that the risk of damage to the fishery is avoided or reduced, the drainage authority may take such steps as are reasonable for the purpose, and may recover from the undertaker the reasonable cost of so doing provided that notice specifying those steps is served on the undertaker as soon as reasonably practicable after the drainage authority has taken, or commenced to take, the steps specified in the notice.

Commencement Information

I115 Sch. 12 Pt. 1 para. 7 in force at 28.11.2014, see art. 1

8.  The undertaker shall indemnify the drainage authority in respect of all costs, charges and expenses which the drainage authority may reasonably incur or have to pay or which it may sustain— E+W

(a) in the consideration or approval of plans under this Part of this Schedule; and

(b) in the inspection of the construction of the specified works or any protective works required by the drainage authority under this Part of this Schedule.

Commencement Information

I116 Sch. 12 Pt. 1 para. 8 in force at 28.11.2014, see art. 1

9.—(1) Without prejudice to the other provisions of this Part of this Schedule, the undertaker shall indemnify the drainage authority from all claims, demands, proceedings, costs, damages, expenses or loss, which may be made or taken against, recovered from, or incurred by, the drainage authority by reason of— E+W

(a) any damage to any drainage work so as to impair its efficiency for the purposes of flood defence;

(b) any raising or lowering of the water table in land adjoining the authorised works or any sewers, drains and watercourses;

(c) any flooding or increased flooding of any such lands;

(d) any damage to the fishery;

(e) inadequate water quality in any watercourse or other surface waters or in any groundwater,

which is caused by the construction of any of the specified works or any act or omission of the undertaker, its contractors, agents or employees whilst engaged upon the work.

(2) The drainage authority shall give to the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made without the agreement of the undertaker which agreement shall not be unreasonably withheld or delayed.

Commencement Information

I117 Sch. 12 Pt. 1 para. 9 in force at 28.11.2014, see art. 1

10.  The fact that any work or thing has been executed or done by the undertaker in accordance with a plan approved or deemed to be approved by the drainage authority, or to its satisfaction, or in accordance with any directions or award of an arbitrator, shall not relieve the undertaker from any liability under the provisions of this Part of this Schedule. E+W

Commencement Information

I118 Sch. 12 Pt. 1 para. 10 in force at 28.11.2014, see art. 1

11.  Nothing in this Part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and the Environment Agency in respect of land belonging to the undertaker on the date on which the Order is made. E+W

Commencement Information

I119 Sch. 12 Pt. 1 para. 11 in force at 28.11.2014, see art. 1

PART 2 E+W PROTECTION FOR OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

1.—(1) For the protection of any operator, the following provisions shall, unless otherwise agreed in writing between the undertaker and the operator, have effect. E+W

(2) In this Part of this Schedule—

“conduit system” has the same meaning as in the electronic communications code and references to providing a conduit system shall be construed in accordance with paragraph 1(3A) of that code;

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the Communications Act 2003(5);

“electronic communications code network” means—

(a)

so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network which the Secretary of State is providing or proposing to provide;

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

“operator” means the operator of an electronic communications code network.

Commencement Information

I120 Sch. 12 Pt. 2 para. 1 in force at 28.11.2014, see art. 1

2.  Paragraph 23 of Schedule 2 to the Telecommunications Act 1984(6) (which provides a procedure for certain cases where works involve the alteration of electronic communications apparatus), shall apply in relation to the exercise of the powers of article 29 (statutory undertakers). E+W

Commencement Information

I121 Sch. 12 Pt. 2 para. 2 in force at 28.11.2014, see art. 1

3.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or their construction, or of any subsidence resulting from any of those works— E+W

(a) any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works, or other property of an operator); or

(b) there is any interruption in the supply of the service provided by an operator, the undertaker shall bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and shall—

(i) make reasonable compensation to an operator for loss sustained by it; and

(ii) indemnify an operator against claims, demands, proceedings, costs, damages and expenses which may be made or taken against, or recovered from, or incurred by, an operator by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) shall impose any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator shall give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand shall be made without the consent of the undertaker which, if it withholds such consent, shall have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this paragraph shall be referred to and settled by arbitration under article 42 (arbitration) of this Order.

Commencement Information

I122 Sch. 12 Pt. 2 para. 3 in force at 28.11.2014, see art. 1

4.  This Part of this Schedule shall not apply to any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act(7). E+W

Commencement Information

I123 Sch. 12 Pt. 2 para. 4 in force at 28.11.2014, see art. 1

5.  Nothing in this Part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which the Order is made. E+W

Commencement Information

I124 Sch. 12 Pt. 2 para. 5 in force at 28.11.2014, see art. 1

PART 3 E+W FOR THE PROTECTION OF UTILITY UNDERTAKERS

1.  For the protection of the utility undertakers referred to in this Part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned, have effect. E+W

Commencement Information

I125 Sch. 12 Pt. 3 para. 1 in force at 28.11.2014, see art. 1

2.  In this Part of this Schedule— E+W

“alternative apparatus” means alternative apparatus adequate to enable the undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989) belonging to or maintained by that undertaker;

(b)

in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;

(c)

in the case of a water undertaker—

(i)

mains, pipes or other apparatus belonging to, or maintained by, the undertaker for the purposes of water supply; and

(ii)

any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991;

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the undertaker under the Water Industry Act 1991; and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

“utility undertaker” means—

(a)

any licence holder within the meaning of Part 1 of the Electricity Act 1989, save that this shall not include National Grid Electricity Transmission plc or any affiliate or successor body thereof;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986;

(c)

a water undertaker within the meaning of the Water Industry Act 1991; and

(d)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised development landward of mean low water level, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

Commencement Information

I126 Sch. 12 Pt. 3 para. 2 in force at 28.11.2014, see art. 1

3.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act. E+W

Commencement Information

I127 Sch. 12 Pt. 3 para. 3 in force at 28.11.2014, see art. 1

4.  Regardless of any provision in this Order or anything shown on the land plan the undertaker shall not acquire any apparatus other than by agreement. E+W

Commencement Information

I128 Sch. 12 Pt. 3 para. 4 in force at 28.11.2014, see art. 1

5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus shall not be removed under this Part of this Schedule and any right of a utility undertaker to maintain that apparatus in that land shall not be extinguished until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question. E+W

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it shall give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker shall, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and for the subsequent maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question shall, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use all reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule shall be constructed in such manner and in such line or situation as may be agreed between the undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 42 (arbitration).

(5) The utility undertaker in question shall, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 42, and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, shall be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) Sub-paragraph (6) applies to any part of any work necessary in connection with construction of alternative apparatus, or the removal of apparatus required to be removed, as will take place in any land of the undertaker.

(8) Nothing in sub-paragraph (6) shall authorise the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Commencement Information

I129 Sch. 12 Pt. 3 para. 5 in force at 28.11.2014, see art. 1

6.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights shall be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 42 (arbitration). E+W

(2) In settling those terms and conditions in respect of the alternative apparatus to be constructed, the arbitrator shall—

(a) give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the electricity generating station and for securing any subsequent alterations or adaptations of the alternative apparatus which may be required to prevent interference with any proposed works of the undertaker; and

(b) so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator shall make such provision for the payment of compensation by the undertaker to that undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I130 Sch. 12 Pt. 3 para. 6 in force at 28.11.2014, see art. 1

7.—(1) Not less than 28 days before starting the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker shall submit to the utility undertaker in question a plan, section and description of the works to be executed. E+W

(2) Those works shall be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and an officer of the utility undertaker shall be entitled to watch and inspect the execution of those works.

(3) Any requirements made by the utility undertaker under sub-paragraph (2) shall be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 5 and 6 shall apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(5) Nothing in this paragraph shall preclude the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan, section and description.

(6) The undertaker shall not be required to comply with sub-paragraph (1) in a case of emergency but in that case it shall give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and shall comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Commencement Information

I131 Sch. 12 Pt. 3 para. 7 in force at 28.11.2014, see art. 1

8.—(1) If in consequence of the exercise of the powers conferred by this Order the access to any apparatus is materially obstructed the undertaker shall provide such alternative means of access to such apparatus as will enable the undertaker to maintain or use the apparatus no less effectively than was possible before such obstruction. E+W

(2) Subject to the following provisions of this paragraph, the undertaker shall repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 5(2).

(3) There shall be deducted from any sum payable under sub-paragraph (2) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

(4) If in accordance with the provisions of this Part of this Schedule—

(a) apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b) apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 42 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the undertaker in question by virtue of sub-paragraph (2), shall be reduced by the amount of that excess.

(5) For the purposes of sub-paragraph (4)—

(a) an extension of apparatus to a length greater than the length of existing apparatus shall not be treated as placing of apparatus of greater dimensions than those of the existing apparatus; and

(b) where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole shall be treated as if it also had been agreed or had been so determined.

(6) An amount which apart from this sub-paragraph would be payable to an undertaker in respect of works by virtue of sub-paragraph (2) shall, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I132 Sch. 12 Pt. 3 para. 8 in force at 28.11.2014, see art. 1

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 5(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker shall— E+W

(a) bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b) make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker, by reason or in consequence of any such damage or interruption,

F4 ...

(2) Nothing in sub-paragraph (1) shall impose any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker shall give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made without the consent of the undertaker, which, if it withholds such consent, shall have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Textual Amendments

F4 Words in Sch. 12 Pt. 3 para. 9(1) omitted (25.4.2015) by virtue of The Walney Extension Offshore Wind Farm (Correction) Order 2015 (S.I. 2015/1270), art. 1, Sch.

Commencement Information

I133 Sch. 12 Pt. 3 para. 9 in force at 28.11.2014, see art. 1

10.  Nothing in this Part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which the Order is made. E+W

Commencement Information

I134 Sch. 12 Pt. 3 para. 10 in force at 28.11.2014, see art. 1

(1)

S.I. 2010/490. There are amendments to these Regulations which are not relevant to this Order.

(2)

1973 c. 26.

(3)

OJ No L 206, 22.7.1992, p7, last amended by Council Directive 2013/17/EU (OJ No L 158, 10.6.2013, p193).

(4)

S.I. 2002/1355, as amended by S.I. 2011/982. There are amendments to that instrument not relevant to this Order.

(5)

2003 c. 21. There are amendments to this Act, which are not relevant to this Order.

(6)

1984 c. 12, as amended by Schedule 3, paragraphs 1 and 5(a), and (d) to the Communications Act 2003, section 190 of, and Schedule 25, paragraph 68 and Schedule 27, Part 1 to, the Water Act 1989, section 112 (4) of, and Schedule 18 to, the Electricity Act 1989 and section 106(2) of, and Schedule 3 paragraphs 1 and 8 to, the Communications Act 2003.

(7)

1991 c. 22.