Search Legislation

The Keadby 3 (Carbon Capture Equipped Gas Fired Generating Station) Order 2022

 Help about what version

What Version

 Help about advanced features

Advanced Features

 Help about opening options

Opening OptionsExpand opening options

Changes over time for: SCHEDULE 10

 Help about opening options

Alternative versions:

Status:

Point in time view as at 29/12/2022.

Changes to legislation:

There are currently no known outstanding effects for the The Keadby 3 (Carbon Capture Equipped Gas Fired Generating Station) Order 2022, SCHEDULE 10. Help about Changes to Legislation

Article 35

SCHEDULE 10E+W+SPROTECTIVE PROVISIONS

PART 1E+W+SFOR THE PROTECTION OF NATIONAL GRID AS ELECTRICITY AND GAS UNDERTAKER

ApplicationE+W+S

1.—(1) For the protection of National Grid as referred to in this Part of this Schedule the following provisions have effect, unless otherwise agreed in writing between the undertaker and National Grid.

(2) Subject to sub-paragraph (3) or to the extent otherwise agreed in writing between the undertaker and National Grid, where the benefit of this Order is transferred or granted to another person under article 7 (consent to transfer benefit of the Order)—

(a)any agreement of the type mentioned in subparagraph (1) has effect as if it had been made between National Grid and the transferee or grantee (as the case may be); and

(b)written notice of the transfer or grant must be given to National Grid on or before the date of that transfer or grant.

(3) Sub-paragraph (2) does not apply where the benefit of the Order is transferred or granted to National Grid.

Commencement Information

I1Sch. 10 para. 1 in force at 29.12.2022, see art. 1

InterpretationE+W+S

2.  In this Part of this Schedule—

1991 Act” means the New Roads and Street Works Act 1991(1);

acceptable credit provider” means a bank or financial institution with a credit rating that is not lower than: (i) “A-” if the rating is assigned by Standard & Poor’s Ratings Group or Fitch Ratings; and “A3” if the rating is assigned by Moody’s Investors Services Inc.;

acceptable insurance” means a third party liability insurance effected and maintained by the undertaker with a limit of indemnity of not less than £100,000,000 (one hundred million pounds) per occurrence or series of occurrences arising out of one event. Such insurance shall be maintained for the construction period of the authorised works which constitute specified works and arranged with an internationally recognised insurer of repute operating in the London and worldwide insurance market underwriters whose security/credit rating meets the same requirements as an “acceptable credit provider”, such policy shall include (but without limitation):

(a)

National Grid Electricity Transmission Plc and National Grid Gas Plc as a Co-Insured;

(b)

a cross liabilities clause; and

(c)

contractors’ pollution liability for third party property damage and third party bodily damage arising from a pollution/contamination event with cover of £10,000,000.00 (ten million pounds) per event or £20,000,000.00 (twenty million pounds) in aggregate;

acceptable security” means either:

(a)

a parent company guarantee from a parent company in favour of National Grid Electricity Transmission Plc and National Grid Gas Plc to cover the undertaker’s liability to National Grid Electricity Transmission Plc and National Grid Gas Plc to a total liability cap of £100,000,000.00 one hundred million pounds) (in a form reasonably satisfactory to National Grid and where required by National Grid, accompanied with a legal opinion confirming the due capacity and authorisation of the parent company to enter into and be bound by the terms of such guarantee); or

(b)

a bank bond or letter of credit from an acceptable credit provider in favour of National Grid Electricity Transmission Plc and National Grid Gas Plc to cover the undertaker’s liability to National Grid Electricity Transmission Plc and National Grid Gas Plc for an amount of not less than £10,000,000.00 (ten million pounds) per asset per event up to a total liability cap of £100,000,000.00 (one hundred million pounds) (in a form reasonably satisfactory to the National Grid);

alternative apparatus” means appropriate alternative apparatus to the satisfaction of National Grid to enable National Grid to fulfil its statutory functions in a manner no less efficient than previously;

apparatus” means:

(a)

any electric lines or electrical plant as defined in the Electricity Act 1989, belonging to or maintained by National Grid;

(b)

any mains, pipes or other apparatus belonging to or maintained by National Grid for the purposes of gas supply;

together with any replacement apparatus and such other apparatus constructed pursuant to this Order that becomes operational apparatus of National Grid for the purposes of transmission, distribution and/or supply and includes any structure in which apparatus is or will be lodged or which gives or will give access to apparatus;

authorised works” has the same meaning as is given to the term “authorised development” in article 2(1) of this Order and includes any associated development authorised by this Order and for the purposes of this Part of this Schedule includes the use and maintenance of the authorised works and construction of any works authorised by this Schedule;

“commence” and “commencement” in this Part of this Schedule shall include any below ground surveys, monitoring, ground work operations or the receipt and erection of construction plant and equipment;

deed of consent” means a deed of consent, crossing agreement, deed of variation or new deed of grant agreed between the parties acting reasonably in order to vary or replace existing easements, agreements, enactments and other such interests so as to secure land rights and interests as are necessary to carry out, maintain, operate and use the apparatus in a manner consistent with the terms of this Part of this Schedule;

functions” includes powers and duties;

ground mitigation scheme” means a scheme approved by National Grid (such approval not to be unreasonably withheld or delayed) setting out the necessary measures (if any) for a ground subsidence event;

ground monitoring scheme” means a scheme for monitoring ground subsidence which sets out the apparatus which is to be subject to such monitoring, the extent of land to be monitored, the manner in which ground levels are to be monitored, the timescales of any monitoring activities and the extent of ground subsidence which, if exceeded, shall require the undertaker to submit for National Grid’s approval a ground mitigation scheme;

ground subsidence event” means any ground subsidence identified by the monitoring activities set out in the ground monitoring scheme that has exceeded the level described in the ground monitoring scheme as requiring a ground mitigation scheme;

“in” in a context referring to apparatus or alternative apparatus in land includes a reference to apparatus or alternative apparatus under, over, across, along or upon such land;

“maintain” and “maintenance” shall include the ability and right to do any of the following in relation to any apparatus or alternative apparatus of National Grid including construct, use, repair, alter, inspect, renew or remove the apparatus;

National Grid” means:

(a)

National Grid Electricity Transmission Plc (Company Number 2366977) whose registered office is at 1-3 Strand, London, WC2N 5EH or any successor as a licence holder within the meaning of Part 1 of the Electricity Act 1989; and

(b)

National Grid Gas plc (Company Number 02006000) whose registered office is at 1-3 Strand, London, WC2N 5EH or any successor as a gas transporter within the meaning of Part 1 of the Gas Act 1986;

parent company” means a parent company of the undertaker acceptable to and which shall have been approved by National Grid acting reasonably;

undertaker” means the undertaker as defined in article 2(1) of this Order;

specified works” means any of the authorised works or activities undertaken in association with the authorised works which:

(a)

will or may be situated over, or within 15 metres measured in any direction of any apparatus the removal of which has not been required by the undertaker under paragraph 7(2) or otherwise; and/or

(b)

may in any way adversely affect any apparatus the removal of which has not been required by the undertaker under paragraph 7(2) or otherwise; and/or

(c)

includes any of the activities that are referred to in paragraph 8 of T/SP/SSW/22 (National Grid’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW/22and/or activity that is referred to in development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”.

Commencement Information

I2Sch. 10 para. 2 in force at 29.12.2022, see art. 1

On Street ApparatusE+W+S

3.  Except for paragraphs 4 (Apparatus of National Grid in stopped up streets), 8 (retained apparatus: protection) and 9 (retained apparatus: protection), 10 (expenses) and 11 (indemnity) of this Schedule which will apply in respect of the exercise of all or any powers under this Order affecting the rights and apparatus of National Grid, the other provisions of this Schedule do not apply to apparatus in respect of which the relations between the undertaker and National Grid are regulated by the provisions of Part 3 of the 1991 Act.

Commencement Information

I3Sch. 10 para. 3 in force at 29.12.2022, see art. 1

Apparatus of National Grid in stopped up streetsE+W+S

4.—(1) Where any street is permanently stopped up under this Order, if National Grid has any apparatus in the street or accessed via that street National Grid has the same rights in respect of that apparatus as it enjoyed immediately before the stopping up and the undertaker must grant to National Grid, or procure the granting to National Grid of, legal easements reasonably satisfactory to National Grid in respect of such apparatus and access to it prior to the stopping up of any such street or highway but nothing in this paragraph affects any right of the undertaker or National Grid to require the removal of that apparatus under paragraph 7 or the power of the undertaker, subject to compliance with this sub-paragraph, to carry out works under paragraph 9.

(2) Notwithstanding the temporary stopping up or diversion of any highway pursuant to Article 13 (Agreement with street authorities), National Grid is at liberty at all times to take all necessary access across any such stopped up highway and to execute all such works and things in, upon, or under any such highway as may be reasonable necessary or desirable to enable it to maintain any apparatus which at the time of the stopping up or diversion was in that highway.

Commencement Information

I4Sch. 10 para. 4 in force at 29.12.2022, see art. 1

Protective works to buildingsE+W+S

5.—(1) The undertaker, in the case of the powers conferred by article 34 (protective work to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any apparatus without the written consent of National Grid and, if by reason of the exercise of those powers any damage to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal or abandonment) or property of National Grid or any interruption in the supply of electricity by National Grid is caused, the undertaker must bear and pay on demand the cost reasonably incurred by National Grid in making good such damage or restoring the supply; and, subject to sub-paragraph (2), shall—

(a)pay compensation to National Grid for any loss sustained by it; and

(b)indemnify National Grid against all claims, demands, proceedings, costs, damages and expenses which may be made or taken against or recovered from or incurred by that undertaker, by reason of any such damage or interruption.

(2) Nothing in this paragraph imposes any liability on the undertaker with respect to any damage or interruption to the extent that such damage or interruption is attributable to the act, neglect or default of National Grid or its contractors or workmen; and National Grid will give to the undertaker reasonable notice of any claim or demand as aforesaid and no settlement or compromise thereof shall be made by National Grid, save in respect of any payment required under a statutory compensation scheme, without first consulting the undertaker and giving the undertaker an opportunity to make representations as to the claim or demand.

Commencement Information

I5Sch. 10 para. 5 in force at 29.12.2022, see art. 1

Acquisition of landE+W+S

6.—(1) Regardless of any provision in this Order or anything shown on the land plans or contained in the book of reference to this Order, the undertaker may not (a) appropriate or acquire any apparatus or (b) appropriate, acquire, extinguish, interfere with or override any easement, other interest or right and/or apparatus of National Grid otherwise than by agreement (such agreement not to be unreasonably withheld).

(2) As a condition of an agreement between the parties in sub-paragraph (1), prior to the carrying out of any part of the authorised works (or in such other timeframe as may be agreed between National Grid and the undertaker) that is subject to the requirements of this Part of this Schedule that will cause any conflict with or breach the terms of any easement or other legal or land interest of National Grid or affect the provisions of any enactment or agreement regulating the relations between National Grid and the undertaker in respect of any apparatus laid or erected in land belonging to or secured by the undertaker, the undertaker must as National Grid reasonably requires enter into such deeds of consent upon such terms and conditions as may be agreed between National Grid and the undertaker acting reasonably and which must be no less favourable on the whole to National Grid or the undertaker unless otherwise agreed by National Grid and/or the undertaker (as applicable), and it will be the responsibility of the undertaker to procure and/or secure the consent and entering into of such deeds and variations by all other third parties with an interest in the land at that time who are affected by such authorised works.

(3) The undertaker and National Grid agree that where there is any inconsistency or duplication between the provisions set out in this Part of this Schedule relating to the relocation and/or removal of apparatus/including but not limited to the payment of costs and expenses relating to such relocation and/or removal of apparatus) and the provisions of any existing easement, rights, agreements and licences granted, used, enjoyed or exercised by National Grid and/or other enactments relied upon by National Grid as of right or other use in relation to the apparatus, then the provisions in this Schedule shall prevail.

(4) Any agreement or consent granted by National Grid under paragraph 8 or 9 or any other paragraph of this Part of this Schedule, shall not be taken to constitute agreement under sub-paragraph (1).

Commencement Information

I6Sch. 10 para. 6 in force at 29.12.2022, see art. 1

Removal of apparatusE+W+S

7.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in or possesses temporarily any land in which any apparatus is placed, that apparatus must not be removed under this Part of this Schedule and any right of National Grid to maintain that apparatus in that land must not be extinguished until alternative apparatus has been constructed, and is in operation to the reasonable satisfaction of National Grid in accordance with sub-paragraph (2) to (5).

(2) If, for the purpose of executing any authorised works in, on, under or over any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, it must give to National Grid advance written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order National Grid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), secure any necessary consents for the alternative apparatus and afford to National Grid to its reasonable satisfaction (taking into account paragraph 8(1) below) the necessary facilities and rights—

(a)for the construction of alternative apparatus in other land of or land secured by the undertaker; and

(b)subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of or land secured by the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2) in the land in which the alternative apparatus or part of such apparatus is to be constructed, National Grid must, on receipt of a written notice to that effect from the undertaker, take such steps as are reasonable in the circumstances in an endeavour to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for National Grid to use its compulsory purchase powers to this end unless it elects to so do.

(4) Any alternative apparatus to be constructed in land of or land secured by the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between National Grid and the undertaker.

(5) National Grid must, after the alternative apparatus to be provided or constructed has been agreed, and subject to a written diversion agreement having been entered into between the parties and the grant to National Grid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Commencement Information

I7Sch. 10 para. 7 in force at 29.12.2022, see art. 1

Facilities and rights for alternative apparatusE+W+S

8.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to or secures for National Grid facilities and rights in land for the construction, use, maintenance and protection of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and National Grid and must be no less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed unless otherwise agreed by National Grid.

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are less favourable on the whole to National Grid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject the matter may be referred to arbitration in accordance with paragraph 16 (Arbitration) of this Part of this Schedule and the arbitrator must make such provision for the payment of compensation by the undertaker to National Grid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I8Sch. 10 para. 8 in force at 29.12.2022, see art. 1

Retained apparatus: protection of electricity undertakerE+W+S

9.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Grid a plan of the works to be executed and seek from National Grid details of the underground extent of their electricity tower foundations.

(2) In relation to works which will or may be situated on, over, under or within (i) 15 metres measured in any direction of any apparatus, or (ii) involve embankment works within 15 metres of any apparatus, the plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus;

(f)any intended maintenance regimes; and

(g)an assessment of risks of rise of earth issues.

(3) In relation to any works which will or may be situated on, over, under or within 10 metres of any part of the foundations of an electricity tower or between any two or more electricity towers, the plan to be submitted under sub-paragraph (1) must, in addition to the matters set out in sub-paragraph (2), include a method statement describing—

(a)details of any cable trench design including route, dimensions, clearance to pylon foundations;

(b)demonstration that pylon foundations will not be affected prior to, during and post construction;

(c)details of load bearing capacities of trenches;

(d)details of any cable installation methodology including access arrangements, jointing bays and backfill methodology;

(e)a written management plan for high voltage hazard during construction and ongoing maintenance of any cable route;

(f)written details of the operations and maintenance regime for any cable, including frequency and method of access;

(g)assessment of earth rise potential if reasonably required by National Grid’s engineers; and

(h)evidence that trench bearing capacity is to be designed to support overhead line construction traffic of at least 26 tonnes in weight.

(4) The undertaker must not commence any works to which sub-paragraphs (2) or (3) apply until National Grid has given written approval of the plan so submitted.

(5) Any approval of National Grid required under sub-paragraphs (4)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (6) or (8); and,

(b)must not be unreasonably withheld or delayed.

(6) In relation to any work to which sub-paragraphs (2) or (3) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage, for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(7) Works executed under sub-paragraphs (2) or (3) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub-paragraph (6), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (6) or (8) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.

(8) Where under sub-paragraph (6) National Grid requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Grid’s satisfaction prior to the commencement of any authorised development (or any relevant part thereof) for which protective works are required and National Grid shall give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

(9) If National Grid in accordance with sub-paragraphs (6) or (8) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1, 2 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).

(10) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the authorised development, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph shall apply to and in respect of the new plan.

(11) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (6), (7) and (8) insofar as is reasonably practicable in the circumstances and comply with sub-paragraph (12) at all times.

(12) At all times when carrying out any works authorised under this Order, the undertaker must comply with National Grid’s policies for development near overhead lines EN43-8 and HSE’s guidance note 6 “Avoidance of Danger from Overhead Lines”.

Commencement Information

I9Sch. 10 para. 9 in force at 29.12.2022, see art. 1

Retained apparatus: protection of gas undertakerE+W+S

10.—(1) Not less than 56 days before the commencement of any specified works the undertaker must submit to National Grid a plan and, if reasonably required by National Grid, a ground monitoring scheme in respect of those works.

(2) The plan to be submitted to National Grid under sub-paragraph (1) must include a method statement and describe—

(a)the exact position of the works;

(b)the level at which these are proposed to be constructed or renewed;

(c)the manner of their construction or renewal including details of excavation, positioning of plant etc;

(d)the position of all apparatus;

(e)by way of detailed drawings, every alteration proposed to be made to or close to any such apparatus; and

(f)any intended maintenance regimes.

(3) The undertaker must not commence any works to which sub-paragraphs (1) and (2) apply until National Grid has given written approval of the plan so submitted.

(4) Any approval of National Grid required under sub-paragraph (3)—

(a)may be given subject to reasonable conditions for any purpose mentioned in sub-paragraphs (5) or (6); and,

(b)must not be unreasonably withheld.

(5) In relation to any work to which sub-paragraphs (1) and/or (2) apply, National Grid may require such modifications to be made to the plans as may be reasonably necessary for the purpose of securing its apparatus against interference or risk of damage for the provision of protective works or for the purpose of providing or securing proper and convenient means of access to any apparatus.

(6) Works executed under sub-paragraphs (1) or (2) must be executed in accordance with the plan, submitted under sub-paragraph (1) or as relevant sub paragraph (5), as approved or as amended from time to time by agreement between the undertaker and National Grid and in accordance with such reasonable requirements as may be made in accordance with sub-paragraphs (5) or (7) by National Grid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and National Grid will be entitled to watch and inspect the execution of those works.

(7) Where National Grid requires any protective works to be carried out by itself or by the undertaker (whether of a temporary or permanent nature) such protective works, inclusive of any measures or schemes required and approved as part of the plan approved pursuant to this paragraph, must be carried out to National Grid’s satisfaction prior to the commencement of any specified works for which protective works are required and National Grid must give notice of its requirement for such works within 42 days of the date of submission of a plan pursuant to this paragraph (except in an emergency).

(8) If National Grid in accordance with sub-paragraphs (4) or (6) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 1, 2 and 6 to 8 apply as if the removal of the apparatus had been required by the undertaker under paragraph 7(2).

(9) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 56 days before commencing the execution of the specified works, a new plan, instead of the plan previously submitted, and having done so the provisions of this paragraph will apply to and in respect of the new plan.

(10) The undertaker will not be required to comply with sub-paragraph (1) where it needs to carry out emergency works as defined in the 1991 Act but in that case it must give to National Grid notice as soon as is reasonably practicable and a plan of those works and must comply with sub-paragraphs (5), (6) and (7) insofar as is reasonably practicable in the circumstances and comply with sub paragraph (11) at all times.

(11) At all times when carrying out any works authorised under this Order National Grid must comply with National Grid’s policies for safe working in proximity to gas apparatus “Specification for safe working in the vicinity of National Grid, High pressure Gas pipelines and associated installation requirements for third parties T/SP/SSW22” and HSE’s “HS(~G)47 Avoiding Danger from underground services”.

(12) As soon as reasonably practicable after any ground subsidence event attributable to the authorised development the undertaker shall implement an appropriate ground mitigation scheme save that National Grid retains the right to carry out any further necessary protective works for the safeguarding of its apparatus and can recover any such costs in line with paragraph 11.

Commencement Information

I10Sch. 10 para. 10 in force at 29.12.2022, see art. 1

ExpensesE+W+S

11.—(1) Save where otherwise agreed in writing between National Grid and the undertaker and subject to the following provisions of this paragraph, the undertaker must pay to National Grid within 30 days of receipt of an itemised invoice or claim from National Grid all charges, costs and expenses reasonably anticipated within the following three months or reasonably and properly incurred by National Grid in, or in connection with, the inspection, removal, relaying or replacing, alteration or protection of any apparatus or the construction of any new or alternative apparatus which may be required in consequence of the execution of any authorised works including without limitation—

(a)any costs reasonably incurred by or compensation properly paid by National Grid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation all costs incurred by National Grid as a consequence of National Grid;

(i)using its own compulsory purchase powers to acquire any necessary rights under paragraph 7(3); or

(ii)exercising any compulsory purchase powers in this Order transferred to or benefitting National Grid;

(b)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus, where no written diversion agreement is otherwise in place;

(c)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(d)the approval of plans;

(e)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works and;

(f)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule.

(2) There will be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule and which is not re-used as part of the alternative apparatus, that value being calculated after removal.

(3) If in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was situated,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with paragraph 16 (arbitration) of this Part of this Schedule to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to National Grid by virtue of sub-paragraph (1) will be reduced by the amount of that excess save to the extent that it is not possible in the circumstances to obtain the existing type of apparatus at the same capacity and dimensions or place at the existing depth in which case full costs will be borne by the undertaker.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus will not be treated as a placing of apparatus of greater dimensions than those of the existing apparatus; and

(b)where the provision of a joint in a pipe or cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole will be treated as if it also had been agreed or had been so determined.

(5) Any amount which apart from this sub-paragraph would be payable to National Grid in respect of works by virtue of sub-paragraph (1) will, if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on National Grid any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, be reduced by the amount which represents that benefit.

Commencement Information

I11Sch. 10 para. 11 in force at 29.12.2022, see art. 1

IndemnityE+W+S

12.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any works authorised by this Part of this Schedule or in consequence of the construction, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by him) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Part of this Schedule or any subsidence resulting from any of these works, any damage is caused to any apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of the authorised works) or property of National Grid, or there is any interruption in any service provided, or in the supply of any goods, by National Grid, or National Grid becomes liable to pay any amount to any third party, the undertaker will—

(a)bear and pay on demand the cost reasonably and properly incurred by National Grid in making good such damage or restoring the supply; and

(b)indemnify National Grid for any other expenses, loss, demands, proceedings, damages, claims, penalty or costs incurred by or recovered from National Grid, by reason or in consequence of any such damage or interruption or National Grid becoming liable to any third party as aforesaid and including Network Code Claims other than arising from any default of National Grid.

(2) The fact that any act or thing may have been done by National Grid on behalf of the undertaker or in accordance with a plan approved by National Grid or in accordance with any requirement of National Grid or under its supervision will not (unless sub-paragraph (3) applies), excuse the undertaker from liability under the provisions of this sub-paragraph (1) unless National Grid fails to carry out and execute the works properly with due care and attention and in a skilful and workman like manner or in a manner that does not accord with the approved plan.

(3) Nothing in sub-paragraph (1) shall impose any liability on the undertaker in respect of—

(a)any damage or interruption to the extent that it is attributable to the neglect or default of National Grid, its officers, servants, contractors or agents;

(b)any authorised works and/or any other works authorised by this Part of this Schedule carried out by National Grid as an assignee, transferee or lessee of the undertaker with the benefit of the Order pursuant to section 156 of the 2008 Act or article 7 (consent to transfer benefit of the order) subject to the proviso that once such works become apparatus (“new apparatus”), any authorised works yet to be executed and not falling within this sub-section 3(b) will be subject to the full terms of this Part of this Schedule including this paragraph 12.

(4) National Grid must give the undertaker reasonable notice of any such third party claim or demand and no settlement, or compromise must, unless payment is required in connection with a statutory compensation scheme, be made without first consulting the undertaker and considering their representations.

(5) National Grid must, in respect of any matter covered by the indemnity given by the undertaker in this paragraph, at all times act reasonably and in the same manner as it would as if settling third party claims on its own behalf from its own funds.

(6) National Grid must use its reasonable endeavours to mitigate and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph applies where it is within National Grid’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of National Grid’s control and if reasonably requested to do so by the undertaker National Grid must provide an explanation of how the claim has been minimised, where relevant.

(7) The undertaker must not commence construction (and not permit the commencement of such construction) of the authorised works on any land owned by National Grid or in respect of which National Grid has an easement or wayleave for its apparatus or any other interest or to carry out any works within 15 metres of National Grid’s apparatus until the following conditions are satisfied:

(a)unless and until National Grid is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has first provided the acceptable security (and provided evidence that it shall maintain such acceptable security for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Grid has confirmed the same to the undertaker in writing; or

(b)unless and until National Grid is satisfied acting reasonably (but subject to all necessary regulatory constraints) that the undertaker has procured acceptable insurance (and provided evidence to National Grid that it shall maintain such acceptable insurance for the construction period of the authorised works from the proposed date of commencement of construction of the authorised works) and National Grid has confirmed the same in writing to the undertaker.

(8) In the event that the undertaker fails to comply with paragraph 11(7) of this Part of this Schedule, nothing in this Part of this Schedule shall prevent National Grid from seeking injunctive relief (or any other equitable remedy) in any court of competent jurisdiction.

Commencement Information

I12Sch. 10 para. 12 in force at 29.12.2022, see art. 1

Enactments and agreementsE+W+S

13.  Save to the extent provided for to the contrary elsewhere in this Part of this Schedule or by agreement in writing between National Grid and the undertaker, nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and National Grid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.

Commencement Information

I13Sch. 10 para. 13 in force at 29.12.2022, see art. 1

Co-operationE+W+S

14.—(1) Where in consequence of the proposed construction of any part of the authorised works, the undertaker or National Grid requires the removal of apparatus under paragraph 7(2) or National Grid makes requirements for the protection or alteration of apparatus under paragraph 9 or 10, the undertaker shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised works and taking into account the need to ensure the safe and efficient operation of National Grid’s undertaking and National Grid shall use its best endeavours to co-operate with the undertaker for that purpose.

(2) For the avoidance of doubt whenever National Grid’s consent, agreement or approval is required in relation to plans, documents or other information submitted by the undertaker or the taking of action by the undertaker, it must not be unreasonably withheld or delayed.

Commencement Information

I14Sch. 10 para. 14 in force at 29.12.2022, see art. 1

AccessE+W+S

15.  If in consequence of the agreement reached in accordance with paragraph 6(1) or the powers granted under this Order the access to any apparatus is materially obstructed, the undertaker must provide such alternative means of access to such apparatus as will enable National Grid to maintain or use the apparatus no less effectively than was possible before such obstruction.

Commencement Information

I15Sch. 10 para. 15 in force at 29.12.2022, see art. 1

ArbitrationE+W+S

16.  Save for difference or dispute arising under paragraph 7(2), 7(4), 8(1), 9 and 10 any difference or dispute arising between the undertaker and National Grid under this Part of this Schedule must, unless otherwise agreed in writing between the undertaker and National Grid, be determined by arbitration in accordance with article 44 (arbitration).

Commencement Information

I16Sch. 10 para. 16 in force at 29.12.2022, see art. 1

NoticesE+W+S

17.  Notwithstanding article 42 (service of notices), any plans submitted to National Grid by the undertaker pursuant to this Part of this Schedule must be sent to National Grid Plant Protection at plantprotection@nationalgrid.com or such other address as National Grid may from time to time appoint instead for that purpose and notify to the undertaker in writing.

Commencement Information

I17Sch. 10 para. 17 in force at 29.12.2022, see art. 1

PART 2E+W+SFOR THE PROTECTION OF CANAL AND RIVER TRUST

InterpretationE+W+S

18.—(1) For the protection of the Canal and River Trust the following provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and the Canal and River Trust.

(2) In this Part of this Schedule—

Code of Practice” means the Code of Practice for Works Affecting the Canal and River Trust (April 2022) or any updates or amendments thereto;

construction”, in relation to any specified work or protective work, includes—

(a)

the execution and placing of that work; and

(b)

any relaying, renewal, or maintenance of that work as may be carried out during the period of 24 months from the completion of that work; and “construct” and “constructed” have corresponding meanings;

Canal and River Trust’s network” means the Canal and River Trust’s network of waterways;

detriment” means any damage to the waterway or any other property of the Canal and River Trust caused by the presence of the authorised development and, without prejudice to the generality of that meaning, includes—

(a)

any obstruction of, or interference with, or hindrance or danger to, navigation or to any use of the waterway (including towing paths);

(b)

the erosion of the bed or banks of the waterway, or the impairment of the stability of any works, lands or premises forming part of the waterway;

(c)

the deposit of materials or the siltation of the waterway so as to damage the waterway;

(d)

the pollution of the waterway;

(e)

any significant alteration in the water level of the waterway, or significant interference with the supply of water thereto, or drainage of water therefrom;

(f)

any harm to the ecology of the waterway (including any adverse impact on any site of special scientific interest comprised in the Canal and River Trust’s network); and

(g)

any interference with the exercise by any person of rights over Canal and River Trust’s network;

the engineer” means an engineer appointed by the Canal and River Trust for the purpose in question;

plans” includes sections, designs, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction) and programmes;

practical completion” means practical completion of all of the specified work notwithstanding that items which would ordinarily be considered snagging items remain outstanding, and the expression “practically complete” and “practically completed” is to be construed accordingly;

protective work” means a work constructed under paragraph 22(3)(a);

specified work” means so much of Work Nos. 4A, 8A, 9A, 9B, 10B and 11A as is situated upon, across, under, over or within 15 metres of, or may in any way affect the waterway;

the waterway” means each and every part of the Stainforth and Keadby Canal within the order limits, and any works, lands or premises belonging to the Canal and River Trust, or under its management or control, and held or used by the Canal and River Trust in connection with that canal in connection with its statutory functions.

(3) Where the Code of Practice applies to any works or matter that are part of the authorised development or that form part of the protective works and there is an inconsistency between these protective provisions and the Code of Practice, the part of the Code of Practice that is inconsistent with these protective provisions will not apply and these protective provisions will apply. The undertaker will identify and agree with the Canal and River Trust those parts of the Code of Practice which are not applicable to the construction of the specified works and for the avoidance of doubt the undertaker will not be required to comply with those agreed parts of the Code of Practice.

Commencement Information

I18Sch. 10 para. 18 in force at 29.12.2022, see art. 1

Powers requiring the Canal and River Trust’s consentE+W+S

19.—(1) The undertaker must not in the exercise of the powers conferred by this Order obstruct or interfere with pedestrian or vehicular access to the waterway unless such obstruction or interference with such access is with the consent of the Canal and River Trust.

(2) The undertaker must not exercise any power conferred by this Order to discharge water into the waterway under article 14 (discharge of water) or in any way interfere with the supply of water to or the drainage of water from the waterway unless such exercise is with the consent of the Canal and River Trust, save as to surface water discharge which will not require the consent of the Canal and River Trust.

(3) The undertaker must not exercise the powers conferred by article 15 (authority to survey and investigate the land) or section 11(3) of the 1965 Act, in relation to the waterway unless such exercise is with the consent of the Canal and River Trust.

(4) The undertaker must not exercise the powers conferred by this Order to temporarily interfere with the waterway under article 16 (temporary interference with canal and public rights of navigation) so as to divert any right of access to or any right of navigation along the waterway but such right of access may be diverted with the consent of the Canal and River Trust.

(5) The consent of the Canal and River Trust pursuant to sub-paragraphs (1) to (4) must not be unreasonably withheld or delayed but may be given subject to reasonable terms and conditions.

Commencement Information

I19Sch. 10 para. 19 in force at 29.12.2022, see art. 1

FencingE+W+S

20.  Where so required by the engineer the undertaker must to the reasonable satisfaction of the engineer fence off a specified work or a protective work or take such other steps as the engineer may require to be taken for the purpose of separating a specified work or a protective work from the waterway, whether on a temporary or permanent basis or both.

Commencement Information

I20Sch. 10 para. 20 in force at 29.12.2022, see art. 1

Survey of waterwayE+W+S

21.—(1) Before the commencement of the initial construction of any part of the specified works and again following practical completion of the specified works the undertaker must bear the reasonable and proper cost of the carrying out by a qualified engineer (the “surveyor”), to be approved by the Canal and River Trust and the undertaker, of a survey including a dip-survey to measure the depth of the waterway (“the survey”) of so much of the waterway and of any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works.

(2) For the purposes of the survey the undertaker must—

(a)on being given reasonable notice (save in case of emergency, when immediate access must be afforded) afford reasonable facilities to the surveyor for access to the site of the specified works and to any land and existing works of the undertaker which may provide support for the waterway as will or may be affected by the specified works; and

(b)supply the surveyor as soon as reasonably practicable with all such information as he may reasonably require and which the undertaker holds with regard to such existing works of the undertaker and to the specified works or the method of their construction.

(3) The reasonable costs of the survey must include the costs of any dewatering or reduction of the water level of any part of the waterway (where reasonably required) which may be effected to facilitate the carrying out of the survey and the provisions of this Part will apply with all necessary modifications to any such dewatering or reduction in the water level as though the same were specified works.

(4) Copies of the survey must be provided to both the Canal and River Trust and the undertaker at no cost to the Canal and River Trust.

Commencement Information

I21Sch. 10 para. 21 in force at 29.12.2022, see art. 1

Approval of plans, protective works etc.E+W+S

22.—(1) The undertaker must before commencing construction of any specified work including any temporary works supply to the Canal and River Trust proper and sufficient plans of that work, on the Canal and River Trust forms, having regard to the Canal and River Trust’s Code of Practice and such further particulars available to it as the Canal and River Trust may within 14 days of the submission of the plans reasonably require for the approval of the engineer and must not commence such construction of a specified work until plans of that work have been approved in writing by the engineer or settled by arbitration.

(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld or delayed, and if within 35 days after such plans (including any other particulars reasonably required under sub-paragraph (1)) have been received by the Canal and River Trust the engineer has not intimated his disapproval of those plans and the grounds of his disapproval he is deemed to have approved the plans as submitted.

(3) When signifying approval of the plans the engineer may specify on land held or controlled by the Canal and River Trust or the undertaker and subject to such works being authorised by this Order or being development permitted by an Act of Parliament or general development order made under the 1990 Act—

(a)any protective work (whether temporary or permanent) which in the reasonable opinion of the engineer should be carried out before the commencement of a specified work to prevent detriment; and

(b)such other requirements as may be reasonably necessary to prevent detriment; and such protective works must be constructed by the undertaker or by the Canal and River Trust at the undertaker’s request with all reasonable dispatch and the undertaker must not commence the construction of a specified work until the engineer has notified the undertaker that the protective works have been completed to the engineer’s reasonable satisfaction such consent not to be unreasonably withheld or delayed.

(4) The undertaker must pay to the Canal and River Trust a capitalised sum representing the reasonably increased or additional cost of maintaining and, when necessary, renewing any works, including any permanent protective works provided under sub-paragraph (3) above, and of carrying out any additional dredging of the waterway reasonably necessitated by the exercise of any of the powers under this Order but if the cost of maintaining the waterway, or of works of renewal of the waterway, is reduced in consequence of any such works, a capitalised sum representing such reasonable saving is to be set off against any sum payable by the undertaker to the Canal and River Trust under this paragraph.

(5) In the event that the undertaker fails to complete the construction of, or part of, the specified works the Canal and River Trust may, if it is reasonably required in order to avoid detriment, serve on the undertaker a notice in writing requesting that construction be completed. Any notice served under this sub-paragraph must state the works that are to be completed by the undertaker and lay out a reasonable timetable for the works’ completion. If the undertaker fails to comply with this notice within 35 days, the Canal and River Trust may construct any of the specified works, or part of such works, (together with any adjoining works) in order to complete the construction of, or part of, the specified works or make such works and the undertaker must reimburse the Canal and River Trust all costs, fees, charges and expenses it has reasonably incurred in carrying out such works.

Commencement Information

I22Sch. 10 para. 22 in force at 29.12.2022, see art. 1

Design of worksE+W+S

23.  Without prejudice to its obligations under the foregoing provisions of this Part of this Schedule the undertaker must consult, collaborate and respond constructively to any reasonable approach, suggestion, proposal or initiative made by the Canal and River Trust on—

(a)the design and appearance of the specified works, including the materials to be used for their construction; and

(b)the environmental effects of those works; and must have regard to such views as may be expressed by the Canal and River Trust to the extent that these accord with the requirements of the local planning authority in response to such consultation pursuant in particular to the requirements imposed on the Canal and River Trust by section 22 (general environmental and recreational duties) of the British Waterways Act 1995(2) and to the interest of the Canal and River Trust in preserving and enhancing the environment of its waterways.

Commencement Information

I23Sch. 10 para. 23 in force at 29.12.2022, see art. 1

Notice of worksE+W+S

24.  The undertaker must give to the engineer 30 days’ notice of its intention to commence the construction of any of the specified works or protective works, or, in the case of repair carried out in an emergency, such notice as may be reasonably practicable so that, in particular, the Canal and River Trust may where appropriate arrange for the publication of notices bringing those works to the attention of users of the Canal and River Trust’s network.

Commencement Information

I24Sch. 10 para. 24 in force at 29.12.2022, see art. 1

LightingE+W+S

25.  The undertaker must provide and maintain at its own expense in the vicinity of the specified or protective works such temporary lighting and such signal lights for the control of navigation as the engineer may reasonably require during the construction or failure of the specified or protective works.

Commencement Information

I25Sch. 10 para. 25 in force at 29.12.2022, see art. 1

Construction of specified worksE+W+S

26.—(1) Any specified works or protective works must, when commenced, be constructed—

(a)with all reasonable dispatch in accordance with the plans approved or deemed to have been approved or settled as aforesaid and with any specifications made under paragraph 22 and paragraph 23 of this Part;

(b)under the supervision (if given) and to the reasonable satisfaction of the engineer;

(c)in such manner as to cause as little detriment as is reasonably practicable;

(d)in such manner as to cause as little inconvenience as is reasonably practicable to the Canal and River Trust, its officers and agents and all other persons lawfully using the waterways, except to the extent that temporary obstruction has otherwise been agreed by the Canal and River Trust;

(e)in such a manner as to ensure that no materials are discharged or deposited into the waterway otherwise than in accordance with article 14 (Discharge of water); and

(f)in compliance with the Code of Practice (where appropriate and where consistent with the exercise the exercise of powers pursuant to this Order and for the timely, safe, economic and efficient delivery of the authorised works).

(2) Nothing in this Order authorises the undertaker to make or maintain any permanent works in or over the waterway so as to impede or prevent (whether by reducing the width of the waterway or otherwise) the passage of any vessel which is of a kind (as to its dimensions) for which the Canal and River Trust is required by section 105(1)(b) and (2) of the Transport Act 1968(3) to maintain the waterway.

(3) Following the completion of the construction of the specified works the undertaker must restore the waterway to a condition no less satisfactory than its condition immediately prior to the commencement of those works unless otherwise agreed between the undertaker and the Canal and River Trust.

(4) In assessing whether the condition of the waterway is no less satisfactory than immediately prior to the works pursuant to sub-paragraph (3), the Canal and River Trust and the undertaker must take account of any survey issued pursuant to paragraph 21 and any other information agreed between them pursuant to this Part.

Commencement Information

I26Sch. 10 para. 26 in force at 29.12.2022, see art. 1

Prevention of pollutionE+W+S

27.  The undertaker must not in the course of constructing a specified work or a protective work or otherwise in connection therewith do or permit anything which may result in the pollution of the waterway or the deposit of materials therein and must take such steps as the engineer may reasonably require to avoid or make good any breach of its obligations under this paragraph.

Commencement Information

I27Sch. 10 para. 27 in force at 29.12.2022, see art. 1

Access to work – provision of informationE+W+S

28.—(1) The undertaker on being given reasonable notice must—

(a)at all reasonable times allow reasonable facilities to the engineer for access to a specified work during its construction; and

(b)supply the engineer with all such information as the engineer may reasonably require with regard to a specified work or the method of constructing it.

(2) The Canal and River Trust on being given reasonable notice must—

(a)at all reasonable times afford reasonable facilities to the undertaker and its agents for access to any works carried out by the Canal and River Trust under this Part during their construction; and

(b)supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them and the undertaker must reimburse the Canal and River Trust’s reasonable costs in relation to the supply of such information.

Commencement Information

I28Sch. 10 para. 28 in force at 29.12.2022, see art. 1

Alterations to the waterwayE+W+S

29.—(1) If during the construction of a specified work or a protective work or during a period of twenty four (24) months after the completion of those works any alterations or additions, either permanent or temporary, to the waterway are reasonably necessary in consequence of the construction of the specified work or the protective work in order to avoid detriment, and the Canal and River Trust gives to the undertaker reasonable notice of its intention to carry out such alterations or additions (which must be specified in the notice), the undertaker must pay to the Canal and River Trust the reasonable costs of those alterations or additions including, in respect of any such alterations or additions as are to be permanent, a capitalised sum representing the increase of the costs which may be expected to be reasonably incurred by the Canal and River Trust in maintaining, working and, when necessary, renewing any such alterations or additions.

(2) If the cost of maintaining, working or renewing the waterway is reduced in consequence of any such alterations or additions a capitalised sum representing such saving is to be set off against any sum payable by the undertaker to the Canal and River Trust under this paragraph.

Commencement Information

I29Sch. 10 para. 29 in force at 29.12.2022, see art. 1

Maintenance of worksE+W+S

30.  If at any time after the completion of a specified work or a protective work, not being a work vested in the Canal and River Trust, the Canal and River Trust gives notice to the undertaker informing it that it reasonably considers that the state of maintenance of the work appears to be such that the work is causing or likely to cause detriment, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put the work in such state of maintenance as not to cause such detriment.

Commencement Information

I30Sch. 10 para. 30 in force at 29.12.2022, see art. 1

Repayment of the Canal and River Trust’s fees, etc.E+W+S

31.—(1) The undertaker must repay to the Canal and River trust in accordance with the Code of Practice all fees, costs, charges and expenses reasonably incurred by the Canal and River Trust—

(a)in constructing any protective works under the provisions of paragraph 22(3)(a);

(b)in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction or repair of a specified work and any protective works;

(c)in respect of the employment during the construction of the specified works or any protective works of any inspectors, watchmen and other persons whom it is reasonably necessary to appoint for inspecting, watching and lighting any waterway and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of the specified works or any protective works;

(d)in bringing the specified works or any protective works to the notice of users of the Canal and River Trust’s network; and

(e)in constructing and/or carrying out any measures related to any specified works or protective works which are reasonably required by the Canal and River Trust to ensure the safe navigation of the waterway save that nothing is to require the Canal and River Trust to construct and/or carry out any measures.

(2) If the Canal and River Trust considers that a fee, charge, cost or expense will be payable by the undertaker pursuant to sub-paragraph (1), the Canal and River Trust will first provide an estimate of that fee, charge, cost or expense and supporting information in relation to the estimate to the undertaker along with a proposed timescale for payment for consideration and the undertaker may, within a period of twenty-one days—

(a)provide confirmation to the Canal and River Trust that the estimate is agreed and pay to the Canal and River Trust, by the date stipulated, that fee, charge, cost or expense; or

(b)provide confirmation to the Canal and River Trust that the estimate is not accepted along with a revised estimate and a proposal as to how or why the undertaker considers that the estimate can be reduced and or paid at a later date.

(3) The Canal and River Trust must take in to account any representations made by the undertaker in accordance with this paragraph 31 and must, within twenty-one days of receipt of the information pursuant to sub-paragraph (1), confirm the amount of the fee, charge, cost or expense to be paid by the undertaker (if any) and the date by which this is to be paid.

(4) The Canal and River Trust must, when estimating and incurring any charge, cost or expense pursuant this paragraph 31, do so with a view to being reasonably economic and acting as if the Canal and River Trust were itself to fund the relevant fee, charge, cost or expense.

Commencement Information

I31Sch. 10 para. 31 in force at 29.12.2022, see art. 1

Making good of detriment; compensation and indemnity, etc.E+W+S

32.—(1) If any detriment is caused by the construction or failure of the specified works or the protective works if carried out by the undertaker, the undertaker (if so required by the Canal and River Trust) must make good such detriment and must pay to the Canal and River Trust all reasonable expenses incurred by the Canal and River Trust, and compensation for any loss sustained by the Canal and River Trust in making good or otherwise by reason of the detriment.

(2) The undertaker must be responsible for and make good to the Canal and River Trust all costs, charges, damages, expenses and losses not otherwise provided for in this Part which may be occasioned to and reasonably incurred by the Canal and River Trust—

(a)by reason of the construction of a specified work or a protective work or the failure of such a work; or

(b)by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon the construction of a specified work or protective work; and subject to sub-paragraph (4) the undertaker must effectively indemnify and hold harmless the Canal and River Trust from and against all claims and demands arising out of or in connection with any of the matters referred to in sub-paragraphs (a) and (b) (provided that the Canal and River Trust is not entitled to recover from the undertaker any consequential losses which are not reasonably foreseeable).

(3) The fact that any act or thing may have been done by the Canal and River Trust on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision or in accordance with any directions or awards of an arbitrator is not to (if it was done without negligence on the part of the Canal and River Trust or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this paragraph.

(4) Nothing in sub-paragraph (2) imposes any liability on the undertaker with respect to any detriment, damage, loss or interruption to the extent that it is attributable to the act, neglect or default of the Canal and River Trust, its officers, servants, contractors or agents.

(5) The Canal and River Trust must give the undertaker reasonable notice of any such claim or demand as aforesaid and no settlement or compromise of such a claim or demand is to be made without the prior consent of the undertaker.

(6) The aggregate cap of the undertaker’s gross liability for consequential losses shall be limited to £15,000,000 (fifteen million pounds) for any one occurrence or all occurrences of a series arising out of the one original cause.

Commencement Information

I32Sch. 10 para. 32 in force at 29.12.2022, see art. 1

ArbitrationE+W+S

33.  Any difference arising between the undertaker and the Canal and River Trust under this Part (other than a difference as to the meaning or construction of this Part) must be referred to and settled by arbitration in accordance with article 44 (arbitration) of this Order.

Commencement Information

I33Sch. 10 para. 33 in force at 29.12.2022, see art. 1

Capitalised sumsE+W+S

34.  Any capitalised sum which is required to be paid under this Part must be calculated by multiplying the cost of the maintenance or renewal works to the waterway necessitated as a result of the operation of the authorised development by the number of times that the maintenance or renewal works will be required during the operation of the authorised development.

Commencement Information

I34Sch. 10 para. 34 in force at 29.12.2022, see art. 1

PART 3E+W+SFOR THE PROTECTION OF ELECTRICITY, GAS, WATER AND SEWERAGE UNDERTAKERS

35.  For the protection of the utility undertakers referred to in this part of this Schedule, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the utility undertakers concerned.E+W+S

Commencement Information

I35Sch. 10 para. 35 in force at 29.12.2022, see art. 1

36.  In this Part of this Schedule—E+W+S

alternative apparatus” means alternative apparatus adequate to enable the utility undertaker in question to fulfil its statutory functions in a manner not less efficient than previously;

apparatus” means—

(a)

in the case of a utility undertaker within sub-paragraph (a) of the definition of that term, electric lines or electrical plant (as defined in the Electricity Act 1989(4)), belonging to or maintained by that utility undertaker;

(b)

in the case of a utility undertaker within sub-paragraph (b) of the definition of that term, any mains, pipes or other apparatus belonging to or maintained by a gas transporter for the purposes of gas supply;

(c)

in the case of a utility undertaker within sub-paragraph (c) of the definition of that term—

(i)

mains, pipes or other apparatus belonging to or maintained by that utility undertaker for the purposes of water supply; and

(ii)

any water mains or service pipes (or part of a water main or service pipe) that is the subject of an agreement to adopt made under section 51A of the Water Industry Act 1991(5);

(d)

in the case of a utility undertaker within sub-paragraph (d) of the definition of that term—

(i)

any drain or works vested in the utility undertaker under the Water Industry Act 1991; and

(ii)

any sewer which is so vested or is the subject of a notice of intention to adopt given under section 102(4) of that Act or an agreement to adopt made under section 104 of that Act,

and includes a sludge main, disposal main (within the meaning of section 219 of that Act) or sewer outfall and any manholes, ventilating shafts, pumps or other accessories forming part of any such sewer, drain or works, and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land; and

utility undertaker” means—

(a)

any licence holder within the meaning of Part 1 of the Electricity Act 1989;

(b)

a gas transporter within the meaning of Part 1 of the Gas Act 1986(6);

(c)

water undertaker within the meaning of the Water Industry Act 1991; and

(d)

a sewerage undertaker within the meaning of Part 1 of the Water Industry Act 1991,

for the area of the authorised development, and in relation to any apparatus, means the utility undertaker to whom it belongs or by whom it is maintained.

Commencement Information

I36Sch. 10 para. 36 in force at 29.12.2022, see art. 1

37.  This Part does not apply to apparatus in respect of which the relations between the undertaker and the utility undertaker are regulated by the provisions of Part 3 of the 1991 Act.E+W+S

Commencement Information

I37Sch. 10 para. 37 in force at 29.12.2022, see art. 1

38.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire any apparatus otherwise than by agreement.E+W+S

Commencement Information

I38Sch. 10 para. 38 in force at 29.12.2022, see art. 1

39.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that the utility undertaker’s apparatus is relocated or diverted, that apparatus must not be removed under this Part, and any right of a utility undertaker to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided, to the reasonable satisfaction of the utility undertaker in question in accordance with sub-paragraphs (2) to (7).E+W+S

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to the utility undertaker in question written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order a utility undertaker reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to the utility undertaker the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, the utility undertaker in question must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably possible use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between the utility undertaker in question and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration).

(5) The utility undertaker in question must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44 (arbitration), and after the grant to the utility undertaker of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part.

(6) Regardless of anything in sub-paragraph (5), if the undertaker gives notice in writing to the utility undertaker in question that it desires itself to execute any work, or part of any work, in connection with the construction or removal of apparatus in any land controlled by the undertaker, that work, instead of being executed by the utility undertaker, must be executed by the undertaker without unnecessary delay under the superintendence, if given, and to the reasonable satisfaction of the utility undertaker.

(7) Nothing in sub-paragraph (6) authorises the undertaker to execute the placing, installation, bedding, packing, removal, connection or disconnection of any apparatus, or execute any filling around the apparatus (where the apparatus is laid in a trench) within 300 millimetres of the apparatus.

Commencement Information

I39Sch. 10 para. 39 in force at 29.12.2022, see art. 1

40.—(1) Where, in accordance with the provisions of this Part, the undertaker affords to a utility undertaker facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and the utility undertaker in question or in default of agreement settled by arbitration in accordance with article 44 (arbitration).E+W+S

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to the utility undertaker in question than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to that utility undertaker as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I40Sch. 10 para. 40 in force at 29.12.2022, see art. 1

41.—(1) Not less than twenty-eight days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to, or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 6(2), the undertaker must submit to the utility undertaker in question a plan, section and description of the works to be executed.E+W+S

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by the utility undertaker for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and the utility undertaker is entitled to watch and inspect the execution of those works.

(3) Any requirements made by a utility undertaker under sub-paragraph (2) must be made within a period of twenty-one days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If a utility undertaker in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 35 to 40 apply as if the removal of the apparatus had been required by the undertaker under paragraph 39(2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than twenty-eight days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to the utility undertaker in question notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Commencement Information

I41Sch. 10 para. 41 in force at 29.12.2022, see art. 1

42.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to a utility undertaker the reasonable expenses incurred by that utility undertaker in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 39(2).E+W+S

(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part, that value being calculated after removal.

(3) If in accordance with the provisions of this Part—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was,

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to the utility undertaker in question by virtue of sub-paragraph (1) is to be reduced by the amount of that excess.

(4) For the purposes of sub-paragraph (3)—

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 39(2); and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

(5) An amount which apart from this sub-paragraph would be payable to a utility undertaker in respect of works by virtue of sub-paragraph (1), if the works include the placing of apparatus provided in substitution for apparatus placed more than 7 years and 6 months earlier so as to confer on the utility undertaker any financial benefit by deferment of the time for renewal of the apparatus in the ordinary course, is to be reduced by the amount which represents that benefit.

Commencement Information

I42Sch. 10 para. 42 in force at 29.12.2022, see art. 1

43.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in paragraph 39(2), any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of a utility undertaker, or there is any interruption in any service provided, or in the supply of any goods, by any utility undertaker, the undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by that utility undertaker in making good such damage or restoring the supply; and

(b)make reasonable compensation to that utility undertaker for any other expenses, loss, damages, penalty or costs incurred by the utility undertaker,

by reason or in consequence of any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of a utility undertaker, its officers, servants, contractors or agents.

(3) A utility undertaker must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

Commencement Information

I43Sch. 10 para. 43 in force at 29.12.2022, see art. 1

44.  Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and a utility undertaking in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.E+W+S

Commencement Information

I44Sch. 10 para. 44 in force at 29.12.2022, see art. 1

PART 4E+W+SFOR THE PROTECTION OF OPERATORS OF ELECTRONIC COMMUNICATIONS CODE NETWORKS

45.—(1) For the protection of any operator, the following provisions have effect, unless otherwise agreed in writing between the undertaker and the operator.E+W+S

(2) In this Part—

the 2003 Act” means the Communications Act 2003(7);

electronic communications apparatus” has the same meaning as set out in paragraph 5 of the electronic communications code;

the electronic communications code” has the same meaning as set out in sections 106 to 119 and Schedule 3A of the 2003 Act(8);

infrastructure system” has the same meaning as in the electronic communications code and references to providing an infrastructure system are to be construed in accordance with paragraph 7 of that code;

network” means—

(a)

so much of a network or infrastructure system provided by an operator as is not excluded from the application of the electronic communications code by a direction under section 106(5) of the 2003 Act; and

(b)

a network which the Secretary of State is providing or proposing to provide;

operator” means a person in whose case the electronic communications code is applied by a direction under section 106 of the 2003 Act and who is an operator of a network.

Commencement Information

I45Sch. 10 para. 45 in force at 29.12.2022, see art. 1

46.  The exercise of the powers of article 29 (statutory undertakers) is subject to Part 10 of Schedule 3A of the 2003 Act.E+W+S

Commencement Information

I46Sch. 10 para. 46 in force at 29.12.2022, see art. 1

47.—(1) Subject to sub-paragraphs (2) to (4), if as the result of the construction of authorised development, or of any subsidence resulting from any of those works—E+W+S

(a)any damage is caused to any electronic communications apparatus belonging to an operator (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property of an operator; or

(b)there is any interruption in the supply of the service provided by an operator,

the undertaker must bear and pay the cost reasonably incurred by the operator in making good such damage or restoring the supply and make reasonable compensation to that operator for any other expenses, loss, damages, penalty or costs incurred by it, by reason, or in consequence of, any such damage or interruption.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of an operator, its officers, servants, contractors or agents.

(3) The operator must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Any difference arising between the undertaker and the operator under this part of this Schedule must be referred to and settled by arbitration under article 44 (arbitration).

Commencement Information

I47Sch. 10 para. 47 in force at 29.12.2022, see art. 1

48.  This Part of this Schedule does not apply to—E+W+S

(a)any apparatus in respect of which the relations between the undertaker and an operator are regulated by the provisions of Part 3 of the 1991 Act; or

(b)any damage, or any interruption, caused by electro-magnetic interference arising from the construction or use of the authorised development.

Commencement Information

I48Sch. 10 para. 48 in force at 29.12.2022, see art. 1

49.  Nothing in this Part affects the provisions of any enactment or agreement regulating the relations between the undertaker and an operator in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.E+W+S

Commencement Information

I49Sch. 10 para. 49 in force at 29.12.2022, see art. 1

PART 5E+W+SFOR THE PROTECTION OF RAILWAY INTERESTS

50.  The provisions of this Part of this Schedule have effect, unless otherwise agreed in writing between the undertaker and Network Rail and, in the case of paragraph 68 of this Part of this Schedule any other person on whom rights or obligations are conferred by that paragraph.E+W+S

Commencement Information

I50Sch. 10 para. 50 in force at 29.12.2022, see art. 1

51.  In this Schedule—E+W+S

asset protection agreement” means an agreement to regulate the construction and maintenance of the specified work in a form prescribed from time to time by Network Rail;

construction” includes execution, placing, alteration and reconstruction and “construct” and “constructed” have corresponding meanings;

the engineer” means an engineer appointed by Network Rail for the purposes of this Order;

network licence” means the network licence, as the same is amended from time to time, granted to Network Rail Infrastructure Limited by the Secretary of State in exercise of their powers under section 8 (licences) of the Railways Act 1993;

Network Rail” means Network Rail Infrastructure Limited (company number 02904587, whose registered office is at 1 Eversholt Street, London NW1 2DN) and any associated company of Network Rail Infrastructure Limited which holds property for railway purposes, and for the purpose of this definition “associated company” means any company which is (within the meaning of section 1159 of the Companies Act 2006 the holding company of Network Rail Infrastructure Limited, a subsidiary of Network Rail Infrastructure Limited or another subsidiary of the holding company of Network Rail Infrastructure Limited;

plans” includes sections, designs, design data, software, drawings, specifications, soil reports, calculations, descriptions (including descriptions of methods of construction), staging proposals, programmes and details of the extent, timing and duration of any proposed occupation of railway property;

railway operational procedures” means procedures specified under any access agreement (as defined in the Railways Act 1993) or station lease;

railway property” means any railway belonging to Network Rail and—

(a)

any station, land, works, apparatus and equipment belonging to Network Rail or connected with any such railway; and

(b)

any easement or other property interest held or used by Network Rail or a tenant or licensee of Network Rail for the purposes of such railway or works, apparatus or equipment.

regulatory consents” means any consent or approval required under:

(a)

the Railways Act 1993;

(b)

the network licence; and/or

(c)

any other relevant statutory or regulatory provisions;

by either the Office of Rail and Road or the Secretary of State for Transport or any other competent body including change procedures and any other consents, approvals of any access or beneficiary that may be required in relation to the authorised development;

specified work” means so much of any of the authorised development as is situated upon, across, under, over or within 15 metres of, or may in any way adversely affect, railway property and, for the avoidance of doubt, includes the powers conferred by article 4 (maintenance of the authorised development);

undertaker” has the same meaning as in article 2 (interpretation) of this Order.

Commencement Information

I51Sch. 10 para. 51 in force at 29.12.2022, see art. 1

52.—(1) Where under this Part of this Schedule Network Rail is required to give its consent or approval in respect of any matter, that consent or approval is subject to the condition that Network Rail complies with any relevant railway operational procedures and any obligations under its network licence or under statute.E+W+S

(2) In so far as any specified work or the acquisition or use of railway property is or may be subject to railway operational procedures, Network Rail must—

(a)co-operate with the undertaker with a view to avoiding undue delay and securing conformity as between any plans approved by the engineer and requirements emanating from those procedures; and

(b)use their reasonable endeavours to avoid any conflict arising between the application of those procedures and the proper implementation of the authorised development pursuant to this Order.

Commencement Information

I52Sch. 10 para. 52 in force at 29.12.2022, see art. 1

53.—(1) The undertaker must not exercise the powers conferred by—E+W+S

(a)Article 14 (discharge of water);

(b)Article 15 (authority to survey and investigate the land);

(c)Article 18 (compulsory acquisition of land);

(d)Article 19 (statutory authority to override easements and other rights);

(e)Article 21 (compulsory acquisition of rights);

(f)Article 22 (private rights);

(g)Article 24 (acquisition of subsoil or airspace only);

(h)Article 27 (temporary use of land for carrying out the authorised development);

(i)Article 28 (temporary use of land for maintaining the authorised development);

(j)Article 29 (statutory undertakers);

(k)Article 33 (felling or lopping of trees and removal of hedgerows);

(l)the powers conferred by section 11(3) (power of entry) of the 1965 Act;

(m)the powers conferred by section 203 (power to override easements and rights) of the Housing and Planning Act 2016;

(n)the powers conferred by section 172 (right to enter and survey land) of the Housing and Planning Act 2016;

(o)the powers conferred by section 18 (power to take temporary possession of land) of the Neighbourhood Planning Act 2017

in respect of any railway property unless the exercise of such powers is with the consent of Network Rail.

(2) The undertaker must not in the exercise of the powers conferred by this Order prevent pedestrian or vehicular access to any railway property, unless preventing such access is with the consent of Network Rail.

(3) The undertaker must not exercise the powers conferred by sections 271 or 272 of the 1990 Act, or article 29 (statutory undertakers), in relation to any right of access of Network Rail to railway property, but such right of access may be diverted with the consent of Network Rail.

(4) The undertaker must not under the powers of this Order acquire or use or acquire new rights over, or seek to impose any restrictive covenants over, any railway property, or extinguish any existing rights of Network Rail in respect of any third party property, except with the consent of Network Rail.

(5) The undertaker must not under the powers of this Order do anything which would result in railway property being incapable of being used or maintained or which would affect the safe running of trains on the railway.

(6) Where Network Rail is asked to give its consent pursuant to this paragraph, such consent must not be unreasonably withheld but may be given subject to reasonable conditions.

Commencement Information

I53Sch. 10 para. 53 in force at 29.12.2022, see art. 1

54.—(1) The undertaker must, before commencing construction of any specified work, supply to Network Rail; (a) proper and sufficient plans of that work for the reasonable approval of the engineer and (b) the specified work must not be commenced, except in accordance with such plans as have been approved in writing by the engineer or settled by arbitration.E+W+S

(2) The approval of the engineer under sub-paragraph (1) must not be unreasonably withheld, and if by the end of the period of 28 days beginning with the date on which such plans have been supplied to Network Rail the engineer has not intimated their disapproval of those plans and the grounds of such disapproval the undertaker may serve upon the engineer written notice requiring the engineer to intimate approval or disapproval within a further period of 28 days beginning with the date upon which the engineer receives written notice from the undertaker. If by the expiry of the further 28 days the engineer has not intimated approval or disapproval, the engineer shall be deemed to have approved the plans as submitted.

(3) If by the end of the period of 28 days beginning with the date on which written notice was served upon the engineer under sub-paragraph (2), Network Rail gives notice to the undertaker that Network Rail desires itself to construct any part of a specified work which in the opinion of the engineer will or may affect the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker desires such part of the specified work to be constructed, Network Rail must construct it without unnecessary delay on behalf of and to the reasonable satisfaction of the undertaker in accordance with the plans approved or deemed to be approved or settled under this paragraph, and under the supervision (where appropriate and if given) of the undertaker.

(4) When signifying their approval of the plans the engineer may specify any protective works (whether temporary or permanent) which in the engineer’s opinion should be carried out before the commencement of the construction of a specified work to ensure the safety or stability of railway property or the continuation of safe and efficient operation of the railways of Network Rail or the services of operators using the same (including any relocation decommissioning and removal of works, apparatus and equipment necessitated by a specified work and the comfort and safety of passengers who may be affected by the specified works), and such protective works as may be reasonably necessary for those purposes must be constructed by Network Rail or by the undertaker, if Network Rail so desires, and such protective works must be carried out at the expense of the undertaker in either case without unnecessary delay and the undertaker must not commence the construction of the specified works until the engineer has notified the undertaker that the protective works have been completed to their reasonable satisfaction.

Commencement Information

I54Sch. 10 para. 54 in force at 29.12.2022, see art. 1

55.—(1) Any specified work and any protective works to be constructed by virtue of paragraph 54(4) must, when commenced, be constructed—E+W+S

(a)without unnecessary delay in accordance with the plans approved or deemed to have been approved or settled under paragraph 54;

(b)under the supervision (where appropriate and if given) and to the reasonable satisfaction of the engineer;

(c)in such manner as to cause as little damage as is possible to railway property; and

(d)so far as is reasonably practicable, so as not to interfere with or obstruct the free, uninterrupted and safe use of any railway of Network Rail or the traffic thereon and the use by passengers of railway property.

(2) If any damage to railway property or any such interference or obstruction shall be caused by the carrying out of, or in consequence of the construction of a specified work, the undertaker must, notwithstanding any such approval, make good such damage and must pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may sustain by reason of any such damage, interference or obstruction.

(3) Nothing in this Part of this Schedule imposes any liability on the undertaker with respect to any damage, costs, expenses or loss attributable to the negligence of Network Rail or its servants, contractors or agents or any liability on Network Rail with respect of any damage, costs, expenses or loss attributable to the negligence of the undertaker or its servants, contractors or agents.

Commencement Information

I55Sch. 10 para. 55 in force at 29.12.2022, see art. 1

56.  The undertaker must—E+W+S

(a)at all times afford reasonable facilities to the engineer for access to a specified work during its construction; and

(b)supply the engineer with all such information as they may reasonably require with regard to a specified work or the method of constructing it.

Commencement Information

I56Sch. 10 para. 56 in force at 29.12.2022, see art. 1

57.  Network Rail must at all times afford reasonable facilities to the undertaker and its agents for access to any works carried out by Network Rail under this Part of this Schedule during their construction and must supply the undertaker with such information as it may reasonably require with regard to such works or the method of constructing them.E+W+S

Commencement Information

I57Sch. 10 para. 57 in force at 29.12.2022, see art. 1

58.—(1) If any permanent or temporary alterations or additions to railway property are reasonably necessary in consequence of the construction of a specified work, or during a period of 24 months after the completion of that work in order to ensure the safety of railway property or the continued safe operation of the railway of Network Rail, such alterations and additions may be carried out by Network Rail and if Network Rail gives the undertaker 56 days written notice.E+W+S

(2) If during the construction of a specified work by the undertaker, Network Rail gives written notice to the undertaker that Network Rail desires itself to construct that part of the specified work which in the opinion of the engineer is endangering the stability of railway property or the safe operation of traffic on the railways of Network Rail then, if the undertaker decides that part of the specified work is to be constructed, Network Rail must assume construction of that part of the specified work and the undertaker must, notwithstanding any such approval of a specified work under paragraph 54(3), pay to Network Rail all reasonable expenses to which Network Rail may be put and compensation for any loss which it may suffer by reason of the execution by Network Rail of that specified work.

(3) The engineer must, in respect of the capitalised sums referred to in this paragraph and paragraph 59(a) provide such details of the formula by which those sums have been calculated as the undertaker may reasonably require.

(4) If the cost of maintaining, working or renewing railway property is reduced in consequence of any such alterations or additions a capitalised sum representing such saving must be set off against any sum payable by the undertaker to Network Rail under this paragraph.

Commencement Information

I58Sch. 10 para. 58 in force at 29.12.2022, see art. 1

59.  The undertaker must repay to Network Rail all reasonable fees, costs, charges and expenses reasonably incurred by Network Rail—E+W+S

(a)in constructing any part of a specified work on behalf of the undertaker as provided by paragraph 54(3) or in constructing any protective works under the provisions of paragraph 54(4) including, in respect of any permanent protective works, a capitalised sum representing the cost of maintaining and renewing those works;

(b)in respect of the approval by the engineer of plans submitted by the undertaker and the supervision by the engineer of the construction of a specified work;

(c)in respect of the employment or procurement of the services of any inspectors, signallers, watch-persons and other persons whom it shall be reasonably necessary to appoint for inspecting, signalling, watching and lighting railway property and for preventing, so far as may be reasonably practicable, interference, obstruction, danger or accident arising from the construction or failure of a specified work;

(d)in respect of any special traffic working resulting from any speed restrictions which may in the opinion of the engineer, require to be imposed by reason or in consequence of the construction or failure of a specified work or from the substitution or diversion of services which may be reasonably necessary for the same reason; and

(e)in respect of any additional temporary lighting of railway property in the vicinity of the specified works, being lighting made reasonably necessary by reason or in consequence of the construction or failure of a specified work.

Commencement Information

I59Sch. 10 para. 59 in force at 29.12.2022, see art. 1

60.—(1) In this paragraph—E+W+S

EMI” means, subject to sub-paragraph (2), electromagnetic interference with Network Rail apparatus generated by the operation of the authorised development where such interference is of a level which adversely affects the safe operation of Network Rail’s apparatus; and

Network Rail’s apparatus” means any lines, circuits, wires, apparatus or equipment (whether or not modified or installed as part of the authorised development) which are owned or used by Network Rail for the purpose of transmitting or receiving electrical energy or of radio, telegraphic, telephonic, electric, electronic or other like means of signalling or other communications.

(2) This paragraph applies to EMI only to the extent that such EMI is not attributable to any change to Network Rail’s apparatus carried out after approval of plans under paragraph 54(1) for the relevant part of the authorised development giving rise to EMI (unless the undertaker has been given notice in writing before the approval of those plans of the intention to make such change).

(3) Subject to sub-paragraph (5), the undertaker must in the design and construction of the authorised development take all measures necessary to prevent EMI and must establish with Network Rail (both parties acting reasonably) appropriate arrangements to verify their effectiveness.

(4) In order to facilitate the undertaker’s compliance with sub-paragraph (3)—

(a)The undertaker must consult with Network Rail as early as reasonably practicable to identify all Network Rail’s apparatus which may be at risk of EMI, and thereafter must continue to consult with Network Rail (both before and after formal submission of plans under paragraph 54(1)) in order to identify all potential causes of EMI and the measures required to eliminate them;

(b)Network Rail must make available to the undertaker all information in the possession of Network Rail reasonably requested by the undertaker in respect of Network Rail’s apparatus identified pursuant to sub-paragraph (a); and

(c)(c) Network Rail must allow the undertaker reasonable facilities for the inspection of Network Rail’s apparatus identified pursuant to sub-paragraph (a).

(5) In any case where it is established that EMI can only reasonably be prevented by modifications to Network Rail’s apparatus, Network Rail must not withhold its consent unreasonably to modifications of Network Rail’s apparatus, but the means of prevention and the method of their execution must be selected in the reasonable discretion of Network Rail, and in relation to such modifications paragraph 54(1) has effect subject to the sub-paragraph.

(6) Prior to the commencement of operation of the authorised development the undertaker shall test the use of the authorised development in a manner that shall first have been agreed with Network Rail and if, notwithstanding any measures adopted pursuant to sub-paragraph (3), the testing of the authorised development causes EMI then the undertaker must immediately upon receipt of notification by Network Rail of such EMI either in writing or communicated orally (such oral communication to be confirmed in writing as soon as reasonably practicable after it has been issued) forthwith cease to use (or procure the cessation of use of) the undertaker’s apparatus causing such EMI until all measures necessary have been taken to remedy such EMI by way of modification to the source of such EMI or (in the circumstances, and subject to the consent, specified in sub-paragraph (5)) to Network Rail’s apparatus.

(7) In the event of EMI having occurred—

(a)The undertaker must afford reasonable facilities to Network Rail for access to the undertaker’s apparatus in the investigation of such EMI;

(b)Network Rail must afford reasonable facilities to the undertaker for access to Network Rail’s apparatus in the investigation of such EMI;

(c)Network Rail must make available to the undertaker any additional material information in its possession reasonably requested by the undertaker in respect of Network Rail’s apparatus or such EMI; and

(d)The undertaker shall not allow the use or operation of the authorised development in a manner that has caused or will cause EMI until measures have been taken in accordance with this paragraph to prevent EMI occurring.

(8) Where Network Rail approves modifications to Network Rail’s apparatus pursuant to subparagraphs (5) or (6)—

(a)Network Rail must allow the undertaker reasonable facilities for the inspection of the relevant part of Network Rail’s apparatus;

(b)any modifications to Network Rail’s apparatus approved pursuant to those sub-paragraphs must be carried out and completed by the undertaker in accordance with paragraph 55.

(9) To the extent that it would not otherwise do so, the indemnity in paragraph 64(1) applies to the costs and expenses reasonably incurred or losses suffered by network Rail through the implementation of the provisions of this paragraph (including costs incurred in connection with the consideration of proposals, approval of plans, supervision and inspection of works and facilitating access to Network Rail’s apparatus) or in consequence of any EMI to which subparagraph (6) applies.

(10) For the purpose of paragraph 59(a) any modifications to Network Rail’s apparatus under this paragraph shall be deemed to be protective works referred to in that paragraph.

(11) In relation to any dispute arising under this paragraph the reference in article 44 (Arbitration) to a single arbitrator shall be read as a reference to the Institution of Engineering and Technology.

Commencement Information

I60Sch. 10 para. 60 in force at 29.12.2022, see art. 1

61.  If at any time after the completion of a specified work, not being a work vested in Network Rail, Network Rail gives written notice to the undertaker informing it that the state of maintenance of any part of the specified work appears to be such as adversely affects the operation of railway property, the undertaker must, on receipt of such notice, take such steps as may be reasonably necessary to put that specified work in such state of maintenance as not adversely to affect railway property.E+W+S

Commencement Information

I61Sch. 10 para. 61 in force at 29.12.2022, see art. 1

62.  The undertaker must not provide any illumination or illuminated sign or signal on or in connection with a specified work in the vicinity of any railway belonging to Network Rail unless it has first consulted Network Rail and it must comply with Network Rail’s reasonable requirements for preventing confusion between such illumination or illuminated sign or signal and any railway signal or other light used for controlling, directing or securing the safety of traffic on the railway.E+W+S

Commencement Information

I62Sch. 10 para. 62 in force at 29.12.2022, see art. 1

63.  Any additional expenses which Network Rail may reasonably incur in altering, reconstructing or maintaining railway property under any powers existing at the making of this Order by reason of the existence of a specified work must, provided that 56 days’ previous written notice of the commencement of such alteration, reconstruction or maintenance has been given to the undertaker, be repaid by the undertaker to Network Rail.E+W+S

Commencement Information

I63Sch. 10 para. 63 in force at 29.12.2022, see art. 1

64.—(1) The undertaker must pay to Network Rail all reasonable costs, charges, damages and expenses not otherwise provided for in this Part of this Schedule (subject to article 31 (recovery of costs of new connections)) which may be occasioned to or reasonably incurred by Network Rail—E+W+S

(a)By reason of the construction, maintenance or operation of a specified work or the failure thereof;

(b)by reason of any act or omission of the undertaker or of any person in its employ or of its contractors or others whilst engaged upon a specified work;

(c)by reason of any act or omission of the undertaker or any person in its employ or of its contractors or others whilst accessing to or egressing from the authorised development;

(d)in respect of any damage caused to or additional maintenance required to, railway property or any such interference or obstruction or delay to the operation of the railway as a result of access to or egress from the authorised development by the undertaker or any person in its employ or of its contractors or others;

(e)in respect of costs incurred by Network Rail in complying with any railway operational procedures or obtaining any regulatory consents which procedures are required to be followed or consents obtained to facilitate the carrying out or operation of the authorised development; and the undertaker must indemnify and keep indemnified Network Rail from and against all claims and demands arising out of or in connection with a specified work or any such failure, act or omission: and the fact that any act or thing may have been done by Network Rail on behalf of the undertaker or in accordance with plans approved by the engineer or in accordance with any requirement of the engineer or under the engineer’s supervision shall not (if it was done without negligence on the part of Network Rail or of any person in its employ or of its contractors or agents) excuse the undertaker from any liability under the provisions of this sub-paragraph.

(2) Network Rail must—

(a)give the undertaker reasonable written notice of any such claims or demands;

(b)not make any settlement or compromise of such a claim or demand without the prior consent of the undertaker; and

(c)take all reasonable steps to mitigate any liabilities relating to such claims or demands.

(3) The sums payable by the undertaker under sub-paragraph (1) shall if relevant include a sum equivalent to the relevant costs.

(4) Subject to the terms of any agreement between Network Rail and a train operator regarding the timing or method of payment of the relevant costs in respect of that train operator, Network Rail must promptly pay to each train operator the amount of any sums which Network Rail receives under sub-paragraph (3) which relates to the relevant costs of that train operator.

(5) The obligation under sub-paragraph (3) to pay Network Rail the relevant costs shall, in the event of default, be enforceable directly by any train operator concerned to the extent that such sums would be payable to that operator pursuant to sub-paragraph (4).

(6) In this paragraph—

the relevant costs” means the costs, losses and expenses (including loss of revenue) reasonably incurred by each train operator as a consequence of any specified work including but not limited to any restriction of the use of Network Rail’s railway network as a result of the construction, maintenance or failure of a specified work or any such act or omission as mentioned in sub-paragraph (1); and

train operator” means any person who is authorised to act as the operator of a train by a licence under section 8 of the Railways Act 1993.

Commencement Information

I64Sch. 10 para. 64 in force at 29.12.2022, see art. 1

65.  Network Rail must, on receipt of a request from the undertaker, from time to time provide the undertaker free of charge with written estimates of the costs, charges, expenses and other liabilities for which the undertaker is or will become liable under this Schedule (including the amount of the relevant costs mentioned in paragraph 64 and with such information as may reasonably enable the undertaker to assess the reasonableness of any such estimate or claim made or to be made pursuant to this Schedule (including any claim relating to those relevant costs).E+W+S

Commencement Information

I65Sch. 10 para. 65 in force at 29.12.2022, see art. 1

66.  In the assessment of any sums payable to Network Rail under this Part of this Schedule there must not be taken into account any increase in the sums claimed that is attributable to any action taken by or any agreement entered into by Network Rail if that action or agreement was not reasonably necessary and was taken or entered into with a view to obtaining the payment of those sums by the undertaker under this Schedule or increasing the sums so payable.E+W+S

Commencement Information

I66Sch. 10 para. 66 in force at 29.12.2022, see art. 1

67.  The undertaker and Network Rail may, subject in the case of Network Rail to compliance with the terms of its network licence, enter into, and carry into effect, agreements for the transfer to the undertaker of—E+W+S

(a)any railway property shown on the works and land plans and described in the book of reference;

(b)any lands, works or other property held in connection with any such railway property; and

(c)any rights and obligations (whether or not statutory) of Network Rail relating to any railway property or any lands, works or other property referred to in this paragraph.

Commencement Information

I67Sch. 10 para. 67 in force at 29.12.2022, see art. 1

68.  In Nothing in this Order, or in any enactment incorporated with or applied by this Order, prejudices or affects the operation of Part I of the Railways Act 1993.E+W+S

Commencement Information

I68Sch. 10 para. 68 in force at 29.12.2022, see art. 1

69.  The undertaker must give written notice to Network Rail if any application is proposed to be made by the undertaker for the Secretary of State’s consent, under article 7 (consent to transfer benefit of the Order) of this Order and any such notice must be given no later than 28 days before any such application is made and must describe or give (as appropriate)—E+W+S

(a)The nature of the application to be made;

(b)the extent of the geographical area to which the application relates; and

(c)the name and address of the person acting for the Secretary of State to whom the application is to be made.

Commencement Information

I69Sch. 10 para. 69 in force at 29.12.2022, see art. 1

70.  The undertaker must no later than 28 days from the date that the plans submitted to and certified by the Secretary of State in accordance with article 41 (certification of plans etc.) are certified by the Secretary of State, provide a set of those plans to Network Rail in a format specified by Network Rail.E+W+S

Commencement Information

I70Sch. 10 para. 70 in force at 29.12.2022, see art. 1

71.  In relation to any dispute arising under this part of this Schedule (except for those disputes referred to in paragraph 60(11)) the provisions of article 44 (Arbitration) shall not apply and any such dispute, unless otherwise provided for, must be referred to and settled by a single arbitrator to be agreed between the parties or, failing agreement, to be appointed on the application of either party (after giving notice in writing to the other) to the President of the Institution of Civil Engineering and Technology.E+W+S

Commencement Information

I71Sch. 10 para. 71 in force at 29.12.2022, see art. 1

PART 6E+W+SFOR THE PROTECTION OF NATIONAL GRID CARBON LIMITED

ApplicationE+W+S

72.  For the protection of NGC the following provisions have effect, unless otherwise agreed in writing between the undertaker and NGC.

Commencement Information

I72Sch. 10 para. 72 in force at 29.12.2022, see art. 1

73.  The undertaker hereby agrees not to exercise its powers under this Order without fully complying with the provisions of this Part of this Schedule.

Commencement Information

I73Sch. 10 para. 73 in force at 29.12.2022, see art. 1

74.  Section A and paragraph 88 of Section B of this Part 6 of Schedule 10 shall have effect from the date this Order is made and the remainder of Section B of this Part 6 of Schedule 10 shall have effect from the date that NGC apparatus is installed and completed in accordance with an agreed schedule of NGC apparatus between the undertaker and NGC.

Commencement Information

I74Sch. 10 para. 74 in force at 29.12.2022, see art. 1

InterpretationE+W+S

75.—(1) In this Part of this Schedule—

1991 Act” means the New Roads and Street Works Act 1991(9);

affiliates” means any of NGC’s parent or subsidiary undertakings together with any subsidiary undertakings of any such parent undertakings from time to time involved in promoting, constructing or operating the NGC Pipeline Network;

alternative apparatus” means apparatus in the alternative to NGC apparatus adequate to enable NGC to operate and maintain its undertaking in a manner no less efficient than previously;

carbon dioxide export connection work” means the infrastructure proposed to deliver the export of carbon dioxide arising from Work No.1C to the NGC Pipeline Network and comprising Work No.7B;

construction” includes execution, placing, installation, altering, replacing, relaying and removal and excavation and “construct” and “constructed” will be construed accordingly;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

NGC” means National Grid Carbon Limited (Company Number 03932833) whose registered office is at 1-3 Strand, London, WC2N 5EH and includes all of its affiliates, transferees and assignees;

NGC apparatus” means any mains, pipes, plant or other apparatus belonging to, operated or maintained by NGC whether temporary or permanent, and includes, where the context so requires, apparatus constructed as part of the authorised development and intended for beneficial use by NGC;

NGC Pipeline Network DCO” means a development consent order for the construction operation and maintenance of the NGC Pipeline Network;

NGC Pipeline Network” means the proposed network of high pressure carbon dioxide and hydrogen pipelines to be developed by NGC for the transportation of carbon dioxide and hydrogen to and from industrial emitters in the Humber region and references to the NGC Pipeline Network in this Part of this Schedule include any part of that network;

NGC Pipeline Network site” means land on which any NGC apparatus is situated;

plan” includes all sections, designs, drawings, maps, specifications, method statements, soil reports and other survey data, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed; and

specified work” means so much of any work or operation authorised by this Order (other than an carbon dioxide export connection work) as—

(a)

will or may be situated over, or within 15 metres measured in any direction of any NGC apparatus; and/or

(b)

may in any way adversely affect any NGC apparatus the removal of which has not been required by the undertaker under paragraph 85 or otherwise.

(2) In paragraph (1), references to “subsidiary undertakings” and “parent undertakings” have the meaning given to them by section 1162 (parent and subsidiary undertakings) of the Companies Act 2006(10), except that references in that section to majority are to be read as references to “25 per cent or more” and provided further that a company will be treated, for the purposes only of the membership requirement contained in that section of that Act, as a member of another company even if its shares in that other company are registered in the name of—

(a)another person (or its nominee) by way of security or in connection with the taking of security; or

(b)its nominee.

Commencement Information

I75Sch. 10 para. 75 in force at 29.12.2022, see art. 1

SECTION AE+W+S

Interaction with the NGC Pipeline NetworkE+W+S

76.  Without limiting any other provision of this Part of this Schedule, the undertaker must use reasonable endeavours to avoid any conflict arising between the carrying out, maintenance and operation of the authorised development and the NGC Pipeline Network. For the purposes of this sub-paragraph, “reasonable endeavours” means—

(a)undertaking consultation with NGC on detailed design of the carbon capture and compression plant, and all works associated with or ancillary to the carbon capture and compression plant, and ensuring the plans as submitted for approval under the requirements do not unreasonably impede or interfere with the construction of the NGC Pipeline Network having regard to such information as NGC notifies to the undertaker;

(b)having regard to the proposed programme of works for the NGC Pipeline Network as may be made available to the undertaker by NGC and facilitating a co-ordinated approach to the programme, land assembly, and the carrying out of the carbon capture and compression plant and the NGC Pipeline Network;

(c)providing a point of contact for continuing liaison and co-ordination throughout the construction and operation of the authorised development; and

(d)keeping NGC informed on the programme of works for the authorised development.

Commencement Information

I76Sch. 10 para. 76 in force at 29.12.2022, see art. 1

Carbon dioxide export connections worksE+W+S

77.  The undertaker must not except with the agreement of NGC carry out Work No.7B, or any part of it.

Commencement Information

I77Sch. 10 para. 77 in force at 29.12.2022, see art. 1

78.  Without limiting any other provision of this Order, where NGC proceeds to carry out Work No.7B or any part of it, the undertaker must use its reasonable endeavours to facilitate the programming, execution, commissioning and future operation and maintenance of those works in a safe, efficient and economic manner alongside any other part of the authorised development.

Commencement Information

I78Sch. 10 para. 78 in force at 29.12.2022, see art. 1

79.—(1) Before beginning to construct any carbon dioxide export connection work, or any part of it, the undertaker must submit to NGC plans of the relevant carbon dioxide export connection work (or part of it) and such further particulars available to it as NGC may request within 28 days of receipt of the plans reasonably requested.

(2) Any carbon dioxide export connection work must not be constructed except in accordance with such plans as may be approved in writing by NGC.

Commencement Information

I79Sch. 10 para. 79 in force at 29.12.2022, see art. 1

80.—(1) Any approval of NGC required under this Schedule—

(a)must not be unreasonably withheld or delayed;

(b)in the case of a refusal must be accompanied by a statement of grounds of refusal; and

(c)may be given subject to such reasonable requirements as NGC may have in connection with the safe, economic and efficient construction, commissioning, operation, maintenance and future decommissioning of the NGC Pipeline Network or otherwise for the protection of NGC apparatus,

provided always that in relation to a refusal under sub-paragraph (b) or any requirements requested pursuant to sub-paragraph (c) the undertaker shall be permitted to refer such matters to dispute resolution pursuant to paragraph 92.

(2) NGC must employ reasonable endeavours to respond to the submission of any plans within a period of 56 days from the date of submission of the plans. If NGC require further particulars, such particulars must be requested by NGC no later than 21 days from the submission of plans and thereafter NGC must employ reasonable endeavours to respond to the submission within 56 days from receipt of the further particulars.

Commencement Information

I80Sch. 10 para. 80 in force at 29.12.2022, see art. 1

81.—(1) The undertaker must give to NGC not less than 14 days’ notice in writing of its intention to commence construction of any carbon dioxide export connection work and notice in writing of its completion not later than 7 days after the date on which it is completed and NGC will be entitled by its officer to watch and inspect the construction of such works.

(2) If any part of a carbon dioxide export connection work is constructed otherwise than in accordance with paragraph 79(2) above NGC may by notice in writing identify the extent to which the carbon dioxide export connection works does not comply with the approved details and request the undertaker at the undertaker’s own expense carry out remedial works so as to comply with the requirements of paragraph 79(2) of this Part of this Schedule or such alternative works as may be agreed with NGC or as otherwise may be agreed between the parties.

(3) Subject to sub-paragraph (4), if within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (2) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, NGC may execute the works specified in the notice and any reasonable expenditure incurred by NGC in so doing will be recoverable from the undertaker.

(4) In the event of any dispute as to whether sub-paragraph (2) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, NGC will not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (3) until the dispute has been finally determined in accordance with paragraph 92.

Commencement Information

I81Sch. 10 para. 81 in force at 29.12.2022, see art. 1

SECTION BE+W+S

On street apparatusE+W+S

82.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and NGC are regulated by the provisions of Part 3 of the 1991 Act.

Commencement Information

I82Sch. 10 para. 82 in force at 29.12.2022, see art. 1

Acquisition of landE+W+S

83.  Regardless of any provision in this Order or anything shown on the land plans, the undertaker must not acquire or extinguish any NGC rights in relation to NGC apparatus, otherwise than by agreement.

Commencement Information

I83Sch. 10 para. 83 in force at 29.12.2022, see art. 1

Protective works to buildingsE+W+S

84.  The undertaker, in the case of the powers conferred by article 34 (protective works to buildings), must exercise those powers so as not to obstruct or render less convenient the access to any NGC apparatus or any NGC Pipeline Network site.

Commencement Information

I84Sch. 10 para. 84 in force at 29.12.2022, see art. 1

Removal of NGC apparatusE+W+S

85.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any NGC apparatus is placed or requires that any NGC apparatus is relocated or diverted, that NGC apparatus must not be removed under this Part of this Schedule, and any right of NGC to maintain that NGC apparatus in that land must not be extinguished, until alternative apparatus has been constructed and is in operation to the reasonable satisfaction of NGC in accordance with sub-paragraphs (2) to (4).

(2) If for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any NGC apparatus placed in that land, the undertaker must give to NGC 28 days’ written notice of that requirement, together with a plan of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order NGC reasonably needs to remove any NGC apparatus) the undertaker must, subject to sub-paragraph (3), afford to NGC the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between NGC and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration).

(4) NGC must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44, and after the grant to NGC of any such facilities and rights as are referred to in sub-paragraphs (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any NGC apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Commencement Information

I85Sch. 10 para. 85 in force at 29.12.2022, see art. 1

Facilities and rights for alternative apparatusE+W+S

86.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to NGC facilities and rights for the construction, commissioning, maintenance and operation of alternative apparatus in substitution for NGC apparatus to be removed, those facilities and rights are to be granted upon such terms and conditions as may be agreed between the undertaker and NGC or in default of agreement settled by arbitration in accordance with article 44 (arbitration).

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to NGC than the facilities and rights enjoyed by it in respect of the NGC apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to NGC as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I86Sch. 10 para. 86 in force at 29.12.2022, see art. 1

Specified works plan approvalE+W+S

87.—(1) Before beginning to construct any specified work, the undertaker must submit to NGC plans of the specified work and such further particulars available to it as NGC may within 28 days of receipt of the plans reasonably request.

(2) Any such specified work must not be constructed except in accordance with such plans as may be approved in writing by NGC, or determined under paragraph 92.

(3) Any approval of NGC required under this paragraph—

(a)must not be unreasonably withheld or delayed;

(b)in the case of a refusal must be accompanied by a statement of grounds of refusal; and

(c)may be given subject to such reasonable requirements as NGC may have in connection with the safe, economic and efficient construction, commissioning, operation, maintenance and future decommissioning of the NGC Pipeline Network or otherwise for the protection of NGC apparatus.

(4) NGC must use its reasonable endeavours to respond to the submission of any plans within a period of 56 days from the date of submission of the plans or receipt of further particulars if such particulars have been requested by NGC for approval.

(5) Without limiting sub-paragraph (3), the requirements which NGC may have under that paragraph include conditions requiring the undertaker, at its own expense, to construct such protective works, whether temporary or permanent, before or during the construction of the specified works or other works as are reasonably considered by NGC to be necessary to safeguard the safe, economic and efficient construction, commissioning, operation, maintenance and future decommissioning of the NGC Pipeline Network or otherwise for the protection of NGC apparatus.

Commencement Information

I87Sch. 10 para. 87 in force at 29.12.2022, see art. 1

88.—(1) Subject to sub-paragraph (5), any specified work, and all protective or additional works required by NGC under sub-paragraph 87(5), must be constructed—

(a)without unreasonable delay in accordance with the plans approved under this Part of this Schedule; and

(b)to the reasonable satisfaction of NGC,

and NGC will be entitled by its officer to watch and inspect the construction of such works.

(2) The undertaker must give to NGC not less than 14 days’ notice in writing of its intention to commence construction of any specified work and notice in writing of its completion not later than 7 days after the date on which it is completed.

(3) If any part of a specified work or any protective or additional work required by NGC is constructed otherwise than in accordance with the requirements of this Part of this Schedule, NGC may by notice in writing require the undertaker at the undertaker’s own expense to comply with the requirements of this Part of this Schedule or (if the undertaker so elects and NGC in writing consents, such consent not to be unreasonably withheld or delayed) to remove, alter or pull down the work and, where removal is required, to restore the site to its former condition to such extent and within such limits as NGC reasonably requires.

(4) Subject to sub-paragraph (5), if within a reasonable period, being not less than 28 days beginning with the date when a notice under sub-paragraph (3) is served upon the undertaker, the undertaker has failed to begin taking steps to comply with the requirements of the notice and has not subsequently made reasonably expeditious progress towards their implementation, NGC may execute the works specified in the notice and any reasonable expenditure incurred by NGC in so doing will be recoverable from the undertaker.

(5) In the event of any dispute as to whether sub-paragraph (4) is properly applicable to any work in respect of which notice has been served under that sub-paragraph, or as to the reasonableness of any requirement of such a notice, NGC will not, except in the case of an emergency, exercise the powers conferred by sub-paragraph (4) until the dispute has been finally determined in accordance with paragraph 92.

Commencement Information

I88Sch. 10 para. 88 in force at 29.12.2022, see art. 1

Expenses and costsE+W+S

89.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to NGC all expenses reasonably and properly incurred by NGC in, or in connection with, the inspection, removal, alteration or protection of any NGC apparatus or the construction of the carbon dioxide export connection works or any alternative apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 86.

(2) Without prejudice to the generality of sub-paragraph (1), the undertaker must repay to NCG all reasonable costs, charges and expenses which NGC may reasonable incur—

(a)in the examination or approval of plans under this Part of this Schedule;

(b)in the inspection of the construction of the carbon dioxide export connection works, the specified works or any protective or additional works required by NGC under this Part of this Schedule and;

(c)in carrying out any of the surveys or tests by NGC which are reasonably required in connection with the construction of the carbon dioxide export connections work or any specified works.

(3) This paragraph shall be subject to—

(a)any contrary provisions made in a charging methodology approved by the Office of Gas and Electricity Markets from time to time (or successor body); or

(b)such alternative cost apportionment as may be agreed between NGC and the undertaker in a connection agreement (and for the avoidance of doubt the provisions of paragraphs 89(1) and 89(2) are not intended to set a precedent for such cost apportionment terms as may be agreed between the parties) whereupon the relevant parts of paragraph 89 shall be of no further effect insofar as such an agreement remains in force.

Commencement Information

I89Sch. 10 para. 89 in force at 29.12.2022, see art. 1

IndemnityE+W+S

90.—(1) Subject to sub-paragraphs (5) to (6), if by reason or in consequence of the construction of the authorised development or in consequence of the construction, use or maintenance of any of the authorised works or of any subsidence resulting from any of those works, or the failure of any such work, any damage is caused to any NGC apparatus or alternative apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works), or other property belonging to NGC, or there is any interruption in the supply of the service provided by NGC, or the efficiency of that supply is impaired in each case directly or in consequence of such construction works, the undertaker must—

(a)bear and pay the cost reasonably incurred by NGC in making good such damage or restoring the supply or making good any impairment of the efficiency of that supply; and

(b)make reasonable compensation to NGC for any other expenses, loss, damages, liabilities, claims, demands, penalty or costs incurred by it, by reason or in consequence of, any such damage or interruption.

(2) NGC must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph 90 applies where it is within NGC’s reasonable ability and control to do so and which expressly excludes any obligation to mitigate liability arising from third parties which is outside of NGC’s control and if reasonably requested to do so by the undertaker, NGC must provide an explanation of how the claim has been minimised, where relevant or details to substantiate any cost or compensation claimed pursuant to sub-paragraph (1).

(3) If as a result of the authorised development NGC’s access to the NGC Pipeline Network, or to any NGC Pipeline Network site, is materially obstructed, the undertaker must provide such alternative means of access that will allow NGC to maintain NGC apparatus or use NGC apparatus no less efficiently than was possible before the obstruction and such alternative means of access must be provided within 24 hours of the undertaker becoming aware of such obstruction.

(4) The fact that any act or thing may have been done by NGC on behalf of the undertaker or in accordance with a plan approved by NGC or in accordance with any requirement of NGC or under its supervision does not, subject to sub-paragraph (5), excuse the undertaker from liability under the provisions of sub-paragraph (1).

(5) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of NGC, its officers, servants, contractors or agents.

(6) NGC must give the undertaker reasonable notice of any third party claim or demand and no settlement or compromise of the claim or demand is to be made without the consent of the undertaker who, if withholding such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(7) This paragraph shall be subject to any alternative indemnity provisions as may be agreed between NGC and the undertaker in a connection agreement or operating agreement (and for the avoidance of doubt the provisions of paragraph 90 are not intended to set a precedent for such indemnity terms as may be agreed between the parties) whereupon the relevant parts of this paragraph shall be of no further effect.

Commencement Information

I90Sch. 10 para. 90 in force at 29.12.2022, see art. 1

Co-operationE+W+S

91.  Where in consequence of the proposed construction of any of the authorised development, the undertaker or NGC requires the removal of NGC apparatus under paragraph 85 or NGC specifies requirements for the protection or alteration of apparatus under paragraph 85 the undertaker must use reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the efficient and economic execution of the authorised development and the NGC Pipeline Network.

Commencement Information

I91Sch. 10 para. 91 in force at 29.12.2022, see art. 1

DisputesE+W+S

92.  Any dispute arising between the undertaker and NGC under this part of this Schedule will, if the parties agree, be determined by arbitration under article 44 (arbitration), but will otherwise be determined by the Secretary of State on a reference to it by the undertaker or NGC, after notice in writing by one to the other.

Commencement Information

I92Sch. 10 para. 92 in force at 29.12.2022, see art. 1

PART 7E+W+SFOR THE PROTECTION OF NORTHERN POWERGRID

93.  For the protection of Northern Powergrid the following provisions have effect, unless otherwise agreed in writing between the undertaker and Northern Powergrid.E+W+S

Commencement Information

I93Sch. 10 para. 93 in force at 29.12.2022, see art. 1

94.  In this Part of this Schedule—E+W+S

1991 Act” means the New Roads and Street Works Act 1991(11);

alternative apparatus” means alternative apparatus adequate to enable Northern Powergrid to fulfil its statutory functions in a manner not less efficient than previously;

apparatus” means electric lines or electrical plant (as defined in the Electricity Act 1989), belonging to or maintained by Northern Powergrid and includes any structure in which apparatus is or is to be lodged or which gives or will give access to apparatus;

authorised works” means so much of the works authorised by this Order which affect existing Northern Powergrid’s apparatus within the Order limits;

functions” includes powers and duties;

“in”, in a context referring to apparatus or alternative apparatus in land, includes a reference to apparatus or alternative apparatus under, over or upon land;

plan” includes all designs, drawings, specifications, method statements, soil reports, programmes, calculations, risk assessments and other documents that are reasonably necessary properly and sufficiently to describe the works to be executed and shall include measures proposed by the undertaker to ensure the grant of sufficient land or rights in land necessary to mitigate the impacts of the works on Northern Powergrid’s undertaking; and

Northern Powergrid” means Northern Powergrid (Yorkshire) PLC (Company Number 04112320) whose registered address is Lloyds Court, 78 Grey Street, Newcastle upon Tyne NE1 6AF being a licence holder within the meaning of Part 1 (electricity supply) of the Electricity Act 1989 for the area of the authorised development and in relation to any apparatus belonging to it or maintained by it.

Commencement Information

I94Sch. 10 para. 94 in force at 29.12.2022, see art. 1

95.  This Part of this Schedule does not apply to apparatus in respect of which the relations between the undertaker and Northern Powergrid are regulated by the provisions of Part 3 (street works in England and Wales) of the 1991 Act.E+W+S

Commencement Information

I95Sch. 10 para. 95 in force at 29.12.2022, see art. 1

96.  Regardless of any provision in this Order or anything shown on the land plans, or contained in the book of reference, the undertaker shall not acquire any apparatus, or override any easement or other interest of Northern Powergrid otherwise than by agreement with Northern Powergrid, such agreement not to be unreasonably withheld or delayed.E+W+S

Commencement Information

I96Sch. 10 para. 96 in force at 29.12.2022, see art. 1

97.—(1) If, in the exercise of the powers conferred by this Order, the undertaker acquires any interest in any land in which any apparatus is placed or over which access to any apparatus is enjoyed or requires that Northern Powergrid’s apparatus is relocated or diverted, that apparatus must not be removed under this Part of this Schedule, and any right of Northern Powergrid to maintain that apparatus in that land and to gain access to it must not be extinguished, until alternative apparatus has been constructed and is in operation, and access to it has been provided pursuant to a completed easement for a tenure no less than exists to the apparatus being relocated or diverted, all to the reasonable satisfaction of Northern Powergrid in accordance with sub-paragraphs (2) to (7).E+W+S

(2) If, for the purpose of executing any works in, on or under any land purchased, held, appropriated or used under this Order, the undertaker requires the removal of any apparatus placed in that land, the undertaker must give to Northern Powergrid 42 days’ advance written notice of that requirement, together with a plan and section of the work proposed, and of the proposed position of the alternative apparatus to be provided or constructed and in that case (or if in consequence of the exercise of any of the powers conferred by this Order Northern Powergrid reasonably needs to remove any of its apparatus) the undertaker must, subject to sub-paragraph (3), afford to Northern Powergrid the necessary facilities and rights for the construction of alternative apparatus in other land of the undertaker and subsequently for the maintenance of that apparatus.

(3) If alternative apparatus or any part of such apparatus is to be constructed elsewhere than in other land of the undertaker, or the undertaker is unable to afford such facilities and rights as are mentioned in sub-paragraph (2), in the land in which the alternative apparatus or part of such apparatus is to be constructed, Northern Powergrid must, on receipt of a written notice to that effect from the undertaker, as soon as reasonably practicable and at the cost of the undertaker (subject to prior approval by the undertaker of its estimate of costs of doing so) use reasonable endeavours to obtain the necessary facilities and rights in the land in which the alternative apparatus is to be constructed save that this obligation shall not extend to the requirement for Northern Powergrid to use its compulsory purchase powers to this end unless:

(a)the undertaker has first used reasonable endeavours to acquire the relevant land, rights and/or interests and provided reasonable evidence of the same to Northern Powergrid in accordance with the measures set out in the plan (in default of agreement, the reasonableness of any such measures to be determined through arbitration under article 44 (arbitration)); and

(b)the undertaker and Northern Powergrid agree (or in default of agreement, it is determined through arbitration under article 44 (arbitration)) that the promotion of compulsory purchase powers by the undertaker would be significantly more onerous than the exercise of Northern Powergrid’s own compulsory powers.

(4) Any alternative apparatus to be constructed in land of the undertaker under this Part of this Schedule must be constructed in such manner and in such line or situation as may be agreed between Northern Powergrid and the undertaker or in default of agreement settled by arbitration in accordance with article 44 (arbitration).

(5) Northern Powergrid must, after the alternative apparatus to be provided or constructed has been agreed or settled by arbitration in accordance with article 44 (arbitration), and after the grant to Northern Powergrid of any such facilities and rights as are referred to in sub-paragraph (2) or (3), proceed without unnecessary delay to construct and bring into operation the alternative apparatus and subsequently to remove any apparatus required by the undertaker to be removed under the provisions of this Part of this Schedule.

Commencement Information

I97Sch. 10 para. 97 in force at 29.12.2022, see art. 1

98.—(1) Where, in accordance with the provisions of this Part of this Schedule, the undertaker affords to Northern Powergrid facilities and rights for the construction and maintenance in land of the undertaker of alternative apparatus in substitution for apparatus to be removed, those facilities and rights must be granted upon such terms and conditions as may be agreed between the undertaker and Northern Powergrid or in default of agreement settled by arbitration in accordance with article 44 (arbitration).E+W+S

(2) If the facilities and rights to be afforded by the undertaker in respect of any alternative apparatus, and the terms and conditions subject to which those facilities and rights are to be granted, are in the opinion of the arbitrator less favourable on the whole to Northern Powergrid than the facilities and rights enjoyed by it in respect of the apparatus to be removed and the terms and conditions to which those facilities and rights are subject, the arbitrator must make such provision for the payment of compensation by the undertaker to Northern Powergrid as appears to the arbitrator to be reasonable having regard to all the circumstances of the particular case.

Commencement Information

I98Sch. 10 para. 98 in force at 29.12.2022, see art. 1

99.—(1) Not less than 48 days before starting the execution of any works in, on or under any land purchased, held, appropriated or used under this Order that are near to (including conducting any activities whether intentionally or unintentionally, through for example ground or machinery collapse, which may affect Northern Powergrid’s apparatus or encroach on safety distances to live equipment) or will or may affect, any apparatus the removal of which has not been required by the undertaker under paragraph 97(2), the undertaker must submit to Northern Powergrid a plan, section and description of the works to be executed.E+W+S

(2) Those works must be executed only in accordance with the plan, section and description submitted under sub-paragraph (1) and in accordance with such reasonable requirements as may be made in accordance with sub-paragraph (3) by Northern Powergrid for the alteration or otherwise for the protection of the apparatus, or for securing access to it, and Northern Powergrid is entitled to watch and inspect the execution of those works.

(3) Any requirements made by Northern Powergrid under sub-paragraph (2) must be made within a period of 42 days beginning with the date on which a plan, section and description under sub-paragraph (1) are submitted to it.

(4) If Northern Powergrid in accordance with sub-paragraph (3) and in consequence of the works proposed by the undertaker, reasonably requires the removal of any apparatus and gives written notice to the undertaker of that requirement, paragraphs 93 to 98 apply as if the removal of the apparatus had been required by the undertaker under paragraph (2).

(5) Nothing in this paragraph precludes the undertaker from submitting at any time or from time to time, but in no case less than 35 days before commencing the execution of any works, a new plan, section and description instead of the plan, section and description previously submitted, and having done so the provisions of this paragraph apply to and in respect of the new plan, section and description.

(6) The undertaker is not required to comply with sub-paragraph (1) in a case of emergency but in that case it must give to Northern Powergrid notice as soon as is reasonably practicable and a plan, section and description of those works as soon as reasonably practicable subsequently and must comply with sub-paragraph (2) in so far as is reasonably practicable in the circumstances.

Commencement Information

I99Sch. 10 para. 99 in force at 29.12.2022, see art. 1

100.—(1) Subject to the following provisions of this paragraph, the undertaker must repay to Northern Powergrid all reasonable and proper expenses costs or charges incurred by Northern Powergrid—E+W+S

(a)in, or in connection with, the inspection, removal, alteration or protection of any apparatus or the construction of any new apparatus which may be required in consequence of the execution of any such works as are referred to in paragraph 97(2) including without limitation:

(i)any costs reasonably incurred or compensation properly paid in connection with the acquisition of rights or the exercise of statutory powers for such apparatus including without limitation in the event that it is agreed Northern Powergrid elects to use compulsory purchase powers to acquire any necessary rights under paragraph 97(3) all costs reasonably incurred as a result of such action;

(ii)in connection with the cost of the carrying out of any diversion work or the provision of any alternative apparatus;

(iii)the cutting off of any apparatus from any other apparatus or the making safe of redundant apparatus;

(iv)the approval of plans;

(v)the carrying out of protective works, plus a capitalised sum to cover the cost of maintaining and renewing permanent protective works;

(vi)the survey of any land, apparatus or works, the inspection and monitoring of works or the installation or removal of any temporary works reasonably necessary in consequence of the execution of any such works referred to in this Part of this Schedule); and

(b)in assessing and preparing a design for its apparatus to address and accommodate the proposals of the undertaker whether or not the undertaker proceeds to implement those proposals or alternative or none at all,

provided that if it so prefers Northern Powergrid may abandon apparatus that the undertaker does not seek to remove in accordance with paragraph 97(1) having first decommissioned such apparatus.

(2) There is to be deducted from any sum payable under sub-paragraph (1) the value of any apparatus removed under the provisions of this Part of this Schedule, that value being calculated after removal and for the avoidance of doubt, if the apparatus removed under the provisions of this Part of this Schedule has nil value, no sum will be deducted from the amount payable under sub-paragraph (1) if in accordance with the provisions of this Part of this Schedule—

(a)apparatus of better type, of greater capacity or of greater dimensions is placed in substitution for existing apparatus of worse type, of smaller capacity or of smaller dimensions; or

(b)apparatus (whether existing apparatus or apparatus substituted for existing apparatus) is placed at a depth greater than the depth at which the existing apparatus was

and the placing of apparatus of that type or capacity or of those dimensions or the placing of apparatus at that depth, as the case may be, is not agreed by the undertaker or, in default of agreement, is not determined by arbitration in accordance with article 44 (arbitration) to be necessary, then, if such placing involves cost in the construction of works under this Part of this Schedule exceeding that which would have been involved if the apparatus placed had been of the existing type, capacity or dimensions, or at the existing depth, as the case may be, the amount which apart from this sub-paragraph would be payable to Northern Powergrid by virtue of sub-paragraph (1) is to be reduced by the amount of that excess save where it is not possible on account of project time limits and/or supply issues to obtain the existing type of operations, capacity, dimensions or place at the existing depth in which case full costs shall be borne by the undertaker.

(3) For the purposes of sub-paragraph (2)—

(a)an extension of apparatus to a length greater than the length of existing apparatus is not to be treated as a placing of apparatus of greater dimensions than those of the existing apparatus where such extension is required in consequence of the execution of any such works as are referred to in paragraph 97(2); and

(b)where the provision of a joint in a cable is agreed, or is determined to be necessary, the consequential provision of a jointing chamber or of a manhole is to be treated as if it also had been agreed or had been so determined.

Commencement Information

I100Sch. 10 para. 100 in force at 29.12.2022, see art. 1

101.—(1) Subject to sub-paragraphs (2) and (3), if by reason or in consequence of the construction of any of the works referred to in in paragraph 97(2), or in consequence of the, maintenance or failure of any of the authorised works by or on behalf of the undertaker or in consequence of any act or default of the undertaker (or any person employed or authorised by it) in the course of carrying out such works, including without limitation works carried out by the undertaker under this Schedule or any subsidence resulting from any of these works any damage is caused to any apparatus (other than apparatus the repair of which is not reasonably necessary in view of its intended removal for the purposes of those works) or property of Northern Powergrid, or there is any interruption in any service provided by Northern Powergrid, or Northern Powergrid becomes liable to pay any amount to a third party as a consequence of any default, negligence or omission by the undertaker in carrying out the authorised works, the undertaker must—E+W+S

(a)bear and pay the cost reasonably incurred by Northern Powergrid in making good such damage or restoring the supply; and

(b)indemnify Northern Powergrid for any other expenses, loss, damages, penalty, proceedings, claims or costs incurred by or recovered from Northern Powergrid,

by reason or in consequence of any such damage or interruption or Northern Powergrid becoming liable to any third party.

(2) Nothing in sub-paragraph (1) imposes any liability on the undertaker with respect to any damage or interruption to the extent that it is attributable to the act, neglect or default of Northern Powergrid, its officers, employees, servants, contractors or agents.

(3) Northern Powergrid must give the undertaker reasonable notice of any such claim or demand and no settlement or compromise is to be made without the consent of the undertaker which, if it withholds such consent, has the sole conduct of any settlement or compromise or of any proceedings necessary to resist the claim or demand.

(4) Northern Powergrid must use its reasonable endeavours to mitigate in whole or in part and to minimise any costs, expenses, loss, demands, and penalties to which the indemnity under this paragraph 101 applies. If requested to do so by the undertaker, Northern Powergrid must provide an explanation of how the claim has been minimised or details to substantiate any cost or compensation claimed pursuant to sub-paragraph (1). The undertaker shall only be liable under this paragraph 101 for claims reasonably incurred by Northern Powergrid.

Commencement Information

I101Sch. 10 para. 101 in force at 29.12.2022, see art. 1

102.  Nothing in this Part of this Schedule affects the provisions of any enactment or agreement regulating the relations between the undertaker and Northern Powergrid in respect of any apparatus laid or erected in land belonging to the undertaker on the date on which this Order is made.E+W+S

Commencement Information

I102Sch. 10 para. 102 in force at 29.12.2022, see art. 1

103.  Where in consequence of the proposed construction of any of the authorised development, the undertaker or Northern Powergrid requires the removal of apparatus under paragraph 97 or otherwise or Northern Powergrid makes requirements for the protection or alteration of apparatus under paragraph 99, the undertaker shall use its reasonable endeavours to co-ordinate the execution of the works in the interests of safety and the need to ensure the safe and efficient operation of Northern Powergrid’s undertaking taking into account the undertaker’s desire for the efficient and economic execution of the authorised development and the undertaker and Northern Powergrid shall use reasonable endeavours to co-operate with each other for those purposes.E+W+S

Commencement Information

I103Sch. 10 para. 103 in force at 29.12.2022, see art. 1

104.  If in consequence of an agreement reached in accordance with paragraph 96 or the powers granted under this Order the access to any apparatus or alternative apparatus is materially obstructed, the undertaker shall provide such alternative means of access to such apparatus or alternative apparatus as will enable Northern Powergrid to maintain or use the said apparatus no less effectively than was possible before such obstruction.E+W+S

Commencement Information

I104Sch. 10 para. 104 in force at 29.12.2022, see art. 1

105.  The plans submitted to Northern Powergrid by the undertaker pursuant to this Part of this Schedule must be sent to Northern Powergrid at property@northernpowergrid.com or such other address as Northern Powergrid may from time to time appoint instead for that purpose and notify to the undertaker in writingE+W+S

Commencement Information

I105Sch. 10 para. 105 in force at 29.12.2022, see art. 1

(3)

1968 c. 73. Sections 105(1) and (2) were amended by paragraph 39 of Schedule 2 to S.I. 2012/1659.

(6)

1986 c. 44. A new section 7 was substituted by section 5 of the Gas Act 1995 (c. 45) and was further amended by the Utilities Act 2000 (c. 27).

(7)

2003 c. 21 as amended by the Digital Economy Act 2017 (c. 30).

(8)

Added by Schedule 1 of the Digital Economy Act 2017 (c. 30).

Back to top

Options/Help

You have chosen to open The Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open The Whole Instrument as a PDF

The Whole Instrument you have selected contains over 200 provisions and might take some time to download.

Would you like to continue?

You have chosen to open the Whole Instrument

The Whole Instrument you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?

You have chosen to open Schedules only

The Schedules you have selected contains over 200 provisions and might take some time to download. You may also experience some issues with your browser, such as an alert box that a script is taking a long time to run.

Would you like to continue?