Search Legislation

The Morlais Demonstration Zone Order 2021

 Help about what version

What Version

 Help about opening options

Opening OptionsExpand opening options

Status:

This is the original version (as it was originally made). This item of legislation is currently only available in its original format.

Article 45

SCHEDULE 11Protective Provisions

PART 1Protection of electricity, gas, water and sewerage undertakers

1.  The provisions of this Part have effect unless otherwise agreed in writing between the undertaker and the utility undertaker in question.

2.  In this Part—

alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner no less efficient than previously;

“apparatus”—

(a)

in the case of a utility undertaker within paragraph (a) of the definition of that term, means electric lines or electrical plant (as defined in the Electricity Act 1989(1)) belonging to or maintained by the utility undertaker;

(b)

in the case of a utility undertaker within paragraph (b) of the definition of that term, means any mains, pipes or other apparatus belonging to or maintained by the utility undertaker for the purposes of gas supply;

(c)

in the case of a utility undertaker within paragraph (c) of the definition of that term, means mains, pipes or other apparatus belonging to or maintained by the utility undertaker for the purposes of water supply; and

(d)

in the case of a utility undertaker within paragraph (d) of the definition of that term—

(i)

means—

(aa)

any drain or works vested in the utility undertaker under the Water Industry Act 1991; and

(bb)

any sewer that is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act(2) or an agreement to adopt made under section 104 of that Act, and

(ii)

includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works,

and in each case includes any structure in which apparatus is or is to be lodged or that gives or will give access to apparatus;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or on land;

utility undertaker” means—

(a)

any licence holder within the meaning of Part 1 of the Electricity Act 1989;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(3);

(c)

a water undertaker(4); and

(d)

a sewerage undertaker, for the area of the onshore works, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

3.  This Part does not apply to—

(a)apparatus in respect of which relations between the undertaker and the utility undertaker are regulated by Part 3 of the 1991 Act; and

(b)the tidal works.

4.  Despite any provision in this Order or anything shown on the onshore plan, the undertaker must not acquire any apparatus otherwise than by agreement.

5.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this Part, and any right of a utility undertaker to maintain that apparatus in that land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of the utility undertaker in question.

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed and of the proposed position of the alternative apparatus to be provided or constructed; and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3) afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use its best endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 49 (arbitration).

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 49 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part.

(6) Despite sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work in connection with the construction or removal of apparatus in any land of the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction, of the utility undertaker.

(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench), within 300 millimetres of the apparatus.

6.—(1) Where, in accordance with this Part, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted on such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 49 (arbitration).

(2) In settling those terms and conditions in respect of alternative apparatus to be constructed in or along the authorised project, the arbitrator must—

(a)give effect to all reasonable requirements of the undertaker for ensuring the safety and efficient operation of the authorised project and for securing any subsequent alterations or adaptations of the alternative apparatus that may be required to prevent interference with any proposed works of the undertaker; and

(b)so far as it may be reasonable and practicable to do so in the circumstances of the particular case, give effect to the terms and conditions, if any, applicable to the apparatus constructed in or along the authorised project for which the alternative apparatus is to be substituted.

(3) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to the utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

7.—(1) Not less than 28 days before starting the execution of any works of the type referred to in paragraph 5(2) that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under that sub-paragraph, the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it; and the utility undertaker is entitled to watch and inspect the execution of the works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the day on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker, in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency, but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

8.—(1) Subject to the provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by the utility undertaker in, or in connection with—

(a)the inspection, removal and relaying or replacing, alteration or protection of any apparatus or the construction of any new apparatus under this Part (including any costs reasonably incurred or compensation properly paid in connection with the acquisition of rights or exercise of statutory powers for such apparatus);

(b)the cutting off of any apparatus from any other apparatus, or the making safe of any redundant apparatus, in consequence of the exercise by the undertaker of any power under this Order;

(c)the survey of any land, apparatus or works, the inspection, superintendence and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the exercise by the undertaker of any power under this Order; and

(d)any other work or thing rendered reasonably necessary in consequence of the exercise by the undertaker of any such power,

within a reasonable time of being notified by the utility undertaker that it has incurred such expenses.

(2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under this Part, that value being calculated after removal.

(3) If in accordance with this Part—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was, and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 49 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of subparagraph (1) must be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1) must, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount that represents that benefit.

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works referred to in paragraph 5(2) any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided by the utility undertaker, the undertaker must—

(a)bear and pay the cost reasonably incurred by the utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to the utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker, by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker must give the undertaker reasonable notice of any claim or demand and no settlement or compromise must be made without the consent of the undertaker which, if it withholds such consent, must have the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

10.  Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaker in respect of any apparatus laid or erected in land belonging to the undertaker at the date on which this Order is made.

PART 2Protection of Network Rail Infrastructure Limited

11.  The provisions of this Part have effect unless otherwise agreed in writing between the undertaker and Network Rail and, where paragraph 15 applies, any other person on whom rights or obligations are conferred by that paragraph.

12.  In this Part—

construction” includes execution, placing, alteration and reconstruction and “construct” and “constructed” have corresponding meanings;

engineer” means an engineer appointed by Network Rail for the purposes of this Order;

network licence” means the network licence, as the same is amended from time to time, granted to Network Rail by the Secretary of State in exercise of powers under section 8 of the Railways Act 1993(5);

Network Rail” means Network Rail Infrastructure Limited and any associated company of Network Rail Infrastructure Limited that holds property for railway purposes, and for the purpose of this definition “associated company” means any company that is (within the meaning of section 1159 of the Companies Act 2006(6)) the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited;

plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property;

railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993(7)) or station lease;

railway property” means any railway belonging to Network Rail and—

(a)

any station, land, works, apparatus and equipment belonging to Network Rail or connected with any such railway; and

(b)

any easement or other property interest held or used by Network Rail for the purposes of such railway or works, apparatus or equipment;

specified work” means so much of any of the onshore works as is situated on, across, under, over or within 15 metres of, or may in any way affect, railway property.

13.—(1) Where under this Part Network Rail is required to give its consent or approval in respect of any matter, that consent or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures, and any obligations under its network licence or under statute.

(2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must—

(a)co-operate with the undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and

(b)use its reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised project pursuant to this Order.

14.—(1) The undertaker must not exercise the powers conferred by—

(a)article 12 (discharge of water);

(b)article 14 (power to survey and investigate land);

(c)article 22 (power to acquire land);

(d)article 23 (power to acquire rights and impose restrictive covenants);

(e)article 26 (power to acquire subsoil only);

(f)article 28 (temporary use of land for construction of works);

(g)article 29 (temporary use of land for maintenance of works);

(h)article 34 (power to override easements and other rights);

(i)article 35 (private rights over land);

(j)article 40 (power to lop trees overhanging the authorised works and removal of hedgerows);

(k)article 44 and Schedule 10 to the Order (statutory undertakers); or

(l)the powers conferred by section 11(3) of the 1965 Act,

in respect of any railway property unless the exercise of such powers is with the consent of Network Rail.

(2) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the consent of Network Rail.

(3) The undertaker must not exercise the powers conferred by sections 271 or 272 of the 1990 Act, or Schedule 10 to this Order, in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the consent of Network Rail.

(4) The undertaker must not under the powers of this Order acquire or use or acquire new rights over, or seek to impose any restrictive covenants over, any railway property, or extinguish any existing rights of Network Rail in respect of any third party property, except with the consent of Network Rail.

(5) Where Network Rail is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld but may be given subject to reasonable conditions.

15.—(1) The undertaker must before commencing construction of any specified work supply to Network Rail proper and sufficient plans of that work for the reasonable approval of the engineer and the specified work must not be commenced except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration.

(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and if by the end of the period of 28 days beginning with the day on which such plans have been supplied to Network Rail the engineer has not intimated disapproval of those plans and the grounds of disapproval, the undertaker may serve on the engineer written notice requiring the engineer to intimate approval or disapproval within a further period of 28 days beginning with the day on which the engineer receives written notice from the undertaker. If by the expiry of the further period of 28 days the engineer has not intimated approval or disapproval, the engineer is deemed to have approved the plans as submitted.

(3) If by the expiry of 28 days beginning with the day on which written notice was served on the engineer under sub-paragraph (2), Network Rail gives notice to the undertaker that Network Rail desires itself to construct any part of a specified work that in the opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker desires such part of the specified work to be constructed, Network Rail must construct it with all reasonable dispatch on behalf of and to the reasonable satisfaction of the undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph and under the supervision (where appropriate and if given) of the undertaker.

(4) When signifying approval of the plans, the engineer may specify any protective works (whether temporary or permanent) that in the engineer’s opinion should be carried out before commencement of construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using the same (including any relocation, decommissioning and removal of works, apparatus and equipment necessitated by a specified work and the comfort and safety of passengers who may be affected by the specified works), and such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the undertaker, if Network Rail so desires, and such protective works must be carried out at the expense of the undertaker, in either case with all reasonable dispatch, and the undertaker must not commence the construction of the specified works until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction.

16.—(1) Any specified work and any protective works to be constructed by virtue of paragraph 15(4) must, when commenced, be constructed—

(a)with all reasonable dispatch in accordance with the plans approved or deemed to have been approved or settled under paragraph 5;

(b)under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

(c)in such manner as to cause as little damage as is possible to railway property;

(d)so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic on it and the use by passengers of railway property.

(2) If any damage to railway property or any such interference or obstruction is caused by the carrying out of, or in consequence of, the construction of a specified work, the undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss that it may sustain by reason of any such damage, interference or obstruction.

(3) Nothing in this Part imposes any liability on the undertaker with respect to—

(a)any damage, costs, expenses or loss attributable to the negligence of Network Rail or its servants, contractors or agents; or

(b)any liability on Network Rail with respect to any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractor or agents.

17.  The undertaker must—

(a)at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

(b)supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

18.  Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.

19.—(1) If any permanent or temporary alterations or additions to railway property are reasonably necessary in consequence of the construction of a specified work or during a period of 24 months after the completion of that work in order to ensure the safety of railway property or the continued safe and efficient operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail, and if Network Rail gives to the undertaker reasonable notice of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to Network Rail the reasonable cost of those alterations or additions including, in respect of any such alterations and additions as are to be permanent, a capitalised sum representing the increase of the costs that may be expected to be reasonably incurred by Network Rail in maintaining, working and, when necessary, renewing any such alterations or additions.

(2) If during the construction of a specified work by the undertaker, Network Rail gives notice to the undertaker that Network Rail itself desires to construct that part of the specified work that in the opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker decides that part of the specified work is to be constructed, Network Rail must assume construction of that part of the specified work and the undertaker must, notwithstanding any approval of the specified work under paragraph 15(1), pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss that it may suffer by means of the execution by Network Rail of that specified work.

(3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 20(1) provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require.

(4) If the cost of maintaining working or renewing railway property is reduced in consequence of any such alterations or additions, a capitalised sum representing such savings must be set off against any sum payable by the undertaker to Network Rail under this paragraph.

20.  The undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses incurred by Network Rail—

(a)in constructing any part of a specified work on behalf of the undertaker as provided by paragraph 15(3) or in constructing any protective works under paragraph 15(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works;

(b)in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work;

(c)in respect of the employment or procurement of the services of any inspectors, signalmen, watchmen and other persons whom it is reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work;

(d)in respect of any special traffic working resulting from any speed restrictions that may, in the opinion of the engineer, be required to be imposed by reason or in consequence of the construction or failure of a specified work or from the substitution or diversion of services that may be reasonably necessary for the same reason; and

(e)in respect of any additional temporary lighting of railway property in the vicinity of the specified works, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work.

21.—(1) In this paragraph—

EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail apparatus generated by the operation of the onshore works where such interference is of a level that adversely affects the safe operation of Network Rail’s apparatus;

Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the onshore works) that are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications.

(2) This paragraph applies to EMI only to the extent that such EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 5(1) for the relevant part of the onshore works giving rise to EMI (unless the undertaker has been given notice in writing before the approval of those plans of the intention to make such change).

(3) Subject to sub-paragraph (2), the undertaker must in the design and construction of the authorised project take all measures necessary to prevent EMI and must establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness.

(4) In order to facilitate the undertaker’s compliance with sub-paragraph (3)—

(a)the undertaker must consult with Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus that may be at risk of EMI, and thereafter must continue to consult with Network Rail (both before and after formal submission of plans under paragraph 5(1)) in order to identify all potential causes of EMI and the measures required to eliminate them;

(b)Network Rail must make available to the undertaker all information in the possession of Network Rail reasonably requested by the undertaker in respect of Network Rail’s apparatus identified pursuant to paragraph (a); and

(c)Network Rail must allow the undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to paragraph (a).

(5) In any case where it is established that EMI can reasonably be prevented only by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution must be selected in the reasonable discretion of Network Rail, and in relation to such modifications paragraph 5(1) has effect subject to this sub-paragraph.

(6) If, at any time before commencement of regular operation of the onshore works and notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing or commissioning of the authorised project causes EMI, the undertaker must immediately on receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) forthwith cease to use (or procure the cessation of use of) the undertaker’s apparatus causing such EMI until all measures necessary have been taken to remedy such EMI by way of modification to the source of such EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5) to Network Rail’s apparatus).

(7) In the event of EMI having occurred—

(a)the undertaker must afford reasonable facilities to Network Rail for access to the undertaker’s apparatus in the investigation of such EMI;

(b)Network Rail must afford reasonable facilities to the undertaker for access to Network Rail’s apparatus in the investigation of such EMI; and

(c)Network Rail must make available to the undertaker any additional material information in its possession reasonably requested by the undertaker in respect of Network Rail’s apparatus or such EMI.

(8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to subparagraph (5) or (6)—

(a)Network Rail must allow the undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus; and

(b)any modifications to Network Rail’s apparatus approved pursuant to those subparagraphs must be carried out and completed by the undertaker in accordance with paragraph 16.

(9) To the extent that it would not otherwise do so, the indemnity in paragraph 25(1) applies to the costs and expenses reasonably incurred or losses suffered by Network Rail through the implementation of the provisions of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which subparagraph (6) applies.

(10) For the purpose of paragraph 20(1) any modifications to Network Rail’s apparatus under this paragraph is deemed to be protective works referred to in that sub-paragraph.

(11) In relation to any dispute arising under this paragraph the reference in article 49 (arbitration) to the Institution of Civil Engineers shall be read as a reference to the Institution of Engineering and Technology.

22.  If at any time after the completion of a specified work, not being a work vested in Network Rail, Network Rail gives notice to the undertaker informing it that the state of maintenance of any part of the specified work appears to be such as adversely affects the operation of railway property, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect railway property.

23.  The undertaker must not provide any illumination or illuminated sign or signal on or in connection with a specified work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail and it must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway.

24.  Any additional expenses that Network Rail may reasonably incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work must, provided that 56 days’ previous notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to Network Rail.

25.—(1) The undertaker must pay to Network Rail all reasonable costs, charges, damages and expenses not otherwise provided for in this Part that may be occasioned to or reasonably incurred by Network Rail—

(a)by reason of the construction or maintenance of a specified work or its failure; or

(b)by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged on a specified work; and the undertaker must indemnify Network Rail and keep Network Rail indemnified from and against all claims and demands arising out of or in connection with a specified work or any such failure, act or omission; and the fact that any act may have been done by Network Rail on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision does not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under this Part.

(2) Network Rail must give the undertaker reasonable notice of any such claim or demand, and no settlement or compromise of such a claim or demand must be made without the prior consent of the undertaker.

(3) The sums payable by the undertaker under sub-paragraph (1) must include a sum equivalent to the relevant costs.

(4) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums that Network Rail receives under sub-paragraph (1) that relates to the relevant costs of that train operator.

(5) The obligation under sub-paragraph (3) to pay Network Rail the relevant costs is, in the event of default, enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub-paragraph (4).

(6) In this paragraph—

relevant costs” means the costs, direct losses and expenses (including loss of revenue) incurred by each train operator as a consequence of any restriction of the use of Network Rail’s railway network as a result of the construction, maintenance or failure of a specified work, or any such act or omission as mentioned in sub-paragraph (1);

train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993.

26.  Network Rail must, on receipt of a request from the undertaker, from time to time provide to the undertaker free of charge written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Part (including the amount of the relevant costs mentioned in paragraph 25) and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Part (including any claim relating to the relevant costs).

27.  In the assessment of any sums payable to Network Rail under this Part, there must not be taken into account any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Part or increasing the sums so payable.

28.  The undertaker and Network Rail may, subject in the case of Network Rail to compliance with the terms of its network licence, enter into, and carry into effect, agreements for the transfer to the undertaker of—

(a)any railway property shown on the works plans and onshore plan and described in the book of reference;

(b)any lands, works or other property held in connection with any such railway property; and

(c)any rights and obligations (whether or not statutory) of Network Rail relating to any railway property.

29.  Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part 1 of the Railways Act 1993.

30.  The undertaker must, no later than 28 days from the date that the plans are certified by the Welsh Ministers in accordance with article 46 (certification of plans etc.), provide to Network Rail a set of plans that relate to the specified works in the form of a computer disc with read-only memory.

PART 3Protection of operators of electronic communications code networks

31.—(1) The provisions of this Part have effect unless otherwise agreed in writing between the undertaker and the operator.

(2) In this Part—

2003 Act” means the Communications Act 2003;

conduit system” has the same meaning as in the electronic communications code and references to providing a conduit system are to be construed in accordance with paragraph 1(3A) of that code(8);

electronic communications apparatus” has the same meaning as in the electronic communications code;

electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(9);

electronic communications code network” means—

(a)

so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network that the Secretary of State is providing or proposing to provide;

electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

operator” means the operator of an electronic communications code network.

32.  The temporary stopping up or diversion of any street under article 8 (temporary stopping up of streets) does not affect any right of the operator under paragraph 9 of the electronic communications code to maintain any apparatus that, at the time of the stopping up or diversion, is in that street.

33.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised project or its construction, or of any subsidence resulting from any of the project—

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the project), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator, the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply;

(c)make reasonable compensation to an operator for loss sustained by it; and

(d)indemnify an operator against claims, demands, proceedings, costs, damages and expenses that may be made or taken against, or recovered from, or incurred by, an operator by reason, or in consequence of, any such damage or interruption.

(2) Sub-paragraph (1) does not apply to—

(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised project.

(3) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(4) The operator must give the undertaker reasonable notice of any such claim or demand, and no settlement or compromise of the claim or demand may be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(5) Any difference arising between the undertaker and the operator under this Part is to be referred to and settled by arbitration under article 49 (arbitration).

(2)

Section 102(4) was amended by section 96 of the Water Act 2003. Section 104 was amended by section 96 of, and Part 3 of Schedule 9 to, the Water Act 2003 and by section 42(3) of the Flood and Water Management Act 2010 (c. 29).

(3)

1986 c. 44. “Gas transporter” is defined in section 7. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45) and was further amended by section 76 of the Utilities Act 2000.

(4)

“Water undertaker” is defined in Schedule 1 to the Interpretation Act 1978.

(5)

1993 c. 43. Section 8 was amended by paragraph 4 of Schedule 17 and Part 4 of Schedule 31 to the Transport Act 2000 (c. 38), paragraphs 3 and 5 of Schedule 2 to the Railways and Transport Safety Act 2003 (c. 20) and paragraph 3 of Schedule 1 and Part 1 of Schedule 13 to the Railways Act 2005 (c. 14).

(7)

“Access agreement” is defined in section 83.

(8)

Paragraph 1(3A) was added to the code (Schedule 2 to the Telecommunications Act 1984) by paragraph 4 of Schedule 3 to the Communications Act 2003.

(9)

“The electronic communications code” is defined in section 106(1).

Back to top

Options/Help