Status:

This is the original version (as it was originally made). This item of legislation is currently only available in its original format.

SCHEDULES

Articles 2 and 3

SCHEDULE 1AUTHORISED DEVELOPMENT

In the County Borough of Wrexham—

A nationally significant infrastructure project as defined in sections 14 and 15 of the 2008 Act comprising—

Work No. 1A development comprising—

(a)one gas turbine building with up to two gas turbines, and one steam turbine building with one steam turbine, each connected to its own generator with a gross rated electrical output of up to 299 MWe;

(b)up to two exhaust gas emission flue stacks;

(c)up to two Heat Recovery Steam Generator buildings with up to two Heat Recovery Steam Generators (HRSG’s);

(d)air cooled condenser; and

(e)switchgear room.

Work No. 1B development comprising—

(a)a workshop;

(b)telemetry apparatus;

(c)auxiliary distilled fuel oil generator; and

(d)a natural gas pressure regulating installation (PRI) (also known as a gas receiving station and gas treatment compound) within the power station complex containing—

(i)full bore 400mm nominal bore manually and remotely actuated isolation valves;

(ii)bypass valves, slam-shut valves, creep-relief valves and pressure reduction valves;

(iii)gas filters;

(iv)liquid separator;

(v)up to two 100% gas heaters (bath water type);

(vi)gas meter(s);

(vii)non-return and relief valves;

(viii)control and instrument kiosk;

(ix)electricity supply kiosk;

(x)a section of isolated pipe suitable for receiving a pressure inspection gauge (PIG) (also known as PIG launching/receiving facility); and

(xi)high pressure steel pipeline with a nominal bore of 400mm.

Work No. 1C development comprising—

(a)a water treatment system;

(b)a raw/fire water storage tank and up to two water storage tanks; and

(c)an above ground foul water pump station.

Work No. 1D development comprising—

(a)a 132kV switchyard containing plant required to manage the transmission of electricity into the distribution network; and

(b)up to three transformer compounds with up to three transformers.

Work No. 1E development comprising an administration/control building.

Work No. 1F development comprising a heat network interface building.

Work No. 1G development comprising—

(a)security infrastructure, including cameras, perimeter fencing, fencing, gate and a gatehouse;

(b)site lighting infrastructure, including perimeter lighting columns and lights;

(c)internal roadways, car parking, pedestrian network, cycle parking and hardstanding;

(d)foul, surface water and trade effluent drainage (including underground pipework and access chambers);

(e)waste management infrastructure;

(f)electricity, water, wastewater and telecommunications and other services;

(g)site preparation works including earthworks and enabling works and tree removal;

(h)high voltage and low voltage cabling, equipment and controls and associated telemetry and electrical protection auxiliary cabling;

(i)part of underground gas pipeline connection;

(j)other ancillary equipment; and

(k)construction compound.

Work No. 2A development comprising temporary construction laydown and car parking area comprising—

(a)fencing;

(b)tree removal;

(c)lighting infrastructure including lighting columns and lighting;

(d)concrete batching plant;

(e)signage;

(f)security kiosk;

(g)weighbridge;

(h)staff welfare cabins; and

(i)site preparation works including earthworks and enabling works and tree removal.

Work No. 2B development comprising—

(a)creation of a construction laydown and car parking area comprising—

(i)fencing;

(ii)tree removal;

(iii)lighting infrastructure including lighting columns and lighting;

(iv)concrete batching plant;

(v)signage;

(vi)security kiosk;

(vii)weighbridge;

(viii)staff welfare cabins; and

(ix)site preparation works including earthworks and enabling works and tree removal; and

(b)an operational and maintenance laydown area comprising—

(i)hardstanding;

(ii)lighting columns and lights; and

(iii)fencing.

Work No. 3 development comprising—

(a)surface water drainage comprising—

(i)underground pipework;

(ii)access chambers; and

(iii)outfall to Redwither Brook;

(b)tree removal;

(c)landscaping and ecological mitigation; and

(d)construction and maintenance of up to three surface water retention pond(s) providing a total minimum capacity of 2,085m3 and vortex flow control to limit the discharge rate to a maximum of 12.2 litres per second.

Work No. 4 development comprising landscaping, bunding, fencing, boundary treatments, tree planting, habitat creation and ecological mitigation.

Work No. 5 development comprising the alteration of the existing access road to Kingmoor Park, off the east side of Bryn Lane including levelling, regrading and resurfacing,

and such other ancillary buildings, structures, works or operations as are integral to and part of the construction, operation and maintenance of the works in this Schedule 1 but only within the Order limits and insofar as they are unlikely to give rise to any materially new or materially different environmental effects from those assessed in the environmental statement.

Articles 2 and 35

SCHEDULE 2DOCUMENTS AND PLANS TO BE CERTIFIED

Table 1

(1) Document name	(2) Document reference	(3) Revision number	(4) Date
access rights of way plan	2.4	2	September 2016
book of reference	4.3	3	January 2017
design objectives statement, contained within—
design and access statement	5.3	0	March 2016
environmental statement, comprising—
Volume 1: Non-Technical Summary to Environmental Statement (English)	6.1	0	March 2016
Volume 1: Non-Technical Summary to Environmental Statement (Welsh	6.1	0	March 2016
Volume 2: Environmental Statement, Main Statement	6.2	0	March 2016
Volume 3: Environmental Statement Figures	6.3	0	March 2016
Volume 4: Environmental Statement Appendices, amended by:	6.4	0	March 2016
Appendix 14.3: Drainage Strategy	6.4.9	1	November 2016
Appendix 19.1: Draft Construction Environmental Management Plan	6.4.11	2	November 2016
Addendum to Environmental Statement Cumulative Effects Assessment - Electrical Connection	11.8	0	September 2016
illustrative landscape and ecological mitigation master plan	2.9.7 (sheet 1 of 7)	0	March 2016
land plans	2.2	5	January 2017
works plan	2.3	0	March 2016

Articles 2 and 3

SCHEDULE 3REQUIREMENTS

Time limits

1. The authorised development must be commenced within five years of the date that this Order is made.

Detailed design approval

2.—(1) The authorised development must be carried out in accordance with the approved plans, inclusive of any limits of deviation, bearing the references listed below and any other plans, drawings, documents, details, schemes, statements or strategies which are approved by the relevant planning authority pursuant to any requirement (as the same may be amended by approval of the relevant planning authority pursuant to requirement 15(1))—

Table 2

works plan	Submission document reference number 2.3
access rights of way plan	Submission document reference number 2.4

(2) The authorised development must not exceed the maximum parameters specified in Table 3 below (as the same may be amended by approval of the relevant planning authority under requirement 15(1))—

Table 3

(1) Element of authorised development	(2) Maximum height (metres) above a site level of 30 metres AOD	(3) Maximum width (metres)	(4) Maximum length (metres)	(5) Other parameters
Gas turbine building (part of numbered work 1A)	25 metres	45 metres	60 metres	-
Each Heat Recovery Steam Generator Building (part of numbered work 1A)	35 metres	13 metres	25 metres	-
Each exhaust gas emission flue stack (part of numbered work 1A)	50 metres	-	-	Maximum diameter 6.5 metres
Steam turbine building (part of numbered work 1A)	21 metres	26 metres	45 metres	-
Air cooled condenser (part of numbered work 1A)	26 metres	48 metres	48 metres	-
Switchgear room (part of numbered work 1D)	5 metres	10 metres	15 metres	-
Raw/fire water storage tank (part of numbered work 1C)	20 metres	-	-	Maximum diameter 15 metres
Each water storage tank (part of numbered work 1C)	20 metres	-	-	Maximum diameter 5 metres
Water treatment system (part of numbered work 1C)	10 metres	25 metres	20 metres	-
Workshop (part of numbered work 1B)	10 metres	20 metres	30 metres	-
Natural gas pressure regulating installation (PRI) (part of numbered work 1B)	5 metres	25 metres	35 metres	-
Administration/ control building (numbered work 1E)	10 metres	10 metres	20 metres	-
Heat network interface building (numbered work 1F)	15 metres	25 metres	45 metres	-
The first transformer compound (part of numbered work 1D)	6 metres	15 metres	15 metres	-
The second and third transformer compounds (part of numbered work 1D)	6 metres	10 metres	15 metres	-
132kV switchyard (part of work numbered 1D)	10 metres	42 metres	73 metres	-
Perimeter fencing (part of numbered work 1G)	2.5 metres	-	-	-

(3) To the extent that design objectives relating to any numbered work are set out in the design objectives statement, that numbered work must be designed substantially in accordance with the relevant design objective set out therein.

(4) Numbered work 1 and, in respect of the security kiosk and weighbridge only, numbered work 2B may not commence until written details of the following have been submitted to and approved by the relevant planning authority—

(a)the siting, design, external appearance, dimensions and floor levels of all permanent buildings and structures; and

(b)the colour, materials and surface finishes of all permanent buildings and structures.

(5) The details to be submitted for approval under sub-paragraph (4) must include appropriately scaled plans and sectional drawings.

Provision of and implementation and maintenance of landscaping and ecological mitigation

3.—(1) No authorised development may commence until a written landscaping and ecological mitigation scheme has been submitted to and approved by the relevant planning authority. The landscaping and ecological mitigation scheme must be substantially in accordance with the illustrative landscape and ecological mitigation master plan and must include details of all proposed hard and soft landscaping and ecological mitigation works, including—

(a)location, number, species, size and planting density of any proposed planting;

(b)site restoration cultivation, importing of materials including topsoil and subsoil handling and storage in accordance with BS 3882:2015 and other landscape reinstatement operations in accordance with BS 4428:1989 Code of Practice for general Landscape Operations, and the earthworks specification to ensure plant establishment;

(c)proposed finished ground levels;

(d)an arboricultural method statement including details of existing trees and tree groups identified for retention, management and reinforcement with the type and extent of protection to be in accordance with BS 5837: 2012;

(e)implementation timetables for all landscaping works;

(f)surface water attenuation ponds;

(g)the locations of low fertility (where applicable) for invertebrates;

(h)butterfly habitat planting; and

(i)the ecological monitoring and management included in the environmental statement.

(2) The relevant planning authority must consult NRW before determining the landscaping and ecological mitigation scheme under sub-paragraph (1). The procedure set out in paragraph 1 of Schedule 10 (procedure for discharge of requirements) shall apply.

(3) The landscaping and ecological mitigation works must be carried out in accordance with the approved landscaping and ecological mitigation scheme.

(4) The landscaping and ecological mitigation works must be carried out in accordance with implementation timetables approved under sub-paragraph (1).

(5) Any tree or shrub planted as part of the approved landscaping scheme that, within a period of five years after planting, is removed, dies or becomes, in the opinion of the relevant planning authority, seriously damaged or diseased, must be replaced in the first available planting season with a specimen of the same species and size as that originally planted, unless otherwise approved by the relevant planning authority.

(6) The landscaping and ecological mitigation works must be managed and maintained throughout the life of the authorised development to ensure the long term adequacy of the approved landscaping and ecological mitigation scheme.

Construction and Environment Management Plan

4.—(1) No authorised development may commence until a construction and environment management plan has been submitted to and approved by the relevant planning authority. The construction and environment management plan must be substantially in accordance with the draft construction and environment management plan forming part of the environmental statement insofar as it relates to the relevant numbered work and must include the following—

(a)the mechanism for ensuring that all relevant environmental controls and mitigation are incorporated into a construction method statement;

(b)confirmation that no explosive blasting will be carried out during any demolition;

(c)environmental objectives and targets;

(d)environmental monitoring;

(e)roles and responsibilities;

(f)means of communication, record keeping, reporting, auditing and review;

(g)complaints procedures;

(h)nuisance management including measures to avoid or minimise the impacts of construction works (covering dust, lighting, noise and vibration);

(i)details of construction lighting to protect potential foraging/commuting features;

(j)habitats protection measures, including fencing, protection zones for retained trees and bat roosts and means of escape for badgers and other small mammals;

(k)measures to minimise the spread of invasive species;

(l)a site waste management plan;

(m)surface and ground water protection measures (including bunding potential contaminate sources);

(n)a construction drainage strategy;

(o)a methodology for using harvested water where possible;

(p)ecology, landscape and visual impact mitigation to include details of any trees or hedgerows to be removed during construction; and

(q)a protocol in the event that unexpected contaminated land is identified during ground investigation or construction.

(2) The relevant planning authority must consult NRW before determining the construction environment management plan under sub-paragraph (1). The procedure set out in paragraph 1 of Schedule 10 (procedure for discharge of requirements) shall apply.

(3) The construction works must be undertaken in accordance with the approved construction environment management plan.

(4) The undertaker may submit for approval by the relevant planning authority a construction and environment management plan for each of numbered work 1, numbered work 2, numbered work 3, numbered work 4, and numbered work 5 individually, and, in such a case, only those parts of the authorised development forming the numbered work the subject of the construction and environment management plan may be commenced following the approval of such a construction and environment management plan.

Ground investigation

5.—(1) Each of numbered works 1 to 5 must not be commenced until, for that numbered work, a scheme (which may be included in the construction environment management plan) to deal with the contamination of any land, including groundwater, which is likely to cause significant harm to persons or significant pollution of controlled waters or the environment has been submitted to and approved in writing by the relevant planning authority.

(2) The relevant planning authority must consult NRW before determining the scheme under sub-paragraph (1). The procedure set out in paragraph 1 of Schedule 10 (procedure for discharge of requirements) shall apply.

(3) The scheme must include an assessment report, prepared by a specialist consultant, to identify the likely extent of any contamination and any remedial measures that may be required to be taken to render the land fit for its intended purpose, together with a management plan which sets out long-term measures with respect to any contaminants remaining on the site.

(4) Any required remediation must be carried out in accordance with the approved scheme.

Piling

6.—(1) No piling may commence until a piling strategy has been submitted to and approved by the relevant planning authority, such strategy to include a piling risk assessment, the results of such assessment and the piling techniques to be used in carrying out the authorised development.

(2) Piling must be carried out in accordance with the approved strategy.

Fencing and other means of enclosure

7.—(1) No authorised development may commence until details of the proposed fencing and other means of enclosure for the authorised development have been submitted to and approved by the relevant planning authority.

(2) Fencing and other means of enclosure must be carried out in accordance with the approved details.

(3) Any construction sites must remain securely fenced at all times during construction of the authorised development.

(4) The undertaker may submit for approval by the relevant planning authority details of the proposed means of enclosure for each of numbered work 1G, numbered work 2A and numbered work 2B individually and, in such a case, only those parts of the authorised development forming the numbered work the subject of the details of the proposed means of enclosure may be commenced following the approval of such details.

Archaeology

8.—(1) No authorised development may commence until a written scheme setting out the methodology for the investigation of areas of archaeological interest has been submitted to and approved by the relevant planning authority.

(2) The scheme must provide for—

(a)the carrying out of a geophysical survey of greenfield areas within the Order land;

(b)a targeted archaeological investigation of any anomalies that may be identified by the geophysical surveys;

(c)the identification of areas where a watching brief is required; and

(d)the measures to be taken to protect, record or preserve any significant archaeological remains that may be found.

(3) The scheme approved under sub-paragraph (1) must be carried out by a suitably qualified person or body.

(4) Any watching brief must be carried out in accordance with the approved scheme.

(5) The undertaker may submit for approval by the relevant planning authority a scheme for each of numbered work 1, numbered work 2, numbered work 3, numbered work 4, and numbered work 5 individually, and, in such a case, only those parts of the authorised development forming the numbered work the subject of the scheme may be commenced following the approval of such a scheme.

Construction traffic management plan

9.—(1) No authorised development may commence until a construction traffic management plan has been submitted to and approved by the relevant planning authority in consultation with the relevant highway authority. The construction traffic management plan must be substantially in accordance with the draft construction traffic management plan forming part of the environmental statement insofar as it relates to the relevant numbered work and must include the following—

(a)details of a plan to encourage car sharing between construction workers travelling to the site, including details encouraging the use of the routes as set out in the construction vehicle routeing plans referred to in sub-paragraph (b);

(b)construction vehicle routing plans;

(c)details of a HGV vehicle booking management system;

(d)site access plans and 24 hour access arrangements;

(e)proposals for the management of junctions to and crossings of highways and other public rights of way;

(f)proposals for the scheduling and timing of movements of delivery vehicles including details of abnormal indivisible loads together with the staggering of construction workers start and finish times;

(g)pre-notification of deliveries involving abnormal indivisible loads and details of where an appropriately authorised vehicle escort would be required;

(h)proposals for temporary warning signs and banksmen and appropriate escort details (including for horse riders, cyclists and users of the road network and public rights of way);

(i)measures to ensure the protection of users of any footpath within the Order limits which may be affected by the construction of the authorised development (including details of any proposed temporary closures and diversions and notification thereof where necessary);

(j)details of the on-site parking arrangements for construction plant and vehicles; and

(k)proposals for traffic management controls (such as temporary signals), diversion routes and signage required during construction of the authorised development.

(2) The construction traffic management plan must be implemented as approved.

(3) The undertaker may submit for approval by the relevant planning authority a construction traffic management plan for each of numbered work 1, numbered work 2, numbered work 3, numbered work 4, and numbered work 5 individually, and, in such a case, only those parts of the authorised development forming the numbered work the subject of the construction traffic management plan may be commenced following the approval of such a construction traffic management plan.

(4) During the operation of the generating station no abnormal indivisible loads may be transported into or out of the site without the prior written approval of the relevant planning authority in consultation the relevant highways authority.

(5) In this requirement “abnormal indivisible load” has the same meaning as in the Road Vehicles (Authorisation of Special Types) (General) Order 2003(1).

Travel plan during operational phase

10.—(1) Prior to the date of final commissioning a written operational travel plan must be submitted to and approved by the relevant planning authority. Such operational travel plan to include—

(a)objectives and targets; and

(b)measures and initiatives to promote sustainable travel.

(2) The operational travel plan must be carried out as approved.

Construction hours

11.—(1) Construction work for the authorised development must not take place outside the hours of—

(a)07:00 to 19:00 on Monday to Friday; and

(b)07:00 to 13:00 on Saturdays and public holidays.

(2) Sub-paragraph (1) does not prevent construction works being carried out on any Sunday or outside the hours set out in sub-paragraph (1) with the prior written approval of the relevant planning authority.

(3) Nothing in sub-paragraph (1) precludes a start-up period from 06:30 to 07:00 and a shut-down period from 19:00 to 19:30 on weekdays (excluding public holidays) and a start-up period from 06:30 to 07:00 and a shut-down period from 13:00 to 13:30 on Saturdays and public holidays.

Foul and surface water drainage

12.—(1) Numbered works 1, 2 and 3 must not commence until written details of the surface water drainage system and separate written details of the foul water drainage system for the operation of the authorised development have been submitted to and approved by the relevant planning authority. The submitted details must be substantially in accordance with the illustrative foul and surface water drainage strategy.

(2) The relevant planning authority must consult NRW and Dŵr Cymru Welsh Water before determining the details of the surface water drainage system and the foul water drainage system under sub-paragraph (1). The procedure set out in paragraph 1 of Schedule 10 (procedure for discharge of requirements) applies.

(3) The surface water drainage system and the foul water drainage system for the authorised development must be constructed and maintained in accordance with the approved details.

Artificial lighting

13.—(1) No generation of electricity on a commercial basis is to take place until written details of the control of artificial lighting during maintenance and operation of the authorised development have been submitted to and approved by the relevant planning authority, such details to include the timetable for implementation of the artificial lighting and measures to keep external lighting to the minimum necessary for operational safety and security reasons, incorporating cut-offs to reduce light pollution.

(2) The relevant planning authority must consult NRW before determining the details of artificial lighting under sub-paragraph (1). The procedure set out in paragraph 1 of Schedule 10 (procedure for discharge of requirements) shall apply.

(3) The artificial lighting for the authorised development must be implemented in accordance with the approved details.

(4) The undertaker may submit for approval by the relevant planning authority written details of the artificial lighting during maintenance and operation of the authorised development for each of numbered work 1G and numbered work 2B individually forming the numbered work the subject of the written details of the control of artificial lighting and, in such a case, only those parts of the authorised development may be commenced following the approval of such details.

Local economic benefit

14.—(1) No part of the authorised development must commence until a scheme for the promotion of local economic benefit from the authorised development in the County Borough of Wrexham has been submitted to and approved by the relevant planning authority. Such scheme must include—

(a)a commitment on the undertaker to invite to tender companies with addresses in the County Borough of Wrexham as the relevant planning authority may notify to the undertaker in writing;

(b)a methodology for the use of local people and local businesses, where appropriate, in relation to the construction of the authorised development; and

(c)a strategy for the provision of training opportunities for local companies (who are successful under sub-paragraph (a)) or local people who are employed to work on the authorised development under sub-paragraph (b).

(2) The authorised development must be carried out in accordance with the scheme approved under sub-paragraph (1).

Amendments to approved details

15.—(1) Subject to sub-paragraph (2), the undertaker may submit to the relevant planning authority for approval any amendments to any plans, drawings, documents, details, schemes, statements or strategies which require approval by the relevant planning authority pursuant to any requirement (the “Approved Plans, Details or Schemes”). Following any such approval by the relevant planning authority the Approved Plans, Details or Schemes are to be taken to include the amendments approved pursuant to this sub-paragraph (1).

(2) Sub-paragraph (1) does not apply to the works plan or the access rights of way plan.

(3) Approval under sub-paragraph (1) and requirement 2(2) must not be given except where it has been demonstrated to the satisfaction of the relevant planning authority that the subject-matter of the approval sought is unlikely to give rise to any materially new or materially different environmental effects in comparison with the authorised development as approved (as identified in the environmental statement).

Combined heat and power

16.—(1) Prior to the date of final commissioning, a review of potential opportunities for the use of heat from the authorised development must be submitted to and approved by the relevant planning authority.

(2) The review must provide for the on-going monitoring and full exploration of potential opportunities to use heat from the authorised development and for the provision of subsequent reviews of such opportunities as necessary.

(3) Where viable opportunities for the use of heat are identified, a scheme for the provision of the necessary plant and pipework to the boundary of numbered work 1 must be submitted to and approved by the relevant planning authority; any plant and pipework installed up to the boundary of numbered work 1 to enable the use of heat must be installed in accordance with the agreed details.

(4) The undertaker must carry out the on-going monitoring, exploration of potential opportunities to use heat from the authorised development and any subsequent reviews in accordance with the review of potential opportunities approved under sub-paragraph (1).

Decommissioning strategy

17.—(1) Subject to obtaining the necessary consents and unless otherwise agreed with the relevant planning authority, within twenty four months of the Order land ceasing to be used for the purposes of electricity generation (either actively generating electricity or being available to generate electricity on a standby basis), a scheme for the demolition and removal of numbered work 1 must be submitted to the relevant planning authority.

(2) The scheme submitted to the relevant planning authority for approval under sub-paragraph (1) must be substantially in accordance with the construction and environment management plan approved under paragraph 4(1) of this Schedule 3.

(3) The demolition and removal of numbered work 1 must be implemented in accordance with the approved scheme.

(4) On the one year anniversary of the Order land ceasing to be used for the purposes of electricity generation (either actively generating electricity or being available to generate electricity on a standby basis) the undertaker must notify the relevant planning authority of the same.

Requirements for written approval, etc.

18.—(1) Where under any of the above requirements the approval or agreement of the relevant planning authority or any other party is required, that approval or agreement must be provided in writing and must not be unreasonably withheld or delayed.

(2) Where under any of the above requirements a written scheme is required it must be accompanied by such illustrations as are necessary and appropriate in the circumstances.

Date of final commissioning and cessation

19.—(1) The undertaker must notify the relevant planning authority of the date of final commissioning as soon as reasonably practicable and in any event within three months after the occurrence of that date.

(2) The undertaker must notify the relevant planning authority of the date the authorised development permanently ceases to generate power on a commercial basis as soon as reasonably practicable and in any event within three months after the occurrence of that date.

Article 9

SCHEDULE 4STREETS SUBJECT TO PERMANENT ALTERATION OF LAYOUT

Table 4

(1) Area	(2) Street subject to alteration of layout	(3) Description of alteration
In the County Borough of Wrexham	Kingmoor Park Access Road	From line A-B to points C and D shown on the access and rights of way plan improvements to the existing access (the bellmouth of the Kingmoor Park Access Road as shown at line A-B on the access rights of way plan), resurfacing and regrading of the Kingmoor Park Access Road

(1)

Area

(2)

Street subject to alteration of layout

(3)

Description of alteration

In the County Borough of Wrexham

Kingmoor Park Access Road

From line A-B to points C and D shown on the access and rights of way plan improvements to the existing access (the bellmouth of the Kingmoor Park Access Road as shown at line A-B on the access rights of way plan), resurfacing and regrading of the Kingmoor Park Access Road

Article 10

SCHEDULE 5STREETS SUBJECT TO STREET WORKS

Table 5

(1) Area	(2) Streets subject to street works	(3) Description of street works
In the County Borough of Wrexham	Kingmoor Park Access Road	Street works to upgrade the existing access (the bellmouth of the Kingmoor Park Access Road as shown between line A-B on the access rights of way plan) and to upgrade and widen the Kingmoor Park Access Road between line A-B and points C and D on the access rights of way plan
In the County Borough of Wrexham	Oak Road	Street works to horizontally drill a gas pipeline with a nominal bore of 400mm underneath Oak Road
In the County Borough of Wrexham	Maelor Gas Works Access Road and Southern Access Track	Street works to emplace a gas pipeline with a nominal bore of 400mm underneath the Maelor Gas Works Access Road and Southern Access Track

(1)

Area

(2)

Streets subject to street works

(3)

Description of street works

In the County Borough of Wrexham

Kingmoor Park Access Road

Street works to upgrade the existing access (the bellmouth of the Kingmoor Park Access Road as shown between line A-B on the access rights of way plan) and to upgrade and widen the Kingmoor Park Access Road between line A-B and points C and D on the access rights of way plan

In the County Borough of Wrexham

Oak Road

Street works to horizontally drill a gas pipeline with a nominal bore of 400mm underneath Oak Road

In the County Borough of Wrexham

Maelor Gas Works Access Road and Southern Access Track

Street works to emplace a gas pipeline with a nominal bore of 400mm underneath the Maelor Gas Works Access Road and Southern Access Track

Article 11

SCHEDULE 6TEMPORARY PROHIBITION OR RESTRICTION OF THE USE OF STREETS

Table 6

(1) Area	(2) Street subject to temporary prohibition or restriction of use	(3) Extent of temporary prohibition or restriction of use of streets
In the County Borough of Wrexham	Kingmoor Park Access Road	Prohibition/Restriction: Between lines A-B and point D on the access rights of way plan being approximately 111 metres Purpose of the Prohibition/Restriction: Temporary closure of no more than half the width of the Kingmoor Park Access Road at any time in order to carry out numbered works 1-5
In the County Borough of Wrexham	Oak Road	Prohibition/Restriction: Between lines E-F and G-H on the access rights of way plan being approximately 111 metres Purpose of the Prohibition/Restriction: Temporary closure of no more than half the width of Oak Road at any time in order to facilitate development necessary for the authorised development that takes place within the Order land
In the County Borough of Wrexham	Maelor Gas Works Access Road and Southern Access Track	Prohibition/Restriction: Between points K and J and lines L-M on the access rights of way plan being approximately 365 metres Purpose of the Prohibition/Restriction: Temporary closure of no more than half the width of the Maelor Gas Works Access Road and Southern Access Track at any time in order to facilitate development necessary for the authorised development that takes place within the Order land
In the County Borough of Wrexham	Public Right of Way known as ISY/18	Prohibition/Restriction: Between lines P-Q on the access rights of way plan being approximately 64m Purpose of the Prohibition/Restriction: Temporary closure of the Public Right of Way at any time during the construction of numbered works 1-5 as is required to facilitate or is incidental to the carrying out of the authorised development
In the County Borough of Wrexham	Public Right of Way known as SES/25	Prohibition/Restriction: Between lines R-S on the access rights of way plan being approximately 103m Purpose of the Prohibition/Restriction: Temporary closure of the Public Right of Way at any time during the construction of numbered works 1-5 as is required to facilitate or is incidental to the carrying out of the authorised development

Article 18

SCHEDULE 7MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS AND IMPOSITION OF NEW RESTRICTIONS

Compensation enactments

1. The enactments for the time being in force with respect to compensation for the compulsory purchase of land apply, with the necessary modifications as respects compensation, in the case of a compulsory acquisition under this Order of a right by the creation of a new right or the imposition of a restriction as they apply as respects compensation on the compulsory purchase of land and interests in land.

2.—(1) Without prejudice to the generality of paragraph 1, the Land Compensation Act 1973(2) has effect subject to the modifications set out in sub-paragraph (2).

(2) In section 44(1) (compensation for injurious affection), as it applies to compensation for injurious affection under section 7 of the 1965 Act as substituted by paragraph 4—

(a)for the words “land is acquired or taken from” there is substituted the words “a right or restrictive covenant over land is purchased from or imposed on”; and

(b)for the words “acquired or taken from him” there is substituted the words “over which the right is exercisable or the restrictive covenant enforceable”.

3.—(1) Without limitation on the scope of paragraph 1, the Land Compensation Act 1961 has effect subject to the modification set out in sub-paragraph (2).

(2) In section 5A (5A) (relevant valuation date) of the 1961 Act, for (a) and (b) substitute—

“(a)the acquiring authority enters on land for the purpose of exercising a right in pursuance of a notice of entry under section 11(1) of the 1965 Act;

(b)the acquiring authority is subsequently required by a determination under paragraph 13 of Schedule 2A to the 1965 Act (as substituted by paragraph 9 of Schedule 5 to the Wrexham Gas Fired Generating Station Order 2017) to acquire an interest in the land, and”.

Application of the 1965 Act

4.—(1) For the purposes of Article 18 only the 1965 Act is subject to the modifications in sub-paragraph 3(2).

(2) For section 7 of the 1965 Act (measure of compensation) there is substituted the following section—

“7. In assessing the compensation to be paid by the acquiring authority under this Act, regard is had not only to the extent (if any) to which the value of the land over which the right is to be acquired or the restrictive covenant is to be imposed is depreciated by the acquisition of the right or the imposition of the restrictive covenant but also to the damage (if any) to be sustained by the owner of the land by reason of its severance from other land of the owner, or injuriously affecting that other land by the exercise of the powers conferred by this or the special Act.”.

5. The following provisions of the 1965 Act (which state the effect of a deed poll executed in various circumstances where there is no conveyance by persons with interests in the land), that is to say—

(a)section 9(4) (failure by owners to convey);

(b)paragraph 10(3) of Schedule 1 (owners under incapacity);

(c)paragraph 2(3) of Schedule 2 (absent and untraced owners); and

(d)paragraphs 2(3) and 7(2) of Schedule 4 (common land),

are so modified as to secure that, as against persons with interests in the land which are expressed to be overridden by the deed, the right which is to be compulsorily created and acquired or the restrictive covenant which is to be imposed is vested absolutely in the acquiring authority.

6. Section 11 of the 1965 Act (powers of entry) is so modified as to secure that, as from the date on which the acquiring authority has served notice to treat in respect of any right or restrictive covenant it has power, exercisable in equivalent circumstances and subject to equivalent conditions, to enter for the purpose of exercising that right or enforcing that restrictive covenant (which is deemed for this purpose to have been created on the date of service of the notice); and sections 12 (penalty for unauthorised entry) and 13 (entry on warrant in the event of obstruction) of the 1965 Act is modified correspondingly.

7. Section 20 of the 1965 Act (protection for interests of tenants at will, etc.) applies with the modifications necessary to secure that persons with such interests in land as are mentioned in that section are compensated in a manner corresponding to that in which they would be compensated on a compulsory acquisition under this Order, but taking into account only the extent (if any) of such interference with such an interest as is actually caused, or likely to be caused, by the exercise of the right or the enforcement of the restrictive covenant in question.

8. Section 22 of the 1965 Act (protection of acquiring authority’s possession where by inadvertence an estate, right or interest has not been got in) is so modified as to enable the acquiring authority, in circumstances corresponding to those referred to in that section, to continue to be entitled to exercise the right created and acquired and to continue to be entitled to the benefit of the restrictive covenant imposed, subject to compliance with that section as respects compensation.

9. For Schedule 2A to the 1965 Act substitute—

“SCHEDULE 2ACOUNTER-NOTICE REQUIRING PURCHASE OF LAND

Introduction

1. This Schedule applies where an acquiring authority serve a notice to treat in respect of a right over, or restrictive covenant affecting, the whole or part of a house, building or factory and have not executed a general vesting declaration under section 4 of the 1981 Act as applied by article 19 (application of the Compulsory Purchase (Vesting Declarations) Act 1981) in respect of the land to which the notice to treat relates.

2. In this Schedule, “house” includes any park or garden belonging to a house.

Counter-notice requiring purchase of land

3. A person who is able to sell the house, building or factory (“the owner”) may serve a counter-notice requiring the authority to purchase the owner’s interest in the house, building or factory.

4. A counter-notice under paragraph 3 must be served within the period of 28 days beginning with the day on which the notice to treat was served.

Response to counter-notice

5. On receiving a counter-notice, the acquiring authority must decide whether to—

(a)withdraw the notice to treat,

(b)accept the counter-notice, or

(c)refer the counter-notice to the Upper Tribunal.

6. The authority must serve notice of their decision on the owner within the period of 3 months beginning with the day on which the counter-notice is served (“the decision period”).

7. If the authority decide to refer the counter-notice to the Upper Tribunal they must do so within the decision period.

8. If the authority do not serve notice of a decision within the decision period they are to be treated as if they had served notice of a decision to withdraw the notice to treat at the end of that period.

9. If the authority serve notice of a decision to accept the counter-notice, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in the house, building or factory.

Determination by Upper Tribunal

10. On a referral under paragraph 7, the Upper Tribunal must determine whether the acquisition of the right or the imposition of the restrictive covenant would—

(a)in the case of a house, building or factory, cause material detriment to the house, building or factory, or

(b)in the case of a park or garden, seriously affect the amenity or convenience of the house to which the park or garden belongs.

11. In making its determination, the Upper Tribunal must take into account—

(a)the effect of the acquisition of the right or the imposition of the covenant,

(b)the use to be made of the right or covenant proposed to be acquired or imposed, and

(c)if the right or covenant is proposed to be acquired or imposed for works or other purposes extending to other land, the effect of the whole of the works and the use of the other land.

12. If the Upper Tribunal determines that the acquisition of the right or the imposition of the covenant would have either of the consequences described in paragraph 10, it must determine how much of the house, building or factory the authority ought to be required to take.

13. If the Upper Tribunal determines that the authority ought to be required to take some or all of the house, building or factory, the compulsory purchase order and the notice to treat are to have effect as if they included the owner’s interest in that land.

14.—(1) If the Upper Tribunal determines that the authority ought to be required to take some or all of the house, building or factory, the authority may at any time within the period of 6 weeks beginning with the day on which the Upper Tribunal makes its determination withdraw the notice to treat in relation to that land.

(2) If the acquiring authority withdraws the notice to treat under this paragraph they must pay the person on whom the notice was served compensation for any loss or expense caused by the giving and withdrawal of the notice.

(3) Any dispute as to the compensation is to be determined by the Upper Tribunal.”.

Article 26

SCHEDULE 8LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN

Table 7

(1) Location	(2) Number of land shown on land plans	(3) Purpose for which temporary possession may be taken
Land at Kingmoor Park, Wrexham located off the east side of Bryn Lane	PS1A	Temporary use to facilitate construction for numbered works 1-5
Land at Kingmoor Park, Wrexham located off the east side of Bryn Lane	PS1B	Temporary use to facilitate construction for numbered works 1-5
Land at Plum Tree Farm, Isycoed, Wrexham	GC3A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Big Bryn Farm, Isycoed, Wrexham	GC4A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Big Bryn Farm, Isycoed, Wrexham	GC4B	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Big Bryn Farm, Isycoed, Wrexham	GC4C	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Big Bryn Farm, Isycoed, Wrexham	GC4D	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Cae Brynner Farm, Bowling Bank, Wrexham	GC5A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Cae Brynner Farm, Bowling Bank, Wrexham	GC5B	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Cae Brynner Farm, Bowling Bank, Wrexham	GC5D	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Cae Brynner Farm, Bowling Bank, Wrexham	GC5E	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Cae Brynner Farm, Bowling Bank, Wrexham	GC7A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Cae Brynner Farm, Bowling Bank, Wrexham	GC7B	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Cae Brynner Farm, Bowling Bank, Wrexham	GC7C	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land located to the west side of the B5130	GC8A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Higher Oak, Oak Road, Wrexham	GC9B	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Higher Oak, Oak Road, Wrexham	GC9C	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Lower Oak Farm, Bowling Bank, Wrexham	GC10A	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Lower Oak Farm, Bowling Bank, Wrexham	GC10B	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land adjoining Lower Oak Farm, Bowling Bank, Wrexham	GC10C	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC12A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC12B - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC12D - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC12E - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham located to the north of the Maelor Gasworks	SAT1A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham located to the north of the Maelor Gasworks	GC14A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham located to the north of the Maelor Gasworks	GC14B - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham located to the north of the Maelor Gasworks	GC15A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC16A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC16B - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC16C - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land
Land at Pickhill Bridge Farm, Cross Lanes, Wrexham	GC17A - except in relation to that land or those interests held by the Welsh Ministers	Temporary use to facilitate construction of other development necessary for the authorised development that takes place within the Order land

Article 34

SCHEDULE 9PROTECTIVE PROVISIONS

PART 1FOR THE PROTECTION OF NATIONAL GRID

Application

1. For the protection of National Grid as referred to in this part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and National Grid, have effect.

Interpretation

2.—(1) In this Part of this Schedule—

“alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;

“apparatus” means mains, pipes or other apparatus belonging to or maintained by National Grid for the purposes of gas supply;

“authorised development” has the same meaning as in article 2 (interpretation) of this Order and (unless otherwise specified) for the purposes of this Schedule shall include the use and maintenance of the authorised development;

“functions” includes powers and duties;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“National Grid” means National Grid Gas plc (Company No. 02006000) whose registered office is at 1-3 Strand, London, WC2N 5EH; and

“plan” or “plans” include all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe and assess the works to be executed;

“specified work” means so much of any of the works comprised in the authorised development or activities undertaken in association with the authorised development which—

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 5(3) or otherwise; and/or

(b)

include any of the activities that are referred to in paragraph 8 of TP/SSW/22 (National Grid’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, high pressure gas pipelines and associated installation requirements for third parties T/SP/SSW/22”).

(2) Except for paragraphs 3 (apparatus of National Grid in streets subject to temporary prohibition or restriction), 7 (retained apparatus: protection of National Grid as gas undertaker), 8 (expenses) and 9 (indemnity) this Schedule does not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus of National Grid in streets subject to temporary prohibition or restriction

3. Notwithstanding the temporary prohibition or restriction under the powers of article 11 (temporary prohibition or restriction of use of streets), National Grid shall be at liberty at all times to take all necessary access across any such street and/or to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

Acquisition of land

4.—(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to the Order the undertaker must not acquire any land interest or apparatus or override any easement or other interest of National Grid otherwise than by agreement (such agreement not to be unreasonably withheld).

(2) The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Schedule relating to the relocation and/or removal of apparatus (including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid as of right or other use in relation to the apparatus then the provisions in this Schedule shall prevail.

Removal of apparatus

5.—(1) If, in the exercise of the agreement reached in accordance with paragraph 4 or in any other authorised manner, the undertaker acquires any interest in any land in which any apparatus is placed, that apparatus must not be removed under this part of this Schedule and any right of National Grid to maintain that apparatus in that land shall not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraphs (3) to (6) inclusive.

(2) As a condition of agreement between the parties in paragraph 4, prior to the carrying out of any part of the authorised development (or in such other timeframe as may be agreed between the National Grid and the undertaker) that are subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement and/or other legal or land interest of National Grid and/or affects the provisions of any enactment or agreement regulating the relations between National Grid and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid unless otherwise agreed by National Grid, and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised development.

(3) If, for the purpose of executing any works comprised in the authorised development in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid 56 days’ advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker shall, subject to sub-paragraph (4) afford to National Grid to their satisfaction (taking into account paragraph 6 (1) below) the necessary facilities and rights for—

(a)the construction of alternative apparatus in other land of the undertaker; and

(b)subsequently for the maintenance of that apparatus.

(4) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (3), in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.

(5) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this part of this Schedule shall be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.

(6) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (3) or (4), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this part of this Schedule.

Facilities and rights for alternative apparatus

6.—(1) Where, in accordance with the provisions of this part of this Schedule, the undertaker affords to National Grid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights shall be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless agreed by National Grid.

(2) If the facilities and rights to be afforded by the undertaker and agreed with National Grid under sub-paragraph (1) above in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject in the matter shall be referred to arbitration and, the arbitrator shall make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case. In respect of the appointment of an arbitrator under this sub-paragraph (2), article 38 (arbitration) of the Order shall apply.

Retained apparatus: protection of National Grid as Gas Undertaker

7.—(1) Not less than 56 days before the commencement of any specified work that does not require the removal of apparatus under paragraph 5(3) (removal of apparatus) the undertaker must submit to National Grid a plan and seek from National Grid details of the apparatus belonging to or maintained by National Grid.

(2) The plan to be submitted to National Grid under sub-paragraph (1) must show—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant;

(d)the position of all apparatus; and

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus.

(3) The undertaker must not commence any works to which sub-paragraphs (1) and (2) apply until National Grid has given written approval of the plan so submitted.

(4) Any approval of National Grid required under sub-paragraph (2)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (5) or (7); and

(b)must not be unreasonably withheld or delayed.

(5) In relation to any work to which sub-paragraphs (1) and/or (2) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Works to which this paragraph applies must only be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (4), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5) or (7) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.

(7) Where National Grid requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Grid’s satisfaction prior to the commencement of any authorised development (or any relevant part thereof) for which protective works are required and National Grid must give 56 days’ notice of such works from the date of submission of a plan pursuant to this paragraph (except in an emergency).

(8) If National Grid in accordance with sub-paragraphs (5) or (7) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1 to 2 and 4 to 6 apply as if the removal of the apparatus had been required by the undertaker under paragraph 5(2).

(9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the authorised development, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(10) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must—

(a)comply with sub-paragraphs (5), (6) and (7) insofar as is reasonably practicable in the circumstances; and

(b)comply with sub-paragraph (11) at all times.

(11) At all times when carrying out any specified works authorised under the Order the undertaker must comply with National Grid’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” and HSE’s “HS(~G)47 Avoiding Danger from underground services” as the same may be replaced from time to time.

(12) As soon as reasonably practicable after any ground subsidence event attributable to the authorised development the undertaker shall implement an appropriate ground mitigation scheme save that National Grid retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 8.

Expenses

8.—(1) Subject to the following provisions of this paragraph, the undertaker shall pay to National Grid on demand all charges, costs and expenses reasonably anticipated or incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any such works as are referred to in this Schedule including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that National Grid elects to use compulsory purchase powers to acquire any necessary rights under paragraph 5 (4) all costs incurred as a result of such action;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works; and

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Schedule.

(2) There must be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or in default of agreement settled by arbitration in accordance with article 38 (arbitration) of the Order to be necessary, then, if such placing involves cost in the construction of works under this part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) shall be reduced by the amount of that excess save where it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity, dimensions or place at the existing depth in which case full costs shall be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus shall not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole shall be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) shall, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Indemnity

9.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Schedule or in consequence of the construction, use, maintenance or failure of any of the authorised development by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works (including without limitation works carried out by the undertaker under this Schedule or any subsidence resulting from any of these works), any material damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker shall—

(a)bear and pay on demand the cost reasonably incurred by National Grid in making good such damage or restoring the supply; and

(b)indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid.

(2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid as a consequence of the authorised development or under its supervision shall not (unless sub-paragraph (3) applies) excuse the undertaker from liability under the provisions of sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not materially accord with the approved plan or as otherwise agreed between the undertaker and National Grid.

(3) Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents; and

(b)any authorised development and/or any other works authorised by this Schedule carried out by National Grid as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act or under article 6 of the Order subject to the proviso that once such works become apparatus (“new apparatus”), any works yet to be executed and not falling within this sub-section (b) shall be subject to the full terms of this Schedule including this paragraph 9 in respect of such new apparatus.

(4) National Grid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

Enactments and agreements

10. Nothing in this part of this Schedule shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Co-operation

11.—(1) Where in consequence of the proposed construction of any of the authorised development, the undertaker or National Grid requires the removal of apparatus under paragraph 5(3) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 7, the undertaker shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid shall use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever National Grid’s consent, agreement or approval to is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by National Grid, it must not be unreasonably withheld or delayed.

Access

12. If in consequence of the agreement reached in accordance with paragraph 4 (1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Arbitration

13. Save for differences or disputes arising under paragraphs 5(3), 5(5), 6(1) and 7 any difference or dispute arising between the undertaker and National Grid under this Schedule shall, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 38 (arbitration) of the Order.

PART 2FOR THE PROTECTION OF BT GROUP PLC

14.—(1) For the protection of BT Group Plc the following provisions have effect, unless otherwise agreed in writing between the undertaker and BT Group Plc.

(2) In this part of this Schedule—

“the 2003 Act” means the Communications Act 2003((3));

“BT apparatus” means all boxes, cables, poles and plant, associated cabling or ducting or such other electronic communications apparatus as is owned by BT Group Plc;

“BT apparatus map” means a map prepared by BT Group Plc showing the location of BT apparatus in or on the Order land;

“BT Group Plc” means British Telecommunications Public Limited Company (Company No. 01800000) whose registered office is at 81 Newgate Street, London, EC1A 7AJ which is an electronic communications code operator;

“Click Before You Dig” means the team within BT Group Plc charged with providing assistance to members of the general public in order to locate BT apparatus on land and includes any successor team within BT Group Plc with the same remit;

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(4);

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act;

“the highway” includes carriageways, verges, footpaths etc; and

“Network Alterations team” means the team within BT Group Plc charged with carrying out planned diversion and protection works to BT apparatus and includes any successor team within BT Group Plc with the same remit.

15.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—

(a)any damage is caused to any BT apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of BT Group Plc; or

(b)there is any interruption in the supply of the service provided by BT Group Plc,

the undertaker must bear and pay the cost reasonably incurred by BT Group Plc in making good such damage or restoring the supply and make reasonable compensation to BT Group Plc for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of BT Group Plc, its officers, servants, contractors or agents.

(3) BT Group Plc must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and BT Group Plc under this part of this Schedule must be referred to and settled by arbitration under article 38 (arbitration).

16. This part of this Schedule does not apply to—

(a)any BT apparatus in respect of which the relations between the undertaker and BT Group Plc are regulated by the provisions of Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

17. Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and BT Group Plc in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

18. The undertaker must not enter into any underground structures owned by BT Group Plc without authorised BT Group Plc personnel.

19. The undertaker must confirm the location and nature of works arising from the construction of the authorised development which, in the undertaker’s reasonable opinion, are likely to affect BT apparatus within or immediately adjacent to the Order land by contacting the Network Alterations team with detailed plans of the works and to check what alterations to BT apparatus (if any) may be required.

20. Prior to any works commencing or the moving of heavy plant or equipment over BT apparatus within or immediately adjacent to the Order land, the undertaker must confirm details of such BT apparatus with a representative from Click Before You Dig who will provide a map(s) showing the location of BT apparatus within or immediately adjacent to the Order land.

21. In the event that any BT apparatus within or immediately adjacent to the Order land is likely to be placed at risk, either temporarily or permanently because of the movement of plant or equipment or both pursuant to the authorised development, the undertaker must contact a Network Alterations team representative.

22. In the event that works undertaken by the undertaker pursuant to the authorised development necessitate a change in level of the frames and covers comprised within BT apparatus, the undertaker must seek consent from a Network Alterations team representative to carry out such works.

23. Where the BT apparatus map(s) show(s) BT apparatus within or immediately adjacent to the Order land, the undertaker must contact Click Before You Dig before commencing works on or moving plant or equipment onto the Order land, to ensure that any sub-surface BT apparatus can be located and marked up by BT Group Plc.

24. Protection measures for BT apparatus within or immediately adjacent to the Order land and which may be affected by the authorised development must be approved in advance by Click Before You Dig. In carrying out the authorised development, the undertaker must take reasonable care in the protection of BT apparatus comprising optical fibre or co-axial cabling or both and use reasonable endeavours to avoid disturbing BT apparatus.

25. Prior written notice must be provided to Click Before You Dig of any excavating or backfilling proposed by the undertaker around BT apparatus, so that BT Group Plc representatives can attend the Order land if necessary. Unless alternative protection is agreed with Click Before You Dig or a Network Alterations team representative in advance, the normal depth of cover for BT apparatus underground of 350mm in footways and 600mm in carriageways must be maintained by the undertaker. Where the undertaker considers that it can not maintain the relevant depth of BT apparatus, the undertaker must provide written notice to Click Before You Dig, and BT Group Plc may, if reasonable in all the circumstances, within 14 days notify the undertaker in writing that it requires the undertaker to divert the BT apparatus at the undertaker’s expense.

26. All excavation works undertaken by the undertaker immediately adjacent to BT apparatus within or immediately adjacent to the Order land is to be carried out by hand until the extent and location of the BT apparatus is known. Mechanical borers or excavators or both must not be used within 1 metre of BT Apparatus (2 metres if it is a pole) without the prior approval of a BT Group Plc representative.

27. To prevent any movement of BT apparatus within or immediately adjacent to the Order land during any excavation as part of the construction of the authorised development, structural support is to be used as directed by Click Before You Dig or the Network Alteration team if the excavation is—

(a)deeper than the immediately adjacent BT apparatus;

(b)within 1 metre of BT apparatus in stable soil; or

(c)within 5 metres of BT apparatus in unstable soil.

28. The undertaker must notify Click Before You Dig in advance of carrying out any of the following methods of construction or site preparation as part of the authorised development on or in Order land that is immediately adjacent to BT apparatus or on or in Order land within which there is BT apparatus—

(a)pile driving within 10 metres of BT apparatus;

(b)using explosives within 20 metres of BT apparatus; or

(c)using laser equipment within 10 metres of BT apparatus.

29. The undertaker will keep clear and unobstructed access to BT Group Plc manhole and joint box chambers within the Order land.

30. In the event of any damage to BT apparatus, the undertaker must immediately inform a BT Group Plc representative.

PART 3FOR THE PROTECTION OF DŴR CYMRU CYFYNGEDIG

31. For the protection of DCC referred to in this Part 3 of Schedule 9, the following provisions will, unless otherwise agreed in writing between the undertaker and DCC, have effect.

32. In this Part of this Schedule—

“acceptable insurance” means a policy of public liability/third party liability insurance effected and maintained by the undertaker and available in the market on commercially reasonable terms having regard (inter alia) to premiums required and the policy terms obtainable, with a level of insurance cover to be agreed between the undertaker and DCC, during the construction of the works pursuant to this Order with a reputable insurer and with DCC named as an insured party under the policy;

“accessories” has the same meaning as that set out in section 219 WIA 1991 but also includes any feature or aspect of a design that is intended to receive or facilitate the receipt of rainwater or surface water and which is part of a sustainable drainage system;

“DCC apparatus” means all apparatus or accessories vested in or belonging to DCC for the purpose of carrying on its statutory undertaking including reservoirs, water treatment works and waste water treatment works;

“clearance area” means the area of land—

(a)

within 3 metres either side of the centre line of any public sewer or public water main that is less than 300mm in diameter;

(b)

within 6 metres either side of a public sewer or public water main where the public sewer or public water main is between 300mm and 600mm in diameter; or

(c)

within 9 metres either side of the centre line of a rising main;

“DCC” means Dŵr Cymru Cyfyngedig, a limited company registered in Wales under Company No. 2366777 and having its registered office at Pentwyn Road, Nelson, Treharris, Mid Glamorgan CF46 6LY or its properly authorised agents or sub-contractors;

“draft specification” means a detailed plan, cross-section and description of the works to be prepared by the undertaker (including, without limitation, a method statement and risk assessment setting out the intention in respect of the works, construction methods and programmes, position of the affected DCC apparatus and intended works and a statement that to the best of the undertaker’s knowledge, and having used all reasonable care and skill to plan the works, the works will not cause damage to the DCC apparatus);

“functions” has the same meaning as in section 219 WIA 1991 and includes powers and duties;

“in” in a context referring to DCC apparatus in land includes a reference to DCC apparatus under, over or upon land;

“sustainable drainage system” means any structure designed to receive rainwater and other surface water which structure is to include any feature or aspect of design that is intended to receive or facilitate the receipt of rainwater except a public sewer or a natural watercourse;

“WIA 1991” means the Water Industry Act 1991 c.56 as amended; and

“works” means any works forming part of the authorised development in, on, over or under any land purchased, held, or used under this Order that are near to, or will or may in any way affect any DCC apparatus together with all ancillary actions relating hereto.

33.—(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference, the undertaker must not acquire any DCC apparatus or its accessories or override or extinguish any easement or other interest of DCC or acquire any land or other interest of DCC identified in the book of reference or create any new rights over the same otherwise than by agreement with DCC in accordance with the provisions of this Schedule.

(2) Sub-paragraph (1) does not apply to the powers conferred on the undertaker by this Order to interfere temporarily with DCC’s rights to access DCC apparatus or accessories but subject always to each sub-paragraph of paragraphs 37 and 38 of this Part and to the undertaker giving DCC 28 days’ notice of such interference.

Precedence of the WIA 1991

34.—(1) Regardless of any provision of this Order and this Schedule the undertaker must comply fully with all provisions of the WIA 1991 in relation to any use of, any connection with or any actions or omissions which in any way affect the DCC apparatus and nothing in this Order releases the undertaker from the requirement to comply with the provisions of the WIA 1991 in relation to any use of, any connection with or any actions or omissions which in any way affect the DCC apparatus, including without limitation—

(a)sections 41-44 of the WIA 1991 in respect of water main requisitions;

(b)section 45 of the WIA 1991 in respect of any connections to a water main;

(c)sections 98-101 of the WIA 1991 in respect of sewer requisitions;

(d)section 102 of the WIA 1991 in respect of the adoption of sewers and disposal works;

(e)section 104 of the WIA 1991 in respect of the adoption of any sewers, drains or sewage disposal works as part of the development;

(f)sections 106 to 109 of the WIA 1991 (inclusive) in respect of any connections to public sewers;

(g)section 111 of the WIA 1991 in respect of the restrictions on use of public sewers;

(h)sections 158 and 159 of the WIA 1991 in respect of statutory rights of access to DCC apparatus;

(i)section 174 of the WIA 1991 in respect of offences of interference with works etc;

(j)section 178 of the WIA 1991 in respect of obstruction of sewerage works etc; and

(k)section 185 of the WIA 1991 in respect of the removal, diversion or alteration of DCC apparatus.

(2) The arbitration provisions at article 38 or specified in this Schedule do not apply where DCC uses a warrant of entry in accordance with the provisions of the WIA 1991.

Protection of DCC apparatus

35.—(1) Not less than 28 days before starting the execution of any works that are within the clearance area or will, or could reasonably foreseeably affect, any DCC apparatus the removal or alteration of which has not been required by the undertaker under paragraph 34(1)(k), the undertaker must submit to DCC written notice together with a draft specification.

(2) DCC must examine the draft specification submitted under sub-paragraph (1) and give its written consent or proposed amendments (each not to be unreasonably withheld or delayed) to the draft specification (including the proposed commencement date and anticipated completion date) within 28 days from the date of receipt (and in the event of amendments the process in this sub-paragraph (2) must be repeated where those amendments are not accepted). For the avoidance of doubt, DCC’s proposed amendments may include such reasonable requirements for the alteration (including but not limited to the extension of DCC apparatus) or otherwise for the protection of DCC apparatus, or for securing access to it.

(3) Once approved under sub-paragraph (2), the draft specification is to be the specification and the works must be executed only in accordance with the specification and such reasonable requirements as may be made in accordance with sub-paragraph (2) and DCC is entitled to watch and inspect the execution of those works.

(4) Nothing in this paragraph 35 precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a draft specification instead of the draft specification previously submitted, and having done so the provisions of this paragraph 35 apply to and in respect of the new draft specification.

(5) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency provided it has complied with paragraph 36 below save that the undertaker must comply with sub-paragraphs (1) and (3) above in so far as is reasonably practicable in the circumstances.

(6) DCC may opt to carry out any temporary and/or protective works specified under sub-paragraph (2) to DCC apparatus, and if DCC opts to do so it must—

(a)agree the scope and timings of the works with the undertaker (and the undertaker must not unreasonably withhold or delay its agreement to the same);

(b)provide an invoice together with supporting evidence of the estimated costs of the works on the basis of which it must agree with the undertaker the reasonable costs of the works to be met by the undertaker;

(c)following agreement and payment of the costs, DCC must as soon as reasonably practicable carry out and complete the works; and

(d)notify the undertaker immediately in writing upon completion of the temporary and/or protective works.

(7) Only those contractors that satisfy DCC’s reasonable health & safety requirements are permitted to make openings into and/or connections with and/or carry out any works on or within any public sewer or drain vested in DCC unless otherwise agreed with DCC.

(8) Only DCC is permitted to make openings into and/or connections with and/or carry out any works on or within any public water main vested in DCC unless otherwise agreed with DCC.

(9) Where DCC apparatus will be affected by the works the undertaker must determine the exact location of DCC apparatus prior to any works being carried out by the undertaker and the undertaker should contact DCC where trial holes are required and such trial holes must be constructed at the undertaker’s expense.

(10) Any affected DCC apparatus which is no longer required by DCC but is not removed must be transferred to the undertaker by way of a deed of transfer from DCC at the undertaker’s expense and on such terms as DCC reasonably requires.

Suspension of works

36. DCC is entitled to instruct the undertaker to suspend the works if in DCC’s reasonable opinion the actions of the undertaker, or those of its contractor(s) or subcontractor(s) in carrying out the works, have caused damage to any DCC apparatus and/or are likely to cause or result in damage to any DCC apparatus and/or have caused or are likely to cause damage to the environment arising as a result of damage to DCC apparatus. In the event of such instruction being given by DCC—

(a)the undertaker must procure that it and its contractor(s) and subcontractor(s) are to forthwith suspend or cease the works having due regard to health and safety factors and discuss and agree with DCC the remedial actions required prior to resuming the works;

(b)the undertaker and DCC must act reasonably and without delay in discussing and agreeing any remedial actions required prior to resuming the works;

(c)DCC must submit to the undertaker within 5 days following the suspension, a written notice specifying the reasons for suspending the works;

(d)in the event that DCC fails to supply the written notice within 5 days of suspension DCC’s instruction to suspend the works will be void and the undertaker will be entitled to recommence the works;

(e)DCC must commence, carry out and complete any remedial works pursuant to sub-paragraph (a) as soon as reasonably practicable and DCC must give the undertaker notice immediately upon completion of such remedial works and on receipt of such notice the undertaker will be entitled to resume the works; and

(f)DCC is entitled to reclaim all reasonable costs of all remedial works undertaken in accordance with this paragraph 36.

37.—(1) In the event that either the undertaker or DCC (for the purpose of this paragraph 37 “the party” or together “the parties”) wishes to take any action which would impact on the ability of the undertaker to carry out the development or DCC to carry out its statutory functions, the parties must use reasonable endeavours to cooperate with one another in order to align work streams so to minimise or avoid disruption to the other party’s works. In respect of the references to ‘work’ and ‘works’ in this sub-paragraph (1), to the extent that this refers to ‘work’ or ‘works’ to be undertaken by DCC, the definition of works in paragraph 32 of this Part does not apply.

(2) Subject to paragraph 38, differences or disputes arising between the undertaker and DCC under this Schedule must, unless otherwise agreed in writing between the undertaker and DCC, be determined by arbitration in accordance with article 38 (arbitration) of the Order.

Emergency Works

38.—(1) The undertaker is permitted to carry out emergency works provided that it first notifies DCC of the proposed emergency works. For the avoidance of doubt, in the event that DCC suffers any loss, cost or damage as a result of the emergency action taken by the undertaker without prior notification the indemnity in paragraph 40 shall apply.

(2) DCC must at all times be permitted to carry out any emergency works in relation to its DCC apparatus within the Order Limits in accordance with Part II Schedule 6 WIA 1991.

(3) Emergency works required in order for DCC to fulfil its statutory functions under sub-paragraph (2) are to take precedence over works to be carried out by the undertaker and, in such circumstances, the undertaker must reschedule its works accordingly.

(4) In respect of the references to ‘work’ and ‘works’ in this paragraph 38, to the extent that this is ‘work’ or ‘works’ to be undertaken by DCC, the definition of works in paragraph 32 of this Part does not apply.

Insurance

39. The undertaker shall not commence any works under paragraph 35(1) to this Part unless and until the undertaker has procured acceptable insurance.

Damage to DCC apparatus

40.—(1) Subject to sub-paragraphs (3), (4), (5) and (6), the undertaker shall indemnify and hold harmless DCC against all claims demands costs damages expenses penalties and losses which DCC may have or sustain or become liable for in consequence of works under paragraph 35(1) to this Part in respect of—

(a)the commencement, carrying out, execution or retention of the works or any breach of this Part relating to the performance of the works and shall pay compensation for loss, damage or injury caused by the actions or default of the undertaker, its contractors, subcontractors, licensees, agents and invitees relating to the performance of the works;

(b)Damage to the environment caused by the undertaker during any works including but not limited to pollution and/or contamination; and

(c)any breach of any stipulation or otherwise of any deeds of grant (or any renewal of any of the deeds of grant made on substantially the same terms provided that DCC has supplied the undertaker with a copy of the new document) arising from the works.

(2) Subject to sub-paragraphs (3), (4), (5) and (6), the undertaker shall bear and pay the costs reasonably incurred by DCC in making good damage to DCC apparatus or restoring an interruption in the supply provided by DCC.

(3) Nothing in sub-paragraph (1) shall impose any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of DCC, its officers, servants, contractors or agents.

(4) DCC shall give the undertaker reasonable notice of any such claim or demand and no settlement or compromise shall be made without the consent of the undertaker and DCC shall use all reasonable endeavours to mitigate any claims, demand, costs, damages, expenses and losses for which the undertaker may be liable under this paragraph 40.

(5) Neither the undertaker, nor any of its officers, employees or agents shall in any circumstances whatsoever be liable to DCC for any indirect or consequential loss.

(6) Nothing in this Part shall affect the provisions of any enactment or agreement regulating the relations between the undertaker and DCC in respect of any DCC apparatus laid or erected in land belonging to the undertaker on the date on which the Order is made.

PART 4FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

41.—(1) For the protection of any operator referred to in this part of this Schedule (save for BT Group Plc which is protected by Part 2 of this Schedule) the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.

(2) In this part of this Schedule—

“the 2003 Act” means the Communications Act 2003(5);

“BT Group Plc” means British Telecommunications Public Limited Company (Company No. 01800000) whose registered office is at 81 Newgate Street, London, EC1A 7AJ;

“conduit system” has the same meaning as in the electronic communications code and references to providing a conduit system are to be construed in accordance with paragraph 1(3A)(6) of that code;

“electronic communications apparatus” has the same meaning as in the electronic communications code;

“the electronic communications code” has the same meaning as in Chapter 1 of Part 2 of the 2003 Act(7);

“electronic communications code network” means—

(a)

so much of an electronic communications network or conduit system provided by an electronic communications code operator as is not excluded from the application of the electronic communications code by a direction under section 106 of the 2003 Act; and

(b)

an electronic communications network which the Secretary of State is providing or proposing to provide;

“electronic communications code operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act; and

“operator” means the operator of an electronic communications code network.

42.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the authorised development or its construction, or of any subsidence resulting from any of those works—

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this part of this Schedule must be referred to and settled by arbitration under article 38 (arbitration).

43. This part of this Schedule does not apply to—

(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

44. Nothing in this part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 5FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

Application

45. For the protection of the utility undertakers referred to in this Part of this Schedule (save for National Grid which is protected by Part 1 of this Schedule and Wales and West Utilities which is protected by Part 6 of this Schedule) the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertaker(s) concerned.

Interpretation

46. In this Part of this Schedule—

“alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means—

(a)

in the case of an electricity undertaker, electric lines or electrical plant (as defined in the Electricity Act 1989(8)), belonging to or maintained by that utility undertaker;

(b)

in the case of a gas undertaker, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;

(c)

in the case of a water undertaker—

(i)

mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and

(ii)

any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991(9);

(d)

in the case of a sewerage undertaker—

(i)

any drain or works vested in the utility undertaker under the Water Industry Act 1991; and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

“utility undertaker” means—

(e)

any licence holder within the meaning of Part 1 of the Electricity Act 1989(10);

(f)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(11);

(g)

a water undertaker within the meaning of the Water Industry Act 1991(12); and

(h)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

Precedence of 1991 Act in respect of apparatus in streets

47. This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus in streets subject to temporary prohibition or restriction

48. Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary prohibition or restriction of use of streets), a utility undertaker is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

No acquisition etc. except by agreement

49. Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

50.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).

(2) If, for the purpose of executing any works in, on or under any land purchased, leased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 38 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Facilities and rights for alternative apparatus

51.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

52.—(1) Not less than 28 days before starting the execution of any works in, on or under any land purchased, leased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 47, the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 45 to 51 apply as if the removal of the apparatus had been required by the undertaker under paragraph 50(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

53.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 50(2).

(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 38 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 50(2); and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1) if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Expenses and costs

54.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 50(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—

(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

55. Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 6FOR THE PROTECTION OF WALES AND WEST UTILITIES

Application

56. For the protection of Wales and West Utilities as referred to in this part of this Schedule the following provisions shall, unless otherwise agreed in writing between the undertaker and Wales and West Utilities, have effect.

Interpretation

57. In this Part of this Schedule—

“alternative apparatus” means alternative apparatus adequate to enable Wales and West Utilities to fulfil its statutory functions in a manner not less efficient than previously;

“apparatus” means any mains, pipes or other apparatus belonging to or maintained by Wales and West Utilities for the purposes of gas supply;

“functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

“security infrastructure” includes cameras, perimeter fencing, fencing and gates and any other security measures required in order to ensure an appropriate level of security in respect of the authorised development or any apparatus;

“specified work” means so much of any of the works comprised in the authorised development or activities undertaken in association with the authorised development which—

(a)

are in, on or under any land purchased, leased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which is not required under paragraph 61 of this Schedule; and/or

(b)

will or may be situated within 4 metres measured in any direction of any security infrastructure belonging to or maintained by Wales and West Utilities; and/or

(c)

comprise security infrastructure to be located on plot AGI1 shown on the land plans and described in the book of reference; and

“Wales and West Utilities” means Wales and West Utilities Limited (Company No. 05046791) whose registered office is at Wales & West House, Spooner Close, Coedkernew, Newport, South Wales, NP10 8FZ.

Precedence of 1991 Act in respect of apparatus in streets

58. This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Wales and West Utilities are regulated by the provisions of Part 3 of the 1991 Act.

Apparatus in streets subject to temporary prohibition or restriction

59. Regardless of the temporary prohibition or restriction of use of streets under the powers conferred by article 11 (temporary prohibition or restriction of use of streets), Wales and West Utilities is at liberty at all times to take all necessary access across any such street and to execute and do all such works and things in, upon or under any such street as may be reasonably necessary or desirable to enable it to maintain any apparatus which at the time of the prohibition or restriction was in that street.

No acquisition etc. except by agreement

60. Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.

Removal of apparatus

61.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that Wales and West Utilities’ apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Wales and West Utilities to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of Wales and West Utilities in accordance with sub-paragraphs (2) to (5).

(2) If, for the purpose of executing any works in, on or under any land purchased, leased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give Wales and West Utilities written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Wales and West Utilities reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Wales and West Utilities the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, Wales and West Utilities must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Wales and West Utilities and the undertaker or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

(5) Wales and West Utilities, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 38 (arbitration), and after the grant to Wales and West Utilities of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Facilities and rights for alternative apparatus

62.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Wales and West Utilities facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Wales and West Utilities or in default of agreement settled by arbitration in accordance with article 38 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Wales and West Utilities than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Wales and West Utilities as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Retained apparatus

63.—(1) Not less than 42 days before the commencement of any specified work the undertaker must submit to Wales and West Utilities a plan, section and description of the specified work to be executed.

(2) Those specified works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements (including but not limited to the form, location and specification of security infrastructure to be located on plot AGI1 shown on the land plans and described in the book of reference) as may be made in accordance with sub-paragraph (4) by Wales and West Utilities for—

(a)the alteration or otherwise for the protection of the apparatus, or for securing access to it; and/or

(b)the alteration or otherwise for the protection of any security infrastructure belonging to or maintained by Wales and West Utilities; and/or

(c)the provision, construction, installation or erection of any security infrastructure to be located on Plot AGI1 shown on the land plans and in the book of reference.

(3) Wales and West Utilities is entitled to watch and inspect the execution of any specified work.

(4) Any requirements made by Wales and West Utilities under sub-paragraph (2) must be made within a period of 42 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(5) If Wales and West Utilities in accordance with sub-paragraph (4) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 61 and 62 apply as if the removal of the apparatus had been required by the undertaker under paragraph 61(2).

(6) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 28 days before commencing the execution of any specified work, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(7) The undertaker is not required to comply with sub-paragraph (1) in the event of any specified work necessary to maintain—

(a)the authorised development (but only after it has been constructed); or

(b)works undertaken in association with the authorised development on plot AGI1 shown on the land plans and described in the book of reference (but only after such works have been constructed),

in a case of emergency but in that case it must give to Wales and West Utilities notice as soon as is reasonably practicable and a plan, section and description of those specified works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Expenses and costs

64. Subject to the following provisions of this paragraph, the undertaker must repay to Wales and West Utilities the reasonable expenses incurred by Wales and West Utilities in, or in connection with, the inspection, removal, alteration or protection of any apparatus or security infrastructure or the construction of any new apparatus or security infrastructure which may be required in consequence of the execution of any of the works referred to in paragraph 61(2) or any specified work.

65.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 61(2) or any specified work, any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Wales and West Utilities, or there is any interruption in any service provided, or in the supply of any goods, by Wales and West Utilities, the undertaker must—

(a)bear and pay the cost reasonably incurred by Wales and West Utilities in making good such damage or restoring the supply; and

(b)make reasonable compensation to Wales and West Utilities for any other expenses, loss, damages, penalty or costs incurred by the Wales and West Utilities,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Wales and West Utilities, its officers, servants, contractors or agents.

(3) Wales and West Utilities must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Enactments and agreements

66. Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Wales and West Utilities in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

PART 7FOR THE PROTECTION OF THE SOLAR OPERATOR

Application

67. For the protection of the solar operator as referred to in this Part of this Schedule 9, the following provisions will, unless otherwise agreed in writing between the undertaker and the solar operator, have effect.

Interpretation

68. In this Part of this Schedule—

“apparatus” means any solar photovoltaic panels, cables or other apparatus belonging to or maintained by the solar operator for the purposes of electricity generation and for the export of electricity pursuant to the solar farm permission (including but not limited to all reasonably necessary protective equipment for such electricity generation and export of electricity such as security devices and fencing);

“authorised development” has the same meaning as in article 2(1) (interpretation) of this Order and (unless otherwise specified) for the purposes of this Schedule is to include the use and maintenance of the authorised development;

“diversionary agreement” means a contractually binding agreement providing for the passage of a gas pipeline around the solar farm site;

“diversionary planning permission” means any planning permission that may be granted pursuant to the 1990 Act providing for the routing of a gas pipeline to avoid the solar farm site;

“gas pipeline” means a pipeline to carry gas between Maelor Gasworks and Work No. 1;

“in” in a context referring to apparatus in land, includes a reference to apparatus under, over or upon land;

“solar farm permission” means full planning permission granted on 31 July 2015 by Wrexham Country Borough Council for the apparatus (Ref P/2015/0287) including any planning permission granted pursuant to an application to vary any condition of planning permission (Ref P/2015/0287) under section 73 of the 1990 Act;

“solar farm site” means the site on which planning permission was granted by the solar farm permission;

“solar operator” means the operator from time to time of the solar farm on the solar farm site which has consent pursuant to the solar farm permission; and

“specified work” means so much of any of the works comprised in the authorised development or works required to facilitate or which are incidental to the authorised development (including, but without limitation, the gas pipeline) which are in, on or under any land purchased, leased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus.

Removal of apparatus

69.—(1) If, for the purpose of executing any specified work, the undertaker requires the removal of any apparatus in the solar farm site, the undertaker must give the solar operator written notice of that requirement, together with a plan and section of the work proposed and a plan, section and description of the specified work to be executed with written confirmation of the extent to which the removed apparatus can be reinstated as soon as reasonably practicable following completion of the execution of the specified work.

(2) Within 56 days of receipt of the written notice referred to in sub-paragraph (1) the solar operator must proceed without unnecessary delay to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

(3) Regardless of anything in sub-paragraph (2), the undertaker may, in the notice issued under sub-paragraph (1), give notice to the solar operator that it desires itself to execute any work, or part of any work, in connection with the removal of apparatus in any of plots GC12, GC12A and GC12B as identified on the land plans, and where such notice is given that work, instead of being executed by the solar operator, must be executed by the undertaker within 56 days of the solar operator receiving such notice.

(4) Where notice is given in the circumstances described in sub-paragraph (3), the undertaker must provide the solar operator with the opportunity to supervise any work, or part of any work, in connection with the removal of apparatus but if the solar operator does not provide any superintendence within the required 56 days, then the undertaker may proceed to execute the works.

(5) Nothing in sub-paragraphs (3) or (4) authorises the undertaker to execute the connection or disconnection of any apparatus. In carrying out any works under sub-paragraph (3) or (4), the undertaker must comply with all statutory obligations which would have been applicable had the works been carried out by the solar operator and the undertaker must ensure that the works are carried out by persons competent and suitably qualified to carry out such works.

(6) Where the undertaker has served written notice in accordance with sub-paragraph (1) the solar operator must proceed to disconnect any apparatus to be removed without delay upon written request from the undertaker.

(7) Where the undertaker has served written notice in accordance with sub-paragraph (1), the solar operator must, within 56 days of receipt of such notice, give written notice to the undertaker whether it requires the undertaker to reinstate the removed apparatus in accordance with such reasonable requirements as the solar operator may specify and if no notice is received by the undertaker, the undertaker is under no obligation to reinstate the removed apparatus.

Retained apparatus

70.—(1) Not less than 56 days before the commencement of any specified work that does not require the removal of apparatus under paragraph 69 (removal of apparatus) the undertaker must submit to the solar operator a plan, section and description of the specified work to be executed.

(2) Those specified works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (4) by the solar operator for the alteration or otherwise for the protection of the apparatus, or for securing access to it.

(3) The solar operator is entitled to watch and inspect the execution of any specified work.

(4) Any requirements made by the solar operator under sub-paragraph (2) must be made within a period of 21 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(5) If the solar operator in accordance with sub-paragraph (4) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraph 69 (removal of apparatus) applies as if the removal of the apparatus had been required by the undertaker under paragraph 69(1).

(6) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of any specified work, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(7) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the solar operator notice as soon as is reasonably practicable and a plan, section and description of those specified works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Expenses and costs

71.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to the solar operator the reasonable expenses incurred by the solar operator in, or in connection with, the inspection, removal, reinstatement, alteration or protection of any apparatus which may be required in consequence of the execution of any of any of the works referred to in paragraph 69 or any specified work.

(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed and not reinstated under the provisions of this Part of this Schedule, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration (as provided for in paragraph 74 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the solar operator by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(5) An amount which apart from this sub-paragraph would be payable to the solar operator in respect of works by virtue of sub-paragraph (1) if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer the solar operator any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

72.—(1) Subject to sub-paragraphs (2) and (3), if by reason of or in consequence of the construction of any of the works referred to in paragraphs 69 or 70 or any specified work, any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of the solar operator, or there is any interruption in any service provided, or in the supply of any goods, by the solar operator, the undertaker must—

(a)bear and pay the cost reasonably incurred by the solar operator in making good such damage or restoring the supply; and

(b)make reasonable compensation to the solar operator for any other expenses, loss, damages, penalty or costs incurred by the solar operator,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of the solar operator, its officers, servants, contractors or agents.

(3) The solar operator must give the undertaker reasonable notice of any claim or demand pursuant to sub-paragraph (1) above and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Co-operation

73. Where in consequence of the proposed construction of any of the authorised development or any specified work, the solar operator makes requirements for the protection or removal of apparatus under paragraphs 69(4) or 69(5), the undertaker shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and/or any specified work and taking into account the need to ensure the safe and efficient and economic operation of the apparatus and the solar operator shall use its best endeavours to co-operate with the undertaker for that purpose.

Arbitration

74. Any difference or dispute arising between the undertaker and the solar operator under this Part of this Schedule shall, unless otherwise agreed in writing between the undertaker and the solar operator, be determined by arbitration in accordance with article 38 (arbitration).

Enactments and agreements

75. Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and the solar operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Compulsory acquisition and temporary use

76.—(1) The rights set out in sub-paragraph (2) are not exercisable by the undertaker over the solar farm site if—

(a)a diversionary agreement has been concluded; and

(b)a diversionary planning permission has been granted which authorises the construction of a gas pipeline over the route to which the diversionary agreement applies; and

(c)the land has been acquired by the undertaker under the diversionary agreement.

(2) Sub-paragraph (1) applies to the following rights—

(a)article 17 (compulsory acquisition of land);

(b)article 18 (compulsory acquisition of rights etc);

(c)article 22 (acquisition of subsoil only);

(d)article 24 (private rights);

(e)article 25 (rights under or over streets);

(f)article 26 (temporary use of land for carrying out the authorised development);

(g)article 27 (temporary use of land for maintaining the authorised development); and

(h)article 28 (statutory undertakers).

Article 37

SCHEDULE 10PROCEDURE FOR DISCHARGE OF REQUIREMENTS

1.—(1) Where an application has been made to the relevant authority for any consent, agreement or approval required by a requirement (including agreement or approval in respect of part of a requirement) included in this Order the relevant authority must give notice to the undertaker of their decision on the application within a period of eight weeks beginning with—

(a)the day immediately following that on which the application is received by the authority;

(b)the day immediately following that on which further information has been supplied by the undertaker under paragraph 2; or

(c)such longer period as may be agreed by the undertaker and the relevant authority in writing.

(2) Subject to sub-paragraph (3), in the event that the relevant authority does not determine an application within the period set out in sub-paragraph (1), the relevant authority is to be taken to have granted all parts of the application (without any condition or qualification) at the end of that period.

(3) Where—

(a)an application has been made to the relevant planning authority for any consent, agreement or approval required by a requirement included in this Order;

(b)the relevant planning authority does not determine such application within the period set out in sub-paragraph (1); and

(c)such application is accompanied by a report that considers it likely that the subject matter of such application will give rise to any materially new or materially different environmental effects in comparison with the authorised development as approved, then the application is to be taken to have been refused by the relevant planning authority at the end of that period.

(4) Where any application is made as described in sub-paragraph (1), the undertaker must include a statement in such application that refers to the timeframe for consideration of the application and the consequences of failure to meet that timeframe as prescribed by sub-paragraphs (1), (2) and (3).

(5) Where an application is made to the relevant planning authority for any consent, agreement or approval required by requirements 3(1), 4(1), 5(1), 12(1) or 13(1) (including agreement or approval in respect of part of a requirement), the undertaker must at the same time as making the application send a copy of the materials provided in support of the application to NRW and, in respect of requirement 12(1) only, Dŵr Cymru Cyfyngedig, and must draw NRW and Dŵr Cymru Cyfyngedig’s attention to the procedure set out in paragraphs 1 to 3 of this Schedule and state that any comments must be provided to the relevant planning authority within 21 days if they are to be considered by the relevant planning authority.

(6) Where an application is made to the relevant planning authority for any consent, agreement or approval required by requirements 3(1), 4(1), 5(1), 12(1) or 13(1) (including agreement or approval in respect of part of a requirement), the relevant planning authority is not required to consider comments received from NRW and, in respect of requirement 12(1) only, Dŵr Cymru Cyfyngedig more than 21 days after the date of the application.

(7) Where an application is made to the relevant planning authority for any consent, agreement or approval required by an article or requirement in this Order and the relevant planning authority intends to consult NRW and Dŵr Cymru Cyfyngedig in relation to that application, the undertaker must as soon as reasonably practicable comply with any direction from the relevant planning authority to provide a copy of the materials provided in support of the application to each body specified in the direction.

Further information

2.—(1) In relation to any part of the application to which this Schedule applies, the relevant authority has the right to request such further information from the undertaker as is necessary to enable it to consider the application.

(2) In the event that it considers such further information to be necessary the relevant authority must, within twenty one days of receipt of the application, notify the undertaker in writing specifying the further information required and (if applicable) to which part of the application it relates. In the event that the relevant authority does not give such notification within this twenty one day period it is deemed to have sufficient information to consider the application and thereafter is not entitled to request further information without the prior agreement of the undertaker.

(3) Where further information is requested under this paragraph 2 in relation to part only of an application, that part is to be treated as separate from the remainder of the application for the purposes of calculating time periods in paragraph 1(1)(b), paragraph 1(3) and this paragraph 2.

Appeals

3.—(1) The undertaker may appeal in the event that—

(a)the relevant authority refuses (including a deemed refusal pursuant to paragraph 1(3)) an application for any consent, agreement or approval required by an article or requirement included in this Order or grants it subject to conditions;

(b)on receipt of a request for further information pursuant to paragraph 2 the undertaker considers that either the whole or part of the specified information requested by the relevant authority is not necessary for consideration of the application; or

(c)on receipt of any further information requested, the relevant authority notifies the undertaker that the information provided is inadequate and requests additional information which the undertaker considers is not necessary for consideration of the application.

(2) The appeal process is to be as follows—

(a)The undertaker must submit the appeal documentation to the Secretary of State and must on the same day provide copies of the appeal documentation to the relevant authority and any article or requirement consultee (together with the undertaker, these are the “appeal parties”);

(b)The Secretary of State must appoint a person as soon as reasonably practicable after receiving the appeal documentation and must forthwith notify the appeal parties of the identity of the appointed person and the address to which all correspondence for his attention should be sent;

(c)The relevant authority and any requirement consultee must submit written representations to the appointed person in respect of the appeal within twenty six days of the appointment of the person pursuant to sub-paragraph (b) and must ensure that copies of their written representations are sent to each other and to the undertaker on the day on which they are submitted to the appointed person;

(d)The appeal parties must make any counter-submissions to the appointed person within twenty six days of receipt of written representations pursuant to sub-paragraph (c) above; and

(e)The appointed person must make his decision and notify it to the appeal parties, with reasons, as soon as reasonably practicable and in any event within forty days of the deadline for the receipt of counter-submissions pursuant to sub-paragraph (d).

The appointment of the person pursuant to sub-paragraph (b) may be undertaken by a person appointed by the Secretary of State for this purpose instead of by the Secretary of State.

(3) In the event that the appointed person considers that further information is necessary to enable him to consider the appeal he must, within twelve days of his appointment, notify the appeal parties in writing specifying the further information required.

(4) Any further information required pursuant to sub-paragraph (3) must be provided by the undertaker to the appointed person, the relevant authority and any requirement consultee on the date specified by the appointed person (the “specified date”), and the appointed person must notify the appeal parties of the revised timetable for the appeal on or before that day. The revised timetable for the appeal must require submission of written representations to the appointed person within fourteen days of the specified date but must otherwise be in accordance with the process and time limits set out in sub-paragraph (2)(c) to (e).

(5) On an appeal under this paragraph, the appointed person may—

(a)allow or dismiss the appeal; or

(b)reverse or vary any part of the decision of the relevant authority (whether the appeal relates to that part of it or not),

and may deal with the application as if it had been made to him in the first instance.

(6) The appointed person may take into account written representations that have been sent outside of the relevant time limits but the appointed person must proceed to a decision within the time limits set by this Schedule.

(7) The appointed person may proceed to a decision even though no written representations have been made within the relevant time limits, if it appears to him that there is sufficient material to enable a decision to be made on the merits of the case.

(8) The decision of the appointed person on an appeal is to be final and binding on the parties, and a court may entertain proceedings for questioning the decision only if the proceedings are brought by a claim for judicial review.

(9) If an approval is given by the appointed person pursuant to this Schedule, it is deemed to be an approval for the purpose of Schedule 1 (authorised development) of this Order as if it had been given by the relevant authority. The relevant authority may confirm any determination given by the appointed person in identical form in writing but a failure to give such confirmation (or a failure to give it in identical form) is not to be taken to affect or invalidate the effect of the appointed person’s determination.

(10) Save where a direction is given pursuant to sub-paragraph (11) requiring the costs of the appointed person to be paid by the relevant authority, the reasonable costs of the appointed person must be met by the undertaker.

(11) On application by the relevant authority or the undertaker, the appointed person may give directions as to the costs of the appeal parties and as to the parties by whom the costs of the appeal are to be paid. In considering whether to make any such direction and the terms on which it is to be made, the appointed person must have regard to Planning Practice Guidance: Appeals (March 2014) or any circular or guidance which may from time to time replace it.

4. In this Schedule “relevant authority” means the relevant planning authority, relevant highway authority, traffic authority, street authority, or the owner of a watercourse, sewer or drain as may be appropriate to the consent, agreement or approval sought.

(1)

S.I. 2003/1998.

(2)

1973 c.26.

(3)

2003 c.21.

(4)

See section 106.

(5)

2003 c.21.

(6)

Paragraph 1(3A) was inserted by section 106(2) of, and paragraphs 1 and 4 of Schedule 3 to, the Communications Act 2003.

(7)

See section 106.

(8)

1989 c. 29; Section 64 was amended by the Utilities Act 2000 (c.27); Section 108, and Schedule 6, paragraphs 24, 38(1), and (3).

(9)

1991 c.56.

(10)

1989 c. 29.

(11)

1986 c. 44; Section 48 amended by Gas Act 1995 (c.45); Section 10(1), and by Schedule 3, paragraph 54(1)(h) and by the Utilities Act 2000 (c.27); Section 108, and Schedule 6, Part I, paragraphs 1, and 2(1).

(12)

1991 c.56.

legislation.gov.uk

Search Legislation

The Wrexham Gas Fired Generating Station Order 2017

You are here:

What Version

Opening Options

More Resources

Status:

SCHEDULES

SCHEDULE 1AUTHORISED DEVELOPMENT

SCHEDULE 2DOCUMENTS AND PLANS TO BE CERTIFIED

Table 1

SCHEDULE 3REQUIREMENTS

Time limits

Detailed design approval

Table 2

Table 3

Provision of and implementation and maintenance of landscaping and ecological mitigation

Construction and Environment Management Plan

Ground investigation

Piling

Fencing and other means of enclosure

Archaeology

Construction traffic management plan

Travel plan during operational phase

Construction hours

Foul and surface water drainage

Artificial lighting

Local economic benefit

Amendments to approved details

Combined heat and power

Decommissioning strategy

Requirements for written approval, etc.

Date of final commissioning and cessation

SCHEDULE 4STREETS SUBJECT TO PERMANENT ALTERATION OF LAYOUT

Table 4

SCHEDULE 5STREETS SUBJECT TO STREET WORKS

Table 5

SCHEDULE 6TEMPORARY PROHIBITION OR RESTRICTION OF THE USE OF STREETS

Table 6

SCHEDULE 7MODIFICATION OF COMPENSATION AND COMPULSORY PURCHASE ENACTMENTS FOR CREATION OF NEW RIGHTS AND IMPOSITION OF NEW RESTRICTIONS

Compensation enactments

Application of the 1965 Act

“SCHEDULE 2ACOUNTER-NOTICE REQUIRING PURCHASE OF LAND

Introduction

Counter-notice requiring purchase of land

Response to counter-notice

Determination by Upper Tribunal

SCHEDULE 8LAND OF WHICH TEMPORARY POSSESSION MAY BE TAKEN

Table 7

SCHEDULE 9PROTECTIVE PROVISIONS

PART 1FOR THE PROTECTION OF NATIONAL GRID

Application

Interpretation

Apparatus of National Grid in streets subject to temporary prohibition or restriction

Acquisition of land

Removal of apparatus

Facilities and rights for alternative apparatus

Retained apparatus: protection of National Grid as Gas Undertaker

Expenses

Indemnity

Enactments and agreements

Co-operation

Access

Arbitration

PART 2FOR THE PROTECTION OF BT GROUP PLC

PART 3FOR THE PROTECTION OF DŴR CYMRU CYFYNGEDIG

Precedence of the WIA 1991

Protection of DCC apparatus

Suspension of works

Emergency Works

Insurance

Damage to DCC apparatus

PART 4FOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

PART 5FOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

Application

Interpretation

Precedence of 1991 Act in respect of apparatus in streets

Apparatus in streets subject to temporary prohibition or restriction

No acquisition etc. except by agreement